Loading...
HomeMy WebLinkAboutContract 35525 `-71-7ETARY CITY OF FORT WORTH, TEXAS --,'-;T No. STANDARD AGREEMENT FOR ENGINEERING SERVICES This AGREEMENT is between the City of Fort Worth (the "CITY"), and Teague Nall & Perkins, Inc., (the "ENGINEER"), for a PROJECT generally described as: Storm Water Utility Project — Lebow Channel Roadway Crossing Replacement at Brennan Street, 28th Street and Dewey Avenue Article I Scope of Services A. The Scope of Services is set forth in Attachment A. Article II Compensation A. The ENGINEER's compensation is set forth in Attachment B. Article III Terms of Payment Payments to the ENGINEER will be made as follows: A. Invoice and Payment (1) The Engineer shall provide the City sufficient documentation to reasonably substantiate the invoices. (2) The ENGINEER will issue monthly invoices for all work performed under this AGREEMENT. Invoices are due and payable within 30 days of receipt. (3) Upon completion of services enumerated in Article I, the final payment of any balance will be due within 30 days of receipt of the final invoice. (4) In the event of a disputed or contested billing, only that portion so contested will be withheld from payment, and the undisputed portion will be paid. The CITY will exercise reasonableness in contesting any bill or portion thereof. No interest will accrue on any contested portion of the billing until mutually resolved. (5) If the CITY fails to make payment in full to ENGINEER for billings contested in good faith within 60 days of the amount due, the ENGINEER may, after giving 7 days' written notice to CITY, suspend services under this AGREEMENT until paid in full, including interest. In the event of suspension of services, the ENGINEER shall have no liability to CITY for delays or damages caused the STANDARD ENGINEERING AGREEMENT(REV 10/06/05) Page 1 of 20 s ORIGINAL i J Il V,IJ CITY because of such suspension of services. Article IV Obligations of the Engineer Amendments to Article IV, if any, are included in Attachment C. A. General The ENGINEER will serve as the CITY's professional engineering representative under this Agreement, providing professional engineering consultation and advice and furnishing customary services incidental thereto. B. Standard of Care The standard of care applicable to the ENGINEER's services will be the degree of skill and diligence normally employed in the State of Texas by professional engineers or consultants performing the same or similar services at the time such services are performed. C. Subsurface Investigations (1) The ENGINEER shall advise the CITY with regard to the necessity for subcontract work such as special surveys, tests, test borings, or other subsurface investigations in connection with design and engineering work to be performed hereunder. The ENGINEER shall also advise the CITY concerning the results of same. Such surveys, tests, and investigations shall be furnished by the CITY, unless otherwise specified in Attachment A. (2) In soils, foundation, groundwater, and other subsurface investigations, the actual characteristics may vary significantly between successive test points and sample intervals and at locations other than where observations, exploration, and investigations have been made. Because of the inherent uncertainties in subsurface evaluations, changed or unanticipated underground conditions may occur that could affect the total PROJECT cost and/or execution. These conditions and cost/execution effects are not the responsibility of the ENGINEER. D. Preparation of Engineering Drawings The ENGINEER will provide to the CITY the original drawings of all plans in ink on reproducible plastic film sheets, or as otherwise approved by CITY, which shall become the property of the CITY. CITY may use such drawings in any manner it desires; provided, however, that the ENGINEER shall not be liable for the use of such drawings for any project other than the PROJECT described herein. STANDARD ENGINEERING AGREEMENT(REV 10/06/05) Page 2 of 20 E. Engineer's Personnel at Construction Site (1) The presence or duties of the ENGINEER's personnel at a construction site, whether as on-site representatives or otherwise, do not make the ENGINEER or its personnel in any way responsible for those duties that belong to the CITY and/or the C11-Y's construction contractors or other entities, and do not relieve the construction contractors or any other entity of their obligations, duties, and responsibilities, including, but not limited to, all construction methods, means, techniques, sequences, and procedures necessary for coordinating and completing all portions of the construction work in accordance with the Contract Documents and any health or safety precautions required by such construction work. The ENGINEER and its personnel have no authority to exercise any control over any construction contractor or other entity or their employees in connection with their work or any health or safety precautions. (2) Except to the extent of specific site visits expressly detailed and set forth in Attachment A, the ENGINEER or its personnel shall have no obligation or responsibility to visit the construction site to become familiar with the progress or quality of the completed work on the PROJECT or to determine, in general, if the work on the PROJECT is being performed in a manner indicating that the PROJECT, when completed, will be in accordance with the Contract Documents, nor shall anything in the Contract Documents or the agreement between CITY and ENGINEER be construed as requiring ENGINEER to make exhaustive or continuous on-site inspections to discover latent defects in the work or otherwise check the quality or quantity of the work on the PROJECT. If, for any reason, the ENGINEER should make an on-site observation(s), on the basis of such on-site observations, if any, the ENGINEER shall endeavor to keep the CITY informed of any deviation from the Contract Documents coming to the actual notice of ENGINEER regarding the PROJECT. (3) When professional certification of performance or characteristics of materials, systems or equipment is reasonably required to perform the services set forth in the Scope of Services, the ENGINEER shall be entitled to rely upon such certification to establish materials, systems or equipment and performance criteria to be required in the Contract Documents. F. Opinions of Probable Cost, Financial Considerations, and Schedules (1) The ENGINEER shall provide opinions of probable costs based on the current available information at the time of preparation, in accordance with Attachment A. (2) In providing opinions of cost, financial analyses, economic feasibility projections, and schedules for the PROJECT, the ENGINEER has no control over cost or price of labor and materials; unknown or latent conditions of existing equipment or structures that may affect operation or STANDARD ENGINEERING AGREEMENT(REV 10/06/05) Page 3 of 20 maintenance costs; competitive bidding procedures and market conditions; time or quality of performance by third parties; quality, type, management, or direction of operating personnel; and other economic and operational factors that may materially affect the ultimate PROJECT cost or schedule. Therefore, the ENGINEER makes no warranty that the CITY's actual PROJECT costs, financial aspects, economic feasibility, or schedules will not vary from the ENGINEER's opinions, analyses, projections, or estimates. G. Construction Progress Payments Recommendations by the ENGINEER to the CITY for periodic construction progress payments to the construction contractor will be based on the ENGINEER's knowledge, information, and belief from selective sampling and observation that the work has progressed to the point indicated. Such recommendations do not represent that continuous or detailed examinations have been made by the ENGINEER to ascertain that the construction contractor has completed the work in exact accordance with the Contract Documents; that the final work will be acceptable in all respects; that the ENGINEER has made an examination to ascertain how or for what purpose the construction contractor has used the moneys paid; that title to any of the work, materials, or equipment has passed to the CITY free and clear of liens, claims, security interests, or encumbrances; or that there are not other matters at issue between the CITY and the construction contractor that affect the amount that should be paid. H. Record Drawings Record drawings, if required, will be prepared, in part, on the basis of information compiled and furnished by others, and may not always represent the exact location, type of various components, or exact manner in which the PROJECT was finally constructed. The ENGINEER is not responsible for any errors or omissions in the information from others that is incorporated into the record drawings. I. Minority and Woman Business Enterprise (M/WBE) Participation In accord with City of Fort Worth Ordinance No. 15530, the City has goals for the participation of minority business enterprises and woman business enterprises in City contracts. Engineer acknowledges the M/WBE goal established for this contract and its commitment to meet that goal. Any misrepresentation of facts (other than a negligent misrepresentation) and/or the commission of fraud by the Engineer may result in the termination of this agreement and debarment from participating in City contracts for a period of time of not less than three (3) years. STANDARD ENGINEERING AGREEMENT(REV 10/06/05) Page 4 of 20 J. Right to Audit (1) ENGINEER agrees that the CITY shall, until the expiration of three (3) years after final payment under this contract, have access to and the right to examine and photocopy any directly pertinent books, documents, papers and records of the ENGINEER involving transactions relating to this contract. ENGINEER agrees that the CITY shall have access during normal working hours to all necessary ENGINEER facilities and shall be provided adequate and appropriate work space in order to conduct audits in compliance with the provisions of this section. The CITY shall give ENGINEER reasonable advance notice of intended audits. (2) ENGINEER further agrees to include in all its subconsultant agreements hereunder a provision to the effect that the subconsultant agrees that the CITY shall, until the expiration of three (3) years after final payment under the subcontract, have access to and the right to examine and photocopy any directly pertinent books, documents, papers and records of such subconsultant, involving transactions to the subcontract, and further, that the CITY shall have access during normal working hours to all subconsultant facilities, and shall be provided adequate and appropriate work space, in order to conduct audits in compliance with the provisions of this article together with subsection (3)hereof. CITY shall give subcon-sultant reasonable advance notice of intended audits. (3) ENGINEER and subconsultant agree to photocopy such documents as may be requested by the CITY. The CITY agrees to reimburse ENGINEER for the cost of copies at the rate published in the Texas Administrative Code in effect as of the time copying is performed. K. ENGINEER's Insurance (1) Insurance coverage and limits: ENGINEER shall provide to the City certificate(s) of insurance documenting policies of the following coverage at minimum limits that are to be in effect prior to commencement of work on the PROJECT: Commercial General Liability $1,000,000 each occurrence $2,000,000 aggregate Automobile Liability $1,000,000 each accident on a combined single limit or $250,000 Property Damage $500,000 Bodily Injury per person per occurrence STANDARD ENGINEERING AGREEMENT(REV 10/06/05) Page 5 of 20 A commercial business policy shall provide coverage on "Any Auto", defined as autos owned, hired and non-owned when said vehicle is used in the course of the PROJECT. Worker's Compensation Coverage A: Statutory limits Coverage B: Employer's Liability $100,000 each accident $500,000 disease - policy limit $100,000 disease- each employee Professional Liability $1,000,000 each claim $2,000,000 aggregate Professional liability shall be written on a claims-made basis and shall contain a retroactive date prior to the date of the contract or the first date of services to be performed, whichever is earlier. Coverage shall be maintained for a period of 5 years following the completion of the contract. An annual certificate of insurance specifically referencing this project shall be submitted to the City for each year following completion of the contract. (2) Certificates of insurance evidencing that the ENGINEER has obtained all required insurance shall be delivered to the CITY prior to ENGINEER proceeding with the PROJECT. (a) Applicable policies shall be endorsed to name the CITY an Additional Insured thereon, as its interests may appear. The term CITY shall include its employees, officers, officials, agents, and volunteers as respects the contracted services. (b) Certificate(s) of insurance shall document that insurance coverage specified in this agreement are provided under applicable policies documented thereon. (c) Any failure on part of the CITY to request required insurance documentation shall not constitute a waiver of the insurance requirements. (d) A minimum of forty-five (45) days notice of cancellation or material change in coverage shall be provided to the CITY. A ten (10) days notice shall be acceptable in the event of non-payment of premium. Such terms shall be endorsed onto ENGINEER's insurance policies. Notice shall be sent to the respective Department Director (by name), City of Fort Worth, 1000 Throckmorton, Fort Worth, Texas 76102. STANDARD ENGINEERING AGREEMENT(REV 10/06/05) Page 6 of 20 (e) Insurers for all policies must be authorized to do business in the State of Texas and have a minimum rating of A: VII in the current A.-M. Best Key Rating Guide or have reasonably equivalent financial strength and solvency to the satisfaction of Risk Management. (f) Deductible limits, or self insured retentions, affecting insurance required herein shall be acceptable to the CITY in its sole discretion; and, in lieu of traditional insurance, any alternative coverage maintained through insurance pools or risk retention groups must be also approved. Dedicated financial resources or letters of credit may also be acceptable to the City. (g) Applicable policies shall each be endorsed with a waiver of subrogation in favor of the CITY as respects the PROJECT. (h) The City shall be entitled, upon its request and without incurring expense, to review the ENGINEER's insurance policies including endorsements thereto and, at the CITY's discretion, the ENGINEER may be required to provide proof of insurance premium payments. Commercial General Liab jitY insurance poticy shall have 7ho exclusions by endorseme»ts 'unless the:G,ITY.."approves such exclusions mwriting., (j) For all lines of coverage underwritten on a claims-made basis, other than Professional Liability, the retroactive date shall be coincident with or prior to the date of the contractual agreement. The certificate of insurance shall state both the retroactive date and that the coverage is claims- made. (k) The CITY shall not be responsible for the direct payment of any insurance premiums required by this agreement and all insurance required in this section, with the exception of Professional Liability, shall be written on an occurrence basis. (1) Sub consultants and subcontractors to/of the ENGINEER shall be required by the ENGINEER to maintain the same or reasonably equivalent insurance coverage as required for the ENGINEER. When sub consultants/subcontractors maintain insurance coverage, ENGINEER shall provide CITY with documentation thereof on a certificate of insurance. L. Independent Consultant The ENGINEER agrees to perform all services as an independent consultant and not as a subcontractor, agent, or employee of the CITY. STANDARD ENGINEERING AGREEMENT(REV 10/06/05) Page 7 of 20 M. Disclosure The ENGINEER acknowledges to the CITY that it has made full disclosure in writing of any existing conflicts of interest or potential conflicts of interest, including personal financial interest, direct or indirect, in property abutting the proposed PROJECT and business relationships with abutting property cities. The ENGINEER further acknowledges that it will make disclosure in writing of any conflicts of interest that develop subsequent to the signing of this contract and prior to final payment under the contract. N. Asbestos or Hazardous Substances (1) If asbestos or hazardous substances in any form are encountered or suspected, the ENGINEER will stop its own work in the affected portions of the PROJECT to permit testing and evaluation. (2) If asbestos or other hazardous substances are suspected, the ENGINEER will, if requested, assist the CITY in obtaining the services of a qualified subcontractor to manage the remediation activities of the PROJECT. O. Permitting Authorities - Design Changes If permitting authorities require design changes so as to comply with published design criteria and/or current engineering practice standards which the ENGINEER should have been aware of at the time this Agreement was executed, the ENGINEER shall revise plans and specifications, as required, at its own cost and expense. However, if design changes are required due to the changes in the permitting authorities' published design criteria and/or practice standards criteria which are published after the date of this Agreement which the ENGINEER could not have been reasonably aware of, the ENGINEER shall notify the CITY of such changes and an adjustment in compensation will be made through an amendment to this AGREEMENT. Article V Obligations of the City Amendments to Article V, if any, are included in Attachment C. A. City-Furnished Data ENGINEER may rely upon the accuracy, timeliness, and completeness of the information provided by the CITY. STANDARD ENGINEERING AGREEMENT(REV 10/06/05) Page 8 of 20 B. Access to Facilities and Property The CITY will make its facilities accessible to the ENGINEER as required for the ENGaNEER's performance of its services and will provide labor and safety equipment as required by the ENGINEER for such access. The CITY will perform, at no cost to the ENGINEER, such tests of equipment, machinery, pipelines, and other components of the CITY's facilities as may be required in connection with the ENGINEER's services. The CITY will be responsible for all acts of the CITY's personnel. C. Advertisements, Permits, and Access Unless otherwise agreed to in the Scope of Services, the CITY will obtain, arrange, and pay for all advertisements for bids; permits and licenses required by local, state, or federal authorities; and land, easements, rights-of-way, and access necessary for the ENGINEER's services or PROJECT construction. D. Timely Review The CITY will examine the ENGINEER's studies, reports, sketches, drawings, specifications, proposals, and other documents; obtain advice of an attorney, insurance counselor, accountant, auditor, bond and financial advisors, and other consultants as the CITY deems appropriate; and render in writing decisions required by the CITY in a timely manner in accordance with the project schedule in Attachment A. E. Prompt Notice The CITY will give prompt written notice to the ENGINEER whenever CITY observes or becomes aware of any development that affects the scope or timing of the ENGINEER's services or of any defect in the work of the ENGINEER or construction contractors. F. Asbestos or Hazardous Substances Release. (1) CITY acknowledges ENGINEER will perform part of the work at CITY's facilities that may contain hazardous materials, including asbestos containing materials, or conditions, and that ENGINEER had no prior role in the generation, treatment, storage, or disposition of such materials. In consideration of the associated risks that may give rise to claims by third parties or employees of City, City hereby releases ENGINEER from any damage or liability related to the presence of such materials. (2) The release required above shall not apply in the event the discharge, release or escape of hazardous substances, contaminants, or asbestos is a result of ENGINEER's negligence or if ENGINEER brings such hazardous substance, contaminant or asbestos onto the project. STANDARD ENGINEERING AGREEMENT(REV 10/06/05) Page 9 of 20 G. Contractor Indemnification and Claims The CITY agrees to include in all construction contracts the provisions of Article W.E. regarding the ENGINEER's Personnel at Construction Site, and provisions providing contractor indemnification of the CITY and the ENGINEER for contractor's negligence. H. Contractor Claims and Third-Party Beneficiaries (1) The CITY agrees to include the following clause in all contracts with construction contractors and equipment or materials suppliers: "Contractors, subcontractors and equipment and materials suppliers on the PROJECT, or their sureties, shall maintain no direct action against the ENGINEER, its officers, employees, and subcontractors, for any claim arising out of, in connection with, or resulting from the engineering services performed. Only the CITY will be the beneficiary of any undertaking by the ENGINEER." (2) This AGREEMENT gives no rights or benefits to anyone other than the CITY and the ENGINEER and there are no third-party beneficiaries. (3) The CITY will include in each agreement it enters into with any other entity or person regarding the PROJECT a provision that such entity or person shall have no third-party beneficiary rights under this Agreement. (4) Nothing contained in this section V.H. shall be construed as a waiver of any right the CITY has to bring a claim against ENGINEER. I. CITY's Insurance (1) The CITY may maintain property insurance on certain pre-existing structures associated with the PROJECT. (2) The CITY will ensure that Builders Risk/Installation insurance is maintained at the replacement cost value of the PROJECT. The CITY may provide ENGINEER a copy of the policy or documentation of such on a certificate of insurance. (3) The CITY will specify that the Builders Risk/Installation insurance shall be comprehensive in coverage appropriate to the PROJECT risks. J. Litigation Assistance The Scope of Services does not include costs of the ENGINEER for required or requested assistance to support, prepare, document, bring, defend, or STANDARD ENGINEERING AGREEMENT(REV 10/06/05) Page 10 of 20 assist in litigation undertaken or defended by the CITY. In the event CITY requests such services of the ENGINEER, this AGREEMENT shall be amended or a separate agreement will be negotiated between the parties. K. Changes The CITY may make or approve changes within the general Scope of Services in this AGREEMENT. If such changes affect the ENGINEER's cost of or time required for performance of the services, an equitable adjustment will be made through an amendment to this AGREEMENT with appropriate CITY approval. Article VI General Legal Provisions Amendments to Article VI, if any, are included in Attachment C. A. Authorization to Proceed ENGINEER shall be authorized to proceed with this AGREEMENT upon receipt of a written Notice to Proceed from the CITY. B. Reuse of Project Documents All designs, drawings, specifications, documents, and other work products of the ENGINEER, whether in hard copy or in electronic form, are instruments of service for this PROJECT, whether the PROJECT is completed or not. Reuse, change, or alteration by the CITY or by others acting through or on behalf of the CITY of any such instruments of service without the written permission of the ENGINEER will be at the CITY's sole risk. The CITY shall own the final designs, drawings, specifications and documents. C. Force Majeure The ENGINEER is not responsible for damages or delay in performance caused by acts of God, strikes, lockouts, accidents, or other events beyond the control of the ENGINEER. D. Termination (1) This AGREEMENT may be terminated only by the City for convenience on 30 days' written notice. This AGREEMENT may be terminated by either the CITY or the ENGINEER for cause if either party fails substantially to perform through no fault of the other and does not commence correction of such nonperformance with 5 days of written notice and diligently complete the correction thereafter. STANDARD ENGINEERING AGREEMENT(REV 10/06/05) Page 11 of 20 (2) If this AGREEMENT is terminated for the convenience of the City, the ENGINEER will be paid for termination expenses as follows: a.) Cost of reproduction of partial or complete studies, plans, specifications or other forms of ENGINEER'S work product; b.) Out-of-pocket expenses for purchasing storage containers, microfilm, electronic data files, and other data storage supplies or services; c.) The time requirements for the ENGINEER'S personnel to document the work underway at the time the CITY'S termination for convenience so that the work effort is suitable for long time storage. (3) Prior to proceeding with termination services, the ENGINEER will submit to the CITY an itemized statement of all termination expenses. The CITY'S approval will be obtained in writing prior to proceeding with termination services. E. Suspension, Delay, or Interruption to Work The CITY may suspend, delay, or interrupt the services of the ENGINEER for the convenience of the CITY. In the event of such suspension, delay, or interruption, an equitable adjustment in the PROJECT's schedule, commitment and cost of the ENGINEER's personnel and subcontractors, and ENGINEER's compensation will be made. F. Indemnification (1) The ENGINEER agrees to indemnify and defend the CITY from any loss, cost, or expense claimed by third parties for property damage and bodily injury, including death, caused solely by the negligence or willful misconduct of the ENGINEER, its employees, officers, and subcontractors in connection with the PROJECT. (2) If the negligence or willful misconduct of both the ENGINEER and the CITY (or a person identified above for whom each is liable) is a cause of such damage or injury, the loss, cost, or expense shall be shared between the ENGINEER and the CITY in proportion to their relative degrees of negligence or willful misconduct as determined pursuant to T.C.P. & R. Code, section 33.011(4) (Vernon Supplement 1996). G. Assignment Neither party shall assign all or any part of this AGREEMENT without the prior written consent of the other party. STANDARD ENGINEERING AGREEMENT(REV 10/06/05) Page 12 of 20 H. Interpretation Limitations on liability and indemnities in this AGREEMENT are business understandings between the parties and shall apply to all the different theories of recovery, including breach of contract or warranty, tort including negligence, strict or statutory liability, or any other cause of action, except for willful misconduct or gross negligence for limitations of liability and sole negligence for indemnification. Parties mean the CITY and the ENGINEER, and their officers, employees, agents, and subcontractors. I. Jurisdiction The law of the State of Texas shall govern the validity of this AGREEMENT, its interpretation and performance, and any other claims related to it. The venue for any litigation related to this AGREEMENT shall be Tarrant County, Texas. J. Alternate Dispute Resolution (1) All claims, disputes, and other matters in question between the CITY and ENGINEER arising out of, or in connection with this Agreement or the PROJECT, or any breach of any obligation or duty of CITY or ENGINEER hereunder, will be submitted to mediation. If mediation is unsuccessful, the claim, dispute or other matter in question shall be submitted to arbitration if both parties acting reasonably agree that the amount of the dispute is likely to be less than $50,000, exclusive of attorney's fees, costs and expenses. Arbitration shall be in accordance with the Construction Industry Arbitration Rules of the American Arbitration Association or other applicable rules of the Association then in effect. Any award rendered by the arbitrators less than $50,000, exclusive of attorney's fees, costs and expenses, will be final, judgment may be entered thereon in any court having jurisdiction, and will not be subject to appeal or modification except to the extent permitted by Sections 10 and 11 of the Federal Arbitration Act (9 U.S.C. Sections 10 and 11). (2) Any award greater than $50,000, exclusive of attorney's fees, costs and expenses, may be litigated by either party on a de novo basis. The award shall become final ninety (90) days from the date same is issued. If litigation is filed by either party within said ninety (90) day period, the award shall become null and void and shall not be used by either party for any purpose in the litigation. K. Severability and Survival If any of the provisions contained in this AGREEMENT are held for any reason to be invalid, illegal, or unenforceable in any respect, such invalidity, illegality, or unenforceability will not affect any other provision, and this AGREEMENT shall be construed as if such invalid, illegal, or unenforceable provision had never been contained herein. Articles V.F., VI.B., VI.D., VI.H., VI.I., and VI.J. STANDARD ENGINEERING AGREEMENT(REV 10/06/05) Page 13 of 20 shall survive termination of this AGREEMENT for any cause. L. Observe and Comply ENGINEER shall at all times observe and comply with all federal and State laws and regulations and with all City-ordinances and regulations which in any way affect this AGREEMENT and the work hereunder-, and shall observe and comply with all orders, laws ordinances and regulations which may exist or may be enacted during the term of this AGREEMENT by governing bodies having jurisdiction or authority for such enactment. No plea of misunderstanding- or ignorance thereof shall be considered. ENGINEER agrees to defend, indemnify and hold harmless CITY and all of its officers, agents and employees from and against all claims or liability arising out of the violation of any such order, law, ordinance, or regulation, whether it be by itself or its employees. STANDARD ENGINEERING AGREEMENT(REV 10/06/05) Page 14 of 20 Article VII Attachments, Schedules, and Signatures This AGREEMENT, including its attachments and schedules, constitutes the entire AGREEMENT, supersedes all prior written or oral understandings, and may only be changed by a written amendment executed by both parties. The following attachments and schedules are hereby made a part of this AGREEMENT: Attachment A - Scope of Services Attachment B — Compensation Attachment C -Amendments to Standard Agreement for Engineering Services Attachment D - Project Schedule Attachment E - Location Map I Executed this theday of l , 20 q ATTEST: CITY FORT WOR H By. ., �l Marty Hendrix arc A. O City Secret��aii''ryy It� Assistant City Manager 'deo'-i I9 APPROVAL RECOMMENDED Contract Authorization --- A. Douglas Rademaker, P.E. Date Director, Engineering Department APPR V D AS TO O Prrou LEGALITY As ' tdnt Ity o ey �- Teague Nall R Perkins, I11G ENGINEER i ATTEST _ /f c By. Ai 'A NAME: Tyra, P 1= TITLE: Vire President STANDARD ENGINEERING AGREEMENT(REV 10/06/05) Page 15 of 20 � �J.IS ATTACHMENT General Smile Qf Services "Scope of Services set forth herein can only be modified by additions, clarifications, and/or deletions set forth in the supplemental Scope of Services. In cases of conflict between the Supplemental Scope of Services and the General Scope of Services, the Supplemental Scope of Services shall have precedence over the General Scope of Services." GENERAL 1) Preliminary Conference with City The Engineer shall attend preliminary conferences with authorized representatives of the City regarding the scope of project so that the plans and specifications which are to be developed hereunder by the Engineer will result in providing facilities which are economical in design and conform to the City's requirements and budgetary constraints. 2) Coordination with Outside Agencies/Public Entities The Engineer shall coordinate with officials of other outside agencies as may be necessary for the design of the proposed street, and storm drain and/or water and wastewater facili- ties/improvements. It shall be the Engineer's duty hereunder to secure necessary information from such outside agencies, to meet their requirements. 3) Geotechnical Investigations The Engineer shall advise the City of test borings, and other subsurface investigations that may be needed. In the event it is determined necessary to make borings or excavate test holes or pits, the Engineer shall in coordination with the City and the City's geotechnical engineering consultant, draw up specifications for such testing program. The cost of the borings or excavations shall be paid for by the City. 4) Agreements and Permits The Engineer shall complete all forms/applications to allow the City of Fort Worth to obtain any and all agreements and/or permits normally required for a project of this size and type. The Engineer will be responsible for negotiating and coordinating to obtain approval of the agency issuing the agreement and/or permits and will make any revisions necessary to bring the plans into compliance with the requirements of said agency, including but not limited to highways, railroads, water authorities, Corps of Engineers and other utilities. 5) Design Changes Relating to Permitting Authorities If permitting authorities require design changes, the Engineer shall revise the plans and specifications as required at the Engineers own cost and expense, unless such changes are required due to changes in the design of the facilities made by the permitting authority. If such changes are required, the Engineer shall notify the City and an amendment to the STANDARD ENGINEERING AGREEMENT(REV 10/06/05) Page 16 of 20 r contract shall be made if the Engineer incurs additional cost. If there are unavoidable delays, a mutually agreeable and reasonable time extension shall be negotiated. 6) Plan Submittal Copies of the original plans shall be provided on reproducible mylar or approved plastic film sheets, or as otherwise approved by the Department of Engineering and shall become the property of the City. City may use such drawings in any manner it desires; provided, however that the Engineer shall not be liable for the use of such drawings for-any project other than the project described herein; and further provided, that the Engineer shall not be liable for the consequences of any changes that are made to the drawings or changes that are made in the implementation of the drawings without the written approval of the Engineer. PHASE 1 7) Right-of-Way, Easement and Land Acquisition Needs The Engineer shall determine the rights-of-way, easement needs for the construction of the project. Engineer shall determine ownership of such land and furnish the City with the necessary right-of-way sketches, prepare necessary easement descriptions for acquiring the rights-of-way and/or easements for the construction of this project. Sketches and easement descriptions are to be presented in form suitable for direct use by the Department of Engineering in obtaining rights-of-way, easements, permits and licensing agreements. All materials shall be furnished on the appropriate City forms in a minimum of four (4) copies each. 8) Design Survey The Engineer shall provide necessary field survey for use in the preparation of Plans and Specifications. The Engineer shall furnish the City certified copies of the field data. 9) Utility Coordination The Engineer shall coordinate with all utilities, including utilities owned by the City, as to any proposed utility liens or adjustment to existing utility lines within the project limits. The information obtained shall be shown on the conceptual plans. The Engineer shall show on the preliminary and final plans the location of the proposed utility lines, existing utility lines, based on the information provided by the utility, and any adjustments and/or relocation of the existing lines within the project limits. The Engineer shall also evaluate the phasing of the water, wastewater, street and drainage work, and shall submit such evaluation in writing to the City as part of this phase of the project. STANDARD ENGINEERING AGREEMENT(REV 10/06/05) Page 17 of 20 10) Conceptual Plans The Engineer shall furnish four (4) copies of the Phase 1 concept engineering plans which include layouts, preliminary right-of-way needs and preliminary estimates of probable construction costs for the Engineer's recommended plan. For all submittals, the Engineer shall submit plans and documents for street/storm drain and waterlwastewater facilities. The Engineer shall receive written approval of the Phase 1 Plans from the City's project manager before proceeding with Phase 2. PHASE 2 11) Design Data The Engineer shall provide design data, reports, cross-sections, profiles, drainage calculations, and preliminary estimates of probable construction cost. 12) Preliminary Construction Plans and Technical Specifications The Engineer shall submit twenty (20) copies of Phase 2 preliminary construction plans and five (5) copies of the preliminary technical specifications for review by the City and for submission to utility companies and other agencies for the purposes of coordinating work with existing and proposed utilities. The preliminary construction plans shall indicate location of existing/proposed utilities and storm drain lines. The Engineer shall receive written approval of the Phase 2 plans from the City's project manager before proceeding with Phase 3. PHASE 3 13) Final Construction Plans The Engineer shall furnish five (5) copies of the final construction plans and contract specifications for review by the City. 14) Detailed Cost Estimate The Engineer shall furnish four(4) copies of detailed estimates of probable construction costs for the authorized construction project, which shall include summaries of bid items and quantities. 15) Plans and Specification Approval The Engineer shall furnish an original cover mylar for the signatures of authorized City officials. The Contract Documents shall comply with applicable local, state and federal laws and with applicable rules and regulations promulgated by local, state and national boards, bureaus and agencies. The Engineer shall receive written approval of the Phase 3 plans from the City's project manager before proceeding with Phase 4. STANDARD ENGINEERING AGREEMENT(REV 10/06105) Page 18 of 20 PHASE 4 16) Final Approved Construction Plans The Engineer shall furnish 45 bound copies of Phase 4 final approved construction plans and contract specifications. The approved plans and contract specifications shall be used as authorized by the City for use in obtaining bids, awarding contracts, and constructing the project. 17) -Bidding Assistance The Engineer shall issue addenda as appropriate to interpret, clarify, or expand the bidding documents, and assist the owner in determining the qualifications and acceptability of prospective constructors, subcontractors, and suppliers. When substitution prior to the award of contracts is allowed by the bidding documents, the Engineer will advise the owner as to the acceptability of alternate materials and equipment proposed by the prospective constructors. 18) Recommendation of Award The Engineer shall assist in the tabulation and review of all bids received for the construction of the project and shall make a recommendation of award to the City. 19) Prebid Conference The Engineer shall attend the prebid conference and the bid opening, prepare bid tabulation sheets and provide assistance to the owner in evaluating bids or proposals and in assembling and awarding contracts for construction, materials, equipment, and services. PHASE 5 20) Preconstruction Conference The Engineer shall attend the preconstruction conference. 21) Construction Survey The Engineer shall be available to the City on matters concerning the layout of the project during its construction and will set control points in the field to allow City survey crews to stake the project. The setting of line and grade stakes and route inspection of construction will be performed by the City. 22) Site Visits The Engineer shall visit the project site at appropriate intervals as construction proceeds to observe and report on the progress and the quality of the executed work. STANDARD ENGINEERING AGREEMENT(REV 10/06/05) Page 19 of 20 23) Shop Drawing Review The Engineer shall review shop and erection drawings submitted by the contractor for compliance with design concepts. The Engineer shall review laboratory, shop, and mill test reports on materials and equipment. 24) Instructions to Contractor The Engineer shall provide necessary interpretations and clarifications of contract documents, review change orders and make recommendations as to the acceptability of the work, at the request of the City. 25) Differing Site Conditions The Engineer shall prepare sketches required to resolve problems due to actual field conditions encountered. 26) Record Drawings The Engineer shall prepare record drawings from information submitted by the contractor. STANDARD ENGINEERING AGREEMENT(REV 10/06/05) Page 20 of 20 EXHIBIT"A-1" SUPPLEMENTAL SCOPE OF SERVICES (SUPPLEMENT TO ATTACHMENT "A") DESIGN SERVICES: PAVING AND/OR DRAINAGE IMPROVEMENTS The following is a clarification of the tasks that the ENGINEER will perform under ATTACHMENT "A". Work under this attachment includes engineering services for paving and/or storm drain improvements for the following: LEBOW CHANNEL ROADWAY CROSSING REPLACEMENT: BRENNAN STREET, 28TH STREET, and DEWEY AVENUE CITY PROJECT NO. 00778 Upon receipt of notice to proceed, the ENGINEER will perform the following tasks: PART A— PRE-ENGINEERING 1. Initial Data Collection a. Pre-Design Coordination Meetings ENGINEER will attend and document meetings, as required, to discuss and coordinate various aspects of the project and to ensure that the project stays on schedule. For purposes of establishing a level of comfort, two (2) meetings are anticipated. These include the following: One (1) pre-design kick-off meeting, (including the CITY's Department of Engineering and other departments that are impacted by the project). One (1) review meeting at completion of the City's review of the conceptual engineering plans. b. Data Collection In addition to data obtained from the City, ENGINEER will research and make efforts to obtain pertinent information to aid in coordination of the proposed improvements with any planned future improvements that may influence the project. ENGINEER will also identify and seek to obtain data for existing conditions that may impact the project including; utilities, City Master plans, CITY drainage EA1-1 )� 71 Rev 11/02/05 11 5 r � ; complaint files, existing applicable drainage studies and property ownership as available from the Tax Assessor's office. C. Coordination with Other Agencies During the concept phase the ENGINEER shall coordinate with all utilities, including utilities owned by the City, TxDOT and railroads. These entities shall also be contacted if applicable, to determine plans for any proposed facilities or adjustment to existing facilities within the project limits. The information obtained shall be shown on the concept plans. The ENGINEER shall show the location of the proposed utility lines, existing utility lines and any adjustments and/or relocation of the existing lines within the project limits. ENGINEER shall complete all forms necessary for City to obtain permit letters from TxDOT and railroads and submit such forms to the City. City shall be responsible for forwarding the forms to the affected agencies for execution. 2. Schedule Submittal and Monthly Progress Report The ENGINEER shall submit a project schedule after the design contract is fully executed. The schedule shall be updated and submitted to the CITY along with monthly progress reports as required under Attachment B of the contract. 3. Additional Tasks Requested by City Task 1— Surveying Services for Property and Easement Acquisition As a result of the Lebow Watershed Hydrologic and Hydraulic Analysis, December 2006, T/PW has identified 36 properties for full or partial acquisition to support the construction of hydraulic improvements for this project, as well as future projects along the channel. The surveying services described in this task will be performed for up to 36 individual tracts of land as identified in writing by T/PW. Efforts in this task will be billed on a monthly basis at a rate of$1,000 per property. This scope and fee does not include: providing property title insurance against loss from defects in title to real property, platting, or replatting of any property. A. Field Work Based on dimensions provided by T/PW, a field survey will be performed to collect property boundary information and to stake the limits of the property (or portion of property)to be acquired. EA1-2 Rev 11/02/05 B. Exhibit Preparation A metes and bounds written description and sketch will be prepared by a Registered Professional Land Surveyor(RPLS) for each tract and delivered to the City for use as exhibits or attachments to the City's property acquisition documents. Task 2—Highway 183(28th Street) Design Coordination with TxDOT In previous meetings, TxDOT has indicated a willingness to participate financially in the design of this bridge. The bridge is in the vicinity of an independent paving project currently under design by TxDOT. This task covers coordination efforts with TxDOT and the City to assist in negotiating financial participation and developing design criteria. This task also includes time for up to four meetings with TOOT and City staff to coordinate design approval. In addition, there is also limited time included for corrdinating design elements with the TOOT consultant. Submittals to TxDOT are also included and will occur at the conceptual, preliminary, and final design phases. Task 3—Environmental Design/Coordination for USACE 404 Individual Permit This scope includes the tasks necessary to prepare an application and mitigation plan for a USACE Individual 404 Permit to offset all work to be performed in the entire Lebow Channel corridor between its confluence with the Trinity River and DeRidder Street. This task includes coordination by ENGINEER with Environmental Consultant, Integrated Environmental Solutions (IES), and the USACE during the application and review process. A. Roadway Delineation and Section 404 Permit Assessment This task is specific to analyzing the impacts associated with proposed roadway crossing improvements at Dewey, NE 28th, and Brennan streets. Professional services to delineate all waters of the United States, including wetlands, within each of the project sites will be provided. Wetland ecologists will delineate the jurisdictional limits of the streams and on-channel ponds based on 33 CFR 328.3[e] and delineate the jurisdictional limits of the wetland based on the 1987 USACE Wetland Delineation Manual and current Regulatory Guidance Letters. After the delineation is completed, these waters of the United States will be digitized for impact calculation and illustration purposes. The proposed projects will be evaluated for compliance under Nationwide Permit (NWP) 14 — Linear Transportation Crossings. It is anticipated that the projects would be authorized under NWP 14. Therefore, a brief letter report will be prepared summarizing the delineation, describing the projects, and summarizing how the project complies with NWP 14, without notification. EA1-3 Rev 11/02/05 E. Waters of the United States Delineation and Pre Application Meeting Professional services will also be provided to delineate all waters of the United States, including wetlands, within the entire corridor. Wetland ecologists will delineate the jurisdictional limits of the streams based on 33 CFR 328.3[e] and delineate the jurisdictional limits of any wetlands based on the 1987 USACE Wetland Delineation Manual and current Regulatory Guidance Letters. The deliverable for this scope of services is a brief letter report that summarizes the delineation of the entire site. The letter report will include: ■ Delineation map of the jurisdictional waters of the United States; ■ Routine Wetland Determination Data Forms completed for all potential wetlands (including any questionable wetlands); ■ Representative photographs of upland and jurisdictional sites; ■ Descriptions of the site and each jurisdictional area; and ■ A submittal to the USACE requesting a Jurisdictional Determination for the property and a pre-application meeting. The submittal to the USACE will include a brief overview of the project, estimated impacts, and mitigation concepts. The USACE may request a site visit to review the delineation, specifically areas that are questionable, prior to providing a Jurisdictional Determination. C. Section 404 Permit Services and Deliverables The preliminary hydraulic analysis and grading concept have been modeled, indicating impacts to waters of the United States that would only be permitted under an Individual Permit (IP) (i.e., greater than 0.5 acre impacts). There are two regulated activities associated with this proposed project that would require the attainment of an individual Section 404 permit. .By definition, discharges of fill material is regulated since "Fill material is material that is placed into waters of the United States where the material has the effect of replacing a water with dry land or changing the bottom elevation of any portion of a water of the United States." This task is initiated with after the pre-application meeting with the USACE and other planning meetings with the design team to ensure desired compensatory mitigation (if any) is incorporated into the site plan. After initial planning has occurred, an IP to the USACE will be will prepared and submitted. This process requires that a mitigation plan be prepared which addresses compensatory mitigation. A stand-alone conceptual mitigation plan for this submittal will be prepared. The Section 404 mitigation plan will include: EA1-4 Rev 11/02/05 • Description of the proposed action; ■ Description of the site, including a delineation of the waters of the United States; ■ Alternatives-analysis to the proposed action that do not impact waters of the United States; ■ Description of the project's avoidance and minimization efforts; ■ Quantitative and qualitative description of the unavoidable impacts to the waters of the United States; and ■ Description of the proposed conceptual mitigation (i.e., proposed earthwork, species and densities of plant materials, success criteria/performance standards, and monitoring program). An IP also requires additional background information for the completion of the permit notification and approval process. Additional services incorporated into this scope to complete the IP include the following services: ■ Completing the IP Application (ENG Form 4345); ■ Identifying and submitting to USACE two tiers of adjacent landowners names and addresses for the Public Notice; ■ Preparing the Public Notice and coordinating with the USACE on initial comments; ■ Submitting an advanced copy of mitigation plan to five regulatory agencies (e.g., Texas Commission on Environmental Quality [TCEQ], Texas Parks and Wildlife Department [TPWD], State Historical Preservation Officer [SHPO], U.S. Fish and Wildlife Service [USFWS], and U.S. Environmental Protection Agency [USEPA]); ■ Completing information for the TCEQ 401 Water Quality Certification (different requirements based on impacts); ■ Coordinating with the five regulatory agencies to receive concurrence with the proposed project, which may require revising the mitigation plan; ■ Addressing all public notice comments received and providing USACE a comment sheet stating how the comments were incorporated into the design/mitigation plan or why they were dismissed; and ■ Assisting the USACE with drafting the Decision Document and Permit. After the permit is submitted to the USACE, additional coordination will be required to finalize the requirements of the permitting process (which includes assisting the USACE with the Public Notice and Decision Document and coordination with the other regulatory agencies to receive concurrence). During the coordination with the USACE or other EA1-5 Rev 11/02/05 regulatory agencies, these agencies may request additional studies/reports be prepared (i.e., a cultural resource assessment to comply with the Texas Antiquities Code). Efforts to conduct any additional studies or reports such as a cultural- resource survey are not included in this proposal, because it is uncertain whether the USACE would require them for this permit. This task also includes effort for coordinating with the design team and client to accomplish the desired mitigated environment. This includes identifying engineering constraints, aesthetic preferences, and USACE mitigation preferences to be coordinated and designed into the project. IES will also attend monthly status meetings (up to 12 meetings) and up to two public hearings. Task 4— Consultation with Public Artist The Fort Worth Public Arts Council has included funding for design of public art improvements as part of this project. The Public Artist, Leticia Huerta, has been involved in the planning phases of this project and will produce a public art design to be incorporated into this project. This task includes coordination with City Staff and the Public Artist regarding how best to incorporate the artist's design into the Project. The task involves two distinct components as follows: A. Collaboration Workshops This project component involves up to two (2) four-hour workshop type meetings with the Public Artist, the Public Arts Council, the ENGINEER, Landscape Architects, T/PW, and others to discuss the artistic theme for the watershed area. These meetings will occur during the conceptual phase of the project with the intent of providing the Public Artist with input and direction for the work she is providing under a separate and independent contract. B. Artistic Design Incorporation It is anticipated and assumed that once the workshop phase is complete, the Public Artist will prepare independent designs and specifications for artwork to be constructed in conjunction with this project. The scope of this project component includes ENGINEER'S efforts to incorporate completed (final) design and specifications (prepared by others) into the contract documents for this project. Minor formatting is assumed and will be a part of this task. If the ENGINEER is required to perform design services or revisions a contract amendment will be required. EA1-6 Rev 11/02/06 Task 5—Coordination and Planning-with City Staff This task provides for consultation (up to 80 hours engineering/20 hours technical resources) with City Staff and/or residents and business owners relative to conceptual planning within the boundary of the entire Lebow watershed area. Meetings and consultation may include items such as park and community facilities planning, trail system planning, pedestrian crossing locations, cost projections, etc. Consultant may also participate in discussions with City Staff and City Council relative to long term project phasing. In addition, this task also provides for the preparation of specialized exhibits relative to meetings and planning as identified above as well as developing alternatives and cost projections as needed. The following sub-tasks further define the scope of work involved in this task: A. Continued refinement of the overall concept for improvements within the Lower Lebow Channel project area, as necessary in order to establish proper limits for property/easement acquisition; B. Meetings with affected residential and business property owners, as requested by the City, for the purpose of evaluating possible alternatives to the concept plan in order to minimize the impact to their properties; C. Assisting the City, as requested, in order to facilitate their negotiations with the property owners of a site upstream of Long Avenue regarding an agreement that would allow the construction of a regional detention facility; D. Continued efforts, as requested by the City, to assist in special public meetings with key project stakeholders in the community; and E. Preparation of exhibits, cost projections, design alternatives, etc. relative to this task. Task 6—Coordination and Planning with T/PW for removal of Vera Cruz low water crossings This task includes design assistance for the removal of pavement and placement of vegetative cover at the two low-water crossings on Vera Cruz Drive, west of Schwartz Avenue. PART B-CONSTRUCTION PLANS AND SPECIFICATIONS 1. Conceptual Engineering EA1-7 Rev 11/02/05 i. Surveys for Design a. ENGINEER will perform field surveys to collect horizontal and vertical elevations and other information needed by ENGINEER in design and preparation of plans for the project. Information gathered during the survey shall include topographic data, elevations of all sanitary and adjacent storm sewers, rim/invert elevations, location of buried utilities, structures, and other features relevant to the final plan sheets. Existing drainage at intersections will be verified by field surveys. Spot elevations will be shown on intersection layouts with cross slope to fit intersecting grade lines. b. ENGINEER will provide the following information: All plans, field notes, plats, maps, legal descriptions, or other specified documents prepared in conjunction with the requested services shall be provided in a digital format compatible with the electronic data collection and computer aided design and drafting software currently in use by the Department of Engineering. All text data such as plan and profile, legal descriptions, coordinate files, cut sheets, etc., shall be provided in the American Standard Code for Information Interchange (ASCII) format, and all drawing files shall be provided in Autocad (DWG or DXF) format (currently Release 12), or as otherwise approved in writing by the CITY, and all data collected and generated during the course of the project shall become the property of the CITY. The minimum survey information to be provided on the plans shall include the following: 1. A Project Control Sheet, showing ALL Control Points, used or set while gathering data. Generally on a scale of not less than 1:400: 2. The following information about each Control Point; a. Identified (Existing. City Monument #8901, PK Nail, 5/8" Iron Rod) b. X, Y and Z Coordinates, in an identified coordinate system, and a referred bearing base. Z coordinate on City Datum only. EA1-8 Rev 11/02105 C. Descriptive Location (Ex. Set in the centerline of the inlet in the South curb line of North Side Drive at the East end of radius at the Southeast corner of North Side Drive and North Main Street). 3. Coordinates on all P.C.'s, P.T.'s, P.I.'s, Manholes, Valves, etc., in the same coordinate system, as the Control. 4. No less than two horizontal bench marks, per line or location. 5. Bearings given on all proposed centerlines, or baselines. 6. Station equations relating utilities to paving, when appropriate. ii. Public Notification and PersonnelNehicle Identification a. Prior to conducting design survey, ENGINEER will notify affected residents of the project in writing. The notification letter shall be on company letterhead and shall include the following: project name limits DOE project No., Consultant's Project Manager and phone no., scope of survey work and design survey schedule. The letter will be reviewed and approved by the City prior to distribution. b. When conducting site visits to the project location, the ENGINEER or any of its sub-consultants shall carry readily visible information identifying the name of the company and the company representative. All company vehicles shall also be readily identifiable. iii. Drainage Computations ENGINEER will review and document the storm water watershed drainage runoff area and existing street, right-of-way and storm sewer capacities for the subject site. A drainage area map will be drawn at 1" = 200' scale from available contour maps. Calculations regarding street and right-of-way capacities and design discharges (5-year and 100-year frequencies) at selected critical locations will be provided. Capacities of existing storm drain will be calculated and shown. The ENGINEER's responsibility includes recommendations for improvements of the EA1-9 Rev 11/02/05 existing system as deemed reasonable and consistent with City standards. iv. Conceptual Engineering Plan Submittal a. Conceptual plans shall be submitted to City 60 days after Notice to Proceed Letter is issued. b. The ENGINEER shall furnish four (4) copies of the Phase 1 concept engineering plans which include layouts, preliminary right-of-way needs and cost estimates for the ENGINEER's recommended plan. The ENGINEER shall also evaluate the phasing of the water, sanitary sewer, street and drainage work, and shall submit such evaluation in writing to the City as a part of the concept phase of the project. 2. Preliminary Engineering Upon approval of Part B, Paragraph IV, ENGINEER will prepare construction plans as follows: a. Drainage area maps with drainage calculations and hydraulic computations. Information shown on the plans will be consistent with Part A, Paragraph 1.b. for proposed condition. b. Preliminary project plans and profile sheets which will show the following and shall be on 22"x 34" sheets: Property Ownership Curb Lines Driveways Medians(if applicable) Sidewalks Existing and proposed water and sanitary sewer mains. C. Proposed roadway profile grades and elevations along each curb line; elevations at all p.v.i.'s; p.i's half stations; high and low points; vertical curve information; and pertinent AASHTO calculations. Profiles for existing curbs (if any) and existing ground at the left and right-of-way lines shall be shown. Existing found property corners (e.g. Iron pins) , along the existing right-of- EA1-10 Rev 11/02/05 way shall be shown on the plans. Profiles for existing and proposed storm drain mains--and leads shall be provided. d. Existing utilities and utility easements will be shown on the roadway plan and profile sheets. ENGINEER will coordinate with utility companies and the City of Fort Worth to ascertain what, if any, future improvements are planned that may impact the project. e. Preliminary roadway cross-sections will be developed, from the survey notes, at intervals not-to-exceed 50 foot along the project length and will extend 10' past the right of way line on both sides of the street. Additional cross-sections at important features including driveways, p.i.'s of intersecting streets, (minimum distance of 100' along cross-street at each P.I.) walks, retaining walls, etc., will also be provided. Profiles of centerline of driveways will also be provided where necessary. Scale will be 1" = 10' horizontal and 1" = 2'vertical. f. Street and intersection layouts. g. Proposed plan/profile sheets will conform to City of Fort Worth construction legend. Adequate horizontal and vertical control shall be provided on the plan sheets to locate all proposed and existing facilities. Legal descriptions (Lot Nos., Block Nos., and Addition Names) along with property ownership shall be provided on the plan view. h. Furnish as a function of final plans, six (6) copies of the final cross-sections on 22" x 34" sheets. Information on these sheets will include centerline station, profile grades and centerline elevations, roadway section (existing and proposed), right-of-way limits. Scale will be 1" = 20' horizontal and 1" = 2' vertical with cross sections plotted with stationing from the bottom of the sheet, and will include laterals and inlets. CITY policy with regard to parking design shall be maintained. Excavation and embankment volumes and end area computations shall also be provided. I. Right-of-Way Research The ENGINEER will conduct preliminary research for availability of existing easements where open-cut construction or relocation of existing alignments is probable. Temporary and permanent easements will be appropriated based on available information and recommendations will be made for approval by the City. EA1-11 Rev 11/02/05 j. Right-of-way/Easement Preparation and Submittal Preparation and submittal of right-of-way, easements and rights-of-entry will- be illbe in conformance with "Submittal of Information to Real Property Division for Acquisition of Property". k. Utility Clearance Phase The ENGINEER will consult with the City's Transportation and PublicWorks Department, Water Department, Department of Engineering, and other CITY departments, public utilities, private utilities, private utilities and government agencies to determine the approximate location of above and underground utilities, and other facilities that have an impact or influence on the project. ENGINEER will design City facilities to avoid or minimize conflicts with existing utilities. The ENGINEER shall deliver a minimum of 13 sets of approved preliminary construction plans to the City's Utility Coordinator for forwarding to all utility companies,which have facilities within the limits of the project. I. Preliminary Construction Plan Submittal i. Preliminary construction plans and specifications shall be submitted to CITY 60 days after approval of Part B, Paragraph iv. ii. The ENGINEER shall deliver two (2) sets of preliminary construction plans and two (2) specifications to CITY for review. Generally, plan sheets shall be organized as follows: Cover Sheet General Layout and Legend Sheet Drainage Area Map and Computations Plan & Profile Sheets Standard Construction Details Special Details (If applicable) iii. Preliminary estimate shall submit a preliminary estimate of probable construction cost with the preliminary plans submitted. Engineer shall assist City in selecting the feasible and or economical solutions to be pursued. EAI-12 Rev 11/02/05 M. Review Meetings with City The ENGINEER shall meet with CITY to discuss review comments for preliminary submittal. The CITY shall direct the ENGINEER in writing to proceed with Final Design for Final Review. n. Public Meeting After the preliminary plans have been reviewed and approved by the City, the ENGINEER shall prepare project exhibits, provide the CITY with the database listing the names and addresses of all residents and business to be affected by the proposed project, and attend public meeting to help explain the proposed project to residents. The CITY shall select a suitable location and mail the invitation letters to the affected customers. o. Storm Water Pollution Prevention Plan ENGINEER will prepare the Storm Water Pollution Prevention Plan (SWPPP) required for the project for use by the Contractor during construction. ENGINEER will prepare drawings and details for proposed SWPPP improvements that the Contractor must use during construction. Contractor shall be responsible for filing the SWPPP with appropriate regulatory agencies. 3. Final Construction Plan Submittal a. Final Construction Documents shall be submitted to CITY 75 days after approval of Part B, Paragraph 2 (b). Following CITY approval of the recommended improvements, the ENGINEER shall prepare final plans and specifications and contract documents to CITY(each plan sheet shall be stamped, dated, and signed by the ENGINEER registered in State of Texas) and submit two (2) sets of plans and construction contract documents within 15 days of CITY's final approval. Plan sets shall be used for Part C activities. b. ENGINEER's Estimate of Probable Construction Cost EAI-13 Rev 11/02/05 The ENGINEER shall submit a final estimate of probable construction cost with the final plans submitted. C. Mylar Submittals The ENGINEER shall submit a final set of mylar drawings for record storage as follows: 1. Street and storm drain plans shall be submitted as one set of plans. Street and storm drain plans shall be separate from water and sanitary sewer plans. All sheets shall be standard size (22" x 34")with all project numbers(TPW and water/sanitary sewer) prominently displayed. 2. For projects where water/sanitary sewer improvements occur on a TPW Department funded project with no Water funding involved, a separate set of mylars with cover sheet shall be submitted for Water Department. 3. Signed plans sets shall also be submitted as an Adobe Acrobat PDF format (version 6.0 or higher) file. There shall be one (1) PDF file for the TPW plan set and a separate PDF file for the Water plan set. Each PDF file shall contain all associated sheets of the particular plan set. Singular PDF files for each sheet of a plan set will not be accepted. PDF files shall conform to naming conventions as follows: I. TPW file name example — "W-1956—org47.pdf" where "W-1956" is the assigned file number obtained from the City of Fort Worth, "—org" designating the file is of an original plan set, "47" shall be the total number of sheets in this file. Example: W 0053_org3.pdf and K-0320—org5.pdf II. Water and Sewer file name example — "X- 35667—org36.pdf' where "X-35667" is the assigned file number obtained from the City of Fort Worth, "—org" designating the file is of an original plan set, 1136" shall be the total number of sheets in this file. EAI-14 Rev 11/02/05 Example: X-12755_org18.pdf Both PDF files shall be submitted on one (1) Compact Disk, which will become property of and remain with the City of Fort Worth. Floppy disks, zip disks e-mail flash media will not be accepted. 4. For information on the proper manner to submit PDF files and to obtain a file number for the project, contact the Department of Engineering Vault at telephone number (817) 392-8426. File numbers will not be issued to a project unless the DOE number and proper fund codes have been assigned and are in the Department of Engineering database. PART C -PRE-CONSTRUCTION ASSISTANCE Administration a. Bid Documents Submittal The ENGINEER will make available for bidding, upon request by the CITY, up to fifty (50) sets of the final approved and dated plans and specifications and contract documents for the projects to the CITY for distribution to potential bidders. Proposal will be provided in electronic format. b. Bidding Assistance The ENGINEER shall assist the CITY during this phase including preparation and delivery of any additional addenda prior to bid opening to plan holders and respond to questions submitted to DOE by prospective bidders. Engineer shall attend the scheduled pre-bid conference. The ENGINEER shall assist in reviewing the bids for completeness and accuracy. The ENGINEER shall attend the project bid opening, develop bid tabulations in hard copy and electronic format and return four (4) copies of the bid tabulation, along with the contract documents to the City within three (3) working days after bid openings. EAI-15 Rev 11/02/05 C. Assistance During Construction The ENGINEER shall attend the pre-construction conference for the project. The ENGINEER shall also consult with and advise the CITY on design and/or construction changes, if necessary. PART D—CONSTRUCTION STAKING—NOT INCLUDED IN THIS CONTRACT EAI-16 Rev 11/02/05 ATTACHMENT "B" COMPENSATION AND PAYMENT SCHEDULE Engineering Design Services Associated With LEBOW CHANNEL ROADWAY CROSSING REPLACEMENT: BRENNAN STREET, 28TH STREET; DEWEY AVENUE CITY PROJECT NO. 00778 1. Compensation A. The ENGINEER shall be compensated a total lump sum fee of $361,072.00 as summarized in Exhibit "B-3". Payment of the total lump sum fee shall be considered full compensation for the services described in Attachment "A" and Exhibit "A-1" for all labor materials, supplies, and equipment necessary to complete the project. All permitting, application, and similar project fees will be paid directly by the City. B. The Engineer shall be paid monthly as described in Exhibit "B-1", Section I — Method of Payment. C. Each invoice is to be verified as to its accuracy and compliance with the terms of this contract by an officer of the Engineer. II. Schedule (Working Days) Final Plans and Contract Documents for bid advertisement shall be submitted within 280 days after the "Notice to Proceed" letter is issued based on the following schedule (all days are working days). Key project phases are shown below; refer to Attachment D for complete schedule. A. Design/Topographic Survey— 30 days B. Conceptual Engineering Plans (30% Design) —60 days C. CITY Conceptual Plan review— 10 days D. Preliminary Engineering Plans & Contract Documents — 60 days E. CITY Preliminary Engineering Plan review— 10 days F. Final Engineering Plans & Contract Documents—76 days (upon receipt of Preliminary Engineering Plan review) G. CITY Final Engineering Plan review— 10 days H. Final Plans and Contract Documents for Bid Advertisement— 10 days (upon receipt of Final Engineering Plan review) B-1 EXHIBIT "13-1" (SUPPLEMENT TO ATTACHMENT B) METHOD OF PAYMENT Engineering Design Services Associated With LEBOW CHANNEL CROSSING REPLACEMENT: BRENNAN STREET, 28TH STREET; DEWEY AVENUE CITY PROJECT NO. 00778 I. Method of Payment The ENGINEER shall be paid monthly upon receipt of an invoice on the basis of statements prepared from the books and records of account of the ENGINEER, based on the ENGINEERS' estimate of the percentage of completion of the project, such statements to be verified as to accuracy and compliance of the project, such statements to be verified as to accuracy and compliance with the terms of this contract by an officer of the ENGINEER. Payment according to statements will be subject to certification by the Director of the Department of Engineering or his authorized representative that such work has been performed. The aggregate of such monthly partial fee payments shall not exceed the following: Until satisfactory completion of Exhibit "A-1", Conceptual Engineering Plan submittal, a sum not to exceed 30 percent of the total lump sum fee. Until satisfactory completion of Exhibit "A-1", Preliminary Construction Plan submittal, a sum not to exceed 60 percent of the total lump sum fee. Until satisfactory completion of Exhibit "A-1", Final Construction Plan submittal, a sum not to exceed 90 percent of the total lump sum fee. The balance of fees, less previous payments, shall be payable after all of the pre- construction meetings for the Project have been conducted. II. Progress Reports A. The ENGINEER shall submit to the designated representative of the Director of the Department of Engineering quarterly progress reports covering all phases of design in the format required by the City. B. If the ENGINEER determines in the course of making design drawings and specifications that the opinion of probable construction cost of $2,493,000.00 (as estimated in Exhibit B-4) will be exceeded, whether by change in the scope of the project, increased cost or other conditions, the ENGINEER shall immediately report such fact to the City's Director of the Department of Engineering and, if so instructed by the Director of the Department of Engineering shall suspend all work hereunder. B1-1 EXHIBIT "B-2" HOURLY AND REIMBURSABLE RATE SCHEDULE LEBOW CHANNEL ROADWAY CROSSING REPLACEMENT: BRENNAN STREET,28TH STREET; DEWEY AVENUE CITY PROJECT NO.00778 Engineering/Technical From To Principal $150 - $220 Per Hour Project Manager $115 - $150 Per Hour Senior Engineer $90 - $160 Per Hour Engineer $80 - $120 Per Hour Landscape Architect/Planner $90 - $150 Per Hour Designer $85 - $110 Per Hour Senior Designer $100 - $130 Per Hour CAD Technician $60 - $85 Per Hour Senior CAD Technician $75 - $100 Per Hour IT Consultant $120 - $140 Per Hour IT Technician $70 - $100 Per Hour Clerical $50 - $70 Per Hour Resident Project Representative $70 - $90 Per Hour Surveying Survey Office Manager $145 - $155 $100 - $130 R.P.L.S. S.I.T. $70 - $90 Senior Survey Technician $70 - $90 Junior Survey Technician $60 - $75 2-Person Field Crew w/Equipment $100 3-Person Field Crew w/Equipment $110 4-Person Field Crew w/Equipment $135 1-Person G.P.S. Crew w/Equipment $110 2-Person G.P.S. Crew w/Equipment $130 3-Person G.P.S. Crew w/Equipment $150 1-Person Robotic Crew w/Equipment $90 2-Person Robotic Crew w/Equipment $110 Direct Cost Reimbursables Photocopies $0.10/page letter and legal size bond paper, B&W $0.20/page 11"x 17" size bond paper, B&W $2.00/page 22" x 34" and larger bond paper or vellum, B&W Plots $1.00/page 11" x 17" size bond paper, B&W $2.00/page 11" x 17" size bond paper, color $4.00/page 22"x34" and larger bond paper or vellum, B&W $6.00/page 22"x34" and larger bond paper or vellum, color $6.00/page 22"x34" and larger mylar or acetate, B&W Mileage $0.48/mile All Subcontracted and outsourced services billed at rates comparable to TNP's billing rates shown above. Rates shown are for calendar year 2007 and are subject to change in subsequent years. 11:" 132-1 ��� �,•;, iG II__U n`1 .. i .�.✓ti a -EXHIBIT ' (SUPPLEMENT TO ATTACHMENT B) SUMMARY OF TOTAL PROJECT FEES Engineering Design Services Associated with LEBOW CHANNEL ROADWAY CROSSING REPLACEMENT: BRENNAN STREET, 28TH STREET; DEWEY_AVENUE (CITY PROJECT NO. 00778) Consulting Firm Prime Responsibility Amount Percent Prime Consultant: Teague Nall and Perkins, Inc. Engineering & Proj. Mgmt. $ 267,193 74.0% M/WBE Consultants: Integrated Environmental Solutions Environmental Consulting $ 52,535 14.5% GM Enterprises Geotechnical Services $ 5,000 1.4% Alpha Graphics Printing / Reproduction $ 9,844 2.7% Gorrondona&Associates, Inc. Surveying Services $ 26,500 7.3% M/WBE SubTotal $ 93,879 26.0% Total for Professional Services $ 361,072 100.0% Note: Non-M/WBE Consultants— None. Project Description Scope of Services Total Fee M/WBE Fee Percent Engineering Services T/PW $ 361,072 $ 93,879 26.0% B3A-1 EXHIBIT"13-36" (SUPPLEMENT TO ATTACHMENT B) PROFESSIONAL SERVICES FEE SUMMARY Engineering Design Services Associated with LEBOW CHANNEL ROADWAY CROSSING REPLACEMENT: BRENNAN STREET, 28TH STREET; DEWEY AVENUE (CITY PROJECT NO. 00778) BASIC ENGINEERING DESIGN FEE: (Construction Cost X TSPE Curve"A"X 85%) T/PW Design: $2,493,000.00 X 6.8% X 85.0% _ $ 143,036.00 ADDITIONAL SERVICES: Surveying Services (by Sub Consultant, Refer to Exhibit 13-3C) = $ 62,500.00 - Public Meetings (4 meetings with Residents & City Staff) = $ 2,000.00 - Design Meetings with City Staff(6 meetings) = $ 4,500.00 - Monthly Reports/Coordination with City PM = $ 4,000.00 - Geotechnical Report/Pavement Design (by Sub Consultant) = $ 15,000.00 - Coordination with TxDOT (28th Street Design) (RE: B-3D-1) = $ 10,200.00 - Environmental USACE 404 IP (by Sub Consultant) = $ 52,535.00 - Coordination w/ Environmental Sub Consultant(RE: B-3D-1) = $ 6,000.00 - Design Coordination with Public Artist(RE: B-3D-1) = $ 5,800.00 - Coordination and.Planning with City Staff(RE: B-3D-1) = $ 15,000.00 - Design Assistance-Vera Cruz Low Water Crossing = $ 3,000.00 - Storm Water Pollution Prevention Plan = $ 5,000.00 - Administrative Fee (10%) on M/WBE Firms = $ 9,388.00 Printing / Reproduction (partially by Sub Consultant) = $ 17,623.00 Pre-Construction Assistance = $ 5,490.00 Additional Services Total: $218,036.00 B3B-1 EXHIBIT"B-3B" (SUPPLEMENT TO ATTACHMENT B) SUMMARY OF TOTAL FEE AND BREAKDOWN OF DESIGN FEE (LESS SURVEY FEE) Engineering Design Services Associated with LEBOW CHANNEL ROADWAY CROSSING REPLACEMENT: BRENNAN STREET, 2-8TH STREET; DEWEY AVENUE (CITY PROJECT NO.-00778) A. SUMMARY OF TOTAL FEE Service Description Total Basic Engineering $ 143,036.00 Services Additional Engineering $ 155,536.00 Services Engineering Subtotal $ 298,572.00 Surveying Services $ 62,500.00 Project Total $ 361,072.00 B. BREAKDOWN OF ENGINEERING FEES (LESS SURVEY FEES) 1. Total T/PW Fee(less survey fee) Breakdown by Conceptual Preliminary&Final Desi n a. Conceptual (30%) _ (Engineering Subtotal)X (0.3) _ $ 89,571.00 b. Preliminary (60%) _ (Engineering Subtotal) X (0.6) _ $ 179,144.00 c. Final (10%) _ (Engineering Subtotal)X (0.1) _ $ 29,857.00 $298,572.00 1336-2 EXHIBIT"B-3C" (SUPPLEMENT TO ATTACHMENT B) FEES FOR SURVEYING SERVICES Engineering Design Services Associated with LEBOW CHANNEL ROADWAY CROSSING REPLACEMENT: BRENNAN STREET, 28TH STREET; DEWEY AVENUE (CITY PROJECT NO. 00778) Surveying Services: Survey for Property and Esmt Acquisition = $ 36,000.00 (Property&Easement Acquisition will be billed on a per lot basis @$1 000/10t) (Only properties actually surveyed for acquisition will be billed) Bridge Design Survey = $ 23,500.00 Subsurface Utility Investigation = $ 3, 00.00 Survey Total $ 62,5600.00 T/PW Subtotal $ 62,500.00 B3C-1 EXHIBIT"13-313" (SUPPLEMENT TO ATTACHMENT B) ADDITIONAL SERVICES Engineering Design Services Associated with LEBOW CHANNEL ROADWAY CROSSING REPLACEMENT: BRENNAN STREET, 28TH STREET; DEWEY AVENUE (CITY PROJECT NO. 00778) Additional Services: - Public Meetings (4 meetings with Residents & City Staff) _ $ 2,000.00 - Design Meetings with City Staff(6 meetings) _ $ 4,500.00 - Monthly Reports/Coordination with City PM = $ 4,000.00 - Geotechnical Report/Pavement Design (by Sub Consultant) _ $ 15,000.00 - Coordination with TxDOT (28th Street Design) (RE: B-3D-1) = $ 520,5035.00 0-00 - Environmental USACE 404 IP (by Sub Consultant) _ $ - Coordination w/ Environmental Sub Consultant (RE: B-3D-1) _ $ 6,000.00 - Design Coordination with Public Artist (RE: B-3D-1) _ $ 5,800.00 - Coordination and Planning with City Staff(RE: B-3D-1) _ $ 15,000.00 - Design Assistance -Vera Cruz Low Water Crossing = $ 3,000.00 - Storm Water Pollution Prevention Plan = $ 5,000.00 -Administrative Fee (10%) on M/WBE Firms = $ 9,388.00 Additional Services Total $ 132,423.00 63D-1 � Cit of Fort Worth - Lebow Channel Roadwa �rossin Re lacement Exhibit B-3D-1 e Task 2— Highway 183 (28th Street) Design Coord. with TxDOT Coordination Meetings 4 meetin s 24 Design Plan Coordination with TxDOT Consultant 50 Plan Pre and Deliver to TxDOT 30 Total $ 10,200 Task 3- Environmental Design/Coordination for USACE 404 IP Coordination with IES for Roadway/Channel Delineation $ Pre Application Meeting with City and Review 12 Review Permit Prior To Submittal/Meet with City 16 Mitigation Coordination and Meetings with Ci /Pro e Owners 14 Total $ 6,000 Task 4-Consultation with Public Artist Task 4A Collaboration Workshops (2 Cad 4hrs eachl 2 Q Meeting2 Pre aration 22 o Meeting 2 o Documentation 11 Task 4B- Incor orate Artistic Design (by Others Total $ 5,800 Task 5—Coordination and Planning with City Staff Task 5A Continued refinement of the overall concept 16 Task 5B Meetings with the affected residential and business property owners 32 Task 5C Assisting the City with a regional detention facility at Long Avenue 16 Task 5D-Assisting inspecial public and/or private meetings with key ro'ect stakeholders 16 Task 5E- Preparation of exhibits cost projections, design alternatives etc. 28 Total $ 15,000 Project Total Cost $ 37,000 EXHIBIT"B-3E" (SUPPLEMENT TO ATTACHMENT B) PRINTING /REPRODUCTION Engineering Design Services Associated with LEBOW CHANNEL ROADWAY CROSSING REPLACEMENT: BRENNAN STREET, 28TH STREET DEWEY AVENUE (CITY PROJECT NO. 00778) Printing/Reproduction Costs: *Description No.Sets **Sheets/Set Cost/Sheet Total Cost Concept Plans 4 48 $ 2.00 $ 384.00 Preliminary Plans 2 72 $ 2.00 $ 288.00 Utility Plans (Full Size) 14 72 $ 2.00 $ 2,016.00 Final Plans 2 72 $ 2.00 $ 288.00 Bid Plans 50 72 $ 2.00 $ 7,200.00 Mylar Plans 1 72 $ 10.00 $ 720.00 Half Size Plans 10 72 $ 1.00 $ 720.00 TxDOT Plan Submittals 12 72 $ 1.00 $ 864.00 Mounted Exhibits 2 20 $ 20.00 $ 800.00 Specs Preliminary Plans 2 450 $ 0.15 $ 135.00 Specs Final Plans 2 450 $ 0.15 $ 135.00 Specs Bid Sets 50 450 $ 0.15 $ 3,375.00 Photocopies 200 1 $ 0.10 $ 20.00 Bind in /Punching/Delivery 1 1 $678.00 $ 678.00 Total Printing/Reproduction $ 17,623.00 Note: Additional or interim check sets requested by the City shall be provided according to the Std. Rate Schedule (Exhibit B-2). * Plans are generally 1:20. In some cases the consultant may choose to use a different scale as the plans, sections, details, and/or sheet sizes warrant. **The number of sheets per set includes TxDOT and City detail sheets as required. 133E-1 EXHIBIT "B-317" (SUPPLEMENT TO ATTACHMENT B) PRE-CONSTRUCTION ASSISTANCE Engineering Design Services Associated with LEBOW CHANNEL ROADWAY CROSSING REPLACEMENT: BRENNAN-STREET, 28TH STREET; DEWEY AVENUE (CITY PROJECT NO. 00778) Construction Assistance Fees Pre-Bid Meeting = $ 1,550.00 Attend Bid Opening = $ 560.00 Tabulate Bids (by City) _ $ - Recommend Contract Award (by City) _ $ - Attend Pre-Construction Meeting = $ 1,000.00 Periodic Site Visits with Brief Report = $ 1,380.00 Prepare Record Drawings (by City) _ $ - Final Walk Through = $ 1,000.00 Construction Assistance Total $ 5,490.00 B3F-1 :Jo't� �LuBe TEAGUE NALL AND PERKINS Exhibit B-4 CONSULTING ENGINEERS OPINION OF PROBABLE CONSTRUCTION COST LEBOW CHANNEL ROADWAY CROSSING REPLACEMENT: BRENNAN STREET,28TH STREET; DEWEY-AVENUE (CITY PROJECT NO.00778) (FEE PROPOSAL) OWNER: CITY OF FORT WORTH DATE: March 8,2007 DEWEY AVENUE CROSSING IMPROVEMENTS UNIT ITEM DESCRIPTION OF ITEMS QUANTITY UNIT COST TOTAL NO. 1 Pro'ect Desi nation Si n 2 EA $300.00 $600.00 2 Remove Existinq Pavement/Pre are ROW 170 LF $25.00 $4,250.00 3 Remove Existing Concrete Bridge Structure 1 LS $20,0nn 600 .00 $ ,000.00 4 8"Lime Stabilized Sub rade O $$66.50 $$33,900.00 14 5 Lime Stabilization(47 LB/SY) 14 TON $125.00 $1,762.50 600 $35.00 $21,000.00 6 7"Concrete Pavement SY 7 6"HMAC Transition Pavement 70 SY $50.00 $3,500.00 8 4'Concrete Sidewalk 1,300 SF $7.50 $9,750.00 $3,000.00 9 Sidewalk Rams 3 EA $1,000.00 250 SF $11.25 $2,812.50 10 Concrete Driveway 11 em ora Pavin /Stri in /Detour 700 $15,400.00 SY $22.00 T 12 Utili Ad'ustments 1 $7,000.00 $7,000.00 LS 13 Unclassified Channel Excavation 900 CY 8.00 $16,200.00 $1 14 Double 20'x10'Arch S an 50 LF $4,800.00 $240,000.00 15 Arch Span Foundation 40 __Cy__ $800.00 $32,000.00 16 Concrete Headwall/Wingwall 80 CY $800.00 $64,000.00 17 Upstream/Downstream Channel Concrete Ri Ra 150 CY $375.00 $56,250.00 2 EA $3,750.00 $7,500.00 18 10'Curb Inlets 50 LF $75.00 $3,750.00 19 21"RCP 180 LF $135.00 $24,300.00 20 Architectural Bridge Railing Basis for Cost Projection: Sub-Total Construction Cost $536,975 0 No Design Completed +/-10% $54,025 ❑ Preliminary Design Total Construction Cost $591,000.00 E] Final Design B4-1 TEAGUE NALL AND PERKINS Exhibit B=4 CONSULTING ENGINEERS OPINION OF PROBABLE CONSTRUCTION COST LEBOW CHANNEL ROADWAY CROSSING REPLACEMENT: BRENNAN STREET,28TH STREET;DEWEY AVENUE (CITY PROJECT NO.00778) (FEE PROPOSAL) OWNER: CITY OF FORT WORTH DATE: March 8,2007 28TH STREET CROSSING IMPROVEMENTS UNIT ITEM DESCRIPTION OF ITEMS QUANTITY UNIT COST TOTAL NO. 1 Project Desi nation Sin 2 EA $300.00 $600.00 2 Remove Existin 1 $9,000.00 Pavement/Pre are ROW 1LF $75.00 3 Remove Existing Concrete Bridge Structure 1 LS $40,0 $ ,000.00 $6.50 $7.00 $7,150.00 4 8"Lime Stabilized Subgrade 1,100 SY $6 5 Lime Stabilization(47 LB/SY) 26 TON $125.00 $3,231.25 6 12"Concrete Pavement11000 SY $70.00 $70,000.00 7 12"HMAC Transition Pavement 120 SY $75.00 $9,000.00 1,280 SF $7.50 $9,600.00 8 4'Concrete Sidewalk 9 Sidewalk Ramps 2 EA $1,000.00 $2,000.00 10 Temporary Paving/Stri ing/Detour/Constr.Phasing( erTxDOT) 3-Phases) 3142000 SY 22.00 LF $$40.00 $16,800.00 11 Remove and Reconstruct Median 12 28th/Decatur Tem ora Si nalization 1 LS $7,000.00 $7,000.00 13 28th/Decatur Permanent Sicinalization Re-Installation 1 LS $8,000.00 $8,000.00 14 Utility Adjustments 1 LS $7,000.00 $7,000.00 15 Unclassified Channel Excavation 1,000 CY $18.00 $18,000.00 16 10'x10'Direct Drive Concrete 90 LF $4, $8 Box Culvert(5 Barrel) 00.00 $440,000.00 17 Concrete Headwall/Wingwall 90 CY $800.00 $72,000.00 18 Upstream/Downstream Channel Concrete RipRap 170 CY $375.00 $63,750.00 19 Architectural Bridge Railing 175 LF $135.00 $23,625.00 20 10'Curb Inlets 2 EA $3,750.00 $7,500.00 21 21"Class III RCP(Replace Existing 3 2 25'each) 75 LF $75.00 $5,625.00 22 36"Class III RCP(Reconnect Existing 3 @ 10'each) 30 LF $120.00 $3,600.00 23 Relocate Storm Water Monitor 1 LS $7,500.00 $7,500.00 24 Reconstruct Manhole/Concrete Encased Sewer Line Crossing 1 LS $12,000.00 $12,000.00 25 6-foot Chain Link Fencing 200 LF $45.00 $9,000.00 26 12'Retaining Walls 65 CY $800.00 $52,000.00 27 8'Retaining Walls 48 CY $800.00 $38,400.00 28 Traffic Rail for Retaining Walls 200 LF $125.00 $25,000.00 Basis for Cost Projection: Sub-Total Construction Cost $1,042,181 Q No Design compieted Contingency: +/-10% $104,819 ❑ Preliminary Design ❑ Final Design Total Construction Cost $1,147,000.00 B4-2 TEAGUE NALL AND PERKINS Exhibit B-4 CONSULTING ENGINEERS OPINION OF PROBABLE CONSTRUCTION COST LEBOW CHANNEL ROADWAY CROSSING REPLACEMENT: BRENNAN STREET,28TH STREET; DEWEY AVENUE (CITY PROJECT NO.00778) (FEE PROPOSAL) OWNER: CITY OF FORT WORTH DATE: March 8,2007 BRENNAN STREET CROSSING IMPROVEMENTS UNIT ITEM DESCRIPTION OF ITEMS QUANTITY UNIT COST TOTAL NO. 1 Pro ect Desi nation Sin 2 EA $300.00 $600.00 2 Remove Existina Pavement/Prepare ROW 300 LF $25.00 $7,500.00 3 Remove Existing Concrete Bridge Structure 1 LS $25,000.00 $25,000.00 4 8"Lime Stabilized 5ubgrade 1,300 SY $6.50 $8,450.00 5 Lime Stabilization(47 LB/SY) 31 TON $125.00 $3,818.75 6 7"Concrete Pavement 1,300 SY $35.00 $45,500.00 7 6"HMAC Transition Pavement 250 SY $50.00 $12,500.00 8 4'Concrete Sidewalk 2,000 SF $6.00 $12,000.00 9 Sidewalk Rams 2 EA $1,000.00 $2,000.00 300 SF $11.25 $3,375.00 10 Concrete Driveway 950 $22.00 $ ,900.00 11 Tem ora Pavin]/Striping/Detour S $7 L , 12 UtilityAdjustments 1 LS $7,$18.00 $7.00 $30,6600.00 00.00 13 Unclassified Channel Excavation 1,700 CY $18 14 10'x10'Skewed Concrete Box Culvert(6 Barrel) 70 LF $4,800.00 $336,000.00 Concrete Headwall�ngwall 7 90 CY $800.00 $$7,000.00 15 2 EA $3,750.00 $ ,500.00 16 10'Curb Inlets 17 21"Class III RCP 75 LF $75.00 $5,625.00 18 Upstream/Downstream Channel Concrete RipRap 150 CY $375.00 $56,250.00 19 Architectural Bridge Railing 220 LF $135.00 $29,700.00 Basis for Cost Projection: Sub-Total Construction Cost $686,319 Q No Design Completed Contingency: +/-10% $68,681 ❑ Preliminary Design ❑ Final Design Total Construction Cost $755,000.00 B4-3 ATTACHMENT "C" CHANGES AND AMENDMENTS TO ATTACHMENT A Engineering Design Services Associated With Paving and Drainage Construction Engineering Design Services Associated With LEBOW CHANNEL ROADWAY CROSSING REPLACEMENT: BRENNAN STREET, 28TH STREET, AND DEWEY AVENUE CITY PROJECT NO. 00778 NONE. C-1 Teague Nall and Perkins,Inc. CITY OF FORT WORTH ATTACHMENT D LEBOW CHANNEL ROADWAY CROSSING REPLACEMENT: Project$CIIeCIU�E' �VIIOCICI119 Days) BRENNAN STREET,28TH STREET,AND DEWEY AVENUE CITY PROJECT NO.00778 2009 + 2007 2008 ID Task Name Duration i Start Finish Qtr 1 Qtr 2 Qtr 3 Qtr 4 Qtr 1 Qtr 2 Qtr 3 Qtr 4 Qtr 1 Qtr 2 Qtr 3 1 ENGINEERING 280 days Mon 5114107 Fri 616108 _. .... ............ I 9 2 Notice to Proceed/Kick Off Meetin 0 da s' Mon 5/14/07 on 5/14/07 Y 3 Design/Topographic Surveys 30 days Mon 5/14/07 Fn 6/22/07 a ---- 60 da s Mon 6125/07 Fn 9/14/07 4 Conceptual Design(30%)Plans Y F s Mon 6/25/07 Fri 8/3107 30 da 5 Geotechnical Report Y „rl P .. g ( ) - g Conce i Desi n 30% Submittal 0 days Fri 9/14107 Fri 9/14/07 ,9114 7 City Review 10 days Mon 9/17107 Fn 9/28/07 _ . j 60 da s Mon 10/1/07 Fri 12/21/07 1 M Preliminary Design(60%)Plans Y 1 ..y e 12121 i Preliminary Design(60%)Submittal 0 days; Fri 12/21/07 Fri 12/21/07 ..........................._................................................._............................. ..... .. Fri 12/21/07 12121 Neighborhood Meeting y I _........._.......................................................O daYs.._..._._..Fn 12/21/07 ........................................................... 12121 Fri . ................ Submit Plans for Utility Coordination 0 da s I F Fri 12/21/07 ................................ .. .. ..... - - 120 da s Mon 12/24/07 Fn 6/6/08 Utility Clearance Phase y 10 daysI Mon 12/24/07City Review Final Design(90%)Plans 75 days Mon 1/7/08 Fn 4118/08 15 Final Design(90%)Submittal 10 da s.e............Mon 4/21/08 Fri 5/2/08 hl 8 _..� O..da...S._i...............Fn 4/18/08...:...._...........Fn 4/18/08... y 16 City Review o........... 10 da s Mon 5/5/08! Fn 5/16/08 17 Final PS&E 100/o y ( ) 18 Circulate Cover Sheet for Signature 6 days Mon 5/19/08 Mon 5/26108 Y .................................._........... - - 290 da s� Mon 619108. Fri 7117109 19 CONSTRUCTION _ -- _ � 20 Pro'ect Advertisement Period 30 days, Mon 6/9/08 —- 0 days Fri 7/18108 Fri 7/18/08 7 8 21 Open Bids " ""' c 30 da s i Mon 7/21108 Fn 8/29/08 22 M&C Circulation Process Y = 9 23 Council Award of Contract y Fn 8/29/08 i 0 da s' Fri 8/29/08 10 da ; Mon 9/1/08 Fn 9/12/081 24 Contract Executiys 9112 on ............................................ 25 Pre-Construction Meeting 0 days Fri 9/12/08 Fri 9/12/08 .............._..................................._.................................................................................. 0 days--•— ---- - I Fri 9/12/08 Fri 9/12108 26 Neighborhood Meeting y 91 220 daysMon 9/1_50 ' Fri 7./.17/09 27 Construction 11It' II '�:I IA„ao I k..lrlfl Y;—1.—!.IN-1�rIrlS�llµ!•uI :Yl le la wr D-1 c; z w E a. —————— D as Dcya z < II w U) ui V) 0 — LLI W 0 w w S b CD b o C) CD C) CO CD C) 'DC) CD C) C) C) CD C> 0 C) O CD Cl CD CD C) CD O 0 co t "t CO co co M m N OO co co CN C) IC-14 N Q 0 N— — 4 LO 'o co a) CD m 11 m w m m C) 0 C) C) C) C) 0 C) 0 C) 0 0 Lu (1) C) C) 0 0 0 c::o 0 C> U) w 0 Z LL.LL LL LL LL LL U- LL U- C.) 0 U- LL U- U- U- U- U- LL U- LL LL U- LL U- O I-- LL E2 2 U) lu-. Z 7E Z w UJ T7 r- 00 OD c� C) CD Q CD CD CD CD C) C� CD 0 C) o C) CD C) 0 Cl W z 0 1-- C) 0 C) 0 C) 0 C) CD (D CD C) (D 0 C) C) 0 C) 0 C.) 4) CD 0 C) 0 C) CD C) 0 C) C) cl C-4 C-4 C'4 N C'4 C'4 C2 2 z �� 0 -4 -4 CN clj CN CN 04 C4 — — — — — — x w U) w 0 C-4 C-4 C'4 Q c c C14 Lf) ul "T —r- C'4 CD CD C) CN N C:) — — — — — — — 0 .2) 0 ❑ Z- :z cl, C,4 (0 r- r,- w m m m m CY) —01 cq C14 cq CD 0 W) Lo Lo (c) C) C) C) CD C) C) C) C) C) C) C) 4) 4z C) C) co C) C) C) 0- B LE LI- o Z 0 Ci C C 0 " C C CC) C I" 0 0 0 0 0 0 U- > 4) wU) U) U) (L) () V V r W >1 cu EU 0 ca m m (a (a c0 c6 c0 cu a "0 �o "D _0 -0 U) UJ W wn. a LO C) C) C) a C) C) C) C) C> C) C� C) cr) C\l Q c1r) (0 (Y) N C14 00 n z 0 rn w co CL m .0 0 C: :5 �p (D E u) E U) CL Co 0 > a- w a) 0 (D (n u) E C) 4- a- 0 4) ::3 C) 0 C) C) rn> (D(1) o c: a- 0 0 c C: c D CL CO Z c 4- 9 (D a) 0 0 0 0) C*D a Ccs CL 0) 0) C:) C� a) a) a) 0) > a) ca cn co Co o LU 42 0 a) z_Um LO) 00)0 - 0 U) 00 > =3 > x =3 0 0 Z cu 3: tm cm �: w L) - ui ULL CL 3� 0 U) 2 U) E Ui 0 LD A) 06 a) o cc co *5 0 0 U) M UJ G C: 0 0- CL 0 a) 0 0 0 Z Z C: w (D (D E = ff �> W — 0 i5 L) > Co U) C: C: 0 cc a) 4) :3 U) 0 (D 0 2 9) �o 0 (D 0 a. n- z 5 61 LO CO co N� �- � � � � T C,4 C,4 N C14 Lu LL— —IC-4 . 1 CITY OF FORT WORTH y Nf 31ST ST / WRA CRUZ d J1ST � DE EY CRO SlN - 30TH RE LA EME T DE N cic3 NE 291H ST 2911i'' MOND HILL ELEMENT Y LORAIN NE 28 riS CR SS/ G RE LA ME T NE 28TH ST NE 28TH ST TRAIL DRIVERS PARK Q � W o . l BRENNAN CROSSI REPLACEMENT BR�T4ygM1, A TTACHMENT E-1 LEBOW CHANNEL ROADWA Y CROSSING REPLACEMENT DEWEY - NE 28TH - BRENNAN CITY PROJECT NO 00181 FoRTWORTH COUNaL DISTRICT N0. 2 MAPSCO N0. 61A, 61B 2048-408 CITY OF FORT WORTH, TEXAS SCALE N A TEAGUE MAU AND PERKINS LEBOW CHANNEL SHEET VEraL ttoo Mmoon arrest Fort worth, T*Xms 78102 DEWY - NUM - BRENNAN 1 DATE �/VC. Pnon•:(817)330-0T73•Fax:l3tT)330-2813 EXHIBIT E-1 MAR 2007 www.tnp-onllnf.com City of Fort Worth, Texas Mayor and Council Communication COUNCIL ACTION: Approved on 6/12/2007 DATE: Tuesday, June 12, 2007 REFERENCE NO.: **C-22177 LOG NAME: 30LEBOW-TNP SUBJECT: Authorize Execution of an Engineering gteatnBrennwith an Street, 28th and Perkins, and Dewey Avenue Channel Roadway Crossing Replaceme (Project No. 00778) RECOMMENDATION: It t recommended that the Inc., in'theuamountorize the City Manager of $361,072.00 foroLebowte an Channel'neering agreement Roadway Crossing with Teague Nall and Perkins,e , Replacement at Brennan Street, 28th Street and Dewey Avenue. DISCUSSION: On August 30, 2005, the City Council authorized an engineering agreement with Teague Nall and Perkins, Inc., (M&C C-20925) to develop a detailed improvement plan for the Lebow Channel watershed. This plan was recently completed and presented to the public in a series of neighborhood meetings. Improvements identified in the plan include the elimination of dangerous low water crossings, enlargement of undersized bridges and culverts, acquisition of flood prone properties, the creation of lineal parks along restored stream beds, storm water detention, and channel enlargement. The 2004 Capitol Improvement Program (CIP) includes funds for the design of capital projects for storm drain facilities to alleviate recurring flooding problems in various locations. plans and This project, the first identified in the Lebow Channel Watershed Plan, will provide 28th Street specifications for the replacement of undersized drainage crossing structures at Brennan Street, and Dewey Street. The scope of services for the project also includes the preparation of a 404 Environmental Study which must be completed prior to other planned improvements in the watershed. Teague Nall and Perkins, Inc., proposes to perform the necessary design work for a lump sum fee of $361,072.00. City Staff considers this to be fair and reasonable for the scope of services proposed. In addition to the contract amount, $93,077.50 is required by the Engineering Department for project management. M/WBE — Teague Nall and Perkins, Inc., is in compliance with the City's M/WBE Ordinance by committing to 26 percent M/WBE participation. The City's goal on this project is 26 percent. This project is located in COUNCIL DISTRICT 2, Mapsco. FISCAL INFORMATION/CERTIFICATION: The Finance Director certifies that funds are available in the current capital budget, as appropriated, of the Page 1 of 2 Street Improvements Fund. TO fund/Account/Centers FROM Fund/Account/Centers 3)C200 531200 202280077831 $89.571.00 MC200 531200 202280077832 $179,144.00 3)C200 .531200 202280077833 $29,857.00 3)C200 531200 202280077851 $62.500.00 Submitted for Cid Manager's Office by, Marc Ott (8476) Originating Department Head: A. Douglas Rademaker (6157) Additional information Contact: Dena Johnson (7866) r ��_ '2nT U1:1n-%17_TTTP Page 2 of 2