HomeMy WebLinkAboutContract 33083 r " CITY SECRETARY ' .
CONTRACT NO.
CITY OF FORT WORTH, TEXAS
STANDARD AGREEMENT FOR ENGINEERING SERVICES
This AGREEMENT is between the City of Fort Worth (the "CITY"), and Teague Nall
& Perkins Inc , (the "ENGINEER"), for a PROJECT generally described as: Pavement
Reconstruction on Chapel Creek Boulevard ( 130 North to Chapin Road 1.
Article I
Scope of Services
A. The Scope of Services is set forth in Attachment A.
Article II
Compensation
A. The ENGINEER's compensation is set forth in Attachment B.
Article III
Terms of Payment
Payments to the ENGINEER will be made as follows:
A. Invoice and Payment
(1) The Engineer shall provide the City sufficient documentation to reasonably
substantiate the invoices.
(2) The ENGINEER will issue monthly invoices for all work performed under this
AGREEMENT. Invoices are due and payable within 30 days of receipt.
(3) Upon completion of services enumerated in Article I, the final payment of any
balance will be due within 30 days of receipt of the final invoice.
(4) In the event of a disputed or contested billing, only that portion so contested
will be withheld from payment, and the undisputed portion will be paid. The
CITY will exercise reasonableness in contesting any bill or portion thereof. No
interest will accrue on any contested portion of the billing until mutually
resolved.
(5) If the CITY fails to make payment in full to ENGINEER for billings contested in
good faith within 60 days of the amount due, the ENGINEER may, after giving
7 days' written notice to CITY, suspend services under this AGREEMENT until
paid in full, including interest. In the event of suspension of services, the
ENGINEER shall have no liability to CITY for delays or damages caused the
CITY because of such suspension of services
4 I'
STANDARD ENGINEERING AGREEMENT(REV 10/06/05)
Page 1 of 14 }
Article IV
Obligations of the Engineer
Amendments to Article IV, if any, are included in Attachment C.
A. General
The ENGINEER will serve as the CITY's professional engineering
representative under this Agreement, providing professional engineering
consultation and advice and furnishing customary services incidental thereto.
B. Standard of Care
The standard of care applicable to the ENGINEER's services will be the
degree of skill and diligence normally employed in the State of Texas by
professional engineers or consultants performing the same or similar services
at the time such services are performed.
C. Subsurface Investigations
(1) The ENGINEER shall advise the CITY with regard to the necessity for
subcontract work such as special surveys, tests, test borings, or other
subsurface investigations in connection with design and engineering
work to be performed hereunder. The ENGINEER shall also advise the
CITY concerning the results of same. Such surveys, tests, and
investigations shall be furnished by the CITY, unless otherwise specified
in Attachment A.
(2) In soils, foundation, groundwater, and other subsurface investigations,
the actual characteristics may vary significantly between successive test
points and sample intervals and at locations other than where
observations, exploration, and investigations have been made. Because
of the inherent uncertainties in subsurface evaluations, changed or
unanticipated underground conditions may occur that could affect the
total PROJECT cost and/or execution. These conditions and
cost/execution effects are not the responsibility of the ENGINEER.
D. Preparation of Engineering Drawings
The ENGINEER will provide to the CITY the original drawings of all plans in ink
on reproducible plastic film sheets, or as otherwise approved by CITY, which
shall become the property of the CITY. CITY may use such drawings in any
manner it desires; provided, however, that the ENGINEER shall not be liable
for the use of such drawings for any project other than the PROJECT
described herein.
STANDARD ENGINEERING AGREEMENT(REV 10/06/05)
Page 2 of 14
r� .. ✓1.6'I.:i ;_, , �
._.......____elf
E. Engineer's Personnel at Construction Site
(1) The presence or duties of the ENGINEER's personnel at a construction site,
whether as on-site representatives or otherwise, do not make the ENGINEER
or its personnel in any way responsible for those duties that belong to the
CITY and/or the CITY's construction contractors or other entities, and do not
relieve the construction contractors or any other entity of their obligations,
duties, and responsibilities, including, but not limited to, all construction
methods, means, techniques, sequences, and procedures necessary for
coordinating and completing all portions of the construction work in
accordance with the Contract Documents and any health or safety precautions
required by such construction work. The ENGINEER and its personnel have
no authority to exercise any control over any construction contractor or other
entity or their employees in connection with their work or any health or safety
precautions.
(2) Except to the extent of specific site visits expressly detailed and set forth in
Attachment A, the ENGINEER or its personnel shall have no obligation or
responsibility to visit the construction site to become familiar with the progress
or quality of the completed work on the PROJECT or to determine, in general,
if the work on the PROJECT is being performed in a manner indicating that the
PROJECT, when completed, will be in accordance with the Contract
Documents, nor shall anything in the Contract Documents or the agreement
between CITY and ENGINEER be construed as requiring ENGINEER to make
exhaustive or continuous on-site inspections to discover latent defects in the
work or otherwise check the quality or quantity of the work on the PROJECT.
If, for any reason, the ENGINEER should make an on-site observation(s), on
the basis of such on-site observations, if any, the ENGINEER shall endeavor
to keep the CITY informed of any deviation from the Contract Documents
coming to the actual notice of ENGINEER regarding the PROJECT.
(3) When professional certification of performance or characteristics of materials,
systems or equipment is reasonably required to perform the services set forth
in the Scope of Services, the ENGINEER shall be entitled to rely upon such
certification to establish materials, systems or equipment and performance
criteria to be required in the Contract Documents.
F. Opinions of Probable Cost, Financial Considerations, and Schedules
(1) The ENGINEER shall provide opinions of probable costs based on the
current available information at the time of preparation, in accordance
with Attachment A.
(2) In providing opinions of cost, financial analyses, economic feasibility
projections, and schedules for the PROJECT, the ENGINEER has no
control over cost or price of labor and materials; unknown or latent
conditions of existing equipment or structures that may affect operation or
maintenance costs; competitive bidding procedures and market
STANDARD ENGINEERING AGREEMENT(REV 10/06/05)
Page 3 of 14
conditions; time or quality of performance by third parties; quality, type,
management, or direction of operating personnel; and other economic
and operational factors that may materially affect the ultimate PROJECT
cost or schedule. Therefore, the ENGINEER makes no warranty that the
CITY's actual PROJECT costs, financial aspects, economic feasibility, or
schedules will not vary from the ENGINEER's opinions, analyses,
projections, or estimates.
G. Construction Progress Payments
Recommendations by the ENGINEER to the CITY for periodic construction
progress payments to the construction contractor will be based on the
ENGINEER's knowledge, information, and belief from selective sampling and
observation that the work has progressed to the point indicated. Such
recommendations do not represent that continuous or detailed examinations
have been made by the ENGINEER to ascertain that the construction
contractor has completed the work in exact accordance with the Contract
Documents; that the final work will be acceptable in all respects; that the
ENGINEER has made an examination to ascertain how or for what purpose
the construction contractor has used the moneys paid; that title to any of the
work, materials, or equipment has passed to the CITY free and clear of liens,
claims, security interests, or encumbrances; or that there are not other matters
at issue between the CITY and the construction contractor that affect the
amount that should be paid.
H. Record Drawings
Record drawings, if required, will be prepared, in part, on the basis of
information compiled and furnished by others, and may not always represent
the exact location, type of various components, or exact manner in which the
PROJECT was finally constructed. The ENGINEER is not responsible for any
errors or omissions in the information from others that is incorporated into the
record drawings.
I. Minority and Woman Business Enterprise (M/WBE) Participation
In accord with City of Fort Worth Ordinance No. 15530, the City has goals for
the participation of minority business enterprises and woman business
enterprises in City contracts. Engineer acknowledges the M/WBE goal
established for this contract and its commitment to meet that goal. Any
misrepresentation of facts (other than a negligent misrepresentation) and/or
the commission of fraud by the Engineer may result in the termination of this
agreement and debarment from participating in City contracts for a period of
time of not less than three (3) years.
J. Right to Audit
(1) ENGINEER agrees that the CITY shall, until the expiration of three (3) years
STANDARD ENGINEERING AGREEMENT(REV 10/06/05)
Page 4 of 14
after final payment under this contract, have access to and the right to
examine and photocopy any directly pertinent books, documents, papers and
records of the ENGINEER involving transactions relating to this contract.
ENGINEER agrees that the CITY shall have access during normal working
hours to all necessary ENGINEER facilities and shall be provided adequate
and appropriate work space in order to conduct audits in compliance with the
provisions of this section. The CITY shall give ENGINEER reasonable
advance notice of intended audits.
(2) ENGINEER further agrees to include in all its subconsultant agreements
hereunder a provision to the effect that the subconsultant agrees that the CITY
shall, until the expiration of three (3) years after final payment under the
subcontract, have access to and the right to examine and photocopy any
directly pertinent books, documents, papers and records of such
subconsultant, involving transactions to the subcontract, and further, that the
CITY shall have access during normal working hours to all subconsultant
facilities, and shall be provided adequate and appropriate work space, in order
to conduct audits in compliance with the provisions of this article together with
subsection (3)hereof. CITY shall give subcon-sultant reasonable advance
notice of intended audits.
(3) ENGINEER and subconsultant agree to photocopy such documents as may
be requested by the CITY. The CITY agrees to reimburse ENGINEER for the
cost of copies at the rate published in the Texas Administrative Code in effect
as of the time copying is performed.
K. ENGINEER's Insurance
(1) Insurance coverage and limits:
ENGINEER shall provide to the City certificate(s) of insurance documenting
policies of the following coverage at minimum limits that are to be in effect
prior to commencement of work on the PROJECT:
Commercial General Liability
$1,000,000 each occurrence
$2,000,000 aggregate
Automobile Liability
$1,000,000 each accident on a combined single limit
or
$250,000 Property Damage
$500,000 Bodily Injury per person per occurrence
A commercial business policy shall provide coverage on "Any Auto", defined
as autos owned, hired and non-owned when said vehicle is used in the
STANDARD ENGINEERING AGREEMENT(REV 10106/05)
Page 5 of 14
r mss, nL I
S
course of the PROJECT.
Worker's Compensation
Coverage A: Statutory limits
Coverage B: Employer's Liability
$100,000 each accident
$500,000 disease - policy limit
$100,000 disease - each employee
Professional Liability
$1,000,000 each claim
$2,000,000 aggregate
Professional liability shall be written on a claims-made basis and shall
contain a retroactive date prior to the date of the contract or the first date of
services to be performed, whichever is earlier. Coverage shall be maintained
for a period of 5 years following the completion of the contract. An annual
certificate of insurance specifically referencing this project shall be submitted
to the City for each year following completion of the contract.
(2) Certificates of insurance evidencing that the ENGINEER has obtained all
required insurance shall be delivered to the CITY prior to ENGINEER
proceeding with the PROJECT.
(a) Applicable policies shall be endorsed to name the CITY an Additional
Insured thereon, as its interests may appear. The term CITY shall include
its employees, officers, officials, agents, and volunteers as respects the
contracted services.
(b) Certificate(s) of insurance shall document that insurance coverage
specified in this agreement are provided under applicable policies
documented thereon.
(c) Any failure on part of the CITY to request required insurance
documentation shall not constitute a waiver of the insurance requirements.
(d) A minimum of forty-five (45) days notice of cancellation or material change
in coverage shall be provided to the CITY. A ten (10) days notice shall be
acceptable in the event of non-payment of premium. Such terms shall be
endorsed onto ENGINEER's insurance policies. Notice shall be sent to the
respective Department Director (by name), City of Fort Worth, 1000
Throckmorton, Fort Worth, Texas 76102.
(e) Insurers for all policies must be authorized to do business in the State UI R
STANDARD ENGINEERING AGREEMENT(REV 10106/05) ? I
Page 17
9 v j `� U=
Texas and have a minimum rating of A: VII in the current A.M. Best Key
Rating Guide or have reasonably equivalent financial strength and
solvency to the satisfaction of Risk Management.
(f) Deductible limits, or self insured retentions, affecting insurance required
herein shall be acceptable to the CITY in its sole discretion; and, in lieu of
traditional insurance, any alternative coverage maintained through
insurance pools or risk retention groups must be also approved.
Dedicated financial resources or letters of credit may also be acceptable
to the City.
(g) Applicable policies shall each be endorsed with a waiver of subrogation in
favor of the CITY as respects the PROJECT.
(h) The City shall be entitled, upon its request and without incurring expense,
to review the ENGINEER's insurance policies including endorsements
thereto and, at the CITY's discretion, the ENGINEER may be required to
provide proof of insurance premium payments.
(i) The 'Commercial :General L;iabil.ity insurance poiicv shall have no
exclusions by eridorsements unless the CITY .approves such exclusions
iia writing.
(j) For all lines of coverage underwritten on a claims-made basis, other than
Professional Liability, the retroactive date shall be coincident with or prior
to the date of the contractual agreement. The certificate of insurance
shall state both the retroactive date and that the coverage is claims-
made.
(k) The CITY shall not be responsible for the direct payment of any
insurance premiums required by this agreement and all insurance
required in this section, with the exception of Professional Liability, shall
be written on an occurrence basis.
(1) Sub consultants and subcontractors to/of the ENGINEER shall be
required by the ENGINEER to maintain the same or reasonably
equivalent insurance coverage as required for the ENGINEER. When sub
consultants/subcontractors maintain insurance coverage, ENGINEER
shall provide CITY with documentation thereof on a certificate of
insurance.
L. Independent Consultant
The ENGINEER agrees to perform all services as an independent consultant
and not as a subcontractor, agent, or employee of the CITY.
STANDARD ENGINEERING AGREEMENT(REV 10106105) c' i
Page 7 of 14
M. Disclosure
The ENGINEER acknowledges to the CITY that it has made full disclosure in
writing of any existing conflicts of interest or potential conflicts of interest,
including personal financial interest, direct or indirect, in property abutting the
proposed PROJECT and business relationships with abutting property cities.
The ENGINEER further acknowledges that it will make disclosure in writing of
any conflicts of interest that develop subsequent to the signing of this contract
and prior to final payment under the contract.
N. Asbestos or Hazardous Substances
(1) If asbestos or hazardous substances in any form are encountered or
suspected, the ENGINEER will stop its own work in the affected portions of
the PROJECT to permit testing and evaluation.
(2) If asbestos or other hazardous substances are suspected, the ENGINEER
will, if requested, assist the CITY in obtaining the services of a qualified
subcontractor to manage the remediation activities of the PROJECT.
O. Permitting Authorities - Design Changes
If permitting authorities require design changes so as to comply with published
design criteria and/or current engineering practice standards which the
ENGINEER should have been aware of at the time this Agreement was
executed, the ENGINEER shall revise plans and specifications, as required, at
its own cost and expense. However, if design changes are required due to the
changes in the permitting authorities' published design criteria and/or practice
standards criteria which are published after the date of this Agreement which
the ENGINEER could not have been reasonably aware of, the ENGINEER
shall notify the CITY of such changes and an adjustment in compensation will
be made through an amendment to this AGREEMENT.
Article V
Obligations of the City
Amendments to Article V, if any, are included in Attachment C.
A. City-Furnished Data
ENGINEER may rely upon the accuracy, timeliness, and completeness of the
information provided by the CITY.
B. Access to Facilities and Property
The CITY will make its facilities accessible to the ENGINEER as required for
the ENGINEER's performance of its services and will provide labor and safety
STANDARD ENGINEERING AGREEMENT(REV 10106/05)
Page 8 of 14
equipment as required by the ENGINEER for such access. The CITY will
perform, at no cost to the ENGINEER, such tests of equipment, machinery,
pipelines, and other components of the CITY's facilities as may be required in
connection with the ENGINEER's services. The CITY will be responsible for all
acts of the CITY's personnel.
C. Advertisements, Permits, and Access
Unless otherwise agreed to in the Scope of Services, the CITY will obtain,
arrange, and pay for all advertisements for bids; permits and licenses required
by local, state, or federal authorities; and land, easements, rights-of-way, and
access necessary for the ENGINEER's services or PROJECT construction.
D. Timely Review
The CITY will examine the ENGINEER's studies, reports, sketches, drawings,
specifications, proposals, and other documents; obtain advice of an attorney,
insurance counselor, accountant, auditor, bond and financial advisors, and
other consultants as the CITY deems appropriate; and render in writing
decisions required by the CITY in a timely manner in accordance with the
project schedule in Attachment A.
E. Prompt Notice
The CITY will give prompt written notice to the ENGINEER whenever CITY
observes or becomes aware of any development that affects the scope or
timing of the ENGINEER's services or of any defect in the work of the
ENGINEER or construction contractors.
F. Asbestos or Hazardous Substances Release.
(1) CITY acknowledges ENGINEER will perform part of the work at CITY's
facilities that may contain hazardous materials, including asbestos
containing materials, or conditions, and that ENGINEER had no prior role
in the generation, treatment, storage, or disposition of such materials. In
consideration of the associated risks that may give rise to claims by third
parties or employees of City, City hereby releases ENGINEER from any
damage or liability related to the presence of such materials.
(2) The release required above shall not apply in the event the discharge,
release or escape of hazardous substances, contaminants, or asbestos is
a result of ENGINEER's negligence or if ENGINEER brings such
hazardous substance, contaminant or asbestos onto the project.
G. Contractor Indemnification and Claims
The CITY agrees to include in all construction contracts the provisions of
Article IV.E. regarding the ENGINEER's Personnel at Construction Site, and
STANDARD ENGINEERING AGREEMENT(REV 10/06/05)
Page 9 of 14
provisions providing contractor indemnification of the CITY and the
ENGINEER for contractor's negligence.
H. Contractor Claims and Third-Party Beneficiaries
(1) The CITY agrees to include the following clause in all contracts with
construction contractors and equipment or materials suppliers:
"Contractors, subcontractors and equipment and materials
suppliers on the PROJECT, or their sureties, shall maintain no
direct action against the ENGINEER, its officers, employees,
and subcontractors, for any claim arising out of, in connection
with, or resulting from the engineering services performed.
Only the CITY will be the beneficiary of any undertaking by
the ENGINEER."
(2) This AGREEMENT gives no rights or benefits to anyone other than the CITY
and the ENGINEER and there are no third-party beneficiaries.
(3) The CITY will include in each agreement it enters into with any other entity or
person regarding the PROJECT a provision that such entity or person shall
have no third-party beneficiary rights under this Agreement.
(4) Nothing contained in this section V.H. shall be construed as a waiver of any
right the CITY has to bring a claim against ENGINEER.
I. CITY's Insurance
(1) The CITY may maintain property insurance on certain pre-existing structures
associated with the PROJECT.
(2) The CITY will ensure that Builders Risk/installation insurance is maintained at
the replacement cost value of the PROJECT. The CITY may provide
ENGINEER a copy of the policy or documentation of such on a certificate of
insurance.
(3) The CITY will specify that the Builders Risk/installation insurance shall be
comprehensive in coverage appropriate to the PROJECT risks.
J. Litigation Assistance
The Scope of Services does not include costs of the ENGINEER for required
or requested assistance to support, prepare, document, bring, defend, or
assist in litigation undertaken or defended by the CITY. In the event CITY
requests such services of the ENGINEER, this AGREEMENT shall be
amended or a separate agreement will be negotiated between the parties.
STANDARD ENGINEERING AGREEMENT(REV 10/06/05)
Page 10of14
1v 4 '} � ' .•r
K. Changes
The CITY may make or approve changes within the general Scope of Services
in this AGREEMENT. If such changes affect the ENGINEER's cost of or time
required for performance of the services, an equitable adjustment will be made
through an amendment to this AGREEMENT with appropriate CITY approval.
Article VI
General Legal Provisions
Amendments to Article VI, if any, are included in Attachment C.
A. Authorization to Proceed
ENGINEER shall be authorized to proceed with this AGREEMENT upon
receipt of a written Notice to Proceed from the CITY.
B. Reuse of Project Documents
All designs, drawings, specifications, documents, and other work products of
the ENGINEER, whether in hard copy or in electronic form, are instruments of
service for this PROJECT, whether the PROJECT is completed or not.
Reuse, change, or alteration by the CITY or by others acting through or on
behalf of the CITY of any such instruments of service without the written
permission of the ENGINEER will be at the CITY's sole risk. The CITY shall
own the final designs, drawings, specifications and documents.
C. Force Majeure
The ENGINEER is not responsible for damages or delay in performance
caused by acts of God, strikes, lockouts, accidents, or other events beyond the
control of the ENGINEER.
D. Termination
(1) This AGREEMENT may be terminated only by the City for convenience on
30 days' written notice. This AGREEMENT may be terminated by either the
CITY or the ENGINEER for cause if either party fails substantially to perform
through no fault of the other and does not commence correction of such
nonperformance with 5 days of written notice and diligently complete the
correction thereafter.
(2) If this AGREEMENT is terminated for the convenience of the City, the
ENGINEER will be paid for termination expenses as follows:
a.) Cost of reproduction of partial or complete studies, plans, specifications
or other forms of ENGINEER'S work product;
STANDARD ENGINEERING AGREEMENT(REV 10/06/05)
Page 11 of 14
b.) Out-of-pocket expenses for purchasing storage containers, microfilm,
electronic data files, and other data storage supplies or services;
c.) The time requirements for the ENGINEER'S personnel to document the
work underway at the time the CITY'S termination for convenience so
that the work effort is suitable for long time storage.
(3) Prior to proceeding with termination services, the ENGINEER will submit to the
CITY an itemized statement of all termination expenses. The CITY'S approval
will be obtained in writing prior to proceeding with termination services.
E. Suspension, Delay, or Interruption to Work
The CITY may suspend, delay, or interrupt the services of the ENGINEER for
the convenience of the CITY. In the event of such suspension, delay, or
interruption, an equitable adjustment in the PROJECT's schedule,
commitment and cost of the ENGINEER's personnel and subcontractors, and
ENGINEER's compensation will be made.
F. Indemnification
(1) The ENGINEER agrees to indemnify and defend the CITY from any
loss, cost, or expense claimed by third parties for property damage and
bodily injury, including death, caused solely by the negligence or willful
misconduct of the ENGINEER, its employees, officers, and
subcontractors in connection with the PROJECT.
(2) If the negligence or willful misconduct of both the ENGINEER and the
CITY (or a person identified above for whom each is liable) is a cause of
such damage or injury, the loss, cost, or expense shall be shared
between the ENGINEER and the CITY in proportion to their relative
degrees of negligence or willful misconduct as determined pursuant to
T.C.P. & R. Code, section 33.011(4) (Vernon Supplement 1996).
G. Assignment
Neither party shall assign all or any part of this AGREEMENT without the prior
written consent of the other party.
H. Interpretation
Limitations on liability and indemnities in this AGREEMENT are business
understandings between the parties and shall apply to all the different theories
of recovery, including breach of contract or warranty, tort including negligence,
strict or statutory liability, or any other cause of action, except for willful
misconduct or gross negligence for limitations of liability and sole negligence
for indemnification. Parties mean the CITY and the ENGINEER, and their
STANDARD ENGINEERING AGREEMENT(REV 10/06/05)
Page 12 of 14 �1
officers, employees, agents, and subcontractors.
I. Jurisdiction
The law of the State of Texas shall govern the validity of this AGREEMENT, its
interpretation and performance, and any other claims related to it. The venue
for any litigation related to this AGREEMENT shall be Tarrant County, Texas.
J. Alternate Dispute Resolution
(1) All claims, disputes, and other matters in question between the CITY and
ENGINEER arising out of, or in connection with this Agreement or the
PROJECT, or any breach of any obligation or duty of CITY or ENGINEER
hereunder, will be submitted to mediation. If mediation is unsuccessful, the
claim, dispute or other matter in question shall be submitted to arbitration if
both parties acting reasonably agree that the amount of the dispute is likely to
be less than $50,000, exclusive of attorney's fees, costs and expenses.
Arbitration shall be in accordance with the Construction Industry Arbitration
Rules of the American Arbitration Association or other applicable rules of the
Association then in effect. Any award rendered by the arbitrators less than
$50,000, exclusive of attorney's fees, costs and expenses, will be final,
judgment may be entered thereon in any court having jurisdiction, and will not
be subject to appeal or modification except to the extent permitted by Sections
10 and 11 of the Federal Arbitration Act (9 U.S.C. Sections 10 and 11).
(2) Any award greater than $50,000, exclusive of attorney's fees, costs and
expenses, may be litigated by either party on a de novo basis. The award shall
become final ninety (90) days from the date same is issued. If litigation is filed
by either party within said ninety (90) day period, the award shall become null
and void and shall not be used by either party for any purpose in the litigation.
K. Severability and Survival
If any of the provisions contained in this AGREEMENT are held for any reason
to be invalid, illegal, or unenforceable in any respect, such invalidity, illegality,
or unenforceability will not affect any other provision, and this AGREEMENT
shall be construed as if such invalid, illegal, or unenforceable provision had
never been contained herein. Articles V.F., VI.B., VI.D., VI.H., VI.I., and VI.J.
shall survive termination of this AGREEMENT for any cause.
L. Observe and Comply
ENGINEER shall at all times observe and comply with all federal and State
laws and regulations and with all City ordinances and regulations which in any
way affect this AGREEMENT and the work hereunder, and shall observe and
comply with all orders, laws ordinances and regulations which may exist or
may be enacted later by governing bodies having jurisdiction or authority for
such enactment. No plea of misunderstanding or ignorance thereof shall be
STANDARD ENGINEERING AGREEMENT(REV 10/06/05)
Page 13 of 14
considered. ENGINEER agrees to defend, indemnify and hold harmless CITY
and all of its officers, agents and employees from and against all claims or
liability arising out of the violation of any such order, law, ordinance, or
regulation, whether it be by itself or its employees.
Article VII
Attachments, Schedules, and Signatures
This AGREEMENT, including its attachments and schedules, constitutes the entire
AGREEMENT, supersedes all prior written or oral understandings, and may only be
changed by a written amendment executed by both parties. The following attachments and
schedules are hereby made a part of this AGREEMENT:
Attachment A - Scope of Services
Attachment B — Compensation
Attachment C -Amendments to Standard Agreement for Engineering Services
Attachment D - Project Schedule
Attachment E - Location Map
Executed this the t day o , 20
ATTEST: ITY FORT TH
f�\" 0--/ 1
Marty Hendrix Marc A. tt
City Secretary Assistant ity Manager
f APPROVAL RECOMMENDED
Contract' Authorization ��C
` Robert D. Goode, P.E.
Director, Transportation & Public Works
Department
APPRO AS T AND LEGALITY
AssYstant/44 Attorney
Teague Nall & Perkins , Inc.
ATTEST: ENGINEER
C. Ty Hilt n,P.E.
Principal
STANDARD ENGINEERING AGREEMENT(REV 10/06/05) 11 ,
Page 14 of 14
ATTACHMENT "A"
General Scope of Services
"Scope of Services set forth herein can only be modified by additions, clarifications, and/or deletions
set forth in the supplemental Scope of Services. In cases of conflict between the Supplemental Scope
of Services and the General Scope of Services, the Supplemental Scope of Services shall have
precedence over the General Scope of Services."
GENERAL
1) Preliminary Conference with City
The Engineer shall attend preliminary conferences with authorized representatives of the City
regarding the scope of project so that the plans and specifications which are to be developed
hereunder by the Engineer will result in providing facilities which are economical in design and
conform to the City's requirements and budgetary constraints.
2) Coordination with Outside Agencies/Public Entities
The Engineer shall coordinate with officials of other outside agencies as may be necessary for
the design of the proposed street, and storm drain and/or water and wastewater
facilities/improvements. It shall be the Engineer's duty hereunder to secure necessary
information from such outside agencies, to meet their requirements.
3) Geotechnical Investigations
The Engineer shall advise the City of test borings, and other subsurface investigations that
may be needed. In the event it is determined necessary to make borings or excavate test holes
or pits, the Engineer shall in coordination with the City and the City's geotechnical engineering
consultant, draw up specifications for such testing program. The cost of the borings or
excavations shall be paid for by the City.
4) Agreements and Permits
The Engineer shall complete all forms/applications to allow the City of Fort Worth to obtain any
and all agreements and/or permits normally, required for a project of this size and type. The
Engineer will be responsible for negotiating and coordinating .to obtain approval of the agency
issuing the agreement and/or permits' and will make any revisions necessary to bring the plans
into compliance with the requirements of said agency, including but not limited to highways,
railroads, water authorities, Corps of Engineers and other utilities.
5) Design Changes Relating to Permitting Authorities
If permitting authorities require design changes, the Engineer shall revise the plans and
specifications as required at the Engineers own cost and expense, unless such changes are
required due to changes in the design of the facilities made by the permitting authority. If such
changes are required, the Engineer shall notify the City and an amendment to the contract
shall be made if the Engineer incurs additional cost. If there are unavoidable delays, a mutually
agreeable, and reasonable time extension shall be negotiated.
6) Plan Submittal
Copies of the original plans shall be provided on reproducible mylar or approved plastic
film sheets, or as otherwise approved by the Department of Engineering and shall become
the property of the City. City may use such drawings in any manner it desires; provided,
however that the Engineer shall not be liable for the use of such drawings for any project
other than the project described herein; and further provided, that the Engineer shall not
be liable for the consequences of any changes that are made to the drawings or changes
that are made in the implementation of the drawings without the written approval of the
Engineer.
PHASE 1
7) Right-of-Way, Easement and Land Acquisition Needs
The Engineer shall determine the rights-of-way, easement needs for the construction of the
project. Engineer shall determine ownership of such land and furnish the City with the
necessary right-of-way sketches, prepare necessary easement descriptions for acquiring
the rights-of-way and/or easements for the construction of this project. Sketches and
easement descriptions are to be presented in form suitable for direct use by the
Department of Engineering in obtaining rights-of-way, easements, permits and licensing
agreements. All materials shall be furnished on the appropriate City forms in a minimum of
four (4) copies each.
8) Design Survey
The Engineer shall provide necessary field survey for use in the preparation of Plans and
Specifications. The Engineer shall furnish the City certified copies of the field data.
9) Utility Coordination
The Engineer shall coordinate with all utilities, including utilities owned by the City, as to
any proposed utility liens or adjustment to existing utility lines within the project limits. The
information obtained shall be shown on the conceptual plans. The Engineer shall show on
the preliminary and final plans the location of the proposed utility lines, existing utility lines,
based on the information provided by the utility, and any adjustments and/or relocation of
the existing lines within the project limits. The Engineer shall also evaluate the phasing of
the water, wastewater, street and drainage work, and shall submit such evaluation in
writing to the City as part of this phase of the project.
10) Conceptual Plans
The Engineer shall furnish four (4) copies of the Phase 1 concept engineering plans, which
include layouts, preliminary right-of-way needs and preliminary estimates of probable
construction costs for the Engineer's recommended plan. For all submittals, the Engineer
shall submit plans and documents for street/storm drain and water/wastewater facilities.
The Engineer shall receive written approval of the Phase 1 Plans from the City's project
manager before proceeding with Phase 2.
-2-
PHASE 2
11) Design Data
The Engineer shall provide design data, reports, cross-sections, profiles, drainage
calculations, and preliminary estimates of probable construction cost
12) Preliminary Construction Plans and Technical Specifications
The Engineer shall submit twenty (20) copies of Phase 2 preliminary construction plans
and five (5) copies of the preliminary technical specifications for review by the City and
for submission to utility companies and other agencies for the purposes of coordinating
work with existing and proposed utilities. The preliminary construction plans shall
indicate location of existing/proposed utilities and storm drain lines. The Engineer shall
receive written approval of the Phase 2 plans from the City's project manager before
proceeding with Phase 3.
PHASE 3
13) Final Construction Plans
The Engineer shall furnish five (5) copies of the final construction plans and contract
specifications for review by the City.
14) Detailed Cost Estimate
The Engineer shall furnish four (4) copies of detailed estimates of probable construction
costs for the authorized construction project, which shall include summaries of bid items
and quantities.
15) Plans and Specification Approval
The Engineer shall furnish an original cover mylar for the signatures of authorized City
officials. The Contract Documents shall comply with applicable local, state and federal
laws and with applicable rules and regulations promulgated by local, state and national
boards, bureaus and agencies. The Engineer shall receive written approval of the Phase
3 plans from the City's project manager before proceeding with Phase 4.
PHASE 4
16) Final Approved Construction Plans
The Engineer shall furnish 45 bound copies of Phase 4 final approved construction plans
and contract specifications. The approved plans and contract specifications shall be used
as authorized by the City for use in obtaining bids, awarding contracts, and constructing
the project.
17) Bidding Assistance
The Engineer shall issue addenda as appropriate to interpret, clarify, or expand the
bidding documents, and assist the owner in determining the qualifications and
acceptability of prospective constructors, subcontractors, and suppliers. When substitu-
tion prior to the award of contracts is allowed by the bidding documents, the Engineer will
advise the owner as to the acceptability of alternate materials and equipment proposed
by the prospective constructors.
3-
18) Recommendation of Award
The Engineer shall assist in the tabulation and review of all bids received for the construction
of the project and shall make a recommendation of award to the City.
19) Prebid Conference
The Engineer shall attend the prebid conference and the bid opening, prepare bid
tabulation sheets and provide assistance to the owner in evaluating bids or proposals
and in assembling and awarding contracts for construction, materials, equipment. and
services.
PHASE 5
20) Preconstruction Conference
The Engineer shall attend the preconstruction conference.
21) Construction Survey
The Engineer shall be available to the City on matters. concerning the layout of the
project during its construction and will set control points in the field to allow City survey
crews to stake the project. The setting of line and grade stakes and route inspection of
construction will be performed by the City.
22) Site Visits
The Engineer shall visit the project site at appropriate intervals as construction
proceeds to observe and report on the progress and the quality of the executed work.
23) Shop Drawing Review
The Engineer shall review shop and erection drawings submitted by the contractor for
compliance with design concepts. The Engineer shall review laboratory, shop, and mill
test reports on materials and equipment
24) Instructions to Contractor
The Engineer shall provide necessary interpretations and clarifications of contract
documents, review change orders and make recommendations as to the acceptability of
the work, at the request of the City.
25) Differing Site Conditions
The Engineer shall prepare sketches required to resolve problems due to actual field
conditions encountered.
26) Record Drawings
The Engineer shall prepare record drawings from information submitted by the
contractor.
EXHIBIT "A-1"
SUPPLEMENTAL SCOPE OF SERVICES
(SUPPLEMENT TO ATTACHMENT "A")
DESIGN SERVICES: PAVING AND/OR DRAINAGE IMPROVEMENTS
The following is a clarification of the tasks that the ENGINEER will perform under ATTACHMENT
'W'. Work under this attachment includes engineering services for paving and/or storm drain
improvements for the following:
2004 CIP—ARTERIAL STREET PROJECT
CHAPEL CREEK BOULEVARD (IH-30 NORTH TO CHAPIN ROAD)
CITY PROJECT NO. 000139
Upon receipt of notice to proceed, the ENGINEER will perform the following tasks:
PART A—PRE-ENGINEERING
1. Initial Data Collection
a. Pre-Design Coordination Meetings
ENGINEER will attend and document meetings, as required, to discuss and
coordinate various aspects of the project and to ensure that the project stays on
schedule. For purposes of establishing a level of comfort, two (2) meetings are
anticipated. These include the following:
One (1) pre-design kick-off meeting, (including the CITY's Department of
Engineering and other departments that are impacted by the project).
One (1) review meeting at completion of the City's review of the conceptual
engineering plans.
b. Data Collection
In addition to data obtained from the City, ENGINEER will research and make
efforts to obtain pertinent information to aid in coordination of the proposed
improvements with any planned future improvements that may influence the
EA2-1
Rev 11/30/04
project. ENGINEER will also identify and seek to obtain data for existing conditions
that may impact the project including; utilities, City Master plans, CITY drainage
complaint files, existing applicable drainage studies and property ownership as
available from the Tax Assessor's office.
C. Coordination with Other Agencies
During the concept phase the ENGINEER shall coordinate with all utilities,
including utilities owned by the City, TxDOT and railroads. These entities shall also
be contacted if applicable, to determine plans for any proposed facilities or
adjustment to existing facilities within the project limits. The information obtained
shall be shown on the concept plans. The ENGINEER shall show the location of
the proposed utility lines, existing utility lines and any adjustments and/or relocation
of the existing lines within the project limits. ENGINEER shall complete all forms
necessary for City to obtain permit letters from TxDOT and railroads and submit
such forms to the City. City shall be responsible for forwarding the forms to the
affected agencies for execution.
2. Schedule Submittal and Monthly Progress Report
The ENGINEER shall submit a project schedule after the design contract is fully
executed. The schedule shall be updated and submitted to the CITY along with
monthly progress reports as required under Attachment B of the contract.
PART B -CONSTRUCTION PLANS AND SPECIFICATIONS
1. Conceptual Engineering
i. Surveys for Design
a. ENGINEER will perform field surveys to collect horizontal and vertical
elevations and other information needed by ENGINEER in design and
preparation of plans for the project. Information gathered during the survey
shall include topographic data, elevations of all sanitary and adjacent storm
sewers, rim/invert elevations, location of buried utilities, structures, and
other features relevant to the final plan sheets. Existing drainage at
intersections will be verified by field surveys. Spot elevations will be shown
on intersection layouts with cross slope to fit intersecting grade lines.
EA2-2
Rev 11/30/04
.^ r1
b. ENGINEER will provide the following information:
All plans, field notes, plats, maps, legal descriptions, or other specified
documents prepared in conjunction with the requested services shall be
provided in a digital format compatible with the electronic data collection
and computer aided design and drafting software currently in use by the
Department of Engineering. All text data such as plan and profile, legal
descriptions, coordinate files, cut sheets, etc., shall be provided in the
American Standard Code for Information Interchange (ASCII) format, and
all drawing files shall be provided in Autocad (DWG or DXF) format
(currently Release 12), or as otherwise approved in writing by the CITY,
and all data collected and generated during the course of the project shall
become the property of the CITY.
The minimum survey information to be provided on the plans shall include
the following:
1. A Project Control Sheet, showing ALL Control Points, used or set
while gathering data. Generally on a scale of not less than 1:400:
2. The following information about each Control Point;
a. Identified (Existing. City Monument #8901, PK Nail,
5/8" Iron Rod)
b. X, Y and Z Coordinates, in an identified coordinate
system, and a referred bearing base. Z coordinate on
City Datum only.
C. Descriptive Location (Ex. Set in the centerline of the
inlet in the South curb line of North Side Drive at the
East end of radius at the Southeast corner of North
Side Drive and North Main Street).
3. Coordinates on all P.C.'s, P.T.'s, P.I.'s, Manholes, Valves, etc., in
the same coordinate system, as the Control.
EA2-3
Rev 11/30/04
4. No less than two horizontal bench marks, per line or location.
5. Bearings given on all proposed centerlines, or baselines.
6. Station equations relating utilities to paving, when appropriate.
ii. Public Notification
Prior to conducting design survey, ENGINEER will notify affected
residents of the project in writing. The notification letter shall be on
company letterhead and shall include the following: project name
limits DOE project No., Consultant's Project Manager and phone
no., scope of survey work and design survey schedule. The letter
will be reviewed and approved by the City prior to distribution.
iii. Drainage Computations
ENGINEER will review and document the storm water watershed
drainage runoff area and existing street, right-of-way and storm
sewer capacities for the subject site. A drainage area map will be
drawn at 1" = 200' scale from available contour maps.
Calculations regarding street and right-of-way capacities and
design discharges (5-year and 100-year frequencies) at selected
critical locations will be provided. Capacities of existing storm
drain will be calculated and shown. The ENGINEER's
responsibility includes recommendations for improvements of the
existing system as deemed reasonable and consistent with City
standards.
iv. Conceptual Engineering Plan Submittal
a. Conceptual plans shall be submitted to City 30 days after
Notice to Proceed Letter is issued.
b. The ENGINEER shall furnish four (4) copies of the Phase 1
concept engineering plans which include layouts, preliminary
right-of-way needs and cost estimates for the ENGINEER's
recommended plan. The ENGINEER shall also evaluate the
EA2-4
Rev 11/30/06
phasing of the water, sanitary sewer, street and drainage work,
and shall submit such evaluation in writing to the City as a part
of the concept phase of the project.
2. Preliminary Engineering
Upon approval of Part B, Paragraph IV, ENGINEER will prepare construction plans as
follows:
a. Drainage area maps with drainage calculations and hydraulic
computations. Information shown on the plans will be consistent with Part
A, Paragraph 1.b. for proposed condition.
b. Preliminary project plans and profile sheets which will show the following
and shall be on 22" x 34" sheets:
Property Ownership
Curb Lines
Driveways
Medians (if applicable)
Sidewalks
Existing and proposed water and sanitary sewer mains.
C. Proposed roadway profile grades and elevations along each curb line;
elevations at all p.v.i.'s; p.i's half stations; high and low points; vertical curve
information; and pertinent AASHTO calculations. Profiles for existing curbs
(if any) and existing ground at the left and right-of-way lines shall be shown.
Existing found property corners (e.g. Iron pins) , along the existing right-of-
way shall be shown on the plans. Profiles for existing and proposed storm
drain mains and leads shall be provided.
d. Existing utilities and utility easements will be shown on the roadway plan
and profile sheets. ENGINEER will coordinate with utility companies and
the City of Fort Worth to ascertain what, if any, future improvements are
planned that may impact the project.
e. Preliminary roadway cross-sections will be developed, from the survey
notes, at intervals not-to-exceed 50 foot along the project length and will
EA2-5
Rev 11/30/04
extend 10' past the right of way line on both sides of the street. Additional
cross-sections at important features including driveways, p.i.'s of
intersecting streets, (minimum distance of 100' along cross-street at each
P.I.) walks, retaining walls, etc., will also be provided. Profiles of centerline
of driveways will also be provided where necessary. Scale will be 1" = 10'
horizontal and 1" = 2' vertical.
f. Street and intersection layouts.
g. Proposed plan/profile sheets will conform to City of Fort Worth construction
legend. Adequate horizontal and vertical control shall be provided on the
plan sheets to locate all proposed and existing facilities. Legal descriptions
(Lot Nos., Block Nos., and Addition Names) along with property ownership
shall be provided on the plan view.
h. Furnish as a function of final plans, six (6) copies of the final cross-sections
on 22" x 34" sheets. Information on these sheets will include centerline
station, profile grades and centerline elevations, roadway section (existing
and proposed), right-of-way limits. Scale will be 1" = 20' horizontal and 1" =
2' vertical with cross sections plotted with stationing from the bottom of the
sheet, and will include laterals and inlets. CITY policy with regard to parking
design shall be maintained. Excavation and embankment volumes and end
area computations shall also be provided.
I. Right-of-Way Research
The ENGINEER will conduct preliminary research for availability of existing
easements where open-cut construction or relocation of existing
alignments is probable. Temporary and permanent easements will be
appropriated based on available information and recommendations will be
made for approval by the City.
EA2-6
Rev 11/30/04
j. Right-of-way/Easement Preparation and Submittal
Preparation and submittal of right-of-way, easements and rights-of-entry
will be in conformance with "Submittal of Information to Real Property
Division for Acquisition of Property".
k. Utility Clearance Phase
The ENGINEER will consult with the City's Transportation and Pubici
Works Department, Water Department, Department of Engineering, and
other CITY departments, public utilities, private utilities, private utilities
and government agencies to determine the approximate location of
above and underground utilities, and other facilities that have an impact
or influence on the project. ENGINEER will design City facilities to avoid
or minimize conflicts with existing utilities.
The ENGINEER shall deliver a minimum of 13 sets of approved preliminary
construction plans to the City's Utility Coordinator for forwarding to all utility
companies, which have facilities within the limits of the project.
I. Preliminary Construction Plan Submittal
i. Preliminary construction plans and specifications shall be submitted
to CITY-3Q_days after approval of Part B, Paragraph iv.
ii. The ENGINEER shall deliver two (2) sets of preliminary
construction plans and two (2) specifications to CITY for review.
Generally, plan sheets shall be organized as follows:
Cover Sheet
General Layout and Legend Sheet
Drainage Area Map and Computations
Plan & Profile Sheets
Standard Construction Details
Special Details (If applicable)
iii. Preliminary estimate shall submit a preliminary estimate of probable
EA2-7
Rev 11/30/04 '• 1 y'
construction cost with the preliminary plans submitted. Engineer
shall assist City in selecting the feasible and or economical
solutions to be pursued.
M. Review Meetings with City
The ENGINEER shall meet with CITY to discuss review comments for
preliminary submittal. The CITY shall direct the ENGINEER in writing to
proceed with Final Design for Final Review.
n. Public Meeting
After the preliminary plans have been reviewed and approved by the City,
the ENGINEER shall prepare project exhibits, provide the CITY with the
database listing the names and addresses of all residents and business to
be affected by the proposed project, and attend public meeting to help
explain the proposed project to residents. The CITY shall select a suitable
location and mail the invitation letters to the affected customers.
3. Final Construction Plan Submittal
a. Final Construction Documents shall be submitted to CITY -Q_ days after
approval of Part B, Paragraph 2 (b).
Following CITY approval of the recommended improvements, the
ENGINEER shall prepare final plans and specifications and contract
documents to CITY (each plan sheet shall be stamped, dated, and signed
by the ENGINEER registered in State of Texas) and submit two (2) sets of
plans and construction contract documents within 15 days of CITY's final
approval. Plan sets shall be used for Part C activities.
b. ENGINEER's Estimate of Probable Construction Cost
The ENGINEER shall submit a final estimate of probable construction cost
with the final plans submitted.
EA2-8
Rev 11/30/04
C. Mylar Submittals
The ENGINEER shall submit a final set of mylar drawings for record
storage as follows:
1. Street and storm drain plans shall be submitted as one set
of plans. Street and storm drain plans shall be separate
from water and sanitary sewer plans. All sheets shall be
standard size (22 x 34") with all project numbers (TPW and
water/sanitary sewer) prominently displayed.
2. For projects where water/sanitary sewer improvements
occur on a TPW Department funded project with no Water
funding involved, a separate set of mylars with cover sheet
shall be submitted for Water Department.
3. Signed plans sets shall also be submitted as an Adobe
Acrobat PDF format (version 6.0 or higher) file. There
shall be one (1) PDF file for the TPW plan set and a
separate PDF file for the Water plan set. Each PDF file
shall contain all associated sheets of the particular plan set.
$jugular PDF files for parh sheet of a plan cet will net
by ar-r-PptPri- PDF files shall conform to naming
conventions as follows:
I. TPW file name example — "W-1956—org47.pdf'
where "W-1956" is the assigned file number
obtained from the City of Fort Worth, "—org"
designating the file is of an original plan set, 1147"
shall be the total number of sheets in this file.
Example: W-0053—org3.pdf and K-0320—org5.pdf
II. Water and Sewer file name example — "X-
35667—org36.pdf" where "X-35667" is the
assigned file number obtained from the City of Fort
Worth, '°—org" designating the file is of an original
EA2-9
Rev 11/30/04
J 'za
plan set, 1136" shall be the total number of sheets in
this file.
Example: X-12755_org18.pdf
Both PDF files shall be submitted on one (1) Compact Disk, which will
become property of and remain with the City of Fort Worth. Floppy dunks.
An dicks, a-mail flash media will net ha ar_r_entad
4. For information on the proper manner to submit PDF files
and to obtain a file number for the project, contact the
Department of Engineering Vault at telephone number (817)
392-8426. File numbers will not be issued to a project
unless the DOE number and proper fund codes have been
assigned and are in the Department of Engineering
database.
PART C -PRE-CONSTRUCTION ASSISTANCE
Administration
a. Bid Documents Submittal
The ENGINEER will make available for bidding, upon request by
the CITY, up to fifty (50) sets of the final approved and dated plans
and specifications and contract documents for the projects to the
CITY for distribution to potential bidders. Proposal will be provided
in electronic format.
b. Bidding Assistance
The ENGINEER shall assist the CITY during this phase including
preparation and delivery of any additional addenda prior to bid
opening to plan holders and respond to questions submitted to
DOE by prospective bidders. Engineer shall attend the scheduled
pre-bid conference.
EA2-10
Rev 11/30/04
The ENGINEER shall assist in reviewing the bids for completeness
and accuracy. The ENGINEER shall attend the project bid opening,
develop bid tabulations in hard copy and electronic format and
return four (4) copies of the bid tabulation, along with the contract
documents to the City within three (3) working days after bid
openings.
C. Assistance During Construction
The ENGINEER shall attend the pre-construction conference for
the project. The ENGINEER shall also consult with and advise the
CITY on design and/or construction changes, if necessary.
EA2-11
Rev 11/30/04
lir
.":6 u.....
PART D — CONSTRUCTION STAKING (OPTIONAL) (PART D TO BE PRINTED ONLY IF
APPLICABLE)
ENGINEER, if directed by City, will set control points (i.e. tie survey to permanent
monument such as TPW monuments and/or property corners, one location each at
beginning and end of project) for the project, these points must be indivisible. Streets over
500 ft or streets on curves may require a greater density of control points to maintain
intervisibility between each point. ENGINEER shall establish a minimum of two bench
marks per plan sheet (bench marks shall be located adjacent to project) and shall provide
the following construction staking services:
1. STORM DRAIN STAKING: Provide an offset stake at 100' intervals (50' intervals in
curves if required) and at all proposed manholes, points of curve, points of tangent, points
of pipe size changes and at all horizontal or vertical angle points with a cut to flow line and
a cut/fill to the top of proposed manholes. Provide centerline elevation at 100' intervals and
at all grade breaks in the natural ground. Lead lines shall also be staked with grades if
greater than 50' in length, or where substantial alignment and/or grade are needed.
Provide two offset stakes at end or each wing of each curb inlet with a cut to flow line and
a cut/fill to the top of curb elevation. Line and grade shall be set to a tolerance of+/- 0.1 ft.
for storm drain pipe and +/- 0.04 ft. for curb inlets.
2. ROADWAY EXCAVATION STAKING: Provide 10' or property line offset at 50' intervals
and at all points of curve, points of tangent, and at all horizontal or vertical angle points
with a cut/fill to the top of proposed curb. The right-of-way shall also be flagged during this
process along with line and grade stakes for excavation purposes. Stake all vertical and
horizontal curves at 50' intervals. Line and grade shall be set to a tolerance of+/-0.1 ft.
3. FINAL ROADWAY STAKING: Provide 4' or 5' offset stakes at 50' intervals and at all
points of curve, points of tangent, and at all horizontal or vertical angle points with a cut/fill
to the top of proposed curb. Staking for curb grade and intersecting streets, if required,
shall be performed under final pavement staking. Inlets shall be staked if needed. Set
tucks in offset hubs for street alignment. Stake all vertical and horizontal curves at 50'
intervals and provide intermediate stakes between curve points, if the radius is less than
300'. Line and grade shall be set to a tolerance of+/- 0.01 ft.
4. "AS STAKED" RECORD OF THE CONSTRUCTION: Throughout the process of all
construction, locate and record anything that does not conform with the construction plans.
EA2-12
Rev 11/30/06
A drawing of the project layout with dimensions and a coordinate list must be submitted.
Contact Kevin Hansen, Survey Division, DOE, (817) 392-8880, for a copy of sample field
notes that must be submitted. The contractor will not be allowed to proceed until all
necessary field notes have been submitted to the City Inspector. The field notes must
include the following information:
a. For storm drain lines and storm drain laterals;
Pipe size and type, percent of grade of laterals and location of inlets. Cut and fill
documentation.
b. For roadways;
Field notes signed and sealed by a licensed surveyor must be submitted to the City
Inspector prior to the beginning of construction.
5. COORDINATION WITH CITY INSPECTOR/CONTRACTOR: Engineer's surveyor is
expected to work with inspector and contractor to provide any special requests contractor
may have providing the scope of work described above is not exceeded. It is expected that
a few stakes will be knocked out during dirt work. Providing that the number of disturbed
stakes is minor (less than 10% of the stakes for any phase of the project), the Engineer's
surveyor shall replace these stakes at no extra cost. If additional major restaking is
required, the consulting engineer's surveyor, shall provide the additional work at an hourly
rate of $ per hour for a field crew. Major restaking may be required if a
substantial number of the initial stakes are knocked down as a result of the contractor's
activity and there are not enough stakes left to complete the project. The contractor shall
be responsible for paying the consulting engineer for this additional work.
6. INCIDENTAL PRE-CONSTRUCTION STAKING: Right-of-way flagging, back of curb
location, driveways, walks and retaining walls as requested by the City Inspector, curb radii
(to determine construction location) for utility clearance.
7. SPECIAL CONDITIONS:
a. The City Inspector assigned to the project shall oversee all construction staking
activity and shall be responsible for all field coordination. All documentation
including field notes, cut and/or fill notes, grades, "as staked" information etc., shall
EA2-13
Rev 11/30/04
r C,
be provided to the City inspector and shall be sealed and signed by a surveyor
licensed in the State of Texas.
b. The Engineer's Surveyor shall attend the pre-construction conference.
C. The Engineer's Surveyor shall meet with City Inspector and Contractor to
coordinate surveying schedule and needs prior to beginning work.
d. The Engineer's Surveyor shall stake each utility separately and at different times
with, if applicable, sanitary sewer first, water second, storm drain third and roadway
construction fourth and shall provide enough construction staking information so
that the projects can be constructed as designed.
e. A member of Engineer's firm familiar with project shall be available at all times to
immediately respond to questions from the field.
EA2-14
Rev 11/30/04 T,- ^^
ATTACHMENT "B"
(SUPPLEMENT TO ATTACHMENT B)
COMPENSATION AND PAYMENT SCHEDULE
Engineering Design Services Associated With
Street Reconstruction, Water and Sanitary Sewer Replacements
2004 CIP—ARTERIAL STREET PROJECT
CHAPEL CREEK BOULEVARD (IH-30 NORTH TO CHAPIN ROAD)
CITY PROJECT NO. 000139
1. Compensation
A. The ENGINEER shall be compensated a total lump sum fee of $61,298 as
summarized in Exhibit "B-3". Payment of the total lump sum fee shall be
considered full compensation for the services described in Attachment "A" and
Exhibit "A-1" for all labor materials, supplies, and equipment necessary to
complete the project.
B. The Engineer shall be paid monthly as described in Exhibit "B-1", Section I —
Method of Payment.
Each invoice is to be verified as to its accuracy and compliance with the terms of
this contract by an officer of the Engineer.
2. Schedule
Final Plans and Contract Documents for bid advertisement shall be submitted
within 180 working days after the "Notice to Proceed" letter is issued based on
the following schedule.
A. Conceptual Engineering Plans— 30 working days
B. CITY Conceptual Plan review— 10 working days
C. Preliminary Engineering Plans & Contract Documents — 30 working days (upon
receipt of Conceptual Plan review)
D. CITY Preliminary Engineering Plan review— 10 working days
E. Final Engineering Plans & Contract Documents — 30 working days (upon
receipt of Preliminary Engineering Plan review)
F. CITY Final Engineering Plan review— 10 working days
G. Final Plans and Contract Documents for Bid Advertisement — 30 working days
(upon receipt of Final Engineering Plan review)
B-1
EXHIBIT "13-1"
(SUPPLEMENT TO ATTACHMENT B)
METHOD OF PAYMENT
Engineering Design Services Associated With
Paving and Drainage Construction
2004 CIP—ARTERIAL STREET PROJECT
CHAPEL CREEK BOULEVARD (I1-1-30 NORTH TO CHAPIN ROAD)
CITY PROJECT NO. 000139
I. Method of Payment
Partial payment shall be made to the Engineer monthly upon City's approval of an
invoice from the Engineer outlining the estimated current percent complete of the total
project.
The aggregate of such monthly partial fee payments shall not exceed the following:
Until satisfactory completion of Exhibit "A-1", Conceptual Engineering Plan submittal and
approval by the City, a sum not to exceed 30 percent of the total lump sum fee.
Until satisfactory completion of Exhibit "A-1", Preliminary Construction Plan submittal
and approval by the City, a sum not to exceed 60 percent of the total lump sum fee.
Until satisfactory completion of Exhibit "A-1", Final Construction Plan submittal and
approval by the City, a sum not to exceed 90 percent of the total lump sum fee.
The balance of fees, less previous payments, shall be payable after all of the pre-
construction meetings for the Project have been conducted.
II. Progress Reports
A. The Engineer shall submit to the designated representative of the Director of the
Department of Engineering quarterly progress reports covering all phases of
design in the format required by the City.
B. If the Engineer determines in the course of making design drawings and
specifications that the opinion of probable construction cost of $ 368,000 (as
estimated in Exhibit B-5) will be exceeded, whether by change in the scope of
the project, increased cost or other conditions, the Engineer shall immediately
report such fact to the City's Director of the Department of Engineering and, if so
instructed by the Director of the Department of Engineering shall suspend all
work hereunder.
EXHIBIT "B-2"
HOURLY AND REIMBURSABLE RATE SCHEDULE
2004 CIP-ARTERIAL STREET PROJECT
CHAPEL CREEK BOULEVARD(IH-30 NORTH TO CHAPIN ROAD)
CITY PROJECT N0.000139
Engineering/Technical From To
Principal $145 - $220 Per Hour
Project Manager $110 - $150 Per Hour
IT Consultant $120 - $140 Per Hour
Senior Engineer $80 - $150 Per Hour
Engineer $70 - $120 Per Hour
Landscape Architect/Planner $80 - $130 Per Hour
Designer $80 - $95 Per Hour
Senior Designer $110 - $120 Per Hour
CAD Technician $50 - $75 Per Hour
Senior CAD Technician $70 - $90 Per Hour
IT Technician $70 - $80 Per Hour
Clerical $45 - $65 Per Hour
Resident Project Representative $70 - $90 Per Hour
Surveying
Survey Office Manager $145 - $155
R.P.L.S. $100 - $100
Senior Survey Technician $70 - $85
Junior Survey Technician $55 - $70
2-Person Field Crew w/Equipment $100
3-Person Field Crew w/Equipment $110
4-Person Field Crew w/Equipment $135
1-Person G.P.S. Crew w/Equipment $110
2-Person G.P.S. Crew w/Equipment $130
3-Person G.P.S. Crew w/Equipment $150
1-Person Robotic Crew w/Equipment $90
2-Person Robotic Crew w/Equipment $110
Direct Cost Reimbursables
Photocopies $0.10/page letter and legal size bond paper, B&W
$0.20/page 11" x 17" size bond paper, B&W
$2.00/page 22" x 34" and larger bond paper or vellum, B&W
Plots $1.00/page 11" x 17"size bond paper, B&W
$2.00/page 11"x 17"size bond paper, color
$4.00/page 22"x34" and larger bond paper or vellum, B&W
$6.00/page 22"x34" and larger bond paper or vellum, color
$6.00/page 22"x34"and larger mylar or acetate, B&W
Mileage $0.40/mile
All Subcontracted and outsourced services billed at rates comparable to TNP's billing rates shown above.
*Rates shown are for calendar year 2006 and are subject to change in subsequent years.
62-1
EXHIBIT "B-3A"
(SUPPLEMENT TO ATTACHMENT B)
SUMMARY OF TOTAL PROJECT FEES
Engineering Design Services Associated With
Paving and Drainage Construction
2004 CIP—ARTERIAL STREET PROJECT
CHAPEL CREEK BOULEVARD (IH-30 NORTH TO CHAPIN ROAD)
CITY PROJECT NO. 000139
Consulting Firm Prime Responsibility Amount Percent
Prime Consultant:
Teague Nall and Perkins, Inc. Engineering & Proj. Mgmt. $ 50,264 82.0%
MIWBE Consultants:
Palmer Price, Inc. Engineering Services $ 6,500 10.6%
Hugo C. Trevino &Associates, Inc. Printing/Reproduction $4,534 7.4%
Total for Professional Services $ 61,298 100%
Note: Non-M/WBE Consultants— None.
Project Description Scope of Services Total Fee M/WBE Fee Percent
Engineering Services Paving & Drainage $ 61,298 $ 11,034 18.0%
B3A-1
EXHIBIT "B-36"
(SUPPLEMENT TO ATTACHMENT B)
PROFESSIONAL SERVICES FEE SUMMARY
Engineering Design Services Associated With
Paving and Drainage Construction
2004 CIP—ARTERIAL STREET PROJECT
CHAPEL CREEK BOULEVARD (I1-1-30 NORTH TO CHAPIN ROAD)
CITY PROJECT NO. 000139
BASIC ENGINEERING DESIGN FEE:
T&PW: (Construction Cost X TSPE Curve"A"X 85%)
Paving & Drainage Improvements: $402,000 X 8.9% X 85% _ $ 30,412
T&PW: Basic Services Total: $ 30,412
ADDITIONAL SERVICES:
Transportation & Public Works:
Surveying Services = $ 8,620
Public Meetings = $2,400
Quarterly Progress Reports/Coordination with Mgr.
[(1 Report x$ 500/report—add'I reports &coord. @ Std. Hourly rates) _ $ 500
SW3P = $4,000
Franchise Utility Conflict Coord. (performed hourly if needed) _ $ 0
TxDOT Permit Coordination = $4,800
Administrative (10%) Fee on M/WBE Firms = $ 1,103
Printing/Reproduction = $6,563
Construction Assistance (Refer to Exhibit B-3F) __ S 2»900
T&PW:Additional Services Total: $ 30,886
B3B-1
(INCLUDE THE FOLLOWING ON EXHIBIT 'S-36")
SUMMARY OF TOTAL FEE AND BREAKDOWN OF DESIGN FEE (LESS SURVEY FEE)
A. SUMMARY OF TOTAL FEE
Service Description Paving/Drainage
Basic Engineering $ 30,412
Services
Additional Engineering $ 22,266
Servi
Subtotal $ 52,678
Surveying Services $ 8,620
Total $ 61,298
B. BREAKDOWN OF PAVING AND DRAINACF FEES (LESS SURVEY FFESI
1. Total Paving/Drainage Fee (less survey fee) Breakdown by Conceptual- Preliminary & Final
D2GIgn
a. Conceptual (30%)= (Total Pave./SD Fee—Pave./SD Survey Fee) x (0.3) = $ 15,803
b. Preliminary(60%) = (Total Pave./SD Fee—Pave./SD Survey Fee)x (0.6) = $31,607
C. Final (10%) = (Total Pave./SD Fee—Pave./SD Survey Fee) x(0.1) _ $ 5,268
Subtotal $ 52,678
63B-2
EXHIBIT "B-3C"
(SUPPLEMENT TO ATTACHMENT B)
FEES FOR SURVEYING SERVICES
Engineering Design Services Associated With
Paving and Drainage Construction
2004 CIP—ARTERIAL STREET PROJECT
CHAPEL CREEK BOULEVARD (I1-1-30 NORTH TO CHAPIN ROAD)
CITY PROJECT NO. 000139
Surveying Services:
Paving and Drainage Topographic Surveys 700 LF x$5.60 = $ 3,920
*ROW Determination/Boundary Survey = $4.700
T&PW: Total for Surveying Services: _ $ 8,620
Transportation and Public Works Department:
Paving & Storm Drainage Cost Opinion /Total Cost Opinion = $402,000/$402,000 = 100.0%
T&PW Survey Subtotal: $ 8,620 x 1.00 = $ 8,620
*NOTE: Preparation of ROW Exhibits is not included in this fee. A preliminary review of ROW maps
and appraisal district maps indicates that sufficient ROW may exist. If the approved alignment and
engineering design requires additional ROW,these services can be provided under the attached hourly
rate schedule.
B3C-1
EXHIBIT "B-313"
(SUPPLEMENT TO ATTACHMENT B)
ADDITIONAL SERVICES
Engineering Design Services Associated With
Paving and Drainage Construction
2004 CIP—ARTERIAL STREET PROJECT
CHAPEL CREEK BOULEVARD (IH-30 NORTH TO CHAPIN ROAD)
CITY PROJECT NO. 000139
Additional Services:
Transportation and Public Works Department:
Paving & Storm Drain Cost Opinion/Total Cost Opinion = $402,000/$402,000 = 100.0%
Public Meetings: 2 x$ 1,200/meeting x 1.000 = $ 2,400
.............................................
Quarterly Progress Reports/Coordination with Program Mgr.:
[(1 Report x$ 500/report—add'I reports & coordination @ Std. Hourly rates) _ $ 500
SW3P:....................................................................................$4,000 x 1.000 = $4,000
Franchise Utility Conflict Coord. (performed hourly if needed): ..$ 0 x 1.000 = $ 0
TxDOT Permit Coordination.................................................$4,800 x 1.000 = $4,800
Administrative (10%) Fee on M/WBE Firms:........................$ 1,206 x 1.000 = $ 1,103
Transportation and Public Works Department Subtotal: $ 12,803
B3D-1 _ . _
EXHIBIT "B-3E"
(SUPPLEMENT TO ATTACHMENT B)
ADDITIONAL SERVICES — PRINTING/ REPRODUCTION
Engineering Design Services Associated With
Paving and Drainage Construction
2004 CIP—ARTERIAL STREET PROJECT
CHAPEL CREEK BOULEVARD (I1-1-30 NORTH TO CHAPIN ROAD)
CITY PROJECT NO. 000139
Additional Services:
Plans:
Concept Plans: 4 x 6 plan sheets x $2 / plan sheet = $ 48
Preliminary Plans: 2 x 26 plan sheets x $2 /plan sheet = $ 104
Utility Plans: 13 x 26 plan sheets x $2/ plan sheet = $ 676
Final Plans: 2 x 26 plan sheets x $2 /plan sheet = $ 104
Bid Plans: 50 x 26 plan sheets x$2 /plan sheet = $ 2,964
Mylar Plans: 1 x 26 plan sheets x$4/plan sheet = $ 104
'/ Size Final Approved Plans: 15 x 26 plan sheets x$1 / plan sheet = $ 390
Note: Additional or interim check sets requested by the City shall be provided according to the Std.
Rate Schedule (Exhibit B-2)
Specifications:
Concept Plan Submittal: 2 sets x $22 /spec. book = $ 80
Final Plan Submittal: 2 sets x$22 /spec. book = $ 80
Bid Plans Submittal: 50 sets x$22 /spec. book = $ 1,680
Photocopies:
200 photocopies x $0.10/photocopy = $ 20
Binding/Punching/Delivery = $ 313
Printing / Reproduction Total = $ 6,563
Transportation and Public Works Department:
Paving & Storm Drainage Cost Opinion /Total Cost Opinion = $402,000/$402,000 = 100.0%
Transportation and Public Works Department Total: $ 6,563 x 1.000 = $ 6,563
B3E-1
EXHIBIT "B-3F"
(SUPPLEMENT TO ATTACHMENT B)
ADDITIONAL SERVICES —CONSTRUCTION ASSISTANCE
Engineering Design Services Associated With
Paving and Drainage Construction
2004 CIP—ARTERIAL STREET PROJECT
CHAPEL CREEK BOULEVARD (IH-30 NORTH TO CHAPIN ROAD)
CITY PROJECT NO. 000139
Additional Services:
Pre-Bid Meeting = $ 500
Attend Bid Opening = $400
Tabulate Bids = $ 500
Recommend Contract Award = $ 300
Attend Pre-Construction Meeting = $ 500
Periodic Site Visits (3 visits— additional visits at Std. Hourly rates) _ $ 600
Final Inspection = 400
Construction Assistance Total = $ 2,900
Transportation and Public Works Department:
Paving & Drainage Cost Opinion/Total Cost Opinion = $402,000/$402,000 = 100.0%
Transportation and Public Works Department Total: $2,900 x 1.000 = $ 2,900
B3F-1
EXHIBIT "B-4"
OPINION OF PROBABLE CONSTRUCTION COSTS
SUMMARY
CITY OF FORT WORTH ENGINEERING
Engineering Design Services Associated With
Paving and Drainage Construction
2004 CIP—ARTERIAL STREET PROJECT
CHAPEL CREEK BOULEVARD (I1-1-30 NORTH TO CHAPIN ROAD)
CITY PROJECT NO.000139
Concrete Pavement Alternate
Street Storm Drain
Location Reconstruction Construction Total Construction
Chapel Creek Boulevard. (IH30 North to Chapin Road $ 252,000 $ 150,000 $ 402,000
TOTALS 4$ 252,000 $ 150,000 $ 402,000
PERCENT COST 62 7%1 37.3%
HMAC Pavement Alternate
Street Storm Drain
Location Reconstruction Construction Total Construction
Chapel Creek Boulevard. (IH30 North to Chapin Road $ 221,000 $ 150,000 $ 371,000
TOTALS $ 221,000 $ 150,000 $ 371,000
PERCENT COST 1 59.6%1 40.4%
B4-1
TEAGUE NALL AND PERKINS Exhibit B-5
CONSULTING ENGINEERS
OPINION OF PROBABLE CONSTRUCTION COST
CHAPEL CREEK BLVD(IH-30 NORTH TO CHAPIN RD)
(FEE PROPOSAL)
OWNER: CITY OF FORT WORTH
DATE: August 25,2005
TOTAL PROJECT SUMMARY
ITEM
NO. DESCRIPTION OF ITEMS TOTAL
1 PAVING IMPROVEMENTS(CONCRETE ALTERNATE) $252,000
2 DRAINAGE IMPROVEMENTS $150,000
TOTAL PROJECT COST $402,000
7n C
`r li r I
I
TEAGUE NALL AND PERKINS Exhibit B-5
CONSULTING ENGINEERS
OPINION OF PROBABLE CONSTRUCTION COST
CHAPEL CREEK BLVD(IH-30 NORTH TO CHAPIN RD)
(FEE PROPOSAL)
OWNER: CITY OF FORT WORTH
DATE: August 25,2005
PAVING IMPROVEMENTS (CONCRETE ALTERNATE)
ITEM I UNIT
NO. DESCRIPTION OF ITEMS QUANTITY UNIT COST TOTAL
1 Project Designation Sin 2 EA $200.00 $400.00
3 Unclassified Street Excavation 4,000 CY $10.00 $40,000.00
4 8"Lime Stabilized Sub rade 5,500 SY $2.65 $14,575.00
5 Lime Stabilization 35 LB/SY) 96 TON $100.00 $9,625.00
6 7"Reinforced Concrete Pavement 5,200 SY $26.00 $135,200.00
7 7"Concrete Curb 1,600 LF $2.50 $4,000.00
8 6"HMAC Transition Pavement(Type D 150 SY $25.00 $3,750.00
9 6"Pipe Subdrain 100 LF $ 8.00 $ 800.00
10 Accessible Curb Rams 2 EA $ 850.00 $ 1,700.00
11 Construct Concrete Sidewalk 3,000 SF $ 4.50 $ 13,500.00
12 Misc. Utility Adjustments 1 LS $ 5,000.00 $ 5,000.00
Basis for Cost Projection Sub-Total Construction Cost: $ 228,550.00
❑' Na Design lbmpleted Contingency: 10% $ 23,450.00
❑ Preliminary Design
❑ Final Design Total Opinion of Construction Cost: $ 252,000.00
B5-2
TEAGUE NALL AND PERKINS Exhibit B-5
CONSULTING ENGINEERS
OPINION OF PROBABLE CONSTRUCTION COST
CHAPEL CREEK BLVD(IH-30 NORTH TO CHAPIN RD)
(FEE PROPOSAL)
OWNER: CITY OF FORT WORTH
DATE: August 25,2005
PAVING IMPROVEMENTS (HMAC ALTERNATE)
ITEM UNIT
NO. DESCRIPTION OF ITEMS QUANTITY UNIT COST TOTAL
1 Project Designation Sin 2 EA $ 200.00 $ 400.00
3 Unclassified Street Excavation 4,000 CY $ 10.00 $ 40,000.00
4 8"Lime Stabilized Sub rade 5,500 SY $ 2.65 $ 14,575.00
5 Lime Stabilization 35 LB/SY 96 TON $ 100.00 $ 9,625.00
6 2"Type D HMAC Pavement 536 TON $ 50.00 $ 26,800.00
7 6"Type B HMAC Pavement 1,608 TON $ 40.00 $ 64,320.00
8 7"Concrete Curb and 18"Gutter 1 600 LF $ 15.00 $ 24,000.00
9 6"Pipe Subdrain 100 LF $ 8.00 $ 800.00
10 Accessible Curb Rams 2 EA $ 850.00 $ 1,700.00
11 Construct Concrete Sidewalk 3,000 SF $ 4.50 $ 13,500.00
12 Misc. Utility Adjustments 1 LS $ 5,000.00 $ 5,000.00
Basis for Cost Projection Sub-Total Construction Cost: $ 200,720.00
0 N0 Design Completed Contingency: 10% $ 20,280.00
❑ Preliminary Design
❑ Final Design Total Opinion of Construction Cost: $ 221,000.00
4.
B5-3
TEAGUE NALL AND PERKINS Exhibit B-5
CONSULTING ENGINEERS
OPINION OF PROBABLE CONSTRUCTION COST
CHAPEL CREEK BLVD(IH-30 NORTH TO CHAPIN RD)
(FEE PROPOSAL)
OWNER: CITY OF FORT WORTH
DATE: August 25,2005
DRAINAGE IMPROVEMENTS
ITEM UNIT
NO. DESCRIPTION OF ITEMS QUANTITY UNIT COST TOTAL
1 Remove Concrete Sloped End Treatment 1 EA $500.00 $500.00
2 21"Class III RCP 180 LF $50.00 $9,000.00
3 30"Class III RCP 100 LF $76.00 $7,600.00
3 42"Class III RCP 745 LF $120.00 $89,400.00
4 10'Curb Inlet 4 EA $2,500.00 $10,000.00
5 Drop Inlet 2 EA $2,500.00 $5,000.00
5 Storm Drain Manhole 3 EA $3,000.00 $9,000.00
6 Sloped End Treatment 1 EA $3,000.00 $3,000.00
7 SW3P 1 LS $2,500.00 $2,500.00
Basis for Cost Projection Sub-Total Construction Cost: $ 136,000.00
2 N0 Design c0A1aeted Contingency: 10% $ 14,000.00
❑ Preliminary Design Total Opinion of Construction Cost: $ 150,000.00
❑ Final Design
135-4
ATTACHMENT "C"
CHANGES AND AMENDMENTS TO ATTACHMENT A
Engineering Design Services Associated With
Paving and Drainage Construction
2004 CIP —ARTERIAL STREET PROJECT
CHAPEL CREEK BOULEVARD (I1-1-30 NORTH TO CHAPIN ROAD)
CITY PROJECT NO. 000139
NONE
C-1
CITY OF FORT WORTH-2004 CIP-Arterial Street Projcect ATTACHMENT D Teague Nall and Perkins,Inc.
CHAPEL CREEK BOULEVARD(I1-1-30 NORTH TO CHAPIN ROAD) Project Schedule(Working Days)
2006 12007
ID Task Name Duration Start Finish Qtr 1 Qtr 2 1 Qtr 3 Qtr 4 Qtr 1 Qtr 2 Qtr 3 Qtr 4
1 ENGINEERING 152 days Tue 1124!06 Wed 8/23106 ;
2 Notice to Proceed 1 day Tue 1/241[16Tue 1/24/06 : 1/24
3 Kick-off Meeting 1 day Wed 1125;06 Wed 1125106 1125
4 Design Surveys 15 days Thu 1{26ig6 Wed 2/15!06
5 Conceptual Design(30%) 30 days Thu 1/26/D6 Wed 3/8106 ;
6 City Review 10 days Thu 319106 Wed 3122/06
8 U1dit Clearance 60-ia G Thu 3/23/06 ed 126/0x;
7 Preliminary Design(6D%) 30 days
y -- y-!, Thu 5/4106 Wed,I26i06
9 City 10 days Thu 514!06 Wed:;/171061,
Y 1 ,
9 ( ) Y —-
11 Cit Review IU days Thu 5x29106 Wed 6/28iU6
10 Final Desi n 90% .0 da s Thu 51t 6 Cry
y y Wed 7/12Jfl6 i
12 Final PS&E(100%) 3o tlays Thu 7/13/06 Wed 8123108
13 CONSTRUCTION 169 days Thu 8124/06 Tue 41171D7
14 Circulate Plans for Sig
15 Advertise for Bids 20 days i Mon 828+06 Fri 8125/06 j
Signature 2 days Thu 8i 24/06
Fri 9122106
16 Open Bids 1 day Mon q 25:05 T 9125
17 Award Contract 25 days Tue 9126106 Mon 10/30 Lt
18 Pre-Construction Meeting 1 day Tue 10131/06 Tue 101 1/06 10/31
19 Construction-Paving 120 days Wed 11/1/06 Tue 4/17/07
D-1
ATTACHMENT D-1
PROJECT SCHEDULE - PROJECTED/ACTUAL PROJECT DATES
2004 CIP -ARTERIAL STREET PROJECT
CHAPEL CREEK BOULEVARD (I1-1-30 NORTH TO CHAPIN ROAD)
ENGINEERING SERVICES CONTRACT ATTACHMENTS
Schedule (WorkingDa s
City of Fort Worth
City Project No. 000139
PROJECTED ACTUAL
ID ITask Name IDurationj Start I Finish Duration Start Finish
1 Notice-to-Proceed/Kick-Off Meeting 1 day Tue 01/24/06 Tue 01/24/06
2 To o ra hic Surve 15 days Thu 01/26/06 Wed 02/15/06
3 Pre are 30% Plan Submittal 30 days Thu 01/26/036 Wed 03/08/06
4 30% Plan Submittal 1 day Wed 03/08/06 Wed 03/08/06
5 City of Fort Worth Review 10 da s Thu 03/09/06 Wed 03/22/06
6 Neighborhood Meeting 1 day Thu 03/23/06 Thu 03/23/06
7 Address DOE/Citizen Comments 2 days Mon 03/26/06 Tue 03/27/06
8 Submit Plans for Utility Coord. 1 daV Wed 03/08/06 Wed 03/08/06
9 Incorporate Comments/Prepare Design 30 days Thu 03/23/06 Wed 05/03/06
10 60% Plan Submittal to DOE 1 day Thu 05/04/06 Thu 05/04/06
11 lFranchise Utility Relocations 60 days Thu 05/04/06 Wed 07/26/06
12 City of Fort Worth Review 10 days Thu 05/04/06 Wed 05/17/06
13 Incorporate Final Comments 30 days Thu 05/18/06 Wed 06/28/06
14 Submit 90% Plans and Specs. 1 dav Thu 06/29/06 Thu 06/29/06
15 City of Fort Worth Review 10 days Thu 06/29/06 Wed 07/12/06
16 Submit Final Plans 30 days Thu 07/13/06 Wed 08/23/06
17 Circulate Plans for Signatures 2 days Thu 08/24/06 Fri 08/25/06
18 Advertise Project 1 day Mon 08/28/06 Mon 08/28/06
19 Advertisement Duration 20 da s Mon 08/28/06 Fri 09/22/06
20 Oen Bids 1 day Mon 09/25/06 Mon 09/25/06
21 M & C Circulation Process 25 Das Tue 09/26/06 Mon 10/30/06
22 lCouncil Award 1 dayl Tue 10/31/06 Tue 10/31/06
D1-1
CITY OF FORT WORTH
"17i i7l I !
17.193 AC SELLERS RD.
CHAPIN _ — CHAPIN RD.
26-99
00 WESTLAND RD. Ar
a
15.66 AC
CHAPEL CREEK BOULEVARD PAWING
AND DRAINAGE IMPROVEMENTS a
COUNCIL DIST. NO. 3 d S f�
MAPSCO N0. 72K3T,
°
'
E
SOUTHvMW
8.33 AC
.75 AC
9.431 AC
q w
m
� I i
CHAPEL SPRDic11. Al
DR
A TTA CHMENT E-1
2004 CIP - ARTERIAL STREET PROJECT
PA VING AND DRAINAGE IMPROVEMENTS
ON CHAPEL CREEK BOULEVARD (IH-30 NORTH TO CHAPIN ROAD
FORTWORTH
SCALE TEAGUI MALL AND PERIUMS CITY OF FORT WORTH, TEXAS 1
1"=300' Of�l 1►I/wlnARl COIIW.r"m 4004 CP—MTMAL STREET PRWECT SHEET
N/A°°" ma"Mm&row CHAPEL CREEK BOULEVARDDATE 1
JULY 005 Four 00� PROJECT LAYOUT 3
CITY OF FORT WORTH
28 1 1 1 213 ! 4 1 5-1_6 1 7 18 9 110 20 1
2 S 6 7 8 9 10 111 1 12 13 X14 `;5 16 17 18 19 20
3
1
38 37 38 35 34�-ll 32 31 30 29 28 27 26 25 `24 12
4 !
A6Ap3 SELLERS RD.
17.193 AC
1 i
I
2 5 6 7 8 9 ( 10 11 12 1314 �15 �1617 18j19 20
3
CHAPIN CHAPIN RD. 38 37 36 35 34 33 32 31 30 1 29 28 27 26 25 24 23
26-99 4
00 WESTLAND RD.
i
PROP 7" CONC. PA VEMENT 17 t 6
15.66 AC AF I I i
1
3
10 11 12 13 14
4
O
SCHARF
e
i 5 7 .r
2
28 27 26 25 2�
SOUTHVIEW
8.33 AC
.75 AC
9.431 AC
qq �
� r
1 2 3 4 5 6 7 g 9 1C 11 12 13 14 15116 17
1
18
CHAPEL SPRINGS DR
A TTA CHMENT E-2
PROPOSED PAVING IMPRO YEMEN TS
PA VIN IMPR0 YEMEN TS
CHAPEL CREEK BOULEVARD
(IH-30 NORTH TO CHAPIN ROAD)
FORTWORTH
air/v?
arrow awr 0I MAPSCO N0. 7N
SCALE Tffw&=NALL AND PENJUNS CITY OF FORT WORTH, TEXAS
1" 300' O�lJI! MWKraai•00R TAM 2004 CP—ARnR&STREET PF"CT SHEET
N/A"°" JIM wconSboo CHAPEL CREEK BOULEVARD 2
DATE,xrLY 2005 rN�' Fo/e 00 PAVING IMPROVEMENTS 3
A
Cl TY OF FOR T WOR TH
3 I
2," 30"
CHAPIN RD . 38 37 ' 36)
2," I 4 �
i 1
PROP DRAINAGE IMPRO I/EMEN TS WEST LAN D
U
Q
CV 1
21" 5 6
2," 2
W 1
W 10 11 12
R' 4
SCHARF
� aW {
U ^
Ir 1 5 6 Qf7
Q
Q 2
PROP DRAINAGE IMPRO EMENTS Q
It
21" 2,"
af
42" ATTACHMENT E-3
DRA INA GE IMPR0 YEMEN TS
CHAPEL CREEK BOULEVARD
(1H-30 NORTH TO CHAPIN ROAD)
MVSDUK FORTWORTH
PROP SD MANHOLE 0
PROP to'CURB uff o
EXIST SD ME
EXIST SD MANHOLE
Mr CURB kYLET o COUNCIL USIMCT NO. 3
MAPSW NO. 72(
S
CALE 7Z4=NA/l AMD PZIWN8 CITY OF FORT WORTH, TEXAS
p�j!8MMOIRS♦00AWWTANTS 2004 CIP—ARTERIAL STREET SOT SHEET
MW�� CHAPEL CREEK BOULEVARD S
�Nc' `°'t M1 vtlLi asap s' DRAINAGE IMPROVEMENTS 3
City of Fort Worth, Texas
Mayor and Council Communication
COUNCIL ACTION: Approved on 12/6/2005
DATE: Tuesday, December 06, 2005
LOG NAME: 30CHAPCREEK139 REFERENCE NO.: **C-21178
SUBJECT:
Authorize Execution of Engineering Agreement with Teague Nall and Perkins Inc., for Chapel Creek
Boulevard Paving and Drainage Improvements from IH-30 North to Chapin Road (City Project No.
00139)
RECOMMENDATION:
It is recommended that the City Council authorize the City Manager to execute an engineering agreement
with Teague Nall and Perkins, Inc., in the amount of $61,298.00, for Chapel Creek Boulevard paving and
drainage improvements from IH-30 North to Chapin Road.
DISCUSSION:
The 2004 Capital Improvement Program (CIP) includes funds for reconstruction of Chapel Creek Boulevard
from IH-30 North to Chapin Road under Arterial Street Project.
This project consists of the preparation of plans and specifications for the above-referenced street with 7-
inch concrete pavement over 6-inch stabilized subgrade including storm drains of various sizes. The
existing two lanes of asphalt street, which is in dilapidated condition, will be removed and five new lanes of
concrete pavement will be constructed with a center turning lane.
Teague Nall and Perkins, Inc., proposes to perform the necessary design work for a lump sum fee of
$61,298.00. City Staff considers this fee to be fair and reasonable for the scope of services proposed.
In addition to the contract amount, $17,716.00 is required for project management by the Engineering
Department.
Teague Nall and Perkins, Inc., is in compliance with the City's M/ BE Ordinance by committing to 18%
M/WBE participation. The City's goal on the project is 18%.
This project is located in COUNCIL DISTRICT 3, Mapsco 72K.
FISCAL INFORMATION/CERTIFICATION:
The Finance Director certifies that funds will be available in the current capital budget, as appropriated, of
the the Street Improvement Fund.
TO Fund/Account/Centers FROM Fund/Account/Centers
C200 531200 203230013931 $15,803.00
C200 531200 203230013932 $31,607.00
C200 531200 203230013933 $5,268.00
C200 531200 203230013951 $8,620.00
Submitted for City Manager's Office by Marc Ott (8476)
Originating Department Head: A. Douglas Rademaker (6157)
Additional Information Contact: A. Douglas Rademaker (6157)