The URL can be used to link to this page

Home My WebLink AboutOrdinance 8081Wig, ., ORDINANCE NO ~:~ 0 8 r ORDINANCE ACCEPTING IMPROVEMENTS ON A PORTION OF MF.A['HAM nnrTr.FVAgD AND PORTIONS OF SiTNDRY OTHE~t STREETS y -AVENUES AND PUEEIC PEACES IN THE CITY OP FORS WbRTHg °TEXAS9 DECLARING THE CONTRACT WITH TEXAS BITULITHIC COMPANY FOR THE CONSTRUCTION OI° SAID IMPROVEMENTS FU3.II~Y COMPY~ETED AND PERFORMED9 DIRECTING THE ISSUANCE s EXECUTION ANY3 DEEI~iERY OF CERTIFICATES IN EVIDENCE OF SPECIAE ASSESSMENTS LEVIED AFTER GIVING EFFECT TO SUIJDRY CREDITS HEREIN AUTIiORIZED AND ALLOWED AGAINST SOME OF SAID ASSESSMENTS DIRECTING THE CYTY SECRETARY TO ENGROSS AND ENROLL THIS ORDINANCE BY CODING THE CAPTION OF SAME IN THE MINUZ°E BOOlg OF THE CITY COUNCIL OF FORT WORTHa TEXASs AND EY EYEING. THE COMPEETE.ORDINANCE IN APPROPRIATE ORDINANCE RECORDS OF SAID CITYa AND PROVIDING AN EFFECTIVE DATE WHEREASp the City of Fort Worthe Texaae has heretofore entered into a contract with texas Bi~,B~ ith; c Cenro,~~ 8 for the malting aired construction of certain street improvrementa on the hereinafter described portions of atreetsa avenues and public places in said Cityn to~~rit MEACHAM BOULEVARD UNIT II From North Beach Street to IFT-35W, known and designated as Project No 13-036'444-00, Unit II, a seven-inch thick concrete pavement on a six-inch thick lime stabilized subgrade with seven-inch high superimposed concrete curb, so that the finished roadway will consist of two twenty- six foot traffic lanes with a twenty-eight foot median Seven-inch thick concrete approaches and turn-lanes will be constructed where specified SYLVANIA AVENUE, UNIT IIIA From Meacham Boulevard to Leamside, known and designated as Project No 13-0364'44-00, Unit IIIA, a seven-inch thick concrete pavement on a six-inch thick lime stabilized sub- grade with seven-inch high superimposed concrete curb so that the finished roadway will consist of twotwenty-six foot traffic lanes with a twenty-eight foot median Seven- inch thick concrete approaches and turn-lanes will be ~on- structed where specified SYLVANIA AVENUE, UNIT IIIB From Meacham Boulevard to Leamside, known and designated as Project No 13-036444-00 Unit IIIB, a seven-inch thick concrete pavement on a six-inch thick lime stabilized sub- grade with seven-inch high superimposed concrete curb, so that the finished roadway will consist of two twenty-six foot traffic lanes with a twenty-eight foot median Seven- inch thick concrete approaches and turn-lanes will be con- structed where specified ~~~~ •:.~,t-.~,,.. tivHEN.~;AS, by sundry proceedings heretofore passed by the City Council of the City of Fort Ydorth, Texas, including Ordinance No 7672 , a portion of the cost of said improvements was levied and assessed against the respective properties abutting on each of the above described portions of streets, avenues and public places and against the real and true owners thereof; and, wHE~~,AS, the City Council of the pity of Fort V+orth, Texas, has, upon review, found and determined that, in some instances, in order to effect substantial justice and equality, it is desirable and necessary to grant and issue certain credits a~.;ainst some one or more of the assessments levied by Ordinance No _7672 , and WHEti~;Aa, the street improvements hereinabove mentioned have been completed upon each of the portions of streets, avenues and public places hereinabove described, and have been inspected and found to be in complete accordance with the contract therefor; NU4d, TtiEhEFURF, BE IN ORDAINED I3Y THE CITY COUNCIL OF THE CITY OF FORT WORTH, TEXAS, THAT I The improvement-s on each of the portions of streets, avenues and public places hereinabove described be, and they are hereby, accepted; and the contract with reference thereto be, and it is hereby, found and declared fully completed and performed II The Mayor, be, and he is hereby, directed to issue and execute in the name of the City, certificates in evidence of the special assessments levied against abutting property and the owner thereof for such improvements, and the City Secretary is directed to attest same and impress thereon the corporate seal of the City, all in accordance Urith the proceedings relating to such improvements and assessments The certificates shall be numbered, shall describe the property against which the assessment has been levied, shall, where known, state the name or names of the true owners of the respective parcels of pro- perty assessed and shall be issued in an amount equal to the difference between the principal amount of the assessment and the amounts of any credit issued thereon The numbers of the certificates, with the property descriptions to be shown on the respective certificates, together with the names of the owners of said property, the principal amount of the assessment, the respective credits, if any which are hereby authorized, granted and allowed against the principal amount of some one or more of the assessments heretofore levied, and the principal amount for which each certificate is to be issued after giving effect to such credit, if arty, are hereby enumerated and itemized as follows ~i >> III When each of the certificates has been duly executed as hereinabove provided, same shall be delivered to the Tax Assessor-Collector as part payment of the contract price IV The City Secretary is hereby directed to engross and enroll this ordinance by copying the caption of same in the Minute Book of the City Council of Fort Worth, Texas, and by filing the complete ordinance in the appropriate Ordinance Records of said City V This ordinance shall take effect and be in full force and effect from and after the date of its passage v ~rL PASSED AIdD APPROVED THIS O _ APPROVED AS ~'0 FORM A1~TD LEGALITY day of ~ '~- ~ 19 ~ y City Attorney 3 1 PROJECT NO 13-036444-00, (104-36000-444) STREET IMPROVEMENTS FOR DILLARD'S WAREHOUSE, UNIT II MEACHAM BOULEVARD FROM NORTH BEACH STREET TO I H 35W, to be improved by constructing a seven- inch thick concrete pavement on a six-inch thick lime stabilized subgrade with seven-inch high superimposed concrete curb, so that the finished roadway will consist of two twenty-six foot traffic lanes with a twenty-eight foot median Seven-inch thick. concrete approaches and turn- lanes will be constructed where specified BLOCK OWNER LOT ZONING FRONTAGE RATE AMOUNT Beginning at the southwest corner of Meacham Boulevard and Beach Street SOUTH SIDE Vantage Properties, Inc 1 6 2525 Stemmons Freeway Vol 6310 Ird Dallas, Texas 75225 Page 569 American Mfg Co Tract 1 of Texas Vol 5590 Ind P 0 Box 7037 Page 453 Riverside Drive intersects American Mfg Co Tract 1 of Texas Vol 5590 Ind P 0 Box 7037 Page 453 NORTH STAR ADDITION 2210' Adjusted to (Drainage easement) 2103' Pavement $35 84 $75,371 52 2083' Curb 1 43 2,978 69 271 S F Driveway 1 59 430 89 2103' Street. lights, Drainage & Gas line relocation 45 40 95,476 20 A. BEARD SURVEY 430' Pavement $35 84 $15,411 20 430' Curb 1 43 614 90 430' Street lights Drainage & Gas line relocation 45 40 1q 522 00 2023' Adjusted to (Drainage easement) 1813' Pavement $35 84 $64,977 A2 1803' Curb 1 43 2 579 29 1937 85 S F Left-turn ~ lane 1 59 3,081 18 1$i3' Street lights Drainage & Gas line relocation 45 40 82,310 20 ASSESSMENT $174,257 30 $ 35 548 10 $152,948 59 1 Q PROJECT NO 13-036444-00, (104-3600 MEACHAM BOULEVARD Continued STRF.F.T TMPR(1vRMRNTS FOR DILLARD' S WAREHOUSE, UNIT II BLOCK OWNER LOT ZONING FRONTAGE RATE AMOUNT ASSESSMENT Polaris Drive intersects A BEARD SURVEY American Mfg Co Tract 1 436' Pavement $35 84 $15,626 24 of Texas Vol 5590 Ind 316° Curb 1 43 451 88 P 0 Box 7037 Page 453 1937 85 S F Right-turn lane 1 59 3,081 18 436' Street lights, Drainage & Gas line relocation 45 40 19,794 40 $ 38 X53 70 Lone Star Gas Co Tract 1-A Ad Valorem Tax Dept Vol 1921 Ind 301 S Harwood St Page 553 Dallas Texas 75201 American Mfg Co Tract 1 of Texas Vol 5590 Ind P 0 Box 7037 Page 453 Sylvania Avenue intersects MARY JOHNSON SURVEY 85~ No benefit -0- 4077 1 S F Right-turn lane $ 1 59 $ 6,482 59 $ 6,482 59 Julius Bruner Tract 1 1054' Pavement $35 84 $37,775 36 Route 6, Box 259 Vol 2012 Ind 1034' Curb 1 43 1,478 62 Alta Vista Road Page 303 1054' Street lights, Fort Worth, TX 76111 Drainage & Gas line relocation 45 40 47 851 60 $ 87 105 58 I H 35W intersects NORTH SIDE DAVID ODUM SURVEY American Mfg Co Tract 11-A 400' of Texas Vol 6334 Ind 400' P 0 Box 7037 Page 545 400° Pavement $35 84 $14,336 00 Curb 1 43 572 00 Street lights, Drainage & Gas line relocation 45 40 18,160 00 $ 33 068 00 2 PROJECT NO 13-036444-00, (104-36000-444) STREET IMPROVEMENTS FOR DILLARD'S WAREHOUSE, UNIT II MEACHAM BOULEVARD Continued OWNER BLOCK LOT ZONING FRONTAGE NORTH SIDE American Mfg Co of Texas P 0 Box 7037 Tract 11 Vol 6199 Ind Page 153 Aquarius Drive intersects American Mfg Co Tract 11 of Texas Vol 6199 Ind P 0 Box 7037 Page 153 Sylvania Avenue intersects American Mfg Co Tract 14 of Texas Vol 5590 Ind P 0 Box 7037 Page 453 Polaris Drive intersects DAVID ODUM SUILVEY RATE 90' Pavement $35 84 90' Curb 1 43 90' Street lights Drainage & Gas line relocation 45 40 505' Pavement $35 84 485' Curb 1 43 4077 1 S F Right-turn lane 1 59 505' Street lights, Drainage & Gas line relocation 45 40 516' Pavement $35 84 496' Curb 1 43 2505 2 S F Left-turn lane 1 59 2856 6 S F Approach 1 59 1937 85 S F Right-turn lane 1 59 516' Street lights, Drainage & Gas line relocation 45 40 AMOUNT ASSESSMENT $ 3,225 60 12s 70 4,086 00 $ 7 440 30 $18,099 20 693 55 6 482 59 22,927 00 $ 48 202 34 $18,493 44 709 28 3,983 27 4 541 99 3,081 18 23 426 40 $ 54 235 56 American Mfg Co Tracts 14, 2020' Adjusted to (Drainage easement) of Texas 14-A-1, 14-A-3, 14-B-1 1810' Pavement $35 84 $64 870 40 P 0 Box 7037 & 14-B Ind 1730' Curb 1 43 2,473 90 Vol 5590 1937 85 S F Right-turn Page 453 lane 1 59 3,081 18 1810' Street lights, Drainage & Gas line relocation 45 40 82 174 00 $152,599 48 3 PROJECT NO 013-036444-00, (104-36000-444) STREET IMPROVEMENTS FOR DILLARD S WAREHOUSE,UNIT II MEACHAM BOULEVARD continued OWNER LOT Riverside Drive intersects NORTH SIDE American Mfg Co of Texas P O Box 7037 Fort Worth,TX BLOCK ZONING FRONTAGE Tract 15 Ind Vol 5590 Pg 453 DAVID ODUM SURVEY 2652 adjusted to 2562' Pavement 2482 Curb 2562 Street lights Drainage & Gas line relocation RATE AMOUNT ASSESSMENT (Drainage easement) $35 84 $91,822 08 1 43 3,549 26 45 40 116 314 80 $211,686 14 UNIT II Total cost to property owners (deferred payment) $1,002,527 68 Total cost to City of Fort Worth $1,255,516 97 Total construction cost ~. $2 258 O~~~,r,65 4 _PROJECT NO 13-036444-00, (104-360008444) STREET" TMf''R~OVEMEI~S 'F'OR DILLARD' S WAREHOUSE, ~~ ,=I2A SYLVANIA AVENUE~FROM MEACHAM BOULEVARD TO LEAMSIDE, to be improved by constructing a seven- inch thick concrete pavement on a six--inch. thick lime stabilized subgrade with seven-inch high superimposed concrete curb, so that the finished roadway will consist of two twenty-six foot traffic lanes with a twenty-eight foot median Seven-inch thick concrete approaches and turn- lanes will be constructed where specified BLOCK OWNER LOT ZONING FRONTAGE RATE AMOUNT WEST SIDE MARY JOHNSON SURVEY Julius Bruner Tract 1 120' Pavement $30 19 $ 3 622 80 Route 6 Box 259 Vol 2012 Ind i20' Curb 1 43 171 60 Alta Vista Road Page 303 Fort Worth, TX 76111 Meacham Boulevard intersects DAVID ODUM SURVEY American Mfg Co Tract 11 507' Pavement $30 19 $15,306 33 of Texas Vol 6199 Ind 497' Curb 1 43 710 71 P 0 Box 7037 Page 153 4072 1 S F Right-tur n 1 47 5,985 99 lane 5102 5 S F Approach. 1 47 7 50n 68 lane 3131 86 S F Left-tur n 1 47 4 603 83 lane Polaris Drive intersects American Mfg Co Tract 11 216' Pavement $30 l9 $ 6 521 ~4 of Texas Vol 6199 and 216° Curb 1 43 308 88 P 0 Box 7037 Page 153 3131 86 S F Right-turn .1 47 4,603 83 lane 1327 2 S F Approach 1 47 1,950 98 lane EAST SIDE American Mfg Co Tract 14 216' Pavement $30 19 $ 6 521 04 of Texas Vol 5590 Ind 216' Curb 1 43 308 88 P 0 Box 7037 Page 453 3131 86 S F Left-turn 1 47 4,603 83 lane 1327 2 S F Approach 1 47 1,950 98 lane ASSESSMENT $ 3 794 40 $34,107 54 $13,384 73 $13 384 73 s PROJECT NO 13-036444-00, (104-36000-444) STREET IMPROVEMENT°S FOR DILLARD'S WAREHOUSE, UT IT ILIA SYLVANIA AVENUE, Continued ~' BLOCK OWNER LOT ZONING FRONTAGE RATE AMOUNT ASSESSMENT Polaris Drive intersects DAVID ODUM SURVEY American Mfg Co Tract 14 507' Pavement $30 19 $15,306 33 of Texas Vol 5590 Ind 487' Curb 1 43 696 41 P 0 Box 7037 Page 453 3131 86 S F Right-turn 1 47 4,603 83 lane 4933 S F Approach lane 1 47 7,251 51 $27,858 08 Meacham Boulevard intersects MARY JOHNSON SURVEY Lone Star Gas Co Ad Valorem Tax Dept 301 S Harwood St Dallas, Texas 75201 Tract 1-A 120' No benefit -0- POLARIS DRIVE Southwest side DAVID ODUM SURVEY American Mfg Co Tract 11 100' Pavement $30 19 $ 3,019 00 of Texas Vol 6199 Ind 100' Curb 1 43 143 00 P 0 Box 7037 Page 153 $ 3,162 00 Northwest side American Mfg Co Tract 11 100' Pavement $30 19 $ 3,019 00 of Texas Vol 6199 Tnd 100' Curb 1 43 143 00 P 0 Box 7037 Page 153 $ 3,162 00 6 PROJECT NO 13-036444-00,(104-36000-444) STREET IMPROVEMENTS FOR DILLARD S WAREHOUSE,UNIT IIIA SYLVANIA AVENUE, continued BLOCK OWNER LOT ZONING FRONTAGE RATE AMOUNT ASSESSMENTS DAVID ODUM SURVEY Northeast side American Mfg Co Tract 14 100' Pavement $30 19 $3,01900 of Texas Ind 100 Curb 1 43 143 00 P O Box 7037 Vol 5590 PG 153 $3 162 00 Fort Worth TX Southeast side American Mfg Co Tract 14 100' Pavement $30 19 $3 019 00 of Texas Tnd 100 Curb 1 43 143 00 P O Box 7037 Vol 5590, Pg 153 $3 162 00 Fort Worth, TX UNIT IIIA Total Bost to property owners r;(+assessments) $105 177 48 7 PROJECT NO 13-036444-00, (104-36000-444) STREET IMPROVEMENTS FOR DILLARD'S WAREHOU4E~ UNIT IIIB SYLVANIA AVENUE FROM MEACHAM BOULEVARD TO LEAMSIDE, to be improved by constructing a seven-inch thick concrete pavement on a six-inch thick lime stabilized subgrade with seven- inch high superimposed concrete curb, so that the finished roadway will consist of two twenty- six foot traffic lanes with a twenty-eight foot median Seven inch thick concrete approaches and turn-lanes will be constructed where specified BLOCK OWNER LOT ZONING FRONTAGE RATE AMOUNT ASSESSMENT DEFERRED PAYMENT ASSESSMENT ROLL WEST SIDE MARY JOHNSON SURVEY Julius Bruner Tract 1 120' Street lights, Route 6, Box 259 Vol 2012 Ind Drainage & Gas Alta Vista Road Page 303 line relocation $45 40 $ 5,448 00 Fort Worth., Texas 76111 $ 5 448 00 Meacham Boulevard intersects DAVID ODUM SURVEY American Mfg Co Tract 11 507' Street lights, of Texas Vol 6199 Ind Drainage & Gas P 0 Box 7037 Page 153 line relocation $45 40 $23 017 80 $23,017 80 Polaris Drive intersects American Mfg Co Tract 11 216' Street lights, of Texas Vol 6199 Ind Drainage & Gas P 0 Box 7037 Page 153 line relocation $45 40 $ 9,806 40 $ 9,806 40 EAST SIDE American Mfg Co Tract 14 216' Street lights, of Texas Vol 5590 Ind Drainage & Gas P 0 Box 7037 Page 453 line relocation $45 40 $ 9 806 40 $ 9,806 40 Polaris Drive intersects American Mfg Co Tract 14 507' Street lights, of Texas Vol 5590 Ind Drainage & Gas P 0 Box 7037 Page 453 line relocation $45 40 $23 017 80 $23 017 80 Meacham Boulevard intersects A.BEARD SURVEY American Mfg Co Tract 1 120' Street lights, of Texas Vol 5590 Drainage & Gas P 0 Box 7037 Page 453 line relocation $45 40 $ 5 448 00 $ 5,448 00 8 a PROJECT NO 13-036444-00, (104-36000--444) STREET IMPROVEMENTS FOR DILLARD'S WAREHOUSE ,UNIT IIIB, SYLVANIA AVENUE continued BLOCK OWNER LOT ZONING FRONTAGE RATE AMOUNT ASSESSMENT Polaris Drive DAVID ODUM SURVEY American Mfg Co of Texas P 0 Box 7037 Fort Worth TX American Mfg Co of Texas P O Box 7037 Fort Worth TX American Mfg Co of Texas P O Box 7037 Fort Worth TX American Mfg Co of Texas P O Box 7037 Fort Worth, Texas Southwest side Tract 11 Ind Vol 6199,PG 153 Northwest side Tract 11 Ind Vol 6199 PG 153 Northeast side Tract 14 Ind Vol 5590 Pg 153 100 Street lights Drainage & Gas line relocation 100 Street lights Drainage & Gas line relocation $45 40 $4 54000 $45 40 $4, 54000 100' Street lights Drainage & Gas line relocation `$45 40 $4 540 00 $4,540 00 $4540 00 $4,540 00 Southeast side Tract 14 Ind ~~ Vol 5590 Pg 153 100 Street lights, drainage & gas line relocation $45 40 $4 540 00 .~ $4 540 00 UNIT IIIB Total cost to property owners (::deferred payments) $94 704 40 UNIT IIIA & IIIB TOTAL COST TO PROPERTY OWNERS (ASSESSMENTS) $105,177 48 TOTAL COST TO PROPERTY OWNERS (DEFERRED PAYMENTS) $ 94 704 40 TOTAL COST TO CITY OF FORT WORTH $261 357 24 TOTAL CONSTRUCTION COST $461,239 12 9 PROJECT NO 13-036444-00, (104-36000-444) STREET IMPROVEMENTS FOR DILLARD'S WAREHOUSE, UNITS II AND III, continued BLOCK OWNER LOT ZONING FRONTAGE RATE AMOUNT ASSESSMENT ALL UNITS TOTAL COST TO PROPERTY OWNERS (ASSESSMENTS) TOTAL COST TO PROPERTY OWNERS (DEFERRED PAYMENTS) TOTAL COST TO CITY OF FORT WORTH TOTAL CONSTRUCTION COST $ 105,177 48 $1 097 232 08 $1,460 76240 $2;663 171 96 10 a~/ City of Fort Worth, texas _ _ IV7ayor ct~d Councal Cornanunzcataon DATE REFERENCE SUBJECT Final Payment - Street Improve- PAGE NUMBER ments for Dillard s Warehouse Unit II- 4/8/80 **FP-1440 Meacham Blvd., Unit III-Svlvania Ave. 1ot_..3~ Project No 104-36444 Final Council action is requested on the project described below Project Descr-iption Name Street Improvements for Dillard s Warehouse Unit 2 Meacham Blvd Unit 3 Sylvania Ave Project No 104-36444, Contract No 9580 dated November 15 1977 Contractor Texas Bitulithic Company Contract Awarded 11-15-77 M&C C-3989 Work Order Issued 12-2-77 Work Order Effective 12-2-77 Work Began 12-1-77 Project Substantially Complete and Final Inspection Made 7-11-79 Final Construction Approval 2-29-80 Working Time Bid 338 Calendar Days Working Time Used 586 Calendar Days Project Cost Original Bid Price $ 2 431,138 97 Change Order No 1 $65 637 05 M&C C-4231 2.2,861 10 M&C C-4231 3 25 255 85 M&C C-4231 4 15 730 70 M&C C-4231 5 2 344 00 M&C C-4231 6 6 825 00 M&C C-4359 7 5 027 70 M&C C-4411 Proposed Change Order No 8 The developer requested that 12 slotted drain be installed at the toe of the riprap between bridges on Sylvania Aver and Meacham Blvd to prevent water flowing across sidewalk to creek This drain can be installed at $33 00 per L F with the developer paying $851 00 of the total cost of $2 508 Original Bid Price Change Orders to Date Proposed Change Order No 8 Revised Contract Cost $2 431 138 97 143 681 40 2,508 00 $2 577 328 37 Final Contract Cost $2 565 362 05 Partial Payments Previously Made 16 Final Payment Due $267 222 04 Deviat-ion from Bid P-r-ice Amount $2,298 140 O1 The final contract cost of this project is $11 966 32 under the revised bid D/4vE REFERENCE SUBJECT Final Payment - Street Improve- I PAGE NUMBER ments for Dillard s'~Warehouse ilnit t1Z- 4/8/80 **FP-1440 Meacham Blvd._i_Unit III-Sy~•vania'"A-ve. •-`~'"- or .~`_ Project No 1014 '36444 i ~ "' ' ~ i price The und'errun is the result of diff~ren~es between quantities estimated for the contract documents and quantities actually used to complete the work Gont.xact T„i:me ~ Thee work order for this prroject was issued on December 2 1977, with computation of time to commence. on that date The con Tact stipulates. that time of completion is an essential element of: the contract and that the street be in full use no Pater than iJuly 22 1978 The contractor completed the concrete roadway sufficiently to meet the needs of Dillard s Warehouse and the public Technically the street was in full use aS specified even though there was other work to be accomplished outside the limit's of the Meacham Blvd paving The cohtracto.r achieved the desired results although he lost in exeess of two months working time due to bad weather in the months of December 1977 and in January February and March, 197$ Between December 2 1977, and l~arcli 31 1978, (119 calendar days), other projects reviewed show that City contractors were able td work only an average of 26 working days As provided under Section 3 of the contract the contractor is entitled to an extension for time he may necessarily lose or be. delayed by unforseen matters over which he has no control such. as inclement weather acts of providence labor strikes and delivery of materials in cases that contractor negligence or carelessness did not contribute to the delay In addition to the delay caused by the extreme winter of 1978 the contractor further was delayed because Lone Star Gas Company did not receive the necessary material to relocate their facilities until after January 1 1978 and Lone Star also was delayed by the weather Their anticipated completion date was changed from December 23 1977 to March 22 1978 Consequently the contractor could not. proceed with the street work where it was in conflict with the gas line Further eight change orders were issued on the project in the total amount of :146 189 30 and of this amount $110 995 45 was paid by the developer The Tast change order on this project in the amount of w2 508 00 was issued on December 31 1979 In summation since the contractor through exerted effort did sufficiently complete the paving on ileacham Blvd by the stipulated time to meet the needs oL Di ].lard s arehouse rand cite publ.i.c s aff recommends that no liquidated damages be charged Financing Funds are available for the final payment to be made from Project Number 104-36444 Account and in water Account No 015-017769 Compliance with Specifications The project has been completed in accordance with the requirements of the contract DATE REFERENCE SUBJECT Final Payment - Street ImprOVe- PAGE NUMBER ments for Dil lard s Warehouse t7nit II- 3 3 4/8/80 **FP-440 Meacham Blvd. Unit III-S Lvania Ave. ar Project No 1 04-36444 Recommendation It is recommended that 1 Change Order No 8 be approved increasing the amount of the contract with Texas Bitulithic Company to $2 577 328 37 and 2 The project described above be accepted by the adoption of on ordi- nance and the final payment of $267 222 04 be mad e to Texas Bitulithic Company RAM lj A~~RdV~~ ~Y CITY ~Ot~(~ClL APB $ t~$(~ SUBMITTED FOR THE ++ ' ~0~ ~ DISPOSITION BY COUNCIL: ~ )R P O ES D BY CITY MANAGER S f OFFICE BY: ~ ^ APPROVED ORIGINATING K~23~~1...~i. ~~~~~~ ~ ~~ DEPARTMENT HEAD: ~ ~~q,~$~ p~pi~R~QF~SCR16~~ ~ / ~Fy ~g gV$U I CITY SECRETARY FOR ADDITIONAL INFORMATION ' + ` CONTACT: .TFO.t1II. JOn' , .~ ,~Ti. DATE