Loading...
HomeMy WebLinkAboutContract 35401/ �, :'��� / )%—�i � �'�. � '.' '.. : t �i__ t e 6 7 CITY OF FORT WORTH, TEXAS '�'� �'' " � ' � �' ° �- �-�- - -�� � ���� STANDARD AGREEMENT FOR ENGINEERING SERVICES This AGREEMENT is between the City of Fort Worth (the "CITY"), and LOPEZGARCIA GROUP, (the "ENGINEER"), for a PROJECT generally described as the design of four box culverts at Sycamore Creek Tributary and East Rosedale. Article I Scope of Services A. The Scope of Services is set forth in Attachment A. Article II Compensation A. The ENGINEER's compensation is set forth in Attachment B. Article III Terms of Payment Payments to the ENGINEER will be made as follows: A. Invoice and Payment (1) The Engineer shall provide the City sufficient documentation to reasonably substantiate the invoices. (2) The ENGINEER will issue monthly invoices for all work performed under this AGREEMENT. Invoices are due and payable within 30 days of receipt. (3) Upon completion of services enumerated in Article I, the final payment of any balance will be due within 30 days of receipt of the final invoice. (4) In the event of a disputed or contested billing, only that portion so contested will be withheld from payment, and the undisputed portion will be paid. The CITY will exercise reasonableness in contesting any bill or portion thereof. No interest will accrue on any contested portion of the billing until mutually resolved. (5) If the CITY fails to make payment in full to ENGINEER for billings contested in good faith within 60 days of the amount due, the ENGINEER may, after giving 7 days' written notice to CITY, suspend services under this AGREEMENT until paid in full, including interest. In the event of suspension of services, the ENGINEER shall have no liability to CITY for ENGINEERING CONTRACT (REV 4/14/05) • - � ' Page 1 of 15 _; J"� ., ..�J �;ilc�;�� r�:i� �i;t�: ��71'i ��;, a � ��!- :: iF, 5 J:i ., � ; ?if j�r�`��J ��rV� � �"J��! �,,;,. J if� U�. `�. � . ,�, � , delays or damages caused the CITY because of such suspension of services. Article IV Obligations of the Engineer Amendments to Article IV, if any, are included in Attachment C. A. General The ENGINEER will serve as the CITY's professional engineering representative under this Agreement, providing professional engineering consultation and advice and furnishing customary services incidental thereto. B. Standard of Care The standard of care applicable to the ENGINEER's services will be the degree of skill and diligence normally employed in the State of Texas by professional engineers or consultants performing the same or similar services at the time such services are performed. C. Subsurface Investigations (1) The ENGINEER shall advise the CITY with regard to the necessity for subcontract work such as special surveys, tests, test borings, or other subsurface investigations in connection with design and engineering work to be performed hereunder. The ENGINEER shall also advise the CITY concerning the results of same. Such surveys, tests, and investigations shall be furnished by the CITY, unless otherwise specified in Attachment A. (2) In soils, foundation, groundwater, and other subsurface investigations, the actual characteristics may vary significantly between successive test points and sample intervals and at locations other than where observations, exploration, and investigations have been made. Because of the inherent uncertainties in subsurface evaluations, changed or unanticipated underground conditions may occur that could affect the total PROJECT cost and/or execution. These conditions and cost/execution effects are not the responsibility of the ENGINEER. D. Preparation of Engineering Drawings The ENGINEER will provide to the CITY the original drawings of all plans in ink on reproducible plastic film sheets, or as otherwise approved by CITY, which shall become the property of the CITY. CITY may use such drawings in any manner it desires; provided, however, that the ENGINEER shall not be liable for the use of such drawings for any project other than the PROJECT described herein. ENGINEERING CONTRACT (REV 4/14/05) Page 2 of 15 E. Engineer's Personnel at Construction Site (1) The presence or duties of the ENGINEER's personnel at a construction site, whether as on-site representatives or otherwise, do not make the ENGINEER or its personnel in any way responsible for those duties that belong to the CITY and/or the CITY's construction contractors or other entities, and do not relieve the construction contractors or any other entity of their obligations, duties, and responsibilities, including, but not limited to, all construction methods, means, techniques, sequences, and procedures necessary for coordinating and completing all portions of the construction work in accordance with the Contract Documents and any health or safety precautions required by such construction work. The ENGINEER and its personnel have no authority to exercise any control over any construction contractor or other entity or their employees in connection with their work or any health or safety precautions. (2) Except to the extent of specific site visits expressly detailed and set forth in Attachment A, the ENGINEER or its personnel shall have no obligation or responsibility to visit the construction site to become familiar with the progress or quality of the completed work on the PROJECT or to determine, in general, if the work on the PROJECT is being perFormed in a manner indicating that the PROJECT, when completed, will be in accordance with the Contract Documents, nor shall anything in the Contract Documents or the agreement between CITY and ENGINEER be construed as requiring ENGINEER to make exhaustive or continuous on-site inspections to discover latent defects in the work or otherwise check the quality or quantity of the work on the PROJECT. If, for any reason, the ENGINEER should make an on-site observation(s), on the basis of such on-site observations, if any, the ENGINEER shall endeavor to keep the CITY informed of any deviation from the Contract Documents coming to the actual notice of ENGINEER regarding the PROJECT. (3) When professional certification of perFormance or characteristics of materials, systems or equipment is reasonably required to perform the services set forth in the Scope of Services, the ENGINEER shall be entitled to rely upon such certification to establish materials, systems or equipment and performance criteria to be required in the Contract Documents. F. Opinions of Probable Cost, Financial Considerations, and Schedules (1) The ENGINEER shall provide opinions of probable costs based on the current available information at the time of preparation, in accordance with Attachment A. (2) In providing opinions of cost, financial analyses, economic feasibility projections, and schedules for the PROJECT, the ENGINEER has no ENGINEERING CONTRACT (REV 4/14/05) Page 3 of 15 control over cost or price of labor and materials; unknown or latent conditions of existing equipment or structures that may affect operation or maintenance costs; competitive bidding procedures and market conditions; time or quality of performance by third parties; quality, type, management, or direction of operating personnel; and other economic and operational factors that may materially affect the ultimate PROJECT cost or schedule. Therefore, the ENGINEER makes no warranty that the CITY's actual PROJECT costs, financial aspects, economic feasibility, or schedules will not vary from the ENGINEER's opinions, analyses, projections, or estimates. G. Construction Progress Payments Recommendations by the ENGINEER to the CITY for periodic construction progress payments to the construction contractor will be based on the ENGINEER's knowledge, information, and belief from selective sampling and observation that the work has progressed to the point indicated. Such recommendations do not represent that continuous or detailed examinations have been made by the ENGINEER to ascertain that the construction contractor has completed the work in exact accordance with the Contract Documents; that the final work will be acceptable in all respects; that the ENGINEER has made an examination to ascertain how or for what purpose the construction contractor has used the moneys paid; that title to any of the work, materials, or equipment has passed to the CITY free and clear of liens, claims, security interests, or encumbrances; or that there are not other matters at issue between the CITY and the construction contractor that affect the amount that should be paid. H. Record Drawings Record drawings, if required, will be prepared, in part, on the basis of information compiled and furnished by others, and may not always represent the exact location, type of various components, or exact manner in which the PROJECT was finally constructed. The ENGINEER is not responsible for any errors or omissions in the information from others that are incorporated into the record drawings. I. Minority and Woman Business Enterprise (M/WBE) participation In accord with City of Fort Worth Ordinance No. 15530, the City has goals for the participation of minority business enterprises and woman business enterprises in City contracts. Engineer acknowledges the M/WBE goal established for this contract and its commitment to meet that goal. Any misrepresentation of facts (other than a negligent misrepresentation) and/or the commission of fraud by the Engineer may result in the termination of this agreement and debarment from participating in City contracts for a period of time of not less than three (3) years. ENGINEERING CONTRACT (REV 4/14/05) Page 4 of 15 J. Right to Audit (1) ENGINEER agrees that the CITY shall, until the expiration of three (3) years after final payment under this contract, have access to and the right to examine and photocopy any directly pertinent books, documents, papers and records of the ENGINEER involving transactions relating to this contract. ENGINEER agrees that the CITY shall have access during normal working hours to all necessary ENGINEER facilities and shall be provided adequate and appropriate work space in order to conduct audits in compliance with the provisions of this section. The CITY shall give ENGINEER reasonable advance notice of intended audits. (2) ENGINEER further agrees to include in all its subconsultant agreements hereunder a provision to the effect that the subconsultant agrees that the CITY shall, until the expiration of three (3) years after final payment under the subcontract, have access to and the right to examine and photocopy any directly pertinent books, documents, papers and records of such subconsultant, involving transactions to the subcontract, and further, that the CITY shall have access during normal working hours to all subconsultant facilities, and shall be provided adequate and appropriate work space, in order to conduct audits in compliance with the provisions of this article together with subsection (3)hereof. CITY shall give subconsultant reasonable advance notice of intended audits. (3) ENGINEER and subconsultant agree to photocopy such documents as may be requested by the CITY. The CITY agrees to reimburse ENGINEER for the cost of copies at the rate published in the Texas Administrative Code in effect as of the time copying is performed. K. ENGINEER's Insurance (1) Insurance coverage and limits: ENGINEER shall provide to the City certificate(s) of insurance documenting policies of the following coverage at minimum limits that are to be in effect prior to commencement of work on the PROJECT: Commercial General Liability $1,000,000 each occurrence $2,000,000 aggregate Automobile Liability $1,000,000 each accident on a combined single limit or $250,000 Property Damage $500,000 Bodily Injury per person per occurrence ENGINEERING CONTR,4CT (REV 4/14/05) Page 5 of 15 A commercial business policy shall provide coverage on "Any Auto", defined as autos owned, hired and non-owned when said vehicle is used in the course of the PROJECT. Worker's Compensation Coverage A: Statutory limits Coverage B: Employer's Liability $100,000 each accident $500,000 disease - policy limit $100,000 disease - each employee Professional Liability $1,000,000 each claim $2,000,000 aggregate Professional liability shall be written on a claims-made basis and shall contain a retroactive date prior to the date of the contract or the first date of services to be performed, whichever is earlier. Coverage shall be maintained for a period of 5 years following the completion of the contract. An annual certificate of insurance specifically referencing this project shall be submitted to the City for each year following completion of the contract. (2) Certificates of insurance evidencing that the ENGINEER has obtained all required insurance shall be delivered to the CITY prior to ENGINEER proceeding with the PROJECT. (a) Applicable policies shall be endorsed to name the CITY an Additional Insured thereon, as its interests may appear. The term CITY shall include its employees, officers, officials, agents, and volunteers as respects the contracted services. (b) Certificate(s) of insurance shall document that insurance coverage specified in this agreement are provided under applicable policies documented thereon. (c) Any failure on part of the CITY to request required insurance documentation shall not constitute a waiver of the insurance requirements. (d) A minimum of forty-five (45) days notice of cancellation or material change in coverage shall be provided to the CITY. A ten (10) days notice shall be acceptable in the event of non-payment of premium. Such terms shall be endorsed onto ENGINEER's insurance policies. Notice shall be ENGINEERING CONTRACT (REV 4/14/05) Page 6 of 15 sent to the respective Department Director (by name), City of Fort Worth, 1000 Throckmorton, Fort Worth, Texas 76102. (e) Insurers for all policies must be authorized to do business in the State of Texas and have a minimum rating of A: VII in the current A.M. Best Key Rating Guide or have reasonably equivalent financial strength and solvency to the satisfaction of Risk Management. (f) Deductible limits, or self-insured retentions, affecting insurance required herein shall be acceptable to the CITY in its sole discretion; and, in lieu of traditional insurance, any alternative coverage maintained through insurance pools or risk retention groups must be also approved. Dedicated financial resources or letters of credit may also be acceptable to the City. (g) Applicable policies shall each be endorsed with a waiver of subrogation in favor of the CITY as respects the PROJECT. (h) The City shall be entitled, upon its request and without incurring expense, to review the ENGINEER's insurance policies including endorsements thereto and, at the CITY's discretion, the ENGINEER may be required to provide proof of insurance premium payments. (i) The Commercial General Liability insurance policy shall have no exclusions by endorsements unless the CITY approves such exclusions. (j) For all lines of coverage underwritten on a claims-made basis, other than Professional Liability, the retroactive date shall be coincident with or prior to the date of the contractual agreement. The certificate of insurance shall state both the retroactive date and that the coverage is claims-made. (k) The CITY shall not be responsible for the direct payment of any insurance premiums required by this agreement and all insurance required in this section, with the exception of Professional Liability, shall be written on an occurrence basis. (I) Sub consultants and subcontractors to/of the ENGINEER shall be required by the ENGINEER to maintain the same or reasonably equivalent insurance coverage as required for the ENGINEER. When sub consultants/subcontractors maintain insurance coverage, ENGINEER shall provide CITY with documentation thereof on a certificate of insurance. L. Independent Consultant The ENGINEER agrees to perform all services as an independent consultant and not as a subcontractor, agent, or employee of the CITY. ENGINEERING CONTRACT (REV 4/14/05) Page 7 of 15 M. Disclosure The ENGINEER acknowledges to the CITY that it has made full disclosure in writing of any existing conflicts of interest or potential conflicts of interest, including personal financial interest, direct or indirect, in property abutting the proposed PROJECT and business relationships with abutting property cities. The ENGINEER further acknowledges that it will make disclosure in writing of any conflicts of interest that develop subsequent to the signing of this contract and prior to final payment under the contract. N. Asbestos or Hazardous Substances (1) If asbestos or hazardous substances in any form are encountered or suspected, the ENGINEER will stop its own work in the affected portions of the PROJECT to permit testing and evaluation. (2) If asbestos or other hazardous substances are suspected, the ENGINEER will, if requested, assist the CITY in obtaining the services of a qualified subcontractor to manage the remediation activities of the PROJECT. O. Permitting Authorities - Design Changes If permitting authorities require design changes so as to comply with published design criteria and/or current engineering practice standards which the ENGINEER should have been aware of at the time this Agreement was executed, the ENGINEER shall revise plans and specifications, as required, at its own cost and expense. However, if design changes are required due to the changes in the permitting authorities' published design criteria and/or practice standards criteria which are published after the date of this Agreement which the ENGINEER could not have been reasonably aware of, the ENGINEER shall notify the CITY of such changes and an adjustment in compensation will be made through an amendment to this AGREEMENT. Article V Obligations of the City Amendments to Article V, if any, are included in Attachment C. A. City-Furnished Data The CITY will make available to the ENGINEER all technical data in the CITY's possession relating to the ENGINEER's services on the PROJECT. The ENGINEER may rely upon the accuracy, timeliness, and completeness of the information provided by the CITY. ENGINEERING CONTRACT (REV 4/14/05) Page 8 of 15 B. Access to Facilities and Property The CITY will make its facilities accessible to the ENGINEER as required for the ENGINEER's performance of its services and will provide labor and safety equipment as required by the ENGINEER for such access. The CITY will perform, at no cost to the ENGINEER, such tests of equipment, machinery, pipelines, and other components of the CITY's facilities as may be required in connection with the ENGINEER's services. The CITY will be responsible for all acts of the CITY's personnel. C. Advertisements, Permits, and Access Unless otherwise agreed to in the Scope of Services, the CITY will obtain, arrange, and pay for all advertisements for bids; permits and licenses required by local, state, or federal authorities; and land, easements, rights-of-way, and access necessary for the ENGINEER's services or PROJECT construction. D. Timely Review The CITY will examine the ENGINEER's studies, reports, sketches, drawings, specifications, proposals, and other documents; obtain advice of an attorney, insurance counselor, accountant, auditor, bond and financial advisors, and other consultants as the CITY deems appropriate; and render in writing decisions required by the CITY in a timely manner in accordance with the project schedule in Attachment A. E. Prompt Notice The CITY will give prompt written notice to the ENGINEER whenever CITY observes or becomes aware of any development that affects the scope or timing of the ENGINEER's services or of any defect in the work of the ENGINEER or construction contractors. F. Asbestos or Hazardous Substances Release. (1) CITY acknowledges ENGINEER will perform part of the work at CITY's facilities that may contain hazardous materials, including asbestos containing materials, or conditions, and that ENGINEER had no prior role in the generation, treatment, storage, or disposition of such materials. In consideration of the associated risks that may give rise to claims by third parties or employees of City, City hereby releases ENGINEER from any damage or liability related to the presence of such materials. (2) The release required above shall not apply in the event the discharge, release or escape of hazardous substances, contaminants, or asbestos is a result of ENGINEER's negligence or if ENGINEER brings such hazardous substance, contaminant or asbestos onto the project. ENGINEERING CONTRACT (REV 4/14/05) Page 9 of 15 G. Contractor Indemnification and Claims The CITY agrees to include in all construction contracts the provisions of Article IV.E. regarding the ENGINEER's Personnel at Construction Site, and provisions providing contractor indemnification of the CITY and the ENGINEER for contractor's negligence. H. Contractor Claims and Third-Party Beneficiaries (1) The CITY agrees to include the following clause in all contracts with construction contractors and equipment or materials suppliers: "Contractors, subcontractors and equipment and materials suppliers on the PROJECT, or their sureties, shall maintain no direct action against the ENGINEER, its officers, employees, and subcontractors, for any claim arising out of, in connection with, or resulting from the engineering services performed. Only the CITY will be the beneficiary of any undertaking by the ENGINEER." (2) This AGREEMENT gives no rights or benefits to anyone other than the CITY and the ENGINEER and there are no third-party beneficiaries. (3) The CITY will include in each agreement it enters into with any other entity or person regarding the PROJECT a provision that such entity or person shall have no third-party beneficiary rights under this Agreement. (4) Nothing contained in this section V.H. shall be construed as a waiver of any right the CITY has to bring a claim against ENGINEER. CITY's Insurance (1) The CITY may maintain property insurance on certain pre-existing structures associated with the PROJECT. (2) The CITY will ensure that Builders Risk/Installation insurance is maintained at the replacement cost value of the PROJECT. The CITY may provide ENGINEER a copy of the policy or documentation of such on a certificate of insurance. (3) The CITY will specify that the Builders Risk/Installation insurance shall be comprehensive in coverage appropriate to the PROJECT risks. ENGINEERING CONTRACT (REV 4/14/05) Page 10 of 15 J. Litigation Assistance The Scope of Services does not include costs of the ENGINEER for required or requested assistance to support, prepare, document, bring, defend, or assist in litigation undertaken or defended by the CITY. In the event CITY requests such services of the ENGINEER, this AGREEMENT shall be amended or a separate agreement will be negotiated between the parties. K. Changes The CITY may make or approve changes within the general Scope of Services in this AGREEMENT. If such changes affect the ENGINEER's cost of or time required for performance of the services, an equitable adjustment will be made through an amendment to this AGREEMENT with appropriate CITY approval. Article VI General Legal Provisions Amendments to Article VI, if any, are included in Attachment C. A. Authorization to Proceed ENGINEER shall be authorized to proceed with this AGREEMENT upon receipt of a written Notice to Proceed from the CITY. B. Reuse of Project Documents All designs, drawings, specifications, documents, and other work products of the ENGINEER, whether in hard copy or in electronic form, are instruments of service for this PROJECT, whether the PROJECT is completed or not. Reuse, change, or alteration by the CITY or by others acting through or on behalf of the CITY of any such instruments of service without the written permission of the ENGINEER will be at the CITY's sole risk. The CITY shall own the final designs, drawings, specifications and documents. C. Force Majeure The ENGINEER is not responsible for damages or delay in performance caused by acts of God, strikes, lockouts, accidents, or other events beyond the control of the ENGINEER. D. Termination (1) This AGREEMENT may be terminated only by the City for convenience on 30 days' written notice. This AGREEMENT may be terminated by either the CITY or the ENGINEER for cause if either party fails substantially to ENGINEERING CONTRACT (REV 4/14/05) Page 11 of 15 perform through no fault of the other and does not commence correction of such nonperformance with 5 days of written notice and diligently complete the correction thereafter. (2) If this AGREEMENT is terminated for the convenience of the City, the ENGINEER will be paid for termination expenses as follows: a.) Cost of reproduction of partial or complete studies, plans, specifications or other forms of ENGINEER'S work product; b.) Out-of-pocket expenses for purchasing storage containers, microfilm, electronic data files, and other data storage supplies or services; c.) The time requirements for the ENGINEER'S personnel to document the work underway at the time the CITY'S termination for convenience so that the work effort is suitable for long time storage. (3) Prior to proceeding with termination services, the ENGINEER will submit to the CITY an itemized statement of all termination expenses. The CITY'S approval will be obtained in writing prior to proceeding with termination services. E. Suspension, Delay, or Interruption to Work The CITY may suspend, delay, or interrupt the services of the ENGINEER for the convenience of the CITY. In the event of such suspension, delay, or interruption, an equitable adjustment in the PROJECT's schedule, commitment and cost of the ENGINEER's personnel and subcontractors, and ENGINEER's compensation will be made. F. Indemnification (1) The ENGINEER agrees to indemnify and defend the CITY from any loss, cost, or expense claimed by third parties for property damage and bodily injury, including death, caused solely by the negligence or willful misconduct of the ENGINEER, its employees, officers, and subcontractors in connection with the PROJECT. (2) If the negligence or willful misconduct of both the ENGINEER and the CITY (or a person identified above for whom each is liable) is a cause of such damage or injury, the loss, cost, or expense shall be shared between the ENGINEER and the CITY in proportion to their relative degrees of negligence or willful misconduct as determined pursuant to T.C.P. & R. Code, section 33.011(4) (Vernon Supplement 1996). ENGINEERING CONTRACT (REV 4/14/05) Page 12 of 15 G. Assignment Neither party shall assign all or any part of this AGREEMENT without the prior written consent of the other party. H. Interpretation Limitations on liability and indemnities in this AGREEMENT are business understandings between the parties and shall apply to all the different theories of recovery, including breach of contract or warranty, tort including negligence, strict or statutory liability, or any other cause of action, except for willful misconduct or gross negligence for limitations of liability and sole negligence for indemnification. Parties mean the CITY and the ENGINEER, and their officers, employees, agents, and subcontractors. I. Jurisdiction The law of the State of Texas shall govern the validity of this AGREEMENT, its interpretation and performance, and any other claims related to it. The venue for any litigation related to this AGREEMENT shall be Tarrant County, Texas. J. Alternate Dispute Resolution (1) All claims, disputes, and other matters in question between the CITY and ENGINEER arising out of, or in connection with this Agreement or the PROJECT, or any breach of any obligation or duty of CITY or ENGINEER hereunder, will be submitted to mediation. If inediation is unsuccessful, the claim, dispute or other matter in question shall be submitted to arbitration if both parties acting reasonably agree that the amount of the dispute is likely to be less than $50,000, exclusive of attorney's fees, costs and expenses. Arbitration shall be in accordance with the Construction Industry Arbitration Rules of the American Arbitration Association or other applicable rules of the Association then in effect. Any award rendered by the arbitrators less than $50,000, exclusive of attorney's fees, costs and expenses, will be final, judgment may be entered thereon in any court having jurisdiction, and will not be subject to appeal or modification except to the extent permitted by Sections 10 and 11 of the Federal Arbitration Act (9 U.S.C. Sections 10 and 11). (2) Any award greater than $50,000, exclusive of attorney's fees, costs and expenses, may be litigated by either party on a de novo basis. The award shall become final ninety (90) days from the date same is issued. If litigation is filed by either party within said ninety (90) day period, the award shall become null and void and shall not be used by either party for any purpose in the litigation. ENGINEERING CONTRACT (REV 4/14/05) Page 13 of 15 K. Severability and Survival If any of the provisions contained in this AGREEMENT are held for any reason to be invalid, illegal, or unenforceable in any respect, such invalidity, illegality, or unenforceability will not affect any other provision, and this AGREEMENT shall be construed as if such invalid, illegal, or unenforceable provision had never been contained herein. Articles V.F., VI.B., VI.D., VI.H., VI.I., and VI.J. shall survive termination of this AGREEMENT for any cause. L. Observe and Comply ENGINEER shall at all times observe and comply with all federal and State laws and regulations and with all City ordinances and regulations which in any way affect this AGREEMENT and the work hereunder, and shall observe and comply with all orders, laws ordinances and regulations which may exist or may be enacted later by governing bodies having jurisdiction or authority for such enactment. No plea of misunderstanding or ignorance thereof shall be considered. ENGINEER agrees to defend, indemnify and hold harmless CITY and all of its officers, agents and employees from and against all claims or liability arising out of the violation of any such order, law, ordinance, or regulation, whether it be by itself or its employees. Article VII Attachments, Schedules, and Signatures This AGREEMENT, including its attachments and schedules, constitutes the entire AGREEMENT, supersedes all prior written or oral understandings, and may only be changed by a written amendment executed by both parties. The following attachments and schedules are hereby made a part of this AGREEMENT: Attachment A- Scope of Services Attachment B — Compensation Executed this the �(' day of �Q , 20�. (REMAINDER OF PAGE INTENTIONALLY LEFT BLANK) ENGINEERING CONTRACT (REV 4/14/05) Page 14 of 15 � ^ � i d �_ir� �1i; i.�y1 l. };`S���jIJ,,'.i�'1 � i� �� ;;: � -�yljrS'r;; rtr � ��J J� Y �! �� �:; u�: LS IL'"� :`',. V� 6��r��. ., v'.F. � ll � 6� ��G��, ATTEST: ��� • _ -, Marty Hendrix City Secretary APPROVED AS TO FORM AND LEGP,�L-bTY , Assistant Ci CITY OF FORT WORTH By. ��� �,-� Assistant City Manager Marc A� Ot� APPROVAL RECOMMENDED: � = -���, �� �� � ; �— e�/ 1ypi� C"'COdC.'r �iCCC'a7C T�w � ��l �Q Contract� �uthariza�tio� � ��� — �� � � .���- . � �--=�--J [aa�� ENGINEERING CONTRACT (REV 4/14/05) Page 15 of 15 ENGINEER � By. r e �* �'� ���� l� � S.._ _. -.�.�.__�.�_ ! �:^). <<' �',� �': 1� � (�, r c.1 /� �fj 1� � �'%�'1' 1'L� J;-'�1 `'� 1S S�':; ��:.i' ����� � t ;a �; ,�, � ,,, �:> ��u' �)�,;� �:�1(�:lc;';;; � f �� `t;V'iTlj ��� U�� � 2 fi( � `:% U�d� City of Fort Worth Cost Proposal for the City of Fort Worth ATTACHMENT "A" SERVICES TO BE PROVIDED BY THE ENGINEER FOR DRAINAGE EASEMENT/ CULVERT DESIGN AT SYCAMORE TRIBUTARY AND E. ROSEDALE STREET CITY OF FORT WORTH E. ROSEDALE ST. THE ENGINEER SHALL PROVIDE THE FOLLOWING SERVICES: The scope of services for this supplemental is for the design of a culvert at E. Rosedale St. and Sycamore Tributary. This scope is to design the culvert for 100 yr design frequency at the City's Request. The following will be included in the set of plans that will be built as part of the E. Rosedale project: Construction of two additional culverts 8'X7' box culverts crossing E. Rosedale Street near Freeman Street. One of the culverts is required by TxDOT to meet the 25 year design and the other is required by the City of Fort Worth to meet the 100 year design at the E. Rosedale and Sycamore Tributary. The culvert for the 100 year storm will be required to be walled off until additional improvements are done downstream of this project. Construction of two additional9'X9' box culverts bored under the UP RailRoad north of East Rosedale St. These culverts will be walled off until further downstream upgrades can be made to handle the 100 year storm. Construction of concrete lined drainage channel in the Sycamore Creek between E. Rosedale Street and the RR. TASK OUTLINE FUNCTION CODE 130 — RIGHT-OF-WAY DATA 1. ROW research 2. ROW preparation 3. Strip Map preparation 4. Metes and Bounds description for property take 5. Drainage Easement Preparation 6. Metes and Bounds description for drainage easement 7. Survey and location of corners FUNCTION CODE 150 - FIELD SURVEYING AND PHOTOGRAMMETRY 1. Right of Entry, the engineer will prepare right-of-entry letters to investigate the site and for surveying needs. 2. Horizontal control will be established by splitting the existing roadway. A sufficient number of horizontal control points (three maximum) will be set with an iron rod or other suitable material to adequately maintain horizontal control through the start of construction of the project. A minimum of three (3) ties to permanent features (monumentation) will be provided for each horizontal control point set. LOPEZGARCIA GROUP City of Fort Worth Cost Proposal for the City of Fort Worth 3. Vertical control will be established. A minimum of two (2) benchmarks will be set and identified on the plane for each Culvert 4. Field Survey will include the following limits for the cross sections: 300 feet in advance of the beginning of the existing culvert structure 300 feet past the end of the existing culvert structure 300 feet right of the existing centerline of roadway 300 feet left of the existing centerline of roadway 150 feet left and right of the RR as needed to complete the survey for RR design These limits may be adjusted if needed. 5. Stream Cross-Sections:, a minimum number of stream cross sections will be taken at the following locations. A cross section will be taken at the upstream and downstream shadowline of the existing structure. If the proposed structure will be on a new alignment, a cross section shall be taken at the approximate centerline of the new structure. One cross section each approximately four times the existing structure length upstream and downstream of the roadway and intermediate cross sections upstream and downstream as needed. 6. Topographic features will include the existing substructure components of the existing culvert structure and profile of the low chord. a) Profiles of intersecting streets and driveways shall extend a sufficient distance beyond the designated topographic survey limits to ensure adequate data is available to determine tie-ins with proposed vertical alignment changes. b) The sections will indicate any ground break, top of banks, toe of slopes, water surface elevation, normal high water surface elevation, etc. that defines the actual contour of the section and the overbank area. The channel section at centerline of existing structure will include a pro�le of the existing channel bottom. c) Each survey shot taken will be assigned a unique point number, which provides a positive identification of the point. An ASCII point �le and hard copy print will be provided. Each line of the data shall contain in this order: the point number, northing, easting, elevation, and the feature number or feature name. d) All surveyed data will be provided in a Microstation.dgn compatible two-dimensional base map format, and with a 3-D DTM model with spot contours and breaklines (3-D). The survey spot shot point number, elevation, and description will appear on separate levels. e) Set stationing along the centerline for the project limits. FUNCTION CODE 160 - ROADWAY DESIGN CONTROLS 1. Prepare Plan & Proiile Sheets for Freeman 2. Prepare Prelim Cross-Sections (50' intervals) for Freeman 3. Grading Plan at the RR for Culvert 4. Grading Plan for Freeman/Culvert 5. Layout of Concrete lined channel FUNCTION CODE 161— DRAINAGE This preliminary submission shall include the overall drainage plan, structure layout, and hydraulic computations. No detailed design of drainage structures is to be preformed, until the City has given the ENGINEER written approval of the preliminary hydraulic design. 1. Perform a site inspection and record field observation for channel modeling. 2. Research and review existing studies and data. FEMA coordination if required. (Does not include preparation and coordination of a conditional or �nal Letter of Map Revision from FEMA). LOPEZGARCIA GROUP City of Fort Worth Cost Proposal for the City of Fort Worth 3. Determine drainage area and develop drainage area map for inclusion in the Plans. 4. Determine existing flows for Q25, Q100, etc., frequencies as directed by the District and the City of Fort Worth. The Q100 will follow the City of Fort Worth criteria. 5. Develop HEC-RAS models for existing and proposed condition using multi-section method with upstream, bridge and downstream channel cross-sections. 6. Analyze the existing and proposed condition using HEC-RAS. 7. Culvert Layouts(one at E. Rosedale and one at the RR) 8. The engineer will produce hydraulic data sheets for review as required by Fort Worth District. 2 sheets are estimated for review. 9. The engineer will produce 2 hydraulic data sheets at the RR, 10. Attend meetings with the UP Railroad as required 11. Attend meetings with T�cDOT and the City of Fort Worth FUNCTION CODE 163 -- MISCELLANEOUS ROADWAY l. Traffic Control Plans - Prepare TCP sheets to show a traffic control plan, a written sequence of operation, and a legend for the TCP based on the closing of Freeman St. during construction. The culverts will be stage constructed. 2. Storm Water Pollution Prevention Plan (SW3P) - Prepare SW3P District/Area Ofiice standard text and notes sheet and plan sheet showing limits of proposed riprap, soil retention, permanent seeding and rock filter dams. The SW3P shall be in accordance with Storm Water Management Guidelines for Construction Activities revised July 2002. 3. Quantity takeoffs for parking lot at Freeman 4. Jack and Bore Details, the engineer will develop jack and bore details for the 2-9X9 boxes that will be added underneath the RR. 5. Structural Details to brick in culvert at E. Rosedale and RR 6. Structural Details for the design of the headwalls at the RR 7. Compute and Tabulate Quantities - Perform quantity calculations and prepare Quantity Summary Sheets. 8. Estimate - Prepare a preliminary Construction Cost Estimate for 60 percent review and a�nal cost estimate for 100 percent review. THE FOLLOWING WII,L BE CONSIDERED ADDITIONAL SCOPE ITEMS: 1. Comprehensive Drainage Report 2. Bridge layouts for any bridges 3. Conditional letter of map revision/letter of map revision if required LOPEZGARCIA GROUP AttachmentB-FEE SCHEDULE LOPEZGARCIA GROUP E. ROSEDALE ST, FoA WoAh Dislrict Funuion Proj¢I Saiior lles�gu Engmar hi- Cale 1'uk Dtsvi won Manpps F���,nuoa G��uea Traiuing RP.L.S. 3 Man trcu� Surv T¢9� Hours ToUI AHachmentB•FEE SCHEDULE LOPEZGARCIA GROUP E. ROSEDALE ST, Fort Worth Diatricl Code �Task DescnWion I Afa"aga I Fngu'� I��RinoQ I Traimu� I RP.L.S. I� M�vi Ge�.v SLIRI�CN � Houa � 1o�a1 Projep Saiior Dai� Enginea RP.L.S. 3 Man Crew Surv Ted� Managa Enginea Enginea In-Training RATES USED FOR EQUATIONS: Direq Cabor Rates 558.66 557.55 53634 531.60 539.32 542.00 524.67 La6or Rz�a w/ovahead and fixed fee $179.69 5164.04 Sll 1.32 596.80 S120A5 5128.66 575.57 Ova6ead Rste 1.664 Fixed Fee Rate IS•/. City of Fort Worth, Texas Mayor and Council Communication _ � �: _ COUNCIL ACTION: Approved on 6/12/2007 - Ordinance No. 17592-06-2007 DATE: Tuesday, June 12, 2007 LOG NAME: 20LGG SYCAMORE REFERENCE NO.: �`*C-22169 SUBJECT: Authorize Execution of Engineering Agreement with LopezGarcia Group to Design Drainage Improvements in Accordance with City Specifications a`��a�f� of the�y-� East�f osedale Street Project (City Project No. 00138) and Adopt Appropriation Ordinance RECOMMENDATION: It is recommended that the City Council: l 1. Authorize the transfer of`$87,632�'from the Storm Water Operating Fund to the Storm Water Capital Projects Fund; 2. Adopt the attached appropriation ordinance increasing estimated receipts and appropriations in the Storm Water Capital Projects Fund in the amount of $87,632 from available funds; and 3. Authorize the City Manager to execute an engineering agreement with LopezGarcia Group, Inc., to design drainage improvements in accordance with City specifrcations as part of the East Rosedale Street Project (from IH-35W to US 287) (City Project No. 00138) in the amount of $87,632. DISCUSSION: On November 27, 1990, the City Council approved M&C G-8922 accepting the provisions of the then State Department of Highways and Public Transportation Commission (now the Texas Transportation Commission) Minute Order No. 90823 providing for the reconstruction of East Rosedale Street from IH-35W to US 287 as a six-lane divided arterial. The Texas Department of Transportation (TxDOT) is administering design and construction. LopezGarcia Group (LGG) was selected by TxDOT to perform roadway and drainage design. TxDOT drainage design standards are limited to the 25-year design frequency, but City standards call for design for the 100-year storm frequency protection. In order to meet City standards, staff requested LopezGarcia Group to submit a cost proposal and scope of work to upgrade the design for drainage improvements, which are located near Sycamore Creek Tributary. The upgraded scope of work includes four additional culverts, channel construction, and storm drain and channel improvements. LopezGarcia Group proposes to perform work for a lump sum fee of $87,632. City staff considers this fee to be fair and reasonable for the scope of services proposed. Because the upgrade design will be performed at the request of the City, the City will be responsible for 100 percent of the cost. LopezGarcia Group is in compliance with the City's M/WBE Ordinance by committing to 18 percent M/WBE participation. The City's goal on this project is 18 percent. This project is located in COUNCIL DISTRICT 8, Mapsco, 77L. T,��name: 20LGG SYCAMORE Page 1 of 2 FISCAL INFORMATION/CERTIFICATION: The Finance Director certifies that, upon approval and adoption of the attached appropriation ordinance of the above recommendations, funds will be available in the current capital budget, as appropriated, of the Storm Water Capital Projects Fund. TO Fund/Account/Centers 1&2)P228 472069 2082800138ZZ 2) P228 531200 208280013833 Submitted for City Man�er's Office by: Originating Department Head: Additional Information Contact: FROM Fund/Account/Centers $87.632.00 1) PE69 538070 0209206 $87.632.00 $87,632.00 3) P228 531200 208280013833 $87,632.00 Marc Ott (8476) Robert Goode (7804) Don McChesney (7901) Lo�name: 20LGG SYCAMORE Page 2 of 2