HomeMy WebLinkAboutContract 33629 CITY SECRETAR �0
CONTRACT NO.
STATE OF TEXAS §
KNOW ALL BY THESE PRESENTS
COUNTY OF TARRANT §
THIS AGREEMENT is made and entered by and between the City of Fort Worth, Texas, a
municipal corporation situated in Tarrant,Denton, and Wise Counties,Texas,hereinafter called the "City",
acting herein by and through Marc Ott, its duly authorized Assistant City Manager, and GRW Engineers,
Inc., hereinafter called the "Architect", acting herein by and through Charles A. Willis, AIA, its duly
authorized representative, for the purpose of developing the programming and budget for a Helicopter
Hangar for the Police Department's Air Support Division at Meacham Airport.
WITNESSETH:
That for and in consideration of the mutual covenants and agreements herein contained,City and Architect
do hereby covenant and agree as follows:
SECTION I SERVICES OF THE ARCHITECT
1.1 The City hereby contracts with Architect as an independent contractor, and the Architect hereby
agrees to perform, within the professional standards normally accepted in the State of Texas,
professional services in connection with the following general scope of work:
Develop the programming and budget for a Helicopter Hangar for the Police
Department's Air Support Division at Meacham Airport on 4201 North Main Street in
Fort Worth, Texas ("Project"). The scope of services is described more fully in
Attachment"A"of this Agreement.
SECTION II PERSONNEL
1. The following personnel will be assigned to this Project:
1.1. City of Fort Worth
1.1.1.Project Manager: Alfonso Meza,Registered Architect
1.2. Architect
1.2.1.Principal in Charge: Charles A.Willis,AIA,NCARB
1.2.2.Project Coordinator: Brian A.Glass,AIA,NCARB
2. Neither party may change key personnel without the prior written agreement of the other party.
SECTION III CHARACTER OF ARCHITECT'S SERVICES
1. Architect shall consult with the City to clarify and define City's requirements relative to the Project and
review available data.
2. Architect agrees to commit the personnel to each Project as necessary in order to complete the
assignment in an expeditious manner.
3. The Architect shall advise City as to the necessity of City's providing or obtaining additional services
and data from others required in connection with the Project at City's cost and expense(which services
and data Architect is not to provide hereunder but on which Architect may rely in performing services
hereunder),and act as City's representative in connection with any such services of others.
4. The Architect shall pay for the printing of contract documents required for prograe
submittals and presentations as a part of the reimbursable allowance. � ' 1 '�,,1A\I Econ
(1V NIC11RAIY
Pagel ORIGINAL
06-15-06 P03 : 20 IN
06-14-06 A09:42 IN
5. The Architect shall perform the programming services as outlined in GRW, Inc. letter dated June 2,
2006 which is attached hereto as Attachment"A"and made a part of this Agreement.
6. If at any time in the course of the design,the City expands the scope of services,or the Architect
believes the City has requested services that are beyond the scope of this Agreement,the Architect shall
submit a proposal for additional fees and a written agreement shall be reached on said proposal prior to
the Architect proceeding with the work considered to be beyond the scope of this Agreement.
Architect shall not perform any additional services without a written agreement with City. Any services
provided prior to reaching an agreement on additional fees will be non-compensable.
SECTION IV SPECIAL SERVICES OF ARCHITECT
1. If authorized in writing by City,Architect shall furnish or obtain from others special services necessary
to complete the Project. These special services are not included as part of the Basic Services outlined
in SECTION I- SERVICES OF THE ARCHITECT and Attachment"A." These special services will
be paid for by City as indicated in Section V.
SECTION V COMPENSATION TO ARCHITECT
1. The total compensation for all of the assignments to be performed by Architect to complete the Project
as described in CHARACTER AND EXTENT of ARCHITECT'S SERVICES and Attachment "A"
hereof shall be$19,612.00,hereinafter referred to as the"total fee."
2. Architect shall be paid the following percentages of the total fee at the following stages of the project:
1.1. Submission of Programming and Budget 80%
1.2. Final acceptance of the Submittal by the City 100%
1.3. Reimbursement of allowable expenses shall have prior approval of the City. Allowable expenses
include:
1.3.1.Printing Costs
1.3.2.Enhanced CAD drawings for public and City meetings.
1.3.3.Long distance phone calls
1.3.4.Postage and courier expenses
1.3.5. Other costs with prior approval of the City.
SECTION VI RESPONSIBILITY FOR CONSTRUCTION COSTS.....NOT APPLICABLE
SECTION VII METHOD OF PAYMENT
1. The Architect shall be paid not more frequently than once per month on the basis of statements
prepared from the books and records of account of the Architect, such statements to be verified as to
accuracy and compliance with the terms of this Agreement by an officer of the Architect. Payment
according to statements will be subject to certification by the Director, Transportation and Public
Works Department or his duly authorized representative that such work has been performed.
2. The above charges are on the basis of prompt payment of bills rendered and continuous progress of the
work on the Project until completion. If City fails to make any payment required herein for services
and reimbursable expenses within sixty days after approval of Architect's statement thereof, Architect
may, after giving seven days written notice to City, suspend services under this Agreement until
�'20�
Page 2 �v�tl U �5l�I�S1511�nI�SU
Architect has been paid in full all amounts due for services actually performed and reimbursable
expenses incurred.
SECTION VIII PROCEDURES FOR PROVIDING DESIGN SERVICES
1. Programming and Budget Phase:
1.1. The Architect shall visit the site and make himself familiar with the scope of the Project.
2. All documents and other work products of the Architect,whether in hard copy or in electronic form,are
instruments of service for this Project, whether the Project is completed or not. Reuse, change, or
alteration by the City or by others acting through or on behalf of the City of any such instruments of
service without the written permission of the Architect will be at the City's sole risk. The City shall
own the final documents. Transfer of ownership of the contract documents does not constitute sale of
the documents
SECTION IX CITY RESPONSIBILITIES
1. Provide criteria and information as to City's requirements and designate a person with authority to act
on City's behalf on all matters concerning the Project.
2. Assist Architect in obtaining existing studies, reports and other available data and services of others
pertinent to the Project and in obtaining additional reports and data as required.
3. Upon reasonable notice arrange for access to and make all provisions for Architect to enter upon public
and private property as may be required for Architect to perform services hereunder.
4. Designate in writing qualified persons who will act as City's representatives with respect to the Project
for the purposes of transmitting instructions, receiving information, interpreting and defining City's
policies and decisions with respect to Architect's services.
5. Review all reports, recommendations and other documents and provide written decisions pertaining
thereto within a reasonable time.
6. Examine all studies, reports, sketches, drawings, specifications, proposals and other documents
presented by Architect, obtain advice of an attorney, insurance counselor and other architects as it
deems appropriate for such examination and render in writing decisions pertaining thereto within a
reasonable time so as not to delay the services of Architect.
SECTION X TERMINATION
1. The City may terminate this Agreement at any time for convenience or for any cause by notice in
writing to the Architect. Upon receipt of such notice, the Architect shall immediately discontinue all
services and work and the placing of all orders or the entering into contracts for supplies, assistance,
facilities and materials in connection with the performance of this Agreement and shall proceed to
cancel promptly all existing contracts insofar as they are chargeable to this Agreement.
2. If the City terminates this Agreement under the foregoing paragraph, the City shall pay the Architect
for services performed in accordance herewith prior to such termination, less such payments having
been previously made. Such payment shall be based upon the work completed up to the date of
termination of the Agreement in accordance with the method of compensation prescribed in Sections V
and VI hereof. Architect shall also be compensated for all termination-related expenses such as
meeting attendance, document reproduction, transfer of records, etc. Provided, however, Architect
shall not be entitled to any compensation that exceeds the total fee to be paid hereunder at the
applicable phase as stated in Section V.
Page 3 �7
3. Upon early termination or conclusion of this Agreement, the Architect shall provide the City
reproducible copies of all completed or partially completed engineering documents prepared under this
Agreement that shall become the property of the City and may be used by the City in any manner it
desires. The Architect shall not be liable for the use of such materials for any project other than the
project described in this Agreement.
SECTION XI INDEMNITY AND INSURANCE
1. Approval by the City of contract documents shall not constitute or be deemed to be a release of the
responsibility and liability of the Architect, its officers, agents, employees and subconsultants, for the
accuracy and competency of the services performed under this Agreement, including but not limited to
surveys, location of subsurface investigations, designs, working drawings and specifications and other
Engineering documents.
2. Such approval shall not be deemed to be an assumption of such responsibility and liability by the City
for any negligent act, error or omission in the conduct or preparation of the subsurface investigations,
surveys, designs, working drawings and specifications and other Engineering documents by the
Architect, its officers, agents, employees and subconsultants, it being the intent of the parties that
approval by the City signifies the Citys approval of only the general design concept of the
improvements to be constructed.
3. In this connection the Architect shall indemnify and hold the City and all its officers, agents, servants
and employees harmless from any loss,damage,liability or expenses,on account of damage to property
and injuries, including death,to all persons, including but not limited to officers, agents, or employees
of the Architect or subconsultant, and all other persons performing any part of the work and
improvements, which may arise out of any negligent act, error or omission in the performance of the
Architect's professional services or in the preparation of designs, working drawings, specifications and
other documents.
4. The Architect shall defend at its own expense any suits or other proceedings brought against the City,
its officers, agents, servants and employees, or any of them on account thereof, and shall pay all
expenses and satisfy all judgments which may be incurred by or rendered against them arising out or
the indemnification; provided and except, however, that this indemnification provision shall not be
construed as requiring the Architect to indemnify or hold the City or any of its officers,agents, servants
or employees harmless from any loss, damages, liability or expense, on account of damage to property
or injuries to person caused by defects or deficiencies in design criteria and information provided to
Architect by City, or any deviation in construction from Architect's designs, working drawings,
specifications or other documents.
5. Without limiting the above indemnity, Architect shall maintain a policy of comprehensive general
liability insurance coverage with carriers acceptable to City in at least the following amounts:
Commercial General Liability $1,000,000 Per Occurrence
$2,000,000 Aggregate Limit
Workers Compensation
Coverage A: Statutory limits
Coverage B: Employers Liability Insurance
$100,000 Each Accident/Each Occurrence
$100,000 Disease—per each employee
$500,000 Bodily Injury/Disease—Policy Limit
Automobile Liability
$1,000,000 each accident on a combined single basis
DR
Page 4
OR
$250,000 Property Damage
$500,000 Bodily Injury per person per occurrence
Professional Liability Insurance
(Errors and Omissions) $1,000,000 Per occurrence
$2,000,000 Project aggregate
6. Architect shall furnish City a Certificate of Insurance in at least the above amounts. Certificate shall
contain a provision that such insurance cannot be canceled without 30 days prior written notice to City.
The City reserves the right to revise insurance requirements specified in this Agreement to the best
interests of the City.
7. General Insurance Requirements
7.1. Commercial General Liability coverage shall be endorsed to name the City an Additional Insured
thereon. The term"City" shall include its employees, officers, officials, agents, and volunteers as
respects the contracted services.
7.2. Certificate(s) of insurance shall document that insurance coverage specified are provided under
applicable policies documented thereon.
7.3. Any failure on part of the City to request required insurance documentation shall not constitute a
waiver of the insurance requirements.
7.4. A minimum of forty-five days notice of cancellation, non-renewal or material change in coverage
shall be provided to the City. A ten days notice shall be acceptable in the event of non-payment of
premium. Such terms shall be endorsed onto Architect's insurance policies. Notice shall be sent to
the Facilities Manager, Transportation and Public Works Department, 1000 Throckmorton, Fort
Worth,TX 76102.
7.5. The City shall not be responsible for the direct payment of any insurance premiums required by this
Agreement. It is understood that insurance cost is an allowable component of the Architect's
general overhead.
7.6. The City reserves the right to revise insurance requirements specified in this Agreement according to
the best interests of the City.
7.7. Insurers for all policies must be authorized to do business in the state of Texas or be otherwise
approved by the City; and, such insurers shall be acceptable to the City in terms of their financial
strength and solvency.
7.8. Deductible limits,or self-insured retentions,affecting insurance required herein may be acceptable to
the City at its sole discretion; and, in lieu of traditional insurance, any alternative coverage
maintained through insurance pools or risk retention groups must be also approved. Dedicated
financial resources or letters of credit may also be acceptable to the City.
7.9. The City shall be entitled, upon its request and without incurring expense, to review the Architect's
insurance policies including endorsements thereto and, at the City's discretion, the Architect may be
required to provide proof of insurance premium payments.
7.10.All insurance, except for the Professional Liability insurance policy, shall be written on an
occurrence basis.
7.11.The Professional Liability Policy shall be written on a"claims made"and shall be in effect for the
duration of this Agreement and for 12 months following Architect's issuance of the Certificate of
Substantial Completion. The Architect's current insurer shall list the City as a certificate holder
for a period of ten years following the issuance of the Certificate of Substantial Completion by the
Page s CITY Y MI CRE qg�,�}I(/U
Architect. The City shall be notified at least 30 days prior to cancellation or substantial change in
coverage.
8. The City shall require its General Contractor to include the Architect as an additional insured on its
general liability insurance.
SECTION XII HAZARDOUS MATERIALS
1. City acknowledges Architect will perform part of the work at City's facilities that may contain
hazardous materials, including asbestos containing materials, or conditions, and that Architect had no
prior role in the generation,treatment, storage,or disposition of such materials. In consideration of the
associated risks that may give rise to claims by third parties or employees of City, the City hereby
releases the Architect from any damage or liability related to the presence of such materials.
2. The release required above shall not apply in the event the discharge, release, or escape of hazardous
substances, contaminants, or asbestos containing materials is a result of Architect's negligence or if
Architect brings such hazardous substance, contaminant, or asbestos containing materials onto the
project site.
SECTION XIII RIGHT TO AUDIT
1. Architect agrees that the City shall,until the expiration of three(3)years after final payment under this
Agreement, have access to and the right to examine any directly pertinent books, documents, papers
and records of the Architect involving transactions relating to this Agreement. Architect agrees that the
City shall have access during normal working hours to all necessary Architect facilities and shall be
provided adequate and appropriate workspace in order to conduct audits in compliance with the
provisions of this section. The City shall give Architect reasonable advance notice of intended audits.
2. Architect further agrees to include in all its subcontracts hereunder a provision to the effect that the
subconsultant agrees that the City shall,until the expiration of three(3)years after final payment under
the subcontract, have access to and the right to examine any directly pertinent books, documents,
papers and records of such subconsultant, involving transactions to the subcontract, and further, that
City shall have access during normal working hours to all subconsultant facilities,and shall be provided
adequate and appropriate work space, in order to conduct audits in compliance with the provisions of
this article. City shall give subconsultant reasonable advance notice of intended audits.
3. Architect and subconsultants agree to photocopy such project-related documents as may be requested
by the City. The City agrees to reimburse Architect and subconsultant for the costs of copies at the rate
published in the Texas Administrative Code.
SECTION XIV SUCCESSORS AND ASSIGNS
1. The City and the Architect each bind themselves, their successors and assigns,to the other party to this
Agreement and to the successors and assigns of each other party in respect to all covenants of this
Agreement.
SECTION XV ASSIGNMENT
1. Neither party hereto shall assign, sublet or transfer its interest herein without prior written consent of
the other party, and any attempted assignment, sublease or transfer of all or any part hereof without
such prior written consent shall be void.
Page 6 vU0 UCUQ?,iiU:q
SECTION XVI INDEPENDENT ARCHITECT
1. Architect shall perform all work and services hereunder as an independent Architect, and not as an
officer, agent, servant or employee of the City. Architect shall have exclusive control of, and the
exclusive right to control the details of the work performed hereunder, and all persons performing
same, and shall be solely responsible for the acts and omissions of its officers, agents, employees and
subconsultants. Nothing herein shall be construed as creating a partnership or joint venture between
the City and the Architect, its officers, agents, employees and subconsultants, and doctrine of
respondent superior has no application as between the City and the Architect.
SECTION XVII M/WBE GOALS.....NOT APPLICABLE
SECTION XVIII OBSERVE AND COMPLY
1. Architect shall at all times observe and comply with all Federal and State laws and regulations and with
all City ordinances and regulations which in any way affect this Agreement and the work hereunder,
and shall observe and comply with all orders, laws,ordinances and regulations which may exist or may
be enacted later by governing bodies having jurisdiction or authority for such enactment. No plea of
misunderstanding or ignorance thereof shall be considered. Architect agrees to defend, indemnify and
hold harmless City and all its officers, agents and employees from and against all claims or liability
arising out of the violation of any such order, law,ordinance,or regulation,whether it be by itself or its
employees.
SECTION XIX MISCELLANEOUS
1. If any action, whether real or asserted, at law or in equity, arises on the basis of any provision of this
Agreement, venue for such action shall lie in state courts located in Tarrant County, Texas or the
United States District Court for the Northern District of Texas—Fort Worth Division. This Agreement
shall be construed in accordance with the laws of the State of Texas.
2. The parties acknowledge that each party and, if it so chooses, its counsel have reviewed and revised
this Agreement and that the normal rule of construction to the effect that any ambiguities are to be
resolved against the drafting party must not be employed in the interpretation of this Agreement or any
amendments or exhibits hereto.
3. This Agreement shall inure only to the benefit of the parties hereto and third persons not privy hereto
shall not, in any form or manner,be considered a third party beneficiary of this Agreement. Each party
hereto shall be solely responsible for the fulfillment of its own contracts or commitments.
IN TESTIMONY THEREOF,the City of Fort Worth has caused this instrument to be signed in triplicate in
its name and on its behalf, by its City Manager and attested by its City Secretary, with the Corporate Seal-
affixed; and the Architect has also properly executed this instrument in triplicate copies, each of which is
deemed an original.
Pagel
EK
EXECUTED IN THE CITY OF FORT WORTH,TEXAS,THIS 4th day of` A.D.,2006.
—L
GRW ENGINEERS,INC. APPRO D:
By: By:
Charles A.Willis,AIA,NCARB Marc tt
Vice President Assist t City Ma er
APPROVAL RECOMMENDED: RECORDED:
Gf5
By: — By:
Robert Goode,Director Marty Hendrix
Transportation and Public Works Department City Secretary
NO M&C REQUIRED
APPROVED ASTO AND LEG A T IIT
By: r r �' Date:
Amy J.Ramsey
Assistant City Attorney
The Texas Board of Architectural Examiners,8213 Shoal Creek Boulevard,Suite 107,Austin,Texas,78758,telephone(512)305-
9000,has jurisdiction over individuals licensed under the Architects'Registration Law,Texas Civil Statutes,Article 249a.
Page
1161 Corporate Drive West Engineering Cincinnati, OH
Suite 170 Architecture Indianapolis,IN
Arlington,TX 76006 Planning Knoxville,TN
Tel 817/543-1100 Lexington,KY
` Louisville,KY
GRW, Inc. Nashville,TN
June 2, 2006 p(�
Mr. Dalto rayama, AIA
Arc ' ctural Services Manager
City of Fort Worth
319 West 10th Street
Fort Worth, Texas 76102-4616
Dear Mr. Murayama,
Pursuant to our conversation in your offices earlier this week, I am pleased to provide you with
this letter proposal to undertake the programming phase of design services for the Fort Worth
Police Department and Helicopter Hangar Facility at Meacham International Airport.
During our meeting, you also indicated that the City is also interested in receiving a similar
proposal for programming the area surrounding the existing airport terminal building as a
possible development site for a City services center, air museum, airpark or other related
activities. We will undertake preparation of that proposal later and will discuss it with you further
at the appropriate time.
This proposal incorporates our proposed methodology and approach for the development a
detailed building program for the project. The project is potentially somewhat complex in that it
may involve other police department activities and functions in addition to helicopter operations
and maintenance. Therefore, I wish to stress that we are flexible in our approach to this
assignment and are prepared to explore creative options to finding the best solution to meet the
City's immediate and long-term needs. The attached scope of work is based upon our
understanding of the goals and objectives of the City and upon our understanding of the City's
proposed approach to the design of the project. The program is the point of departure for
detailed design development and the preparation of construction documents — but, more
importantly, it is the defining document which will give the project size, shape, scope, direction
and architectural character.
I have also enclosed a fee proposal for the programming effort, shown in Task 1.3.
1 hope this form of proposal is adequate for your purposes. We visualize an exciting and
challenging project and look forward to beginning work at the earliest possible time. In the
meantime, if you have available a proposed professional services contract that we can review,
I would appreciate receiving it as soon as possible.
Please contact me if you have any questions or comments concerning this proposal or if you
require any changes.
Sincerely,
Charles Willis, NCARB, AIA v, � � L R.E C 02"D
Vice President
01117
��7 SII? yc ., 55''771IU IOQI o4
J U iq,il.iC�UUI' YI�1'/ e
I o
a`.
FORT WORTH POLICE DEPARTMENT—AIR SUPPORT DIVISION
HELICOPTER HANGAR FACILITY
MECHAM INTERNATIONAL AIRPORT
TASK 1.0 — PROJECT PROGRAM/SCHEMATIC DESIGN
Project Program - We will prepare a detailed project program which identifies current and
future hangar requirements, and for any associated or attached structures. The program will
define functional requirements in terms of square footage and other characteristics that will
influence project design, construction costs and maintenance. Building materials and equipment
recommendations will be included in the project program. The project program will also present
the functional and physical relationships of uses and spaces, and will incorporate any special or
unique features that the City wishes to be in the building.
1.1 Data Collection
We will develop the basic programming information through the collection of data
from all appropriate sources, including the Police Department, Air Support
Division, Department of Aviation, FAA and others as required. We will prepare
questionnaires (to be approved by your office and Aviation) and will conduct at
least two workshop/visioning meetings.
The input from the users and affiliated interests will be compiled, analyzed and
formulated for specific application to the design process. A comparative analysis
of certain building features or systems will be prepared if appropriate; such
systems could be structural systems, mechanical equipment, fire protection,
exterior and interior finishes, etc.
Based upon the data collected a preliminary functional analysis will be prepared,
and an affinity matrix developed which will objectively show the relationships
between functions and activities. Emphasis will be placed upon clearly
delineating the required functions and facilities from those that are desired;
amenities will be identified and evaluated in terms of value added, life-cycle
issues and city policies.
1.2 Project Program Development
Specifically, the program will address the following major components of the
project:
• Functional Requirements - the necessary activities to be accommodated
and the relationship between them will -be defined. Utility and service
requirements, including electrical, water, sewer and gas requirements will be
defined.
• Siting Constraints Analysis - helicopter operational requirements,
helicopter parking, drainage or other issues, which may affect the way the
building is positioned on the site, will be analyzed. The helicopter parking
apron (size, configuration, and efficiency) and landing area will be of special
concern, and the apron layout and functional arrangement will be a primary
Page 1 Task 1.0 Propos - 2 0
CITY MC1 1"Ry
determinant in siting the hangar. Security, special functional requirements,
such as van or large vehicle parking or shelters, access and staff parking will
also be addressed. Overflight of neighborhoods during helicopter arrivals
and departures to the site will be analyzed for possible conflicts.
• Building Size—scale, square footage, height limitations, etc.
• Square Footage Requirements by Function — using the output of Task 1.1,
an analysis will be prepared of current and possible future needs, based upon
the anticipated uses of the hangar, and for other Fort Worth Police
Department requirements beyond the helicopter operational and
maintenance activities.
• Schematic Designs — based upon the size and space requirements, site
constraints and the input received in Task 1.1, we will prepare at least two
schematic designs, and will present them to the City for review and comment
in a workshop setting.
• Structural and Fabrication Requirements — it will be important to carefully
analyze options for building structural systems and for hangar doors.
Building orientation, wind exposure and loads, heating and cooling, fire
protection and other key construction elements will be considered in the
program. Foundation and hangar door design will be of principle interest, as
will the requirements for specialized maintenance equipment such as
overhead cranes, etc.
• Mechanical, Electrical, Plumbing Requirements — the project functional
and operational parameters will be used to evaluate and recommend building
mechanical, electrical and plumbing requirements. Specializing equipment
for communications and information technology will be included as a principle
area of interest in the program.
• Architectural Design Character — best materials for the area, architectural
appropriateness, appearance, maintenance, etc, will be studied and
recommendations made for consideration by the City, City representatives
including flight crews and flight department-management and others who may
have a role in programming hangar requirements.
• Cost Analysis and Budget — availability of materials, cost effectiveness of
certain construction techniques, etc, will be analyzed and presented in the
program. Alternatives to permit evaluation of potential cost savings will also
be prepared. A preliminary budget for the project will be prepared and
presented for review and comment in a workshop setting.
• Recommended Schedule — preparation of construction documents, bidding
and constructing the project will be prepared.
The schematic design(s) developed in Task 1.0 will be used for Site
Analysis/Geotechnical Investigations in Task 2.0, and Design Development in
Task 3.0.
Page 2 Task 1.0 P oftryvJu e;f09-K b
1.3 Fee Proposal and Schedule
We proposed to undertake Task 1.0 for a not-to-exceed fee of $19,612 based
upon our estimate of professional services required to complete the work
assumed in this proposal, as shown below.
ARCHITECTURAL FEES TASK 1.0
City of Fort Worth Police Helicopter Hangar Design
Project
Program/Schematic
Design
MANPOWER CLASSIFICATION HOURLY RATE MH AMT
Principal $140.00 30 $4,200.00
Senior Architect $92.00 45 $4,140.00
Architect $85.00 40 $3,400.00
Structural Designer/Engineer $92.00 24 $2,208.00
MEP Engineer $90.00 24 $2,160.00
Technician $60.00 44 $2,640.00
Clerical $48.00 18 $864.00
Geotechnical 0
Topographic Surveys 0
TOTAL 225 $19,612.00
Schedule —We estimate that eight weeks will be required to complete Task 1.0,
assuming not major delays in data collection or due to extended reviews.
0� 9(;1 6AIL 0C
Page 3 Task 1.0 Propo al-opffN _ Aly