HomeMy WebLinkAboutOrdinance 22728-05-2017 ORDINANCE NO.22728-05-2017
AN ORDINANCE INCREASING THE ESTIMATED RECEIPTS AND
APPROPRIATIONS IN THE AMOUNT OF $199,959.00 IN THE STREET
IMPROVEMENTS FUND CLOSE, FROM AVAILABLE FUNDS, FOR THE
PURPOSE OF FUNDING THE ADDITIONAL PROJECT COSTS IN THE OLD
DECATUR ROAD PROJECT; PROVIDING FOR A SEVERABILITY CLAUSE;
MAKING THIS ORDINANCE CUMULATIVE OF PRIOR ORDINANCES;
REPEALING ALL ORDINANCES IN CONFLICT HEREWITH;AND PROVIDING
AN EFFECTIVE DATE.
BE IT ORDAINED BY THE CITY COUNCIL OF THE CITY OF FORT WORTH,
TEXAS:
SECTION 1.
That in addition to those amounts allocated to the various City departments for Fiscal Year 2016-2017 in the
Budget of the City Manager,there shall also be increased estimated receipts and appropriations in the amount
of$199,959.00 in the Street Improvements Fund Close, from available funds, for the purpose of funding the
additional project costs in the old Decatur road project.
SECTION 2.
That should any portion, section or part of a section of this ordinance be declared invalid, inoperative or void
for any reason by a court of competent jurisdiction,such decision,opinion or judgment shall in no way impair
the remaining portions, sections,or parts of sections of this ordinance,which said remaining provisions shall
be and remain in full force and effect.
SECTION 3.
That this ordinance shall be cumulative of Ordinance 22394-09-2016 and all other ordinances and
appropriations amending the same except in those instances where the provisions of this ordinance are in
direct conflict with such other ordinances and appropriations,in which instance said conflicting provisions of
said prior ordinances and appropriations are hereby expressly repealed.
SECTION 4.
This ordinance shall take effect upon adoption.
APPROVED AS TO FORM AND LEGALITY:
9 "1 1 W/ Z'K�—
Douglas W. Black, Mary J. er
Sr.Assistant City Attorney City Secretary
ADOPTED AND EFFECTIVE: May 16,2017
Ordinance No.22728-05-2017
Page 1 of 1
WIN
I �""iwiii_`y � - ■ ■ I
==gill
l=folk
• • •rAl�r Jw.. y1k♦♦ i/�A IIIIIIi ■ i
.Y.:'. r"�:rr'r�.w��' M'+t';'�r►♦♦fit"' _ a 1111
'a e I -f"': . MI.♦ IC♦ ty�r r1{/
«I•�:C y��♦r�l'�♦♦'v ':rr{.Vy f{{riit lutner•"• -
li 'j14t 1 ► w'#"'�� w,r'►'1♦♦V♦♦1'♦1♦j Il, l.4\lll. IIu1t�1T .... ♦�r�
1�..1t���Tt 'MMF v+i�!� +♦ ♦wk�Y ny'�►`yr1`ygift{J 1lllllll► 1/11!11�r ..■..r;/. rA.■
_ �Mi{fl�_ �f��— Mr.�,�y;���♦ r1i'11 , '` i,.!,iH.r I�
t �\.®���.,,n. ♦,t♦ r♦,fir♦�{r{J'I�M� f\l\lll ��1111
�'Y .1+ ! 1'� ♦'` �♦'*r r� I !Y fit.
Vii " ••`*i.�"'�rir riit lingiiii�i l�
A� 1 ♦ *Hill/IIIIR,I11:7-1
! �' • „�-�.
azo 1 1��,9 If1'.�t91�1/■1111iJ1,�� �t A ..1.-
� r ° �1fM1�IIJYI{JI{Irf � „y
/:�• ,� ..:J' y4� C r13�11��I..f�1U1 � Ii1�A :,�i.
d
1 ! TT\ .�Y + «1�i� tl•ilii�.�ir ■ ,Ir �►r1�r1g;rr ♦ 1kr1a !�, ._�f.�r=w
rtlr 11�1#,1,1�y Yitl_ !11!! �w21 fi�l� �+t �'r.!y♦fir �� �,,. !� 1 Mimi
At paim,
Ae
o. � rl 1 4 /1!�'rS�►,w/ 11, w--- 111 - '\ �%■�. :'w'i,'1.
agg
ti>- ':.
,� *+� �. ■!! �r v wt.� •1111111 y
T'rid
.7• ■rte A-•r�l� ,•==
n
affligr.-1'��•�,�'. -• — ...w.. �11� --at.
r rr it r
river �ww�-wwww !1 1/.f-���_r. �.
wieti� 'Irrrr r rrrrrwr'1.•— r111- — _ 1.t 1/--..=w
r 0 �,
r ^ Ilwr"3C`ri.�.i ri.G ♦V'r +-.:1�. iii r:�1� ii iiilr foil
irr. —wrr ■ rwr ♦ _ / \�� t onurun u . /.i_IAL
eat- rrw �!....rr'y,�� I r i ! t ei..P��:C�
r
.ri rwi�q:%��� � �M ter. /I{Iii r/ t Wis ..
� _•. , .. t � ill GLH — C�
I!wwwww 'rye. � f l/Ire�r • IAlll O�"'_"'� �+
lrrrrrr t l� # (m BE®r
' f�rrrrrr :�,ytl / /�!��rr'rl 1/■111 � ���
f.J11J �� /`• —err
• ..�;, ;�.� 111Qi i iiia 1_liii/ :#i, 11_.���. �I
asIt1111IN
,r
Lltlltt�yi�111'u�r,�1ui11 1111:
I nor-, a for AAI a �I
1TNIfl111t11i11T�1t111/1 will{f{ f1i1 g '-'-^ �
X1111111111!IYANIIII1t _Arrf r IIIfI'.'�1►,1�irF '
Jrr\#ril +. ♦� IIIc ww.. / 111111
II1 111111.1�1--;::�Iaiuuu
f y'�.,ly'►•,,I,ni'I �;�did�i'�//' .�:��u�c:nur��f iii{{fort,a� 'fit 1
NOW 'UNMI 11111111' _
legal .
uUMN
rr
Jim I
ro it a a�r.r:M11fP 1��I
la y�..``ooll 1, 11:9,10
♦ I � # ^
� ° r1// !
�llr..'�....�.► 1 1•..•.—.. .- IIs 'r+
. �iI1'`�i••1��!�r►���t``�1.`�c..t'' ,���r1 Iliti:�.�l
lie
r/►ff�t� .""Y+r.:�::+�liji, :1 . ti'�w�.► t!!III .L.r .�,.`��
p
.':• r i
137s�pip1+;"�`itth``rtl����t/i.J ++1=�'rr • i!���'f_�11F�':,+I
�j'�{�"j��l�,�r �^�•r1A I 2000 4000 8000 11.2,„ •
City of Fort Worth, Texas
Mayor and Council Communication
COUNCIL ACTION: Approved on 5/16/2017 - Ordinance No. 22726-05-2017, 22727-05-2017
& 22728-05-2017
DATE: Tuesday, May 16, 2017 REFERENCE NO.: C-28244
LOG NAME: 20OLD DECATUR ROAD PHASE 2-CO2014
SUBJECT:
Authorize Execution of a Contract with Jackson Construction, Ltd., in an Amount Up to $4,319,628.00 for
Old Decatur Road Reconstruction from IH-820 to Angle Avenue (CO2014) and Provide for Additional
Project Costs for a Total Project Budget of$10,186,139.07 to Include Contingency, Staff Costs and
Potential Incentive Award, and Adopt Appropriation Ordinances (2014 BOND PROGRAM) (COUNCIL
DISTRICT 2)
RECOMMENDATION:
It is recommended that the City Council:
1. Adopt the attached appropriation ordinance increasing estimated receipts and appropriations in the Old
Decatur Road Project of the Transportation Impact Fee Capital Legacy Fund (39008) in the amount of
$1,753,390.68 and reduce the fund balance in the Service Area G Project (UN9917) of that fund by the
same amount;
2. Adopt the attached appropriation ordinance increasing estimated receipts and appropriations in the Old
Decatur Road Project of the Transportation Impact Fee Capital Fund (30108) in the amount of
$859,011.22 and reduce the fund balance in the Service Area G Project (UN9917) of that fund by the
same amount;
3. Adopt the attached appropriation ordinance increasing estimated receipts and appropriation in the Old
Decatur Road Project of the Street Improvements Fund Close (39409) in the amount of$199,959.00
(CFA#2005115; RD#346165; DOE#5045) and reduce the fund balance in the Unspecified Project of that
fund by the same amount; and
4. Authorize the execution of a construction contract with Jackson Construction, Ltd., in the amount of
$4,319,628.00 for Old Decatur Road Reconstruction from IH-820 to Angle Avenue and authorize a
potential incentive payment in the amount of$90,000.00.
DISCUSSION:
The 2014 Bond Program included Old Decatur Road as an improvement project from IH-820 to Angle
Avenue and is being delivered in two separate phases.
Phase 1, (Mayor and Council Communication (M&C C-27500) was the construction of a roundabout
intersection at Old Decatur Road and Angle Avenue and the extension of a large diameter water
transmission main. Phase 1 was completed in August 2016.
Phase 2 of the roadway improvement includes the construction of a three-lane street segment, capable of
Logname: 20OLD DECATUR ROAD PHASE 2-CO2014 Page 1 of 3
being expanded to four lanes in the future when traffic volumes warrant.
The project was advertised on January 12, 2017 and January 19, 2017 in the Fort Worth Star-Telegram
using the low bid with potential incentives method. On February 9, 2017 the following bids were received:
Bid Results
ontractor Bid Amount
ackson Construction, LTD $4,319,628.00
cMahon Contracting L.P. $4,390,663.21
Paw- con Pubiicworks, LP $5,536,647.63
ccelerated Critical Path, Inc $5,791,770.00
Jackson Construction, LTD, is the apparent low bidder. Old Decatur Road Reconstruction includes
contingencies, Staff costs and potential incentives. Upon approval of this M&C, the total project budget is
$10,186,139.07. There are potential incentives of$3,000.00 per day, up to a maximum $90,000.00, if the
contractor delivers the project prior to a specified final completion date, of 300 calendar days. Failure to
deliver the project by the specified final completion date will subject the contractor to liquidated damages
of$1,250.00 per day for an unlimited number of days until final completion is achieved.
Construction is anticipated to commence in June 2017 and be complete in 300 calendar days.
M/WBE OFFICE: Jackson Construction, Ltd., is in compliance with the City's BDE Ordinance by
committing to one percent MBE participation and documenting good faith effort. Jackson Construction,
Ltd., identified several subcontracting and supplier opportunities. However, the MBE's contacted in the
areas identified did not respond or did not submit the lowest bids. The City's MBE goal on this project is 13
percent.
A portion of this project will include 2014 Bond Funds. Available resources within the General Fund will be
used to provide interim financing for these expenses until debt is issued. Once debt associated with this
project is sold, bond proceeds will reimburse the General Fund in accordance with the statement
expressing official intent to reimburse.
This project is located in COUNCIL DISTRICT 2.
FISCAL INFORMATION / CERTIFICATION:
The Director of Finance certifies that upon approval of the above recommendations and adoption of the
attached appropriation ordinances, funds will be available in the current capital budget as appropriated, of
the Transportation Impact Fee Capital Legacy Fund, the Transportation Impact Fee Capital Fund, the
Street Improvement Fund Close Fund and the 2014 Bond Program Fund. The current fund balance in the
Service Area G Project of the Transportation Impact Fee Capital Legacy Fund is $1,825,389.80 and of the
of the Transportation Impact Fee Capital Fund is $1,250,267.40. The current fund balance in the
Unspecified Project of the Street Improvements Fund Close is $12,614,757.58.
FUND IDENTIFIERS (FIDs):
TO
Fund Department �4ccoun Project 'ProgramActivity Budget Reference # moun
L____
_ _ ID _ ID Year (Chartfield 2)
FROM
r7!t--
partment ccoun Project Program ctivity Budget Reference # moun
ID I I ID I Year Chartfield 2
Logname: 20OLD DECATUR ROAD PHASE 2-CO2014 Page 2 of 3
CERTIFICATIONS:
Submitted for City Manager's Office by: Jay Chapa (5804)
Originating Department Head: Douglas Wiersig (7801)
Additional Information Contact: Lissette Acevedo (2722)
Logname: 20OLD DECATUR ROAD PHASE 2-CO2014 Page 3 of 3