Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
Contract 51069
THIS COPY IS�POR. CONTRACTOR .. CRY SECRETARY CITY SECRETARY CONTRACT N0. PROJECT MANAGER PMD FILE COPY r THE CITY OF FORT WORTH, TEXAS CMAR Construction Contract (Construction Manager-at-Risk) PARD Service Center Project PMD2017-08 City Project # 101010 FORT WORTH CHI BETSY PRICE DAVID COOKE MAYOR CITY MANAGER Fernando Costa Assistant City Manager RECEIVED Richard Zavala AUG -1 2018 Director, Park and Recreation Department MYOFFOAT �- ' ' Steve Cooke Director, Property Management Department June 2018 OFFICIAL.RECORD CITY SECRETARY L . ".1 OR", rx PARD Service Center Project -- — of 58 Byrne CMAR Construction Contract June 2018 C-a s I ? CERTIFICATE OF INTERESTED PARTIES FORM 1295 1 of 1 Complete Nos. 1-4 and 6 if there are interested parties. OFFICE USE ONLY Complete Nos. 1,2,3,5,and 6 if there are no interested parties. CERTIFICATION OF FILING 1 Name of business entity filing form,and the city,state and country of the business entity's place Certificate Number: of business. 2017-279499 Thos. S. Byrne, Inc. Fort Worth,TX United States Date Filed: 2 Name of governmental entity or state agency that is a party to the contract for which the form is 11/02/2017 being filed. City of Fort Worth Date Acknowledged: �1. 3 Provide the identification number used by the governmental entity or state agency to track or identify the contract,and provide a description of the services,goods,or other property to be provided under the contract. PARD Service Center Construction Manager-at-Risk Services for the Parks and Recreation Department Service Center Nature of interest 4 Name of Interested Party City,State,Country(place of business) (check applicable) Controlling I Intermediary Avila,John Fort Worth, TX United States X 5 Check only if there is NO Interested Party. ❑ 6 AFFIDAVIT I swear,or affirm,under p alty of p that th above disclosure is true and correct. �; Y P'-1 BENJAMIN LOUELL ROBERTSON :Notary Public,State of Texas "r�oF �� Comm.Expires 10-17-2021 om Notary ID 12802846-3 Signa ure of authorized age of contracting business entity AFFIX NOTARY STAMP/SEAL ABOVE Sworn to and subscribed before me,by the said Paul Avila this the 2nd day of November 20 17 to certify which,witness my hand and seal of office. �- Benjjumnmbertson Director of Business Development Sigriature of officer administering oath Printed name of officer administering oath Title of officer administering oath Forms provided by Texas Ethics Commission www.ethics.state.tx.us Version V1.0.3337 City of Fort Worth, Texas Mayor and Council Communication - COUNCIL ACTION: Approved on 12/12/2017 DATE: Tuesday, December 12, 2017 REFERENCE NO.: C-28518 .- LOG NAME: 21 PARD CONSOLIDATED SERVICE CENTER CMAR SERVICES SUBJECT: Authorize Execution of Construction Manager at Risk Construction Contract with Thomas S. Byrne d/b/a Byrne Construction Services, with a Construction Services Fee of 3.57 Percent of the Construction and General Conditions Costs Within a Construction Contract Budget Amount of$7,801,234.00 Inclusive of a 7.5 Percent Owner's Allowance for Additional Construction Services for the New Park and Recreation Department Consolidated Service Center Located at Greenbrier Park, 5199 James Avenue (COUNCIL DISTRICT 9) , RECOMMENDATION: It is recommended that the City Council authorize execution of a Construction Manager at Risk .. Construction Contract with Thomas S. Byrne d/b/a Byrne Construction Services, with a Construction Services Fee of 3.57 percent of the construction and general conditions costs within a construction contract budget amount of$7,801,234.00 inclusive of a 7.5 percent owner's allowance for additional construction services for the•new Park and Recreation Department Consolidated Service Center located at Greenbrier Park, 5199 James Avenue. DISCUSSION: The Park and Recreation Department's (PARD) Crestline Service Center will be displaced as a result of the use of approximately three acres of Trinity Park and the Fort Worth Botanic Garden for the dedication •. of public road rights-of-way for the construction of the extension of Trail Drive and Van Zandt Lane Mayor and Council Communication (M&C L-16073). These PARD facilities will be replaced and located adjacent to other PARD service facilities currently located at Greenbrier Park, 5199 James Avenue. These and other improvements currently proposed in the 2018 Bond Program will consolidate the various service centers providing improved efficiency and management. Design of the new service center was authorized on June 20, 2017 with M&C C-28283. It was determined - that engaging a construction contractor early on this project to assist with the design and cost estimating would be beneficial. A requested for Statement of Qualifications (SOQ) for Construction Manager at Risk (CMAR) contractors was advertised in the Fort Worth Star-Telegram on June 15th and 20th, 2017. The City received SOQs from 11 offerors, listed below: Balfour Beatty Construction *- . Byrne Construction Services FPI Builders Inc. Haydon Building Corp . Imperial Construction, Inc. Joeris General Contractors, Ltd. Muckleroy & Falls Pogue Construction Co., LP Sedalco, Inc. Logname: 21PARD CONSOLIDATED SERVICE CENTER CMAR SERVICES Page 1 of 4 . Steele & Freeman, Inc. . W.B. Kibler Construction Co., Ltd. A selection team, comprised of representatives of Park and Recreation Department, Property Management Department and the Office of Business Diversity, reviewed the SOQs. After individual review and consideration, the selection team met to review a detailed comparison of the published criteria, including cost of services, references and CMAR experience, similar project types and MBE commitment and plan. After this discussion, scores were tabulated and the team recommends award of the CMAR construction contract to Thomas S. Byrne, Inc., d/b/a Byrne Construction Services. MBE Proposed Goal & References' Past Contractor Fees Utilization & Relationship ITOTAL� Plan Experience with City Thomas S. Byrne, Inc. { I I d/b/a Byrne 52 7.0 25 7 91.0 I Construction j Services ` — Ridgemont � R �— Commercial 52 6.5 25 7 190.5 i Construction AUI Partners, ;— LLC 54 6.5 24 5 i 89.5 f FPI Builders LLC ! 54 5.0 ! 22 i 7 88.0 Sedalco, Inc. F 5 —I 6 5 20 6 ; 87 5 j Steele & � Freeman, 1 54 5.0 17 5 81.0 Inc. j Schwob �— Building Co., i 53 F5.5 15 5 i 78.5 LTD Muckleroy & j 54 5.5 12 ; 6 77.5 Falls ; Speed Fab- 51 5.0 15 5 76.0 I Crete Corp. ; Azteca ? F-1 Enterprises, 53 7.0 , 5 5 j 70.0 I Inc. j Key Construction 54 1.0 I F-5 5 65.0 TX, LLC Dennett 1 ICon.struction 1 50 1.0 I 5 6 162.0 f Logname: 21PARD CONSOLIDATED SERVICE CENTER CMAR SERVICES Page 2 of 4 Estimated Costs: Construction - Byrne Construction Services is in the process of establishing a Guaranteed Maximum Price (GMP) for the construction of the new Consolidated Service Center. Once presented and accepted by staff, the contract will be amended to incorporate the GMP. A Pre-Construction Services contract was administratively awarded to Byrne Construction Services in the amount of$18,500.00. The estimated project costs for the new Consolidated Service Center are as follows: DESCRIPTION i PROJECT COST) .. Design $ 975,600.00; Project Management, Platting, I I esting, Surveying, Utilities,etc. Is 32,400.001 r Design Sub Total$ 1,008,000.001 Construction Contract Budget including 3.57 ,percent CMAR Fee and 7.5 percent Owner's $ 7,801,234.001 Allowance .. Site Utilities, IT, Security, FFE, Materials s (Testing, Project Management, Contingency, Is 1,172,266.00 ;etc. , I Construction Sub Total$ 8,973,500.001 PROJECT TOTAL$ 10,000,000.001 Thomas S. Byrne, Inc., d/b/a Byrne Construction Services is in compliance with the City's BDE Ordinance by committing to 30 percent MBE participation on this CMAR project. The City's MBE goal on this CMAR project is 17 percent. Additionally, Thomas S. Byrne Inc., d/b/a Byrne Construction Services is a certified M/WBE contractor. In accordance with the City Code, City of Fort Worth Building and Trade Permit fees are waived. The PARD Service Center is located in COUNCIL DISTRICT 9. .. FISCAL INFORMATION /CERTIFICATION: The Director of Finance certifies that upon approval of the above recommendation, funds will be available in the current capital budget, as appropriated of the Tax Note 2017 Fund. (Park and Recreation -� Department Maintenance Facility Relocation Project; City Project No. 101010). FUND IDENTIFIERS (FIDs): -� TO (Fund Department Accoun Project Program ctivity Budget Reference # mount ID ID , Year (Chartfield 2 FROM. Fund Department Accoun Project Program ctivityl Budget Reference # moun .. ID ID Year ChartPield 2 CERTIFICATIONS: Logname: 21PARD CONSOLIDATED SERVICE CENTER CMAR SERVICES Page 3 of 4 Jay Chapa (5804) Originating Department Head: Steve Cooke (5118) Additional Information Contact: Brian Glass (8088) ATTACHMENTS 1. Form 1295 Byrne.pdf (Public) 2. Greenbriar Park Location Map.pdf (Public) 3. SAM Byrne Construction Services.pdf (CMInternal) 4. Thomas S. Byrne - New PARD Center-Compliance Memo.pdf (CMInternal) r r r r Logname: 21PARD CONSOLIDATED SERVICE CENTER CMAR SERVICES Page 4 of 4 NOTICE TO CONSTRUCTION MANAGER-AT-RISK(CMAR) OFFERORS Proposals from Construction Manager-at-Risk (CMAR) Offerors for the PARD Service Center Project located at 5199 James Avenue, Fort Worth, Texas will be received at the Purchasing Office, City of Fort Worth, 200 Texas Street, Fort Worth, 76102, until 1:30 P.M on Thursday, July 13, 2017, and will be opened and the names of the CMAR firms will be publicly read aloud approximately thirty minutes later in the Council Chambers. A Pre-Proposal Conference will be held at 1:00 P.M., Thursday, June 29, 2017 at the Architectural Services Conference Room, 401 West 13th Street, Fort Worth, 76102. _ The last day for questions from prospective Offerors is at 5:00 PM on Friday,July 7, 2017. The City will select the CMAR Contractor by using a two-step Request for Proposal (RFP) process. After evaluating the submitted Proposals from the CMAR Offerors, the City will shortlist and interview up to three Offerors. The City will then select and enter into negotiations with the Best Value Offeror. The City may discuss with the selected Offeror, options for a scope or time modification and any price change associated with such modification. The selected CMAR Contractor will provide Pre-Construction Services including Constructability Reviews, Value Engineering Recommendations and Estimating Services Fees to review during the _ various phases of the design process. Once the construction documents are completed, the selected CMAR Contractor will provide a Guaranteed Maximum Price (GMP) and construction performance period for each of the three major portions of the work and all work combined. This GMP will be inclusive of Value Engineering and Estimating Services fees, General Conditions, Construction Manager's Fee, contingency, bonds, insurance, and other agreed upon costs; plus the .City's General Contingency Allowance. The total construction cost is anticipated to be approximately $7,500,000.00, refer to the attached "Project Proposal Form". The City of Fort Worth will negotiate a Pre-Construction Services Contract and later negotiate a Construction Services Contract with the selected CMAR firm determined to have made the Best Value offer. Refer to the"Project Proposal Form". Refer to the Request for Proposal documents for the Minority Business Enterprise (MBE) Information. MBE participation will be evaluated in awarding this contract. The MBE participation goal is 17% for the — estimated construction budgets. The goal will be applied to the GMPs (and fees) when the GMP agreements are reached. Offerors must submit an anticipated MBE Utilization Plan with their CMAR Proposal submittal. The submitted Plan' will be part of'the weighted selection criteria. Refer to _ Instructions to Construction Manager-at-Risk (CMAR) Offerors for additional information. Contact the MW/BE Office at(817)212-2674 to obtain a list of certified subcontractors and suppliers. Also, Refer to Section 3. BUSINESS DIVERSITY ENTERPRISE (BDE) ORDINANCE PROVISION in the Instructions to Construction Manager-at-Risk(CMAR) Offerors. Upon completing the negotiations with the selected CMAR firm, the City will recommend to the City Council to award the CMAR contract to the selected CMAR firm based on the negotiations and the agreed upon estimated construction budgets for each of the three major tasks. The CMAR contract will be adjusted based on the agreed upon Guaranteed Maximum Price (GMP) after the design is completed. PARD Service Center Project, Page 2 of 58 Byrne CMAR Construction Contract June 2018 The selected CMAR Contractor will be required to provide Payment and Performance Bonds and provide Contractors General Liability and Statutory Workers Compensation Coverage once the T GMP is agreed upon. CMAR Offerors may access the.Instructions to Offerors, any Addendum, Sample Contract, General — Conditions, Site Plans and other Reference Drawings, and any other related documents through the City's Buzzsaw website by cutting and pasting the following link in a web browser: https://promectpoint.buzzsaw.com/fortworthgov/PMD%20Promects/PARD%20Service%2OCenter?public Contact the Project Manager, Ronald Clements, at (817) 392-8014 or email Ronald.Clementsa-fortworthtexas.gov for assistance. Advertisement: June 15, 2017 June 22, 2017 �- PARD Service Center Project Page 3 of 58 .� Byrne CMAR Construction Contract June 2018 TABLE OF CONTENTS • NOTICE TO CONSTRUCTION MANAGER-AT-RISK(CMAR) OFFERORS • TABLE OF CONTENTS • PROJECT LOCATION MAP,AREA MAP, PHASE I SITE PLAN (FOR REFERENCE ONLY)AND MASTER SITE PLAN (FOR REFERENCE ONLY) • INSTRUCTIONS TO CONSTRUCTION MANAGER-AT-RISK(CMAR)OFFERORS • PROPOSAL FORM • CONFLICT OF INTEREST AFFIDAVIT • CONFLICT OF INTEREST QUESTIONAIRE(CIQ) • CONFLICT DISCLOSURE STATEMENT (CIS) • TEXAS SALES AND USE TAX EXEMPTION CERTIFICATE • 2013 PREVAILING WAGE RATES • WEATHER TABLE • CMAR CONSTRUCTION CONTRACT • GENERAL CONDITIONS FOR CMAR CONSTRUCTION ' 0 PAYMENT BOND • PERFORMANCE BOND • CERTIFICATE OF INSURANCE • CONTRACTOR COMPLIANCE WITH WORKERS' COMPENSATION LAW • PROJECT SIGN PARD Service Center Project Page 4 of 58 Byrne CMAR Construction Contract June 2018 ON (V C7 N = �- LL ��r CD { N LLL - vl; p LO j: _Q) Q LL CD .v �} }, 0 U U C Cl) ca N t. 01 1 �.. Y U } coo N� r`. O "' COD Sf18 AZ•� --�-- "� Ky MCJL A r O Ai C CD �, J J a Z Z �. N � � INSTRUCTIONS TO CONSTRUCTION MANAGER-AT-RISK (CMAR) OFFERORS 1. PROPOSAL REQUIREMENTS: The following requirements shall be used in the preparation of the response to this Request for Proposals(RFP): • Use the Proposal Form provided in this RFP document. • Entries on the Proposal Form may be handwritten or typed. • Acknowledge all addenda on the Proposal Form. • Have a Principal sign the Proposal. If the Offeror is a corporation, the president or a vice- president must sign the Proposal. If the Offeror is a partnership, then the person/entity who is the managing/general partner must sign the proposal. • Complete and submit the Conflict of Interest Affidavit form. (Also submit associated Form CIQ { and Form CIS if required.) • Cashier's check or an acceptable bidder's bond IS NOT REQUIRED for this Request for Proposals. 2. SELECTION OF CMAR CONTRACTOR: The City shall select the Offeror that offers the best value based upon the below criteria and ranking evaluation. In determining the Best Value Offeror, the City will consider: A. Proposed Fees and Expenses (55%) (Refer to Proposal form). B. Proposed MBE Goal and Utilization Plan (10%). C. References and Experience in Executing CMAR Projects and Similar Type Projects (25%) ' - References and experience of the Offeror, Project Manager, and Superintendent as demonstrated by listing recently completed and current, "vertical" facilities, CMAR projects, including references with names, positions, company names, and current telephone numbers; and list of subcontractors. D. Past relationship with the City (10%) — Offeror's past relationship with the City of Fort Worth for"vertical" facilities projects shall receive up to 10 points for this rating criteria. If the Offeror does not have a past relationship with the City of Fort Worth, the Offeror will receive 5 points for this rating criteria. After ranking the responses to the RFP, the City shall first attempt to negotiate a contract with the selected Offeror. The City and its architect may discuss with the selected Offeror options for a scope modification and any price change associated with the modification. If the City is unable to negotiate a contract with the selected Offeror, the City shall, formally and in writing, end negotiations with that Offeror and proceed to the next Offeror in the order of the selection ranking until a contract is reached or all proposals are rejected. PARD Service Center Project Page 5 of 58 Byrne CMAR Construction Contract June 2018 3. BUSINESS DIVERSITY ENTERPRISE (BDE) ORDINANCE PROVISION A. The City of Fort Worth implemented the Business Diversity Enterprise Ordinance to reflect the City's availability and disparity study findings. All proposers shall note that it is the policy of the City to ensure the full and equitable participation of Minority Business Enterprises (MBEs) in the R procurement of goods and services. If the total dollar value of the contract is greater than $50,000, then an MBE subcontracting goal may be applicable. There is no MBE diverse goal for Pre-Construction Phase Services on this solicitation. The MBE.diverse goal is 17%for Construction Phase Services (subcontractors, suppliers, etc.) Byrne Construction Services has committed to a Goal of 30%. B. If the Proposer self-performs Construction Phase Services as the general contractor, the MBE goal must be met. No exceptions. C. Proposers must obtain MBE listings from the City of Fort Worth's M/WBE Office at (817) 212- 2674 or email mwbeoffice(a)fortworthtexas.gov. This will ensure that CMAR firms are = acknowledging MBEs (which include DBE firms that are minority owned, controlled and daily managed) currently certified by the North Central Texas Regional Certification Agency(NCTRCA) or other certifying agencies that the City may deem appropriate and accepted by the City of Fort Worth at the time proposals/bids are submitted, in order for the participation to be counted = towards the established diverse goals. The firms must be located in the City's six (6) county geographic marketplace that includes the counties of: Tarrant, Dallas, Denton, Johnson, Parker and Wise. D. At the time the.Guaranteed Maximum Price (GMP) is due and submitted to the City, it shall be accompanied by the MBE Utilization Plan to address the diverse MBE goals for use when proposals/bids are sought from trade contractors or subcontractors for performance of all major elements of the Work. At a minimum, the Plan must provide: • the company name, address, point of contact, email address, office and fax telephone numbers of the MBE subcontractors and suppliers; ■ a detailed description of the work to be performed by each MBE; ■ the tier level, i.e., 1s', 2"d, 3"d, etc. (if other than 1s' tier, the plan must clearly identify the firm name and tier from whom the MBE firm will be receiving payment); ■ the sub-contract value or percentage of the GMP construction cost for each phase of work identified for each MBE participant; ■ state the MBE percentage level of commitment achieved; ■ the timing of the major elements of the work including approximate advertising dates and ■ provide the same identification information for all non-MBE participants = The Plan must also include an element detailing how the Proposer will communicate with, and report Plan compliance to, the City's Project Manager and the City's MWBE Office during the Project including providing to the MWBE Office Letter(s) of intent, purchase orders and or executed sub-contract agreements after award by the CMAR and prior to the issuance of the notice to proceed of each relevant phase of the Work. E. MBE firms must be certified at the time each of the Work's major.elements are bid or proposals submitted, in order for the participation to be counted towards the established goal. F. If a Proposer is certified as a DBE, MBE, SBE or WBE firm, the City's Ordinance does not allow a Proposer to count itself or its subsidiary-owned companies towards the established goals; the goals represent subcontracting opportunities. G. The participation commitment of the MBE Construction Phase Services will be part of the final weighted selection criteria. PARD Service Center Project Page 6 of 58 Byrne CMAR Construction Contract June 2018 H. Failure to address the diverse goals and state the MBE commitments shall render the Proposer non-responsive. .. For additional information contact the MWBE Office at(817)212-2674. 4. PROPOSAL SECURITY: This is NOT REQUIRED for this Request for Proposals. 5. PAYMENT BOND AND PERFORMANCE BOND: For projects in excess of$25,000 and when the Guaranteed Maximum Prices (GMPs) are agreed upon, the successful Offeror entering into a contract for the work will be required to give the City surety in a sum equal to the amount of the contract attributable to each phase. The form of the bond shall be as herein provided and the surety shall be acceptable to the City. All bonds furnished hereunder shall meet the requirements of Texas Government Code Section 2253, as amended. In order for a surety to be acceptable to the City, the surety must(1) hold a certificate of authority from the United States Secretary of the Treasury to qualify as a surety on obligations permitted or required under federal law; or(2) have obtained reinsurance for any liability in excess of$100,000 from a reinsurer that is authorized and admitted as a reinsurer in the State of Texas and is the holder of a certificate of authority from the United States Secretary of the Treasury to qualify as a surety on obligations permitted or required under federal law. Satisfactory proof of any such reinsurance shall be provided to the City upon request. The City, in its sole discretion, will determine the adequacy of the proof required herein. No sureties will be accepted by the City that are at the time in default or delinquent on any bonds or which are interested in any litigation against the City. Should any surety on the contract be determined unsatisfactory at any time by the City, notice will be given to the contractor to that effect and the contractor shall immediately provide a new surety satisfactory to the City. If the total contract price is $25,000 or less, payment to the contractor shall be made in one lump sum. Payment shall not be made for a period of 45 calendar days from the date the work has been completed and accepted by the City. If the contract is in excess of$25,000, a Payment Bond shall be executed, in the amount of the contract, solely for the protection of all claimants supplying labor and materials in the prosecution of the work. If the contract amount is in excess of$100,000, a Performance Bond shall also be provided, in the amount of the contract, conditioned on the faithful performance of the work in accordance with the plans, specification, and contract documents. Said bond shall be solely for the protection of the City of Fort Worth. 6. PRE-PROPOSAL SITE INVESTIGATION: Prior to filing a response, the Offeror shall examine the site(s) of the work and the details of the requirements set out in these specifications to satisfy itself as to the conditions which will be encountered relating to the character,-quality, and quantity of the work to be performed and materials and equipment required. The filing of a response by the Offeror shall be considered evidence that it has complied with these requirements. 7. WAGE RATES: Not less than the prevailing wage rates set forth in Contract Documents must be paid on this project. 8. CMAR OFFERORS SUBMITTALS: With their Request for Proposal submittal, Offerors are required to submit the following additional information to the Purchasing Office, 200 Texas Street, Fort Worth, Texas 76102 in order to assist City staff in determining the Contractor's capability of performing the work and in meeting City contract requirements: • Contractor's CMAR Qualification Statement (AIA Form A305 or equivalent form), including client references �. PARD Service Center Project Page 7 of 58 Byrne CMAR Construction Contract June 2018 • List of any Proposed Specialist or Subcontractors required for Pre-Construction Services • Proof of insurability for Statutory Workers Compensation Insurance • Conflict of Interest Affidavit The Offerors Minority Business Enterprise (MBE) Utilization Plan Documentation will be required prior to and evaluated as part of the Interview Phase. Refer to Paragraph 2 (Selection of CMAR Contractor) and Paragraph 3 (Business Diversity Enterprise) for additional information on these submittals. 9. PROPOSED SUBCONTRACTORS: Acceptance of the Proposal in no way requires the City to accept the qualifications of the subcontractors. The Subcontractor lists are for use by the City in preparing recommendations for award of the contract. The Contractor must provide and use subcontractors listed unless the City agrees to allow a substitute. 10. DISCREPANCIES AND ADDENDA: Should an Offeror find any discrepancies in the Request for Proposals Documents, or should it be in doubt as to their meaning, it shall notify the City at once. If required, the City will then prepare a written addendum that will be available to all Offerors at the place designated for distribution of the Request for Proposal Documents by the Notice to Offerors. The Contractor is responsible for determining if addenda are available and for securing copies prior to submitting a response to this request for sealed Proposals. Oral instructions or decisions unless confirmed by written addenda will not be considered valid, legal or binding. No extras will be authorized because of failure of the contractor to include work called for in the addenda. Offeror must acknowledge addenda in the Proposal. Failure to acknowledge addenda may cause the Proposal to be ruled non-responsive. It is the Contractor's responsibility to obtain Addenda and include its information in the Proposal. 11. WORKERS COMPENSATION INSURANCE: Offerors will be required to demonstrate that coverage is in effect at time of the agreed upon Final Guaranteed Maximum Prices (FGMPs) for — Phases I and II. Sample Certificate of Insurance, or other proof that Workers Compensation Insurance will be obtained, must be submitted within five working days of agreed upon FGMP. 12. TAXES: Equipment and materials not consumed by or incorporated into the work are subject to State sales taxes under House Bill 11, enacted August 15, 1991. 13. PERMITS: Contractor shall apply for all City of Fort Worth Permits and for any other permits required by this project. City of Fort Worth Building and Trade Permit fees are waived. Separate permits may be required for each work location. 14. UTILITIES AND IMPACT FEES: The City will pay water and sewer utilities tap fees and impact fees. Unless shown otherwise, the City will coordinate and pay for water and sewer taps and meters to the property line. The Contractor will include all remaining fees from the electrical and gas companies in the Base Proposal. The Contractor will be responsible for coordinating with City and utility companies for installation of utilities. The Contractor will be responsible for all fees for electrical, gas, and other utilities within the property line of the project. Unless indicated otherwise on the plans, the contractor will be responsible for costs and installations from the building side of — the water meter and sewer tap. 15. INSTRUCTIONS TO OFFERORS: Offerors may access the Instructions to Offerors, any Addendum, Sample Contract, General Conditions, Drawings, and any other related documents through the City's Buzzsaw website at the following link: https://Proiectpoint.buzzsaw.com/fortworthgov/PMD%20Projects/Como%20CMAR?public _ PARD Service Center Project Page 8 of 58 Byrne CMAR Construction Contract June 2018 16. TESTING SERVICES: The City shall provide for, independently of the contractor, the inspection services, the testing of construction materials engineering, and the verification testing services necessary for the acceptance of the construction work. 17. PROJECT SCHEDULE: The Project Schedule will be submitted with the Guaranteed Maximum Price (GMP) and at the minimum, include the following: quality control submittals and approvals mobilization, site preparation, under slab utilities, foundation work, structural erection, interior finish, commissioning, and closeout. 18. STATE FORM 1295 "CERTIFICATE OF INTERESTED PARTIES": Texas Ethics Commission regulations require that the business entity must fill out the Form 1295 on an electronic filing application on the Texas Ethics Commission website (www.ethics.state.tx.us). The business entity that wishes to enter into the contract must supply the completed, signed and notarized Form 1295 to the City. PARD Service Center Project Page 9 of 58 Byrne CMAR Construction Contract June 2018 PARD SERVICE CENTER PROJECT PROPOSALFORM T0: MR. DAVID COOKE CITY MANAGER ATTN: PURCHASING OFFICE 200 TEXAS STREET CITY OF FORT WORTH, TEXAS FOR: Construction Manager-at-Risk Agreement for the PARD Service Center Project Located at Greenbriar Park 5199 James Ave Fort Worth, Texas Project PMD 2017-08 — Pursuant to the foregoing "INSTRUCTIONS TO CONSTRUCTION MANAGER-AT-RISK (CMAR) _ OFFERORS", the undersigned understands the amount of work to be done for the Preconstruction Services and Construction Services, and hereby proposes to do all the work and furnish all labor, equipment and materials necessary to fully complete all the work as provided in the plans and specifications and subsequent agreed upon Guaranteed Maximum Prices (GMPs) and subject to the inspection and approval of the Director of Property Management Department of the City of Fort Worth. Upon acceptance of this Proposal by the City Council and upon subsequent agreement to the GMPs the _ Offeror, if the agreement amount exceeds $25,000.00, shall furnish acceptable Performance and Payment Bonds approved by the City of Fort Worth for performing and completing the Work within the time agreed to for the following sum, to wit: DESCRIPTIONS AND COSTS OF ITEMS IN CMAR AGREEMENT PRE-CONSTRUCTION SERVICES: including Constructability Reviews, Value Engineering Recommendations and Estimating Services Fees for: "PARD Service Center"—Including all associated Site Utilities &Civil Site Work: CONSTRUCTION SERVICES: Based on an estimated total budget of $7,500,000.00, your standard practice regarding project cost structure and your understanding of this project, complete the line items below. These items are included in the total not-to-exceed estimated construction budget for: "befined Fees"—Estimated Budget of$7,500,000.00 for all associated work. A) $ , % (% of Total Budget) Subcontractors Material Labor and Equipment(Lump Sum) B) $ % (% of Total Budget) General Condition Expenses(Attach description of items included) C) $ , % (%of Items A+B) Construction Management Fee (Attach description of items included) PARD Service Center Project Page 10 of 58 _ Byrne CMAR Construction Contract June 2018 _ D) $ % 7.5 (7.5% of Items A+B+C) 7.5%Owners Construction Contingency Allowance (Remaining Contingency allowance will be retained by the City) E) $ % (% of Items A+B+C+D) Anticipated Cost of Insurance and Bonds F) $ % -(% of Items A+B+C+D) Any other anticipated Costs (Attach description of items included) A Project Schedule will be mutually agreed at the time the Guaranteed Maximum Price is developed. The City reserves the right to accept or reject any and all bids or any combination thereof proposed for the above work. The undersigned assures that its employees and applicants for employment and those of any labor organization, subcontractors or employment agency in either furnishing or referring employee applicants to the undersigned are not discriminated against as prohibited by the terms of City Ordinance 7278 as amended by City Ordinance 7400 (Fort Worth City Code Section 13A-21 through 13A-29). Residency of Offerors: The 1985 Session of the Texas Legislature passed House Bill 620 relative to the award of contracts to non-resident bidders. The law provides that, in order to be awarded a contract as low bidder, non-resident bidders (out of state contractors whose corporate offices or principal place of business are outside of the State of Texas) that bid projects for construction, improvements, supplies or services in Texas at an amount lower than the lowest Texas resident bidder by the same amount that Texas resident bidder would be required to underbid a non-resident bidder in order to obtain a comparable contract in the state in which the non-resident's principal place of business is located. The appropriate blanks in Section A must be filled out by all non-resident bidders in order for your bid to meet specifications. The failure of out of state or non-resident bidders to complete the forms may disqualify that bidder. Resident bidders must check the box in Section B. A. 1_1 Non-resident vendors in (give state), our principal place of business, are required to be percent lower than resident bidders by state law. I_l Non-resident vendors in (give state), are not required to underbid resident bidders. B. �_� Our principal place of business or corporate offices are in the State of Texas. Approved Performance and Payment Bonds for the faithful performance of this contract will be required upon agreement of the Guaranteed Maximum Prices (GMPs) for Phases I and II. An acceptable bidder's bond or cashier's check is NOT REQUIRED with this Request for Proposal. PARD Service Center Project Page 11 of 58 Byrne CMAR Construction Contract June 2018 MINORITY BUSINESS ENTERPRISE (MBE): (For Proposals in excess of$50,000) 1 am aware that I must submit information concerning the Minority Business Enterprise (MBE) Utilization Plan with the submittal of this Proposal in order to be considered RESPONSIVE. I will commit to the City's — MBE goals for this project. Respectfully submitted, Company Name ' By. -- Signature — Printed Name of Principal Title — Address: Street City Zip Phone: Fax: Email: Receipt is acknowledged of the following addenda: Addendum No. 1: Addendum No. 2: Addendum No. 3: Addendum No. 4: Addendum No. 5: Addendum No. 6: r+ PARD Service Center Project Page 12 of 58 — Byrne CMAR Construction Contract June 2018 - CONFLICT OF INTEREST AFFIDAVIT Each bidder, offeror, or respondent (hereinafter also referred (o as 'you) to a City of Fort Worth(also referred to as"City) procurement are required to complete Conflict of Interest Questionnaire (the attached CIQ Form) and Local Government Officer Conflicts Disclosure Statement(the attached CIS Form)below pursuant to state law. This affidavit will certify that the Bidder has on file with the City Secretary the required documentation and is eligible to bid on City Work.The referenced forms may be downloaded from the website links provided below. htti)://www.ethics.state.tx.us/forms/CIQ.Pd hftp://www.athics.state.tx,us/forms/CIS.odf t A CIQ Form is on file with City Secretary 71 CIQ Form Is being provided to the City Secretary 1-71 CIS Form Is on File with City Secretary 71 CIS Form is being provided to the CitySecretary BIDDER: By:_ Company(Please Print) Signature: Address Title: City/State2ip (Please Print) Company:Thos.S.Byrne,Inc.dba Byrne Construction Services Submitted by:Matthew Avila,Chief Executive Officer Signature: Address:5S1 E.Berry Street City/State/Zip:Fort Worth,Texas 76110 PARD Service Center Project Page 13 of 58 Byrne CMAR Construction Contract June 2018 CONFLICT OF INTEREST QUESTIONNAIRE FORM CIO i? For vendor doing business with local governmental entity This questionnaire reflects changes made to the law by H.B. 23, 84th Leg., Regular Session. OFFiCELISEONLY This questionnaire is being filed in accordance with Chapter 176,Local Government Code,by a vendor who Date Received has a business relationship as defined by Section 176.001(1-a) with a local governmental entity and the vendor meets requirements under Section 176.006(a). By law this questionnaire must be filed with the records administrator of the local governmental entity not later than the 7th business day after the date the vendor becomes aware of facts that require the statement to be filed. See Section 176.006(a-1),Local Government Code. A vendor commits an offense if the vendor knowingly violates Section 176.006,Local Government Code. An offense under this section Is a misdemeanor. !J Name of vendor who has a business relationship with local governmental entity. 2 Check this box if you are filing an update to a previously filed questionnaire.(The law requires that you file an updated j completed questionnaire with the appropriate filing authority not later than the 7th business day after the date on which you became aware that the originally filed questionnaire was incomplete or Inaccurate.) I 3 Name of local government officer about whom the Information is beirig disclosed. N/A € Name of Officer i Describe each employment or other business relationship with the local government officer,or a family member of the officer,as described by Section 176.003(a)(2)(A). Also describe any family relationship with the local government officer. Complete subparts A and B for each employment or business relationship described. Attach additional pages to this Form CIQ as necessary. A. is the local government officer or a family member of the officer receiving or likely to receive taxable income, other than investment income,from the vendor? ` Yes F-1 No t B. Is the vendor receiving or likely to receive taxable Income,other than investment income,from or at the direction of the local government officer or a family member of the officer AND the taxable income is not received from the local governmental entity? F-1 Yes F-1 No ' 5 Describe each employment orbusiness relationship that the vendor named in Section 1 maintains with a corporation or other business entity with respect to which the local government officer serves as an officer or director,or holds an ownership Interest of one percent or more. s ❑ Check this box if the vendor has given the local government officer or a family member of the officer one or more gifts as described in Section 176.003(a)(2)(B),excluding gifts described in Section 176.003(a-1). 7 7/12/2018 Signature of vendor doing business with the governmental entity Date PABtQiaaciitHgt�tiksjtics Commission www.ethics.state.ti.us Page 14 of 5811evised 11/30/2015 Byrne CMAR Construction Contract June 2018 Part 1 - CONFLICT OF INTEREST QUESTIONNAIRE For vendor doing business with local governmental entity A complete copy of Chapter 176 of the Local Government Code may be found at http://www.statutes.legis.state.tx.us/ Docs/LG/htm/LG.176.htm.For easy reference,below are some of the sections cited on this form. Local Government Code S 176.001(1-a):'Business relationship"means a connection between two or more parties based on commercial activity of one of the parties. The term does not include a connection based on: (A) a transaction that is subject to rate or fee regulation by a federal,state,or local governmental entity or an agency of a federal,state,or local governmental entity; (B) a transaction conducted at a price and subject to terms available to the public;or (C) a purchase or lease of goods or services from a person that is chartered by a state or federal agency and that is subject to regular examination by,and reporting to,that agency. .1 Local Government Code§176.003(a)(2)(A)and(B): (a) A local government officer shall file a conflicts disclosure statement with respect to a vendor if: (2) the vendor: (A) has an employment or other business relationship with the local government officer or a family member of the officer that results in the officer or family member receiving taxable income, other than investment income, that exceeds $2,500 during the 12- month period preceding the date that the officer becomes aware that (i) a contract between the local governmental entity and vendor has been executed;or (ii) the local governmental entity is considering entering into a contract with the vendor, (B) has given to the local government officer or a family member of the officer one or more gifts that have an aggregate value of more than$100 in the 12-month period preceding the date the officer becomes aware that: (i) a contract between the local governmental entity and vendor has been executed; or (ii) the local governmental entity is considering entering into a contract with the vendor. 1.2 Local Government Code§ 176.006(a) and (a-1) T (a) A vendor shall file a completed conflict of interest questionnaire if the vendor has a business relationship with a local governmental entity and: (1) has an employment or other business relationship with a local government officer of that local governmental entity,or a family member of the officer,described by Section 176.003(a)(2)(A); (2) has given a local government officer of that local governmental entity, or a family member of the officer,one or more gifts with the aggregate value specified by Section 176.003(a)(2)(B),excluding any gift described by Section 176.003(a-1);or (3) has a family relationship with a local government officer of that local governmental entity. (a-1) The completed conflict of interest questionnaire must be filed with the appropriate records administrator not later than the seventh business day after the later of: (1) the date that the vendor: (A) begins discussions or negotiations to enter into a contract with the local governmental entity; or (B) submits to the local governmental entity an application, response to a request for proposals or bids, correspondence, or another writing related to a potential contract with the local governmental entity;or (2) the date the vendor becomes aware: (A) of an employment or other business relationship with a local government officer, or a family member of the officer,described by Subsection(a); (B) that the vendor has given one or more gifts described by Subsection(a);or (C) of a family relationship with a local government officer. PARD Service Center Project Page 15 of 58 Byrne CMAR Construction Contract June 2018 LOCAL .GOVERNMENT OFFICER FORM CIS CONFLICTS DISCLOSURE STATEMENT _ (Instructions for completing and filing this form are provided on the next page.) This questionnaire reflects changes made to the law by H.B. 23, 84th Leg., Regular Session. OFFICE USEONLY This is the notice to the appropriate local governmental entity that the following local government officer has become aware of facts that require the officer to file this statement Date Received in accordance with Chapter 176,Local Government Code. 1 Name of Local Government Officer 2 Office Held 3 Name of vendor described by Sections 176.001(7)and 176.003(a), Local Government Code — 4 1 Description of the nature and extent of each employment or other business relationship and each family relationship with vendor named in item 3. 51 List gifts accepted by the local government officer and any family member, if aggregate value of the gifts accepted from vendor named in item 3 exceeds $100 during the 12-month period described by Section 176.003(a)(2)(B). Date Gift Accepted Description of Gift _ Date Gift Accepted Description of Gift Date Gift Accepted Description of Gift (attach additional forms as necessary) _ 6 AFFIDAVIT I swear under penalty of perjury that the above statement is true and correct. I acknowledge that the disclosure applies to each family member(as defined by Section 176.001(2), Local Government Code) of this local government officer. I also acknowledge that this statement covers the 12-month period described by Section 176.003(a)(2)(B),Local Government Code. i Signature of Local Government Officer AFFIX NOTARY STAMP / SEAL ABOVE Sworn to and subscribed before me,-by the said this the day of -20 to certify which,witness my hand and seal of office. w Signature of officer administering oath Printed name of officer administering oath Title of officer administering oath BW8"V&8r§rg4g9 WAdommission www.ethics.state.tx.us . June 2018 Revised 11/30/2015 LOCAL GOVERNMENT OFFICER CONFLICTS DISCLOSURE STATEMENT Section 176.003 of the Local Government Code requires certain local government officers to file this form. A "local government officer'is defined as a member of the governing body of a local governmental entity;a director,superintendent, administrator,president,or other person designated as the executive officer of a local governmental entity;or an agent of a local governmental entity who exercises discretion in the planning, recommending, selecting, or contracting of a vendor. This form is required to be filed with the records administrator of the local governmental entity not later than 5 p.m.on the seventh business day afterthe date on which the officer becomes aware of the facts that require the filing ofthis statement. A local government officer commits an offense if the officer knowingly violates Section 176.003,Local Government Code. An offense under this section is a misdemeanor. — Refer to chapter 176 of the Local Government Code for detailed information regarding the requirement to file this form. Part 2- INSTRUCTIONS FOR COMPLETING THIS FORM The following numbers correspond to the numbered boxes on the other side. 1. Name of Local Government Officer. Enter the name of the local government officer filing this statement. 2. Office Held. Enter the name of the office held by the local government officer filing this statement. 3.Name of vendor described by Sections 176.001(7) and 176.003(a), Local Government Code. Enter the name of the vendor described by Section 176.001(7), Local Government Code, if the vendor: a) has an employment or other business relationship with the local government officer or a family member of the officer as described by Section 176.003(a)(2)(A), Local Government Code; b)has given to the local government officer or a family member of the officer one or more gifts as described by Section 176.003(a)(2)(B),Local Government Code;or c)has a family relationship with the local government officer as defined by Section 176.001(2-a),Local Government Code. 4. Description of the nature and extent of each employment or other business relationship and each family relationship with vendor named in item 3. Describe the nature and extent of the employment or other business relationship the vendor has with the local government officer or a family member of the officer as described by Section 176.003(a)(2)(A),Local Government Code,and each family relationship the vendor has with the local government officer as defined by Section 176.001(2-a),Local Government Code. 5. List gifts accepted, if the aggregate value of the gifts accepted from vendor named in item 3 exceeds $100. List gifts accepted during the 12-month period (described by Section 176.003(a)(2)(B), Local Government Code)by the local government officer or family member of the officer from the vendor named in item 3 that in the aggregate exceed$100 in value. 6.Affidavit. Signature of local government officer. Local Government Code S 176.001(2-a): "Family relationship" means a relationship between a person and another person within the third degree by consanguinity or the second degree by affinity,as those terms are defined by Subchapter B,Chapter 573,Government Code. Part 3- Local Government Code S 176.003(a)(2)(A): (a) A local government officer shall file a conflicts disclosure statement with respect to a vendor if: (2) the vendor: (A) has an employment or other business relationship with the local government officer or a family member of the officer that results in the officer or family member receiving taxable income, other than investment income, that exceeds $2,500 during the 12-month period preceding the date that the officer becomes aware that: -� (i) a contract between the local governmental entity and vendor has been executed;or (ii) the local governmental entity is considering entering into a contract with the vendor. PARD Service Center Project Page 17 of 58 Byrne CMAR Construction Contract June 2018 TEXAS SALES AND USE TAX EXEMPTION CERTIFICATE Name of Purchaser, Firm or Agency: Cfir of Fort Worth,Texas Address(Street&Number, P.O. Box or Route Number): 1000 Throckmorton City,State,Zip Code: Fort Worth,Texas 76102 Telephone: (817)392-8360 I,the purchaser named above, claim an exemption from payment of sales and use taxes for the purchase of taxable items described below or on the attached order or invoice from: All vendors Description of the items to be purchased, or on the attached order or invoice: All items except motor vehicles as listed below Purchaser claims this exemption for the following reason: Governmental Entity I understand that I will be liable for payment of sales or use taxes which may become due for failure to comply with the provisions of the state, city,and/or metropolitan transit authority sales and use tax laws and comptroller rules regarding exempt purchases. Liability for the tax will be determined by the price paid for the taxable items purchased or the fair market rental value for the period of time used. _ I understand that it is a misdemeanor to give an exemption certificate to the seller for taxable items which I know,at the time of purchase,will be used in a manner other than expressed in this certificate and that upon conviction I may be fined not more than$500 per offense. Purchaser: Title: Purchasinq Manager Date: February 1,2007 Note:This certificate cannot be issued for the purchase, lease or rental of a motor vehicle. THIS CERTIFICATE DOES NOT REQUIRE A NUMBER TO BE VALID Sales and Use Tax"Exemption Numbers"or"Tax Exempt"Numbers do not exist. — This certificate should be furnished to the supplier. Do not send the completed certificate to the Comptroller of Public Accounts. k . r. PARD Service Center Project Page 18 of 58 Byrne CMAR Construction Contract June 2018 .� 2013 PREVAILING WAGE RATES Commercial Construction Projects CLASSIFICATION • AC Mechanic $ 25.24 AC Mechanic Helper 13.67 Acoustical Ceiling Installer 16.83 Acoustical Ceiling Installer Helper $ 12.70 Bricklayer/Stone Mason $ 19.45 i Bricklayer/Stone Mason Trainee $ 13.31 Bricklayer/Stone Mason Helper $ 10.91 Carpenter $ 17.75 MR Carpenter Helper $ 14.32 Concrete Cutter/Sawer $ 17.00 Concrete Cutter/Sawer Helper 11.00 Concrete Finisher $ on 15.77 Concrete Finisher Helper $ 11.00 Concrete Form Builder $ 15.27 Concrete Form Builder Helper $ 11.00 Drywall Mechanic $ 15.36 MR Drywall Helper $ 12.54 Drywall Taper $ 15.00 Drywall Taper Helper $ 11.50 Electrician(Journeyman) $ 19.63 Electrician Apprentice(Helper) $ 15.64 Electronic Technician $ 20.00 Floor Layer $ 18.00 Floor.Layer Helper $ PARD Service Center Project Page 19 of 58 ;. Byrne CMAR Construction Contract June 2018 10.00 Glazier $ 21.03 Glazier Helper $ 12.81 Insulator $ 16.59 Insulator Helper $ 11.21 Laborer Common $ 10.89 Laborer Skilled $ 14.15 Lather $ 12.99 Metal Building Assembler 16.00 Metal Building Assembler Helper 12.00 Metal Installer(Miscellaneous) 13.00 Metal Installer Helper(Miscellaneous) $ 11.00 Metal Stud Framer 16$12 r.. Metal Stud Framer Helper $ 12.54 Painter $ — 16.44 Painter Helper $ 9.98 Pipefitter $ 21.22 Pipefitter Helper $ — 15.39 Plasterer $ 16.17 Plasterer Helper •$ 12.85 Plumber $ • 21.98 Plumber Helper $ 15.85 Reinforcing Steel Setter 12.87 Reinforcing Steel Setter Helper 11.08 _ Roofer $ 16.90 Roofer Helper $ — 11.15 Sheet Metal Worker $ 16.35 Sheet Metal Worker Helper $ �. PARD Service Center Project Page 20 of 58 Byrne CMAR Construction Contract June 2018 — 13.11 # Sprinkler System Installer $ 19.17. .. Sprinkler System Installer Helper $ 14.15 Steel Worker Structural 17.00 Steel Worker Structural Helper 13.74 Waterproofer $ 15.00 Equipment Operators Concrete Pump $ 18.50 Crane,Clamshell,Backhoe, Derrick, Mine Shovel $ 19.31 — Forklift $ 16.45 Foundation Drill Operator $ 22.50 Front End Loader $ 16.97 Truck Driver $ 16.77 Welder $ _ .19.96 Welder Helper $ 13.00 The prevailing wage rates shown for Commercial construction projects were based on a salary survey conducted and published by the North Texas Construction Industry(Fall 2012)Independently compiled by the Lane Gorman Trubitt,PLLC Construction Group. The descriptions for the classifications listed are provided on the TEXO's(The Construction Association)website. www.texoassociation.org/Chapter/wagerates.asp PARD Service Center Project Page 21 of 58 Byrne CMAR Construction Contract June 2018 CITY OF FORT WORTH WEATHER TABLE Average Days Month of Inches of Rainfall Rain/Snow/Ice nary 6 2.51 Februa 7 2.23 March 9 3.49 ril 7 2.97 May 10 4.56 une 8 3.31 ly 4 1.83 ugust 5 1.88 ptember 5 234 October 7 3.65 LE vember 7 2.70 cember 6 2.34 nually 81 33.81 (1)Mean number of days precipkation of 0.01'or more or 117 snowlice (2)Average normal precipitation,in inches This table is based on information reported from Dallas-Fort Worth International Airport, Texas.Latitude 32 deg 54 min north,longitude 97 deg 02 mm west,elevation(ground)551 tt Average number of days of rain,snow,and ice days are based on records covering 21 years_ Precipitation is based on recorded infatuation from 1996 through 2016 period. This table is to be used as a baisis for calculation of excess rain or weather days for projects with duration in calendar days.If the site records indicate that the Contractor was unable to carry out operations due to weather,it is counted as a weather day.If the number of weather days exceeds the number of average rain days plus the snowlice days for the contract duration,the contract will be adjusted by Change Order. - Fort Worth Weather Table 24 April 2017 PARD Service Center Project Page 22 of 58 Byrne CMAR Construction Contract June 2018 CONSTRUCTION CONTRACT FOR CONSTRUCTION MANAGER AT RISK(CMAR) This AGREEMENT is between the City of Fort Worth, a Texas home-rule municipality(the "CITY"), and Thomas S. Byrne, Inc. d/b/a/ Byrne Construction Services of the City of Fort Worth, County of Tarrant, State of Texas, hereinafter called CONTRACTOR. AGREEMENT DOCUMENTS: The Agreement documents shall include the following: 1. This CMAR Construction Contract; 2. Exhibit A-1, Dated Jun 20, 2018 3. Drawings and Specification prepared by Quorum Architects, Inc. Dated April 6, 2018. WITNESSETH: That for and in consideration of the payments and agreements hereinafter mentioned to be made and performed by the Owner, and under the conditions expressed in the bond bearing even date herewith, the said Contractor hereby agrees with the said Owner to commence and complete the construction of certain improvements described as follows: City of Fort Worth PARD Service Center Project Greenbriar Park 5199 James Ave Fort Worth, Texas PMD2017-08 City Project#101010 That the work herein contemplated shall consist of furnishing as an independent contractor all labor, tools, appliances and materials necessary for the construction and completion of said project in accordance with the Plans and Specifications and Contract Documents adopted by the City Council of the City of Fort Worth, which Pians and Specifications and Contract Documents are hereto attached and made a part of this contract the same as if written herein. The Contractor hereby agrees and binds himself to commence the construction of said work within ten (10)days after being notified in writing to do so by the Owner. City agrees and binds itself to pay, and the said Contractor agrees to receive, for all of the aforesaid work, and for stated additions thereto or deductions there from, the fixed stipulated sum shown on the Pricing Proposal, Exhibit A-1, dated June 20, 2018 submitted by the successful bidder hereto attached and made a part hereof. Payment will be made in monthly installments upon actual work completed by contractor and accepted by the Owner and receipt of invoice from the Contractor. The agreed upon total contract amount, as shown in the Pricing Proposal is $7,798,644.00 which includes the City's General Contingency Allowance in the amount of$544,091.00 for use by the OWNER only and any Allowance remaining at the end of construction will be retained by the OWNER. The performance periods in calendars for each phase will be determined when the Guaranteed Maximum Price is agreed upon for each phase. PARD Service Center Project Page 23 of 58 Byrne CMAR Construction Contract June 2018 INSURANCE REQUIREMENTS: All insurance and bonds will be required once the Guaranteed Maximum Price for all phases are agreed T upon. The Contractor shall not commence work under this contract until it has obtained all insurance -' required under the Contract Documents, and the Owner has approved such insurance. The Contractor shall be responsible for delivering to the Owner the sub-contractors' certificates of insurance for approval. The Contractor shall indicate on its certificate of insurance included in the — documents for execution whether or not its insurance covers subcontractors. It is the intention of the Owner that the insurance coverage required herein shall include the coverage of all subcontractors. a. WORKER'S COMPENSATION INSURANCE: • Statutory limits. — • Employer's liability: • $100,000 disease each employee. • $500,000 disease policy limit. • $100,000 each accident. b. COMMERCIAL GENERAL LIABILITY INSURANCE: The Contractor shall procure and shall maintain during the life of this contract public liability insurance coverage in the form of a Commercial General Liability insurance policy to cover bodily injury, including death, and property damage at the following limits: — $1,000,000 each occurrence and $2,000,000 aggregate limit. • The insurance shall be provided on a project specific basis and shall be endorsed accordingly. -� • The insurance shall include, but not be limited to, contingent liability for independent contractors, XCU coverage, and contractual liability. �. C. BUSINESS AUTOMOBILE LIABILITY: • $1,000,000 each accident. — • The policy shall cover any auto used in the course of the project. d. BUILDER'S RISK OR INSTALLATION FLOATER: — This insurance shall be applicable according to the property risks associated with the project and commensurate with the contractual obligations specified in the contract documents. — e. EXCESS LIABILITY UMBRELLA: • $1,000,000 each occurrence; $2,000,000 aggregate limit. — • This insurance shall provide excess coverage over each line of liability insurance required herein. The policy shall follow the form(s)of the underlying policies. f. SCOPE OF INSURANCE AND SPECIAL HAZARD: The insurance required under the above paragraphs shall provide adequate protection for the Contractor and its subcontractors, respectively, against damage claims which may arise from operations under this contract, whether such operations be by the insured or by anyone directly or indirectly employed by it, against any insurable hazards which may be encountered in the performance of the Contract. — PARD Service Center Project Page 24 of 58 Byrne CMAR Construction Contract June 2018 g. PROOF OF CARRIAGE OF INSURANCE: The Contractor shall furnish the owner with satisfactory proof of coverage by insurance required in these Contract Documents in the amounts and by insurance carriers satisfactory to the Owner. The form to be used shall be the current Accord certificate of insurance form or such other form as the Owner may in its sole discretion deem acceptable. All insurance requirements made upon the Contractor shall apply to the sub- contractors, should the Contractor's insurance not cover the subcontractor's work operations performed in the course of this contracted project. ADDITIONAL INSURANCE REQUIREMENTS: a. The Owner, its officers, employees and servants shall be endorsed as an additional insured on Contractor's insurance policies excepting employer's liability insurance coverage under Contractor's workers'compensation insurance policy. b. Certificates of insurance shall be delivered to the City of Fort Worth, contract administrator in the respective department as specified in the bid documents, 200 Texas Street, Fort Worth, TX 76102, prior to commencement of work on the contracted project. C. Any failure on part of the Owner to request required insurance documentation shall not constitute a waiver of the insurance requirements specified herein. d. Each insurance policy shall be endorsed to provide the Owner a minimum thirty day's notice of cancellation, non-renewal, and/or material change in policy terms or coverage. A ten days' notice shall be acceptable in the event of non-payment of premium. e. Insurers must be authorized to do business in the State of Texas and have a current A.M. Best rating of A-VII or equivalent measure of financial strength and solvency. f. Deductible limits, or self-funded retention limits, on each policy must not exceed $10,000.00 per occurrence unless otherwise approved by the Owner. g. In lieu of traditional insurance, Owner may consider alternative coverage or risk treatment measures through insurance pools or risk retention groups. The Owner must approve in writing any alternative coverage. h. Workers' compensation insurance policy(s) covering employees employed on the project shall be endorsed with a waiver of subrogation providing rights of recovery in favor of the Owner. i. Owner shall not be responsible for the direct payment of insurance premium costs for contractor's insurance. j. Contractor's insurance policies shall each be endorsed to provide that such insurance is primary protection and any self-funded or commercial coverage maintained by Owner shall not be called upon to contribute to loss recovery. k. In the course of the project, Contractor shall report, in a timely manner, to Owner's officially designated contract administrator any known loss occurrence which could give rise to a liability claim or lawsuit or which could result in a property loss. I. Contractor's liability shall not be limited to the specified amounts of insurance — required herein. PARD Service Center Project Page 25 of 58 Byrne CMAR Construction Contract June 2018 M. Upon the request of Owner, Contractor shall provide complete copies of all insurance policies required by these contract documents. .� If this Contract is in excess of$25,000, the Contractor shall provide a Payment Bond in the full amount of the contract. If the contract is in excess of $100,000 Contractor shall provide both Payment and Performance Bonds for the full amount of the contract. When the Guaranteed Maximum Prices (GMPs) for Phases I and II are agreed upon, the successful Offeror entering into a contract for the work will be required to give the City surety in a sum equal to the amount of the contract attributable to each phase. The form of the bond shall be as herein provided and the surety shall be acceptable to the City. All bonds furnished hereunder shall meet the requirements of Texas Government Code Section 2253, as amended. Contractor shall apply for all City of Fort Worth Permits and for any other permits required by this project. City of Fort Worth Permit fees are waived. Separate permits will be required for each facility. If the Contractor should fail to complete the work as set forth in the Plans and Specifications and Contract Documents within the time so stipulated, plus any additional time allowed as provided in the General Conditions, there shall be deducted from any monies due or which may thereafter become due him, the liquidated damages outlined in the General Conditions, not as a penalty but as liquidated damages, the Contractor and his Surety shall be liable to the Owner for such deficiency. IMMIGRATION NATIONALITY ACT: City actively supports the Immigration & Nationality Act (INA) which _ includes provisions addressing employment eligibility, employment verification, and nondiscrimination. Vendor shall verify the identity and employment eligibility of all employees who perform work under this Agreement. Vendor shall complete the Employment Eligibility Verification Form (1-9), maintain photocopies of all supporting employment eligibility and identity documentation for all employees, and upon request, provide City with copies of all 1-9 forms and supporting eligibility documentation for each employee who performs work under this Agreement. Vendor shall establish appropriate procedures and controls so that no services will be performed by any employee who is not legally eligible to perform such services. Vendor shall provide City with a certification letter that it has complied with the verification requirements required by this Agreement. Vendor shall indemnify City from any penalties or liabilities due to violations of this provision. City shall have the right to immediately terminate this Agreement for violations of this provision _ by Vendor. PARD Service Center Project Page 26 of 58 Byrne CMAR Construction Contract June 2018 _ IN WITNESS WHEREOF, the City of Fort Worth has caused this instrument to be signed in four counterparts in its name and on its behalf by the City Manager and attested by its Secretary, with the corporate seal of the City of Fort Worth attached. The Contractor has executed this instrument through its duly authorized officers in Four counterparts with its corporate seal attached. Done in Fort Worth, Texas, this thec)/ day of A.D., 2018. Thomas S. Byrne, Inc. ���11111111111111,�'y d/b/a/ e Construe ices APPROVED: CITY OF ORT WORTH By: By: Pa Avila = Q o g Jesus J. Chapa Senior Vice Preside �� •'' Assistant City Manager 1111 �pF.F.....RT� p _ APPROV EC MMEND D: RECORDED: r By. By. >� !� Steve 4oke Mary J. Kay vy Director, Property Management Dept. City Secretary XAS APPROVED S M AND LEGALITY: M&C: C-28518 (December 12, 2017) Contract Authorization � By: �Rrl1 �2�C1"C'l ohn B. Strong Assistant City /orney T OFFICIAL.RECORD CITY 81CRNTARY -- FT.WORTH,TX CONTRACT COMPLIANCE MANAGER:By signing 1 acknowledge that I am the person responsible for the monitoring and administration of this contract,including ensuring all performance and reporting requirements. By: + A. C Brian R.Glass,AIA Architectural Services Manager PARD Service Center Project Page 27 of 58 Byrne CMAR Construction Contract June 2018 EXHIBIT A-� NINE DECADES OF EXCELLENCE BYRN551 E.Berry Street Fort Worth,Teras 76110 CONSTRUCTION SERVICES Phone @M 3353394 Fu @17)877-5507 Cost Estimate Summary Sheet Fort Worth Park&Recreation Department-Consolidated Service Center 100%CD Pricing Proposal(With No Accepted Alternates) Date:June 20,2018 Building S uare Feet: 37,913 R�'k'Y'4 Bid Package Description cool C.stJSF % $ Notes 011000 General Conditions $ 433,276 $ 11.43 $ 015000 Temporary Construction $ 128,561 $ 3.39 $ 020000 Demolition&Abatement None Shown $ 033000 Concrete $ 1,585,062 $ 41.81 10% $ 158,506 Partial Pier Casing Allowance $ 25,000 033536 Concrete Floor Finish $ 41,569 $ 1.10 $ 048100 Masan $ 167,017 $ 4.41 40% $ 66,807 051000 Miscellaneous Steel 1$ 81,000 $ 2.14 J $ 061000 Rough Carpentry $ 46,954 $ 1.24 ,Q% .$ Plywood Decking @ Ice&Water Shield $ 27,861 $ 0.73 0% $ 064000 Architectural Woodwork $ 16,066 $ 0.42 $ 071000 Waterproofing&Sealants $ 94,031 $ 2.48 ON $ Ice&Water Shield $ 28,068 $ 0.74 0%-$ 072129 Spray Foam Insulation $ 30,391 $ 0.80 t 0°.6 $ 074000 Metal Panels In BP-133000 PEMB $ 075000 Roofing Systems In BP-133000 PEMB $ 078000 Spray-Applied Fireproofing None Shown $ 081000 Doors,Doorframes,Hardware $ 61,546 $ 1.62 0,% $ 083616 VerticalOpening Doors $ 30,888 $ 0.81 0% $ 084000 lGlass&Glazing Systems $ 49,215 $ 1.30 $ �. 086223 Solatube Skylights $ 33,472 $ 0.88 $ 092000 Drywall&Acoustical Systems $ 329,972 $ 8.70 80% $ 263,978 093000 Tile $ 15,677 $ 0.41 $ 096500 Flooring&Wall Base $ 4,652 $ 0.12 $ 099000 Paint&Wall Coverings $ 97,877 $ 2.58 100°x6 $ 97,877 101000 Specialty Items $ 33,027 $ 0.87 100% $ 33,027 101000 Wire Mesh Partitions $ 13,150 $ 0.35 0% $ 104000 Si na e&Graphics $ 9,987 $ 0.26 $ 110000 E ui ment $ 16,700 $ 0.44 0% $ 114000 linstall Residential Appliances In Above $ Furnished By Omer 122400 lWindow Treatments I$ 1,672 $ 0.04 $ 129313 Bike Racks in Equipment 133418 Pre-Engineered Metal Building $ 865,251 $ 22.82 0% $ 210500 Fire Sprinkler Systems None Shown $ 220500 Plumbing Systems $ 278,000 $ 7.33 0% $ 230000 HVAC Systems $ 193,480 $ 5.10 0% $ 260000 Electrical Systems $ 581,303 $ 15.33 20% $ 116,261 Oncore Pole Relocate Allowance $ 7,500 $ 0.20 $ Per Oncor Quote 270500 Communications Systems By Owner $ 270500 Audio/Video Systems By Owner $ 280500 Security Systems By Owner $ 310000 Earthwork $ 776,971 $ 20.49 100% $ 776,971 310050 Site Enabling $ 99,315 $ 2.62 0% $ 313130 Termite Treatment $ 2,994 $ 0.08 $ 321720 IPavement Markings $ 6,889 $ 0.18 $ 323113 Fencin and Gates $ 155,290 $ 4.10 $ 329223 Landsca in Blrri anon $ 319,271 $ 8.42 0% $ Isite Utilities $ 339,467 $ 8.95 0% $ Accepted Alternates None lNoreAccepted Accepted Cast Value 0 tions $ 301,858) $ 7.96) $ Cost of Work Subtotal $ 6,726,564 $177.42 $ 1,513,426 Contractor's Contin ency 1.90% $ 127,805 $ 3.37 Escalation Contin ency 0.004 $ - $ Owner Conti ngencyl IBy Owner Buildinq Permitill I Excluded Construction Costs Subtotal $ 6,854,369 $180.79 CGL&Umbrella Insurancel 0.96%1$ 74,945 $ 1.98 Builders Riskj GaIc.1$ 8,111 ji$ 0.21 Payment&Performance Bondl 0.86%1$ 67,068 1$ 1.77 Construction Costs&Insurance Subtotal $ 7,004,493 1$184.75 _ Fee 3.57%/% $ 250,060 $ 6.60 Construction Total 1$ 7,254,553 1$191.35 City of Fort Worth Allocation Allowance 7.50-/ol$ 544,091 1$ 14.35 Total $ 7,798,644 1$205.70 ALTERNATES Alt 01 Jemea Avenue Entrance Not Accepted Alt 02 Polished Concrete Floors Not Accepted Alt 03 Chi2 Seal Road Base Not Accepted Exhibit A-1 Page 1 of 20 Pricing Proposal Cost Summary COST VALUE OPTIONS LOG CONSTRUCTION SERVICES Fort Worth PARD Service Center-100%CD Pricing Proposal Accepted Options Value(without markups)($301,858) dw bate DescriptionNo. Originated G-001 5/24/2018 Provide 6"thick road base throughout ILO 12"thick road $ (93,610) $ (93,610) Access road and firelane to remain 12". .iw base throughout. Lime stabilization at all locations.Will require two mobilizations for road base and lime stabilization. G-002 5/24/2018 Provide metal wall panels to grade ILO masonry water table $ (134,292) $ (134,292) and trim.(Delete all masonry from project.) G-003 5/24/2018 Reduce landscaping cost by($50,000). $ M14 G-004 5/24/2018 Remove plywood roof deck and ice&water shield from $ (55,929) $ (55,929) PEMB roof design. ' G-005 5/24/2018 Reduce abuse resistant gyp.Locations TBD... $ (4,031) $ (4,031)This savings is based on removal of ALL impact resistant gyp. G-006 5/24/2018 Remove wall framing,rigid insulation,interior sheathing,and $ (10,278) $ (10,278) # paint from Building 2 Ventilated Spaces.Add PEMB wall purlins and keep spray foam insulation In these areas. G-007 5/24/2018 Remove wall framing,rigid insulation,interior sheathing,and $ (23,272) $ (23,272) paint from Building 4 Storage Spaces.Add PEMB wall purlins Aw and keep sprayfoam insulation in these areas. G-008 6/7/2018 Containment pond to remain in place at completion of $ (11,981) $ (11,981) project. G-009 6/7/2018 Delete Building 4 above slab. - $ G-010 6/7/2018 Alternate light fixture/source options. $ (12,793) $ (12,793) G-011 6/7/2018 Eliminate bottom rail from fencing.(Include tension wire) $ (7,400) $ (7,400) G-012 6/13/2018 Delete curb and gutter around POV lot.(Curbs at island will $ (11,705) $ (11,705) remain) G-013 6/13/2018 Move eastern fence line and lot size inward by 5o'-0". $ (18,372) $ (18,372) G-014 6/13/2018 Delete mow strips from fence. $ (55,590) $ (55,590) G-015 6/13/2018 Delete 160 5Y of 4"sidewalk for access to existing buildings. $ (3,190) $ (3,190) Existing sidewalk to remain. G-016 6/13/2018 Delete 285 SY of 8"sidewalk for access to Building 4. $ (2,670) $ (2,6701 G-017 6/13/2018 Provide hydromulch ILO St.Augustine sod. $ (13,440) $ (13,440) G-018 6/13/2018 Provide new Crepe Myrtles ICO transplanting existing. $ (10,035) $ (10,035) i ll� . Exhibit A-1 Page 2 of 20 Cost k GENERAL Adjustment Provide 6"thick road base throughout ILO 12" G-001 thick road base throughout. Qty UM Sub Labor Material JSubTotaI Lab.Total I Mat Total Total DELETE 12"road base -1 Isum 344250 (344,250.00) - - (344,250) ADD 6"Road Base 1 Isum 194000 194,000.00 - - 194,000 ADD 12"Road base at temporary access/fire lane 1]sum 56640 56,640.00 - - 56,640 Sub Total (93,610) Tax G-001 Grand Total $ (93,610) Provide metal wall panels to grade ILO masonry water table and trim. (Delete all masonryfrom G-002 project.) Qty UM Sub Labor Material Sub Total Lab.Total Mat Total Total DELETE Masonry scope of work from project -1 Isum 167017 (167,017.00) - - (167,017) ADD Metal Wall Panels to grade ILO MasonryVeneer 1 Isum 32725 1 32,725.00 _ _ 32,725 Sub Total T (134,292) Tax G-002 Grand Total $ (134,292) G-003 Reduce landscaping cost by($50,000). JQty JUMISub Labor Material JSub Total ILab.Total Mat Total Total Reduce Landscaping Scope. 1 -11 1 30000 (30,000.00) - - 1 (30,000) Sub Total (30,000) F!I ill '01=11 dm= Tax • (+/_) G-003 Grand Total $ (30,000) Remove plywood roof deck and ice&water G-004 shield from PEMB roof design. Qty UM Sub Labor Material Sub Total Lab.Total Mat Total Total DELETE Plywood decking -20638 sgft 1.35 (27,861.30) - - (27,861) DELETE Ice&Water Shield -20638 sgft 1.36 (28,067.68) - - (28,068) Sub Total (55,929) Tax Pin G-004 Grand Total $ (55,829) G-005 Reduce abuse resistant gyp. Locations TBD... Qty UM Sub Labor Material Sub Total Lab.Total Mat Total Total Replace abuse resistant gyp with standard gyp. -12216 sgft 0.33 (4,031.28) - - (4,031) Sub Total (4,031) Tax - G-005 Grand Total $ (4,031) Remove wall framing,rigid insulation,interior r. sheathing,and paint from Building 2 Ventilated Spaces.Add PEMB wall purlins and keep spray. G-006 foam insulation in-these areas. Qty UM Sub Labor Material Sub Total Lab.Total Mat Total Total DEDUCT wall framing,rigid insulation&interior sheathing -1 Isum 14340 (14,340.00) - - (14,340) Deduct paint I -1 Isum 4944 (4,944.00) - (4,944) rrw ADD perlins I 1 Isum 6256 6,256.00 1 6,256 Add plywood to inside face of walls 1 Isum 2750 2,750.00 - - 2,750 Sub Total (10,278) Tax All (+! ) G-006 Grand Total $ (10,278) Exhibit A-1 Page 3 of 20 Cost Value Option Detail Remove wall.framing,rigid insulation,interior sheathing,and paint frons Building 4 Storage Spaces.Add PEMB wall purlins and keep spray G-007 foam insulation in these areas. Qty UM Sub Labor Material Sub Total Lab.Total Mat Total Total DEDUCT wall framing,rigid insulation&interior sheathin -1 Isum 28800 (28,800.00) - - (28,800) Deduct paint, -1[sum 3296 (3,296.00) - - (3,296) ADD perlins 1 Isum 5824 5,824.00 - - 5,824 Add plywood to inside face of walls 1 'sum 300011 3,000.00 Sub Total (23,272; Accepted -- (+ G-007 Grand Total $ (23,272) G-008 Containment pond to remain in place at I Qty I UM ISub Labor Imaterial JSubTotaI Lab.Total I Mat Total Total Containment pond to remain in place at completion of pr -1 jl'uMj 11981 (11 981.00) - I - (10,981) Sub TotaSIMl (11,981) Tax _ G-008 Grand Total $ (11,981) G-009 Delete Building 4 above slab. I Qty JUMISub I Labor IMaterial jSubTotaI jLab.TotaI I Mat Total Total Not Evaluated V -" MmSubTotal Tax (+H - G-009 Grand Total $ - G-010 Alternate light fixture/source options. IQty UM Sub IlLabor IMaterial ISub Total I Lab.Total jMatTotal Tota( Deduct for alternate Lighting package -111sumj 12793 (12,793.00) - - (12,793) Sub Total (12,793) lam I I Tax (+( ) G-010 Grand Total $ (12,793) G-011 Eliminate bottom rail from fencing. (Include Qty UM Sub Labor IM.terial JSubTotaf I Lab.Total I Mat Total Total DELETE bottom rail from chain link fence -1 11surnj 7400 (7,400.00) - (7,400) �^�r- Sub Total (7,400) /Tax - - G-011 Grand Total $ (7,400) G-012 Delete curb and gutter around POV lot. (Curbs jQty ILIM JSub Labor liviateri2i jSub Total Lab.Total IMatTotal Total DELETE curb&gutter @ vehicle parking I -111suml 10355 (10,355.00) 10,355) ADD road base @ vehicle parking I -1 Isum 1350 (1,350.00) - - (1,350) Sub Total (ti,705) Tax - G-012 Grand Total $ (11,7051 Move eastern fence line and lot size inward by G-013 50'-0". Qty UM Sub Labor Material Sub Total Lab.Total Mat Total Total DELETE 50'chainlink fence -1 Isum 900 (900.00) (9001 DELETE 50'wood privacy fence -1 Isum 1400 (1,400.00) - - (9,400) DELETE lime stabilization -1 Isun 7816 (7,816.D0) - - (7,816) rr DELETE Road base -1 Isum 10236 (10,236.00) - - (10,236) - ADD hydromulch at former base locations 16500 sqft 0.121 1 1 1,980.001 1,980 - jhijl� Sub Total (18,372) Tax t • (+ ) G-013 Grand Total $ (18,372) G-014 Delete mow strips from fence. Qty JUMISub I Labor IMateHal I Sub Total I Lab.Total IMatTotal Total DELETE mow strip -11sum 55590 (55,590.00) - - (55,590) Suh Total {55,590)' `.^�6.�f-`.�_, Tax M Exhibit A-1 Page 4 of 20 Cost Value Option Detail G-014 Grand Total $ (55,590) Delete 160 SY c 4"sidewalk for access to G-015 existing buildings. Existing sidewalk to remain. Qty UM Sub Labor Material ISubTotal ill Mat Total Total DELETE 4"sidewalk -1 Isum 3190 (3,190.00) (3,190) ADD Bermuda Hydromulch-NOT REQUIRED with existing sidewalk to remain. I 0 Isum SUbTOtal (3,190) Tax G-015 Grand Total $ (3,190) G-016 Delete 285 SY of 8"sidewalk for access to I Qty JUM ISub ILabor Imaterial ISubTotal I Lab.Total IMatTotal Total ADD Road base I 111SUMI 1900 1 1,900.00 1 1,900 DELETE concrete -11sum 4570 (4,570,00) - - (4,570) Sub Total 2,670) Tax G-016 Grand Total $ (2,670) G-017 Provide hydromulch ILO St.Augustine sod. 1QtY JUMISub Labor Imaterial jSubTotal I Lab.Total ji Total DEDUCT for hydromulch ILO St.Augustine I -111s.1 13440 1 1 (13,440.00) - 1 (13,440) li,11111mm-1, =11ill'Al, i ii I ill 1 1:1,111111:111 111111 Sub Total 3,440) jj Tax (+/ ) G-017 Grand Tata) $ (13,440) G-018 Provide new Crepe Myrtles ILO transplanting jQty JUMISub I Labor IMaterial jSubTotaI Lab.Total IMat Total Total DEDUCT provide new crepe myrtles -111sur-1 10035 (10,035.00) - (10,035) Sub Total (10,035) " w I-m- i i 11, Tax 115 G-018 Grand Tota) $ (10,035) Exhibit A-1 Page 5 of 20 Cost Value Option Detail NINE DECADES OF EXCELLENCE BYRN551 E.Berry Street Fort Worth,Texas 79110 CONSTRUCTION SERVICES Phone(817)335-3394 Fax(817)9775507 Cost Estimate Summary Sheet Fort Worth Park&Recreation Department-Consolidated Service Center 100%CD Pricing Proposal-Alternate 1 James Avenue Entrance(with Motorized Gate) Date:June 20,2018 37,913 Bid Package 0 Bid Package Description CD01 Cost/SF Notes 011000 General Conditions $ 015000 Temporary Construction $ 020000 Demolition&Abatement $ 033000 Concrete $ 21,193 $ 0.56 033536 Concrete Floor Finish $ 048100 Masonry $ 051000 Miscellaneous Steel $ 061000 Rough Carpentry $ 064000 Architectural Woodwork $ 071000 Waterproofing&Sealants $ 072129 Spray Foam Insulation $ 074000 Metal Panels $ 075000 Roofing Systems $ 078000 Spray-Applied Fire roofing $ 081000 Doors,Doorframes,Hardware $ 083616 Vertical Opening Doors $ 084000 Glass&Glazing Systems $ 086223 Solatube Skylights $ .. 092000 Drywall&Acoustical Systems $ 093000 Tile $ 096500 Flooring&Wall Base $ 099000 Paint&Wall Coverings $ 101000 Specialty Items $ 104000 Signage&Graphics $ 110000 Chain Hoist $ 114000 Residential Appliances $ 122400 Window Treatments $ 129313 Bike Racks $ 133418 Pre-Engineered Metal Building $ = 210500 Fire Sprinkler Systems $ 230000 Plumbing&HVAC Systems $ 260000 Electrical Systems $ 42,165 $ 1.11 270500 Communications Systems By Owner $ 270500 Audio/Video Systems By Owner $ 280500 Security Systems By Owner $ 310000 Earthwork $ 37,247 $ 0.98 310050 Site Enabling $ 313130 Termite Treatment $ 321720 Pavement Markings $ 323113 Fencing and Gates $ 17,430 $ 0.46 329223 Landscaping&Irrigation $ 35,826 $ 0.94 331000 Site Utilities $ 4,166 $ 0.11 Cost of WorkSubtota) $ 158,027 $ 4.17 Contractor's Conting $ 3,003 $ 0.08 Escalati�Confingerncy $ $ OwnBy Owner Excluded Construction Costs Subtotal $ 161,030 $ 4.25 CGL&Umbrella Insurance 0.96% $ 1,635 $ 0.04 Builder's Risk Calc. $ 190 $ 0.01 Payment&Performance Bond 0.86% $ 1,464 $ 0.04 Construction Costs&Insurance Subtotal $ 164,319 $ 4.33 Fe3.57%1$ 5,866 0.15 Construction Total $ 170,185 1$ 4.49 City of Fort Worth Allocation Allowance 7.50° $ 12,764 $ 0.34 Total 1$ 182,949 1$ 4.83 NOT ACCEPTED t� # Exhibit A-1 Page 6 of 20 Alt 1 James Ave Entrance NINE DECADES OF EXCELLENCE nYRAE551 E.Berry Street Fort Worth,Texas 76110 CONSTRUCTION SERVICES Phone(817)335-3394 Fax(817)8775507 Cost Estimate Summary Sheet Fort Worth Park&Recreation Department-Consolidated Service Center 100%CD Pricing Proposal-Alternate 2 Polished Concrete Floors Date:June 20,2018 37,913 Em C-Struction Estimate P.ckageg Bid Package Description cool CostJSF Notes 011000 General Conditions $ 015000 ITemporary Construction $ 020000 IDemolition&Abatement $ 033000 Concrete $ 11033536 Concrete Floor Finish $ 5,080 $ 0.13 Alpha insulation 048100 IMasonry $ 051000 1 Miscellaneous Steel $ 061000 Rough Carpentry $ 064000 Architectural Woodwork $ 071000 Waterproofing&Sealants $ .� 072129 Spray Foam Insulation $ 074000 Metal Panels $ 075000 Roofing Systems $ 078000 Spray-Applied Fireproofing $ 081000 Doors,Doorframes,Hardware $ 083616 Vertical Opening Doors $ 084000 Glass&Glazing Systems $ 086223 Solatube Skylights $ 092000 Drywall&Acoustical Systems $ 093000 Tile $ 096500 Flooring&Wall Base $ 099000 Paint&Wall Coverings $ 101000 Specialty Items $ 104000 Signage&Graphics $ 110000 Chain Hoist $ 114000 Residential Appliances $ 122400 Window Treatments $ 129313 Bike Racks $ 133418 Pre-Engineered Metal Building $ 210500 Fire Sprinkler Systems $ 230000 JlPlumbing&HVAC Systems $ 260000 Electrical Systems $ 270500 Communications Systems $ 270500 Audio/Video Systems $ 280500 Security Systems $ .,,. 310000 Earthwork $ 310050 Site Enabling $ 313130 Termite Treatment $ 321720 IPavement Markings $ 323113 IFencing and Gates $ 329223 1 Landscaping&Irrigation $ 331000 Site Utilities $ $ Cost of Work Subtotal $ 5,080 I$ 0.19 Contractor's Contingency 1.90% $ 97 $ 0.00 Escalation Contingency 0.00% $ $ Owner Contingencyl I By Owner Building Permiti I Excluded Construction Costs Subtotal I$ 5,177 $ 0,14 CGL&Umbrella Insurancel 0.96% $ 53 $ 0.00 Builder's Riski Calc. $ 6 $ 0.00 Payment&Performance Bondi 0.86% $ 47 $ 0.00 Construction Costs&Insurance Subtotal $ 5,283 $ 0.14 Feel 3.57%1$ 189 $ 0.00 Construction Total 1$ 5,472 1$ 0.14 City of Fort Worth Allocation Allowancer 7.50%1$ 410 1$ 0.01 Total I$ 5,882 1$ 0.16 NOT ACCEPTED w Exhibit A-1 Page 7 of 20 Alt 2 Polished Concrete Floors NINE DECADES OF EXCELLENCE 551 E.Berry Street nyRihEFort Worth,Taxes 76110 CONSTRUCTION SERVICES Phone(817)335-3394 Fax(817)8775507 Cost Estimate Summary Sheet Fort Worth Park&Recreation Department-Consolidated Service Center 100%CD Pricing Proposal-Alternate 3 Chip Seat at Road Base Areas Date:June 20,2018 37,913 Bid Gotistruction Estimate P_kag e 4 Bid Package Description CD01 Cost/SF Notes a 011000 General Conditions $ 015000 Temporary Construction $ 020000 Demolition&Abatement $ 033000 Concrete $ 033536 Concrete Floor Finish $ 048100 Masonry $ 051000 Miscellaneous Steel $ 061000 1 lRough Carpentry $ 064000 Architectural Woodwork $ 071000 Waterproofing&Sealants $ 072129 Spray Foam Insulation $ 074000 Metal Panels $ 075000 lRoofing Systems $ 078000 Spray-Applied Fireproofing $ 081000 Doors,Doorframes,Hardware $ 083616 Ivertical Opening Doors $ 084000 Glass&Glazing Systems $ 086223 Solatube Skylights $ 092000 Drywall&Acoustical Systems $ 093000 Tile $ 096500 Flooring&Wall Base $ 099000 Paint&Wall Coverings $ 101000 Specialty Items $ 104000 Signage&Graphics $ 110000 Chain Hoist $ 114000 Residential Appliances $ 122400 Window Treatments $ 129313 jBike Racks $ 133418 Pre-Engineered Metal Building $ Mile 210500 Fire Sprinkler Systems $ 230000 1PIumbing&HVAC Systems $ 260000 jElectrical Systems $ 270500 Communications Systems $ 270500 Audio/Video Systems $ 280500 Security Systems $ 310000 Earthwork $ 307,248 $ 310050 ISite Enabling $ 313130 Termite Treatment $ 321720 Pavement Markings $ 323113 IFencing and Gates $ 329223 Landscaping&Irrigation $ 331000 Site Utilities $ $ _ _ Cost of Work Subtotal 1$ 307,248 $ 8.10 Contractor's Contingency 1.90% $ 5,838 $ 0.15 Escalation Contingency 0.00% $ $ Owner Contingencyl By Owner Will Building Permltj I Excluded Construction Costs Subtotal 1$ 313,086 1$ 8.26 CGL&Umbrella Insurancel 0.96%1$ 3,180 $ 0.08 Builder's Riskj Calc. $ 370 1$ 0.01 Payment&Performance Bondi 0.86%1$ 2,846 1$ 0.08 Construction Costs&Insurance Subtotal $ 319,482 1$ 8.43 Feel 3.57%1$ 11,406 0.30 Construction Total $ 330,888 $ 8,73 Ci of Fort Worth Allocation Allowancel f.bU%l$ 24,817 is 0.65 Total 1$ 355,705 $ 9.38 NOT ACCEPTED Exhibit A-1 Page 8 of 20 Alt 3 Chip Seal Road Base ELM NINE DECADES OF EXCELLENCE nYRN551 E.Berry Street Fort Worth,Texas 76110 CONSTRUCTION SERVICES Phone(817)335-3394 Fax(817)877-5507 Qualifications & Clarifications Fort Worth Park& Recreation Department-Consolidated Service Center 100% CD Pricing Proposal (With No Accepted Alternates) Date: June 20, 2018 -eneral Conditions: 1 A Contractor's Construction Contingency of 1.90% is included in this budget, and is intended for construction use only. 2 A construction fee of 3.57% is included on the cost summary, and is based upon the total construction cost. 3 A City of Fort Worth Allocation Allowance of 7.5% is included at the bottom of the summary, and is calculated upon the Construction Total amount. This allowance does not include fee markups. Fee must be added to any reallocation/use of this City of Fort Worth Allowance. 4 Builders Risk Insurance is included, and based upon the total cost. 5 CGL& Umbrella Insurance is included, and based upon the total cost. 6 Payment and Performance bonds for Byrne have been included on the cost summary, and are based upon the total cost. Y 7 The CM pre-construction services fee is excluded from this budget, but is listed for reference outside the project total. 8 All costs associated with approvals, easements, assessments, fees, deposits, charges, permits, studies, impact _ fees, tap fees, services fees, or similar, required by any governing agency to include County, City, State, or Federal entities, in addition to any and all utility entities are specifically excluded. 9 Building permit cost is excluded. 10 Testing Lab services for materials or delegated engineering components are to be provided by the Owner, and are excluded. 11 Commissioning Agent and Services are to be provided by the Owner. 12 The General Conditions included in this budget are based upon approximately 11 months to substantial completion. Overall project completion is 12 months. 13 Design Fees or services are not included. Where required in the specifications, the Construction Manager will provide design calculations and information provided by the Trade Contractors to the Architect and Engineer for ` a roval and acceptance of the design, 14 The CM does not warrant of guarantee functionality of the design with the Owner's requirements. The CM relies upon the designers to provide and implement the Owner's requirements into the design documents. 15 The CM will provide oversight and review of submittals for compliance with the contract documents. 16 Includes trucks, fuel, tolls, and maintenance related to the Byrne personnel assigned to this project. Truck/Auto Allowance is inclusive of vehicle costs, insurance, fuel and maintenance. 17All costs for mobile phones and iPads is inclusive of mobile data management. 18 All initial and final surve 's and plats required b the Cit are b the Owner. 19 This budget is to be reviewed as a whole; not as individual line items. •e e • • • s 1 Sales tax is excluded 2 This budget is based upon electronic design document files and models being available to all subcontractors at no additional cost. 3 All FF&E, OFE, and furnishings are excluded from this budget. 4 All hazardous or contaminated material and soil testing, remediation, investigation, and abatement is excluded. 5 Site is assumed to be free of any contaminants, unencumbered, and ready to begin excavation work. 6 Temporary utilities are included. 7 Temporary fencing and gates are included per the project specific site logistics plans. 8 Temporary and final cleaning is included. Exhibit A-1 Page 9 of 20 Qualifications &Clarifications NINE DECADES OF EXCELLENCE uYRAE551 E.Berry Street Fort Worth,Texas 76110 CONSTRUCTION SERVICES Phone(817)335-3394 Fax(817)877-5507 Qualifications & Clarifications Fort Worth Park& Recreation Department-Consolidated Service Center 100% CD Pricing Proposal(With No Accepted Alternates) Date: June 20, 2018 IDivision • Conditions 1 IDemolition of existing structures is excluded from this budget. 2 Abatement of structures or soil conditions is excluded from this budget. B o e 1 Concrete is included as indicated, except for modifications made per approved Cost Value Options Items (which are narrated in these qualifications). e • 11 Masonry is included as indicated. Division 1 Steel for the freestanding main entrance canopy is included within the Division 13 Pre-Engineered Metal -- Building. 2 Miscellaneous steel is included as indicated. e ese Plastics and • •• 1 Rough wood blocking and limited temporary protection is included as indicated, except for modifications made per approved Cost Value Options Items (which are narrated in these qualifications). 2 Finish cabinetry is included as indicated. 3 Locks for cabinet doors and drawers are called for in specs but are not shown in drawings and are not included in this bud et. S a o Moisturee • 1 Water repellent for masonry is included as indicated. 2 All flashings through and behind masonry are included as flexible flashings (similar to details 1 &2/A1-305). 3 Damproofing and flashings are included as indicated, except for modifications made per approved Cost Value - Options Items which are narrated in these qualifications). 4 Insulation is included as indicated, except for modifications made per approved Cost Value Options Items (which are narrated in these qualifications). 5 Building and site sealants are included as indicated. 6 Fireproofing is not indicated, and is excluded. 7 All metal roofing,wall panels, and smaller awnings are included within the Division 13 Pre-Engineered Metal Buildin . ® . 11 Doors, doorframes, and door hardware is included as indicated. 2 Coiling doors and Overhead Sectional doors are included as manual operation. 3 All glass and windows is included as indicated. 4 Water testing is included as to be performed by Glazing subcontractor to specified standards, but will not be erformed b AAMA certified third-party agency. �. [--5,Solatube-type skylights are included indicated. 1 Metal stud walls with drywall are included as indicated, except for modifications made per approved Cost Value Options Items (which are narrated in these qualifications). 2 Tile is included as indicated. 3 All sealed concrete floors are included as indicated. Polished floor finish is excluded. 4 Painted finishes are included as indicated, except for modifications made per approved Cost Value Options Items which are narrated in these ualifications . Divisi 0-fil 0,Specialties: 1 I Division 10 specialties and toilet accessories are included as indicated. Exhibit-A-1 Page 10 of 20 Qualifications&Clarifications nick NINE DECADES OF EXCELLENCE MIT551 E.Berry Street Fort Worth,Texas 76110 CONSTRUCTION SERVICES Phone(817)335-3394 Fax(817)877-5507 Qualifications & Clarifications Fort Worth Park&Recreation Department-Consolidated Service Center 100% CD Pricing Proposal(With No Accepted Alternates) Date: June 20, 2018 2 Wire mesh partitions and gates are included as indicated. Wire mesh partitions are free standing with straight bottom gates not contoured to the round to allow proper swing function. - 3 Signage is included as indicated. 4 Signage along James Avenue is indicated to be by Owner per sheets AS-101 and AS-103, and is excluded from this budget. All associated foundations, power, etc. are also excluded. 51FIagpoles are excluded, as none are indicated. ■ 1 Chain hoist is included as indicated. 2 Installation is included for Owner-furnished and delivered appliances and equipment per the indicated listing of + equipment. 'DiviiMlon 12-Furnishinas: 112"Aluminum blinds are included as indicated. ■ o • • 0 1 Pre-Engineered Metal Buildings are included as indicated for Building 1 Crew Staging, Building 2A ar.d 2B Central Storage, Building 3 Botanic Storage, and Building 4 Covered Trades. 2 Entrance Canopy at Building 1, Gutters, Downspouts, Extruded Aluminum Downspout Boots, Roofing, and Metal Wall Panels are included in this Division. oiviijon-14-Conveyingfiqu!pment., 1 None ■ • . . 1 Firesprinkler systems are not indicated, and are excluded. 0 a • • 1 Plumbing systems included as indicated. 2 Piping for air com ressor is included only as indicated. Wivisione ventiiating7nGT -onoitioqiiRg: 11 HVAC systems included as indicated. ■ 1 Electrical systems are included as indicated, except for lighting modifications made per approved Cost Value Options Items (which are narrated in these qualifications). 2 Electrical risers, rough-in, and wiring is included as per MEPC (Electrical Engineer)responses to post-bid questions. These responses were included in 5/24/2018 email from Tanner Kopp(MEPC)to Quorum Architects, and then to Byrne on 5/24/2018. 3 Fire alarm system is included as indicated per drawings for Building 1 only. No specifications are available. 4 Rough-in stub ups only is included for tele/data, communications, audio/visual, security, and access control s stems as indicated in documents. 5 Oncor Pole Relocate allowance of$7,500 is per Oncors quotation to Ronald Clements, dated 1/17/2018, in the amount of$7,143.43. WR#3391934 Transaction ID: 11909 _ ■ Com' Imunication S_: 1 Tele/Data and Communications systems are excluded, and to be By Owner. Special back boxes are excluded. 2 Audio/Visuals stems are excluded, and to be By Owner. Special back boxes are excluded. 'Division 1 Security and Access Control systems are excluded, and to be By Owner. 2 All low voltage wiring at card readers and electric hardware is excluded, and is to be furnished and installed by Divisione Exhibit A-1 Page 11 of 20 Qualifications&Clarifications NINE DECADES OF EXCELLENCE BYRINE 551 E.Berry Street Fort Worth,Texas 76110 CONSTRUCTION SERVICES Phone(817)335-3394 Fax(817)877-5507 Qualifications & Clarifications Fort Worth Park& Recreation Department-Consolidated Service Center 100% CD Pricing Proposal(With No Accepted Alternates) Date: June 20, 2018 1 Earthwork scope is included as indicated in the available documents, except for modifications made per approved Cost Value Options Items (which are narrated in these qualifications). 2 Lime stabilization is included at road base areas. 3 The temporary access road from the east will remain in place at the end of construction. 4 Road base is included as indicated, except for modifications made per approved Cost Value Options Items (which are narrated in these qualifications). 12"thick road base is included for installation of a temporary access road to the East and a fire lane/temporary road from existing site to the east entrance. Division!121-Exterior Improvements, 1 Road as is included at locations noted for"GC to add additional asphalt pavement as required to meet fire lane requirements". The indicated narrow strip of asphalt will be less durable to traffic than road base for this type of temporary lane widening; road base should perform better. 2 Pavement markings are included as indicated in the available documents for concrete paved areas. Pavement markings t parking indicated at"road base"are excluded. 3 Bike racks are included as indicated. 4 Fencing and gates are included as indicated, except for modifications made per approved Cost Value Options Items which are narrated in these qualifications). 5 Landscaping and irrigation is included as indicated, except for modifications made per approved Cost Value Options Items which are narrated in these qualifications). 9 s 1 Site utilities are included as indicated. 2 All utility tie-ins are to be provided by City of Fort Worth, and are excluded from this pricing proposal. These tie- ins shall be made by Cit of Fort Worth to all n with the project schedule re uirements. Accepted Cost Value Oe a a Option Log), G-001 Provide 6"thick road base throughout ILO 12"thick road base throughout. Access road and fire lane to remain 12". Lime stabilization at all locations. Includes the following modifications: Changed road base from 12"thickness to 6"thickness (except at fire lane and access road). G-004 Remove plywood roof deck and ice&water shield from PEMB roof design. Includes the following modifications: Delete plywood decking; delete ice&water shield. G-006 Remove wall framing, rigid insulation, interior sheathing, and paint from Building 2 Ventilated Spaces. Add PEMB wall purlins and keep spray foam insulation in these areas. Includes the following modifications: Delete wall framing, rigid insulation, and interior sheathing; delete painting of interior sheathing at these spaces; add purlins to PEMB; add unfinished plywood to interior face of PEMB walls to height of 8'AFF. G-007 Remove wall framing, rigid insulation, interior sheathing, and paint from Building 4 Storage Spaces. Add PEMB wall purlins and keep spray foam insulation in these areas. Includes the following modifications: Delete wall framing, rigid.insulation, and interior sheathing; delete painting of interior sheathing at these spaces; add purlins to PEMB; add unfinished plywood to interior face of PEMB walls to height of 8'AFF. G-008 Containment pond to remain in place at completion of project. Includes the following modifications: Delete regrading and removal of containment pond. Containment pond shall remain in place as indicated in design prior to removal. G-010 Alternate light fixture/source options. Includes the following modifications: Provide alternate light fixtures in lieu of basis of design. G-011 Eliminate bottom rail from fencing. (Include tension wire) Includes the following modifications: Eliminate bottom rail from fencing. Include tension wire Exhibit A-1 Page 12 of 20 Qualifications&Clarifications BYRAE NINE DECADES OF EXCELLENCE 551 E.Berry Street Fort Worth,Texas 76110 CONSTRUCTION SERVICES Phone(817)335-3394 Fax(817)877-5507 Qualifications & Clarifications Fort Worth Park& Recreation Department-Consolidated Service Center 100% CD Pricing Proposal(With No Accepted Alternates) TM Date: June 20, 2018 G-012 Delete curb and gutter around Privately Owned Vehicle(POV) lot. Includes the following modifications: Delete concrete curb and gutter around POV lot. (Curbs at POV island will remain.) Add road base at locations in lieu of concrete curb and gutter. G-014 Delete mow strips from fence. Includes the following modifications: Deletion of mow strips in their entirety from the project. G-015 Delete 160 SY of 4"sidewalk for access to existing buildings. Existing sidewalk to remain. Includes the following modifications: Delete new 4"concrete sidewalks leading to existing buildings on site. Existinq sidewalks shall remain in place during and after construction without repair). G-016 Delete 285 SY of 8"sidewalk for access to Building 4. Includes the following modifications: Delete 8"concrete sidewalk leading to Building 4. Add road base at locations in lieu of concrete sidewalk. G-017 Provide hydromulch ILO St. Augustine sod. -- Includes the following modifications: Provide hydromulch at all indicated locations in lieu of St.Augustine sod . Exhibit A-1 Page 13 of 20 Qualifications&Clarifications .. NINE DECADES OF EXCELLENCE .. BTRAE 551 E.Berry Street Fort Worth,Texas 76110 CONSTRUCTION SERVICES Phone(817)335-3394 Fax(817)877-5507 Contract Documents List Fort Worth Park& Recreation Department-Consolidated Service Center 100% CD Pricing Proposal Date: June 20, 2018 Specifications Specification No. of Issue Date Specification Section Title Section Pages 01 0200 04/06/18 INFORMATION AVAILABLE TO CMAR 01 0201 04/06/18 GEOTECHNICAL REPORT 01 11 00 04/06/18 SUMMARY OF WORK ' 01 11 13 04/06/18 ADMINSTRATIVE PROVISIONS 01 2000 04/06/18 CONTRACT CONSIDERATIONS 01 2300 04/27/18 ALTERNATES 01 31 13 04/06/18 PROJECT COORDINATION t 01 31 19 04/06/18 PROJECT MEETINGS 01 3300 04/06/18 SUBMITTALS 01 43 00 04/06/18 QUALITY ASSURANCE 01 45 29 04/06/18 TESTING LABORATORY SERVICES 01 5200 04/06/18 CONSTRUCTION FACILITIES AND TEMPORARY CONTROLS 01 5723 04/06/18 POLLUTION PREVENTION AND CONTROL 01 60 00 04/06/18 PRODUCT REQUIREMENTS 01 7329 04/06/18 CUTTING AND PATCHING 01 7500 04/06/18 STARTING OF SYSTEMS 01 7700 04/06/18 CONTRACT CLOSEOUT ` 03 10 00 04/06/18 CONCRETE FORMING AND ACCESSORIES 03 20 00 04/06/18 CONCRETE REINFORCING 03 30 00 04/06/18 CAST-IN-PLACE CONCRETE 03 35 36 04/06/18 INTEGRAL COLORED POLISHED CONCRETE FLOOR FINISH 04 05 00 04/06/18 MORTAR AND GROUT 04 05 23 04/06/18 MASONRY ACCESSORIES- FLASHINGS 042200 04/06/18 REINFORCED UNIT MASONRY 04 72 00 04/06/18 CAST STONE 05 40 00 05/14/18 COLD FORMED METAL FRAMING 05 50 00 04/06/18 MISCELLANEOUS METALS 06 10 00 04/06/18 ROUGH CARPENTRY 06 22 00 04/06/18 FINISH CARPENTRY AND MILLWORK 071113 04/06/18 DAMPROOFING 071900 04/06/18 WATER REPELLENT 0721 00 04/06/18 INSULATION 07 27 00 04/06/18 FLUID-APPLIED MEMBRANE AIR BARRIERS 07 62 00 04/06/18 METAL FLASHING AND TRIM 07 84 00 04/06/18 FIRESTOPPING 07 92 00 05/14/18 CAULKING AND SEALANT 0811 00 04/06/18 METAL DOORS 081101 04/06/18 PREFINISHED STEEL DOOR FRAMES 0831 00 04/06/18 ACCESS DOORS _ 08 33 23 04/06/18 OVERHEAD COILING STEEL DOORS&SECURITY GRILLE 08 36 13 04/06/18 OVERHEAD SECTIONAL DOOR 0841 00 04/06/18 ALUMINUM ENTRANCES, STOREFRONTS,AND WINDOWS 08 62 23 1 04/06/18 ITUBULAR DAYLIGHTING DEVICE Exhibit A-1 Page 14 of 20 Contract Documents List NINE DECADES OF EXCELLENCE BTM 551 E.Berry Street Fort Worth,Texas 76110 CONSTRUCTION SERVICES Phone(817)335-3394 Fax(817)877-5507 Contract Documents List Fort Worth Park& Recreation Department-Consolidated Service Center 100% CD Pricing Proposal Date: June 20, 2018 0871 00 04/27/18 FINISH HARDWARE 08 80 00 04/06/18 GLASS AND GLAZING 09 20 00 04/06/18 GYPSUM WALLBOARD, METAL FRAME SYSTEMS 09 30 00 04/06/18 CERAMIC TILE 09 34 00 04/06/18 THIN-BED WATERPROOF SHEET MEMBRANE 0951 00 04/06/18 ACCOUSTICAL CEILINGS 09 65 13 04/06/18 RUBBER BASE 09 90 00 04/06/18 PAINTING 100000 04/06/18 MISCELLANEOUS ACCESSORIES 1021 13 04/06/18 TOILET PARTITIONS 10 28 00 04/06/18 TOILET ACCESSORIES 13 34 19 04/06/18 METAL BUILDING SYSTEMS 22 05 00 04/06/18 COMMON WORK RESULTS FOR PLUMBING 22 05 19 04/06/18 THERMOMETERS AND GAGES FOR PLUMBING PIPING 22 05 23 04/06/18 GENERAL-DUTY VALVES FOR PLUMBING PIPING 22 05 29 04/06/18 HANGERS AND SUPPORTS FOR PLUMBING PIPING AND EQUIPMENT 22 05 33 04/06/18 HEAT TRACING FOR PLUMBING PIPING 22 05 53 04/06/18 IDENTIFICATION FOR PLUMBING PIPING AND EQUIPMENT ` 22 07 00 04/06/18 PLUMBING INSULATION 2211 16 04/06/18 DOMESTIC WATER PIPING 22 13 16 04/06/18 SANITARY WASTE AND VENT PIPING 22 13 19 04/06/18 SANITARY WASTE PIPING SPECIALTIES 22 15 13 04/06/18 GENERAL-SERVICE COMPRESSED-AIR PIPING 22 33 00 04/06/18 ELECTRIC DOMESTIC WATER HEATERS 22 40 00 04/06/18 PLUMBING FIXTURES 22 45 00 04/06/18 EMERGENCY PLUMBING FIXTURES 22 47 00 04/06/18 DRINKING FOUNTAINS AND WATER COOLERS — 23 05 00 04/06/18 COMMON WORK RESULTS FOR HVAC 23 05 29 04/06/18 HANGERS&SUPPORTS FOR HVAC PIPING AND EQUIPMENT 23 05 53 04/06/18 IDENTIFICATION FOR HVAC PIPING AND EQUIPMENT 23 05 93 04/06/18 TESTING,ADJUSTING, AND BALANCING FOR HVAC R 23 07 00 04/06/18 HVAC INSULATION 23 23 00 04/06/18 REFRIGERANT PIPING 2331 13 04/06/18 METAL DUCTS n 23 33 00 04/06/18 AIR DUCT ACCESSORIES 23 34 23 04/06/18 HVAC POWER VENTILATORS 23 37 13 04/06/18 DIFFUSERS, REGISTERS,AND GRILLES 233723 04/06/18 HVAC GRAVITY VENTILATORS 23 55 33 04/06/18 FUEL-FIRED UNIT HEATERS 23 81 26 04/06/18 SPLIT-SYSTEM AIR-CONDITIONERS .� 26 05 00 04/06/18 COMMON WORK RESULTS FOR ELECTRICAL 26 05 19 04/06/18 LOW-VOLTAGE ELECTRICAL POWER CONDUCTORS 26 05 26 04/06/18 GROUNDING AND BONDING FOR ELECTRICAL SYSTEMS 26 05 29 04/06/18 HANGERS AND SUPPORTS FOR ELECTRICAL SYSTEMS 26 05 33 04/06/18 RACEWAY AND BOXES FOR ELECTRICAL SYSTEMS 26 05 43 04/06/18 JUNDERGROUND DUCTS AND RACEWAYS FOR ELECTRICAL SYSTEMS Exhibit A-1 Page 15 of 20 Contract Documents List R NINE DECADES OF EXCELLENCE BYRN 551 E.Berry Street Fort Worth,Texas 76110 CONSTRUCTION SERVICES Phone(817)335-3394 Fax(817)877-5507 Contract Documents List Fort Worth Park&Recreation Department-Consolidated Service Center 100% CD Pricing Proposal Date: June 20, 2018 26 05 53 04/06/18 IDENTIFICATION FOR ELECTRICAL SYSTEMS 26 09 23 04/06/18 LIGHTING CONTROL DEVICES 26 24 16 04/06/18 PANELBOARDS 26 27 26 04/06/18 WIRING DEVICES 2651 00 04/06/18 INTERIOR LIGHTING 26 56 00 04/06/18 EXTERIOR LIGHTING 31 1000 04/06/18 SITE DEMOLITION AND CLEARING 31 23 00 04/06/18 EXCAVATION& FILL 31 23 16 04/06/18 CIVIL EXCAVATING, BACKFILLING,AND COMPACTION 31 23 33 04/06/18 TRENCHING 31 25 14.13 04/27/18 HYDRAULICALLY APPLIED EROSION CONTROL 31 41 00 04/06/18 SHORING AND BRACING 31 63 29 04/06/18 DRILLED CONCRETE PIERS AND SHAFTS 32 13 13 04/06/18 PORTLAND CEMENT CONCRETE PAVING AND CURBS 32 17 23 04/06/18 PAVEMENT MARKINGS 3231 00 04/06/18 CHAIN LINK FENCES AND GATES 32 31 29 04/06/18 WOOD PRIVACY FENCES AND GATES 32 84 00 04/27/48 PLANTING IRRIGATION 3284.50 04/06/18 CONCRETE WHEEL STOPS 32 90 00 04/06/18 LANDSCAPE PLANTING 32 92 00 04/27/18 TURF AND GRASSES 32 93 00 04/27/18 PLANTING 33 10 00 04/06/18 WATER UTILITIES 33 30 00 04/06/18 SANITARY SEWERAGE UTILITIES 334000 04/06/18 STORM DRAINAGE UTILITIES - . Sheet Number Issue Date Drawing Title G-001 04/06/18 COVERSHEET G-002 04/06/18 CODE CRITERIA G-003 04/06/18 ACCESSIBILITY GUIDELINES TAS G-004 04/06/18 ACCESSIBILITY GUIDELINES TAS G-005 04/06/18 ACCESSIBILITY GUIDELINES TAS G-006 04/06/18 ACCESSIBILITY GUIDELINES TAS C0.1 04/27/18 GENERAL NOTES C0.2 04/06/18 DEMOLITION PLAN C0.3 04/27/18 DRIVEWAY DEMOLITION PLAN C1.0 04/06/18 SITE PLAN �* C2.0 04/06/18 COORDINATE CONROL PLAN LAYOUT MAP C2.1 04/06/18 COORDINATF CONTROL PLAN SHEET(1 OF 4) C2.2 04/06/18 COORDINATE CONTROL PLAN SHEET(2 OF 4) C2.3 04/27/18 COORDINATE CONTROL PLAN SHEET(3 OF 4) C2.4 04/06/18 COORDINATE CONTROL POINT TABLE (SHEET 4 OF 4) C3.0 04/06/18 WATER PLAN LAYOUT MAP C3.1 05/14/18 WATER PLAN SHEET (1 OF 6) Exhibit A-1 Page 16 of 20 Contract Documents List NINE DECADES OF EXCELLENCE 551 E.Berry Street Fort Worth,Texas 76110 CONSTRUCTION SERVICES Phone(817)335-3394 Fax(817)877-5507 Contract Documents List Fort Worth Park&Recreation Department-Consolidated Service Center 100% CD Pricing Proposal Date: June 20, 2018 C3.2 04/27/18 WATER PLAN SHEET(2 OF 6) C3.3 04/27/18 WATER PLAN SHEET(3 OF 6 ) - C3.4 04/27/18 WATER PLAN SHEET (4 OF 6 ) C3.5 04/27/18 WATER PLAN SHEET(5 OF 6 ) C3.6 04/27/18 WATER PLAN SHEET(6 OF 6) - C3.7 04/06/18 WATER DETAILS SHEET(1 OF 2) C3.8 04/06/18 WATER DETAILS SHEET(2 OF 2) C3.9 04/06/18 FIRE LANE AND HYDRANT LOCATIONS C4.0 04/06/18 SEWER PLAN 1 SHEET(1 OF 2) C4. 1 04/06/18 SEWER PLAN 1 SHEET(2 OF 2 ) C4.2 04/27/18 SEWERPLAN 2 _ C4.3 04/06/18 SEWER DETAILS C5.0 04/06/18 EXISTING DRAINAGE AREA MAP C6.0 04/06/18 PROPOSED DRAINAGE AREA MAP C7.0 04/06/18 STORM DRAIN LINE A(SHEET 1 OF 2) C7.1 04/06/18 STORM DRAIN LINE A(SHEET 2 OF 2) C7.2 04/06/18 STORM DRAIN LINE B C7.3 04/06/18 TXDOT HEADWALL DETAIL - C7.4 04/06/18 STORMDRAIN CALCULATIONS C8.0 04/06/18 GRADING PLAN LAYOUT MAP C8.1 05/14/18 GRADING PLAN SHEET (1 OF 6) C8.2 05/14/18 GRADING PLAN SHEET(2 OF 6) C8.3 04/27/18 GRADING PLAN SHEET (3 OF 6) C8.4 04/27/18 GRADING PLAN SHEET(4 OF 6) _ C8.5 04/27/18 GRADING PLAN SHEET (5 OF 6 ) C8.6 04/27/18 GRADING PLAN SHEET (6 OF 6) C8.7 04/06/18 POST CONSTRUCTION GRADING PLAN _ C9.0 05/14/18 PAVING PLAN C9.1 04/06/18 PAVING DETAILS (SHEET 1 OF 2) C9.2 04/06/18 PAVING DETAILS (SHEET 2 OF 2) 010.0 04/06/18 EROSION CONTROL PLAN C10.1 04/06/18 EROSION CONTROL DETAILS C10.2 04/06/18 SEDIMENT BASIN PLAN IR1.0 04/27/18 OVERALL SHEET PLAN = IR1.1 04/27/18 IRRIGATION PLAN IR1.2 04/27/18 IRRIGATION PLAN IR1.3 04/27/18 PLANTING PLAN = IR1.4 04/27/18 IRRIGATION DETAILS IR1.5 04/27/18 IRRIGATION DETAILS L-1.0 04/06/18 TREE MITIGATION PLAN L-1.1 04/06/18 TREE MITIGATION PLAN L-1.2 04106/18 TREE MITIGATION PLAN L-1.3 04/06/18 TREE MITIGATION CHART L-1.4 04/06/18 TREE MITIGATION CHART i L-1.5 04/06/18 TREE MITIGATION CHART L-2.0 04/06/18 OVERALL SHEET PLAN Exhibit A-1 Page 17 of 20 Contract Documents List = NINE DECADES OF EXCELLENCE iBY 551 E.Berry Street Fort Worth,Texas 76110 CONSTRUCTION SERVICES Phone(817)335-3394 Fax(817)877-5507 Contract Documents List Fort Worth Park&Recreation Department-Consolidated Service Center 100% CD Pricing Proposal Date: June 20, 2018 L-2.1 04/06/18 PLANTING PLAN L-2.2 04/27/18 PLANTING PLAN L-2.3 04/27/18 PLANTING PLAN L-2.4 04/06/18 PLANTING DETAILS ASD-101 04/06/18 DEMOLITION SITE PLAN AS-100 04/06/18 OVERALL SITE PLAN AS-101 04/06/18 SITE PLANS L AS-102 04/06/18 ENLARGED SITE PLANS AND DETAILS AS-103 04/06/18 ENLARGED SITE PLANS AND DETAILS AS-104 04/06/18 ENLARGED SITE PLANS AND DETAILS Al-100 04/06/18 BUILDING 1 OVERALL PLAN Al-101A 04/06/18 BUILDING 1 FLOOR PLAN-WEST Al-101B 04/06/18 BUILDING 1 FLOOR PLAN -EAST �. Al-102A 04/06/18 BUILDING 1 DIMENSION PLAN-WEST Al-102B 04/06/18 BUILDING 1 DIMENSIONS PLAN-EAST Al-103 04/06/18 BUILDING 1 PARTITION TYPES T Al-104A 04/06/18 BUILDING 1 REFLECTED CEILING PLAN-WEST Al-104B 04/06/18 BUILDING 1 REFLECTED CEILING PLAN-EAST A1-105 04/06/18 BUILDING 1 ROOF PLAN Al-201 04/27/18 BUILDING 1 EXTERIOR ELEVATIONS Al-202 04/27/18 BUILDING 1 EXTERIOR ELEVATIONS Al-203 04/06/18 BUILDING 1 INTERIOR ELEVATIONS Al-301 04/06/18 BUILDING 1 BUILDING SECTIONS Al-302 04/06/18 BUILDING 1 WALL SECTIONS Al-303 04/06/18 BUILDING 1 WALL SECTIONS Al-304 04/06/18 BUILDING 1 WALL SECTIONS Al-305 04/06/18 BUILDING 1 SECTION DETAILS Al-306 04/06/18 BUILDING 1 SECTION DETAILS Al-401 04/06/18 BUILDING 1 ENLARGED RESTROOM PLAN Al-402 04/06/18 BUILDING 1 RESTROOM ELEVATIONS Al-501 04/06/18 BUILDING 1 DETAILS Al-502 04/06/18 BUILDING 1 PLAN DETAILS Al-503 04/06/18 BUILDING 1 DETAILS Al-504 04/06/18 BUILDING 1 STAIR AND RAMP DETAILS Al-601 04/06/18 BUILDING 1 DOOR AND WINDOW SCHEDULES A1-701 04/06/18 BUILDING 1 FINISH PLAN A2-101 04/06/18 BLDG 2A&2B FLOOR PLAN A2-102 04/06/18 BLDG 2A&2B REFLECTED CEILING PLAN A2-103 04/06/18 BLDG 2A&2B ROOF PLAN _ A2-201 04/27/18 BLDG 2A EXTERIOR ELEVATIONS A2-202 04/06/18 BLDG 2B EXTERIOR ELEVATIONS A2-301 04/06/18 BUILDING 2A&2B BUILDING SECTIONS y A2-302 04/06/18 BUILDING 2A&2B WALL SECTIONS A2-303 04/06/18 BUILDING 2A&2B WALL SECTIONS A2-304 04/06/18 BUILDING 2A&2B SECTION DETAILS A2-701 04/06/18 BUILDING 2A&2B FINISH PLAN Exhibit A-1 Page 18 of 20 Contract Documents List BYRN NINE DECADES OF EXCELLENCE 551 E.Berry Street Fort Worth,Texas 76110 CONSTRUCTION SERVICES Phone(817)3355-3394 Fax(817)877-5507 Contract Documents List Fort Worth Park&Recreation Department-Consolidated Service Center 100% CD Pricing Proposal Date: June 20,2018 A3-101 04/06/18 BUILDING 3 FLOOR PLAN AND EXTERIOR ELEVATIONS A3-102 04/06/18 BUILDING 3 REFLECTED CEILING PLAN AND ROOF PLAN A3-301 04/06/18 BUILDING 3 BUILDING SECTIONS A4-101 04/06/18 BUILDING 4 FLOOR PLAN A4-102 04/06/18 BUILDING 4 REFLECTED CEILING PLAN A4-103 04/06/18 BUILDING 4 ROOF PLAN A4-201 04/27/18 BUILDING 4 EXTERIOR ELEVATIONS A4-301 04/06/18 BUILDING 4 BUILDING SECTIONS A4-302 04/06/18 BUILDING 4 WALL SECTIONS A4-303 04/06/18 BUILDING 4 WALL SECTIONS A4-304 04/06/18 BUILDING 4 SECTION DETAILS .. A4-305 04/06/18 BUILDING 4 SECTION DETAILS A4-701 04/06/18 BUILDING 4 FINISH PLAN S-001 04/06/18 SPECIAL INSPECTION &GENERAL NOTES S-101 04/06/18 FOUNDATION DETAILS S-102 04/06/18 FOUNDATION DETAILS S-103 04/06/18 FOUNDATION DETAILS S-104 04/06/18 FOUNDATION DETAILS S-105 04/06/18 FOUNDATION DETAILS SS-201 04/06/18 STRUCTURAL SITE PLAN SS-202 04/06/18 STRUCTURAL FOUNDATION PLANS A' S1-201 04/06/18 BUILDING 1 OVERALL FOUNDATION PLAN S1-202 04/06/18 BUILDING 1 FOUNDATION PLAN WEST S1-203 04/06/18 BUILDING 1 FOUNDATION PLAN EAST S2-201 04/06/18 BUILDING 2A&2B FOUNDATION PLANS S3-201 04/06/18 BUILDING 3 FOUNDATION PLAN S4-201 04/06/18 BUILDING 4 FOUNDATION PLAN M-101 04/06/18 LEGEND AND NOTES M-102 04/06/18 MECHANICAL SITE PLAN M1-103A 04/06/18 BUILDING 1 WEST MECHANICAL PLAN M1-103B 04/06/18 BUILDING 1 EAST MECHANICAL PLAN T M2-103 04/06/18 BUILDING 2A MECHANICAL PLAN M4-103 04/06/18 BUILDING 4 MECHANICAL PLAN M-201 04/06/18 MECHANICAL SCHEDULES M-301 04/06/18 MECHANICAL DETAILS M-401 04/06/18 VENTILATION CALCULATIONS P-101 04/06/18 LEGEND AND NOTES P-102 04/06/18 PLUMBING ENLARGED SITE PLAN P1-103A 04/06/18 BUILDING 1 WEST PLUMBING SUPPLY PLAN P1-103B 04/06/18 BUILDING 1 EAST PLUMBING SUPPLY PLAN P1-201A 04/06/18 BUILDING 1 WEST PLUMBING WASTE PLAN P1-201B 04/06/18 BUILDING 1 EAST PLUMBING WASTE PLAN 132-103 04/06/18 BUILDING 2A&2B PLUMBING SUPPLY PLANS P2-201 04/06/18 BUILDING 2A PLUMBING WASTE PLAN P4-103 04/06/18 BUILDING 4 PLUMBING SUPPLY PLAN P4-201 04/06/18 BUILDING 4 PLUMBING WASTE PLAN Exhibit A-1 Page 19 of 20 Contract Documents List NINE DECADES OF EXCELLENCE nYRN 551 E.Berry Street Fort Worth,Texas 76110 CONSTRUCTION SERVICES Phone(817)335-3394 Fax(817)877-5507 Contract Documents List Fort Worth Park&Recreation Department-Consolidated Service Center 100% CD Pricing Proposal Date: June 20, 2018 P-301 04/06/18 PLUMBING SCHEDULES AND DETAILS P-401 04/06/18 PLUMBING DETAILS E1-103A 04/06/18 BUILDING 1 WEST LIGHTING PLAN E1-103B 04/06/18 BUILDING 1 EAST LIGHTING PLAN R' E1-203A 04/06/18 BUILDING 1 WEST POWER PLAN E1-203B 04/06/18 BUILDING 1 EAST POWER PLAN E2-103 04/06/18 BUILDING 2A&2B LIGHTING PLANS E2-203 04/06/18 BUILDING 2A&2B POWER PLANS E3-103 04/06/18 BUILDING 3 LIGHTING PLAN E3-203 04/06/18 BUILDING 3 POWER PLAN E4-103 04/06/18 BUILDING 4 LIGHTING PLAN E4-203 04/06/18 BUILDING 4 POWER PLAN E-101 04/06/18 ELECTRICAL LEGEND AND NOTES E-102 04/06/18 ELECTRICAL SITE PLANS E-301 04/06/18 ELECTRICAL SCHEDULES AND DETAILS E-302 04/06/18 ELECTRICAL SCHEDULES AND DETAILS F1-103A 04/06/18 BUILDING 1 WEST FIRE ALARM PLAN F1-103B 04/06/18 BUILDING 1 EAST FIRE ALARM PLAN . . - . Sheet Number Issue Date Drawing Title SL0.1 06/13/18 Site Logistics Plan SI-0.2 06/13/18 Site Logistics Plan SL0.3 06/13/18 Site Logistics Plan SL0.4 06/13/18 Site Logistics Plan dd . . Addendum No. of Original Date Specification Section Title Pages Addendum 1 84 04/27/18 Addendum 1 Addendum 2 16 05/14/18 Addendum 2 Exhibit A-1 Page 20 of 20 Contract Documents List ,.t 0 , ----------------- -----------------= ------------ — a a — N , 0 N coCIO j C7. p EL N T C r a (L00 ° m, o C) c '0: m °' a > i •'a m Vy LL E'U cA c > O -o U d; w '0 _ -ca ppb LM L (0, 0 'E > Urn'y Q a- LL C 75 4) E tH �h o co ------------ 4----- - a 06 CD CL 0 v ' ' �w to� o 0L'fE'j cp7c '0E •oc : ° m cm E > a o Q1ia�i 0 s —0' O LL 00 CL 0 N' _ o oc m u) o d'm13 10- j Iy ;o I ! I �Q QQ..Q LLcL' j�r !i�ceM. d�� •'�N 'i�vi��l� N �N Idj(uh '� j'!ocdo� !,'doho, ;co > CO (C 0 O (1) _ I � a�o =3 :3 ca 0 O � ,+'a��' 3 00 z � ti A iro ohb u5 h N Mi0 N ONO' I- N O OO o QQ Q � Q 'Q :Q Q .Q Q , Q ! :Q � IQ , QQ iQ 1� 7� IQi � ,� ,II •�. r r r r r r r r co 'co co !co Ico ao oo co co ao U T p/ cc C ` 1 7 7 7 3 U ' N y I O '- ' W (0 7 ! 7 7 O O i ,� Fj•i O�p LL NqI 'N ;O 'N IM �0i Mt.. c) O i� meq, Lh glNq ab Cb��N ',� I,C) d1 ,6:— C3 , w ,. r N O O O p -6 -c-') O O C) C) i0 'O Oi0 O O O O (O C O O O O O Oi0 'O 'N ;O � .:� M ! O I`C O O 0 '(O CO O O iO 'O 'O O !O O �,� �O ' O O`er c) c) i(O iM 10. tC') U 0 c00 'N r1i LO 0) 10to jam , co i L N C O li i w d : UI� c � a� ! i otpLL, !�cl m; I E ° :3otiE I� � j ,Yloi� j oo c :3 y �lQo� ji.�° `o�$ ;: oml io� lD❑ l�w ' li°l "0 w ! c tijCco to il0 a yi(� ,•rnF3o , cc 0 �6> / ° ° y :N EL iLLEm ,Up � o o 4) °oq clE 'Y �. I '� � .y c 0 C) 06 ycm, c , o atm t !� U : 'o,� m c d o � j� ic i•- ° c bio cI. m o mi ol d jiU m apt Ui� ' c . 3i' Ei ml�j a .mjti Qlff, olo c I� a°il � iu, � f° � j o,.� ' o . o, o !ml m ' a ° ' c at o !� mI LL , rnt °; E a� Ei�S C ' t m , mI o a Y , o m +� . Q - y 'Q ' E oi � jp �'- o m1E ` 'U o U 0i 4 $ d 44 m ! o � j.o � to o; ._ d ;�tSim 'd �o !� T, O ' 7 U a ` ' d : U > a � :a N ; oi w mj° ami o a! N > ° Z ti:c � ; 4) m' O ; o c) � i� ,tj L} rn ,iuj o m qip p 3 m .2 p ,'Yjmj � I UiOj.v !a . �.n p ,_ � ;rYI._ I• ° o m oia o ' c m ma°i ' a > ;3 m U : � iw o I � o Q ' E E U aip � •g , o '� . U wi0 O .�_' 'q :� (0 .00 ico 0, 7 1 O ;� , N O d N 0 7 7 .� -.�� O y d to Q (� :(� a U 'Q .� IQ a N U ;U d :Ula " I u CL IU) 1LL ,U10 z 6- O iO O O O C) C'll C)iiO '_OI iI1 ._ _ _jN_ C,4 iM O ! r 0 VM O ' O N iN OO 0 0 0O 0Y O0 : ;:: ;;: ;z p N_ - • Q I Q %Q Q !Q Q Q Q Q Q Q. Q I Q Q Q Q Q Q Q Q Q Q Q :Q Q Q ! Q-; t m @, _ O 6 E Ot 10 o •iai IN > U U' n O �!C1. W C �� ' a)' nm N ° N N' C , C 3 a' >, � ; c OCA C O; CO i _.. COL; m c3 .co � w ca 0)° LL: o ci a o; 1� m N •o N �. N N cu t m TV- c�6 a) p V'• N C N ; ' 'O C N a).0 di: O) a) (n J m U o ° co n c cc U)EO '; om rm ai j cp O c °d E. ' N T' am ¢ m± O=o) cc c oc o mO a� pU c O co) c 0. to '� p7 Z3 - m a ----�----; <!} c0 00 i a m E "� o m, in 00 0, 0 o � N CD 0C14 Co r 05 04 �. N; 'vs fa CO aapa ao ao m CO ao 1 co 'co co !m ao l co l ao l ao a0 a0 1 ao 1 a0 ao l ao "m m ao ao ao rn l ar l m x017 l� 7I� r I wl i Imo ; i i •� t r o)I_ Cl)I a t �= rnl rn a o) o) ln, 61 h.h b.1 -q a; h1 6-1 &1 I U , c � Ih � c I U N 7 ! 7 7 jI7 7 a) R� 7 7 7I7 I ,7I 7 � Q) IN IN r =I a) a) a) a) I 1 I-� (� ; -� � �� Q '� QI� �Q �� (� i((�n (n U) co (n (n O :0 � Io ii ' � I [i LL � Ifb lr - ' ia0 r1N 1n - �M Cb L6 • �abl -'aDIMi ,N CVP °) I jd l(b i0d' ICb .CV 'N ,rl -•'.r ' Imo _ 'O 'N ,N N -IN � IN ;O OI -O O ,MN �� ,O SIN -O ! O SIN �O ' {'":., ,.,..-_. 1- i.._., -F_ .1.. ._.. 1 ,� � .._ .. 0 i i I r :� S O) O): r i S r m r m1 �; b., i �I 6- a 0 7i7 7 7 7 7 7 7 1 7 7 7 7 mea) . a) Q) Q nt y� O- N N N N ! C -� ,� -) � I-nl-ni� � I� I-n � '� I� '� uJ (A u) U) U) to tnlZ a 01u_ p AS N `cb ` r I N !cb (� c� I "r� i r- ±o) co N 1 N 16 16 14 1 d• :cb 1 1$ I�} 1 ch cb jr O ,N Frgd r IN OI � �:M IM � 1 IO .O1 `� ;N ,O p MIN . O •OiO )t) � NIL jU I� N IN i� r O '� MIO IO OIN,N IM C', r r N N I pO MIN � 1N IC) �O IN i�iO NiIp LILo1 -,N Lo IN it I` O ,Lo 1 !L ,M 1C) iO C) LO NiM M -,X11 .� j� _ I !� 1 � i ' rOj I u C ! a C: . al owl o T I Q! ° lIoi En I ol� i ; ! { r ! I � ; off ,�I al Iaf�� C° IN m � 1 v ca i ! _ ' a°)i cni � aUi � ayii' N i. 1 ti � o) c I rloJ U s M to a C9 � � I� i z C9 J; w1 = lmlai 'p �'Im ° E ' c m m, > m N ! �y � rn�aNilQl ��m mlo �� i i I U , co .� I !.� c `�' v i ad' 1 c c_ N Zc i .�j !ad i U Ica I a E Y 8 Y a U m �w � m o r� CIc N, c NIS Eml Ij w o 'er miN1 m oi m pIa p` i� _ ci� N, 'ZI W ! ' � ' � � '¢ v LL �� coo ' n, r n w m •C ' O � , i 1 a) Q) r i )f Q I C �•N1 ad OiN O 1 7 a) I Io. C O - oi i i- a)I� Ni 2' C r ` r s t � m , cesl:9lE _ Ids ml= ' aslcn ' � ! m! mIco .0610: �wl a� �jclE : ml U) LL ;m c ILL1a1 >> �� ;ca m . c- m �' m m c: 75 is c N 1 N 1t U I a I C m I•- Cl) cm O O I O o Nlp � I�I� �iN M 1� c �" al o �calc ; ° ' JI m; mj— m calve U ' I ° ad F" =3 m m O u� ,5 m l U o a a) i t m I 1 " t m �i I c Slc c Ula p o c N , :&'o o U o O n� ' � ° vt W mli� m a l o c m f 6 I o O d 1 m c rn.a I•� in l '= c ° i u� c,a �Zf � Im mim ' �oa ` jololalcl Ef� u) i� co � !�'o — ; U U(a Ic' E m 1p 1 m m 'm` N m •o m I'v I Co I t o 6 5 I m m E 1 4 J c l i . ra cm ". aH o 06 _ _________ O'--------------------�. _y___---_ _ __________________i___-__ -____ ___________i __mo — IL J N'y w- O ' 0 C t6 r CL N > N ° c, - d id o 4 J m c c o o mR v af0i uJi 8 @ c!4 c ; 0. m T 0 06 fY ' N � LL � oiS m� L N � o � - O ; rn > 41 -------------------`----v�-- -C,)- c- <9 C O - - _-'(5__ o , r 3 = H n Sami o - c o �° c >m o ai j LL N , '� C A I N N N N S'c; � `O a, N C C > '(••5 f0 S E c m N m 5 y o m c o GJ d W a m I v V- d vy O O c In LL co Cl a r/J _ of W d; l!J m m o ; 2 0 r� _ {` m � U o m 2 m o o a c S m; c3 06 M In ca a $ o c ® m 0 � _ � ®I s= o m (L 16 LLdc: NLL W0 •' �_ MZ E; i O :- 0 ❑ p 04 Qu — m U) LL o g' M ______________________________________ N . =z ----------------------------------------------------- cmN N 4 ffl on � o �rotilaolaolao 'ao �p�.� °� mlmrnrn of tLLct M r i• !tO I I )IIII >' I0�4..0 0 N NN NI J O N N. IiN� N� II � I �' II CdNN DZ ICC 'C0IO Z � C 'CC � - 1� wLL 'LL U) OZ LL LL LL! N0 � a O6 � M 'M IA iN 14 l4 14I ib 4I ' 4 NN { oN - oIN N oO NN� cc4O I co !co I� 1 0 co co CO - CO I co m co j 0 (p - O W CO I� 00 I� I�I O i 0 O 'O V ..I_.- i � I ' OI� lI�III I� INc1.6 I p.,m 61 6-! b. 6.: 6. O mmIN aN, NN �NO : Cb Lb A4L6 6 fb4 i6 1'd I N 1& j6INOIN O O O O N C) N O / p oioio o nioMlo o W) Ln ofolin !LO o .- l� �n o�n ;n ,� Ivinlo (cniL LOl Cf o 0 0 i o n I o n n M I o o {.cn cn i o o I o' ,n .o r� i n I' v o I u� f ILO ( U nn O N N I ;• � �_ Imo ! I I I I- _' i .. I�— I -' I - � a � i i � I I j ; I 1 I � I i i o �• L I Jl 1 i CI NI I po N ' 1 aJi m ' I 1 Oi , = j LL j I o l c I I I +a 'E i nn U) 10 ° o ! � �kx mlw I iE LLI � ylm, a� � E 3 3 ��e Imoy , IN� o ;o° I 1 CIN NI { mI C INININ } m OI iNI {a ( I l iCI ID ; C CI f0 f[I , I I N i 0 (.! N N +N I �• N I C c O) .{ I G ° `p l 1+N+ , h1 O CLI�y N ( aI i c U) � ; clCa I> Icot - .r ' c �'� I I 05 o 0- o1 aj � I ( � > Is o 'm m Ialc > p)r + O •a`) alc I o : a �� I� °4y = I ` IIo � Io ' ��>> ;�;a_ Ioi lyQ1{ fy 'LLI V' U CO ! • BIW 71Nij C O J J i7 �I C) 0 = C LL > l0 CO Ijlo6 N a IO) �i0 O ° 7I7 LL C Q _ w •� I I ILL' I � J I E I Iw. LL O _ I d Ia .I W O N N I— Ln aIm LL m llJl� N N m m N �1- - 1� i•- Ial� fa miNILLI0) LLLu a o . w , ;t$ co I m c o c 5 �� W 5 I Hta) 0 0 0 N �!gI- ,rjj ��o 1?M: l-. Ip 'Iy , N � I� I_ y�m� 4J HI ^INI �IQI o LL Z `c ! ° ISI of af°iI- _ ia - c �- I IN (m 7 7N ILL - INI0 3 00 3io11o , `O_ �Io `o t �mlllJ 3 �IN' � UI �UI >t Ca to N - � Ic I-NO � I � ,� 1N ro ' IN � i*`N•, I ° .N., i� N S NI N N � I> N Io+ 11J -� NiN N NI•CIc O N .. O 7ININ , .; ,� i ° iY. 0 2 Ci> , C , C CIa, N tCVI aI8 5 LL II- LL �U E CIW INS_ ,_+ �I2 LL110I �� O ,LL � SOI- i(niUiLLI21Fl cc I j I m• ! i I Oi , 1 I CjO O IO 10 O 'O is O 0 'O O10 0 O10 i0 i0 'O OI ... 0 O O 0 0 010 O O 'O C) CD IO - - tO IO IM I N I O I O Ir i °. � j�n ltD I n aO IO) C) O NlM jvl N I M tf) n I ro O,O N M i tO (Oy CCcy),c0 l_O a0 CO tO a0 j .a0 CO CO CO CI Q�Q I� ' M MIM vI� I� I� II� +-7'� QIQ %Q QIQ .Q IQ C;Q jQ IQ iQ Qf Q I Q 'Q IQ IQ 'Q IQ ..- ' � r i.Q Q iQ 'Q Q IQ Q Q m; � I! I I i i I I a I , a. � cc c o d 06m o ! cu d ____ ___ __ ___�__�t_E___ --C_______ _________________________ _____ ___-____________ __________-_ -moi' O � 4S � 1 � i N a' L"y rn y U o N W m -S; oa O05 0 i 0 (0 O w EFE O m m U' Q o o' y �I > c� 0 m U a I LL c o o' c v m od ' rty W _.._ 6_m - 41 rw 0 v � a tt< ---------------- ,g © ; C9' ❑' ® o C' O! ° m O c a w a I o U! U LL; 0 m W f o m OIN (1 N. co 5 m � -n c �! a 5 0! m w o v; o o o c r - cu c W o LL v o c �; 3 0 v m` > >75 c ® -)U oO E; '7 0 LL: _____ ________________ __________________•_________________ ________________ _________ O m_ � O LL = 0 N 01 7 Q0n C N co (n LL cu O Na.. J c LLd0LL rniolirn rn 'rn 0) 0) rn ' , l ! � om co co I Nm - m ,o> im )1od 1 0I $1ea tjo !_o Cd l . m ' mim (1 1 LL LL LL LLLLI2I2gim !m � Oi 1 10 O z zim Im N 1I�ININ0 N ' N N iNN Lh O 0LL N 10 N co O N i > rO" 01 1 01 1 01 1 10) 0) rn rn rnlrn rn rn rn 'i m m m�mlmjmlaro _rol. co co mim mlaorml U J , mlm o1� 0o ' od l iI ' N l' oi mmm ( Co u 000 !n + i oI � � ' ) Om 00 c? ol(h ( � � o mh (b (; INM o1c0 I N I N i N "Co N N ON } n OJ10 'O�r :iO N !10 n 1O !n IM IM M 1O Ir N C') !1O in Ofn O +n !O +(O Cl) O u7 (O rl CA L n�0lO ,1OIN�I to r- to jn,Mjci.l C,) to� nO �n !, C) r- O Oj1O +�..-1Oir er I i i i INI ! oio ' lo : 1 ( $ -. ac I , co m ? OIOr lJi Ji IJI I1Iivadi lillam�Oc !l O !11cn ImmSmlIIj,.e. mwJl c J{Oom IllJ I�IiI o-oN 1lif 9 oo v `n�! w '--o 0 0 NooECca ca 'O eslO d og�E n1E 0iC � c LL Cc: II U � 1 o ; I I W l l c l (�1 `i 5 l o l m l f° I c o f !� I• r H 10` JIm ! J . ..a > ' 0o o wo iIo 2 1 LL DJIm�I i-6c NIo LL a , o m ' o ca LL wLU O d v o 0 ' 9n " ! Ja Io I! - 3iw1 I! (l1 121 c i 07 Plw WOm or t0!0 C I �o IE `1l > �LL 0i0 . 0 c . 'a f > E cc o _�=a1o o - O> o � 10 � LL ou7 ° > m U a � 0 ILLLL un� olololoio !olo !(0 0 oiolo o 'o ! I i �'� INfM !omim A;� �_Icool m 0 1O m 0 n M N W (co, 1O M O O I O O O O 'O O O : OjW i C') 01 !0101 O O W O 'O .O O . n nim 0) IO NiM �m mlai0 lr .O -� ,r ` L � � I to to aJala ?ala a ,.m' "a �� '51! •�' i J I , I I i � + i � I J O I � a r di_ W a w (1 °o :; ; w IL 'A ------------- od w cn cm o m orl; c' a rn' U m a a; E m U s 2d) I m a ------- -------- - a c c U m c o EI c m' v rn o '�' _ m a •> j�j t U I > a� •5 'n N y Fil o ma m m (D rn; m a ami d i m c m E LL (q N aS ,� m ' co o N CL co; N otS m v :° li ° co 'O 00 �.r �. o' N cL w Ir 5 c a m m `; m Y Fit m m m c U m �> > a W mI LL I U m �; c U) N, — �- iU W Y O o O C N T. m Q O N d 7 '�' o a a N; .0 a O, c t U) a O O LL (D .(/J m w �1 a 'm O, C L) c 7 (a a. U I N W p aai cm.o o r c �, N �' a aai > o a0i' •m rn d c c m a Z6 >,Z o m m �' U rn m m Z �; a e v a o m 3. a C a:j m > > a. �- a C N a j i® c0 I j •� LL c ._ t� 0 0 :3. a� H d • U fr 5;� ® o d UC) mI _ _ <' o; m m k U' m £ ------w -- E u o m .. E ( `mom -r ti- a`�; Q � ❑ CL:— C) LL ' m ® C o MV. aa v'® O ° c CM cv - - U) LL o s mlm m m N aaoa an: co 'm m aoi �o ;m ;ool�ol�_o '�o,00 rojoo ao ��o oo aolao aolm ao � j�' � ��1� I� ;oo1co � 1 r � j r rI 'r �r ,: > aol$b > y > . > > o�imloolrn �; h �;s I r I L O O O O1 7I mlm o •olo o O 71 m m U0 O: > 7Im1a� cd N zIZ z zl Q ;�' I� Ita� :cn cn �o10 010cnita/3 O z Z Q Q (n .(n , LL O 1� IN N p i� Iry iN Ir !N ;N �!r IO IN i0 10 i� IN IN'MN IN N IO IN I� 1� c,4 IN IM Id Id> �� O _ r __ _ r. 1 .... _.. ... •�:+ i 1 ao ao coIao 0 ao loo ao m 1 ao I ao ao ao co ao j ao ao 0 co co ao Go ao co oo I m co co ao ao I r ao V r 1 r r I r 1 r l r r I r t r t I r rl r rl i I .r! i , t i i, , t j > ; �Im' Ol Ol1Ol O., aI > > i > - > , o, rn, m rn mih 0 1) , 010 o m,a1 Olt °' a6 o ; o O I 0� 0 m P� r z° iz Iz° �z ' a' I� I� I m o�o �o o "o I '�I �� -m o o Iz a a Im X93 rw m IN I� cb o� lb col ' aSICU� d> cb o5 d> cb rn m d 'ch Id 1 cb Ib cb d�i d IN r 1r ' W in O Ir lr IN l O Ir Ir IN N ; O I N O Ir IN IN 'M Ir M O O `r iN N IN O r a) M M to N I V Mto 1✓n N ... 1 1;\' N M 1-LO 'O t,- 1 0 1 O Gi0 ✓n N M Lo 1 u-) ;\ r M co I Lr) INI r V �M I� iO �h 1014) j N ;'r I✓-) rIN M ✓2),O Ih O OI� t� 1C')Ir N M ✓2) yt07h.� r� t w ttt o 1 iyl I 1 I d o6I+ I 10 c inI I j 3 .�`•� # ... a I mI 'm ; Ni m, `al aoi N o a ! = 3 £ E j � 1 N1t � cjE � �' Ia ' E g ,• E I O j coI I � I I I C I I NI Sal o IN a) Y P a i C) jml I Ialat m !d cicL, j a!aI d4�j�! u1I i� ip !, Imus ' m m �C .01EI co otS iml c: l Ur cc co iC U i<AI[nit '%71�j1 iVlm , U11=iv1 ml a 09101 a of ml lyiml ;mlm ' �'I idjm : m � 91 _ m lfOlOi(75 � � �I '� • i i - I a' oo l d, c l C9 fn co U) (L la !g1 i7i7 N -pic IN1'1W ! ,a 'w Im c1i of INWj 11IC C ml !N IW Ij ' 7 ) ' o ' o � � ��_ I• I 0 17 oi«-, •$ I I I 1o1N10 al,� o !cn a a o ' rn,� oI<nI rn o ol: gl o m _ I I olc !._ la m e a ala m Ln Ni �_Iala a U, U, LU �m m his a rn cnlin{� � m of i (a HILL �n i c mIO1 I� I� 'LL cl wm, l 1 LL I--Ic CC al w 51NI � 1� 1� ,� o o Iml 51w1 � 1�; m cio 'd 116 UI5 NI ' IcI cc I i I a s I-w o o m ; > 1 (Y o l'm' d U � 1311rn1 Im12 ' clafOilac°i ml� . �?� rnl� ;E ',a1 � o cI�' � iIm , �,� '� �� i c m aIHlalmio ;` 'c a � ml:= ,•- c : ala , > �JyIIo � 1 m Em ! mj > 'o m m .ro - !SIE E : mi > 0101. N � I_ Iv EIEImI cc a' i"c1o !E ; o m , � 1 > 1 > •m,t _ Ic , o' 15 ;mI mlm `c : I._ c o , o. I Llan Q, UI,U_1� 1,LL." a TILL .7 IUlpiwl0 0 C) a1D1� LL UID W`Ja U aI� I� ILL LL __. - t I I � I I � 1 c)jc)jrn `ol ojolo o o b ojololo�0 0 o Oj010!0 O 0 0l0 0 0 0+0 :o O 0jc) oC 1 j . I I � I V Ln r ,r 4N . N CO IO IN IM (0 it O N w) 1c0 .N 10.m 0 1r IN 10 �� O IM t V � t0 h• iaO l 1 3 1 t0 ✓A -. E N.�(O I ( N N (O ;(O O f0 (O ;h I>` ;v N co h h h :h ,;v ;v 1 ala a j¢ is is j� j� !� , ala !a ja':.a a ;a ;¢,� I� a'a la la •a a o i dCD lJJ O # p__ �____________ �Ip n 0 cp� U � CL E U a) OCa) N =1 C14 IOU 0 °�s rn Oycc m m 9, 0 °' (� <. °U ___ _ O; w LL oiyOts pl0cw o m �m c. w y O- oca °ow °2 S' rn ° LL > ❑ c ' , _ Lo 0 co _______________r____________________________________________________________________ _________________ a) f0 7 CJ cc cj 04co (n LL *4') 0 W' 4=s CO N. O o N f0 dLL0LL I I ; m a0 ,a0 a0 ;co '00 'm a0 I C0 00 00 'I oO ; rn I rn °' m p� j rn rn rn ' .r- b i l > > i l i l b o �� U 0 ce m m' m m' c o a� 0 0 0 0 0 a) . m m .m m m d q q q y In IZ Z Z iZ IZ `a '� I0 iQ i� t� .D Q iQ I� .� �� -it 4I4I , -i I� W I� �N cb 1a01M th N ;� Ih iO �,� I4 L6 fO ;N M O> � O :aD IN C� '�, I i0 � LL N ! _ �. � I � rn rn i 0 I� 1 0. �rn rn :rn O r N N O O I N !N O N O O O O O N N Cl) O I I I l co au au au co CO au ao ao ao rn { rn l rn rn rn i m l o l O � ! > > > U U olU �Ic �. � �' cic G� 10 U o olo oio a) ININ d : m `ml 0 , 01 xN r Oz zzz !zoo '000 � � '� a � ;� m . ;d !c$ d d � ,o� .F d 'cb ao o> d !m ',m 4 ,L6 a5 !� � 4 41— C,3 UJ - N N N ,N '0 ,� i N N ;O N 7N IN 1N O O O:O ' N O (x N L0 0 c) j Lo LO h N N M M co � Il 1p m in (O I_O -M ;N O � �O I N W 0,0 !LO O 1C9 LO i� �ih h IN iM co M LO I� �� iLO (O0 M 'N O I I`p iN U Cq _ �' •` I I co Cc 0 oa �a i 06 ; i rn U ° � o 'ul - NI1F. , � I Ir N Co lN 06 cl> ; !�! I I m mlal co r s ISS � , � I � ; o � o o U 1 0) i 0 cccc r y al i plf i 0 ' U N p ° c C C l ! !I U U m ; m c U c i m c �j y j? m' c �'o rn a� -mm ! y c , of Ic c . c I'- 1f0 E2 SILL !ci� lt d tii0 U ml old oi�tS ' > 0i ml 0 0 1 c i N r m o ' c f0 y w a ol" Zlcn co m � ' � . c; J Ulo m O alv � ' Eio LL plolci `olalSlm o m ' w N � cLilc alp C7 ' `0i � l� lml Lj0i= # N 0 - CO m y : a) 0 j d s plc y 06 y J ° U (A In � imlm m . o �a� !LL ; c y Oicn ; 'u� lo LL � ,5 ! � c c Ulo� LL :mt° i w c a n Z� c 'vl� ! ci� cl� �� 115 c'. cja l jl- ciu �` c !� 'UIo ' °� im �Ul > pl � l7 ?� fT' O l� l Ipp it ~ I'C = 1Z5 :2 c IM•O IJ . a) U N L N iNl [r IW S l� ul l a� fO W J � iI� O iU 0uj C7 :� ;� 1 Q i(n �u VI tD �1 oio !o 0 0 0 oiolo 0 0 '0 'o O o o !0 0io 0 0 !010 0 , o oto oC WIO cc O n W M ,^ �' ;O a0iW ,O 10 Ia0 ,n :M • O m IN ,M LLO cc 1 IV IN N N N N ;O �' ,�' �' ,M V AM M;�' � ,N1V Imo - -M ;� . VI � City of Fort Worth, Texas Facilities Management Department Facilities Division GENERAL CONDITIONS OF THE CONTRACT FOR CONSTRUCTION CONSTRUCTION MANAGER AT RISK SECTION A DEFINITIONS,PROCEDURES AND INTERPRETATIONS A-1 CONTRACT DOCUMENTS. By the term Contract Documents is meant all of the written and drawn documents setting forth or affecting the rights of the parties, including but not necessarily limited to, the Contract, General Conditions, Special Conditions, Specifications, Plans, Bonds and all Addenda and Amendments signed by all parties, Change Orders, written Interpretations and any written Field Order for a minor change in the Work. A-2 ENTIRE AGREEMENT. The Contract Documents represent the entire agreement between the Parties, and no prior or contemporaneous, oral or written agreements, instruments or negotiations shall be construed as altering the terms and effects of the Contract Documents. After being executed, the Contract Documents can be changed only by a written Amendment, Change Order or Field Order signed by the Construction Manager at Risk("CMAR")and the Owner. — A-3 WORK. By the term "Work' is meant all labor, supervision, materials and equipment necessary to be used or incorporated in order to produce the construction required by Contract Documents. A4 EXECUTION OF THE CONTRACT DOCUMENTS. The Contract Documents shall be executed in four originals,with all required attachments, including required bonds and insurance certificates, by the CMAR and the Owner in such form as may be prescribed by law and returned to the Owner within ten business days of delivery to CMAR. Failure to execute contracts and provide all required bonds and insurance will be grounds for revocation of award and taking of Bid Bond. A-5 FAMILIARITY WITH PROPOSED WORK. Before filing a proposal, the CMAR shall examine carefully the proposal, plans, specifications, special provisions, and the form of contract to be entered into for the work contemplated. He shall examine the site of work and satisfy himself as to the conditions that will be encountered relating to the character, quality and quantity of work to be performed and materials to be furnished. The filing of a proposal by the bidder shall be considered evidence that he has complied with these requirements and has accepted the site as suitable for the work. Claims for additional compensation due to variations between conditions actually encountered in construction and as indicated by the plans will not be allowed. A-6 ONE UNIFIED CONTRACT. Insofar as possible, the Contract Documents will be bound together and executed as a single unified Contract,the intention of the Contract Documents being to provide for all labor,supervision,materials,equipment and other items necessary for the proper execution and completion of the Work. Words that have well-recognized technical or trade meanings are used herein in accordance with such recognized meanings. — A-7 DIVISION OF WORK. The arrangement of Drawings and/or Specifications into Divisions, Sections, Articles, or other Subdivisions shall not be binding upon the CMAR in dividing the work among Subcontractors or Trades. A-8 INTERPRETATIONS. The Architect will furnish such Interpretations of the Plans and Specifications as may be necessary for the proper execution or progress of the work. Such Interpretations shall be furnished at the instance of the Architect or at the request of the CMAR, or Owner,and will be issued with reasonable promptness and at such times and in accordance with such schedule as may be agreed upon. Such Interpretations shall be consistent with the purposes and intent of the Plans and Specifications and may be effected by Field Order. In the event of any dispute between any of the parties to the Contract and the Architect or each other involving the interpretation of the Contract Documents, the evaluation of work or materials performed or furnished by the Architect,CMAR,or any subcontractor or materialman,or involving any question of fault or liability of any party,the decision of the Owner shall be final and binding. In the event of inconsistency in the contract documents, the following sequence for interpretation shall be used in order of precedence: Change Orders and/or Field Orders (by date of issuance); Addenda (by date of issuance); Drawings; Notes and dimensions on Drawings; Technical Specifications; Special Provisions; Supplementary General Conditions; General Conditions; and,Construction Contract. — A-9 COPIES OF WORKING DRAWINGS AND SPECIFICATIONS. The CMAR will furnish to City three (3)sets of working Drawings, Three(3)sets of Specifications, and one(1)set in electronic format prior to starting work. CMAR shall pay the cost of reproduction for all other copies of Drawings and Specifications furnished to him. — A-10 MINORITY AND WOMENS BUSINESS ENTERPRISE POLICY. The City of Fort Worth has goals for the participation of disadvantaged business enterprises in City contracts. Compliance with the policies designed to meet these goals is mandatory in order to be considered a responsive bidder. The City policy and procedures to be followed in submitting bids is included. The City of Fort Worth MWBE Program will take precedence over other subcontractor utilization programs on Block Grant and other Federally funded Projects. A-11 CORRELATION AND INTENT. In general,the drawings indicate dimension, locations,positions,quantities,and kinds of — construction;the specifications indicate the quality and construction procedures required. Work indicated on the drawings and not PARD Service Center Project Page 28 of 58 Byrne CMAR Construction Contract June 2018 specified of vice-versa,shall be furnished as though set forth in both. Work not detailed, marked or specified shall be the same as — similar parts that are detailed,marked or specified. If the drawings are in conflict or conflict with the specifications the better quality or greater quantity or work or materials shall be estimated and shall be furnished or included. Dimensions on drawings shall take precedence over small-scale drawings. Drawings showing locations of equipment, piping, ductwork,electrical apparatus,etc., are diagrammatic and job conditions may not allow installation in the exact location shown. Relocation shall not occur without the Architects approval. A-12 AGE In accordance with the policy("Policy") of the Executive Branch of the federal government, CMAR covenants that neither it nor any of its officers,members,agents,employees,program participants or subcontractors,while engaged in performing this contract, shall, in connection with the employment, advancement or discharge of employees or in connection with the terms, = conditions or privileges of their employment, discriminate against persons because of their age except on the basis of a bona fide occupational qualification, retirement plan or statutory requirement. CMAR further covenants that neither it nor its officers, members, agents, employees, subcontractors, program participants, or = persons acting on their behalf, shall specify, in solicitations or advertisements for employees to work on this contract, a maximum age limit for such employment unless the specified maximum age limit is based upon a bona fide occupational qualification, retirement plan or statutory equipment. CMAR warrants it will fully comply with the Policy and will defend, indemnify and hold City harmless against any claims or allega- tions asserted by third parties or subcontractor against City arising out of CMAR's and/or its subcontractors' alleged failure to comply with the above referenced Policy concerning age discrimination in the performance of this agreement. A-13 DISABILITY: In accordance with the provisions of the Americans With Disabilities Act of 1990("ADA"), CMAR warrants that it and any and all of its subcontractors will not unlawfully discriminate on the basis of disability in the provision of services to the general public, nor in the availability, terms and/or conditions of employment for applicants for employment with, or employees of CMAR or any of its subcontractors. CMAR warrants it will fully comply with ADA provisions and any other applicable federal, state and local laws concerning disability and will defend, indemnify and hold City harmless against any claims or allegations asserted by third parties or subcontractors against City arising out of CMAR's and/or its subcontractors' alleged failure to comply with the above-referenced laws concerning disability discrimination in the performance of this agreement. _ SECTION B IDENTITY OF ARCHITECT B-1 CONTRACT ADMINISTRATION. The Architect is the person or person lawfully licensed to practice architecture identified as such in the Agreement. The Architect is retained by the Owner to prepare the construction documents and represent = the Owner during the construction phase as directed by the Owner. B-2 DUTIES OF THE ARCHITECT. As used herein,the term Architect means the Architect or his authorized representative. Nothing contained in these Contract Documents shall create any privity,of contract between the Architect and the CMAR. B-3 ARCHITECT AS REPRESENTATIVE OF THE OWNER. The Architect will have authority to act as the representative of the Owner to the extent provided in the Contract Documents unless changed in writing by the Owner. The Architect will be available for conferences and consultations with the Owner or the CMAR at all reasonable times. B-4 ACCESS TO JOB SITES. The Architect shall at all times have access to the Work whenever it is in preparation and progress. The CMAR shall provide facilities for such access so the Architect may perform its assigned functions under the Contract Documents. The Architect will make periodic visits to the Site to familiarize himself with the progress and quality of the work and to determine if the work is proceeding in accordance with the Contract documents. On the basis of on-site observations,the Architect will keep the Owner informed of the progress of the Work and will endeavor to guard the Owner against defects and deficiencies in the Work of the CMAR. Based upon such observations and the CMAR's applications for payments,the Architect will make determinations and recommendations concerning the amounts owing to the CMAR and will issue certificates for payment amounts. B-5 INTERPRETATIONS. The Architect will be, in the first instance, the interpreter of the requirements of the Plans and Specifications and the judge of the performance thereunder by the CMAR,subject to the final decision of the Owner. The Architect's decisions in matters relating to artistic effect will be final if consistent with the intent of the Contract Documents. B-6 AUTHORITY TO STOP WORK. The Architect will have authority to reject work that does not conform to the Plans and Specifications. In addition, whenever, in its reasonable opinion,the Architect considers it necessary or advisable in order to insure the proper realization of the intent of the Plans and Specifications,the Architect will have authority to require the CMAR to stop the Work or any portion thereof, or to require special inspection or testing of the Work whether or not such Work be then fabricated, installed or completed. B-7 MISCELLANEOUS DUTIES OF ARCHITECT. Shop Drawings. The Architect will review Shop Drawings and Samples as provided in Section D. The Architect will provide two copies of each approved Shop Drawing and submittal to the Owner. Change Orders Change Orders and Field Orders for Minor Changes in the Work will be issued by the Owner through the Architect in accordance with the provisions of Section L. PARD Service Center Project Page 29 of 58 = Byrne CMAR Construction Contract June 2018 Guarantees. The Architect will receive on behalf of the Owner all written guarantees and related documents required of the CMAR. Upon completion of the project the CMAR shall provide the Architect five copies of each guarantee.The Architect will provide three copies of each guarantee to the Owner. Inspections The Architect will conduct inspections for the purpose of determining and making his recommendations concerning the dates of substantial completion and final completion. Operation and Maintenance Manuals The Architect will receive on behalf of the Owner, six copies of all applicable equipment installation, operation,and maintenance brochures and manuals required of the CMAR. The Architect will provide three copies of this information to the Owner. B-8 TERMINATION OF THE ARCHITECT. In case of the termination of the employment of the Architect by the Owner, the Owner shall either assume the duties of the Architect through the Director of the Property Management Department, or shall appoint a successor Architect against whom the CMAR makes no reasonable objection. SECTION C OWNER C-1 IDENTIFICATION. By the term Owner is meant the City of Fort Worth acting herein by its duly authorized representatives in the manner provided by law. Authorized representatives include the City Manager,Assistant City Manager,the Director of the Property Management Department, and members of the Facilities Management Division. Generally speaking a designated representative will be identified from within the Facilities Division to act as a point of contact for day-to-day contract administration. C-2 DUTIES OF THE OWNER. The Owner shall furnish surveys describing the physical characteristics,legal limits and utility locations for the site of the Work; provided, however, that the CMAR hereby covenants that he has inspected the premises and familiarized himself therewith and that the locations of utilities and other obstacles to the prosecution of the Work as shown on the Owner's survey are for information only, are not binding upon the Owner, and the Owner shall not incur any liability for loss or damage by virtue of any inaccuracies or deficiencies in such surveys. The Owner shall secure and pay for title to the site and all necessary permanent or construction easements. The Owner will cooperate with the CMAR in the prosecution of the Work in such manner and to such extent as may be reasonable and shall furnish information under its control with reasonable promptness at the request of the CMAR. C-3 INSTRUCTIONS. The Owner shall issue all instructions to the CMAR through the Architect. C-4 ACCESS TO JOB SITE. The Owner shall at all times have access to the Work whenever it is in preparation and progress. The CMAR shall provide facilities for such access so the Owner may perform its assigned functions under the Contract Documents. C-5 PROGRESS INSPECTIONS. The Owner and the Architect will make visits to the Site to familiarize themselves with the progress and quality of the Work and to determine if the work is proceeding in accordance with the Contract documents. On the basis of on-site observations and reports provided by the Architect concerning the progress and quality of the work,the Owner will approve and authorize the CMAR's applications for payments. C-6 AUTHORITY TO STOP WORK. The Owner will have authority to reject work that does not conform to the Plans and Specifications. Whenever, in its reasonable opinion, the Owner considers it necessary or advisable in order to insure the proper realization of the intent of the Plans and Specifications,the Owner will have authority to require the CMAR to stop the work or any portion thereof, or to require the CMAR to stop the Work or any portion thereof, or to require special inspection or testing of the Work whether or not such Work be then fabricated, installed or completed. C-7 SUBSTANTIAL COMPLETION INSPECTION. Upon agreement of the CMAR and Architect that the Work is substantially complete,the Owner will schedule a Substantial Completion Inspection to be conducted by the Architect and attended by representatives of the Architect, Owner and CMAR. Items identified during this inspection as being incomplete, defective or deficient shall be incorporated into a punch list to be prepared by the Architect and attached to the AIA document G704,which is to be prepared and signed by the CMAR,and accepted,approved and signed by the Owner. C-8 RIGHT TO AUDIT: CMAR agrees that the City shall, until the expiration of three years after final payment under this contract, have access to and the right to examine any directly pertinent books, documents, papers and records of the CMAR involving transactions relating to this contract. CMAR further agrees to include in all his subcontracts hereunder a provision to the effect that the subcontractor agrees that the City shall, until the expiration of three years after final payment under the subcontract,have access to and the right to examine any directly pertinent books,documents, papers and records of such subcontractor, involving transactions to the subcontract.The term "subcontract"as used herein includes purchase orders. CMAR agrees to photocopy such documents as may be requested by the city. The city agrees to reimburse CMAR for the costs of copies at the rate published in the Texas Administrative Code. PARD Service Center Project Page 30 of 58 Byrne CMAR Construction Contract June 2018 SECTION D CONSTRUCTION MANAGER AT RISK(CMAR) D-1 IDENTIFICATION. The Construction Manager at Risk ("CMAR") is the person or organization identified as such in the Contract.The term CMAR means the Contractor or his authorized representative. The term Contractor is synonymous with CMAR in his performance of the construction portion of the Project. The duties of the CMAR are as follows: CMAR shall work with the Architect prior to construction to analyze the Architect's design, including the Plans and Specifications,to ensure the feasibility and constructability of the Project design, and to assist in bringing the estimated construction cost of the Project within the Construction Budget through value engineering, the selection of building systems and materials, cost estimating, scheduling, and other means, without adversely affecting the capacity and quality of the Project;and 2. The CMAR will propose a Guaranteed Maximum Price ("GMP") for the construction of.the Project, which is within the Construction Budget,after or during completion of the pre-construction services. 3. The CMAR will serve as general contractor for the Project during the construction phase including the selection of subcontractors and prompt payment to the subcontractors. D-2 INDEPENDENT CONTRACTOR.Contractor shall perform all work and services hereunder as an independent contractor, not as an officer, agent, or employee of the City. Contractor shall have exclusive control of and the exclusive right to control the details of the work and services performed hereunder,,and all persons performing same,and Contractor shall be solely responsible for the acts and omissions of its officers, agents, and employees. Nothing herein shall be construed as creating a partnership or joint enterprise between City and the Contractor, its officers, agents and employees, and the doctrine of respondeat superior shall not apply. D-3 SUBLETTING It is further agreed that the performance of this Contract,either in whole or in part, shall not be sublet or assigned to anyone else by said Contractor without the prior written consent of the Director of Property Management Department of the City of Fort Worth. D-4 REVIEW OF CONTRACT DOCUMENTS. The CMAR shall carefully study and compare the Agreement, Conditions of the Contract, Drawings, Specifications,Addenda and modifications and shall at once report to the Owner and to the Architect any error,inconsistency or omission he may discover.CMAR shall do no work without Drawings,Specifications and Interpretations. D-5 SUPERVISION. CMAR shall supervise and direct the Work, using its best skill and attention. It shall be solely responsible for all construction means, methods, safety,techniques, sequences and procedures and for coordinating all portions of the Work under the Contract Documents. D-6 LABOR AND MATERIALS. Unless otherwise specifically noted, CMAR shall provide and pay for all labor, materials, equipment, tools, construction equipment and machinery, water, heat, utilities, transportation and other facilities and services necessary for the proper execution and completion of the Work. CMAR will use its reasonable best efforts to hire or contract with local laborers,workmen and materialmen. This general condition is not to be construed as limiting the right of the CMAR to employ laborers,workmen or materialmen from outside local area. CMAR shall at all times enforce strict discipline and good order among its employees, and shall not employ any unfit person or anyone not skilled in the task assigned to him. D-7 PREVAILING WAGE RATE. CMAR agrees to pay not less than the general prevailing rate of per diem wages for work of a similar character in the locality in which the Work is performed, and not less than the general prevailing wage of per diem wages for a legal holiday and overtime work to all laborers, workmen and mechanics employed on the Work under this Contract. CMAR agrees to pay at least the minimum wage per hour for all labor as the same is classified and set out by the City of Fort Worth, Texas, a copy of which is attached hereto and made a part hereof the same as if it were copies verbatim herein. D-8 WARRANTY. CMAR warrants to the Owner and the Architect that all materials and equipment furnished under this — Contract will be new unless otherwise specified, and that all work will be of good quality, free from faults and defects, and in conformance with the Contract Documents. All work not so conforming to these standards may be considered defective. If required by the Architect or the Owner, CMAR shall furnish satisfactory evidence as to the kind and quality of materials and equipment. The warranty provided in this Section shall be in addition to and not in limitation of any other warranty or remedy provided by law or the Contract Documents. D-9 TAXES. CMAR is exempt from State Sales Tax on material incorporated into the finished construction, Excise and Use Tax. D-10 LICENSES, NOTICES AND FEES. CMAR shall obtain all Permits, Licenses, Certificates, and Inspections, whether permanent or temporary, required by law or these Contract Documents. City of Fort Worth Building and Trade Permit fees are waived. Separate permits may be required for each work location. It is the responsibility of the contractor to ensure all permits are kept active and do not expire.The contractorwill be responsible for any reinstatement fees due to expired permits. CMAR shall give all notices and comply with all laws, ordinances, rules, regulations and orders of any public authority bearing on the performance of the Work. If the Contractor observes or becomes aware that any of the Contract Documents are at variance with any such laws, ordinances, rules, regulations and orders in any respect, it shall promptly notify the Architect in writing and any necessary changes will be made. If the Contractor performs any work knowing that it is in violation of, or contrary to, any of such PARD Service Center Project Page 31 of 58 Byrne CMAR Construction Contract June 2018 +•a Laws, Statutes, Charter, Ordinances, Orders or Directives, or Regulations without furnishing Notice to the Architect, CMAR will assume full responsibility therefore and bear all costs attributable thereto. w D-11 CASH ALLOWANCES. CMAR shall include in the Contract Sum all allowances stated in the Contract Documents. These allowances shall cover the net cost of the materials and equipment delivered and unloaded at the site, and all applicable taxes. CMAR's handling costs on the site, labor, installation costs, overhead, profit and other expenses contemplated for the original allowance shall be included in the GMP and not in the allowance.CMAR shall cause the Work covered by these allowances to be performed for such amounts and by such persons as the Architect may direct, but it will not be required to employ persons against whom he makes a reasonable objection. If the cost, when determined, is more than or less than the allowance,the GMP shall be adjusted accordingly by Change Order which will include additional handling costs on the site,labor, installation costs,field overhead, profit and other direct expenses or savings resulting to the CMAR from any increase or decrease in the original .F allowance. D-12 SUPERINTENDENT. CMAR shall employ a competent superintendent and necessary assistants who shall be in attendance at the Project site during the progress of the Work. The superintendent shall be satisfactory to the Owner. The superintendent shall represent the CMAR and all communications given to the superintendent shall be binding as if given to the CMAR. Important communications will be confirmed in writing. Other communications will be so confirmed on written request in each case. D-13 RESPONSIBILITIES FOR EMPLOYEES AND SUBCONTRACTORS. The CMAR shall be responsible to the Owner for the acts and omissions of all his employees and all Subcontractors,their agents and employees, and all other persons performing any of the Work under a contract with the CMAR. D-14 FAILURE TO COMMENCE WORK: Should the CMAR fail to begin the work herein provided for within the time herein fixed or to carry on and complete the same according to the true meaning of the intent and terms of said Plans, Specifications and Contract Documents,then the Owner shall have the right to either demand the surety to take over the work and complete same in accordance with the Contract Documents or to take charge of and complete the work in such a manner as it may deem proper, and if, in the completion thereof,the cost to the City shall exceed the contract price or prices set forth in the plans and specifica- tions made a part hereof, the CMAR and/or its Surety shall pay said City on demand in writing, setting forth and specifying an itemized statement of the total cost thereof,said excess cost. D-15 PROGRESS SCHEDULE. CMAR, immediately after execution of the contract, shall prepare and submit for the Architect's approval, an estimated progress schedule for the Work. The progress schedule shall be related to the entire Project. — This schedule shall indicate the dates for the starting and completion of the various states of construction and shall be revised as required by the conditions of the Work, subject to the Architect's approval. It shall also indicate the dates for submission and approval of shop drawings and submittals as well as the delivery schedule for major pieces of equipment and/or materials. CMAR shall update the progress schedule monthly and submit to the Architect for approval with the CMAR's monthly progress payment requests. D-16 DRAWINGS AND SPECIFICATIONS AT THE SITE. The CMAR shall maintain at the site for the Owner one copy of all _ Drawings,Specifications,Addenda, approved Shop Drawings, Change Orders, and other Changes and Amendments in good order and marked to record all changes made during construction.These shall also be available to the Architect. The Drawings,marked to record all changes made during construction, shall be delivered to the Architect upon completion of the Work, and the Architect will prepare,and provide to the Owner,one complete set of reproducible,record drawings of the work. D-17 SHOP DRAWINGS AND SAMPLES. Shop Drawings are drawings, diagrams, illustrations, schedules, performance charts, brochures and other data which are prepared by the Contractor or any Subcontractor, manufacturer, supplier or distributor, and which illustrate some portion of the Work. Samples are physical examples furnished by the CMAR to illustrate materials, equipment or workmanship, and to establish standards by which the Work will be judged. The CMAR shall review, stamp with its approval and submit,with reasonable promptness and in orderly sequence so as to cause no delay in the Work or in the work of any other contractor, normally within the first 90 days of the work, six copies of all shop Drawings and Samples required by the Contract Documents or subsequently by the Architect as covered by changes or amendments. Shop Drawings and Samples shall be properly identified as specified, or as the Architect may require.At the time of submission the CMAR shall inform the Architect in writing of any deviation in the Shop Drawings or Samples from the requirements of the Contract Documents. By approving and submitting Shop Drawings and Samples, the CMAR thereby represents that it has determined and verified all field measurementsi field construction criteria, materials, catalog numbers and similar data, and that it has checked and coordinated each shop drawing given in the Contract Documents. The Architect's approval of a separate item shall not indicate approval of an assembly in which the item functions. The Architect will review and approve Shop Drawings and Samples with reasonable promptness so as to cause no delay, but only for conformance with the design concept of the Project and with the information given in the Contract Documents. The Architect's approval of a separate item shall not indicate approval of an assembly in which the item functions, The CMAR shall make any corrections required by the Architect and shall resubmit the required number of corrected copies of Shop Drawings or new Samples until approved. The CMAR shall direct specific attention in writing or on resubmitted Shop Drawings to revisions other than the corrections requested by the Architect on previous submissions. PARD Service Center Project Page 32 of 58 Byrne CMAR Construction Contract June 2019 , The Architect's approval of Shop Drawings or Samples shall not relieve the CMAR of responsibility for any deviation from the requirements of the Contract Documents unless the CMAR has informed the Architect in writing of such deviation at the time of submission and the Architect has given written approval to the specific deviation. .Architect's approval of the shop drawings shall not relieve the CMAR from responsibility for errors or omissions in the Shop Drawings or Samples. No portion of the Work requiring a Shop Drawing or Sample submission shall be commenced until the Architect has approved the submittal.All such portions of the Work shall be in accordance with approved Shop Drawings and Samples. D-18 SITE USE. The CMAR shall confine operations at the site to areas permitted by law, ordinances, permits and the Contract Documents and shall not unreasonably encumber the site with any materials or equipment. Until acceptance of the work by the City Council of the City of Fort Worth,the entire site of the Work shall be under the exclusive control,care and responsibility of the CMAR. CMAR shall take every precaution against injury or damage to persons or property by the action of the elements or from any other cause whatsoever. The CMAR shall rebuild, repair, restore and make good at its own expense all injuries or damages to any portions of the Work occasioned by any of the above,caused before acceptance. D-22 CUTTING AND PATCHING OF WORK. The CMAR shall do all cutting, fitting or patching of its Work that may required to make its several parts fit together properly, and shall not endanger any Work by cutting, excavating or otherwise altering the Work or any part of it. D-23 CLEAN UP. The CMAR at all times shall keep the premises free from accumulation of waste materials or rubbish.At the completion of the Work it shall remove all its waste materials and rubbish from and about the Project as well as all its tools, construction equipment, machinery and surplus materials,and shall clean all glass surfaces and leave the Work"Broom-clean"or its equivalent,except at otherwise specified. In addition to removal of rubbish and leaving the buildings"broom-clean", CMAR shall clean all glass, replace any broken glass, remove stains, spots, marks and dirt from decorated work,clean hardware, remove paint spots and smears from all surfaces,clean fixtures and wash all concrete,tile and terrazzo floors. If the Contractor fails to clean up,the Owner may do so,and the cost thereof shall be charged to the Contractor. D-24 COMMUNICATIONS. As a general rule,the CMAR shall forward all communications to the Owner through the Architect, and in all other instances the CMAR shall furnish the Architect a copy of any communication sent directly to the Owner. SECTION E SUBCONTRACTORS E-1 DEFINITION. A Subcontractor is a person or organization that has a direct contract with the CMAR to perform any of the work at the site. The term Subcontractor is referred to throughout the Contract Documents as if singular in number and masculine in gender and means a Subcontractor or his authorized representative. Nothing contained in the Contract, Documents shall create any contractual relation between the Owner and the Architect and any subcontractor or any of his sub-subcontractors or materialmen. E-2 AWARD OF SUBCONTRACTS. The CMAR shall comply with all requirements of Section 271.118 and Chapter 252, Texas Local Government Code, in advertising and awarding contracts to subcontractors. Owner shall comply with the requirements of Section of 271.1180),Texas Local Government Code. CMAR must publicly advertise and solicit competitive bids or competitive sealed proposals for all major elements of work other than General Conditions. To Self-Perform work,the CMAR must submit a bid or proposal in same manner as trade subcontractors and subcontractors. The CMAR shall not make any substitution for any Subcontractor or person or organization that has been accepted by the Owner and the Architect, unless the substitution is also acceptable to the Owner and the Architect. E-3 TERMS OF SUBCONTRACTS. All work performed for the Contractor by a Subcontractor shall be pursuant to an .� appropriate agreement between the CMAR and the Subcontractor (and where appropriate between Subcontractors and Sub- subcontractors)which shall contain provisions that: 1. preserve and protect the rights of the Owner and the Architect under the Contract with respect to the Work to be performed under the subcontract so that the subcontracting thereof will not prejudice such rights; 2. require that such Work be performed in accordance with the requirements of the Contract Documents; 3. require submission to the CMAR of applications for payment under each subcontract to which the Contractor is a party, in reasonable time to enable the Contractor to apply for payment; 4. require that all claims for additional costs, extensions of time,damages for delays or otherwise with respect to subcontracted portions of the Work shall be submitted to the CMAR(via any Subcontractor or Sub-subcontractor where appropriate) in the manner provided in the Contract Documents for like claims by the CMAR upon the Owner; 5. waive all rights the contracting parties may have against one another for damages caused by fire or other perils covered by the property insurance,except such rights,if any,as they may have to proceeds of such insurance held by the Owner,and, 6. obligate each Subcontractor specifically to consent to the provisions of this Section PARD Service Center Project Page 33 of 58 Byrne CMAR Construction Contract . June 2018 All of the provisions set out in this section shall be deemed to have been included in every subcontract,and every subcontract shall be so construed and applied as to the Owner and the Architect,whether or not such provisions are physically included in the sub- ! contract. E-4 MINORITY AND WOMENS BUSINESS ENTERPRISE(M/WBE) The City will consider the CMAR's performance on other City Projects regarding its M/WBE program in the evaluation of bids. — Failure to comply with the City's M/WBE program, or to demonstrate a "good faith effort", shall result in a bid being considered irresponsible. Upon request, CMAR must provide the City with complete and accurate information regarding actual work performed by a Minority or Women Business Enterprise (M/WBE) on the contract and proof of payment thereof. CMAR further agrees to permit an audit and/or examination of any books, records or files in it's possession that will substantiate the actual work performed by an M/WBE. The misrepresentation of acts (other than a negligent misrepresentation) and/or the commission of fraud by the CMAR will be grounds for termination of the contract and/or initiating action under appropriate federal,state,or local laws or ordinances relating to false statement. Further any such misrepresentation (other than a negligent misrepresentation) and/or commission of fraud will result on the CMAR being determined to be irresponsible and barred from participating in City work for a period of time of not less than three years. CMAR shall provide copies of subcontracts or cosigned letters of intent with approved M/WBE subcontractors prior to execution of the contract. CMAR shall also provide monthly reports on utilization of the subcontractors to the M/WBE Office. The CMAR may count any tier subcontractors and/or suppliers toward meeting the goals. The CMAR may count toward its goal a portion of the total dollar amount of the contract with a joint venture equal to the percentage of the M/WBE participation in the joint —. venture for a clearly defined portion of the work to be performed. All subcontractors used in meeting the goals must be certified by either the North Central Texas Regional Certification Agency or by Texas Department of Transportation, Highway Division prior to the award of the Contract. Whenever a change order affects the work of an M/WBE subcontractor or supplier, the M/WBE shall be given an opportunity to perform the work. Whenever a change order is in excess of 10% of the original contract, the M/WBE coordinator shall determine the goals applicable to the work to be performed under the change order. During the term of the contract the CMAR shall: — 1. Make no unjustified changes or deletions in its M/WBE participation commitments submitted with or subsequent to the bid, and, 2. If substantial subcontracting and/or substantial supplier opportunities arise during the term of the contract which the CMAR had represented he would perform with his forces,the CMAR shall notify the City before subcontracts or purchase orders are let,and shall be required to comply with modifications to goals as determined by the City,and, 3. Submit a REQUEST FOR APPROVAL OF CHANGE FORM, if the CMAR desires to change or delete any of the M/WBE — subcontractors or suppliers. Justification for change may be granted for the following: 1. Failure of subcontractor to provide evidence of coverage by Workers'Compensation Insurance w 2. Failure of subcontractor to provide required general liability or other insurance. 3. Failure of subcontractor to execute a standard subcontract form in the amount of the proposal used by the CMAR in preparing his M/WBE Participation plan 4. Default by the M/WBE subcontractor or supplier in the performance of the subcontract. Other reasons at the discretion of the M/WBE Coordinator Before final payment from the City, the CMAR shall provide the M/WBE Office with documentation to reflect final participation of each M/WBE subcontractor and supplier used on the project. Upon verification by the M/WBE Office that the CMAR has fulfilled it's the M/WBE goal commitment with bond fide M/WBEs performing commercially useful functions, a recommendation will be made to the Director,Transportation and Public Works that no reduction in fee should be withheld from the final payment. E-5 PAYMENTS TO SUBCONTRACTORS. The CMAR shall pay each Subcontractor, upon receipt of payment from the Owner, an amount equal to the percentage of completion allowed to the CMAR on account of such Subcontractor's Work. The CMAR shall also require each Subcontractor to make similar payments to his subcontractors. If the Architect refuses to issue a Certificate for Payment for any cause which is the fault of the CMAR and not the fault of a particular subcontractor, the CMAR shall pay that Subcontractor on demand, made at any time after the Certificate for Payment would otherwise have been issued,for his Work to the extent completed, less the retained percentage. The CMAR shall pay each Subcontractor a just share of any insurance monies received by the Contractor, and he shall require each Subcontractor to make similar payments to his Subcontractors. PARD Service Center Project Page 34 of 58 Byrne CMAR Construction Contract June 2018 The Architect may, on request and at its discretion,furnish to any Subcontractor, if practicable, information regarding percentages of completion certified to the CMAR on account of Work done by such Subcontractors. Neither the Owner nor the Architect shall have any obligation to pay or to see to the payment of any monies to any Subcontractor. SECTION F SEPARATE CONTRACTS F-1 OWNER'S RIGHT. The Owner reserves the right to award separate contracts in connection with other portions of the Work. When separate contract are awarded for other portions of the Work, "the Contractor' in the Contract Documents in each case shall be the contractor who signs each separate contract. F-2 MUTUAL RESPONSIBILITY OF CONTRACTORS. The CMAR shall afford other contractors reasonable opportunity for the introduction.and storage of their materials and equipment and the execution of their work, and shall properly connect and coordinate his work with theirs. If any part of the CMAR's Work depends for proper execution or results upon the work of any other separate contractor,the CMAR shall inspect and promptly report to the Architect any apparent discrepancies or defects in such work that render it unsuitable for such proper execution and results. Failure of the CMAR to inspect and report shall constitute an acceptance of the other contractors work as fit and proper to receive his Work, except as to defects which may develop in the other separate contractor's work after the execution of the Contractor's Work. Should the CMAR cause damage to the work or property of any separate contractor on the site,the CMAR shall, upon due notice, settle with such other contractor by agreement, if he will so settle. If such separate contractor sues the Owner on account of any damage alleged to have been so sustained,the Owner shall notify the CMAR who shall defend against such suit at the Contractors expense, and if any judgment against the Owner arises therefrom, the CMAR shall pay or satisfy such judgment and shall reimburse the Owner for all attorney's fees,court costs and expenses which the Owner has incurred in connection with such suit. F-3 CUTTING AND PATCHING UNDER SEPARATE CONTRACTS. The CMAR shall do all cutting,fitting or patching of his Work that may be required to fit it to receive or be received by the work of other contractors shown in the Contract Documents.The CMAR shall not endanger any work or any other contractors by cutting,excavating or otherwise altering any work and shall not cut or alter the work of any other contractor except with the written consent of the Architect. Any costs caused by defective or ill-timed work shall be borne by the party responsible therefore. F-4 OWNER'S RIGHT TO CLEAN UP. If a dispute arises between the separate contractors as to their responsibility for cleaning up, the Owner may clean up and charge the cost thereof to the several contractors as the Director of the Department of Transportation and Public Works shall determine to be just. SECTION G MISCELLANEOUS PROVISIONS G-1 CONFLICT OF LAWS. The Contractor must familiarize himself and strictly comply with all Federal, State, and County and City Laws,Statutes, Charter, Ordinances, Regulations, or Directives controlling the action or operation of those engaged upon the work affecting the materials used. He shall indemnify and save harmless the City and all of its officers and agents against any claim or liability arising from or based on the violation of any such Laws, Statutes, Charter, Ordinances, Regulations,or Directives, whether by himself,his employees,agents or subcontractors. G-2 GOVERNING LAWS AND VENUE. It is mutually agreed and understood that this agreement is made and entered into by the parties hereto with reference to the existing Charter and Ordinances of the City of Fort Worth and the laws of the State of Texas with reference to and governing all matters affecting this Contract, and the Contractor agrees to fully comply with all the provisions of the same. Venue for any cause of action arising out of this Contract shall lie exclusively in the state courts of Tarrant County,Texas and contracts consents to such jurisdiction. G-3 PERSONAL LIABILITY OF PUBLIC OFFICIALS. In performing their duties under the Statutes of the State of Texas and the Charter and Ordinances of the City of Fort Worth in connection with this Contract,or in exercising any of the powers granted the Owner herein, the officers, agents and employees of the City of Fort Worth are engaged in the performance of a governmental function and shall not incur any personal liability by virtue of such performance hereunder, except for gross negligence or willful wrong. G-4 COMPLIANCE WITH LAWS. CMAR agrees to comply with all laws, Federal, state and local, including all ordinances, rules and regulations of the City of Fort Worth, Texas. Materials incorporated into the finished Project are not subject to State Sales Tax. CMAR and any subcontractors are responsible for obtaining construction permits from the governing agencies. CMAR shall schedule all code inspections with the Code Inspection Division in accordance with the permit requirements and submit a copy of updated schedule to the Construction manager weekly. Building, plumbing, electrical and mechanical building permits are issued without charge. Water and sewer access fees and impact fees will be paid by the City. Any other permit fees are the responsibility of the Contractor. G-5 INDEMNIFICATION: CMAR covenants and agrees to indemnify City's engineer and architect, and their personnel at the project site for CMAR's sole negligence. In addition, CMAR covenants and agrees to indemnify, hold harmless and defend, at its PARD Service Center Project Page 35 of 58 Byrne CMAR Construction Contract June 2018 own expense, the Owner, its officers, servants and employees, from and against any and all claims or suits for property loss, property damage, personal injury, including death, arising out of, or alleged to arise out of, the work and services to be performed hereunder by CMAR, its officers, agents, employees, subcontractors, licensees or invitees, whether or not any such iniury. '! damage or death is caused,in whole or in part,by the negligence or alleged negligence of Owner,its officers servants or employees. CMAR likewise covenants and agrees to indemnify and hold harmless the Owner from and against any and all injuries to Owner's officers, servants and employees and any damage, loss or destruction to property of the Owner arising from the performance of any of the terms and conditions of this Contract,whether or not any such injury or damage is caused in whole or in part by the negligence or alleged negligence of Owner,its officers,servants or employees. In the event Owner receives a written claim for damages against the CMAR or its subcontractors prior to final payment, final payment shall not be made until CMAR either(a)submits to Owner satisfactory evidence that the claim has been settled and/or a -- release from the claimant involved, or(b) provides Owner with a letter from CMAR's liability insurance carrier that the claim has been referred to the insurance carrier. The Director may, if he deems it appropriate, refuse to accept bids on other City of Fort Worth public work from a CMAR against _ whom a claim for damages is outstanding as a result of work performed under a City Contract. G-6 SUCCESSORS AND ASSIGNS. Except as provided in Paragraph E-2, this contract shall be binding upon and insure to the benefit of the parties hereto,their Successors or Assigns. CMAR shall not assign or sublet all or any part of this Contract or his rights or duties hereunder without the prior written consent of the Owner.Any such purported assignment or subletting without the T prior written consent of Owner shall be void. G-7 WRITTEN NOTICE. Written Notice shall be deemed to have been duly served if delivered in person to the individual or member of the firm or to an officer of the corporation for whom it was intended, or if delivered at or sent by registered or certified mail to the last business address known to him who gives the notice. G-8 SURETY BONDS: Surety Bonds are required on all Owner contracts in excess of $25,000. CMAR agrees, on the execution of the contract to make, execute and deliver to said City of Fort Worth good and sufficient surety bonds for the faithful performance of the terms and stipulations of the Contract and for the payment to all claimants for labor and/or materials furnished in the prosecution of the work,such bonds being as provided and required in Chapter 2253,Texas Government Code. Bonds shall be made on the forms furnished by or otherwise acceptable to the Owner. Both the Contractor and the Surety Company shall properly execute each bond. If the total contract price is$25,000 or less,payment to the contractor shall be made in one lump sum. Payment shall not be made for a period of 45 calendar days from the date the work has been completed and accepted by the Owner. If the contract amount is in excess of$25,000, a Payment Bond shall be executed, in the amount of the contract, solely for the protection of all claimants supplying labor and material in the prosecution of the work. If the contract amount is in excess of$100,000, a Performance Bond shall be executed, in the amount of the contract conditioned on the faithful performance of the work in accordance with the plans, specifications, and contract documents. Said bond shall solely be for the protection of the City of Fort Worth. In order for a surety to be acceptable to the Owner, the surety must (1) hold a certificate of authority from the Untied States secretary of the treasury to qualify as a surety on obligations permitted or required under federal law; or (2) have obtained reinsurance for any liability in excess of$100,000 from a reinsurer that is authorized and admitted as a reinsurer in the state of Texas and is the holder of a certificate of authority from the Untied States secretary of the treasury to qualify as a surety on obligations permitted or required under federal law. Satisfactory proof of any such reinsurance shall be provided to the Owner upon request. The Owner,in its sole discretion,will determine the adequacy of the proof required herein. No sureties will be accepted by the Owner that are at the time in default or delinquent on any bonds or which are interested in any litigation against the Owner. Should any surety on the contract be determined unsatisfactory at any time by the Owner, notice will be given to the CMAR to that effect and the CMAR shall immediately provide a new surety satisfactory to the Owner G-9 OWNER'S RIGHT TO CARRY OUT THE WORK. If the CMAR defaults or neglects to carry out the Work in accordance with the Contract Documents or fails to perform any provision of the Contract, the Owner may, without prejudice to any other remedy he may have,enter the site and make good such deficiencies. In such case an appropriate Change Order shall be issued deducting from the payments then or thereafter due the CMAR the cost of correcting such deficiencies, including the cost of the Architect's additional services made necessary by such default, neglect or failure. if the payments then or thereafter due the CMAR are not sufficient to cover such amount,the CMAR or its surety shall pay the difference to the Owner. G-10 ROYALTIES AND PATENTS. The CMAR shall pay all royalties and license fees. He shall defend all suits or claims for infringement of any patent rights and shall save the Owner harmless from loss on account thereof and shall be responsible for all such loss when a particular design, process or the product of a particular manufacturer or manufacturers is specified; however, if the CMAR has reason to believe that the design, process or product specified is an infringement of a patent, he shall be responsible for such loss unless he promptly gives such information to Architect. G-11 INTERRUPTION OF EXISTING UTILITIES SERVICES. The CMAR shall perform the work under this Contract with a minimum of outage time for all utilities. Interruption shall be by approved sections of the utility. In some cases, the CMAR may be required to perform the work while the existing utility is in service. The existing utility service may be interrupted only when approved by the Owner. When it is necessary to interrupt the existing utilities, the CMAR shall notify the,Owner in writing at least ten days in advance of the time that he desires the existing service to be interrupted. The interruption time shall be kept to a PARD Service Center Project Page 36 of 58 Byrne CMAR Construction Contract June 2018 minimum. Depending upon the activities at an existing facility that requires continuous service from the existing utility, an interruption may not be subject to schedule at the time desired by the CMAR. In such cases, the interruption may have to be scheduled at a time of minimum requirements of demand for the utility. The amount of time requested by the CMAR of existing utility services shall be as approved by the Owner. G-13 LAYING OUT WORK. The CMAR shall verify dimensions and elevations indicated in layout of existing work. Discrepancies between Drawings, Specifications, and existing conditions shall be referred to Architect for adjustment before work affected is performed. Failure to make such notification shall place responsibility upon CMAR to carry out work in satisfactory workmanlike manner at the CMAR's sole expense. The CMAR shall be held responsible for the location and elevation of all the construction contemplated by the Construction Documents. Prior to commencing work, the CMAR shall carefully compare and check all Architectural, Structural, Mechanical an Electrical drawings; each with the other that in any affects the locations or elevation of the work to be executed by him, and should any discrepancy be found, he shall immediately report the same to the Architect for verification and adjustment.Any duplication of work made necessary by failure or neglect on his part to comply with this function shall be done at the CMAR's sole expense. G-14 MEASUREMENTS: Before ordering any material or doing any work,the CMAR shall verify all measurements at the site or at the building and shall be wholly responsible for the correctness of same. No extra charge or compensation will be allowed on account of any difference between actual dimensions and dimensions indicated on the drawings. Any difference which may be found shall be submitted to the Architect for consideration and adjustment before proceeding with the project. G-15 EXISTING OVERHEAD OR UNDERGROUND WORK. The CMAR shall carefully check the site where the project is to be erected and observe any existing overhead wires and equipment. Any such work shall be moved, replaced or protected, as required,whether or not shown or specified at the CMAR's sole expense. �• Attention is directed to the possible existence of pipe and other underground improvements that may or may not be shown on the Drawings.All reasonable precautions shall be taken to preserve and protect any such improvements whether or not shown on the Drawings. Location of existing underground lines shown on the Drawings are based on the best available sources, but are to be regarded as approximate only.Exercise extreme care in locating and identifying these lines before excavation in adjacent areas. G-16 ALIGNMENT OF JOINTS IN FINISH MATERIALS. It shall be the responsibility of the CMAR to make certain in the installation of jointed floor,wall and ceiling materials that: 1. Preserve and protect the rights of the Owner and the Architect under the Contract with respect to the Work to be performed under the subcontract so that the subcontracting thereof will not prejudice such rights; 2. Place joints to relate to all opening and breaks in the structure and be symmetrically placed wherever possible.This includes ^' heating registers,light fixtures,equipment,etc. If because of the non-related sizes of the various materials and locations of openings, etc., it is not possible to accomplish the above,the CMAR shall request the Architect to determine the most satisfactory arrangement.The CMAR shall establish centerlines for all trades. G-17 INTEGRATING EXISTING WORK. The CMAR shall protect all existing street and other improvements from damages. CMAR's operations shall be confined to the immediate vicinity of the new work and shall not in any interfere with or obstruct the ingress or egress to and from existing adjacent facilities. Where new site work is to be connected to existing work,special care shall be exercised by the CMAR not to disturb or damage the existing work more than necessary.All damaged work shall be replaced, repaired and restored to its original condition at no cost to the Owner. G-18. HAZARDOUS MATERIAL CERTIFICATION: It is the intent of the contract documents,whether expressly stated or not, that nothing containing hazardous materials, such as asbestos, shall be incorporated in to the project. CMAR shall exercise every reasonable precaution to ensure that hazardous materials are not incorporated into any portion of the project, including.advising all materials suppliers and subcontractors of this requirement. The CMAR shall verify that components containing lead do not contact the potable water supply. G-19 LOCATION OF EQUIPMENT AND PIPING. Drawing showing location of equipment, piping, ductwork, etc. are diagrammatic and job conditions may not always permit their installation in the location shown.When this situation occurs, it shall be brought to the Architect's attention immediately and the relocation determined in a joint conference. The CMAR will be held responsible for the relocating of any items without first obtaining the Architect's approval. He shall remove and relocate such items at his own expense if so directed by the Architect.Where possible, uniform margins are to be maintained between parallel lines and or adjacent wall,floor or ceiling surfaces. G-20 OVERLOADING. The CMAR shall be responsible for loading of any part or parts of structures beyond their safe carrying capacities by placing of materials, equipment, tools, machinery or any other item thereon. No loads shall be placed on floors or roofs before they have attained their permanent and safe strength. PARD Service Center Project Page 37 of 58 Byrne CMAR Construction Contract June 2018 G-21 MANUFACTURER'S INSTRUCTIONS. Where it is required in the Specifications that materials, products, processes, equipment,or the like be installed or applied in accordance with manufacturer's instructions,direction or specifications,or words to this effect, it shall be construed to mean that said application or installation shall be in strict accordance with printed instructions furnished by the manufacturer of the material concerned for use under conditions similar or those at the job site.Six copies of such instructions shall be furnished to the Architect and his approval thereof obtained before work is begun. G-22 CLEANING UP. The CMAR shall keep the premises free from accumulation of waste material or rubbish caused by employees,its subcontractors or as a result of the work. At completion of work, the CMAR shall, immediately prior to final inspection of complete building, execute the following final cleaning work with trained janitorial personnel and with material methods recommended by the manufactures of installed materials. 1. Sweep and buff resilient floors and base, and vacuum carpeting. 2. Dust all metal and wood trim and similar finished materials. 3. Clean all cabinets and casework. 4. Dust all ceilings and walls. 5. Dust,and if necessary wash,all plumbing and electrical fixtures. 6. Wash all glass and similar non-resilient materials. 7. All hardware and other unpainted metals shall be cleaned and polished and all equipment and paint or decorated work shall be cleaned and touched-up if necessary, and all temporary labels, tags, and paper coverings removed throughout the buildings. Surfaces that are waxed shall be polished. 8. The exterior of the building,the grounds, approaches,equipment,sidewalks,streets,etc.shall be cleaned similar to interior of buildings and left in good order at the time of final acceptance. All paint surfaces shall be clean and unbroken, hardware shall be clean and polished,all required repair work shall be completed and dirt areas shall be scraped and cleared of weed growth. 9. Clean all glass surfaces and mirrors of putty, paint materials,etc.,without scratching or injuring the glass and leave the work — bright,clean and polished.Cost of this cleaning work shall be borne by CMAR. 10. Cleaning, polishing, scaling,waxing and all other finish operations indicated on the Drawings or required in the Specifications shall be taken to indicate the required condition at the time of acceptance of all work under the Contract. 11. Burning:Burning of rubbish on the premises will not be permitted. G-23 DUST CONTROL. Precaution shall be exercised at all times to control dust created as a result of any operations during the construction period. If serious problems or complaints arise due to air-borne dust, or when directed by the Architect,operations — causing such problems shall be temporarily discontinued and necessary steps taken to control the dust. G-24 FIRE PROTECTION. The CMAR shall at all times maintain good housekeeping practices to reduce the risk of fire damage or injury to workmen.All scrap materials, rubbish and trash shall be removed daily from in and about the building and shall �- not be scattered on adjacent property. Suitable storage space shall be provided outside the immediate building area for storing flammable materials and paints; no storage will be permitted in the building. Excess flammable liquids being used inside the building shall be kept in closed metal ... container and removed from the building during unused periods. A fire extinguisher shall be available at each location where cutting or welding is being performed.Where electric or gas welding or cutting work is done, interposed shields of incombustible material shall be used to protect against fire damage due to sparks and hot metal.When temporary heating devices are used, a watchman shall be present to cover periods when other workmen are not on the premises. The CMAR shall provide fire extinguishers in accordance with the recommendations and NFPA Bulletins Nos. 10 and 241. However,in all cases a minimum of two fire extinguishers shall be available for each floor of construction. — G-25 CUTTING AND PATCHING Wherever cutting and removal of portions of the existing work is indicated, such work shall be neatly sawed or cut by CMAR in a manner that will produce a neat straight line,parallel to adjacent surfaces or plumb for vertical surfaces.Care should be exercised not to damage any work that is to remain. — At no time shall any structural members be cut without written consent from the Architect. G-26 PROJECT CLOSEOUT. Final Inspection,Record Drawings:Attention is called to General Conditions Section I entitled,"Payments and Completion." Maintenance Manual:Sheets shall be 8%"x 11",except pull out sheets may be neatly folded to 8%"x 11".Manuals shall be bound in plastic covered,3 ring,loose leaf binder with title of project lettered on front and shall contain: — PARD Service Center Project Page 38 of 58 Byrne CMAR Construction Contract June 2018 1) Name,address and trade of all sub-contractors. 2) Complete maintenance instructions; name, address, and telephone number of installing CMAR, manufacturer's local representative,for each piece of operative equipment. 3) Catalog data on plumbing fixtures, valves, water heaters, heating and cooling equipment, temperature control,fan, electrical panels,service entrance equipment and light fixtures. 4) Manufacturer's name, type, and color designation for resilient floors, windows, doors, concrete block, paint, roofing, other materials. Submit two electronic and 1 hard copy Maintenance Manual,prior to request for final payment. Operational Inspection and Maintenance Instruction: The CMAR shall provide at its expense, competent manufacturer's representatives to completely check out all mechanical and electrical systems and items covered by the Drawings and Specifications. This requirement shall be scheduled just prior to and during the initial start up. After all systems are functioning properly the representatives shall instruct maintenance personnel of the Owner in the proper operation and maintenance of.each item. G-27 GUARANTEE AND EXTENDED GUARANTEE. Upon completion of the Project, prior to final payment, guarantees required by technical divisions of Specifications shall be properly executed in quadruplicate by subcontractors and submitted through the CMAR to Architect.Delivery of guarantees shall not relieve CMAR from any obligation assumed under Contract. The CMAR shall guarantee the entire Project for one year. In addition,where separate guarantees,for certain portions of work,are for longer periods, CMAR's guarantee shall be extended to cover such longer periods. Manufacturer's extended warrantees shall be included in this contract. i Guarantees shall become valid and operative and commence upon issuance of Certificate of Inspection and Acceptance by Owner. Guarantees shall not apply to work where damage is result of abuse, neglect by Owner or his successor(s)in interest. CMAR agrees to warrant its work and materials provided in accordance with this contract and the terms of the Technical Specifications contained herein. Unless supplemented by the Technical Specifications or the manufacturer's normal extended warrantees, the CMAR shall warrant all work materials, and equipment against defects for a period of one year from the date of final acceptance. CMAR further agrees to bear all costs of making good all work that is found to be defective or not provided in accordance with the Contract Documents. Additionally if the facility or contents are damaged due to defective materials or workmanship of the CMAR,the CMAR further agrees to bear all cost of repairing and/or replacing damaged items and components to bring such items back to at least their original condition. G-28 RECORD DRAWINGS. Upon completion of the Work and prior to application for final payment, one print of each of the drawings accompanying this specification shall be neatly and clearly marked in red by the CMAR to show variations between the construction actually provided and that indicated or specified in the Contract Documents. The annotated documents shall be delivered to Architect. Where a choice of materials and/or methods is permitted herein and where variations in the scope or character of the work from the entire work indicated or specified are permitted either by award of bidding items specified for,that purpose, or by subsequent change to the drawings, the record drawings shall define the construction actually provided. The representation of such variations shall conform to standard drafting practice and shall include supplementary notes, legends and details which may be necessary for legibility and clear portrayal of the actual construction. The record drawings shall indicate, in addition,the actual location of all sub-surface utility lines,average depth below the surface and other appurtenances, G-29 CONSTRUCTION FENCE.-At the CMAR's option,it may provide a substantial chain-link construction fence around all or a part of the site. The fences and gates must be maintained throughout the construction period. Remove the fences and gates upon completion of the Project and restore the site to the required original or contract condition. G-30 PRODUCT DELIVERY, STORAGE, HANDLING. CMAR shall handle, store and protect materials and products, including fabricated components, by methods and means which will prevent damage, deterioration and loss, including theft (and resulting delays), thereby ensuring highest quality results as the work progresses. Control delivery schedules so as to minimize unnecessary long-term storage at project site prior to installation. G-31 REMOVAL OF SALVAGED MATERIAL. The CMAR shall remove salvaged material and equipment from the Project site and dispose of it in accordance with the law. Equipment or material identified in the Specifications or Plans for Owner salvage shall be carefully removed and delivered to the Owner at any location within the City limits as directed by the City. G-32 MANUFACTURER'S REFERENCE: Catalog, brand names, and manufacturer's references are descriptive, not restrictive. Bids on brands of like nature and quality will be considered.CMAR shall inform the City of any substitutions intended for the project within 5 business days of execution of the contract. Failure to inform the City of substitute projects will obligate the CMAR to provide the specified material. Within 14 days after execution of the contract and upon request of the architect or contractor,the CMAR will submit a full sized sample and/or detailed information as required allowing the architect to determine the acceptability of proposed substitutions. Where equipment has been listed as "no substitute accepted", the City will accept no alternates to the specified equipment. PARD Service Center Project Page 39 of 58 �. Byrne CMAR Construction Contract June 2018 SECTION H ✓ CONTRACT TIME H-1 DEFINITIONS. The Contract Time is the period of time allotted in the Contract Documents for completion of the Work. The date of commencement of the Work is the date established in the Notice to Proceed. If there is no notice to proceed,it shall be the date of the Agreement or such other date as may be established therein. The Date of Substantial Completion of the Work or designated portion thereof is the Date certified by the Architect with the approval of the Owner'that construction is sufficiently complete, in accordance with the Contract Documents, so the Owner may occupy the Work or designated portion thereof for the use for which it is intended. Final acceptance of the completed work or any portion — thereof can be made only by Owner,and no other form of acceptance will be binding upon the Owner. A calendar day constitutes 24 hours of time and is any one of the seven days of a week, including Sunday, regardless of whether a "Working Day' or not, and regardless of weather conditions or any situation which might delay construction. An extension of — contract time shall be in accordance with this Section. Extensions of time will be as recommended by the Architect with final approval by City of Fort Worth. A working day is defined as a calendar day, not including Saturdays, Sundays, and legal holidays, in which weather or other conditions not under the control of the Contractor permit the performance of work for a continuous period of not less than seven 4 hours between 7:00 a.m. and 6:00 p.m. However, nothing in these Contract Documents shall be construed as prohibiting the Contractor from working on Saturdays if he so desires. Should the Contractor choose to work on Saturdays, one day will be charged as contract-working time when weather or other conditions permit seven hours of work as delineated above.Legal holidays are defined as being New Year's Day, Martin Luther King Day, Independence Day, Labor Day, Thanksgiving Day, the day After Thanksgiving,Christmas Day, and Memorial Day. If Christmas Day or New Year's Day falls on a Saturday,the preceding Friday is a legal holiday. If Christmas Day or New Year's Day falls on a Sunday,the following Monday will be a legal holiday. H-2 PROGRESS AND COMPLETION. All the time limits stated in the Contract Documents are of essence to the Contract. w CMAR shall begin the Work on the date of commencement as defined in this Section and carry the Work forward expeditiously with adequate forces and shall complete it within the Contact Time. H-3 DELAYS AND EXTENSIONS OF TIME. If the CMAR is delayed at any time in the progress of the Work by any act or neglect of the Owner or the Architect, or by any employee of the Owner,or by any separate contractor employed by the Owner, or by changes ordered in the Work, or by labor disputes, fire, unusual delay in transportation, unavoidable casualties or any causes beyond the CMAR's control, or by any cause which the Architect determines may justify the delay, then the contract time may be extended by Change Order for such reasonable time as recommended by the Architect and approved by the Owner. When the CMAR is delayed due to abnormal weather conditions, the Fort Worth Weather Table provided in these Contract Documents shall be used as the basis for providing a fair and equitable adjustment of the contract time. All claims for extension of time shall be made in writing to the Architect no more than fifteen days after the occurrence of the delay; otherwise they'shall be waived. If no schedule or agreement is made stating the dates upon which written interpretations shall be furnished,then no claim for delay shall be allowed on account of failure to furnish such interpretation until fifteen days after demand is made for them, and not then unless such a claim is reasonable. H-4 WEATHER. The Fort Worth Weather Table is to be used as a basis for calculation of excess rain or weather days for projects with duration in calendar days. If the site records indicate that the Contractor was unable to carry out operations due to weather, it is counted as a weather day. If the number of weather days exceeds the number of average rain days plus the snow/ice-pellet days for the contract duration,the contract period will be adjusted by Change Order. H-5 NO DAMAGE FOR DELAY. Not withstanding anything to the contrary contained herein, the CMAR shall never be entitled to any compensation or damages for delay of any nature. In that regard, the CMAR shall receive no compensation for delays or hindrances to the work,except when direct and unavoidable extra cost to the CMAR is caused by the failure of the Owner to provide information or material. If any, which is to be furnished by the Owner. When such extra compensation is claimed a written statement thereof shall be presented by the CMAR to the Architect and if found to be correct shall be approved and referred by him to the Council for final approval or disapproval; and the action thereon by the Council shall be final and binding. If delay is caused by specific orders given by the Architect or Owner to stop work,or by the performance of extra work,or by the failure of the Owner to provide material or necessary instructions for carrying on the work,then such delay will entitle the CMAR to an equivalent extension of time, his application for which shall, however, be subject to the approval of the Owner and no such extension of time shall release the CMAR or the surety on its performance bond from all his obligations here under which shall remain in full force until the discharge of the contract. SECTION I PAYMENTS AND COMPLETION 1 GAURANTEED MAXIMUM PRICE AND GMAR FEE. The GuaFanteed Maximum PFiG8("GIVIR")as stated in the GGntraGt GentFaGteF will be re*mbuF6ed for the aGtual Gest f9F the GenstFuGtian inGluding buFdens up to the amount of the GMP. He will also- be paid a management fee aGGOrding to the following sGhedule� a 20%of fee upon ,.,,ti. of the GMAR AgFeement PARD Service Center Project Page 40 of 58 Byrne CMAR Construction Contract June 2018 _ 5004 of the fee&FiRg GGRGtFUGtiGR in propertien to the value of woFk GGFRpleted. o prGjeGt. 1-2 SCHEDULE OF VALUES. Before the first Applicable for Payment for construction, the CMAR shall submit to the Architect a Schedule of Values of the various portions of the Work, including quantities if required by the Architect, aggregating the total expected construction cost or current GMP whichever is less, divided so as to facilitate payments to Subcontractors,prepared in such form as specified or as the Architect and the CMAR may agree upon, and supported by such data to substantiate its correctness as the Architect may require. Each item in the Schedule of Values shall include its proper share of overhead and profit. This Schedule,when approved by the Architect and the Owner,shall be used as a basis for the CMAR's Applications for Payment. 1-3 PROGRESS PAYMENTS. On the first day of each month after the first month's work has been completed, the CMAR will make current estimates in writing for review by the Architect of materials in place complete and the amount of work performed during the preceding month or period and the value thereof at the prices contracted for as shown on the approved Schedule of Values and Progress Schedule. If payments are to be made on account of materials or equipment not incorporated in the Work but delivered and suitably stored at the site or in an independent, bonded warehouse, such payments shall be conditioned upon submission by the CMAR of bills of sale or such other procedures satisfactory to the Owner to establish the Owner's title to such materials or equipment or otherwise protect the Owner's interest including applicable insurance and transportation to the site. CMAR warrants and guarantees that title to all Work, materials and equipment covered by an Application for Payment, whether incorporated into the Project or not, will pass to the Owner upon the receipt of such payment by the CMAR , free and clear of all liens, claims, security interests or encumbrances hereinafter referred to as "liens"; and that no Work, materials or equipment covered by an Application for Payment will have been acquired by the CMAR, or by any other persons performing the Work at the site or furnishing materials and equipment for the Work, subject to an agreement under which an interest therein or an encumbrance thereon is retained by the seller or otherwise imposed by the CMAR or such other person. CMAR shall prepare each application for payment on AIA Document G702,"Application and Certificate for Payment", and attached thereto AIA Document G703, "Continuation Sheet", to indicate the progress made to date and the period or month for which payment is requested for each Item listed in the Schedule of Values. A copy of the revised monthly work progress schedule must be attached before the pay request can be accepted. 1-4 CERTIFICATES FOR PAYMENT. If the CMAR has made Application for Payment, the Architect will, with reasonable promptness but not more than seven days after the receipt of the Application, prepare a Certificate of Payment,with a copy to the CMAR,for such amount determined to be properly due,or state in writing reasons for withholding a Certificate. The issuance of a Certificate for Payment will constitute a representation by the Architect to the Owner, based on the Architect's observations at the site and the data comprising the Application for Payment,that the Work has progressed to the point indicated; that the quality of the Work is in accordance with the Contract Documents (subject to an evaluation of the Work as a functioning whole upon Substantial Completion,to the results of any subsequent tests required by the Contract Documents,to minor deviations from the Contract Documents correctable prior to completion, and to any specific qualifications stated in the Certificate); and recommendations to the Owner that the CMAR be paid in the amount certified. In addition,the Architect's approval of final payment assures the Owner that the conditions precedent to the CMAR being entitled to final payment as set forth in this Section have been fulfilled. After the Architect has issued a Certificate for Payment,the Owner shall approve or disapprove it within ten days after it has been delivered to the Director of the Property Management Department. For contracts less than $400,000, Owner shall pay 90%of the approved estimate to the Contractor within seven days after its approval, and the remaining 10% of each such estimate will be retained by the Owner until Substantial Completion. For contracts in excess of$400,000, the Owner will retain only 5% of each estimate until Substantial Completion. No Certificate for Payment, nor any progress payment, nor any partial or entire use or occupancy of the Project by the Owner,shall constitute an acceptance of any Work not in accordance with the Contract Documents, or relieve the Contractor of liability and responsibility in respect to any warranties or responsibility for faulty materials or workmanship. CMAR shall promptly remedy any defects in the Work and pay for any damage to other work resulting there from that shall appear within a period of one year from = the date of final acceptance of the Work unless a longer period is specified. 1-5 PAYMENTS WITHHELD. The Architect may decline to approve an Application for Payment and may withhold his Certificate in whole or in part if in his opinion he is unable to make the representations to the Owner as provided in this Section.The Architect may also decline to approve any Applications for Payment or, because of subsequently discovered evidence or subsequent inspections,may nullify the whole or any part of any Certificate for Payment previously issued to such extent as maybe necessary in his opinion to protect the Owner from loss because of: 1) Defective work not remedied; 2) Claims filed or reasonable evidence indicating probable filing of claims; 3) Failure of the CMAR to make payments properly to Subcontractors,or for labor,materials or equipment; 4) Reasonable doubt that the Work can be completed for the unpaid balance of the Contract Sum; 5) Damage to another contractor; PARD Service Center Project Page 41 of 58 Byrne CMAR Construction Contract June 2018 6) Reasonable indication that the Work will not be completed within the Contract Time;or 7) Unsatisfactory prosecution of the Work by the CMAR. When such grounds for the refusal of payment are removed, payment shall be made for amounts withheld because of them, without payment of interest. The Owner reserves the right to withhold the payment of any monthly estimate, without payment of interest,if the CMAR fails to perform the Work in accordance with the specifications or instructions of the Architect. _ 1-6 LIQUIDATED DAMAGES:CMAR and Owner agree that the following Liquidated Damages are reasonable with respect to the damages that Owner will sustain if the Project is not completed within the Contract Time. The deduction for liquidated damages shall be as follows: Amount of Contract Liquidated Damages Per Day $15,000 or less $45 $15,001 to $25,000 $63 $25,001 to $50,000 $105 $50,001 to $100,000 $154 $100,000 to $500,000 $210 $500,001 to$1,000,000 $315 �. $1,000,001 to$2,000,000 $420 $2,000,001 to$5,000,000 $630 $5,000,001 to$10,000,000 $840 Over$10,000,000 $980 1-7 FAILURE OF PAYMENT If, without fault on the part of the CMAR, the Architect should fail to issue any Certificate for Payment within seven days after receipt of the CMAR's Application for Payment, if the CMAR's Application for Payment, or if, without fault on the part of the CMAR, the Owner should fail to approve such estimate or to pay to the CMAR 90% or 95% (as applicable) of the amount thereof within the period of time specified,then the CMAR may, upon seven (7)days additional written notice to the Owner and to the Architect,stop the Work until payment of the amount owing has been received. 1-8 SUBSTANTIAL COMPLETION AND FINAL PAYMENT Prior to the request for final payment, the CMAR must meet all provisions for Project Closeout. When the CMAR determines that the Work is substantially complete, the City shall inspect the project with the CMAR and the contractor will prepare a"Preliminary Punch List". When the Architect, on the basis of a subsequent inspection, determines that the Work is substantially complete, he then will prepare a Certificate of Substantial Completion (G704) which, when approved by the Owner, shall allow the CMAR to request a Certificate of Occupancy which will establish the Date of Substantial Completion. The Certificate of Substantial Completion shall state the responsibilities of the Owner and the CMAR for maintenance, heat, utilities, and insurance, shall set forth the remaining work as a "final punch list". The CMAR shall complete the remaining work listed therein within 30 calendar days. When the — Certificate of Occupancy has been issued,the retainage may be reduced to 4%. Upon completion of the work listed on the final punch list to the satisfaction of the City of Fort Worth,the retainage may be reduced to 2.5%. ,t Should the CMAR fail to complete all contractual requirements of the contract, including submittals and final pay request within the fixed time, the contract time will again commence. Should the CMAR fail to complete the work within the contract duration, liquidated damages will be assessed Upon receipt of written notice that the Work is ready for final inspection, the City will conduct a joint inspection and certify completion of the final punch list by cosigning it with the CMAR. The CMAR shall submit the following items to the City prior to requesting final payment: .. 1) CMARs Affidavit of Payment of Debts and Claims(G706)stating that all payrolls, bills for materials and equipment,and other indebtedness connected with the Work for which the Owner or his property might in any way be responsible, have been paid or otherwise satisfied, 2) Consent of Surety to Final Payment(G707),if any,to final payment, 3) CMAR's Affidavit of Release of Liens(G706A),and, 4) Other data establishing payment or satisfaction of all such obligations,such as receipts, releases,and waivers of liens arising out of the Contract,to the extent and in such form as may be designated by the Owner. 5) CMAR's Warranty 6) Statement that all outstanding work has been completed 7) Issuance of the Final Certificate of Substantial Completion 8) Final acceptance by the City of Fort Worth. If any Subcontractor, materialman or laborer refuses to furnish a Contractor's Affidavit of Release of Liens,the CMAR may, at the election of the Owner, furnish a bond satisfactory to the Owner to indemnify him against any right, claim or lien which might be asserted by such Subcontractor, materialman or laborer. If any such right, claim or lien remains unsatisfied after all payments are made. The CMAR shall refund to the Owner all monies that the latter may be compelled to pay to discharging such right,claim or lien,including all costs and reasonable attorney's fees. — PARD Service Center Project Page 42 of 58 Byrne CMAR Construction Contract June 2018 The CMAR may then request final payment. The acceptance of final payment shall constitute a waiver of all claims by the CMAR except those previously made in writing and still unsettled. The CMAR's one-year warranty will commence upon final acceptance of the Project by the City of Fort Worth. The designated representative of the City of Fort Worth will make final acceptance and no other form of acceptance will be binding upon the Owner. 1-9 FINAL PAYMENT FOR UN-BONDED PROJECTS. Final payment will not be made for a period of 30 calendar days and until all requirements have been met,with the exception of Consent of Surety for Final Payment. SECTION J PROTECTION OF PERSONS AND PROPERTY J-1 SAFETY PRECAUTIONS AND PROGRAMS The CMAR shall be responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the Work. CMAR shall designate a responsible member of its organization at the site whose duty shall be the prevention of accidents. This person shall be the CMAR's superintendent unless otherwise designated in writing by the CMAR to the Architect. J-2 SAFETY OF PERSONS AND PROPERTY. The CMAR shall take all reasonable precautions for the safety of, and shall provide all reasonable protection to prevent damage, injury or loss to: (1) all employees on the Work and all other persons who may be affected thereby; (2) all the Work and all materials and equipment to be incorporated therein,whether in storage on or-off the site, under the care, custody or control of the Contractor or any of his Subcontractors or Sub-contractors;and (3) other property at the site or adjacent thereto, including trees, shrubs, lawns, walks, pavements, roadways, structures and utilities not designated for removal, relocation or replacement in the course of construction. Until final acceptance of the Work, it shall be under the charge and care of the CMAR, who shall take every precaution against injury or damage to the Work by the action of the elements or from any other cause whatsoever,whether arising from the execution or from the non-execution of the Work. CMAR shall rebuild, repair, restore and make good, at its own expense, all injuries or damages to any portion of the Work occasioned by any of the above,caused before its completion and acceptance. CMAR shall comply with all applicable Laws, Ordinances, Rules, Regulations and Orders of any public authority having jurisdiction for the safety of persons or property or to protect them from damage, injury or loss. He shall erect and maintain, as required by existing conditions and progress of the Work, all reasonable safeguards for safety and protection, including posting danger signs _. and other warnings against hazards,promulgating safety regulations and notifying owners and users of adjacent utilities. When the use or storage of explosives or other hazardous materials or equipment is necessary for the execution of the Work, CMAR shall exercise the utmost care and shall carry on such activities under the supervision of properly qualified personnel. All damage or loss to any property referred to in the preceding paragraphs caused in whole or in part by the CMAR, .any Subcontractor, or anyone directly or indirectly employed by any of them, or by anyone for whose acts any of them may be liable, shall be remedied by the CMAR. The CMAR shall not load or permit any part of the Work to be loaded so as to endanger its safety. J-3 HARD HATS. Hard Hats will be required at all construction sites included in this Contract from start to completion of work. Each contractor, employee and visitor at any construction site included in the Contract will be required to wear a hard hat. .� The CMAR shall enforce the wearing of hard hats by CMAR, employees and visitors. CMAR shall provide ten hard hats for use by the consulting Architects and Engineers and visitors. J-4 EMERGENCIES. In any emergency affecting the safety of persons or property, CMAR shall act at his discretion to prevent threatened damage, injury or loss.Any additional compensation or extension of time claimed by the CMAR on account of emergency work shall be determined as provided in Changes in the Work. J-5 SAFE WORK PRACTICES. CMAR shall employ safe practices in handling materials and equipment used in performing required work so as to insure the safety of his workmen, City employees and the public.- CMAR shall keep the premise free at all times from accumulation of waste materials or rubbish,refer to D-23. J-6 TRENCH SAFETY The CMAR shall be responsible for all design and implementation of trench shoring and stabilization to meet regulatory requirements. If the Proposal requires,the CMAR shall include a per-unit cost for trench safety measures in his bid. If not included in the Proposal,the CMAR shall include a cost for trench safety measures for all trenches over 5 feet in depth in his Schedule of Values. SECTION K-INSURANCE K-1 Insurance Required. The Contractor shall not commence work under this Contract until he has obtained all insurance required under this Section and such insurance has been approved by the City of Fort Worth, nor shall the Contractor allow any PARD Service Center Project Page 43 of 58 �. Byrne CMAR Construction Contract June 2018 Subcontractor to commence work to be performed under this Contract until all similar insurance of the Subcontractor has been so obtained and approved. K-2 Workers'Compensation.Insurance: 1) General a) Contractors Worker's Compensation Insurance. CMAR agrees to provide to the Owner(City)a certificate showing that it has obtained a policy of workers compensation insurance covering each of its employees employed on the project in compliance with state law. No Notice to Proceed will be issued until the CMAR has complied with this section. b) Subcontractor's Workers Compensation Insurance. CMAR agrees to require each and every subcontractor who will perform work on the project to provide to'it a certificate from such subcontractor stating that the subcontractor has a policy of workers compensation insurance covering each employee employed on the project. CMAR will not permit any subcontractor to perform work on the project until such certificate has been acquired. CMAR shall provide a copy of all such certificates to the Owner(City). — c) By signing this contract or providing or causing to be provided a certificate of coverage,the CMAR is representing to the City that all employees of the CMAR who will provide services on the project will be covered by worker's compensation coverage for the duration of the project, that the coverage will be based on proper reporting of classification codes and payroll amounts, and that all coverage agreements will be filed with the appropriate insurance carrier or, in the case of a ' self-insured,with the Texas Workers Compensation Commission's Division of Self-Insurance Regulation.Providing false or misleading information may subject the CMAR to administrative penalties, criminal penalties, civil penalties or other civil actions. d) The CMAR's failure to comply with any of these provisions is a breach of contract by the CMAR which entitles the City to .. declare the contract void if the CMAR does not remedy the breach within ten days after receipt of notice of breach from the City. 2) Definitions: — a) Certificate of coverage("certificate"). A copy of a certificate of insurance,a certificate of authority to self-insure issued by the Texas Workers'Compensation Commission, or a coverage agreement(TWCC-81, TWCC-82,TWCC-83, or TWCC- 84), showing statutory workers' compensation insurance coverage for the person's or entity's employees providing services on a project,for the duration of the project. b) Duration of the Project. Includes the time from the beginning of the work on the project until the CMAR's/person's work on the project has been completed and accepted by the City. c) Persons providing services on the project("subcontractor'in section 406.096)-includes all persons or entities performing all or part of the services the CMAR has undertaken to perform on the project, regardless of whether that person contracted directly with the CMAR and regardless of whether that person has employees. This includes, without limitation, independent contractors, subcontractors, leasing companies, motor carriers, owner-operators, employees of any such entity, or employees of any entity which furnishes persons to provide services on the project. "Services" ,. include, without limitation, providing, hauling, or delivering equipment or materials, or providing labor, transportation, or other services related to a project. "Services"does not include activities unrelated to the project,such as food/beverage vendors,office supply deliveries,and delivery of portable toilets. 3) Requirements -� a) The CMAR shall provide coverage, based on proper reporting of classification codes and payroll amounts and filing of any coverage agreements, which meets the statutory requirements of Texas Labor Code, Section 401.011(44) for all employees of the CMAR providing services of the project,for the duration of the project. b) The CMAR must provide a certificate of coverage to the Architect prior to the execution of the contract. c) If the coverage period shown on the CMAR's current certificate of coverage ends during the duration of the project, the CMAR must,prior to the end of the coverage period,file a new certificate of coverage with the City showing that coverage has been extended: d) The CMAR shall obtain from each person providing services on a project,and provide to the City: i) a certificate of coverage,prior to that person beginning work on the project, so the governmental entity will have on file certificates of coverage showing coverage for all persons providing services on the project;and ii) no later than seven days after receipt by the CMAR, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the project. e) The CMAR shall retain all required certificates of coverage for the duration of the project and for one year thereafter. f) The CMAR shall notify the City in writing by certified mail.or personal delivery,within ten(10)days after the CMAR knew or should have known,of any change that materially affects the provision of coverage of any person providing services on the project. g) The CMAR shall post on each project site a notice, in the text, form and manner prescribed by the Texas Worker's Compensation Commission, informing all persons providing services on the project that they are required to be covered, and stating how a person may verify coverage and report lack of coverage. h) The CMAR shall contractually require each person with whom it contracts to provide services on a project,to: " PARD Service Center Project Page 44 of 58 Byrne CMAR Construction Contract June 2018 — i) provide coverage, based on proper reporting on the classification codes and payroll amounts and.filing of any coverage agreements, which meets the statutory requirements of Texas labor Code, Section 401.011(44)for all of its employees providing services on the project,for the duration of the project; ii) provide to the CMAR , prior to that person beginning work on the project, a certificate of coverage showing that coverage is being provided for all employees of the person providing services on the project,for the duration of the project; iii) provide the CMAR, prior to the end of the coverage period, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the project; iv) obtain from each other person with whom it contracts,and provide to the CMAR: (1) a certificate of coverage,prior to the other person beginning work on the project;and (2) a new certificate of coverage showing extension of coverage, prior to the end of the coverage period, if the coverage period shown on the current certificate of coverage ends during the duration of the project; v) retain all required certificates of coverage on file for the duration of the project and for one year thereafter. vi) notify the City in writing by certified mail or personal delivery, within ten (10)days after the person knew or should have known,of any change that materially affects the provision of coverage of any person providing services on the project;and vii) contractually require each person with whom it contracts, to perform as required by paragraphs h-i)-vii), with the certificates of coverage to be provided to the person for whom they are providing services. 4) Posting of Required Worker's Compensation Coverage. a) The CMAR shall post a notice on each project site informing all persons providing services on the project that they are required to be covered,and stating how a person may verify current coverage and report failure to provide coverage.This notice does not satisfy other posting requirements imposed by the Texas Worker's Compensation Act or other Texas Worker's Compensation Commission rules. This notice must be printed with a title in at least 30-point bold type and text in at least 19-point normal type,and shall be in both English and Spanish and any other language common to the worker population. The text for the notices shall be the following text,without any additional words or changes: "REQUIRED WORKER'S COMPENSATION COVERAGE The law requires that each person working on this site or providing services related to this construction project must be covered by worker's compensation insurance. This includes persons providing, hauling, or delivering equipment or materials, or providing labor or transportation or other service related to the project, regardless of the identity of their employer or status as an employee". Call the Texas Worker's Compensation Commission at 512-440-3789 to receive information on the legal requirement for coverage, to verify whether your employer has provided the required coverage, or to report an employer's failure to provide coverage." K-3 LIABILITY INSURANCE. CMAR shall procure and maintain during the term of this Contract such Liability Insurance as shall protect him, Owner and any Subcontractor performing work covered by this Contract,from claims of damage which may arise from operations under this Contract, including blasting, when blasting is done on, or in connection with the Work of the Project, whether such operations be by himself or by any Subcontractor or by anyone directly or indirectly employed by either of them and the limits of such insurance shall be not less than the following: 1) Automobile Liability: $1,000,000 each accident, or reasonably equivalent split limits for bodily injury and property damage. Coverage shall be on "any auto" including leased, hired, owned, non-owned and borrowed vehicles used in connection with this Contract. 2) Commercial General Liability: $1,000,000 each occurrence. Coverage under the policy shall be as comprehensive as that provided in a current Insurance Services Office (ISO) policy form approved for use in Texas and the policy shall have no exclusions by endorsement unless such are approved by the City. 3) Asbestos Abatement Liability Insurance:When the Project specifically requires the removal of Asbestos Containing Materials, the Contractor,or subcontractor performing the removal,shall be required to maintain Asbestos Abatement Liability Insurance as follows: $1,000,000 per occurrence; $2,000,000 aggregate limit. The coverage shall include any pollution exposure, including environmental impairment liability, associated with the services and operations perfoirned under this contract in addition to sudden and accidental contamination or pollution liability for gradual emissions and clean-up costs. K-4 BUILDER'S RISK INSURANCE. Unless stated otherwise in the negotiated contract,the CMAR shall procure, pay for and maintain at all times during the term of this Contract, Builder's Risk Insurance against the perils of fire, lightning, windstorm, hurricane, hail, riot, explosion, civic commotion, smoke,aircraft,land vehicles,vandalism, and malicious mischief,at a limit equal to 100%of the GMP. The policy shall include coverage for materials and supplies while in transit and while being stored on or off site. If specifically required in the Instructions to Bidders,the policy shall include coverage for flood and earthquake. The City must approve different �. sub-limits for these coverages. PARD Service Center Project Page 45 of 58 Byrne CMAR Construction Contract June 2018 Consequential damage due to faulty workmanship and/or design performed by the CMAR or his agents shall be covered. Upon completion of the Work,the CMAR shall notify the City of Fort Worth in writing before terminating this insurance. K-5 PROOF OF CARRIAGE OF INSURANCE. The CMAR shall provide a certificate of insurance documenting the City of Fort Worth as a "Certificate Holder", and noting the specific project(s) covered by the CMAR's insurance as documented on the certificate of insurance. More than one certificate may be required of the CMAR depending upon the agents and/or insurers for the CMAR's insurance coverages specified for the project(s). K-6 OTHER INSURANCE RELATED REQUIREMENTS. 1) The City of Fort Worth shall be added as an additional insured,by endorsement,on all applicable insurance policies. 2) Applicable insurance policies shall each be endorsed with a waiver of subrogation in favor of the City of Fort Worth. 3) Insurers of policies maintained by CMAR and its subcontractor(s),if applicable,shall be authorized to do business in the State — of Texas, or otherwise approved by the City of Fort Worth, and such shall be acceptable to the City of Fort Worth insofar as their financial strength and solvency are concerned. Any company through which the insurance is placed must have a rating of at least A:VII, as stated in current edition of A. M. Best's Key Rating Guide. At the City's sole discretion, the City may accept a less favorable rate. 4) Deductible limits on insurance policies and/or self-insured retentions exceeding $10,000 require prior written approval of the City of Fort Worth as respects this Contract. 5) The City of Fort Worth shall be notified in writing a minimum of thirty days prior to an insurer's action in the event of cancellation, non-renewal or material change in coverage regarding any policy providing insurance coverage required in this Contract.A 10 day notice for failure to pay premium is acceptable. 6) Full limits of insurance shall be available for claims arising out of this Contract with the City of Fort Worth. — 7) The CMAR shall provide certificates of insurance to the City prior to commencement of operations pursuant to this Contract. Any failure on part of the City of Fort Worth to request such documentation shall not be construed as a waiver of insurance requirements specified herein. _ 8) The City of Fort Worth shall be entitled, upon request and without incurring expense,to review the insurance policies including endorsements thereto and,at its discretion,to require proof of payment for policy premiums. 9) The City of Fort Worth shall not be responsible for paying the cost of insurance coverages required herein. — 10) Notice of any actual or potential claim and/or litigation that would affect insurance coverages required herein shall be provided to the City in a timely manner. 11) "Other insurance" as referenced in any policy of insurance providing coverages required herein shall not apply to any insurance policy or program maintained by the City of Fort Worth. 12) CMAR agrees to either require its subcontractors to maintain the same insurance coverages and limits thereof as specified herein or the Contractor shall provide such coverage on the Contractor's subcontractors. .. SECTION L CHANGES IN THE WORK L-1 CHANGE ORDER. The Owner, without invalidating the Contract, may order Changes in the Work within the general scope of the Contract consisting of additions, deletions or other revisions, the GMP and the Contract Time being adjusted accordingly. All Such Changes in the Work shall be authorized by a written Change Order, and shall be executed under the applicable conditions of the Contract Documents. — A Change Order'is a written order to the CMAR signed by the Owner and the Architect, issued after the execution of the Contract, authorizing a Change in the Work or adjustment in the GMP or the Contract Time. The GMP and the Contract Time may be changed only by Change Order. ! Any changes in work required due to changed or unforeseen conditions,or by request of either the Contractor or the City,shall be coordinated with the Director,Department of Transportation and Public Works. A change.order must be written and duly negotiated and executed prior to performing changed work. The cost or credit to the Owner resulting from a Change Order shall be the actual cost to be incurred or deducted as the case might be multiplied by the allowance for contractual overhead and profit If after the contract has been executed,the Architect, requests a price proposal from the CMAR for a proposed change in scope of — the work,Contractor shall process such proposal within seven days of receipt and return the price quote to the Architect in writing. CMAR is advised that when the cumulative effect of Change Orders results in an increase in GMP by over $25,000, the City Council must approve all such Change Orders that will exceed this limit. Normal processing time for the City Staff to obtain City Council approval, once the recommended change order has been received at the City, is approximately thirty(30)days. Owner, PARD Service Center Project Page 46 of 58 Byrne CMAR Construction Contract June 2018 Architect and CMAR shall endeavor to identify Change Order items as early in the Construction process as possible to minimize their impact on the construction schedule. If the CMAR claims that additional cost or time is involved because of(1) any written interpretation issued pursuant to Section A, (2) any order by the Architect or Owner to stop the Work pursuant to Section B, where the Contract was not at fault, or(3) any written order for a minor change in the Work,the Contractor shall make such claim. L-2 CLAIMS FOR ADDITIONAL COST OR TIME. If the CMAR wishes to make a claim for an increase in the GMP or an extension in the Contract Time, he shall give the Architect written notice thereof within a reasonable time after the occurrence of the event that gave rise to such claim.This notice shall be given by the CMAR before proceeding to execute the Work. No such claim = shall be valid unless so made.Any change in the GMP or Contract Time resulting from such claim, if approved by the Owner,shall be authorized by Change Order. L-4 MINOR CHANGES IN THE WORK.. The Architect shall have authority to order minor changes in the Work not involving _ an adjustment in the GMP or an extension of the Contact Time and not inconsistent with the intent of the Contract Documents. Such changes may be effected by Field Order or by other written order.Such changes shall be confirmed in writing by the Architect and shall be binding on the Owner and the CMAR. L-5 FIELD ORDERS. The Architect may issue written Field Orders which interpret the Contract Documents, or which order minor changes in the Work without change in GMP or Contract Time.The CMAR shall carry out such Field Orders promptly. SECTION M UNCOVERING AND CORRECTION OF WORK M-1 UNCOVERING OF WORK. If any Work should be covered contrary to the request of the Owner or Architect, it must be uncovered for observation and replaced,at the CMAR's expense. If any other work has been covered which the Owner or Architect have not specifically requested to observe prior to being covered, the Architect or the Owner may request to see such work and it shall be uncovered by the Contractor. If such Work is found to be in accordance with the Plans and Specifications, the cost of uncovering and replacement shall, by appropriate Change Order, be charged to the Owner. If such work is found not to be in accordance with the Plans and Specifications, the CMAR shall pay such costs unless it be found that this condition was caused by a separate contractor employed by the Owner. M-2 CORRECTION OF WORK. The CMAR shall promptly correct all work rejected by the Owner or Architect as defective or as failing to conform to the Plans and Specifications whether observed before or after Substantial Completion and whether or not fabricated, installed or completed. The CMAR shall bear all costs of correcting such rejected Work, including the cost of the Architect's additional service thereby made necessary. If, within one year after the Date of Substantial Completion or within such longer period of time as may be prescribed by law or by the terms of any applicable special guarantee required by the Contract Documents, any of the work is found to be defective or not in accordance with the Contract Documents, the CMAR shall correct it promptly after receipt of a written notice from the Owner to do so, unless the Owner has previously given the Contractor a written acceptance of such condition, describing same specifically and not generally.The Owner shall give such notice promptly after discovery of the condition. All such defective or non-conforming work under the preceding paragraphs shall be removed from the site where necessary, and the work shall be corrected to comply with the Contract Documents without cost to the Owner. The CMAR shall bear the cost of making good all work of separate contractors destroyed or damaged by such removal or correction. If the CMAR does not remove such defective or non-conforming work within a reasonable time fixed by written notice from the Architect or the Owner, the Owner may remove it and may store the materials or equipment at the expense of the CMAR. If the CMA does not pay the cost of such removal and storage within ten days thereafter, the Owner may upon ten additional days' .. written notice sell such work at auction or at private sale and shall account for the net proceeds thereof,after deducting all the costs that should have been borne by the CMAR including compensation for additional architectural services. If such proceeds of sale do not cover all costs that the CMAR should have borne, the difference shall be charged to the CMAR and an appropriate Change Order shall be issued. If the payments then or thereafter due the CMAR are not sufficient to cover such amount,the CMAR shall pay the difference to the Owner.. If the CMAR fails to correct such defective or non-conforming work,the Owner may correct it in accordance with Section G. The obligation of the CMAR under this Section shall be in addition to and not in limitation of any obligations imposed upon him by special guarantees required by the Contract Documents or otherwise prescribed by law. M-3 ACCEPTANCE OF DEFECTIVE OR NON-CONFORMING WORK. If the Owner prefers to accept defective or non- conforming work, he may do so instead of requiring its removal and correction, in which case a Change Order will be issued to reflect an appropriate reduction in the final payment to the CMAR, or, if the amount is determined after final payment,the CMAR shall pay Owner the amount of the appropriate reduction. PARD Service Center Project Page 47 of 58 Byrne CMAR Construction Contract June 2018 SECTION N TERMINATION OF THE CONTRACT N-1 TERMINATION BY THE CMAR. if the work is stopped for a period of 30 days under an order or any court or other public authority having jurisdiction, through no act or fault of the CMAR or a Subcontractor or their agents or employees or any other persons performing any of the work under a contract with the CMAR,or if the work should be stopped for a period of 30 days by the CMAR for the Owner's failure to make payment thereon as provided in Section I,then the CMAR may after the end of such period of 30 days and upon seven additional days'written notice to the Owner and the Architect,terminate the Contract. N-2 TERMINATION BY THE OWNER. If the CMAR is adjudged as bankrupt, or if he makes a general assignment for the benefit of his creditors,or if a receiver is appointed on account of his insolvency, of if the CMAR refuses,except in cases for which �- extension of time is provided,to supply enough properly skilled workmen or proper materials,or if he fails to make prompt payment to Subcontractors or for materials or labor,or fails to comply with al Laws, Statutes, Charter,Ordinances, Regulations or Orders of any public authority having jurisdiction, or otherwise is guilty of a substantial violation of a provision of the Contract Documents, then the Owner, on its own initiative or upon certification by the Architect that sufficient cause exists to justify such action, may, without prejudice to any rights or remedy and after giving the CMAR and his surety, if any,seven(7)days'written notice,terminate the contract and take possession of the site and of all materials, equipment,tools, construction equipment and machinery thereon owned by the CMAR and may finish the work by whatever method he may deem expedient. In such case the CMAR shall not be entitled to receive any further payment until the Work is finished. If the costs of finishing the Work, including compensation for the Architect's additional services, exceed the unpaid balance of the Contract,the CMAR shall pay the difference to the Owner. Owner may terminate this contract in whole, or from time to time, in part, whenever such termination is in the best interest of the - City. Termination will be effected by delivering to the CMAR a notice of termination specifying to what extent performance of the work of the contract is being terminated and the effective date of termination. After receipt of termination the CMAR shall: a) Stop work under the Contract on the date and to the extent specified on the notice of termination. b) Place no further orders or subcontracts except as may be necessary for the completion of the work not terminated. c) Terminate all orders and subcontracts to the extent that they relate to the performance of the work terminated by the notice of termination. After termination as above,Owner will pay the CMAR a proportionate part of the contract price based on the work completed; provided,however,that the amount of payment on termination shall not exceed the total contract price as reduced by the portion thereof allocated to the work not completed and further reduced by the amount of payments, if,any otherwise made. CMAR shall submit its claim for amounts due after termination as provided in this paragraph within 30 days after receipt of such claim. In the event of any dispute or controversy as to the propriety or allowability of all or any portion of such claim under this paragraph,such dispute or controversy shall be resolved and be decided by the City Council of the City of Fort Worth,and the decision by the City Council of the City of Fort Worth shall be final and binding upon all parties to this contract. _ SECTION O SIGNS The CMAR shall construct and install the project designation sign as required in the Contract Documents and in strict accordance with the Specifications for"Project Designation Signs."This sign shall be a part of this Contract and shall be included in the GMP. SECTION P TEMPORARY FACILITIES P-1 SCOPE. The CMAR shall furnish,erect, and maintain facilities and perform temporary work required in the performance of this Contract,including those shown and specified. P-2 USE OF TEMPORARY FACILITIES. All temporary facilities shall be made available for use by all workmen and subcontractors employed on the project, subject to reasonable directions by the .CMAR as to their proper and most efficient utilization. P-3 MAINTENANCE AND REMOVAL. The CMAR shall maintain temporary facilities in a proper,safe operating and sanitary condition for the duration of the Contract. Upon completion of the Contract,all such temporary work and facilities shall be removed from the premises and disposed of unless otherwise directed or specified hereunder. P-4 FIELD OFFICES AND SHEDS. The CMAR is not required to provide a temporary field office or telephone for projects under$1,000,000. CMAR shall equip the Project Superintendent with a cellphone and provide 24-hour contacts to the City. The CMAR shall provide a temporary field office building for himself, his subcontractors and use by the Architect. For construction contracts with a price in excess of$1,000,000.00, the CMAR shall provide a separate field office for the City's field representative (but the separate office may be in the same structure). The buildings shall afford protection against the weather, and each office shall have a lockable door, at least one window, adequate electrical outlets and lighting,and a shelf large enough to accommodate perusal of the project drawings. Openings shall have suitable locks. Field offices shall be maintained for the full time during the operation of the work of the Contract. During cold weather months, the field offices shall be suitably insulated and equipped with a PARD Service Center Project Page 48 of 58 Byrne CMAR Construction Contract June 2018 heating device to maintain 70 degree Fahrenheit temperature during the workday. During warm weather the offices shall be equipped with an air conditioning device to maintain temperature below 75 degrees F. Upon completion of the work of the Contract, CMAR shall remove the building from the premises. In addition to the drawing shelf, provide for the City field representatives office: one desk,four chairs, plan rack and a four-drawer filing cabinet(with lock). Each office shall contain not less than 120 square feet of floor space. CMAR shall provide and maintain storage sheds and other temporary buildings or trailers on the project site as required for his use. Location of sheds and trailers shall be as approved by the Architect. Remove sheds when work is completed,or as directed. P-5 TOILET FACILITIES. CMAR shall provide proper sanitary and adequate toilet facilities for the use of all workmen and subcontractors employed on the project. -. P-6 UTILITIES. CMAR shall make all necessary arrangements and provide for temporary water and electricity required during the construction. CMAR shall provide and install temporary utility meters during the contract construction period. These meters will be read and the CMAR will be billed on this actual use.The CMAR shall provide all labor and materials required to tap into the utilities. The CMAR shall make the connections and extend the service lines to the construction area for use of all trades. Upon completion of the work all utility lines shall be removed and repairs made to the existing lines. Only utilities at existing voltages,pressures,frequencies,etc.will be available to the CMAR. Water. Provide an ample supply of potable water for all purposes of construction at a point convenient to the project or as shown on the Drawings. Pipe water from the source of supply to all points where water will be required. Provide sufficient hose to carry water to every required part of the construction and allow the use of water facilities to subcontractors engaged on the work. Provide pumps,tanks and compressors as may be required to produce required pressures. Electric Service. Provide adequate electric service for power and lighting to all points where required. Temporary, electric service shall be of sufficient capacity and characteristics to supply proper current for various types of construction tools, motors, welding machines, lights, heating plant, air conditioning system, pumps, and other work required. Provide sufficient number of electric outlets so that 50 foot long extension cords will reach all work requiring light or power. Lighting. Supply and maintain temporary lighting so that work of all trades may be properly and safely performed, in such areas and at such time that day-lighting is inadequate. Provide at least 0.75 watts of incandescent lighting per squgr4e foot and maintain a socket voltage of at least 110 volts. Use at least 100 watt lamps. In any event,the lighting intensity shall not be less than 5 foot candles in the vicinity of work and traffic areas. P-7 HEATING. Heating devices required under this paragraph shall not be electric. CMAR shall provide heat, ventilation, fuel and services as required to protect all work and materials and to keep the humidity down to the extent required to prevent corrosion of any metal and to prevent dampness or mildew which is potentially damaging to materials and finishes. All such heating, ventilation and services shall be provided and maintained until final acceptance of all work. In addition, the CMAR shall .� provide heat ventilation prior and during the following work operations as follows: a) At all times during the.placing, setting and curing of concrete provide sufficient heat to insure the heating of the spaces involved to not less than 40 F. b) From the beginning of the application of drywall and during the setting and curing period, provide sufficient heat to produce a temperature in the spaces involved of not less than.55 F. c) For a period of seven (7)days previous to the placing of interior finish materials and throughout the placing of finish painting, decorating and laying of resilient flooring materials,provide sufficient heat to produce a temperature of not less than 60 F. P-8 TEMPORARY CONSTRUCTION,EQUIPMENT AND PROTECTION .. CMAR shall provide, maintain, and remove upon completion of the work all temporary rigging, scaffolding, hoisting equipment, rubbish chutes, ladders to roof, barricades around openings, and all other temporary work as required to complete all work of the Contract.Contractor shall coordinate the use and furnishing of scaffolds with his sub-contractors. CMAR shall provide, maintain, and remove upon completion of the work, or sooner, if authorized by the Architect, all fences, barricades, lights, shoring, pedestrian walkways, temporary fire escapes, and other protective structures or devices necessary for the safety of workmen,City employees,equipment,the public and property. All temporary construction and equipment shall conform to all regulations, ordinances, laws and other requirements of the �^ authorities having jurisdiction,including insurance companies,with regards to safety precautions,operation and fire hazard. CMAR shall provide and maintain pumping facilities, including power, for keeping the site, all times, whether from underground seepage, rainfall,drainage of broken lines. CMAR shall maintain provision for closing and locking the building at such time as possible to do so. If this is not feasible, maintain a night CMAR shall provide and maintain all barricades or enclosures, required to protect the work in progress from outside elements, dusts, and other disturbances as a result of work under this Contract. Such protection shall be positive, shall meet the approval of PARD Service Center Project Page 49 of 58 Byrne CMAR Construction Contract June 2018 the Architect and shall be maintained for the duration of the construction period or as required to provide for the protection as specified. ! P-9 PROJECT BULLETIN BOARD. CMAR shall furnish, install and maintain during the life of the project a weather-tight bulletin board approximately 3 feet high by 5 feet wide having not less than two hinged or sliding glass doors with provisions for locking. The bulletin board shall be mounted where and as approved by the Architect, in a prominent place accessible to employees of the Contractor and sub-contractors, and to applicants for employment.The bulletin board shall remain the property of the CMAR and shall be removed by him upon completion of the Contract work.The following information which will be furnished by the City to the CMAR, shall be posted on the bulletin board and shall be maintained by the Contractor in easily readable condition at all times for the duration of the Contract. a. The Equal Opportunity Poster and Notice Nondiscrimination of Employment(Standard Form 38). b. Wage Rate Information Poster(Form SOL 155), with the Contract Schedule of minimum wage rates as required by the Davis-Bacon Act. C. Safety Posters. SECTION Q VENUE AND JURISDICTION Should any action arise out of the terms and conditions of this contract,venue for said action shall lie in the state courts of Tarrant County,Texas. END OF GENERAL CONDITIONS PARD Service Center Project Page 50 of 58 Byrne CMAR Construction Contract June 2018 Bond# 022052369 PERFORMANCE BOND THE STATE OF TEXAS § § KNOW ALL BY THESE PRESENTS: COUNTY OF TA.RRANT § _. That we, Thos.S.Byrne,Inc.dba Byrne Construction Services ,known as"Principal" „R herein and Liberty Mutual Insurance C'.nmpany ,a corporate surety(sureties,if more than one)duly authorized to do business in the State of Texas,known as"Surety"herein(whether one or more),are held and firmly bound unto the City of Fort Worth,a municipal corporation created pursuant to the laws of Texas,known as"City"herein,in the penal sum of,Seven Million.Seven Hundred Ninety-Eight Thousand,Six Hundred Forty-Four Dollars and no Cents($7,798.644.00),lawful money of the United States,to be paid in Fort Worth,Tarrant County, Texas for the payment of which sum well and truly to be made,we bind ourselves,our heirs,executors, administrators,successors and assigns,jointly and severally,firmly by these presents. T p+ WHEREAS,the Principal has entered into a certain written contract with the City awarded the 12th day of December .2017,which Contract is hereby referred to and made a part hereof for all P" purposes as if fully set forth herein,to furnish all materials,equipment labor and other accessories defined by law,in the prosecution of the Work,including any Change Orders,as provided for in said P" Contract designated as CNLi R for the PARD Service Center located at 5199 James Ave in Fort Worth,Texas(Project PMD2017-08)pity Prolect#101010. NOW,THEREFORE,the condition of this obligation is such that if the said Principal shall faithfully perform it obligations under the Contract and shall in all respects duly and faithfully perform the Work,including Change Orders,under the Contract,according to the plans,specifications,and contract documents therein referred to,and as well during any period of extension of the Contract that may be granted on the part of the City,then this obligation shall be and become null and void,otherwise to remain in full force and effect. PROVIDED FURTHER,that if any legal action be filed on this Bond,venue shall lie in Tarrant County,Texas or the United States District Court for the Northern District of Texas,Fort Worth Division. This bond is made and executed in compliance with the provisions of Chapter 2253 of the Texas Government Code,as amended,and all liabilities on this bond shall be determined in accordance with the provisions of said statue. IN WITNESS WHEREOF,the Principal and the Surety have SIGNED and SEALED this instrument by duly authorized agents and officers on this thel6th day ofJuly•2018. ON PRINCIPAL: Thos.S.Byrne,Inc.dba Byrne .. _ Constru Se ces BY: Signature _ ATT TV• - T P I ffr;la e&S Owr1f,' , OFF,,cer = (Principal)Secretary Name and Title Address: 551 E Berry Street '! Ft Worth,TX 76110 PM Witness as to Principal SURETY: Liberty Mutual Insurance Company .. BY: Signature Tracy Tucker,Attornex-in-Fagf Name and Title � Ion �_ J Address: 685 John B.Sias Me! +R iar.Kwy#215- Ft Worth,TX 76134 .. Witness as to Surety Telephone Number. 817/336-8520' *Note: If signed by an officer of the Surety Company,there must be on file a certified extract from the by-laws showing that this person has authority to sign such obligation. If Surety's physical address is different from its mailing address,both must be provided.The date of the bond shall not be prior to the date the Contract is awarded. P, A. Bond#' 022052369 "" PAYMENT BOND THE STATE OF TEXAS § § KNOW ALL BY THESE PRESENTS: COUNTY OF TARRANT § ^ That we, Thos.S.Byrne,Inc.dba Byrne Construction Services . ,[mown as"Principal' herein, and _ LibertyMutual Insurance Compaay . a ^ corporate surety (sureties), duly authorized to do business in the State of Texas, known as "Surety" herein (whether one or more), are held and firmly bound unto the City of Fort Worth, a municipal corporation created pursuant to the laws of the State of Texas, known as "City" herein, in the penal sum of, Seven Million,Seven Hundred Ninety-Eight Thousand,Six Hundred Forty-Four Dollars and no Cents ($7,798,644.00), lawful money of the United States, to be paid in Fort Worth, Tarrant County, Texas, for the payment of which sum well and truly be made, we bind ourselves, our heirs, executors, administrators,successors and assigns,jointly and severally,firmly by these presents: WHEREAS,Principal has entered into a certain written Contract with City,awarded the 12th day of December , 2017,which Contract is hereby referred to and made a part hereof for all purposes as if fully set forth herein,to furnish all materials, equipment, labor and other accessories as defined by ^ law, in the prosecution of the Work as provided for in said Contract and designated as CMAR for the PARD Service Center located at 5199 James Ave in Fort Worth,Texas(Project PMD2017-08)City Proiect#101010. NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION is such that if Principal shall pay all monies owing to any(and all)payment bond beneficiary(as defined in Chapter 2253 of the ^ Texas Government Code, as amended) in the prosecution of the Work under the Coatiact, then this LL obligation shall be and become null and void;otherwise to remain in full force and effect. ^ This bond is made and executed in compliance with the provisions of Chapter 2253 of the Texas 4 Government Code,as amended,and all liabilities on this bond shall be determined in accordance with the provisions of said statute. ^ ^ w, IN WITNESS WHEREOF, the Principal and Surety have each SIGNED and SEALED this instrument by duly authorized agents and officers on this the 16th day of July ,2018. PRINCIPAL: �. Thos.S.Byrne,Inc.dba Byrne Construction Services ATTEST: BY: Si ature � V _ APQPCA,.e- � P�9�� Df#CPI� JJ I� (Principal)Secretary Name and Title Address: 551 E Berry Street Ft Worth,TX 76110 Witness as to Principal SURETY: Liberty Mutual Insurance Company ATTEST: BY: Signature Tracy Tucker,Attorney-in-Fact (Surety)Secretary Name and Title _ - Address: 685 Inhn R CiaS Memadal is pr#215 1 Ft Worth,TX 76134 - Witness as to Surety _ Telephone Number: S17/336-8520 'Note: If signed by an officer of the Surety,there must be on file a certified extract from the bylaws showing that this person has authority to sign such obligation. If Surety's physical address is different from its mailing address, both must be provided. The date of the bond shall not be prior to the date the Contract is awarded. PM 1rHIS POWER OF ATTORNEY IS NOT VALID UNLESS IT IS PRINTED ON RED BACKGROUND. This Power of Attorney limits the acts of those named herein,and they have no authority to bind the Company except in the manner and to the extent herein stated. Certificate No.7743219 Liberty Mutual Insurance Company The Ohio Casualty Insurance Company West American Insurance Company POWER OF ATTORNEY KNOWN ALL PERSONS BY THESE PRESENTS:That The Ohio Casualty Insurance Company is a corporation duly organized under the laws of the State of New Hampshire,that Liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts, and West American Insurance Company is a corporation duly organized under the laws of the State of Indiana(herein collectively called the'Companies'),pursuant to and by authority herein set forth,does hereby name,constitute and appoint, Kevin J.Dunn:Steven Tucker,Tanner Langston:Tracy Tucker;W.Lawrence Brown Lall of the city of Ft.Worth state of TX each individually if there be more than one named,its he and lawful attomey-in-W to make,execute,seat,acknowledge and deliver,for and on its behalf as surety and as its act and deed,any and all undertakings,bonds,recognizances and other surety obligations,in pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies in their own proper persons. IN WITNESS WHEREOF,this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 25th day of April 2017 to `jy}NSU �,thtSUq NtNSUq Z hJ � °crarFA9yr J1`���w-onpA.{st' �P P4avcuttrc^�r<" f� e' The Ohio Casualty Insurance Company p n M U a 16 Liberty Mutual Insurance Company 4)1919 1972 $ 7997 WestAmerican Insurance Company 2 ac �a a 'N C) # * # # By. Cf STATE OF PENNSYLVANIA ss David M.Care ,Assistant Secretary COUNTY OF MONTGOMERY _ C ` p) On this 25th day of April 2017 before me personally appeared David M.Carey,who acknowledged himself to be the Assistant Secretary of Liberty Mutual Insurance v�— v m Company,The Ohio Casualty Company,and West American Insurance Company,and that he,as such,being authorized so to do,execute the foregoing instrument for the purposes >, therein contained by signing on behalf of the corporations by himself as a duly authorized officer. > IN WITNESS WHEREOF,I have hereunto subscribed my name and affixed my notarial sea)at King of Prussia,Pennsylvania,on the day and year first above written. C C. 0, PAST COMMONWEALTH OF PENNSYLVANIA Q M 13 �41 o�yoww'r. -1� Notarial Sear Teresa Pastetle,Notary Public By: A ` of Upper Merton Twp.,Montgomery County Teresa Pastells,Notary Pubho y C ` av My Cornmission Expires March 28,2821 3 1p JP p � �4rrY „ave Member,Pennsylvania Association of Notaries a W� M JS This Power of Attorney is made and executed pursuant o and by authority of the following By-laws and Authorizations of The Ohio Casualty Insurance Company, Liberty Mutual .00 Insurance Company,and West American Insurance Company which resolutions are now in full force and effect reading as follows: Q1 10) ARTICLE IV—OFFICERS—Section 12.Power of Attorney.Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President,and subject O e to such limitation as the Chairman or the President may prescribe,shall appoint such attomeys-in-fact,as may be necessary to act in behalf of the Corporaticn to make,execute,seal, y acknowledge and deliver as surety any and all undertakings,bonds,recognizances and other surety obligations. Such attorneys-in-fact,subject to the limitations set forth in their respective p powers of attomey,shall have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation. When so 4) p executed,such instruments shall be as binding as if signed by the President and attested to by the Secretary.Any power or authority granted to any representative or attorney-in-fact under >u0 the provisions of this article may be revoked at any time by the Board,the Chairman,the President or by the officer or officers granting such power or authority. t ++ � ARTICLE X111—Execution of Contracts—SECTION 5.Surety Bonds and Undertakings.Any officer of the Company authorized for that purpose in writing by the chairman or the president, and subject to such limitations as the chairman or the president may prescribe,shall appoint such attomeys-in-fact,as may be necessary to act in behalf of the Company to make,execute, 6 M seal,acknowledge and deliver as surety any and all undertakings,bonds,recognizances and other surety obligations. Such attorneys-in-fact subject to the limitations set forth in their o? v respective powers of attorney,shall have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company. When so 0 a executed such instruments shall be as binding as if signed by the president and attested by the secretary. C Certificate of Designation—The President of the Company,acting pursuant to the Bytaws of the Company,authorizes David M.Carey,Assistant Secretary to appoint such attomeys-in• fad as may be necessary to act on behalf of the Company to make,execute,seal,acknowledge and deliver as surety any and all undertakings,bonds,recognizances and other surety obligations. Authorization—By unanimous consent of the Company's Board of Directors,the Company consents that facsimile or mechanically reproduced signature of any assistant secretary of the I Company,wherever appearing upon a certified copy of any power of attorney issued by the Company In connection with surety bonds,shall be valid and binding upon the Company with the same force and effect as though manually affixed. I, Renee C. Llewellyn, the undersigned, Assistant Secretary, The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company do hereby certify that the original power of attorney of which the foregoing is a full,true and correct copy of the Bower of Attorney executed by said Companies,is in full force and effect and has not been revoked. IN TESTIMONY WHEREOF,I have hereunto set my hand and affixed the seals of said Companies this 16th day of July pg 18� ,AYINSU L1NSUq N NSU�G PJ��aecanr�9yr v m n 1++Z 0 19t9 0 197 a 1997 By. Renee C.Lie t9R"Aasistant Secretary G9�ti,,er���ac L 26 of 150 LMS 12873 022017 0 Liberty �mutuil. Important Notice TO OBTAIN INFORMATION OR TO MAKE A COMPLAINT: You may write to Liberty Mutual Surety at: Liberty Mutual Surety Interchange Corporate Center 450 Plymouth Road, Suite 400 Plymouth Meeting, PA 19462-8284 You may contact the Texas Department of Insurance to obtain information on companies, coverages, rights or complaints at: 1-800-252-3439 You may write the Texas Department of Insurance: P. O. Box 149104 Austin, TX 78714-9104 Fax: (512) 475-1771 Web: http://www.tdi.state.tx.us E-mail: ConsumerProtectiona-tdi.state.tx.us Premium or Claim Disputes - Should you have a dispute concerning a premium, you should contact the agent first. If you have a dispute concerning a claim, you should contact the company first. If the dispute is not resolved, you may contact the Texas Department of Insurance. Attach This Notice To Your Policy: This notice is for information only and does not become a part or condition of the attached document. LMIC-3500 Page 1 of 2 Rev.7.1.07 Liberty �VlutualW NOTIFICACION IMPORTANTE PARA OBTENER INFORMACION O REALIZAR UNA QUEJA: Usted puede escribir la notificacion y dirigirla a Liberty Mutual Surety en la siguiente direccion: Liberty Mutual Surety Interchange Corporate Center 450 Plymouth Road, Suite 400 Plymouth Meeting, PA 19462-8284 Usted puede contactar al Departamento de Seguros de Texas para obtener informacion acerca de las compahlas, coberturas, derechos o quejas: Y 1-800-252-3439 Usted puede escribir al Departamento de Seguros de Texas a la siguiente direccion: P. O. Box 149104 Austin, TX 78714-9104 Fax: (512) 475-1771 Web: http://www.tdi.state.tx.us E-mail: ConsumerProtectiona-tdi.state.tx.us Disputas acerca de primas o reclamos En caso de que usted quiera eievar una disputa concerniente al tema de primas, por favor contacte en primer lugar a su agente. Si el tema de la disputa es relativo a un reclamo, por favor contacte a la compahia de seguros en primer termino. Si usted considera que la disputa no es apropiadamente resuelta en estas instancias, entonces usted puede contactar - al Departamento de Seguros de Texas.. Adjunte esta notificacion a su poliza: Esta notificacion es a los solos fines de su informacion y la misma no forma parte o condiciona de manera alguna el documento adjunto. LMIC-3500 Page 2 of 2 Rev.7.1.07 ACOR[?® CERTIFICATE OF LIABILITY INSURANCE 7/12/2018 Y' THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS '^ CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the pol(cy(ies) must be endorsed. if SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT Jud Branch NAME: y Tucker Agency, Ltd. PHONE (817)336-8520 FAX No): (817)336-6501 P O Box 2285 E OR :judy@tuckeragency.com INSURERS AFFORDING COVERAGE NAIC# Ft. Worth TX 76113 INSURER A Amerisure Insurance Com an INSURED INSURERS Amerisure Partners Ins Co Thos S Byrne Inc INSURERC:Travelers Property & Casualty P O Box 470546 INSURERD:Hanover Insurance Co INSURER E Ft Worth TX 76147 INSURER F: COVERAGES CERTIFICATE NUMBER:17/18 All Lines w/BR REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL SUBR POLICY EFF POLICY EXP LTR POLICY NUMBER MM/DD/YYYY1 (MM/DD/YYYY1 LIMITS GENERAL LIABILITY EACH OCCURRENCE $ 1,000,000 DAMAGE TO RENTEG__ X COMMERCIAL GENERAL LIABILITY PREMISES Ea occurrence $ 100,000 A CLAIMS-MADE I—XI OCCUR Y Y CPP 2048720 11 0/1/2017 0/1/2018 MED EXP(Any one person) $ 5,000 .n X XCU Included PERSONAL&ADV INJURY $ 1,000,000 X Contractual Liability GENERAL AGGREGATE $ 2,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: PRODUCTS-COMP/OPAGG $ 2,000,000 POLICY X PRO LOC $ AUTOMOBILE LIABILITY COMBINEDSINGLE LIMIT Ea accident 11000,000 A X ANY AUTO BODILY INJURY(Per person) $ ALL OWNED SCHEDULED Y Y CA 2048723 10 0/1/2017 0/1/2018 BODILY INJURY(Per accident) $ AUTOS AUTOS X HIRED AUTOS X NON-OWNED PROPERTY DAMAGE $ AUTOS Per acc d PIP-Basic $ 2,500 X UMBRELLA LIABX OCCUR EACH OCCLRRENCE $ 25,000,000 C EXCESS LIAB CLAIMS-MADE AGGREGATE $ 25,000,000 DED I X I RETENTION 1o,000 Y Y UP-21N55695-17-NF 0/1/2017 0/1/2018 $ B WORKERS COMPENSATIONX WC STATU- OTH- AND EMPLOYERS'LIABILITY Y/N LIM ANY PROPRIETOR/PARTNER/EXECUTNE[!E] NIA E.L.EACH ACCIDENT $ 1 000 000 on OFFICER/MEMBER EXCLUDED? (Mandatory in NH) C 2048722 10 0/1/2017 0/1/2018 E.L.DISEASE-EA EMPLOYE $ 1,000, 000 If yes,describe under DESCRIPTION OF OPERATIONS below Y E.L.DISEASE-POLICY LIMIT $ 1,000,000 Blanket Builder's Risk IHD A740196 02 0/01/2017 0/01/2018 Limit Per Disaster $20,000,000 D Deductible 10,000 DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES (Attach 101,Additional Remarks Schedule,if more space is required) Project No. 101010 - PARD Service Center, Greenbriar Park, 5199 James Ave., Ft. Worth, TX Additional insured in favor of The Owner, its officers, employees and servants applies to all policies except workers compensation if required by written contract. Coverage is primary and non-contributory if required by written contract. Waiver of subrogation in favor of additional insured applies to all policies if required by written contract. All policies include blanket 30 day notice of cancellation if required by written contract. CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN City of Fort Worth ACCORDANCE WITH THE POLICY PROVISIONS. 200 Texas Street Fort Worth, TX 76102 AUTHORIZED REPRESENTATIVE Tracy Tucker/JUDY J y ACORD 25(2010/05) ©1988-2010 ACORD CORPORATION. All rights reserved. INS025(201005).01 The ACORD name and logo are registered marks of ACORD CONTRACTOR COMPLIANCE WITH WORKER'S COMPENSATION LAW Pursuant to Texas Labor Code Section 406.096(a), as amended, Contractor certifies that it provides worker's compensation insurance coverage for all of its employees employed on City Project, CMAR for PARD Service Center Located at 5199 James Ave in Fort Worth,Texas(Proiect PMD2017-081 City*Proiect #101010. Contractor further certifies that, pursuant to Texas Labor Code, Section 406.096(b), as amended, it will provide to City its subcontractor's certificates of compliance with worker's compensation coverage. CONTRACTOR: A Thos.S. Byrne, Inc. By: Paul Avila Company (PIe se Tint) 551 E. Berry Street Signature: Address Fort Worth,TX 76110 Title: Chief Operating Officer 4 City/State/Zip (Please Print) A THE STATE OF TEXAS § § KNOW ALL BY THESE PRESENTS: COUNTY OF TARRANT § BEF-RE ME,the undersigned authority,on this day personally appeared known to me to be the person whose name is subscribed to the foregoing instrument, and acknowledged to me that he/she executed the same as the act and deed of 71105- -4- 64rpt t, L�f _ for the purposes and consideration therein expressed and in the capacity therein stated. GIVEN UNDER MY HAND AND SEAL OF OFFICE this day of _ A Notary Public in and or the State of Texas ANDREW GARCIA ° $Notary Public.State of Texas Comm.Expires 07-142022 ���'�!;,;;,`�•`�� Notary ID 12831066.5 4'-0" 2'-0" 2'-0" 01 — CENTERLINE OF SIGN, LOGO & TEXT INFORMATION F (SRT WORTH, Project Title 0 Architect: Architect's Name i Contractor: Contractor's Name FUNDED BY (List Bond Fund,etc.) _ SCHEDULED COMPLETION DATE YEAR �a SIGN COLOR & FONT: BACKGROUND - WHITE BORDER - 5/16"WIDE, WRADIUS CORNERS, PMS 288 (BLUE) TEXT - HELVETICA or ARIAL, PMS 288 (BLUE) FORT WORTH LOGO COLORS & FONT: FORT WORTH - PMS 288 (BLUE), CHELTENHAM BOLD LONGHORN LOGO - PMS 725 (BROWN) PROJECT DESIGNATION SIGN