Loading...
HomeMy WebLinkAboutContract 32162 CITY SECRETARY in MOTOROLA CONTRACT intelligence everywhere" EMERGENCY COMMUNICATIONS TRAILER COMMUNICATIONS SYSTEM AGREEMENT CITY OF FORT WORTH, TX Motorola Western Division Svstems Integration CSA REVISION HISTORY: Date Version AuthorDescription 07-11-05 1 gVS Initial Draft. Inco orated CSA and technical documents. 07-11-05 2 gvs Minor corrections. Incorporated payment terms&Acceptance Certificate. 07-14-05 3 gvs Training revision. Minor corrections. 07-20-05 4 gVS Corrected environmental specifications table. Added combining scheme. 07-26-05 5 do Corrected payment terms mistype. Contract No. Doc en j is' 4 City of Fort Worth TABLE OF CONTENTS COMMUNICATION SYSTEM AGREEMENT....................................................................... l SECTIONl EXHIBITS.......................................................................................................l SECTION DEFINITIONS................................................................................................l SECTION 3 SCOPE OF AGREEMENT-------------------.--.-----7 SECTION PERFORMANCE SCHEDULE .....................................................................4 SECTION PAYMENT SCHEDULE................................................................................4 SECTION 6 INSTALLATION AND SITE CONDITIONS................................................5 SECTION TRAINING ---------------------------------'5 SECTION 8 FINAL SYSTEM ACCEPTANCE .................................................................5 SECTION 9 VV/\RKANT`/ --------------------------------.6 SECTION 10 FCC LICENSES AND AUTHORIZATIONS ----------------Q SECTION ll [)E[/\`/S-----------------------------------8 SECTION12 DEFAULT ......................................................................................................9 SECTION 13 LIABILITY AND INDEMNIFICATION .......................................................9 SECTION 14 DISPUTES....................................................................................................l0 SECTION 15 LIMITATION OF LIABILITY -----------------.-----.11 SECTION16 INSURANCE................................................................................................ll SECTION 17 TB\0\4UN/\Tl()N------------------------------]2 SECTION 18 GENERAL....................................................................................................l2 EXHIBIT SOFTWARE LICENSE AGREEMENT—....'.—.'...—.—..—,'..—.---------' 17 SBCT10Nl SCOPE..........................................................................................................l7 Contract No. Paaei Document Version O7/| l05 Rev. 5.07'2h'Uj City of Fort Worth SECTION 2 GRANT OF LICENSE..................................................................................17 SECTION 3 LIMITATIONS ON USE..............................................................................17 SECTION4 TRANSFERS................................................................................................17 SECTION 5 OWNERSHIP AND TITLE..........................................................................18 SECTION 6 CONFIDENTIALITY...................................................................................18 SECTION 7 LIMITED WARRANTY ..............................................................................18 SECTION 8 LIABILITY AND INDEMNIFICATION .....................................................19 SECTION 9 TERM AND TERMINATION......................................................................19 SECTION10 NOTICES......................................................................................................19 SECTION1 1 GENERAL....................................................................................................20 EXHIBIT B PAYMENT SCHEDULE............................................................................... 21 EXHIBIT C TECHNICAL DOCUMENTATION............................................................22 SYSTEM DESCRIPTION..........................................................................................................23 PRELIMINARY TASK LISTING ...............................................................................................25 AC CIRCUIT REQUIREMENTS ...............................................................................................27 ENVIRONMENTAL SPECIFICATIONS......................................................................................29 SYSTEMDRAWINGS..............................................................................................................30 EQUIPMENTLIST...................................................................................................................36 STATEMENT OF WORK..........................................................................................................40 FUNCTIONAL ACCEPTANCE TEST PLAN...............................................................................55 EXHIBIT D SYSTEM ACCEPTANCE CERTIFICATE................................................. 59 r,r-r Contract No. Page ii Document Ver.'or;0?':I-J?051. 29' 7 "Ni Rev 5>tiff L ti� X711* City of Fort Worth COMMUNICATION SYSTEM AGREEMENT EMERGENCY COMMUNICATIONS TRAILER CITY OF FORT WORTH Motorola, Inc., a Delaware corporation ("Motorola"), and the City of Fort Worth, Texas, a municipal corporation organized under the laws of the state of Texas and situated in Tarrant, Denton, and Wise counties, Texas ("Customer or the City") enter into this Communications System Agreement (the "Agreement" or "Communications System Agreement'), effective as of the last date signed below (the "Effective Date"), pursuant to which Customer will purchase and Motorola will provide Customer with an Emergency Communications Trailer. Section 1 EXHIBITS The Exhibits below are hereby incorporated into and made a part of this Agreement. In interpreting this Agreement and resolving any ambiguities, the main body of this Agreement will take precedence over the Exhibits and any inconsistency between the Exhibits will be resolved in the order in which the Exhibits appear below. Exhibit A Motorola Software License Agreement Exhibit B Payment Schedule Exhibit C Technical and Implementation Documents • Emergency Communications Trailer System Description • Emergency Communications Trailer Equipment List • Emergency Communications Trailer Statement of Work • Emergency Communications Trailer Functional Acceptance Test Plan Exhibit D System Acceptance Certificate Section 2 DEFINITIONS Capitalized terms used in this Agreement and 'not otherwise defined within the Agreement have the following meanings: "Communications System" or "System" is the communications system described in Exhibit C, including, but not limited to, the Equipment, Software and all services described in the System Description, Statement of Work, Acceptance Test Plan and Equipment List. "Equipment" is the equipment specified in the Equipment List included in Exhibit C-2. "Motorola Software" is software whose copyright is owned by Motorola. Contract No. Page 1 Document Version 07/11/05 Rev. 5, 07-26-05 City of Fort Worth "Non-Motorola Software" is software whose copyright is owned by a party other than Motorola. "Software" includes Motorola and any Non-Motorola Software that may be furnished with the Communications System. Section 3 SCOPE OF AGREEMENT A. SCOPE OF WORK. Motorola will assemble and integrate the Equipment and Software, and deliver, install and test the Communications System in accordance with this Agreement and, specifically, with the Project Timeline and Implementation Schedule, as specified in Exhibit C, and the Payment Milestones, as specified in Exhibit B. Customer will perform its responsibilities as specified in Exhibit C and in accordance with this Agreement. Motorola shall perform all work described in and pursuant to this Agreement in a professional manner and in conformance to professional standards. B. CHANGE ORDERS. Either party may request changes within the general scope of this Agreement. If a requested change causes an increase or decrease in the cost of or time required for the performance of this Agreement, Motorola and Customer will agree to an equitable adjustment in the Agreement price or performance schedule, or both; provided, however, that if Motorola requests the change and Customer consents, such change shall not result in or create any delay in any milestone set forth in the Project Timeline and Implementation Schedule set forth in Exhibit C unless otherwise specifically agreed to in writing by Customer. Motorola is not obligated to comply with requested changes unless and until both parties execute a written change order. Changes that increase Customer's costs under this Agreement by more than $25,000.00 must be approved by Customer's City Council prior to execution of a written change order. C. ADDITIONAL PRODUCTS. For one (1) year after the date of Final System Acceptance, Customer may purchase additional Equipment as add-ons to the Communications System ("Add-on Equipment") at the same prices as those established for such Equipment hereunder. For years two (2) and three (3) year after Final System Acceptance, Customer may submit purchase orders for additional equipment manufactured by Motorola's CGISS which is within the scope of this Agreement and which is currently available at the time of order. If Customer and Motorola have agreed to a convention for processing electronic data interchange ("EDI") transactions, purchase orders may be transmitted electronically. Each purchase order must specifically refer to this Agreement and will be an offer by Customer subject to Motorola's acceptance. Except for pricing (other than for Add- on Equipment, which prices are itemized in the Equipment List and are guaranteed from the Effective Date of this Agreement until the expiration of one (1) year following the date of Final System Acceptance) and delivery terms, which must be stated on the purchase order, Customer and Motorola agree that the applicable terms of this Agreement will be the only terms and conditions that govern the purchase and sale of products identified on such purchase orders. Customer and Motorola agree that the procedure for payment of all additional products so purchased will be in accordance with the procedure set forth in Section 5 of this Agreement. Contract No. Page 2 Document Version 07/11/05 Rev. 5, 07-26-05 City of Fort Worth D. MAINTENANCE SERVICE. After the first year following expiration of the Warranty Period, Customer may purchase maintenance services and software support for the Communications System pursuant to a separately executed service agreement and software subscription agreement between Motorola and Customer. E. MOTOROLA SOFTWARE. Any Motorola Software furnished will be licensed to Customer solely according to the terms and restrictions of the Software License Agreements attached as Exhibit A. Customer hereby accepts all of the terms and restrictions of the Software License Agreements as negotiated between Motorola and the City of Fort Worth. F. NON-MOTOROLA SOFTWARE. Non-Motorola Software furnished by Motorola will be subject to the terms and restrictions of its copyright owner unless such copyright owner has granted to Motorola the right to sublicense such Non-Motorola Software, in which case the Software License Agreement (including any addendum to satisfy such copyright owner's requirements) shall apply; provided, however, that nothing in this Section 3.F, the Software License Agreement or any restrictions or requirements of copyright owners of Non-Motorola Software shall be deemed or construed to limit or restrict in any way the System Functionality Warranty provided by Motorola in accordance with Section 9.13 of this Agreement. G. PROJECT MANAGEMENT. Motorola shall assign a project manager acceptable to Customer, who is authorized to exercise technical direction of all duties and obligations of Motorola and Motorola's subcontractors under this Agreement. Motorola agrees to meet and consult with Customer before designating a new or alternate project manager. Motorola's project manager shall have authority to negotiate changes in or amendments to this Agreement on behalf of Motorola. In addition, any and all of Motorola's officers, agents, employees, and subcontractors may, at the option of Customer, be subject to a security check at any time. Customer shall have the right to require the removal from Customer's premises any of Motorola's officers, agents, employees or subcontractors if Customer reasonably determines, such individual's presence is inappropriate under the circumstances, and Motorola agrees that it will immediately comply with and assist Customer in such removal. At Customer's request, Motorola shall promptly provide Customer with the names, dates of birth, drivers' license numbers and other identification documents required by Customer of Motorola's officers, agents, employees or subcontractors that will be present on Customer's premises in order for Motorola to fulfill its obligations under this Agreement. Contract No. Page 3 Document VeM46 gb�34U06 = ll City of Fort Worth H. PROJECT STATUS MEETINGS. From the Effective Date of this Agreement until Final System Acceptance, Motorola agrees to conduct periodic project status meetings at locations specified by Customer. These meetings shall be conducted on not less than a monthly basis and may be conducted more frequently if requested by Customer. Motorola agrees to submit monthly status reports covering such items as progress of work being performed, milestones attained, problems encountered, corrective actions taken and project financial status. Each progress report will include status and milestone progress of all subcontracted work. Section 4 PERFORMANCE SCHEDULE A. Motorola and Customer agree to perform their responsibilities in accordance with the Statement of Work and the Project Timeline and Implementation Schedule. Milestones and milestone payments are to be activity based / related, not cumulative time based / related. If milestone payments are tied to deliverables, if the deliverable moves so does the milestone payment. B. By executing this Agreement, Customer authorizes Motorola to proceed with the manufacture, assembly, integration, delivery, installation, and testing of the Communications System. No further notice to proceed, purchase order, authorization, resolution, or any other action will be required unless required by applicable laws or ordinances. Section 5 PAYMENT SCHEDULE A. The total contract price for all equipment, software and services provided under this Agreement is not to exceed $499,450, for which Customer agrees to make payments in accordance with the Payment Milestones in Exhibit B. B. Freight charges for all Equipment, software and any and all other products and supplies provided hereunder are included in the Contract Price. All material to be shipped FOB Destination. C. Notwithstanding anything to the contrary in this Agreement, Motorola understands that Customer has appropriated no more than $499,450 for purposes of the manufacture, assembly, integration, delivery, installation and testing of the Communications System and all other work or services provided by Motorola or its subcontractors under this Agreement. Motorola understands and agrees that Customer shall not be liable to Motorola or any of its subcontractors for any sums in excess of such amount unless Customer's City Council first approves and appropriates sums in excess of such amount, in which case such additional sums shall also be included as part of the Contract Price as defined and interpreted in this Agreement. D. All invoices from Motorola shall be submitted to Customer's Project Manager or, in his or her absence, the Director of Customer's IT Solutions Department. Customer shall pay invoices for services and deliverables received and approved by Customer within thirty (30) days of receipt. If Customer has any questions or disputes regarding such invoices, Motorola shall make Motorola personnel available as needed to answer or resolve such, and Customer shall be allowed additional time to pay the questioned or disputed portion of those invoices. Contract No. Page 4 Document Version 07/11/05 Rev. 5, 07-26-05 City of Fort Worth Section 6 INSTALLATION AND SITE CONDITIONS A. In addition to its responsibilities described in the Statement of Work, Customer agrees to provide a designated project director, also known as the Project Manager, procure any necessary construction permits, building permits, zoning variances and the like, provide access to the sites identified in the Exhibits as requested by Motorola, and have such sites available for installation of the Equipment by Motorola in accordance with the performance schedule and Statement of Work. B. If either Motorola or Customer determines during the course of performance of this Agreement that the sites identified in the Exhibits are no longer available or desired, or, if subsurface, structural, adverse environmental or latent conditions at any site differ from those indicated on the specifications in the Exhibits, Motorola and Customer will promptly investigate the conditions and in good faith negotiate an equitable solution and, based on such solution, execute any written amendments to this Agreement or the Exhibits attached hereto that may be deemed necessary by both parties. C. If Customer and Motorola determine that any change requested by Customer in site availability, installation plans, or specifications may require an adjustment in the Contract Price or in the time required for the performance of this Agreement, the parties will in good faith negotiate an equitable solution and, based on such solution, execute any written amendments to this Agreement or the Exhibits attached hereto that may be deemed necessary by both parties. Amendments will be via the Change Order process described in "Section 3 Scope of Agreement, Paragraph B. Change Orders." Section 7 TRAINING Motorola will provide training as set forth in the Statement of Work attached hereto. If Motorola or Customer request a change in any Training schedule within thirty (30) days of the date that such Training was originally to occur, the party requesting the change shall pay the other party any actual and reasonable increased costs directly associated with the change. Section 8 FINAL SYSTEM ACCEPTANCE A. Motorola will perform tests of various components of the Communications System and a final test of the fully integrated Communications System in accordance with the Statements of Work/Acceptance Test Plans. Acceptance of the Communications System will occur upon the successful completion of such final testing of the System as a fully integrated Communications System, as outlined in and in accordance with the Statement of Work/Acceptance Test Plan ("System Acceptance"), at which time both parties shall promptly document any deficiencies, failures, or problems, in the form of a Punch List. Final System Acceptance Certificates will not be issued by the City of Fort Worth until all issues on the Punch List have been resolved to the sole satisfaction of the City of Fort Worth ("Final System Acceptance"). Customer shall not unreasonably delay Final System Acceptance. In addition, both parties shall promptly execute certificates of subsystem acceptance upon the successful Contract No. Pale 5 Document Version 07/11/05 Rev. 5, 07-26-05 City of Fort Worth completion of testing of such subsystems, as outlined in and in accordance with the Acceptance Test Plans attached hereto. Customer and Motorola will jointly prepare a list of such omissions and variances which Motorola will correct according to an agreed upon schedule with clearly defined and agreed to due dates. Reference to 'System Acceptance' SHALL NOT equate to 'Final System Acceptance'. B. Motorola agrees to notify Customer when the Communications System is ready for acceptance testing. Motorola and Customer agree to commence acceptance testing within ten (10) business days after receiving such notification, subject to resource availability for both Motorola and the City, the testing may be delayed for up to an additional ten (10) business days. Section 9 WARRANTY A. WARRANTY PERIOD. Upon System Acceptance, the System Functionality representation described below is fulfilled. The Equipment and Motorola Software is warranted for a period of one (1) year after System Acceptance ("Warranty Period") in accordance with the applicable limited warranties shown below. Customer must notify Motorola in writing if Equipment or software does not conform to these warranties no later than one month after the expiration of the Warranty Period. B. SYSTEM FUNCTIONALITY WARRANTY. Motorola represents that the Communications System will satisfy the functional requirements in Exhibit C. Upon System Acceptance, this System Functionality representation is fulfilled. After System Acceptance, the Equipment Warranty set forth below and the Software Warranty set forth in the Software License Agreement will apply in accordance with their terms and conditions. Motorola will not be responsible for performance deficiencies of the System caused by ancillary equipment not furnished or specified for use by Motorola or another party in accordance with the provisions of this Agreement that is attached to or used in connection with the System provided hereunder. Additionally, Motorola will not be responsible for System performance where the functionality is reduced for reasons beyond Motorola's control including but not limited to i) an earthquake, adverse atmospheric conditions or other natural causes; ii) the construction of a building that adversely affects the microwave path reliability or Radio Frequency (RF) coverage; iii) the addition of additional frequencies at System sites that cause RF interference or intermodulation; iv) Customer changes to load usage and/or configuration outside the parameters specified in Exhibit D; v) any other act outside the scope of the ordinary use of the Communications System by parties who are beyond Motorola's control, including Customer or its employees, contractors, consultants or agents. C. EQUIPMENT WARRANTY. Motorola warrants the Equipment against material defects in material and workmanship under normal use and service during the Warranty Period. The Warranty Period for non-Motorola manufactured Equipment will be stated in this section. Contract No. Page fi Document Fy, `-NUH, YEK, City of Fort Worth At no additional charge and at its option, Motorola will either repair the defective Equipment, replace the defective Equipment with the same or equivalent Equipment acceptable to Customer or refund the purchase price of the defective Equipment, and such action on the part of Motorola will be the full extent of Motorola's liability hereunder. Repaired or replaced Equipment is warranted for the balance of the Warranty Period. All replaced parts of the Equipment shall become the property of Motorola. THIS WARRANTY DOES NOT APPLY TO a) Defects or damage resulting from use of the Equipment in other than its normal and customary manner. b) Defects or damage occurring from misuse, accident, water, or neglect. c) Defects or damage occurring from testing, operation, maintenance (except first line/front line echelon maintenance provided by Customer), installation, alteration, modification, or adjustment not (i) provided by Motorola pursuant to this Communications System Agreement or (ii) otherwise authorized in writing by Motorola. d) Breakage or damage to antennas unless caused directly by defects in material or workmanship. e) Equipment that has been subjected to unauthorized Equipment modifications, disassembly or repairs (including the addition to the Equipment of non-Motorola supplied equipment if not authorized by Motorola) which adversely affect performance of the Equipment or interfere with Motorola's normal warranty inspection and testing of the Equipment to verify any warranty claim. f) Equipment that has had the serial number removed or made illegible. g) Batteries (because they carry their own separate limited warranty). h) Equipment which, due to illegal or unauthorized alteration of the software/firmware in the Equipment, does not function in accordance with Motorola's published specifications or with the FCC type acceptance labeling in effect for the Equipment at the time the Equipment was initially distributed from Motorola. i) Scratches or other cosmetic damage to Equipment surfaces that does not affect the operation of the Equipment. j) Software (which is covered by the Software License Agreement). k) Normal and customary wear and tear. 1) On site response, except where it pertains to specific new equipment, that is purchased as part of this Agreement. Contract No. Page 7 Document N efi (,1�/ w eV.._ City of Fort Worth m) After hours warranty support. n) Systems diagnostics or response is not included as part of this Agreement. o) Any services requested that do not pertain to specific equipment that is part of this Agreement, will be billed at prevailing time and material rates. D. MOTOROLA SOFTWARE WARRANTY. Motorola Software is warranted in accordance with the terms of the Software License Agreement attached as Exhibit A. E. These express limited warranties as set forth in this Section are extended by Motorola to the original end user purchasing or leasing the System for commercial, industrial, or governmental use only, and is not assignable or transferable. These are the complete warranties for the Equipment and Software provided pursuant to this Agreement. F. THESE WARRANTIES ARE GIVEN IN LIEU OF ALL OTHER WARRANTIES. MOTOROLA DISCLAIMS ALL OTHER WARRANTIES OR CONDITIONS, EXPRESS OR IMPLIED, INCLUDING THE IMPLIED WARRANTIES OR CONDITIONS OF MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE. Section 10 FCC LICENSES AND AUTHORIZATIONS Customer agrees to obtain all Federal Communications Commission ("FCC") licenses and authorizations required for installation and use of the Communications System prior to the scheduled installation of the Equipment. Equipment can be installed while the FCC is processing the application, it shall not be turned on and radiate energy until either the application / license is processed / granted by the FCC, or the FCC grants the City an STA (Special Temporary Authorization) to operate the station(s). Although Motorola may assist in the preparation of license applications, in no event will Motorola or any of its employees be an agent or representative of Customer in FCC matters. Customer is solely responsible for obtaining all FCC licenses and for complying with FCC rules. Section 11 DELAYS A. Successful project implementation will require cooperation and fairness between the parties. Because it is impractical to provide for every contingency that may arise during the course of performance of this Agreement, the parties agree to notify the other in writing if they become aware that any condition will significantly delay performance. The parties will agree to reasonable extensions of the project schedule by executing a written change order that may, or may not, have a financial impact. B. Under no circumstances will either party be responsible for delays or lack of performance resulting from events beyond the reasonable control of that party ("Excusable Delays"). Such events include, but are not limited to, acts of God, Contract No. Page 8 Document N etsj�;) -11 ev� sQv7, `.... City of Fort Worth weather conditions, compliance with laws and regulations (excluding Customer's failure to properly and timely apply for all required FCC licenses), governmental action, bid protests, fire, strikes, lock-outs, and other labor disruptions, material shortages, riots, acts of war, and an Excusable Delay of a Motorola subcontractor. C. Customer will make available to Motorola the sites when scheduled and Customer will not otherwise unreasonably delay or prevent Motorola's performance of its responsibilities. In the event of a Customer delay during the time of shipment, Motorola may ship the equipment as scheduled to a location as designated by the Customer or if no such location is designated, a Motorola designated storage facility. Motorola shall not ship equipment until advised by the City that the site is ready. If either party materially delays performance under this Agreement, Motorola and Customer shall discuss the reasons for the particular delay and negotiate in good faith a solution to address such delay and will execute a written change order that may, or may not, have a financial impact, if appropriate. Section 12 DEFAULT A. If Motorola fails to complete delivery, installation or acceptance testing in accordance with this Agreement, Customer may consider Motorola to be in default, unless an Excusable Delay has caused such failure. Customer agrees to give Motorola written notice of such default. Motorola will have thirty (30) calendar days from the receipt of such notice to provide a written plan of action that is acceptable to Customer to cure the default. Such written plan of action shall include milestones necessary to cure the default and timetables for achieving those milestones and shall be signed by Motorola and Customer. B. If Motorola fails to cure the default within the timetables and in accordance with the plan of action that Customer has accepted, Customer may (i) terminate any unfulfilled portion of this Agreement and, at Customer's sole option, complete the Communications System at a quality and to a capability equaling, that specified in this Agreement through a third party or (ii) if the Communications System or any component thereof cannot be completed through a third party as provided in subsection (i) above, demand and receive specific performance by Motorola. If Customer completes the Communications System through a third party, Customer may recover all reasonable costs and expenses incurred in the course of completing the Communications System to a capability not exceeding that specified in the Agreement, less the unpaid portion of the Contract Price. Customer agrees to use its best efforts to mitigate such costs. Motorola's liability under this Section is subject to the limitations of the Section entitled Limitation of Liability of this Agreement. Section 13 LIABILITY AND INDEMNIFICATION A. GENERAL LIABILITY AND INDEMNITY. MOTOROLA SHALL BE RESPONSIBLE FOR ANY AND ALL PROPERTY LOSS OR DAMAGE AND/OR PERSONAL INJURY, INCLUDING DEATH, TO ANY AND ALL PERSONS, OF ANY KIND OR CHARACTER, WHETHER REAL OR ASSERTED, TO THE EXTENT CAUSED BY THE NEGLIGENT ACT(S) OR OMISSION(S) OR INTENTIONAL MISCONDUCT OF MOTOROLA, ITS OFFICERS, AGENTS, SERVANTS, EMPLOYEES, AND/OR SUBCONTRACTORS, IN THE PERFORMANCE OF OR RELATED TO THE Contract No. Page 9 Document Version 07/11/05 Rev. 5, 07-26-05 City of Fort Worth PERFORMANCE OF THIS AGREEMENT. IN ADDITION, MOTOROLA SHALL DEFEND, INDEMNIFY AND HOLD CUSTOMER HARMLESS FROM AND AGAINST ANY AND ALL LAWSUITS, CLAIMS, ACTIONS, DEMAND, LIABILITIES OR OTHER COSTS AND EXPENSES WHICH MAY ACCRUE AGAINST CUSTOMER TO THE EXTENT THAT THE SAME ARE CAUSED BY THE NEGLIGENT ACT(S) OR OMISSION(S) OR INTENTIONAL MISCONDUCT OF MOTOROLA, ITS OFFICERS, AGENTS, SERVANTS, EMPLOYEES, AND/OR SUBCONTRACTORS. THE TERMS, CONDITIONS AND PROVISIONS OF THIS PARAGRAPH SHALL SURVIVE THE EXPIRATION OR TERMINATION OF THIS AGREEMENT. B. PATENT AND COPYRIGHT INFRINGEMENT. Motorola will defend, at its own expense, any suit brought against the Customer to the extent that it is based on a claim that the Equipment or Motorola Software infringes a patent or copyright, and Motorola will pay those costs and damages finally awarded against the Customer in any such suit which are attributable to any such claim, but such defense and payments are conditioned on the following: i) Motorola must be notified promptly in writing by Customer of any notice of such claim; ii) Motorola will have sole control of the defense of such suit and all negotiations for its settlement or compromise; and iii) should the Equipment or Motorola Software become, or in Motorola's opinion be likely to become, the subject of a claim of infringement of a United States patent or copyright, Customer will permit Motorola, at its option and expense, either to procure for Customer the right to continue using the Equipment or Motorola Software or to replace or modify the same so that it becomes non-infringing. In addition, at Customer's sole option and directive, Motorola shall grant Customer a credit for the Equipment or Motorola Software as depreciated and accept its return. The depreciation amount will be based upon generally accepted accounting standards for such Equipment and Software. MOTOROLA WILL HAVE NO LIABILITY WITH RESPECT TO ANY CLAIM OF PATENT OR COPYRIGHT INFRINGEMENT TO THE EXTENT THAT SUCH CLAIM IS BASED UPON A PATENT OR COPYRIGHT INFRINGEMENT ARISING DIRECTLY BECAUSE OF A COMBINATION OF THE EQUIPMENT OR MOTOROLA SOFTWARE FURNISHED HEREUNDER WITH SOFTWARE, APPARATUS OR DEVICES NOT FURNISHED OR SPECIFIED BY MOTOROLA HEREUNDER, NOR WILL MOTOROLA HAVE ANY LIABILITY FOR THE USE OF ANCILLARY EQUIPMENT OR SOFTWARE NOT FURNISHED OR SPECIFIED BY MOTOROLA AND WHICH IS ATTACHED TO OR USED IN CONNECTION WITH THE EQUIPMENT. Section 14 DISPUTES A. Motorola and Customer will attempt to settle any claim or controversy arising from this Agreement through consultation and negotiation in good faith and a spirit of mutual cooperation. If those attempts fail, the dispute may be mediated by a mediator chosen jointly by Motorola and Customer within thirty (30) business days after notice by one of the parties requesting non-binding mediation. If both parties consent to mediation, Motorola and Customer will share the cost of the mediation equally. The parties may postpone mediation until they have completed some specified but limited discovery about the dispute. The parties may also replace mediation with some other form of non-binding alternate dispute resolution ("ADR") Contract No. Page 10 Document Version 07/11/05 Rev. 5, 07-26-05 City of Fort Worth procedure. Any mediation, ADR procedure or other negotiations or meetings pertaining to a claim, controversy or problem arising under this Agreement shall be held at a location in Fort Worth, Tarrant County, Texas. B. Any dispute that cannot be resolved between the parties through negotiation or mediation within two (2) months after the date of the initial request for non-binding mediation may then be submitted by either party to a court of competent jurisdiction in accordance with Section 18.J of this Agreement. Each party consents to jurisdiction over it by such a court. The use of any ADR procedures will not be considered under the doctrine of laches, waiver, or estoppel to affect adversely the rights of either party. Either party may resort to the judicial proceedings described in this paragraph prior to the expiration of the two-month ADR period if (a) good faith efforts to attempt resolution of the dispute under these procedures have been unsuccessful or (b) interim relief from the court is necessary to prevent serious and irreparable injury to such party or any of its affiliates, agents, employees, customers, suppliers, or subcontractors. Section 15 LIMITATION OF LIABILITY Except for personal injury or death, Motorola's total liability to Customer for claims or damages asserted by Customer, whether for breach of contract, warranty, negligence, strict liability in tort, indemnification, or otherwise, will be limited to the total Contract Price. IN NO EVENT WILL MOTOROLA BE LIABLE FOR ANY LOSS OF USE, LOSS OF TIME, INCONVENIENCE, COMMERCIAL LOSS, LOST PROFITS OR SAVINGS, OR OTHER SPECIAL, INCIDENTAL OR CONSEQUENTIAL DAMAGES IN ANY WAY RELATED TO OR ARISING FROM THIS AGREEMENT, THE SALE OR USE OF THE EQUIPMENT, OR THE PERFORMANCE OF SERVICES BY MOTOROLA PURSUANT TO THIS AGREEMENT. This Limitation of Liability will survive the expiration or termination of this Agreement. Section 16 INSURANCE From the Effective Date of this Agreement until Final System Acceptance, Motorola shall maintain, in full force and effect, a policy or policies of insurance as specified in this Section 16 to cover all risks related to Motorola's scope of work under this Agreement. At a minimum, Motorola shall provide coverage of the types and at the limits specified herein: • Commercial General Liability: $1,000,000.00 per occurrence; $2,000,000 annual aggregate; • Business Automobile Liability: $1,000,000 combined single limit • Worker's Compensation: Applicable Statutory Limits The insurers for all policies must be approved to do business in the State of Texas. Certificates of Insurance provided by Motorola under this Agreement shall (i) list Customer as an additional insured and (ii) provide that the respective policy shall not be canceled, limited in scope or coverage, or non-renewed until after thirty (30) days prior written notice has been give to the Risk Manager, City of Fort Worth, 1000 - Contract No. Page 11 Docume A5C-rev City of Fort Worth Throckmorton Street, Fort Worth, Texas 76102. Motorola shall provide Customer with a copy of its Certificate(s) of Insurance prior to the effective date of this Agreement. Section 17 TERMINATION Customer may terminate this Agreement, in whole or in part, at any time and for any reason following at least thirty (30) calendar days' advance written notice to Motorola. Customer shall pay Motorola for (i) all Equipment provided and services and other work performed by Motorola through the effective date of termination; (ii) actual and reasonable expenses incurred by Motorola in the removal of installation and test equipment from Customer's premises; and (iii) any actual and reasonable costs which may be borne by Motorola in the early and abrupt termination for convenience of subcontracts, provided that Customer has approved in writing the provisions of such subcontracts that relate to termination by Motorola or liquidated damages or other financial obligations of Motorola due to termination by Motorola, which approval shall not unreasonably be withheld Section 18 GENERAL A. TITLE AND RISK OF LOSS. Title to respective Equipment will pass to Customer upon delivery to Customer's facilities as directed by Customer. Full risk of loss, however, shall not pass to Customer until completion of the Installation of Equipment Milestone set forth in Exhibit C; provided, however, that after delivery of Equipment to Customer's facilities but before payment by Customer to Motorola for that Equipment, Customer shall be responsible for any losses or damages to Equipment to the extent that such are directly caused by the negligent act(s) or omission(s) or intentional misconduct of Customer, its officers, agents, servants and/or employees. Title to Software will not pass to Customer at any time. B. TAXES. The purchase price does not include any amount for federal, state, or local excise, sales, lease, service, rental, use, property, occupation, or other taxes, all of which (other than federal, state, and local taxes based on Motorola's income or net worth) will be paid by Customer except as exempt by law. C. CONFIDENTIAL INFORMATION. Customer and Motorola will not disclose to third parties any material or information that is identified by either party to the other as proprietary and confidential ("Confidential Information") without the other party's prior written permission unless required by law; provided, however, that Customer may disclose Confidential Information of Motorola to Customer's employees, agents, consultants and other contractors, in which case Customer shall identify to such parties the nature and obligations of Customer with respect to that Confidential Information. Notwithstanding the foregoing, Motorola understands and acknowledges that the Customer is a public entity under the laws of the State of Texas, and as such, all information held by Customer or that customer has a right of access to is subject to public disclosure under Chapter 552 of the Texas Government Code. Customer may be required to disclose information that may reveal Motorola proprietary information to third parties under the Texas Government Code or by any other legal process, law, rule or judicial order by a court of competent jurisdiction. If either Customer or Motorola is required by law to disclose Contract No. Page 12 Documentar 7! 14.',- R CITY SEC diff' City of Fort Worth such material or information, the disclosing party will notify the other party prior to such disclosure. D. DISCLAIMER OF LICENSE. Except as explicitly provided in the Motorola Software License Agreement included in Exhibit A, nothing in this Agreement will be deemed to grant, either directly or by implication, estoppel, or otherwise, any license or right under any patents, patent applications, copyrights, trade marks, trade secrets or other intellectual property of Motorola. E. ASSIGNABILITY. This Agreement may not be assigned by either party without the prior written consent of the other party except that Motorola may assign this Agreement to any of its affiliates or its right to receive payment following at least thirty (30) days' advance written notice to Customer. F WAIVER. Failure or delay by either party to exercise any right or power under this Agreement will not operate as a waiver of such right or power. G. SEVERABILITY. If any portion of this Agreement is held to be invalid or unenforceable, that provision will be considered severable and the remainder of this Agreement will remain in full force and effect as if the invalid provision were not part of this Agreement. H. HEADINGS AND SECTION REFERENCES. The headings given to the sections of this Agreement are inserted only for convenience and are not to be construed as part of this Agreement or as a limitation of the scope of the particular Section to which the heading refers. I. ENTIRE AGREEMENT. This Agreement (including the Exhibits) constitutes the entire agreement of the parties regarding the subject matter of this Agreement and supersedes all previous agreements and understandings, whether written or oral, relating to such subject matter. This Agreement may be altered, amended, or modified only by a written instrument signed by the duly authorized representatives of both parties. J. GOVERNING LAW AND VENUE. This Agreement will be governed by and construed in accordance with the laws of the State of Texas. Venue for any action arising under or related to the terms and conditions of this Agreement shall lie in state courts located in Tarrant County, Texas or in the United States District Court for the Northern District of Texas, Fort Worth Division. K. NOTICES AND CORRESPONDENCE. Notices authorized or required under this Agreement must be in writing and, along with all written correspondence, mailed via United States Mail, certified, return receipt requested, to the below addresses: City of Fort Worth Motorola, Inc. Attn: Project Manager Wireless Services Division Attn: Contracts and Compliance IT Communications Services 6450 Sequence Drive 1000 Throckmorton San Diego, CA 92121 Fort Worth, TX 76102 Contract No. Page 13 Document Version 07/11/05 Rev. 5, 07-26-05 City of Fort Worth As to written correspondence from one party to the other that concerns or is related to the clarification, proposed solution or any other situation requiring a written response from the other party, both Motorola and Customer shall have a maximum of ten (10) business days from receipt to respond in writing to such correspondence. If the receiving party believes that the contents of such correspondence does not conform to the requirements of this Agreement, or otherwise disagrees with such correspondence, it shall notify the sending party in writing within the above-stated ten (10) business days, defining in detail such non-acceptance. In the event that the receiving party finds the content of the correspondence in conformance to the requirements of this Agreement, it shall, within the above stated ten (10) business days, notify sending party in writing of this fact, and such notification shall constitute acceptance of the content of the correspondence delivered. Because certain Agreement deliverable documents requiring Customer's approval may require more than ten (10) business days for Customer to complete its review process, Customer may have up to thirty (30) business days to review and approve documents and manuals relating to the functional specification and administration of the System or any portion thereof. L. COPIES. Customer shall have the right to make as many copies of Motorola's written application system documentation as necessary for Customer's own internal use (including, but not limited to, any consultants or other contractors retained by Customer for assistance related to this Agreement or the Communications System) except as prohibited by copyright restriction. Customer agrees that authorized copies will contain any trade secret notice found in Motorola's original document. In addition, Customer shall have the right to make as many copies of any user manuals, technical manuals, maintenance manuals or other similar types of documents provided by Motorola under this Agreement as necessary for Customer's own internal use. Customer shall also have the right to make copies of Motorola's software programs and documentation except as may be specifically prohibited under the Software License Agreement. M. MOTOROLA SUBCONTRACTORS AND SUPPLIERS. Motorola may not subcontract with a third party for the provision of any services or materials whose value or cost exceeds $1,000.00 without the advance written consent of Customer which consent will not be unreasonably withheld. Motorola will enter into written contracts with all subcontractors that are approved by Customer, which contracts shall incorporate this Agreement for all purposes. In no event shall Customer's approval of any subcontractor of Motorola relieve Motorola of its responsibilities and obligations under this Agreement. Throughout this Agreement and all Exhibits attached hereto, references to the duties and obligations of a specific subcontractor of Motorola shall also be fully binding on and enforceable against Motorola as if Motorola itself were providing the services or supplies provided by the subcontractor. N. DISASTER RECOVERY. In the event a disaster or accident beyond Customer's control impairs the operation of the System, Motorola shall use its best efforts to help Customer restore operations as quickly as possible at rates not to exceed those Contract No. Page 14 Document Vi rstop ;11705 _ R City of Fort Worth set forth in or calculated in accordance with those in the Service Agreement or those last paid by Customer for similar services. O. SECTIONS SURVIVING TERMINATION OR FINAL SYSTEM ACCEPTANCE. The terms and conditions of Sections 9, 12, 13, 14, 15, 18.J shall survive the termination date of and/or date of Final System Acceptance under this Agreement. P. RIGHT TO AUDIT. Motorola agrees that Customer shall, until the expiration of three (3) years after final payment under this contract, have access to and the right to examine and photocopy any directly pertinent books, documents, papers and records of Motorola involving transactions relating to this contract. Customer may send a representative to a Motorola facility during normal business hours to conduct such limited review, or at Customer's request Motorola will provide copies of the specific documents to Customer's location for its review. Motorola books and records provided to Customer pursuant to this provision shall not be used, duplicated or disclosed to any other third party without the express written permission of Motorola, unless required by law. In no circumstances will Motorola be required to create or maintain documents not kept in the ordinary course of Motorola's business operations, nor will Motorola be required to disclose any information, including but not limited to product cost data, which it considers confidential or proprietary to Motorola. Motorola agrees that Customer shall have access during normal working hours to all necessary Motorola facilities and shall be provided adequate and appropriate workspace in order to conduct audits in compliance with the provisions of this section. Customer shall give Motorola reasonable advance notice of intended audits. (a) Motorola further agrees to include in all its subcontractor agreements hereunder a provision to the effect that the subcontractor agrees that Customer shall, until the expiration of three (3) years after final payment under the subcontract, have access to and the right to examine and photocopy any directly pertinent books, documents, papers and records of such subcontractor, subject to the provisions of Paragraph P above, involving transactions to the subcontract, and further, that Customer shall have access during normal working hours to all subcontractor facilities, and shall be provided adequate and appropriate workspace, in order to conduct audits in compliance with the provisions of this article together with subsection (3) hereof. Customer shall give subcontractor reasonable advance notice of intended audits. (b) Motorola and subcontractor agree to photocopy such documents as may be requested by the City. The City agrees to reimburse Motorola and or subcontractor for the cost of copies at the rate published in the Texas Administrative Code in effect as of the time copying is performed_ Contract No. Page 15 Document Version 0711105 Rev. 5, 07-26-05 City of Fort Worth In witness whereof, the parties have caused duly authorized representatives to execute this Agreement in multiples on the dates set forth below. IN WITNESS WHEREOF: City of ort Wort Motorola, Inc. By: By: Name: Name: STEVEN J. PALM Title: Title: AREA CONTROLLER v1 Date: Date: APROVED AS TO FORM AND LEGALITY: Assistant Nty Attorney ,�iLcsted By: PtaavH e City Secretary (2—D32KE 'ontract authorization QL to OFFICIAL RECOID CITY JEOIETARY Ft WORTH, TEX. Contract No. Page 16 Document Version 07/11/05 Rev. 5,07-26-05 City of Fort Worth Emergency Communications Trailer Exhibit A EXHIBIT A SOFTWARE LICENSE AGREEMENT This Software License Agreement is between Motorola, Inc., a Delaware corporation ("Motorola"), and the City of Fort Worth ("Licensee"). Section 1 SCOPE Licensee may acquire from Motorola's Commercial, Government, and Industrial Solutions Sector ("CGISS") radio communication products ("Products") that contain embedded or pre-loaded Motorola software such as in a ROM, PROM, or EPROM, or other Motorola software provided on media such as a floppy disk, tape, diskette, or CD- ROM. All such software (including Radio Service Software and FLASHport® Software) is referred to as "Motorola Software." In addition, third party software may be included which Motorola does not own but is licensed to distribute. The terms of this Agreement apply to any such third party software unless an additional license agreement pertaining to the third party software is enclosed, in which case the terms of such license apply to said third party software. This Agreement contains the terms under which Licensee may use Motorola Software acquired from CGISS. Section 2 GRANT OF LICENSE Motorola hereby grants to Licensee a personal, non-exclusive license for use of those products and quantities as described in the Statement of Work under Motorola's applicable proprietary rights to use Motorola Software in accordance with the terms of this Agreement. Section 3 LIMITATIONS ON USE Licensee may use Motorola Software only for Licensee's internal business purposes and only as described in the Motorola Software or Product documentation. Any other use of Motorola Software is strictly prohibited and will be deemed a breach of this Agreement. Licensee may not copy, modify, adapt, merge with other software, reverse engineer, prepare derivative works of, or disassemble any Motorola Software for any reason, except that Licensee may make at most two copies of Motorola Software provided with infrastructure equipment for back-up purposes. Licensee must purchase a copy of Radio Service Software for each site at which Licensee uses Radio Service Software; Licensee may make one additional copy for each computer owned or controlled by Licensee at each such site. Licensee may temporarily use Radio Service Software on portable or laptop computers at other sites. Prior to acquiring any Radio Service Software or upon Motorola's request, Licensee must provide a written list of all sites where Licensee uses or intends to use Radio Service Software. Licensee must reproduce all Motorola copyright and trademark notices on all copies of Motorola Software. Section 4 TRANSFERS If Licensee transfers ownership of Products to a third party, Licensee may assign its rights to use Motorola Software (other than Radio Service Software and FLASHport® Software) embedded in or furnished for use with those Products provided that (a) Licensee transfers all copies of such Motorola Software to the new owner and (b) Contract No. Page 17 Document Version 07/11/05 Rev. 5,07-26-05 City of Fort Worth Emergency Communications Trailer Exhibit A Motorola receives a transfer form (which Motorola will provide upon request) completed and signed by the new owner. Otherwise, Licensee may not transfer or make available any Motorola Software to any third party. Section 5 OWNERSHIP AND TITLE Title to all copies of Motorola Software in any form, including all rights in patents, copyrights, trade secrets, and other intellectual properties, remains vested exclusively in Motorola. Section 6 CONFIDENTIALITY Licensee acknowledges that all Motorola Software contains valuable proprietary information and trade secrets and that unauthorized dissemination, distribution, modification, reverse engineering, disassembly, or other improper use of Motorola Software will result in harm to Motorola. Accordingly, Licensee will limit access to Motorola Software to those of its employees and agents who need to use Motorola Software for Licensee's internal business purposes, and Licensee will take appropriate action with those employees and agents to preserve the confidentiality of Motorola Software. Section 7 LIMITED WARRANTY During the Warranty Period, as defined in Section 9.A of the Communication System Agreement, Motorola warrants that the Motorola Software and Non-Motorola Software whose copyright owner has granted to Motorola the right to sublicense such Non- Motorola Software, when used properly, will be free from reproducible defects that eliminates the functionality of a feature critical to the primary functionality of the System. The primary functionality of a voice communication system is subscriber-to-subscriber, subscriber-to-dispatcher, and dispatcher-to-subscriber voice communication. The primary functionality of a data system is point-to-point data transmission. Motorola does not warrant that Licensee's use of the Software or the Products will be uninterrupted or error-free, but does warrant that the Motorola Software and/or the Products will perform in accordance with the Communication System's functional requirements as a fully integrated system and in accordance with the representations made by Motorola in the Communication System Agreement. During the Warranty Period, Motorola, at Motorola's sole cost and expense and at no cost to Customer, will promptly take all steps necessary, including, but not limited to, complete replacement of any Motorola Software causing a respective malfunction of the System, to make the Motorola Software fully operational for purposes of the System as a fully integrated System as specified in Exhibit D. EXCEPT FOR PERSONAL INJURY OR DEATH, MOTOROLA'S TOTAL LIABILITY, AND LICENSEE'S SOLE REMEDY, FOR ANY BREACH OF THIS WARRANTY WILL BE LIMITED TO, AT MOTOROLA'S OPTION, REPAIR OR REPLACEMENT OF THE MOTOROLA SOFTWARE AT NO COST TO LICENSEE OR PAYMENT OF LICENSEE'S DIRECT DAMAGES LIP TO THE CONTRACT PRICE. THIS WARRANTY EXTENDS ONLY TO THE FIRST LICENSEE; SUBSEQUENT TRANSFEREES MUST ACCEPT THE MOTOROLA SOFTWARE "AS IS" AND WITH NO WARRANTIES OF ANY KIND. MOTOROLA DISCLAIMS ALL OTHER Contract No. Page 18 Document Version 07/11/05 Rev. 5,07-26-05 City of Fort Worth Emergency Communications Trailer Exhibit A WARRANTIES, EXPRESS OR IMPLIED, INCLUDING THE IMPLIED WARRANTIES OF MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE. Section 8 LIABILITY AND INDEMNIFICATION The liability and indemnification provisions set forth in the paragraphs of Section 13 of the Communications System Agreement shall extend and fully apply to and be a part of this Software License Agreement. IN NO EVENT WILL MOTOROLA BE LIABLE FOR INCIDENTAL OR CONSEQUENTIAL DAMAGES EVEN IF ADVISED OF THE POSSIBILITY OF SUCH DAMAGES. Section 9 TERM AND TERMINATION Licensee's right to use Motorola Software will begin when Licensee sends a duly executed copy of this Agreement to Motorola, and either (a) Motorola returns a fully executed Agreement to Licensee or (b) Motorola ships Motorola Software or a Product containing Motorola Software to Licensee, and will continue in perpetuity unless terminated as follows. Licensee's right to use Motorola Software will terminate upon written notice following a breach of this Agreement, by Licensee and Licensee's failure to cure such breach within ten (10) business days after being given a written notice by Motorola of such breach. In addition, if Motorola reasonably believes that Licensee has breached or intends to breach this Agreement with respect to Radio Service Software or FLASHport® Software, Motorola may, by notice to Licensee, terminate Licensee's right to use such Motorola Software, unless within ten (10) business days of receipt of such notice, Licensee delivers a letter to Motorola which states that Licensee does not intend to breach this Agreement and such letter in good faith addresses all facts and circumstances giving rise to the sending of the letter as set forth therein to the reasonable satisfaction of Motorola. Within thirty (30) business days after termination of Licensee's right to use any Motorola Software, Licensee must certify in writing to Motorola that all copies of such Motorola Software have been returned to Motorola or destroyed. Section 10 NOTICES All notices, consents, and waivers permitted or required under this Agreement will be deemed given upon receipt and must be delivered in writing to the below addresses. Change of address must be in writing to the other party. City of Fort Worth Motorola Inc. Attn: Project Manager—Wireless Services Division IT Solutions Department Attn: Contract and Compliance Manager 1000 Throckmorton 6450 Sequence Drive Fort Worth, TX 76102 San Diego, CA 92121 Contract No. Page 19 Document Verson Q7/1'1/OS ;. Rev, 5,071.-#-0 J Zr rv'is lc iG' �J:/ City of Fort Worth Emergency Communications Trailer Exhibit A Section 11 GENERAL A. COPYRIGHT NOTICES. The existence of a copyright notice on Motorola Software will not be construed as an admission or presumption that public disclosure of Motorola Software or any trade secrets associated with Motorola Software has occurred. B. WAIVERS. No waiver of a right or remedy of a party will constitute a waiver of another right or remedy of that party. C. ASSIGNMENTS. Motorola may not assign any of its rights or subcontract any of its obligations under this Agreement, or encumber or sell any of its rights in any Motorola Software, without the advance written consent of Licensee except that Motorola may assign such rights or subcontract such obligations to any of its affiliates following at least thirty (30) days' advance written notice to Licensee. D. ENTIRE AGREEMENT AND AMENDMENT. Except for the Communication System Agreement and all Exhibits thereto, this Agreement contains the parties' entire agreement regarding Licensee's use of Motorola Software and may be amended only in a writing signed by both parties. If Motorola is required to modify this Agreement as necessary to comply with applicable laws and regulations, including FCC regulations, Licensee shall cooperate fully with such efforts and this Software License Agreement shall be reasonably amended in a writing signed by both parties to comply with such laws and regulations. E. GOVERNING LAW AND VENUE. This Agreement will be governed by the laws of the United States of America to the extent that they apply and otherwise by the laws of the State of Texas. Venue for any action arising under or related to the terms and conditions of this Software License Agreement shall lie in state courts located in Tarrant County, Texas or in the United States District Court for the Northern District of Texas, Fort Worth Division. F. TERMS. Terms in this Software License Agreement that are capitalized but not specifically defined shall have the same definitions as those provided for such terms in the body of the Communication System Agreement. In witness whereof, the parties have caused duly authorized representatives to execute this Agreement in multiples on the dates set forth below. City of Fort Worth Motorola, Inc. By: By: Name z� Qr Name: STEVEN J. PALM Title: ' 1 �, 5�-el,irl� Title: AREA CONTROLLER Date: Date: APROVED AS TO FORM AND LEGALITY: Contract o. VV Page 20 Document Version 07/11/05 Assistant C ty Attorney Rev. 5,07-26-05 City of Fort Worth Emergency Communications Trailer Exhibit B EXHIBIT B PAYMENT SCHEDULE No. Milestone Percent Amount 1 Execution of contract 25% $124,862 3 Delivery of Trailer to the City of Ft Worth's WCT site 50% $249,725 4 Acceptance of Optimization of Trailer on System 25% $124,863 Contract No. Page 21 Document RK City of Fort Worth Emergency Communications Trailer Exhibit C EXHIBIT C TECHNICAL DOCUMENTATION Contract No. Page 22 Document Version 07/11/05 Rev. 5, 07-26-05 City of Fort Worth Emergency Communications Trailer Exhibit C System Description Overview • Lighting. The emergency communications trailer will contain Type I(SAD) site AC surge suppression. all the necessary equipment for a compete trunked 09 Trunked Repeaters. site. It will have external connections for power, 0 1 Channel Bank equipped with redundant CPU grounding, controUdata circuits,and antenna RF and modules for 12 channels. cables. The base trailer proposal contains equipment 1 Negative 48 VDC power supply for E&M for a 9 channel trunked simulcast site with no switching relays. conventional channels. Options are shown to add and delete trunked channels and to add conventional 01 GPS Site Standard. channels. Installing more than 9 channels in the trailer 0 1 T-Bar T1 Switch. will require that additional MSF5000 stations are replaced at the existing sites. The base trailer will be E&M Switching Relay Box. equipped and wired to ultimately accommodate 20 0 3 ea 4 channel Transmitter Combiners. trunked channels, 5 UHF channels,and 7 VHF 0 1 32 channel Receiver Multicoupler. channels. • Miscellaneous cabling,wiring, interface panels, Equipment etc. 1. Following is a list of equipment included in Remote Site Controller this proposal: This proposal does not include a simulcast remote site Emergency Trailer controller. As discussed in project meetings, it is the City's responsibility to procure a 6809 remote site • 28'x 8'trailer with 8'inside ceiling height. controller. Motorola can provide assistance in • Cable trays as indicated on drawing below. locating potentia] units. • 12 equipment racks installed as shown on Control Channel Swap drawing below. • 12 vertical rack ground bus bars. Currently control channels l &3 utilize MSF5000 • Main 400 amp AC circuit panel. repeaters operating at 150 watts. In order to prevent having MSF5000 stations installed in the trailer, it is • Sixty Six(66)20 Amp circuits. necessary to swap those stations with the Quantro • Waveguide entry window with bulk-head mount repeaters on channels 18 &20. This must be connectors as feed-through ports for 20 lines. completed at each of the existing 4 sites as part of the • 3 inch wall penetration for future use. With trailer implementation. rubber boot and screw-on cap for weather AC Main and Backup Power proofing. • External ground bus at waveguide entry. This trailer as proposed will not be equipped with any • Internal ground bus/panel for bulkhead mount generator/UPS power or a power transfer switch. The Polyphasor suppressors. trailer will be equipped with an external power • Air conditioning/Heating units. connection. The City is to provide the power source. ZP • Anti-static floor. The trailer will be equipped with a 400 amp AC • Insulated walls. breaker panel containing sixty six (66)20-amp • External connection for AC power. breakers. Refer to the AC power table for details. • External connection for ground. • External connection for Telco/Tl. • Internal ground system per R-56. Contract No. Page 23 Document Version 07/11/05 Rev. 5, 07-26-05 City of Fort Worth Emergency Communications Trailer Exhibit C Grounding Existing Combining Scheme The trailer will be equipped with an internal ground 95 Watts 150 Watts system in accordance with Motorola R56 standards. Combiner 1 1 2 3 4 5 All equipment and racks will be connected to this ground network.An external ground bus will be 2 4 1 3 5 provided which is to be connected to an external °' 7 9 6 8 10 ground system(rod)when the trailer is deployed. c 12 14 11 13 15 System Impact U 17 19 16 18 20 The impact to the simulcast system will be kept to a minimum.However,when the trailer is brought on- Proposed Trailer Combining Scheme line, each channel will have to be optimized. Also if more than 9 channels are installed,channels will be 100 Watts out of service during installation and optimization at Combiner 1 2 3 -the existing sites.A detailed implementation plan will be submitted which will provide sufficient information that can be used in the City's Change 4 2 4 1 - Management Process. — 7 9 3 - - 12 14 11 - Microwave Equipment U 17 19 16 - Three 7' racks are being installed for the microwave equipment. The City will be responsible for Note: The shaded channels will be utilised in the trailer. procuring, installing, and optimizing this equipment. Space Requirements The proposed combiners have a specified minimum channel separation of 150 KHz. However channel 3 is As proposed,the trailer will contain 12 equipment only 125 KHz from channel 1. Celwave technical support has stated that the combiner should still racks arranged in 4 rows of 3 racks each as shown in operate satisfactorily but the potential exists for the trailer layout and rack face diagrams. This degraded performance. If unacceptable degradation arrangement provides 3' of space between each row does occur, it will be necessary for the City to and 2' of space between the wall and end of each purchase and install an additional combiner to row. alleviate the problem. Combining Scheme This proposal contains three 4-channel combiners. The combiner channel layout will be kept as close as possible to that of the existing sites.However, only Quantar/Quantro based channels can be used and a]14 control channels must be included. The following tables illustrate the differences between the trailer combiners and the existing combiners. Contract No. Page 24 Docume tiA 3 l� City of Fort Worth Emergency Communications Trailer Exhibit C Preliminary Task Listing Installation of Equipment in Emergency Trailer 0 Supply and install (3)25 pair patch cables from TeNSr channel bank to DSM patch Emergency Trailer-Install(1)RESC panels. • Supply and install (1)25 pair patch cable • Remove RESC equipment from cabinet. from TeNSr channel bank to TI/EI Interface • Install RESC equipment in specified rack. patch panel • Install AC cable to designated AC outlet. • Supply and install (2)25 pair patch cable • Supply and install (1)Site link cables to from TeNSr channel bank to 4Wire E&M TeNSr channel bank SRU port. patch panels • Ground RESC equipment to FNE specs • Install AC cables to designated AC outlets. (R56). aSupply and install(1)Cat.5 T1 cable from T 1/E 1 Interface Panel to TBAR switch. Emergency Trailer-Install(9) Quantar repeaters • Supply and install (2) 1 pps cables from designated DSM cards to site standard. • Mount(9)Quantar repeaters into specified • Ground TeNSr channel bank and patch racks. panels to FNE specs(R56). • Supply,assemble and install (9)Tx cables to • Apply new labeling. combiners(1/2"Super flex jumpers). • Supply,assemble and install(9)Rx cables to Emergency Trailer-Install(1)site standard Rx multi-coupler(1/4"Super flex jumpers). • Supply,assemble and install (9)5Mhz site • Install site standard onto designated frequency standard cables to site standard. equipment rack. • Install (9)Quantar controller cables to • Install (2)AC cables to designated AC RESC. outlets. • Supply,assemble and install (9) satin audio • Supply,assemble, and install (2)GPS cables to TeNSr patch panels. antenna coaxial cables from GPS receiver to • Install AC cables to designated AC outlets. antenna line surge protection devices. • Ground racks and Quantar repeaters to FNE • Ground to FNE specs(R56). specs(R56). • Supply any needed connectors to terminate GPS cabling to surge protection device. Emergency Trailer-Install(1)TeNSr channel • Supply and install alarm cabling to bank designated alarm punchblock. • Apply new labeling. • Install TeNSr channel bank on equipment rack. Emergency Trailer- Install(1) TBAR switch • Install (2)TeNSr channel bank DSM patch panels. • Install TBAR switch equipment into • Supply and install (1)RS232 cable from designated equipment rack. TeNSr channel bank to designated data • Install(2)AC cables to designated AC channel for remote diagnostics. outlets. • Supply and install (1)alarm cable from • Supply and install (2)Cat5 TI cables to TeNSr channel bank to designated alarm designated Microwave demarc and punchblock. terminate. • Install (1)TeNSr channel bank TI patch 0 Terminate(2)TeNSr Cat5 T 1 cables to panel on rack. designated ports. Contract No. Page 25 Document Version 07/11/05 Rev. 5,07-26-05 City of Fort Worth Emergency Communications Trailer Exhibit C • Supply,fabricate and install TBAR Emergency Trailer-Install (3)4 channel, Main/backup switching control circuit and Transmit combiners interface to TBAR switch. • Supply and install(1)—48vdc power cable • Install combiner systems into equipment from TENSR-48 VDC power supply to rack. Main/backup switching control circuit. • Ground combiner equipment and equipment • Supply and install Main/backup switching rack to FNE specs(R56). control lines from designated Microwave • Install and ground(3) lightning protection "E-lead"point to switching control circuit. devices at antenna coaxial entry window. • Ground TBAR switch equipment to FNE • Install(3)TX filters. specs(R56). • Supply,assemble,and install associated RF • Apply any new labeling cabling between filters and combiners. (1/2" superflex) Emergency Trailer-Install (1)Rx Multicoupler • Supply,assemble, install,and terminate(3) Tx coaxial jumpers from combiner antenna • Install(1)Rx multicoupler into designated port to lightning protection at coaxial entry equipment rack. window(1/2" Superflex). • Install AC cable to designated AC outlets. • Apply new labeling. • Ground receiver multicoupler equipment to FNE specs(R56). • Install bandpass filter. • Supply, assemble, and install associated RF cabling between filter and multicoupler. (1/4" superflex) • Install and ground (2)DC passive lightning protection devices at antenna coaxial entry window. • Supply, assemble, install, and terminate(2) Rx coaxial jumpers from receiver multicoupler antenna port and test port to lightning protection devices at coaxial entry window(1/2"Superflex). • Supply and install alarm cabling to designated alarm punchblock. • Apply any new labeling. Contract No. Page 26 Document Version 07/11/05 Rev. 5, 07-26-05 City of Fort Worth Emergency Communications Trailer Exhibit C AC Circuit Requirements Rack No.of No Equipment 20 Amp Comments Ckts Repeater 1 1 Repeater 2 I Repeater 3 l 1 Repeater 4 1 Repeater 5 1 Repeater 6 1 Repeater 7 1 Repeater 8 1 2 Multicou ler 1 Repeater 9 1 Repeater 10 1 Repeater l l l 3 Repeater 12 l Repeater 13 1 Repeater 14 1 Repeater 15 1 Repeater 16 1 Repeater 17 1 Repeater 18 1 Repeater 19 1 4 Repeater 20 1 Future 1 Future l Future l Future 1 5 Controller 2 Main/Backup PS on separate Circuits. Future l T-Bar Switch 2 Main/Backup PS on separate Circuits. Channel Bank 2 Main/Backup PS on separate Circuits. 6 Site Standard 2 Main/Backup PS on separate Circuits. Future 1 Future 1 UHF Conventional l l UHF Conventional 2 l UHF Conventional 3 1 7 UHF Conventional 4 1 UHF Conventional 5 1 Future 1 Future l Future l Contract No. Page 27 Document Version 07/11/05 Rev. 5,07-26-05 City of Fort Worth Emergency Communications Trailer Exhibit C Rack No. of No. Equipment 20 Amp Comments Ckts VHF Conventional 1 1 VHF Conventional 2 1 VHF Conventional 3 l 8 VHF Conventional 4 1 VHF Conventional 5 1 VHF Conventional 6 1 VHF Conventional 7 1 Future 1 NPSPAC 1 1 NPSPAC 2 1 NPSPAC 3 1 9 NPSPAC 4 l NPSPAC 5 1 Future I Future 1 Future 1 ]0 Microwave Charger 1 1 1 Microwave Radios 0 No AC Required 12 Microwave Batteries 0 No AC Required Lighting 2 Lighting split between two circuits. Need to verify number and capacity of Air Conditioning l circuits for HVAC. Maintenance Outlets 2 Instaal at least 9 outlets as shown on layout diagram. Split outlets between 2 circuits. Total 66 Contract No. Page 28 Document Version 07/11/05 Rev. 5, 07-26-05 � o 0 O O . O V O O O O O V V) k/1) N 00 O v a, � s o N 0 kr) \0 00 O N O� 00 C>O O C C- v) 00 00 r C - M O� T V O I I kn C5- 0 0 0 0 O O o a d p + O 00 O CD O OO N � N a rz O � ICO V' ^ O [- M O O, O N mi- oo M N O1 Vf O o vi Q Q q q q q "T 0 0 0 N o y O kn O b `r C v, O Vf "T N NN �' y N kn O to O O N to , b ^ 00 V ` O v) O O O v) v) N 00 O n `r h b kn O �}• O� y r N V \D V N N — O p O en N O O b ^ N kn I.Q b4 to Ilk c `° "-. � e e o, y 0 3a soz c c E c m o c%) o C,3m� � i ro v) F- 0. > 3 < F F- Q 02 M D D Q y M 00 0 rn N p O, C� C� s oo p y �•' v) _ O C� Cl U O 00 I-Q 00 kn 3 " k.� , T . ;. V V, to C 0 0 � � o a� • J y � LL o, V ur 0 w lY m g U y m O NJ O w. L) u 0 70 c L U 0 cc3 m r n _ m m 0 rO m 2 L N Ul '0 v O O U U J O � U 3 v C C N J LL Cn O .L alewaa ll � Z WAWA c U a E $$ lowawend y o 0 m c— Cm 3 a— u_ oar a� 0 z o m �o � D WU b 1^ m 3 Cd 0. ya�epawl tl �atdepV m--o m O c u — E Z_ H o tq w 3 F Z U ~ T E c f 0 C � N ialdepy mueno b O y m m Y C m Q 0: c 7 d U a, ~dtY F!2 in Z f H � m 0 0 m c � o �atdepy C � U V U O O O O LL p v� o > •� O c Y o w Qo o > x J Cn o U 0 C " Z •y ? O '� (6 u�G E v Il E C O O p 0 a p 0 O m U c 7 w D n. a >1Q Fp 0 0 c J a) U O w w> O Z c y c o o �Q Q) m 4� r m m E a W xc wa E ai n oCT =3Z aa) on Ta I I eM 7117.1 n a F577 N JALN JACK Japi-L JOCK JgCK JACK XPLUG PLW y 2.c PLW O= PLW PLUG d o m°z E U N E U 4l a E U m ' E .O > a o y x m m 4l X LL m LL \LL y N /�I' N J4 JAL ►le'a11Vlng JA ; JALN JAC PLUG PLUG jaddoo PLUG PLUG PLUG ANT ANT ANT ANT ANT tr': x y o y o of o oc m o L Rx Rx Tx Tx Tx cca a 6 U y JACK JACK JPCK JACK JACK 7 O �' Q1 N �PLUG O= PLW PLUG PLW PLUG E v m p s X w JACK Q1 m E U Q1 m OE J - LL N ' U cE 6 a V d LL X \ N % U O L JALN LL c 7 U E U 4l LL N vLUG JALK U L X s Luc PLUG U E U N X I-x- NO LQ1 G1 N= ISOLATOR U N U C C d 0Oj OY =O a H d a CD JACK 4 m 2r E U d Im LL vLW ' PLW � U _ m LUO \LL Q1 pN PLUG PLUG N JA N N J4 N C anne ransmi er ° Receiver Multicoupler Combiners Duplexe NOYf MOYf MOYf NOYf AC m BNC BNL m PLUG PLUG PLW PLUG PLUG PLUG LL XX X `Lm a 'm OPLW PLUG PLW PLUG PLUG PLUG O N C Q) O T O m e a E Y N I \ N v O / a C N 5 5 a' a LII c o o X V o X V o Qo in >�m °1 uJ �E °1 rn � LL aL c U7 O O E 6 LL C m U) Q) m N f% J m C J m �..� C C C 6 0 C _ a 0 N a) Q m ry 2 -< E ? CE n 12 =3 V ' ~ ' Z w C7wJ r U kr) C) �6 > CZ (U > Z5 d) LL IL E (D LU *�e 0 > Tj 0) CO 0 > LL C) Ci .............................. L) ....... .......... Rack 10 Rack 11 Rack 12 ul I ................................... .............. ................. ......................... Rack 7 Rack 8 Rack 9 9 N Rack 4 Rack 5 Rack 6 Z:@ ........... ........... Rack 1 Rack 2 Rack 3 -Y LO C: L) AMIN V 00 •v � ^ CV cel 1 o O O � O i N N J71� U C m m m E ULLJ O j 2 ! � d U Ln 4 Ww. c� a e Ci G m e. `4 a> � U c brp CD a W � Q �b i C7 .a d L � Q i d Ci O ~ i d i M U - O N H I 0 in 0.£ 2>1 m mm a� om U U N N y _c � � m +r [�L i U cd v U L V kr) kr) y o0 r yr — N O O Vj O U U � Lt7 y N T _ Y c a a u E N o cu c- m` 0 rnE N c Z ~w ogEom m o.a QH•� m D NCnN `5 C— m �< 3m c z � m a .wa�w > o U m a p w U z a a Q ~z Q ~ N (U t4 41 R by W U tn cc Y U- C� 41 Y U U w °D 3 a, m ya g Q = a k k f # 4 co m Y N a Um Q C — M Q 0 Ltl � R R 8 •� Q, c H X a1� a d Y ' d Q a L (0 O` Y - N N M M L Lo _ N U) d L) C_ d. C_ aid+ C_ r_�. C U C. a y ¢. LL lz C M a LL a t0 C 7 a m l r -0 Y ++ R K F 4 O I � Z F d Y U ° r �+ 7 oo n O *' (D V Z i m'Q ' _ Qm [T� z U ld v \ \ o / ƒ 2 \ § � ! $ \ � � o .) � � \ \ t 2 u / % \ cu \ � o � � { Neco o eI \ � \CL + f- - - - - \Mn kgr § : / 2 / \ \ : 00 2 2 tm $ 0 . m Z � \\ �`` _ ■!E )\! � _ q 2 2 � \. f/ � /!` }•� � � � � � � \ � \ City of Fort Worth Emergency Communications Trailer Exhibit C Equipment List Qty Model Number Description Mobile Trailer-Housings&Housing Accessories 1 TRN7342 SEVEN FOOT RACK 1 TRN7342 SEVEN FOOT RACK 1 TRN7342 SEVEN FOOT RACK 1 TRN7342 SEVEN FOOT RACK I TRN7342 SEVEN FOOT RACK I TRN7342 SEVEN FOOT RACK 1 TRN7342 SEVEN FOOT RACK 1 TRN7342 SEVEN FOOT RACK 1 TRN7342 SEVEN FOOT RACK 1 TRN7342 SEVEN FOOT RACK 1 TRN7342 SEVEN FOOT RACK 1 TRN7342 SEVEN FOOT RACK 9 TTN5028A HDW RACKMNT QUANTAR STDALONE Trailer Trunked Equipment-TNSRI 1 DSPREM891830 UNIVERSAL ENCLOSURE TENSR 800 2 DSPREM880160 CPU 8 TI El CROSS CONNT I DSPREM892060 8T1 EI IF CARD 32K WITH MODEM I DSPREM8903 48 VDC CONVERTER 2 DSPREM8901 AC POWER SUPPLY 110/220VAC 1 DSPREM822560 10 PORT LD-SRU CARD 3 DSPREM816460 4 PORT 4W DSM CARD 1 DSPREM8I 1960 8 PORT 4W E M TO EXT RANGE CRD 2 DSPREM801065 DUAL TI E1 WAN CARD 2 DSPREM81230 CSU PLUG IN MODULE 2 DSPREM81130 DSX CEPT PLUG IN MODULE 2 DSTSJ48CLT RJ-45 8 WIRE MOD PROT. INSTALL RJ-45 OR HARD WIIRED 1 DSTSJADP RACK BUS BAR FOR TSJ AND WPH SERIES NETWORK PROTECTOR Trailer Trunked Equipment-Repeaterl 1 T5365 QUANTAR/QUANTRO FAMILY MODEL 1 X750 ADD: 800 MHZ BAND RX 806-825 N4 Z/TX 851-870 MHZ, 100-20 WATTS 1 X997 A ENH: QUANTAR 6809 TRUNKING OPERATION I X87 DEL: CABINET I X432 ADD: MANUAL, SERVICE 1 U752 ADD: POWER CORD, 12 FT AC,QTAR 1 X777 ALT:ANALOG SIMULCAST Trailer Trunked Equipment-Repeater2 1 T5365 QUANTAR/QUANTRO FAMILY MODEL I X750 ADD: 800 MHZ BAND RX 806-825 M1=X 851-870 MHZ, 100-20 WATTS 1 X997 A ENH: QUANTAR 6809 TRUNKING OPERATION 1 X87 DEL: CABINET 1 U752 ADD: POWER CORD, 12 FT AC, QTAR Contract No. Page 36 Document Version 07/11/05 Rev.5,07-26-05 City of Fort Worth Emergency Communications Trailer Exhibit C Qty Model Number Description 1 X777 ALT:ANALOG SIMULCAST Trailer Trunked Equipment-Repeater3 1 T5365 QUANTAR/QUANTRO FAMILY MODEL I X750 ADD: 800 MHZ BAND RX 806-825 N*IVTX 851-870 MHZ, 100-20 WATTS 1 X997 A ENH: QUANTAR 6809 TRUNKING OPERATION 1 X87 DEL: CABINET 1 U752 ADD: POWER CORD, 12 FT AC,QTAR 1 X777 ALT: ANALOG SIMULCAST Trailer Trunked Equipment- Repeater4 I T5365 QUANTAR/QUANTRO FAMILY MODEL 1 X750 ADD: 800 MHZ BAND RX 806-825 MHZ/TX 851-870 MHZ, 100-20 WATTS 1 X997 A ENH:QUANTAR 6809 TRUNKING OPERATION 1 X87 DEL:CABINET 1 U752 ADD: POWER CORD, 12 FT AC,QTAR 1 X777 ALT:ANALOG SIMULCAST Trailer Trunked Equipment-Repeater5 I T5365 QUANTAR/QUANTRO FAMILY MODEL I X750 ADD: 800 MHZ BAND RX 806-825 MHZ/TX 851-870 MHZ, 100-20 WATTS 1 X997 A ENH: QUANTAR 6809 TRUNKING OPERATION 1 X87 DEL: CABINET I U752 ADD: POWER CORD, 12 FT AC,QTAR I X777 ALT: ANALOG SIMULCAST Trailer Trunked Equipment-Repeater6 I T5365 QUANTAR/QUANTRO FAMILY MODEL 1 X750 ADD: 800 MHZ BAND RX 806-825 MHZ/TX 851-870 MHZ, 100-20 WATTS 1 X997 A ENH: QUANTAR 6809 TRUNKING OPERATION 1 X87 DEL: CABINET 1 U752 ADD:POWER CORD, 12 FT AC,QTAR 1 X777 ALT:ANALOG SIMULCAST Trailer Trunked Equipment-Repeater7 1 T5365 QUANTAR/QUANTRO FAMILY MODEL 1 X750 ADD: 800 MHZ BAND RX 806-825 MHZ/TX 851-870 MHZ, 100-20 WATTS I X997 A ENH: QUANTAR 6809 TRUNKING OPERATION 1 X87 DEL: CABINET 1 U752 ADD: POWER CORD, 12 FT AC, QTAR 1 X777 ALT: ANALOG SIMULCAST Trailer Trunked Equipment-Repeater8 I T5365 QUANTAR/QUANTRO FAMILY MODEL 1 X750 ADD: 800 MHZ BAND RX 806-825 MHZ/TX 851-870 MHZ, 100-20 WATTS 1 X997 A ENH: QUANTAR 6809 TRUNKING OPERATION 1 X87 DEL: CABINET Contract No. Page 37 Document Version 07/11/05 Rev. 5,07-26-05 City of Fort Worth Emergency Communications Trailer Exhibit C Qty Model Number Description I U752 ADD: POWER CORD, 12 FT AC, QTAR 1 X777 ALT: ANALOG SIMULCAST Trailer Trunked Equipment-Repeater9 I T5365 QUANTAR/QUANTRO FAMILY MODEL 1 X750 ADD: 800 MHZ BAND RX 806-825 MHZ/TX 851-870 MHZ, 100-20 WATTS 1 X997 A ENH: QUANTAR 6809 TRUNKING OPERATION I X87 DEL: CABINET 1 U752 ADD: POWER CORD, 12 FT AC,QTAR 1 X777 ALT:ANALOG SIMULCAST Trailer Trunked Equipment-Audio/Data Distribution 1 DSTRAK91009 REMOTE SITE CON-FIG AC POWER 6 DSTRAK91061 FOUR PORT DDM 4 TDN9714 1/4" CONN N MALE S FLEX PLTD 40 L1700 1/4" SUPERFLEX POLY JKT PER FOOT Trailer Trunked Equipment-RF Mixing and Antennas 1 DSWIJD86204S COMB WAV-G 851-869 4CH 7/16 ANT, 150 KHZ MIN SEP 1 DSWIJD86204S COMB WAV-G 851-869 4CH 7/16 ANT, 150 KHZ MIN SEP 1 DSWIJD86204S COMB WAV-G 851-869 4CH 7/16 ANT, 150 KHZ MIN SEP 1 DSPD504481 FILTER BAND PASS 806-880MHZ CWA,5 MHZ 1 DSPD504481 FILTER BAND PASS 806-880MHZ CWA,5 MHZ 1 DDF1004 NARROW BAND BASE SELECTOR KIT I DSPD504481 FILTER BAND PASS 806-880MHZ CWA, 5 MHZ 1 DS42486A03 AUTOQUAD TTA 806 TO 824 MHZ WITH TRI MODE TEST FEATURE 1 DDX1002 16 PORT EXPANSION KIT Trailer Trunked Equipment- Manual Entries 20 30-82128X02 Trunked Repeater Cable 20 5882653X 1 1 50 Pin RJ45 Adapter Trailer Trunked Equipment- Site Accessories 1 HMN 1001 MICROPHONE, LOCAL TEST, MOBILE,HT90 17 RRX4039A ISB50HNC2MA BULKHEAD ARRESTOR 125-1000 1 DSISDC50LNZ30MA DC INJECTOR 30V M CONN ANTENNA POR 3 DSISCT50HNMA COMBINER COAX PROTECTOR 10 DSOP820B POWER DIST.UNIT SURGE PROTECT 12 DSCBIS14.62572MOT VERTICAL MOUNTED COPPER CONDUCTOR BUS BAR I HSN 1000 6 WATT AMPLIFIED EXTERNAL SPEAKER 1 0182643X14 4 WIRE/ENM INTERFACE PANEL 2 0182643X13 DSM2 INTERFACE PANEL I 0182643X12 DSI INTERFACE PANEL Trailer Prime Equipment-Interconnects and TBars 4 DS58104 SWITCH MODULE A B ONLY 1 DS58084 REDUNDANT PWR ALARM SHELF Contract No. Page 38 Document Version 07/11/05 Rev. 5,07-26-05 City of Fort Worth Emergency Communications Trailer Exhibit C QtY Model Number Description 16 DS58091 BLANK MODULE I DS58044 CONTROL MODULE WITH CONTACT I DS58022 FRAME MASTER 20 CHANNEL Trailer Prime Equipment-Manual Entries 2 TRN7056B ACB Board Contract No. Pagge 39 Docume V, 107 /D5 - YH, r t City Of Fort Worth Emergency Communications Trailer Exhibit C Statement of Work This document, known as the Statement of Work (SOW), describes the deliverables to be furnished to The City of Fort Worth, and the tasks to be performed by Motorola, its subcontractors, and The City of Fort Worth to implement the solution described in this proposal. It describes the actual work involved in installation, identifies the installation standards to be followed, and clarifies the responsibilities for both Motorola and The City of Fort Worth during the project implementation. Specifically, this SOW provides: • A summary of the phases and tasks to be completed within the project lifecycle • A list of the deliverables associated with the project • A description of the responsibilities for both Motorola and The City of Fort Worth • The qualifications and assumptions taken into consideration during the development of this project This SOW provides the most current understanding of the work required by both parties to ensure a successful project implementation. It is understood that this SOW is a working document, and that it will be revised as needed to incorporate any changes associated with contract negotiations, Design Review (DR), and any other change orders that may occur during the execution of the project. Phases and Tasks Based on many years of experience, Motorola has developed a project implementation methodology that identifies major project phases—Contract/Project Initiation, Design Review, Order Processing, Manufacturing, Installation, System Optimization, Acceptance Testing, Subscriber Installation, and Project Finalization. Depending on the particular project, all or some of these phases may be required. A visual representation of these phases is shown in Figure 1. Each phase follows a Work Breakdown Structure (WBS) that clearly identifies the work to be performed during this project. Contract No. Page 40 Document Version 07/11/05 Rev. 5,07-26-05 City of Fort Worth Emergency Communications Trailer Exhibit C L Initiation Design Review Order Project Lifecycle Processing Methodolgy LF ManufacWring LF Installation system Optimization Acceptance Testing Installation Project Finalization Figure 1:Project Lifecycle Methodology. Throughout the duration of this project, Motorola will provide the equipment and services within each phase as described within this proposal. Detailed descriptions of the specific tasks associated with the individual phases are contained in the following sections. Contract/Proiect Initiation The implementation process will begin with the WBS WBS Contract/Project Initiation phase. During this phase, the project teams from Motorola and The 1 Implementation Project City of Fort Worth meet to begin the project. 1.1 Contract/Project Initiation 1.2 Design Review This phase is considered complete when the 1.3 Order Processin Project Kickoff Meeting has been held. 1.4 Manufacturing 1.5 Installation 1.6 System Optimization Identify Team and Administer Proiect 1.7 Acceptance Testing 1.8 Subscriber Installation As the systems integrator, Motorola provides the 2 Project Finalization Contract No. Page 41 Document Version 07/11/05 Rev. 5,07-26-05 City Of Fort Worth Emergency Communications Trailer Exhibit C resources and processes necessary to complete the tasks within this project. Motorola will designate a single individual as the project manager whose primary responsibility and authority will be to manage and administer this project to successful completion as defined within the Communications System Agreement(CSA). This individual is the Motorola point of contact for The City of Fort Worth. The project manager will ensure that all objectives are met within cost and schedule constraints, and provide timely reporting of the overall progress of the project via the refinement of the proposed Project Schedule (DELIVERABLE 1) and project status reports (DELIVERABLE 2). In addition Motorola will ask that The City of Fort Worth identify a single point of contact to represent The City of Fort Worth and be responsible for all The City of Fort Worth signature approvals. Conduct Proiect Kickoff Meeting The project will be initiated with a Project Kickoff Meeting that includes key Fort Worth and Motorola project participants. The date, time, and location of the meeting will be mutually agreed upon between Motorola and The City of Fort Worth. The objectives of this meeting include: ■ Introduction of all project participants ■ Review of the roles of the project participants ■ Review of the overall project scope and objectives ■ Review of the resource and scheduling requirements ■ Review of the project schedule ■ Review of the team interaction, meetings, reports, milestone acceptance, and The City of Fort Worth participation in particular phases Detailed project schedules are integral to the management of the project and will be produced by the Motorola team to provide a timeline analysis for all phases of the project. The final Project Schedule will emphasize all milestones and the critical path, which is essential for the successful completion of the project. The City of Fort Worth and Motorola will mutually agree upon the final schedule. Contract No. Page 42 Document Version 07/11/05 Rev. 5,07-26-05 City Of Fort Worth Emergency Communications Trailer Exhibit C Design Review After the Project Kickoff Meeting, the Motorola WBS WBS and The City of Fort Worth project teams will Element � meet to review the proposed system design. The 1 Implementation Project goal of this review is to achieve written agreement 1-1 Contract/Project Initiation on the overall system design and deliverables. 1.2 Design Review Various design documents will be presented for 1.3 Order Processing approval from The City of Fort Worth. These 1.4 Manufacturing 1.5 Installation documents will form the basis of the system that 1.6 System Optimization will be built, assembled, staged, and installed. This 1.7 Acceptance Testing review is not intended to redesign the system 1.8 Subscriber Installation architecture or to re-evaluate any specifications 2 1 Project Finalization previously reviewed and approved. This phase is considered complete when all documentation deliverables associated with this phase have been delivered to The City of Fort Worth and signed by the designated representative from The City of Fort Worth. Conduct Design Review A Design Review (DR) Meeting will be held with The City of Fort Worth to ensure that all customer requirements are shown in the necessary customer approved documents and that the design meets those requirements. During this meeting, Motorola and The City of Fort Worth will review the operational requirements and the impact of those requirements on various equipment configurations. The goals of this meeting are to establish a firm baseline for the system design, identify any special product requirements and their impact on system implementation, and review the system implementation plan. The system design is "frozen" at this point, in preparation for the subsequent phases of the project such as Order Processing and Manufacturing. A discussion of the Cutover Plan and methods to document a detailed procedure for cutover will begin at this meeting. The results of the DR Meeting will be documented in the Design Documents (DELIVERABLE 3) that may include the updated System Description, programming templates, updated Equipment List, and system drawings or other documents specific to the project. Contract No. Page 43 Document Version 07/11/05 Rev. 5, 07-26-05 City of Fort Worth Emergency Communications Trailer Exhibit C Order Processin The completion of the Design Review phase, WBS WBS resulting in a final design and equipment list that Element � includes any modifications as identified during the 1 Implementation Project DR Meeting, triggers the onset of the Order 1.1 Contract/Project Initiation Processing phase. 1.2 Design Review 1.3 Order Processing Within this phase, the Equipment List goes 1.4 Manufacturing 1.5 Installation through a validation process that checks for valid 1.6 System Optimization model numbers, valid versions, compatible 1.7 Acceptance Testin options to main equipment, current pricing and 1.8 Subscriber Installation delivery data. Validation is not complete until the 2 Project Finalization system verifies that the Equipment List contains the correct model numbers, version, options, pricing, and delivery data. As part of this process, Motorola also confirms with The City of Fort Worth the storage location(s) for this equipment and creates Ship Views. Ship Views are the mailing labels that carry complete shipping information as supplied by The City of Fort Worth. They direct the timing, method of shipment and ship path each item will take to reach their ultimate destination. This makes the tracking of the factory orders more manageable for the project manager and team. The final step within order processing is the creation of the orders for the equipment based on all the information gathered. Once the Equipment List has cleared all validation points, a Motorola Credit Analyst will reconcile the list(s) to the original purchase order or contract. The procurement of third party equipment also takes place during this phase of the project. This phase will be deemed complete when the equipment order is bridged to the manufacturing facility. Manufacturing Based on the equipment order, Motorola will WBS Element WBS manufacture and/or procure the items 1 Implementation Project necessary for the system. For Motorola 1.1 Contract/Project Initiation manufactured equipment, the manufacturing 1.2 Design Review facility will test each subsystem from its base 1.3 Order Processing kit or module level up to the complete 1.4 Manufacturing subsystem at factory staging. In addition to the 1.5 Installation 1.6 System Optimization individual tests applied to all units shipped, 1.7 Acceptance Testing Motorola's Product Quality Engineering 1.8 Subscriber Installation Department performs additional tests on 2 Project Finalization periodic samples. These additional tests include performance tests under environmental extremes (e.g., temperature, humidity, vibration, etc.). Contract No. Page 44 Document Vers } Rev. I` FT, 0NqTH, U6z. City of Fort Worth Emergency Communications Trailer Exhibit C Sta in There is no staging associated with this proposal This phase will be deemed complete when the equipment is ready to be shipped to the field. Installation Once the equipment is received, Motorola will WBS WBS install the equipment per the customer approved Element � design documentation. During field installation of 1 Implementation Project the equipment, any required changes to the 1.1 Contract/Project Initiation installation will be noted and included with the 1.2 Design Review final "as-built" documentation of the system. The 1.3 Order Processing "as-built" documents will berovided along with 1.4 Manufacturing p g 1.5 Installation the maintenance and operator manuals upon 1.6 System Optimization project completion. 1.7 Acceptance Testing 1.8 Subscriber Installation 2 Project Finalization Manage Receipt of Equipment Motorola will ensure that all equipment is sent to a secured storage location, coordinate the receipt of all equipment with The City of Fort Worth point of contact, and inventory all equipment. Install Equipment Motorola will install the equipment included in this project in the trailer. Specifically, Motorola Will bond the supplied equipment to the internal ground system in accordance with the Motorola document Standards and Guidelines for Communication Sites (R56) (DELIVERABLE 4). Will install system equipment in accordance with the Motorola document Standards and Guidelines for Communication Sites (R56) as specified by the Equipment List, System Description and system drawings Contract No. Pale 45 Document Version 07/11/05 Rev. 5, 07-26-05 City of Fort Worth Emergency Communications Trailer Exhibit C System Optimization Optimization of the trailer equipment cannot occur WBS until it is brought on-site and integrated into the Element simulcast system. This task can be completed by 1 Implementation Project either Motorola or City of Fort Worth personnel. 1.1 Contract/Project Initiation The cost for optimization is shown as an optional 1.2 Design Review item. 1.3 Order Processing 1.4 Manufacturing Thishase will be deemed complete when 1.5 Installation p p 1.6 System Optimization Motorola and The City of Fort Worth agree that 1.7 Acceptance Testing the equipment is ready for use. 1.8 Subscriber Installation 2 Project Finalization Configure, Optimize, and Program Equipment Motorola will perform box level testing and diagnostics of the equipment during installation. If the City selects this option, Motorola and its subcontractors will optimize each subsystem individually. Audio and data levels will be checked to verify factory settings. Communication interfaces between devices will be verified for proper operation. Features and functionality will be tested to ensure that they are functioning according to the manufacturer's specifications and per the agreed configuration. The trailer will then be integrated into the simulcast network and optimized as a whole. Training No formal training has been included in this proposal. Acceptance Testing All tests will be performed as described in a WBS WBS Acceptance Test Plan and Acceptance Test Element � Procedures mutually approved during the Design 1 Implementation Project Review phase. This will consist of box level 1.1 Contract/Project Initiation functional testing during the installation and 12 Design Review optimization phases. During acceptance testing, 1.3 Order Processing the system will be tested and the results 1.4 Manufacturing 1.5 Installation documented as defined in the Acceptance Test 1.6 System Optimization Plan. This phase is considered complete when The 1.7 Acceptance Testing City of Fort Worth acknowledges successful 1.8 Subscriber Installation completion of the procedures by signing a System 2 Project Finalization Acceptance Certificate. Contract No. Page 46 Document Version 07/11/05 Rev. 5, 07-26-05 City of Fort Worth Emergency Communications Trailer Exhibit C Review Acceptance Test Procedures The Acceptance Test Procedures (ATP) (DELIVERABLE 6) detail the procedures to be run to confirm that the system provided by Motorola is complete and meets the acceptance test criteria. Each segment will be tested independently using detailed check sheets provided by Motorola, as appropriate, and approved by The City of Fort Worth prior to commencement of acceptance testing. Acceptance testing for the trailer will consist of box level functional and diagnostic testing during installation and programming using manufacturers recommended test procedures. Motorola will review any system testing that The City of Fort Worth wants performed that is not specified in the Acceptance Test Plan and documented in the test procedures. Additional tests may represent a change in the project's scope and may result in a change order to address the supplemental costs to perform the extra tests. Conduct Acceptance Test Motorola will conduct acceptance testing based upon the test documents approved during the Design Review phase. Both Motorola and The City of Fort Worth representatives must witness the conduct of the acceptance test to approve the test(s). Resolutions to any deficiencies found during testing will be agreed upon and documented. If the documented deficiencies do not prevent productive operational use of the system, then the test will be deemed completed. Motorola will remain responsible for the resolution of any documented deficiencies. Upon successful completion of the acceptance test, The City of Fort Worth and Motorola will sign a System Acceptance Certificate. Section 8 of the CSA describes System Acceptance. An example of the Systems Acceptance Certificate can also be found within the CSA. Subscriber Installation Subscribers are not included as part of this offering. Therefore, no tasks are associated with this phase. Contract No. Page 47 Document Versio 0"/; S Rev. 015. City of Fort Worth Emergency Communications Trailer Exhibit C Project Finalization The Project Finalization phase ensures that all WBS WBS criteria for Final Project Acceptance have been Element met. During this phase, Motorola will provide The 1 Implementation Project City of Fort Worth with an electronic System 1.1 Contract/Project Initiation Manual (DELIVERABLE 7), software licenses 1.2 Design Review and necessary software to read the electronic 1.3 Order Processing manuals (DELIVER1.4 Manufacturing 8), and any equipment 1.5 Installation manuals supplied as part of the purchased 1.6 System Optimization equipment (DELIVERABLE 9). 1.7 Acceptance Testing 1.8 Subscriber Installation This phase will be deemed complete when 2 Project Finalization Motorola and The City of Fort Worth sign the Final Project Acceptance portion of the System Acceptance Certificate. Additional information regarding Final Project Acceptance can be found in Section 8 of the CSA. Resolve Punchlist Items Motorola will work with The City of Fort Worth to resolve punchlist items documented during the Acceptance Testing phase and any other phase during project implementation to ensure that all the criteria for final acceptance have been met. Conduct System and Proiect Readiness Review During this task, Motorola conducts a System and Project Readiness Review to obtain concurrence from all Motorola functional groups and The City of Fort Worth that • The factors and plans necessary for the high quality and reliability of the system, its components, installation, testing and training, have been addressed and successfully completed. • The system is ready for beneficial use (cut-over) as a simulcast remote trunked site. • The project is evaluated and assessed to identify any issues that may affect the satisfaction of the end users of the system. Perform System Cutover Motorola and The City of Fort Worth will develop a mutually agreed upon Cutover Plan during the Design Review phase that will be used to implement the cutover process. During cutover, the written plan will be followed and the defined contingencies will be implemented as required. Cutover will consist of bringing the trailer on-site, making external connections (power, interconnect circuits, ground, antennas), optimization, and integration into the existing simulcast network. Contract No. Page 48 Document Version 07/11/05 Rev. 5,07-26-05 City of Fort Worth Emergency Communications Trailer Exhibit C Transfer System to Service Motorola will review the items necessary for transitioning the project to Service. Motorola will provide a Customer Support Plan (DELIVERABLE 10) detailing the warranty associated with the equipment supplied as part of this project. This task will be deemed complete when all service information has been delivered to The City of Fort Worth. Proiect Deliverables Services, equipment, software and documentation are several types of project deliverables Motorola provides as part of this project. Services are specified within this SOW and the equipment is defined within the Equipment List. The documentation and drawings to be developed and delivered as part of this project are described below. Motorola develops documentation and drawings of the system not only to assist with the implementation of the project, but also to provide The City of Fort Worth with reference materials that can be used for training, as a basis for future system upgrades, and even disaster recovery. For these reasons, Motorola creates and updates documentation and drawings during the implementation of the project. Motorola provides a comprehensive "as-built" documentation package in the form of an electronic System Manual. The electronic System Manual contains a description of the system including drawings and equipment lists, screen configurations, site pictures, programming data sheets, final test plans, and warranty information. Table 1 lists each deliverable, describes its contents, states the quantity to be provided, and provides the delivery method. Contract No. Page 49 Document Ver Re . WORTH, TES, City of Fort Worth Emergency Communications Trailer Exhibit C Table I: Project Deliverables. # Title Description Qty Format Type/ Delivery I. Master Project This is the schedule for the 1 Electronic/Email Schedule project that is completed after the Project Kickoff Meeting. 2. Project Status These reports capture the 1 Electronic/Email Reports/Schedule status of the project and will Updates be provided on a basis that is mutually agreed upon by Motorola and The City of Fort Worth. 3. Design The items included within I Electronic/Email Documentation this proposal are further refined and updated to reflect the"as-built"description of the system. This documentation may include documents such as System Description, system drawings,Equipment List, site connectivity,power requirements, document approval process, programming templates, etc. The final information is included as part of the System Manual. 4. Standards and This is a site standard 1 Electronic/CD-ROM Guidelines for recognized in the industry Communication and is provided after contract Sites(R56) award as reference for The City of Fort Worth. 5. Training Plan If training is provided as part I Electronic/Email of this proposal,the Training Plan outlines the details of the training to be provided as part of the project. 6. Acceptance Test Generic Acceptance Test 1 Hardcopy Procedures Procedures are included in this proposal and they are used to perform acceptance testing. These plans are updated during the Design Review phase and will include the results of the testing. Contract No. Page 50 Document Version 07/11/05 Rev. 5, 07-26-05 City Of Fort Worth Emergency Communications Trailer Exhibit C Description Delivery 7. System Manual A document that contains the 2 Electronic/CD ROM final versions of the System Description,Equipment List, drawings,Acceptance Test Procedures,programming templates,and Customer Support Plan. 8. System Manual The software required to 2 Electronic/CD ROM Licenses and view the electronic system Readers manuals. 9. Equipment These are the manuals As As received Manuals provided by the received manufacturer(s)for the equipment that was supplied as part of this project. 10. Customer Support This document outlines the N/A Electronic/CD ROM Plan plan for customer support (provided as part of during the warranty period. System Manual) Notes: a. Hardcopy Format:Printed documentation that may be delivered in person, U.S. mail, Fed Ex, UPS, or any other carrier. b. Electronic Format: Documentation that is in an electronic format and can delivered via . Email, diskette, and/or CD ROM. Responsibilities A successful project requires responsibilities to be managed by both Motorola and The City of Fort Worth. Motorola and The City of Fort Worth responsibilities are outlined throughout this proposal. The information contained within the Equipment List and work defined in this SOW is based on the understanding that certain tasks will be performed by The City of Fort Worth. These tasks are enumerated in the Responsibility Matrix below, which details the tasks that are to be completed by The City of Fort Worth in order to successfully complete the implementation. Contract No. Page 51 Document Version 07/11/05 Rev. 5,07-26-05 City of Fort Worth Emergency Communications Trailer Exhibit C Table 2: Responsibility Matrix. Task Description p1 1 Provide Notice Upon project award,The City of Fort The City of Fort to Proceed Worth needs to officially grant Motorola Worth the Contract. 2 Provide Primary The City of Fort Worth needs to identify The City of Fort Point of Contact an individual as a primary point of contact Worth who will work with the Motorola project manager. 3 Complete Project The City of Fort Worth needs to ensure The City of Fort Scheduled Tasks that tasks assigned to them as agreed upon Worth during the Project Kickoff Meeting are completed on a timely basis. 4 Grant Site The City of Fort Worth needs to provide a The City of Fort Access letter to all owners/managers of sites and Worth provide any keys or other necessary items to allow Motorola or third party personnel to enter all sites within this proposal. 5 Ensure Personnel The City of Fort Worth needs to provide The City of Fort Safety the Motorola project manager with safety Worth rules during the Project Kickoff Meeting. These rules must be followed during the integration phase of this project. The Motorola project manager will also share Motorola's Safety Plan as found in Motorola's Field Operation Safety Manual. Motorola will conduct regular periodic inspections of all active job sites to ensure strict compliance with this Safety Plan as well as any safety rules set forth by The City of Fort Worth. 6 Assist with Site Motorola may require assistance in The City of Fort Access obtaining access to secure sites. Worth 7 Review The City of Fort Worth needs to review The City of Fort Documentation project documentation as it is received to Worth provide feedback for appropriate and timely discussions and or changes. Documentation includes the System Design, Training Plan and course materials,Acceptance Test Plans,and Acceptance Test Procedures. Contract No. Page 52 Document Version 07/11/05 Rev. 5,07-26-05 City of Fort Worth Emergency Communications Trailer Exhibit C Task Description Responsibility 8 Responsibility Third party services and/or equipment The City of Fort for Third Party contracted by The City of Fort Worth are Worth Equipment, the responsibility thereof. Motorola has Software, or responsibility for al] third party services Services provided under this proposal. 9 Provide all AC main and backup power, interconnect The City of Fort external circuits(Tl links),grounding, and Worth equipment antennas(800 MHz and microwave). required for connection to trailer. 10 Procure and The City is to procure and install the The City of Fort install microwave radios and DC power source Worth microwave required. radios and DC power source. 11 Procure 6809 The trailer needs a simulcast 6809 based The City of Fort controller. remote site controller. Worth 12 The City of Fort The connectivity performance standards The City of Fort Worth-provided will be included in a Design Document Worth Site Connectivity developed during the Design Review Equipment Phase. Motorola may test for compliance of the connections prior to commencing installation. 13 Installation, The City of Fort Worth will provide times The City of Fort Acceptance and dates of availability to perform these Worth Tests, and events. Cutover 14 Decommission If not specified in the proposal,The City The City of Fort and Removal of of Fort Worth will decommission and Worth Existing remove the old system. Equipment 15 Communicate The City of Fort Worth needs to The City of Fort Project Changes communicate schedule changes for tasks Worth or phase events, and/or changes to training dates to the project manager to avoid additional costs. Contract No. Page 53 Document Ve e7 aff City of Fort Worth Emergency Communications Trailer Exhibit C Interference Motorola is not responsible for interference caused or received by the Motorola provided equipment except for interference that is directly caused by the Motorola provided transmitter(s) to the Motorola provided receiver(s). Should The City of Fort Worth's system experience interference, Motorola can be contracted to investigate the source and recommend solutions to mitigate the issue. Training Informal training covering the set-up and operation of the trailer will be provided. No formal training classes are included or necessary. System Documentation Fifteen copies of the system documentation will be delivered in hardcopy and softcopy in its native format to ensure that all receiving parties are able to read the documentation. Final copies of the drawings are included in the System Manual in *.dxf electronic format. Upon request, drawings can be delivered in an AutoCAD (*.dwg) format. Contract No. Page 54 Document Version 07/11/05 Rev. 5,07-26-05 City of Fort Worth Emergency Communications Trailer Exhibit C Functional Acceptance Test Plan Overview do not prevent productive operational use of the system, the test will be deemed to have The Functional Acceptance Test Plan been completed. Motorola will, however, (FATP) will be executed at the completion remain responsible for the resolution of the of equipment installation and optimization. remaining deficiencies as agreed. The purpose of this plan is to verify correct system functionality of the Emergency Communications Trailer. Equipment at the Test Objective existing sites will not be tested. These tests are being performed to exercise Representatives of both the City of Fort the basic functionality and operating Worth and Motorola will witness the test parameters of the system as related to Phase and provide sign off upon completion of 2 of the Western Communications Tower each individual test and the summary results Project. of the entire test. The failure of one test in the testing process will be considered a failure of that portion of Methodolo the test only, and not the entire test. The Each test identified in this document shall be individual test or group of the tests affected conducted by a Motorola representative and by the failure will be repeated after witnessed by an authorized City of Fort corrections have been completed. An Worth representative. The results of each acceptance punch list of items to be test will be compared with the test goals and improved or corrected will be created and recorded as Pass/Fail on the record sheets. If tracked to completion. deficiencies are found during the tests, both the deficiencies and the resolutions will be Acce tance Test Procedures agreed on and documented. Any deviations Any system testing that the City of Fort detected during this testing will be corrected Worth wants performed that is not specified by Motorola, retested, and witnessed by the in the ATP listing section may reviewed by City. Motorola for feasibility and acceptability. Any additional tests may represent a change As each test is completed, the Motorola and in the project's scope. Fort Worth representatives will record the date of the test,the test results, and their Each test will be conducted independently initials. The City of Fort Worth and using detailed check sheets to be provided Motorola will sign a statement of by Motorola, as appropriate, and approved conditional acceptance upon successful by the City of Fort Worth prior to completion of this ATP. commencement of acceptance testing. If deficiencies are found during the testing, both the deficiencies and resolutions to the deficiencies shall be agreed upon and documented. Where the defined deficiencies Contract No. Page 55 Document Version 07/11/05 Rev. 5. 07-26-05 City of Fort Worth Emergency Communications Trailer Exhibit C Quantar Hardware Testing Each Quantar repeater supplied as part of this project will be tested and measured during the installation phase. All pertinent station data will be documented as part of the final documentation package. In addition, a full complement of station diagnostics will be performed and critical parameters will be measured and recorded. The sample chart shown on the following page will be completed for each of the 5 Quantars supplied during this phase. Contract No. Page 56 Document Version 07/11/05 Rev. 5,07-26-05 City of Fort Worth Emergency Communications Trailer Exhibit C Sample Quantar Datasheet System ID Customer Name Site name Site number Channel Number/ Name Date of Test Model Number Serial Number Performed by Title Versions Board/Kit# Typical Value/*Note Firmware Version Station Control Board R020.10.513 Station Wireline Board R020.10.001 Station Exciter Board R020.09.005 Station Boot2 Firmware R020.10.001 Station IP address 145.1. Site ID . Chan # Backplane ID *Example 000001 B3BF7B Codeplug Version Date Dependant Transmitter Tests Note Measured Transmitter Frequency Programmed TX Frequency in MHz Reference Oscillator Frequency Error, Measured in Hertz TX Deviation Adjustment Refer to Service Manual / RSS Help Frequency 1 Frequency 2 Frequency 3 Frequency 4 Modulation Compensation Observe Modulation Scope Pass or Fail Frequency 1 Frequency 2 Power Output During Calibration Full PA Output Power 100 Reflected Power at Station Measured in Watts 0 VSWR at Station Auto-Calculated 1.00 Receiver Tests Note Typical Value Measured Receiver Frequency in MHz Refer to Site Doc. N/A 12dB SINAD at Receiver Refer to Service Manual Refer to Service Manual 12dB SINAD at Multicou ler Refer to MOP Same as 12dB SINAD Squelch Setting Refer to Service Manual Site Dependant Wireline Adjustments RSS Programmed Test Set Rx Wireline Test Tone Level 1 kHz Status/Activity Tone Level TX Wireline Input Power Source Note Measured Input Supply Voltage AC or DC input supply voltage Contract No. Page 57 Document Version 07/11/05 Rev. 5, 07-26-05 City of Fort Worth Emergency Communications Trailer Exhibit C SmartNet Trunking Features 2. TEST Talkgoup Call Step 1. Initiate a clear talkgroup call with RADIO-1. 1.DESCRIPTION Step 2. Verify the ISW is decoded by the Central Control ler. The talkgroup call is the primary level of organization Step 3. Verify communication with RADIO-2. for communications on a trunked radio system. Radios with talkgroup call capability will be able to communicate with other members of the same Pass Fail talkgroup. Radio users can select between the different talkgroups that are programmed in the radio using a manual switch or keypad. This test will be completed within the coverage of the Eagle Mountain site to verify that it is processing calls on a random sampling of 5 channels. SETUP RADIO-] - TALKGROUP 1 RADIO-2 - TALKGROUP 1 '� _` � 1 Contract No. Page 58 Document e i 5 fr�6�i , a � , YELL City of Fort Worth Emergency Communications Trailer Exhibit D Exhibit D System Acceptance Certificate Customer Name: Project Name: This System Acceptance Certificate memorializes the occurrence of System Acceptance. Motorola and Customer acknowledge that: 1. The Acceptance Tests set forth in the Acceptance Test Plan have been successfully completed. 2. The System is accepted. Customer Representative: Motorola Representative: Signature: Signature.- Print ignature:Print Name: Print Name: Title: Title: Date: Date: FINAL PROJECT ACCEPTANCE: Motorola has provided and Customer has received all deliverables, and Motorola has performed all other work required for Final Project Acceptance. Customer Representative: Motorola Representative: Signature: Signature: Print Name: Print Name: Title: Title.- Date: itle:Date: Date: Contract No. Page 59 Document V rsi t, 3a�o R City of Fort Worth, Texas Mayor and Council Communication COUNCIL ACTION: Approved on 7/26/2005 DATE: Tuesday, July 26, 2005 LOG NAME: 04WCTTRAILER REFERENCE NO.: **C-2087 , SUBJECT: Authorize Execution of a Sole Source Contract with Motorola Communications Systems for a Mobile Emergency Communications Facility as a Part of the Western Communications Tower Project and for the System-Wide Trunked Radio Network for the Information Technology Solutions Department RECOMMENDATION: It is recommended that the City Council authorize the City Manager to execute a contract with Motorola Communications Systems for a mobile emergency communications facility as a part of the Western Communications Tower Project and for the system-wide trunked radio network for the Information Technology Solutions Department at a cost not to exceed $525,000.00. DISCUSSION: The purpose of this proposed purchase contract is to enhance the system-wide trunked radio network coverage for public safety by providing a mobile emergency communications facility. Initially, the mobile facility will be used at the Western Communications Tower (WCT) and then it will be available for Homeland Security and Disaster Recovery issues. BACKGROUND: The WCT project is being developed to support delivery of radio communication services to the Lake Country Estates area, the general western segment of Fort Worth to the Parker County line and the City's Extraterritorial Jurisdiction in northwest Tarrant County. The Information Technology Solutions Department (IT Solutions) is coordinating the development of the new communications tower, which will be located at the Eagle Mountain Water Treatment Plant. This project was funded by the sale of $2.6 million in Certificates of Obligation and a $2.6 million allocation from the Crime Control and Prevention District (M&C G-13558), for a total project budget of $5.2 million. The WCT site is an extension of the existing digital microwave radio system, the public safety trunked radio system, and the mobile data system infrastructure. Motorola is the sole source vendor due to the proprietary operation and design of the Motorola SmartNet II infrastructure. As a result, only Motorola Communications Systems can manufacture, deliver and install the infrastructure components. FACILITY OVERVIEW: The new Motorola mobile emergency communications facility will contain all the necessary equipment for a complete trunked radio site and it is compatible with the existing infrastructure. The mobile facility will be 28 feet long, 8 feet wide and the inside ceiling height will be 8 feet. It will have external connections for power, grounding, control/data circuits, and antenna Radio Frequency (RF) cables. The mobile facility contains equipment for a 9-channel trunked simulcast site with no conventional channels. The mobile facility will be Logname: 04WCTTRAILER Page 1 of 2 equipped and wired to ultimately accommodate 20 trunked channels, 5 UHF channels, and 7 VHF channels. The mobile communication facility will initially be used at the WCT site to provide temporary communication services until the tower project is completed and activated. Due to the growth in the northwestern and western segments of Fort Worth, the need to establish communications support for public safety services warrants the interim portable solution. Thereafter, the mobile communications facility can be used to provide emergency services in the event of a disaster or major interruptions of service at one of the other 10 remote telecommunications tower sites. It is anticipated that through future grant opportunities, the mobile emergency communications facility will be equipped with additional electronics and communications capabilities. PROJECT BUDGET: Since November 30, 2004, the City Council has approved four M&Cs (C-20424, C-20449, P-10086 and C- 20833) pertaining to the WCT Project. The approved actions were for radio communications equipment, construction of the tower, and construction of an equipment facility. For Homeland Security and disaster response reasons, the mobile emergency communication facility has been incorporated into this project. The approval of this M&C will facilitate the site being functional this Fall. Additionally, the mobile facility will provide the City with an emergency option not previously available. The following information is a recap of the WCT Project Budget as originally developed in mid 2000, and its current status: Project CategorX Ori inal Budget Re-Estimate Notes 1. Land $110,000.00 $0.00 No land acquisition costs 2. Tower and Components $891,000.00 $940,915.00 Microwave expansion cost higher than anticipated 3. Radio System Modifications " $3,763,000.00 $3,179,403.00 ** Contract savings 4. Facility Development $276,000.00 $1,054,682.00 Some costs originally budgeted in 2&3 5. Professional Work $160,000,00 $25 000_00 Savings from use of City staff Totals $5,200,000.00 $5,200,000.00 **The cost of the mobile emergency communication facility is included in the total for this expenditure category. The WCT project is located in Council District 7; the emergency communication facility will be utilized throughout the City. M/WBE — A waiver of the goal for MINVBE subcontracting requirements was requested and approved by the M/WBE Office because the purchase of goods and services is from sources where subcontracting or supplier opportunities are negligible. FISCAL INFORMATION/CERTIFICATION: The Finance Director certifies that the funds are available in the current capital budget, as appropriated, of the Fire Services Fund. TO Fund/Account/Centers FROM Fund/Account/Centers C132 541390 004132001001 $525 000.00 Submitted for City Manager's_Office_b Richard Zavala (Acting) (6222) Originating Department Head: Peter Anderson (8781) Additional Information Contact: Peter Ungar (7889)Mark Bottorff(8750) Logname: 04WCTTRAILER Page 2 of 2