HomeMy WebLinkAboutContract 35375CITY OF FORT WORTH, TEXAS t� �; f,, d`'���� �� ��
����� - �3�1�
STANDARD AGREEMENT FOR ENGINEERING SERVICES ���1_`- "�" �. .
This AGREEMENT is between the City of Fort Worth (the "CITY"), and TranSystems
Corporation d/b/a TranSystems Corporation Consultants (the "ENGINEER"), for a PROJECT
generally described as: Water and Sanitary Sewer Extensions to serve Hicks Industrial Park.
Article I
Scope of Services
A. The Scope of Services is set forth in Attachment A.
Article II
Compensation
A. The ENGINEER's compensation is set forth in Attachment B.
Article III
Terms of Payment
Payments to the ENGINEER will be made as follows:
A. Invoice and Payment
(1) The Engineer shall provide the City sufficient documentation to reasonably
substantiate the invoices.
(2) The ENGINEER will issue monthly invoices for all work performed under this
AGREEMENT. Invoices are due and payable within 30 days of receipt.
(3) Upon completion of services enumerated in Article I, the final payment of any
balance will be due within 30 days of receipt of the final invoice.
(4) In the event of a disputed or contested billing, only that portion so contested will
be withheld from payment, and the undisputed portion will be paid. The CITY
will exercise reasonableness in contesting any bill or portion thereof. No
interest will accrue on any contested portion of the billing until mutually
resolved.
(5) If the CITY fails to make payment in full to ENGINEER for billings contested in
good faith within 60 days of the amount due, the ENGINEER may, after giving 7
days' written notice to CITY, suspend services under this AGREEMENT until
paid in full, including interest. In the event of suspension of services, the
ENGINEER shall have no liability to CITY for delays or damages caused the
CITY because of such suspension of services.
STANDARD ENGINEERING AGREEMENT (REV 10/06lO5) t;,,;,,
Page 1 of 14 i 5 ���I;�; }�)
a '�( �
. ...i;;� �I.�.L4a .._�
��--...,
Art.icle IV
Obligations of the Engineer
Amendments to Article IV, if any, are included in Attachment C.
�
�
�
�
General
The ENGINEER will serve as the CITY's professional engineering
representative under this Agreement, providing professional engineering
consultation and advice and furnishing customary services incidental thereto.
Standard of Care
The standard of care applicable to the ENGINEER's services will be the
degree of skill and diligence normal(y employed in the State of Texas by
professional engineers or consultants perForming the same or similar services
at the time such services are perFormed.
SubsurFace Inves4igations
(1) The ENGINEER shall advise the CITY with regard to the necessity for
subcontract work such as special surveys, tests, test borings, or other
subsurFace investigations in connection with design and engineering
work to be performed hereunder. The ENGINEER shall also advise the
CITY concerning the results of same. Such surveys, tests, and
investigations shall be furnished by the CITY, unless otherwise specified
in Attachment A.
(2) In soils, foundation, groundwater, and other subsurFace investigations,
the actual characteristics may vary significantly between successive test
points and sample intervals and at locations other than where
observations, exploration, and investigations have been made. Because
of the inherent uncertainties in subsurFace evaluations, changed or
unanticipated underground conditions may occur that could affect the
total PROJECT cost and/or execution. These conditions and
cost/execution efFects are not the responsibility of the ENGINEER.
Preparation of Engineering Drawings
The ENGINEER will provide to the CITY the original drawings of all plans in ink
on reproducible plastic film sheets, or as otherwise approved by CITY, which
shall become the property of the CITY. CITY may use such drawings in any
manner it desires; provided, however, that the ENGINEER shall not be liable
for the use of such drawings for any project other than the PROJECT
described herein.
STANDARD ENGINEERING AGREEMENT (REV 10/06/05}
Page 2 of 14
� 'v��,.,��-.:���`,�J��i
�
`�� t;; :1�;.,;<<;s ,�,;;�,;
�.7U � I� V J� L��-L'1�. J
?nIf ,.t'� � p}j ��' j�17
' 'f U, .: ��.� 1: U �1 � ! � �.:,5 ,
1__- ._ -- __ -- - - _ _ --- - -__.__--. _ _ __ _- _ - _ _ -
E. Engineer's Personnel at Construction Site
(1) The presence or duties of the ENGINEER's personnel at a construction site,
whether as on-site representatives or otherwise, do not make the ENGINEER
or its personnel in any way responsible for those duties that belong to the
CITY and/or the CITY's construction contractors or other entities, and do not
relieve the construction contractors or any other entity of their obligations,
duties, and responsibilities, including, but not limited to, all construction
methods, means, techniques, sequences, and procedures necessary for
coordinating and completing all portions of the construction work in
accordance with the Contract Documents and any health or safety precautions
required by such construction work. The ENGINEER and its personnel have
no authority to exercise any control over any construction contractor or other
entity or their employees in connection with their work or any health or safety
precautions. �
(2) Except to the extent of specific site visits expressly detailed and set forth in
Attachment A, the ENGINEER or its personnel shall have no obligation or
responsibility to visit the construction site to become familiar with the progress
or quality of the completed work on the PROJECT or to determine, in general,
if the work on the PROJECT is being performed in a manner indicating that the
PROJECT, when completed, will be in accordance with the Contract
Documents, nor shall anything in the Contract Documents or the agreement
between CITY and ENGIMEER be construed as requiring EMGINEER to make
exhaustive or continuous on-site inspections to discover latent defects in the
work or otherwise check the quality or quantity of the work on the PROJECT.
If, for any reason, the ENGINEER should make an on-site observation(s), on
the basis of such on-site observations, if any, the ENGINEER shall endeavor
to keep the CITY informed of any deviation from the Contract Documents
coming to the actual notice of ENGINEER regarding the PROJECT.
(3) When professional certification of perFormance or characteristics of materials,
systems or equipment is reasonably required to perform the services set forth
in the Scope of Services, the ENGINEER shall be entitled to rely upon such
certification to establish materials, systems or equipment and performance
criteria to be required in the Contract Documents.
F. Opinions of Probable Cost, Financial Considerations, and Schedules
(1) The ENGINEER shall provide opinions of probable costs based on the
current available information at the time of preparation, in accordance
with Attachment A.
(2) In providing opinions of cost, financial analyses, economic feasibility
projections, and schedules for the PROJECT, the ENGINEER has no
control over cost or price of labor and materials; unknown or latent
conditions of existing equipment or structures that may affect operation or
maintenance costs; , competitive bidding procedures and market
conditions; time or quality of performance by third parties; quality, type,
STANDARD ENGINEERING AGREEMENT (REV 10/O6/05)
Page 3 of 14
f U� ��� �J�'1;�u�L� �I�G'ta
__ �
G.
H.
J.
management, or direction of operating personnel; and other economic
and operational factors that may materially affect the ultimate PROJECT
cost or schedule. Therefore, the ENGINEER makes no warranty that the
CITY's actual PROJECT costs, financial aspects, economic feasibility, or
schedules will not vary from the ENGINEER's opinions, analyses,
projections, or estimates.
Construction Progress Payments
Recommendations by the ENGINEER to the CITY for periodic construction
progress payments to the construction contractor will be based on the
ENGINEER's knowledge, information, and belief from selective sampling and
observation that the work has progressed to the point indicated. Such
recommendations do not represent that continuous or detailed examinations
have been made by the ENGINEER to ascertain that the construction
contractor has completed the work in exact accordance with the Contract
Documents; that the final work will be acceptable in all respects; that the
ENGINEER has made an examination to ascertain how or for what purpose
the construction contractor has used the moneys paid; that title to any of the
work, materials, or equipment has passed to the CITY free and clear of liens,
claims, security interests, or encumbrances; or that there are not other matters
at issue befinreen the CITY and the construction contractor that affect the
amount that should be paid.
Record Drawings
Record drawings, if required, will be prepared, in part, on the basis of
information compiled and furnished by others, and may not always represent
the exact location, type of various components, or exact manner in which the
PROJECT was finally constructed. The ENGINEER is not responsible for any
errors or omissions in the information from others that is incorporated into the
record drawings.
Minority and Woman Business Enterprise (M/WBE) Participation
In accord with City of Fort Worth Ordinance No. 15530, the City has goals for
the participation of minority business enterprises and woman business
enterprises in City contracts. Engineer acknowledges the M/WBE goal
established for this contract and its commitment to meet that goal. Any
misrepresentation of facts (other than a negligent misrepresentation) and/or
the commission of fraud by the Engineer may result in the termination of this
agreement and debarment from participating in City contracts for a period of
time of not less than three (3) years.
Right to Audit
(1) ENGINEER agrees that the CITY shall, until the expiration of three (3) years
after final payment under �his - co��tract, have access to and the right to
examine and photocopy an� d'irectly pertinent books, documents, papers and
�
STANDARD ENGINEERING AGREEMENT REV 10/06/0
� �
Page 4 of �4 , , _ � : ,
, `' " `���
s YU� .�':J��':i'lriU�1' ����ih
i i
records of the ENGINEER involving transactions relating to this contract.
ENGINEER agrees that the CITY shall have access during normal working
hours to all necessary ENGINEER facilities and shall be provided adequate
and appropriate work space in order to conduct audits in compliance with the
provisions of this section. The CITY shall give ENGINEER reasonable
advance notice of intended audits.
(2) ENGINEER further agrees to include in all its subconsultant agreements
hereunder a provision to the effect that the subconsultant agrees that the CITY
shall, until the expiration of three (3) years after final payment under the
subcontract, have access to and the right to examine and photocopy any
directly pertinent books, documents, papers and records of such
subconsultant, involving transactions to the subcontract, and further, that the
CITY shall have access during normal working hours to all subconsultant
facilities, and shall be provided adequate and appropriate work space, in order
to conduct audits in compliance with the provisions of this article together with
subsection (3)hereof. CITY shall give subcon-sultant reasonable advance
notice of intended audits.
(3) ENGINEER and subconsultant agree to photocopy such documents as may
be requested by the CITY. The CITY agrees to reimburse ENGINEER for the
cost of copies at the rate published in the Texas Administrative Code in effect
as of the time copying is perFormed.
K.
(1)
ENGINEER's Insurance
Insurance coverage and limits:
ENGINEER shall provide to the City certificate(s) of insurance documenting
policies of the following coverage at minimum limits that are to be in effect
prior to commencement of work on the PROJECT:
Commercial General Liability
$1,000,000 each occurrence
$2,000,000 aggregate
Automobile Liability
$1,000,000 each accident on a combined single limit
or
$250,000 Property Damage
$500,000 Bodily Injury per person per occurrence
A commercial business policy shall provide coverage on "Any Auto", defined
as autos owned, hired and non-owned when said vehicle is used in the
course of the PROJECT.
STANDARD ENGINEERING AGREEMENT (REV 10/06/05)
Page 5 of 14
;
± �; , i ....-._ :�:�`::='��a:J
I '"7;jj' ;:�,^';i;�;'rS'4 .``t?
� �t� �� u f �'C c� n;, 2 j�.-' �'l li
�
� �n �-� .�Illf ((�I'''��,Sr��,
�^I�� �1���`�J:�'U:U� J��!;�o
Worker's Compensation
Coverage A: Statutory limits
Goverage B: Employer's Liability
$100,000 each accident
$500,000 disease - policy limit
$100,000 disease - each employee
Professional Liability
$1,000,000 each claim
$2,000,000 aggregate
Professional liability shall be written on a claims-made basis and shall
contain a retroactive date prior to the date of the contract or the first date of
services to be perFormed, whichever is earlier. Coverage shall be maintained
for a period of 5 years following the completion of the contract. An annual
certificate of insurance specifically referencing this project shall be submitted
to the City for each year following completion of the contract.
(2) Certificates of insurance evidencing that the ENGINEER has obtained all
required insurance shall be delivered to the CITY prior to ENGINEER
proceeding with the PROJECT.
(a) Applicable policies shall be endorsed to name the CITY an Additional
Insured thereon, as its interests may appear. The term CITY shall include
its employees, officers, officials, agents, and volunteers as respects the
contracted services.
(b) Certificate(s) of insurance shall document that insurance coverage
specified in this agreement are provided under applicable policies
documented thereon.
(c) Any failure on part of the CITY to request required insurance
documentation shall not constitute a waiver of the insurance requirements.
(d) A minimum of forty-five (45) days notice of cancellation or material change
in coverage shall be provided to the CITY. A ten (10) days notice shall be
acceptable in the event of non-payment of premium. Such terms shall be
endorsed onto ENGINEER's insurance policies. Notice shall be sent to the
respective Department Director (by name), City of Fort Worth, 100D
Throckmorton, Fort Worth, Texas 76102.
(e) Insurers for all policies must be authorized to do business in the State of
Texas and have a minimum rating of A: VII in the current A.M. Best Key
Rating Guide or have reasonably equivalent financial strength and
solvency to the satisfaction of Risk Management.
STANDARD ENGINEERING AGREEMENT (REV 10l06/0�
Page 6 of 14 , J . . , �. .. . .: .
-,�1C �^ ��
1��� .,.���1:UJl} ��SG���
�
(f� Deductible limits, or self insured retentions, affecting insurance required
herein shall be acceptable to the CITY in its sole discretion; and, in lieu of
traditional insurance, any alternative coverage maintained through
insurance pools or risk retention groups must be also approved.
Dedicated financial resources or letters of credit may also be acceptable
to the City.
(g) Applicable policies shall each be endorsed with a waiver of subrogation in
favor of the CITY as respects the PROJECT.
(h) The City shall be entitled, upon its request and without incurring expense,
to review the ENGINEER's insurance policies including endorsements
thereto and, at the CITY's discretion, the ENGINEER may be required to
provide proof of insurance premium payments.
(i) The Commercial General Liability insurance policy shall have no
exclusions by endorsements unless the CITY approves such exclusions
in writing.
(j) For all lines of coverage underwritten on a claims-made basis, other than
Professional Liability, the retroactive date shall be coincident with or prior
to the date of the contractual agreement. The certificate of insurance
shall state both the retroactive date and that the covera�e is claims-
made.
(k) The CITY shall not be responsible for the direct payment of any
insurance premiums required by this agreement and all insurance
required in this section, with the exception of Professional Liability, shall
be written on an occurrence basis.
(I) Sub consultants and subcontractors to/of the ENGINEER shall be
required by the ENGINEER to maintain the same or reasonably
equivalent insurance coverage as required for the ENGINEER. When sub
consultants/subcontractors maintain insurance coverage, ENGINEER
shall provide CITY with documentation thereof on a certificate of
insurance.
L. Independent Consultant
The ENGINEER agrees to perForm all services as an independent consultant
and not as a subcontractor, agent, or employee of the CITY.
M. Disclosure
The ENGINEER acknowledges to the CITY that it has made full disclosure in
writing of any existing conflicts of interest or potential conflicts of interest,
including personal financial interest, direct or indirect, in property abutting the
proposed PROJECT and business relationships with abutting property cities.
STANDARD ENGINEERING AGREEMENT (REV 10/06/0�
Page7of14 v'�� �;�� �'�r�,� U� �
�� ��,� �J:
17I ' :� � �p;I;tb c: ��
p �7 Uo .�'::"J�:fl'f:l� �L✓La
L�
The ENGINEER further acknowledges that it will make disclosure in writing of
any conflicts of interest that develop subsequent to the signing of this contract
and prior to final payment under the contract.
N. Asbestos or Hazardous Substances
(1) If asbestos or hazardous substances in any form are encountered or
suspected, the ENGINEER will stop its own work in the affected portions of
the PROJECT to permit testing and evaluation.
(2) If asbestos or other hazardous substances are suspected, the ENGINEER
will, if requested, assist the CITY in obtaining the services of a qualified
subcontractor to manage the remediation activities of the PROJECT.
O. Permitting Authorities - Design Changes
If permitting authorities require design changes so as to comply with published
design criteria and/or current engineering practice standards which the
ENGINEER should have been aware of at the time this Agreement was
executed, the ENGINEER shall revise plans and specifications, as required, at
its own cost and expense. However, if design changes are required due to the
changes in the permitting authorities' published design criteria and/or practice
standards criteria which are published after the date of this Agreement which
the ENGINEER could not have been reasonably aware of, the ENGIfVEER
shall notify the CITY of such changes and an adjustment in compensation will
be made through an amendment to this AGREEMENT.
Article V
Obligations of the City
Amendments to Article V, if any, are included in Attachment C.
A. City-Furnished Data
ENGINEER may rely upon the accuracy, timeliness, and completeness of the
information provided by the CITY.
B. Access to Facilities and Properiy
The CITY will make its facilities accessible to the ENGINEER as required for
the ENGINEER's performance of its services and will provide labor and safety
equipment as required by the ENGINEER for such access. The CITY will
perform, at no cost to the ENGINEER, such tests of equipment, machinery,
pipelines, and other components of the CITY's facilities as may be required in
connection with the ENGINEER's services. The CITY will be re�pon�ible for all
acts of the CITY's personnel.
C. Advertisements, Permits, and Acces�s ,, :, �;�. :;,; �
`, � 1� ��'l �� �O�i i 1 J i J.�%/
STANDARD ENGINEERING AGREEMENT (REV 10/06/05) Y J � ��� J��v
Page8of14 J`��I � � �_f 5�? ���
� i;� I i
�.�i li u •
. .r �i ���'7�� `� �l �/ U J L' V' � �,; .
L!�
E.
F.
G.
Unless otherwise agreed to in the Scope of Services, the CITY will obtain,
arrange, and pay for all advertisements for bids; permits and licenses required
by local, state, or federal authorities; and land, easements, rights-of-way, and
access necessary for the ENGINEER's services or PROJECT construction.
Timely Review
The CITY will examine the ENGINEER's studies, reports, sketches, drawings,
specificafions, proposals, and other documents; obtain advice of an attorney,
insurance counselor, accountant, auditor, bond and financial advisors, and
other consultants as the CITY deems appropriate; and render in writing
decisions required by the CITY in a timely manner in accordance with the
project schedule in Attachment A.
Prompt Notice
The CITY will give prompt written notice to the ENGINEER whenever CITY
observes or becomes aware of any development that affects the scope or
timing of the ENGINEER's services or of any defect in the work of the
ENGINEER or construction contractors.
Asbestos or Hazardous Substances Release.
(1) CITY acknowledges ENGINEER will perform part of the work at CITY's
facilities that may contain hazardous materials, including asbestos
containing materials, or conditions, and that ENGINEER had no prior role
in the generation, treatment, storage, or disposition of such materials. In
consideration of the associated risks that may give rise to claims by third
parties or employees of City, City hereby releases ENGINEER from any
damage or liability related to the presence of such materials.
(2) The release required above shall not apply in the event the discharge,
release or escape of hazardous substances, contaminants, or asbestos is
a result of ENGINEER's negligence or if ENGINEER brings such
hazardous substance, contaminant or asbestos onto the project.
Contractor Indemnification and Claims
The CITY agrees to include in all construction contracts the provisions of
Article IV.E. regarding the ENGINEER's Personnel at Construction Site, and
provisions providing contractor indemnification of the CITY and the
ENGINEER for contractor's negligence.
STANDARD ENGINEERING AGREEMENT (REV 10/06/O5)
Page 9 of 14
� __ _ _- �, _
� - �, `_
, � r'J�.,;j;, �l �c;+':.'Ja'�u''
�J��/`�' ".,?.�;�.'�'j1�����,�1:��.1
--,���I �I7� /
I�y�a ^.��":J:. C 1l� U ���\ a
i
H. Contractor Claims and Third-Party Beneficiaries
(1) The CITY agrees to include the following clause in all contracts with
construction contractors and equipment or materials suppliers:
"Contractors, subcontractors and equipment and materials
suppliers on the PROJECT, or their sureties, shall maintain no
direct action against the ENGINEER, its officers, employees,
and subcontractors, for any claim arising out of, in connection
with, or resulting from the engineering services perFormed.
Only the CITY will be the beneficiary of any undertaking by
the ENGINEER."
(2) This AGREEMENT gives no rights or benefits to anyone other than the CITY
and the ENGINEER and there are no third-party beneficiaries.
(3) The CITY will include in each agreement it enters into with any other entity or
person regarding the PROJECT a provision that such entity or person shall
have no third-party beneficiary rights under this Agreement.
(4) Nothing contained in this section V.H. shall be construed as a waiver of any
right the CITY has to bring a claim against ENGINEER.
I. CITY's Insurance
(1) The CITY may maintain property insurance on certain pre-existing structures
associated with the PROJECT.
(2) The CITY will ensure that Builders Risk/Installation insurance is maintained at
the replacement cost value of the PROJECT. The CITY may provide
ENGINEER a copy of the policy or documentation of such on a certificate of
insurance.
(3) The CITY will specify that the Builders Risk/Installation insurance shall be
comprehensive in coverage appropriate to the PROJECT risks.
J. Litigation Assistance
The Scope of Services does not include costs of the ENGINEER for required
or requested assistance to support, prepare, document, bring, defend, or
assist in litigation undertaken or defended by the CITY. In the event CITY
requests such services of the ENGINEER, this AGREEMENT shall be
amended or a separate agreement will be negotiated between the parties.
K. Changes
The CITY may make or approve changes within the general Scope of Services
in this AGREEMENT. If such changes affect the ENGfNEER's cost of or time
required for perFormance of the services�, an equitable adjustment will be made
f �
STANDARD ENGINEERING AGREEMENT (REV 10/O6/0� .
Page 10 of 14 ;; � I�f �� � �, o�-r.�" �i ," 9
0
i:�J � ,:'S'.,.���jt��lrr
du'
❑ r��.;.,�^�c�-� [7 Ct7
� �y� �:yf�Ji!i 17i�i I1�(��"� �i �5\
J i "�l'J:��L' ��1i1�1
�"'�����
through an amendment to this AGREEMENT with appropriate CITY approval.
Article VI
General Legal Provisions
Amendments to Article VI, if any, are included in Attachment C.
A.
Q
C.
�a
Authorization to Proceed
ENGINEER shall be authorized to proceed with this AGREEMENT upon
receipt of a written Notice to Proceed from the CITY.
Reuse of Project Documents
All designs, drawings, specifications, documents, and other work products of
the ENGINEER, whether in hard copy or in electronic form, are instruments of
service for this PROJECT, whether the PROJECT is completed or not.
Reuse, change, or alteration by the CITY or by others acting through or on
behalf of the CITY of any such instruments of service without the written
permission of the ENGINEER will be at the CITY's sole risk. The CITY shall
own the final designs, drawings, specifications and documents.
Force Majeure
The ENGINEER is not responsible for damages or delay in performance
caused by acts of God, strikes, lockouts, accidents, or other events beyond the
control of the ENGINEER.
Termination
(1) This AGREEMENT may be terminated only by the City for convenience on
30 days' written notice. This AGREEMENT may be terminated by either the
CITY or the ENGINEER for cause if either party fails substantially to perform
through no fault of the other and does not commence correction of such
nonperformance with 5 days of written notice and diligently complete the
correction thereafter.
(2) If this AGREEMENT is terminated for the convenience of the City, the
ENGINEER will be paid for termination expenses as follows:
a.)
��
Cost of reproduction of partial or complete studies, plans, specifications
or other forms of ENGINEER'S work product;
Out-of-pocket expenses for purchasing storage containers, microfilm,
electronic data files, and other data storage supplies or services;
c.) The time requirements for the ENGINEER'S personnel to document the
work underway at the tim� the CITY'S termination for convenience so
,
STANDARD ENGINEERING AGREEMENT (REV 10/06/05)
Page 11 of 14
:1,
���J'u ;isv����;:�:'u'
7' l�, ��:'�: ��J,': L',f.' �� 1j
� '� U��4�
l�
(3)
E.
F.
G.
that the work effort is suitable for long time storage.
Prior to proceeding with termination services, the ENGINEER will submit to the
CITY an itemized statement of all termination expenses. The CITY'S approval
will be obtained in writing prior to proceeding with termination services.
Suspension, Delay, or Interruption to Work
The CITY may suspend, delay, or interrupt the services of the ENGINEER for
the convenience of the CITY. In the event of such suspension, delay, or
interruption, an equitable adjustmen� in the PROJECT's schedule,
commitment and cost of the ENGINEER's personnel and subcontractors, and
ENGINEER's compensation will be made.
Indemnification
(1) The ENGINEER agrees to indemnify and defend the CITY from any
loss, cost, or expense claimed by third parties for property damage and
bodily injury, including death, caused solely by the negligence or willful
misconduct of the ENGINEER, its employees, officers, and
subcontractors in connection with the PROJECT.
(2) If the negligence or willful misconduct of both the ENGINEER and the
CITY (or a person identified above for whom each is liable) is a cause of
such damage or injury, the loss, cost, or expense shall be shared
between the ENGINEER and the CITY in proportion to their relative
degrees of negligence or willful misconduct as determined pursuant to
T.C.P. & R. Code, section 33.011(4) (Vernon Supplement 1996).
Assignment
Neither party shall assign all or any part of this AGREEMENT without the prior
written consent of the other party.
H. Interpretation
Limitations on liability and indemnities in this AGREEMENT are business
understandings between the parties and shall apply to all the different theories
of recovery, including breach of contract or warranty, tort including negligence,
strict or statutory liability, or any other cause of action, except for willful
misconduct or gross negligence for limitations of liability and sole negligence
for indemnification. Parties mean the CITY and the ENGINEER, and their
officers, employees, agents, and subcontractors.
I. Jurisdiction
The law of the State of Texas shall govern the validity of this AGREEMENT, its
interpretation and perFormance, and any other claims related to it. The venue
for any litigation related to this AGREEMENT shall be Tarrant County, Texas.
STANDARD ENGINEERINGAGREEMENT(REV 10/06/05) , .
Page 12 of 14 ., �,
1Ir „
i U � �;l��.r J .� l�'is11�`�,
S �� 'V.,.,,,� �:�'`�', �� �,
I , �� �:�� �t
J. Alternate Dispute Resolution
(1) All claims, disputes, and other matters in question befinreen the CITY and
ENGINEER arising out of, or in connection with this Agreement or the
PROJECT, or any breach of any obligation or duty of CITY or ENGINEER
hereunder, will be submitted to mediation. If inediation is unsuccessful, the
claim, dispute or other matter in question shall be submitted to arbitration if
both parties acting reasonably agree that the amount of the dispute is likely to
be less than $50,000, exclusive of attorney's fees, costs and expenses.
Arbitration shall be in accordance with the Construction Industry Arbitration
Rules of the American Arbitration Association or other applicable rules of the
Association then in effect. Any award rendered by the arbitrators less than
$50,000, exclusive of attomey's fees, costs and expenses, will be final,
judgment may be entered thereon in any court having jurisdiction, and will not
be subject to appeal or modification except to the extent permitted by Sections
10 and 11 of the Federal Arbitration Act (9 U.S.C. Sections 10 and 11).
(2) Any award greater than $50,000, exclusive of attorney's fees, costs and
expenses, may be litigated by either party on a de novo basis. The award shall
become final ninety (90) days from the date same is issued. If litigation is filed
by either party within said ninety (90) day period, the award shall become null
and void and shall not be used by either party for any purpose in the litigation.
L:�
L.
Severability and Survival
If any of the provisions contained in this AGREEMENT are held for any reason
to be invalid, illegal, or unenforceable in any respect, such invalidity, illegality,
or unenforceability will not affect any other provision, and this AGREEMENT
shall be construed as if such invalid, illegal, or unenforceable provision had
never been contained herein. Articles V.F., VI.B., VI.D., VI.H., VI.I., and VI.J.
shall survive termination of this AGREEMENT for any cause.
Observe and Comply
ENGINEER shall at all times observe and comply with all federal and State
laws and regulations and with all City ordinances and regulations which in any
way affect this AGREEMENT and the work hereunder, and shall observe and
comply with all orders, laws ordinances and regulations which may exist or
may be enacted later by governing bodies having jurisdiction or authority for
such enactment. No plea of misunderstanding or ignorance thereof shall be
considered. ENGINEER agrees to defend, indemnify and hold harmless CITY
and all of its officers, agents and employees from and against all claims or
liability arising out of the violation of any such order, law, ordinance, or
regulation, whether it be by itself or its employees.
BTANDARD ENGINEERING AGREEMENT (REV 10/06/05)
Page 13 of 14
, , :
� � � r,� '�: - �.�: �
;
i�',I �l �;��[,'�r� ���'�'�� 1
3 l;'J�l G' :'•:i�'c�Li�.U:�l
� �;rcii 1•,4i' I� j��(
�1�� ..,.��:�I��; l� �»,
Article v� z
Attachments, Schedules, and Signatures
This AGREEMENT, including its attachments and schedules, constitutes the entire
AGREEMENT, supersedes all prior written or oral understandings, and may only be changed
by a written amendment executed by both parties. The following attachments and schedules
are hereby made a part of this AGREEMENT:
Attachment A- Scope of Services
Attachment B — Compensation
Attachment C- Amendments to Standard Agreement for Engineering Services
Attachment D - Project Schedule
Attachment E - Location Map
Executed this the (� `' � day of
ATTEST:
'- � 'V-- - . 2007.
� ,,
Marty Hendri
City Secretary
�� �,,�i �, / �� _ - �,� � �;; = J
�fi�tt act Authoriz��.a.o�
`�I�Ic,� `� .��-;�,yi
, �--.
U���
APPRO D �S TO F
�
�' l� -
Assi nt�Cit ttorrie�
� '
I
ATTEST:
STANDARD ENGINEERING AGREEMENT (REV 10/06/05)
Page 14 of 14
GALITY
CITY OF FORT WORTH
` J l�
By: �i�%�-i ,i
Marc A. Ott
Assistant City Manager
APPROVAL RECOMMENDED
A. Douglas Rademaker, P. E.
Director, Engineering Department
TranSystems Corporation d/b/a
TranSvstems Corporatiot� Con�
ENGINEER
:
Rau� Pena III,
Principal
4� : � , �.: � ,
:-'��'r��:�,:'-,.� .`��s!':?'����:i;;
��`9��1 �7' '\i��� �r��r �, �����
.t. ^�I a�'� ,,
� v�l::-',.is�=�!:
l��, �••� '(�
i:i��i li;(; ��L� � ir �10
�':�:� '/i� V'�G�{o y
— I
ATTACHMENT "A"
-�- ..- . -. -
"Scope of Services set forth herein can only be mod�ed by additions, cla�cations, and/or
deletions set forth in the supplemental Scope of Services. In cases of conflict between the
Supp/emental Scope of Services and the General Scope of Services, �he Supplementa1 Scope of
Services shall have precedence over the General Scope of Services. "
. ;_
1) Preliminary Conference with City
The Engineer shall attend preliminary conferences with authorized representatives of the
City regarding the scope of project so that the plans and specifications which are to be
developed hereunder by the Engineer will result in providing facilities which are
economical in design and conform to the City's requirements and budgetary constraints.
2) Coordination with Outside Agencies/Public Entities
The Engineer shall coordinate with officials of other outside agencies as may be
necessary for the design of the proposed street, and storm drain and/or water and
wastewater facilities/improvements. It shall be the Engineer's duty hereunder to secure
necessary information from such outside agencies, to meet their requirements.
3) Geotechnicallnvestigations
The Engineer shall advise the City of test borings, and other subsurface investigations that
may be needed. In the event it is determined necessary to make borings or excavate test
holes or pits, the Engineer shall in coordination with the City and the City's geotechnical
engineering consultant, draw up specifications for such testing program. The cost of the
borings or excavations 5hall be paid for by the City.
4) Agreements and Permits
The Engineer shall complete all forms/applications to allow the City of Fort Worth to obtain
any and all agreements and/or permits normally required for a project of this size and type.
The Engineer will be responsible for negotiating and coordinating to obtain approval of the
agency issuing the agreement and/or permits and will make any revisions necessary to
bring the plans into compliance with the requirements of said agency, including but not
limited to highways, railroads, water authorities, Corps of Engineers and other utilities.
5) Design Changes Relating to Permitting Authorities
If permitting authorities require design changes, the Engineer shall revise the plans and
specifications as required at the Engineers own cost and expense, unless such changes
are required due to changes in the design of the facilities made by the permitting authority.
If such changes are required, the Engineer shall notify the City and an amendment to the
contract shall be made if the Engineer incurs additi�nal cost if there� are unavoidable
;. �; ,
��� �;� � � b
-1- � ��, i 6 ����� �� � �;,,.,; �;�j
.t:; n`: �l 1 f S� �,�n
:��. .:,��:�iw�, J ���5�
delays, a mutually agreeable and reasonable time extension shall be negotiated.
6) Plan Submittal
Copies of the original plans shall be provided on reproducible mylar or approved plastic
film sheets, or as otherwise approved by the Department of Engineering and shall become
the property of the City. City may use such drawings in any manner it desires; provided,
however that the Engineer shall not be liable for the use of such drawings for any project
other than the project described herein; and further provided, that the Engineer shall not
be liable for the consequences of any changes that are made to the drawings or changes
that are made in the implementation of the drawings without the written approval of the
Engineer.
PHASE 1
7) Right-of-Way, Easement and Land Acquisition Needs
The Engineer shall determine the rights-of-way, easement needs for the construction of
the project. Engineer shall determine ownership of such land and furnish the City with the
necessary right-of-way sketches, prepare necessary easement descriptions for acquiring
the rights-of-way and/or easements for the construction of this project. Sketches and
easement descriptions are to be presented in form suitable for direct use by the
Department of Engineering in obtaining rights-of-way, easements, permits and licensing
agreements. All materials shall be furnished on the appropriate City forms in a minimum of
four (4) copies each.
8) Design Survey
The Engineer shall provide necessary field survey for use in the preparation of Plans and
Specifications. The Engineer shall furnish the City certified copies of the field data.
9) Utility Coordination
The Engineer shall coordinate with all utilities, including utilities owned by the City, as to
any proposed utility liens or adjustment to existing utility lines within the project limits. The
information obtained shall be shown on the conceptual plans. The Engineer shall show on
the preliminary and final plans the location of the proposed utility lines, existing utility lines,
based on the information provided by the utility, and any adjustments and/or relocation of
the existing lines within the project limits. The Engineer shall also evaluate the phasing of
the water, wastewater, street and drainage work, and shall submit such evaluation in
writing to the City as part of this phase of the project.
�- - -
., J 1 l'c�; � r;5- J./:. ,
yy� • ,,,y �,, �.��!it`+rna
u� �''L �l � u'1�� l.�i ll_�,� �, G
j I�S7 `;� f �; �;ti�q
� II . '911, � u �. S � �
-2- � _ �.,__
10) Conceptual Plans
The Engineer shall fumish four (4) copies of the Phase 1 concept engineering plans which
include layouts, preliminary right-of-way needs and preliminary estimates of probable
construction costs for the Engineer`s recommended plan. For all submittals, the Engineer
shall submit plans and documents for street/storm drain and water/wastewater facilities.
The Engineer shall receive written approval of the Phase 1 Plans from the City's project
manager before proceeding with Phase 2.
PHASE 2
11) Design Data
The Engineer shall provide design data, reports, cross-sections, profles, drainage
calculations, and preliminary estimates of probable construction cost.
12) Preliminary Construction Plans and Technical Specifications
The Engineer shall submit twenty (20) copies of Phase 2 preliminary construction plans
and five (5) copies of the preliminary technical specifications for review by the City and for
submission to utility companies and other agencies for the purposes of coordinating work
with existing and proposed utilities. The preliminary construction plans shall indicate
location of existing/proposed utilities and storm drain lines. The Engineer shall receive
written approval of the Phase 2 plans from the City's project manager before proceeding
with Phase 3.
PHASE 3
13) Final Construction Plans
The Engineer shall furnish five (5) copies of the final construction plans and coniract
specifications for review by the City.
14) Detailed Cost Estimate
The Engineer shall furnish four (4) copies of detailed estimates of probable construction
costs for the authorized construction project, which shall include summaries of bid items
and quantities.
15) Plans and Specification Approval
The Engineer shall furnish an original cover mylar for the signatures of authorized City
officials. The Contract Documents shall comply with applicable local, state and federal
laws and with applicable rules and regulations promulgated by local, state and national
boards, bureaus and agencies. The Engineer shall receive written approval of the Phase 3
plans from the City's project manager before proceeding with Phase 4.
,_, .�
1j :J ���`.JJ `.� 1:SJL/1•.v
S _ , r, ^, �^ @�
'��Jn'.. , � � �'o [ �i
1'�1 '�2c'I;�s�i.-�.?;�
, �s�:;..
?� �;;;'���,;;;Sjlt, I�I��:�,
-�J- i u� _. _ ....
PHASE 4
16) Final Approved Construction Plans
The Engineer shall fumish 45 bound copies of Phase 4 final approved construction plar�s
and contract specifications. The approved plans and contract specifications shall be used
as authorized by the City for use in obtaining bids, awarding contracts, and constructing
the project.
17) Bidding Assistance
The Engineer shall issue addenda as appropriate to interpret, clarify, or expand the
bidding documents, and assist the owner in determining the qualifications and
acceptability of prospective constructors, subcontractors, and suppliers. When substitution
prior to the award of contracts is allowed by the bidding documents, the Engineer will
advise the owner as to the acceptability of altemate materials and equipment proposed by
the prospective constructors.
18) Recommendation of Award
The Engineer shall assist in the tabulation and review of all bids received for the
construction of the project and shall make a recommendation of award to the City.
19) Prebid Conference
The Engineer shall attend the prebid conference and the bid opening, prepare bid
tabulation sheets and provide assistance to the owner in evaluating bids or proposals and
in assembling and awarding contracts for construction, materials, equipment, and
services.
PHASE 5
20) Preconstruction Conference
The Engineer shall attend the preconstruction conference.
21) Construction Survey
The Engineer sha11 be available to the City on matters concerning the layout of the project
during its construction and will set control points in the field to allow City survey crews to
stake the project. The setting of line and grade stakes and route inspection of construction
will be performed by the City.
22) Site Visits
The Engineer shall visit the project site at appropriate intervals as construction proceeds to
observe and report on the progress and the quality of the executed work.
;
� rn?i ��,1 ?�(���i��j�
d �, �;� ���, 1. '- r. S�� �'�s �%%
�� .
—4— i ��;'��,�� �'z,`';''ic��'?J;;'�1��
y �� '•��:; �•, ^.�' ll, ��;�n
;r,sp �'�G�.a
� J ' y,`Jf` �4i
23) Shop Drawing Review
The Engineer shall review shop and erection drawings submitted by the contractor for
compliance with design concepts. The Engineer shall review laboratory, shop, and mill test
reports on materials and equipment.
24) Instructions to Contractor
The -Engineer shall provide necessary inte[pretations and clarifications of contract
documents, review change orders and make recommendations as to the acceptability of
the work, at the request of the City.
25) Differing Site Conditions
The Engineer shall prepare sketches required to resolve problems due to actual field
conditions encountered.
26) Record Drawings
The Engineer shall prepare record drawings from information submitted by the contractor.
`:1f�i��;�5,1 �1,;'�(�Ji�?��✓
� �.1 ��e �"�1'S i','�i,:%ir
„� ; `+ �� i
�,�L �� :+Ic.lylj(�5�;�`.t:��
-s- ��� .. � �:�'n, U�����,
Street
Hicks Field
(Bus. 287. to
Dead-ends.)
Undeveloped
Land
(Wagley-
Robertson to
Hicks Field)
EXHIBIT "A-1"
SUPPLEMENTAL SCOPE OF SERVICES
(SUPPLEMENT TO ATTACHMENT "A")
DESIGN SERVECES: WATER AND/OR SANITARY SEWER IMPROVEMENTS
The following is a clarification of the tasks that the ENGINEER will perform under ATTACHMENT
"A". Work under this attachment includes engineering services for water and/or sanitary sewer
improvements for the following:
Water and Sanitary Sewer Improvements to Serve Hicks Industrial Park
D.O.E. No.: 5580
City Project No.: 00367
Council Pavement Pavement Curb � Curb & Water Line Sewer Line
Districts Type Condition Gutter Gutter
(Asphalt / (Good , (Yes / Condition Water Exist. Prop. Length Sewer Exist. Prop. Length
Concrete) Fair, No) (Good, Map Size Replacement (ft.) Map Size Replacement (ft.)
Poor) Fair, No. (In.) Size (In.) No. (In.) Size (In.)
Poor)
2030-
- 448 and 6�
2 Asphalt Fair No N/A 2030- None 12"
452 16"
2 I N/A I N/A I N/A I N/A I I - I -
560
5500
3100
2030-
448,
2036-
- 448, None
and
2030-
452
Total I 9160
Upon receipt of notice to proceed, the ENGINEER will perform the following tasks:
8" 1000
10" 5400
12" 4500
15" 2000
21" 4600
Total 17500
PARTA— PRE-ENGINEERING
1. Initial Data Collection
a. Pre-Design Coordination Meetings
ENGINEER will attend and document meetings, as required, to discuss and
coordinate various aspects of the project and to ensure that the project stays on
schedule. For purposes of establishing a level of comfort, two (2) meetings are
anticipated. These include the following:
EA1-1
Rev 11/02/OS
� � 1 � c .._ ,
� . 5 1 `\�7
i�� � �I'i ','�I, �i:�'�' �IYu��. �
� �� L � :; _. "✓ , .�
`•�o ; n nc;;,C S n�.
�'';' :;�;, ,.,D, �'�� V,� o
f p� � ";L''.11I!ltl�
�"^
One (1) pre-design kick-off meeting, (including the CITY's Department of
Engineering and other departments that are impacted by the project).
One (1) review meeting at completion of the City's review of the conceptual
engineering plans.
b. Data Collection
In addition to data obtained from the City, ENGINEER will research and
make efforts to obtain pertinent information to aid in coordination of the
proposed improvements with any planned future improvements that may
influence the project. ENGINEER will also identify and seek to obtain data
for existing conditions that may impact the project including; utilities, City
Master plans, property ownership as available from the Tax Assessor's
office.
The data collection efforts will also include conducting special coordination
meetings with affected property owners and businesses as necessary to
develop sewer re-routing plans.
The foJlowing shall be applicable at all locations where it is necessary to
relocate or reroute the existing private sanitary sewer service line due to
the abandonment or realignment of the existing public sanitary sewer
lateral or main:
The CITY shall furnish the Engineer with a sample format of how the sewer
service line reroute/relocation should be designed and submitted for
construction. During design survey, if a rod can be inserted through the
cleanout to the bottom of the service line, the Engineer will obtain the flow
line elevation and design the service line prior to advertising the project for
bid. If the service flow line information cannot be obtained during design
survey, the Engineer shall delay the design of the sewer service line until
after the start of construction. The CITY will then direct the Contractor to
de-hole the service line at the clean-out location of all buildings or
structures so that the Engineer's surveyor can determine the flow line of the
sewer service line. The Engineer shall use this information to provide the
design for the sanitary sewer service line to be rerouted or relocated.
c. Coordination with Other Agencies
EAl-2
Rev 11/02/OS
� � ,'1�:,, , ... a:.:�v'�._ ::�
--c-�: i �j
r.:I���•r �.�('i,��,��.���l�f�'I�.:r��
�'�J 1 � lr ., .. ��i .'8 :, liiti ���
�'1.�'� .i.�'�i ,[�n")� �'...al'�'
U� .. ���::�'J:� I
During the concept phase the ENGINEER shall coordinate with all utilities,
including utilities owned by the City, TxDOT and railroads. These entities
shall also be contacted if applicable, to determine plans for any proposed
facilities or adjustment to existing facilities within the project limits. The
information obtained shall be shown on the concept plans. The ENGINEER
shall show the location of the proposed utility lines, existing utility lines and
any adjustments and/or relocation of the existing lines within the project
limits. ENGINEER shall complete all forms necessary for City to obtain
permit letters from TxDOT and railroads and submit such forms to the City.
City shall be responsible for forwarding the forms to the affected agencies
for execution.
2. Schedule Submittal and Monthly Progress Report
The ENGIENER shall submit a progress schedute after the design contract is fully
executed. The schedule shall be updated and submitted to the CITY along with monthly
progress reports as required under Attachment B of the contract.
PART B- CONSTRUCTION PLANS AND SPECIFICATIONS
1. Conceptual Engineering
i. Surveys for Design
a. ENGINEER will perform field surveys to collect horizontal and vertical
elevations and other information which will be needed for use by the
ENGINEER in design and preparation of plans for the project.
Information gathered during the survey shall include topographic
data, elevations of all sanitary and adjacent storm sewers, rim/invert
elevations, location and buried utilities, structures, and other features
relevant to the final plan sheets. For sewer lines located in alleys or
backyards, ENGINEER will obtain the following:
Obtain permission for surveying through private property.
Locate horizontal and vertical alignment of utility lines. Tie
improvements, trees, fences, walls, etc., horizontally along rear lines
in an approximately 50' wide strip. In addition, locate all rear house
corners and building corners in backyards.
EA1-3
Rev 11/02/OS
( ._. :� �;, , �)
- i;sF��`.� :J
'�,��-,� �;lr,� _,.���• n`,?
� � �� '•. �
i � '. �,7 � � � � �U��\ �
E ���y��L J'��u,'�:.� +
??nl' 'i'',(=1 (j`I�I' I Sj �`y �'(
�J Uo '�l:-,✓�f�.U��� tlL'U�1a
Profile existing water and/or sewer line centerline.
Compile base plan from field survey data at 1"-40' scale.
Obtain permission for surveying through private property. Locate
horizontal and vertical alignment of utility lines, existing utilities, trees,
fences, walls, etc., horizontally along rear lot lines in an
approximately 20' wide strip. In addition, locate all rear house corners
and building corners in backyards. Compile base plan from field
survey data at 1" = 40' horizontal and 1" = 4' vertical scale.
When conducting design survey at any location on the project, the
consultant or its sub-consultant shall carry readily visible information
identifying the name of the company and the company
representative. All company vehicles shall also be readily identified.
b. Engineer will provide the following information:
All plans, field notes, plats, maps, legal descriptions, or other
specified documents prepared in conjunction with the requested
services shall be provided in a digital format compatible with the
electronic data collection and computer aided design and drafting
software currently in use by the CITY Department of Engineering.
All text data such as plan and profile, legal descriptions, coordinate
files, cut sheets, etc., shall be provided in the American Standard
Code for Information Interchange (ASCII) format, all drawing files
shall be provided in MicroStation (DGN) or Autocad (DWG or DXF)
format (currently Release 2002), or as otherwise approved in writing
by the CITY, and all data colleted generated during the course of
the project shall become the property of the CITY.
The minimum information to be provided in the plans shall include
the following:
1. A Project Control Sheet, showing ALL Control Points, used
or set while gathering data. Generally on a scale of not less
than 1:400:
2. The following information about each Control Point;
FsAl - 4
Rev 11/02/OS
i ;.: :J �_�� '�!.'J
��j l ���� , i � .li1�lr,,l
° `) .. � r -� :.��
�\. ��i�i.(� ��I��,•; o
%,���� ��".�� �J��� ��1�
�'i
a. Identified (Existing City Monument #8901, PK Nail,
5/8" Iron Rod)
b. X, Y and Z Coordinates, in an identified coordinate
system, and a referred bearing base. Z coordinate
on City Datum only.
c. Descriptive Location (Ex. Set in the centerline of the
inlet in the South curb line of North Side Drive at the
East end of radius at the Southeast corner of North
Side Drive and North Main Street).
3. Coordinates on all P.C.'s, P.T.'s, P.I.'s, Manholes, Valves,
etc., in the same coordinate system, as the Control Points.
4. No less than iwo bench marks plan/profile sheet.
5. Bearings given on all proposed centerlines, or baselines.
6. Station equations relating utilities to paving, when
appropriate.
7. Obtain the "foot print" of all properties where the sanitary
sewer service line is to be relocated or rerouted.
ii. Public Notification and PersonnelNehicle Identification
a. Prior to conducting design survey, ENGINEER will notify
affected residents of the project in writing. The notification letter
shall be on company letterhead and shall include the following:
project name, limits, DOE project no., Consultant's project
manager and phone no., scope of survey work and design
survey schedule. The letter will be reviewed and approved by
the City prior to distribution.
b. When conducting site visits to the project location, the
ENGINEER or any of its sub-consultants shall carry readily
visible information identifying the name of the company and the
company representative. All company vehicles shall also be
EA1-5
Rev 11/02/OS
, `r�i:i�:,�J:..' :�:s'�;��.��;:1
` � ' ": � �J ,. II.,,1 � ��
. '':::, i ��j �;:�, � o:�: � Us i!
' l l� SiC�,n
` ; �, -,� � ��� � � �;; ,
��._ ___.
readily identifiable.
iii. Conceptual Engineering Plan Submittal
a. 'Conceptual plans shall be submitted to City 90 days after
Notice to Proceed Letter is issued.
b. The ENGINEER shall perform conceptual design of the
proposed improvements and furnish four (4) copies of the
concept engineering plans which includes layouts,
preliminary right-of-way needs and cost estimates for the
ENGINEER's recommended plan. ENGINEER shall perform
remaining field surveys required for final design of selected
route(s). The ENGINEER shall also evaluate the phasing of
the water, sanitary sewer, street and drainage work, and
shall submit such evaluation in writing to the City as a part
of the concept phase of the project. All design shall be in
conformance with Fort Worth Water Department policy and
procedure for processing water and sewer design.
ENGINEER shall review the City's water and sewer master
plan, other pertinent design information and provide a
summary of findings pertaining to the proposed project.
2. Preliminary Engineering
Upon approval of Part B, Paragraph iii (b), ENGINEER will prepare
preliminary construction plans as follows:
a. Overall water and/or sanitary sewer layout sheets and an
overall easement layout sheet(s).
b. Preliminary project plans and profile sheets on 22" x 34"
sheets which show the following: Proposed water and/or
sanitary sewer plan/profile and recommended pipe size, fire
hydrants, water service lines and meter boxes, gate valves,
isolation valves, manholes etc., related appurtenances and
all pertinent information needed to construct the project.
Legal description (Lot Nos., Block Nos., and Addition
Names) along with property ownership shall be provided on
the plan view.
EA1-6
Rev 11/02/O5
"^:_�y�.:: � :,-,-���,, �,.�
' "_;�!' -�f
�;�.�:��i;�,.
�s I'�� �:'(1',�'.�i!!l' �I��n
� .� � G'10 �..
c. For sewer lines, pipelines schedule for point repairs,
rehabilitation and replacement will be located on the base
sheets prepared from survey information gathered under
Part B, Paragraph b. Conflicts shall be resolved where
pipelines are to be rehabilitated on the same line segment.
Base sheets shall reference affected or adjacent streets.
Where open-cut and trenchless technology construction is
anticipated, below and above ground utilities will be located �
and shown on the base sheets.
d. Existing utilities and utility easements will be shown on the
plan and profile sheets. ENGINEER will coordinate with
utility companies and the City of Fort Worth to determine if
any future improvements are planned that may impact the
project.
e. The design for sewer service line reroute/relocation will be
provided if the flow line elevation of the sewer service can
be determined from the cleanout location. If this elevation
cannot be determined during design survey, the design
shall be provided after award of the construction contract
as specified in Part A, Paragraph 1 b.
f. The ENGINEER shall make provisions for reconnecting all
identifiable water and/or wastewater service lines which
connect directly to any main being replaced, including
replacement of existing service lines within City right-of-
way or utility easement. When the existing alignment of a
water and sanitary sewer main or lateral is changed,
provisions will be made in the final plans and/or
specifications by the ENGINEER to relocate all service
lines which are connected to the existing main and
connect said service lines to the relocated main.
g. The ENGINEER will prepare standard and special detail
sheets for water line installation and sewer rehabilitation or
replacement that are not already included in the D-Section
of the City's specifications. These may include connection
details between various parts of the project, tunneling
EAl-7
Rev 11/02/OS
r , i
i_ u'�'1 �'.� ; �� �.�;;,I��
� -�1��. '�`-�,= .��,�r�.�r_�C,! �
� �.. �i � �� �d�� �., � �I�-�.:: ���
• � G� �
�._�.'r�� ':n,'{r�}p� r^l� ..�
� u 1.� ��� ���� ��`,�,G;�Op
J u� ��:i,':�Ia�)
�,��
Rev 11/02/OS
details, boring and jacking details, waterline relocations,
details unique to the construction of the project, trenchless
details, and special service lateral reconnections.
h. Right-of-Way Research
The ENGINEER will conduct preliminary research for
availability of existing easements where open-cut
construction or relocation of existing alignments is probable.
Temporary and permanent easements will be appropriated
based on available information and recommendations will
be made for approval by the City.
i. Right-of-way/Easement Preparation and Submittal
Preparation and submittal of right-of-way, easements and
rights-of-entry will be in conformance with "Submittal of
Information to Real Property for Acquisition of Properfy".
j. Utility Clearance Phase
The ENGINEER will consult with the City's Water
Department, Department of Engineering, and other CITY
departments, public utilities, private utilities and government
agencies to determine the approximate location of above
and underground utilities, and other facilities that have an
impact or influence on the project.
ENGINEER will design City facilities to avoid or minimize
conflicts with existing utilities.
The ENGINEER shall deliver a minimum of 13 sets of
approved preliminary construction plans to the City's Utility
Coordinator for forwarding to all utility companies, which
have facilities within the limits of the project.
k. Preliminary construction plan submittal
i. Preliminary plans and specifications shall be
submitted to City 60 days after approval of Part B,
EA1-8 I �,�
( ��li l j��..l.`.�J'��U '
'I � :✓
, —�a �
;;"�1i�' ''�ii"�I���!�,i�'`j�lt��!
�J'1 : � ; �
,:�1� r �,t
Y�: ��•✓}`���I�'��SI�G�o
Rev 11/02/OS
Paragraph iii (b).
ii. The ENGINEER shall deliver two (2) sets of
preliminary construction plans and two (2) sets of
specifications and contract documents to CITY for
review. Generally, plan sheets shall be organized as
follows:
Cover Sheet
General Notes/Legend
Easement layout (if applicable)
Abandonment
Plan & Profile Sheets
Standard Construction Details
Special Details (If applicable)
iii. The ENGINEER shall submit a preliminary estimate
of probable construction cost with the preliminary
plans submitted. ENGINEER shall assist City in
selecting the feasible and/or economical solutions to
be pursued.
I. Review Meetings with City
The ENGINEER shall meet with CITY to discuss review
comments for preliminary submittal. The CITY shall direct the
ENGINEER in writing to proceed with Final Design for Final
Review.
m. Public Meeting
After the preliminary plans have been reviewed and approved
by the City, the ENGINEER shall prepare project exhibits,
provide the CITY with the database listing the names and
addresses of all residents and business to be affected by the
proposed project, and attend public meeting to help explain the
proposed project to residents. The CITY shall select a suitable
location and mail the invitation letters to the affected customers.
EAl-9
-✓'J 1 3� J�:'.� k �_'.J .;J �
� � ', '. �' ' �
� t��'� ��'�`� '. ��I: i�; �I:fS:: �%
�J� � t+ �.�� �. . .
� � �� ��� �
' j� �1 �J��; U^�''„
� _;
Rev 11/02/OS
n. Storm Water Pollution Prevention Plan
ENGINEER will prepare the Storm Wafer Pollution Prevention
Plan (SWPPP) required for the project for use by the Contractor
during consfruction. Engineer will prepare drawings and details
for proposed SWPPP improvements that the Contractor must
use during construction. Contractor shall be responsible for
filing the SWPPP with appropriate regulatory agencies.
o. Trench Analysis
I. BASIC SERVICES
A. SUBSURFACE EXPLORATION
Evaluate subsurface conditions with sampie borings to a depth
of 10 feet below existing grades.
Cohesive and non-cohesive soil samples will be continuously
obtained using 3-inch diameter Shelby tube samplers and 2-
inch diameter standard split-spoon samplers, respectively. In
addition, rock encountered will be evaluated by use of Texas
Department of Transportation (TxDOT) cone penetration tests.
A soils logger will extrude the samples in the field, check the
samples for consistency with a hand penetrometer, carefully
wrap them to preserve their condition, and return them to the
laboratory for testing. A log of each boring will be prepared to
document field activities and results.
Personnel will stake the boring locations using normal taping
procedures. Approximate locations of the borings will be
shown on a plan of borings. Precise surveying of boring
locations and elevations will be done to show location of
boring in ROW. At the completion of drilling operations,
boreholes will be backfilled with drill cuttings and an asphalt or
concrete patch placed at the surface.
B. LABORATORY SERVICES
Laboratory tests will be required for classification purposes,
and to determine strength characteristics. The following types
of tests will be run:
• moisture content and soil identification
• liquid and plastic limit determinations
,
EAl-10 ' i ,
.�' ._'��....
�. ��J'�����i,y� i?',4�':,�I�;�i;i 1.r,,i
4� � '�: i ���� �' �
• � -�.o ��f i5°i
j�", : iJ .
14i ,uC�1i,�' '1��� d�45'�:�
�_ '.�
• unconfined compression tests on soil
• unit weight determinations
• moisture density relationship, Standard Proctor
procedure
The specific types and quantities of tests will be determined
based on geologic conditions encountered in the borings.
C. ENGINEERING SERVICES
An engineering report will be prepared to present the results of
the field and laboratory data together with analyses of the
results and recommendations for repair. We will provide three
copies of the report. The report will address:
• general soil and ground-water conditions
• cause(s) of trench backfill settlement
• recommendations for remedial measures
• earthwork recommendations
3. Final Construction Plan Submittal
a. Final Construction Documents shall be submitted to CITY 45 days after
approval of Part B, Paragraph 2 k.
Following CITY approval of the recommended improvements, the
ENGINEER shall prepare final plans and specifications and contract
documents to CITY (each plan sheet shall be stamped, dated, and signed
by the ENGINEER registered in State of Texas) and submit two (2) sets of
plans and construction contract documents within 15 days of CITY's final
approval. Plan sets shall be used for Part C activities.
b. ENGINEER's Estimate of Probable Construction Cost
The ENGINEER shall submit a final estimate of probable construction cost
with the final plans submitted.
c. Mylar Submittals
Rev 11/02/O5
F.'Al -11
1 J' , :, . . l . . _.' <i �.. . . �.
� . � T. �,. �I� : I� �,;:
v',� '�?�' L; C., ;( �,U;�, : d
� ':n'.� n�1J �I,,C�r
.i �a ..`;J1:�U`��+ �`�i,t:a
The ENGINEER shall submit a final set of mylar drawings for record
storage as follows:
1. Water and sanitary sewer plans shall be submitted as one
set of plans. Water and sanitary sewer plans shall be
separate from paving and drainage plans. All sheefs shall
be standard size (22" x 34") with all project numbers
(Water/Sanitary Sewer and TPW) prominently displayed.
2. For projects where paving/grating/drainage improvements
occur on a Water Department funded project with no T&PW
funding involved, a separate set of mylars with cover sheet
shall be submitted for TPW.
3. Signed plans sets shall also be submitted as an Adobe
Acrobat PDF format (version 6.0 or higher) file. There
shall be one (1) PDF file for the Water plan set and a
separate PDF file for the TPW plan set. Each PDF file shall
contain all associated sheets of the particular plan set.
Sinqular PDF files for each sheet of a plan set will not
be accepted. PDF files shall conform to naming
conventions as follows:
I. Water and Sewer file name example —"X-
35667_org36.pdf" where "X-35667" is the
assigned file number obtained from the City of Fort
Worth, "_org" designating the file is of an original
plan set, "36" shall be the total number of sheets in
this file.
Example: X-12755 org18.pdf
II. TPW file name example —"W-1956_org47.pdf'
where "W-1956" is the assigned file number
obtained from the City of Fort Worth, "_org"
designating the file is of an original plan set, "47"
shall be the total number of sheets in this file.
Example: W-0053 org3.pdf and K-0320_org5.pdf
EA1-12
Rev 11/02/OS
�� � � � '`(I, (1 �
.. ,'� jt,'tJ'� �}�n
. •I _,,• ;,C;,r:;�(�c��Jt�, �f`�f
� i� �� ,. .. � :> ( �
� �;�,a .."J:.U'ti� I��`�74
�
Both PDF files shall be submitted on one (1) Compact Disk, which will
become property of and remain with the City of Fort Worth. Floppv disks,
zip disks, e-mail flash media will not be accepted.
4. For information on the proper manner to submit PDF files
and to obtain a file number for the project, contact the
Department of Engineering Vault at telephone number (817)
392-8426. File numbers will not be issued to a project
unless the DOE number and proper fund codes have been
assigned and are in the Department of Engineering
database.
PART C - PRE-CONSTRUCTION ASSISTANCE
Administration
a. Deliver Bid Documents
The ENGINEER will make available for bidding, upon request by the CITY, up to
fifty (50) sets of the final approved and dated plans and specifications and contract
documents for the projects to the CITY for distribution to potential bidders.
Proposal will be delivered in electronic format.
b. Bidding Assistance
The ENGINEER shall assist the CITY during this phase including preparation and
delivery of any additional addenda prior to bid opening to plan holders and respond
to questions submitted to DOE by prospective bidders. Engineer shall attend the
scheduled pre-bid conference.
The ENGINEER shall assist in reviewing the bids for completeness and accuracy.
The ENGINEER shall attend the project bid opening, develop bid tabulations in
hard copy and electronic format and return four (4) copies of the bid tabulation,
along with the contract documents to the City within three (3) working days after
bid openings.
c. Assistance During Construction
The ENGINEER shall attend the pre-construction conference for the project. The
ENGINEER shall also consult with and advise the CITY on design and/or
Rev 11/02/05
construction changes, if necessary.
EAl-13 _�-._ ---
; } �,� �=�;->' ; �
�i;�`� � d, ,��,i�j �i
' . . . „ _ .. -._ 'Z,��9'':J ::LJ
r7
� �' �1 � � �' � �' ��(1�', IIl: ��
� 7 L �, �. . , ; �
,,� .^ �}� ���,�
� rV, .. '``:�'ui, �L�c�:,
°�',
u
ATTACHMENT "B"
COMPENSATION AND SCHEDULE
ENGINEERING DESIGN SERVICES ASSOCIATED WITH
Water and Sanitary Sewer Improvements to Serve Hicks Industrial Park
D.O.E. No.: 5580
City Project No. : 00367
I. Compensation
A. The Engineer shall be compensated a total lump sum fee of $348,032.00 as
summarized Exhibit "B-3A". Payment of the total lump sum fee shall be considered
full compensation for the services described in Attachment "A" and Exhibit "A-1" for
all labor, materials, supplies and equipment necessary to compensate the project.
The Engineer shall be paid monthly as described in Exhibit "B-1", Section 1— Method
of Payment. Upon receipt of invoices submitted by the Engineer, based on an
estimate of the percentage of completion of the project, not to exceed the milestone
limits described in EXHIBIT "B-1".
Each invoice is to be verified as to its accuracy and compliance with the terms of this
contract by an officer of the Engineer.
II. Schedule
Final Phase I Plans shall be submitted within 215 calendar days after the "Notice to
Proceed" letter is issued. This time frame does not include Client review periods of the
prescribed submittals as noted below.
A. Conceptual Engineering Plans —100 calendar days
B. Preliminary Engineering Plans and Contract Documents — 60 calendar days
C. Final Engineering Plans and Contract Documents — 45 calendar days
D. Final P�ans and Contract Documents for Bid Advertisement —10 calendar days
� �N � �
��i � '�i
,,, l �
B-� �� J t J'� , l. .�':�'., :; ..,��
� �; + �� i�>- ,0�1 nn
;' �j� ;� '�"'y'II!� �%'�4
� " ��;,1 '1� �7 lu''.: �Ua
V�u v—:. �
�� n
�� : ��„�1 �I��j St;� �
J � e .<�`J :��. I� J`� ��� i� u�` n
��
EXHIBIT "B-1"
(SUPPLEMENT TO ATTACHMENT B)
METHOD OF PAYMENT
ENGINEERING DESIGN SERVICES ASSOCIATED WITH
Water and Sanitary Sewer Improvements to Serve Hicks Industrial Park
D.O.E. No.: 5580
City Project No. : 00367
I. Method of Payment
Partial payment shall be made to the Engineer monthly upon City's approval of an invoice
from the Engineer outlining the estimated current percent complete of the project.
The aggregate of such monthly partial fee payments shall not exceed the following:
Until satisfactory completion of Exhibits "A-1", Conceptual Engineering Plan submittal and
approval by the City, a sum not to exceed 30 percent of the total lump sum fee.
Until satisfactory completion of Exhibits "A-1", Construction Plan submittal and approval by
the City, a sum not to exceed 60 percent of the total lump sum fee.
Until satisfactory completion of Exhibits "A-1", Final Construction Plan submittal and
approval by the City, a sum not to exceed 90 percent of the total lump sum fee.
The balance of fees, less previous payments, shall be payable after all of the pre-
construction meetings for the Project have been conducted.
Note: If the Engineer determines in the course of making design drawings and
specifications that the opinion of probable construction cost of $2,988,437.00 as
estimated in Exhibit "B-4" will be exceeded, whether by change in the scope of the
project, increased cost or other conditions, the Engineer shall immediately report
such fact to the CITY's Director of the Department of Engineering and, if so
instructed by the Director of the Department of Engineering shall suspend all work
hereunder.
j'_�-,;,;,; 1 �;ic�';�;jl`i�
( _; i ;' � •.. .: . i::'s':� J +�
i ,%,;�i �; "�4�" �ti5 u,'''+'if.��'�
y .:�f'l' .,._�.
�. _. � � � 1
2S '�"'_�1%SI�r�� �'�s�:
��� �..
B1-1 _ �.f�. -- _
EXHIBIT B-2
(SUPPLEMENTAL TO ATTACHMENT B)
SCHEDULE OF RATES
For The Year Beginning January 1, 2006
General Labor Category GLC FW-202
Technician V T5 115.00
Technician IV T4 98.00
Technician III T3 78.00
Technician II T2 65.00
Technician I T1 55.00
Surveyor V S5 115.00
Surveyor IV S4 105.00
Surveyor III S3 75.00
Surve or II S2 55.00
Surveyor I S1 45.00
Planner V P5 150.00
Planner IV P4 125.00
Planner III P3 85.00
Planner II P2 80.00
Planner I P1 70.00
inspector V 15 120.00
Inspector IV 14 85.00
Inspector III 13 80.00
Ins ector II 12 65.00
Ins ector I 11 55.00
Principal/Engineer V E5 220.00
Engineer IV E4 150.00
Engineer III E3 120.00
Engineer II E2 110.00
Engineer I E1 90.00
Clericallll C3 50.00
Clericalll C2 45.00
Clerical I C1 40.00
Architect IV AR4 130.00
Architect III AR3 125.00
Architect II AR2 80.00
Architect I AR1 65.00
Administrator V A5 300.00
Administrator IV A4 135.00
Administrator III A3 75.00
Administrator II A2 60.00
Administrator I A1 55.00
4 Man Survey Crew 4M 175.00
3 Man Survey Crew 3M 140.00
2 Man Survey Crew 2M 100.00
GPS Survey Crew 1 M 160.00 -
,
,� „�; � �`�
. !''':,�;. ., s._.�. � , 1�
✓'�Su•.t'' J ir.?'5�;1(',`ty
• d'� i.i J-. b 'J�'�
��y� �'•�'���' i�l�;�o
�J ' `•�`✓i�ili����V ��
0
EXHIBIT "B-3A"
(SUPPLEMENT TO ATTACHMENT B)
SUMMARY OF TOTAL PROJECT FEES
Water and Sanitary Sewer Improvements to Serve Hicks Industrial Park
D.O.E. No. 5580
City Project No. 00367
Consulting Firm Scope of Services
Prime Consultant:
TranSystems Design Services
M/WBE Consultants:
ANA Consultants Surveying, Property
Research / Rights of
Entry / Easements
Arlington Blueline Reproduction
Integrated Environmental Wetlands Delineation
Solutions
Stream Water Group Design Services
Non-M/V11BE Consultants:
CMJ Engineering, Inc. Geotechnical
B-3A
Totai Fee M/WBE
$348,032,00 $91,220
$56,740.00
$ 5,180.00
$ 4,500.00
$ 24,800.00
$14,412.00
Percent
26 %
% of Total
7%
4%
,-, ; � ; �
k � !"� ` IJ;✓ 7J:U
� � J ,. � q nP,�
�.''_J'��'� "�.Jlj�,i�I�i=1iJ:J
,�,n ' .^:, 'I,Lr. J'�`�%
i Y a �:�� �•:%'1:�1 �J 1� 9 G' : o
EXHIBIT "B-3B"
(SUPPLEMENT TO ATTACHMENT B)
PROFESSIONAL SERVICES FEE SUMMARY
Water and Sanitary Sewer Improvements to Serve Hicks Industrial Park
D.O.E. No.: 5580
City Project No. : 00367
Part A— Conceptual Design and Part B— Plans & Specification
Water Department: (Construction Cost X ASCE Curve "A" X 85%)
Water Improvements
Sanitary Sewer Improvements
Water: Basic Services Total
Additional Services:
Water Department:
$1,143,892 X 6.7% X 85% _$ 65,145
$1,844,545 X 6.7% X 85% _ $105,047
Design Survey
Easement Preparation (16 @ $750 EA.)
Route Study
Geotechnical
Environmental Site Assessment
Wetlands Delineation
COE Permitting
TxDOT Permitting
BNSF Railroad Permitting
Bid Opening / Pre-Construction Meetings
Public Meetings
Mounted Exhibits
Erosion Control Plans & SW3P
Printing and Reproduction
Administrative (10%) Fee on Sub-Consultants
Water: Additional Services Total
B-3B-1
$170,192
_ $44,740
_ $12,000
_ $48,604
_ $14,412
_ $10,307
_ $ 4,500
_ $ 5,422
_ $ 3,286
_ $ 3,286
_ $ 1,500
_ $10,000
_ $ 1,520
_ $ 5,000
_ $ 5,180
_ $ 8,083
_ $177,840
' � , t s, !�1
r ���.. �����
7v �, � 17 1'.�1,%
;�J,' ,_�r-.i�i�.t J
:� ; ��;, �,�,.1� j� � ;%`
�.., .u'JL3 Utu.,e
(INCLUDE THE FOLLOWING ON EXHIBIT "B-3B")
SUMMARY OF TOTAL FEE AND BREAKDOWN OF DESIGN FEE (LESS SURVEY FEE)
A. SUMMARY OF TOTAL FEE
Service Description Water Sewer Total
Engineering Services $115,251 $188,041 $303,292
Survey Services $17,039 $27,701 $44,740
Total $132,290 $215,742 $348,032
B. BREAKDOWN OF WATER, SEWER (LESS SURVEY FEES)
1. Total Water Fee (less survey fee) Breakdown by Concept, Preliminary and Final Desiqn
a. Concept (30%) _(Total Water Fee — Water Survey Fee) x 0.3) _$34,575
b. Preliminary (60%) _(Total Water Fee — Water Survey Fee) x(0.6)= $69,1518
c. Final (10%) _(Total Water Fee — Water Survey Fee) x(0.1) _$11,525
2. Total Sewer Fee (less survey fee) Breakdown by Concept, Preliminary and Final Desiqn
a. Concept (30%) _(Total Sewer Fee — Sewer Survey Fee) x 0.3) _$ 56,412
b. Preliminary (60%) _(Total Sewer Fee — Sewer Survey Fee) x(0.6)= $112,825
c. Final (10°/o) _(Total Sewer Fee — Sewer Survey Fee) x(0.1) _$ 18,804
� �,,- � . w
Jv{J,,�
� 1 i` _
,r� ! ;� . '�;;� ����� :r�7jr�� r-"?�
1�' „�.:
`�;J _��J� �S J �'�": L14�y i': . .
B-3B-2 ;,a� ;;7;'"`;,'���Il�� S�'7
�� .. �ri u¢t �L—l�.a
EXHIBIT 'B-3C"
(SUPPLEMENT TO ATTACHMENT B)
FEES FOR SURVEYING SERVICES
Water and Sanitary Sewer Improvements to Serve Hicks Industrial Park
D.O.E. No.: 5580
City Project No.: 00367
Surveying Services:
Water
Topographic Surveys
Sanitary Sewer
Topographic Surveys
Total for Surveying Services
�
$ 17,039
$ 27,701
$44,740
, .,-- �:. � �,:��,
' �:}i�" � `� :�'�v )�.'.�
�;; � 7 i i� '�.'�+; ' i}�'��!�'s '0J ��
C�1'�4 L ��`� �' �'�I.�
�l ,...'�`:�If;� �u��Z�
_ ' _.
EXHIBIT "B-3D"
(SUPPLEMENT TO ATTACHMENT B)
ADDITIONAL SERVICES
Water and Sanitary Sewer Improvements to Serve Hicks Industrial Park
D.O.E. No.: 5580
City Project No. : 00367
Additional Services:
Water Improvements :
Easement Preparation
Route Study
Geotechnical
Environmental Site Assessment
Wetlands Delineation
COE Permitting
TxDOT Permitting
BNSF Railroad Permitting
Bid Opening / Pre-Construction Meetings
Public Meetings
Mounted Exhibits
Erosion Control Plans & SW3P
Printing and Reproduction
Administrative (10%) Fee on Sub Consultants
Sub-Total Water
Sewer Improvements:
Easement Preparation
Route Study
Geotechnical
Environmental Site Assessment
Wetlands Delineation
COE Permitting
TxDOT Permitting
BNSF Railroad Permitting
Bid Opening / Pre-Construction Meetings
Public Meetings
Mounted Exhibits
Erosion Control Plans & SW3P
Printing and Reproduction
Administrative (10%) Fee on Sub Consultants
Sub-Total Sewer
Total for Additional Services
B-3 D
_ $ 4,560
_ $18,470
_ $ 5,477
_ $ 3,917
_ $ 1,710
_ $ 2,060
_ $ 1,249
_ $ 1,249
_ $ 570
_ $ 3,800
_ $ 578
_ $ 1,900
_ $ 1,968
= 3 072
_ $ 7,440
_ $30,134
_ $ 8,935
_ $ 6,390
_ $ 2,790
_ $ 3,362
_ $ 2,037
_ $ 2, 037
_ $ 930
_ $ 6,200
_ $ 942
_ $ 3,100
_ $ 3,212
= 5 011
$50,580
$82,520
. �^ ;
I 1����„ �;,'J
133 100 "
. � �� ,?
, J�j7�5�'����1 �
:� iJ� ..��✓�.:`I��f��� �i�i��o
a
l
EXHIBIT "B-3E"
(SUPPLEMENT TO ATTACHMENT B)
FEE FOR REPRODUCTION SERVICES
Water and Sanitary Sewer Improvements to Serve Hicks Industrial Park
D.O.E. No.: 5580
City Project No.: 00367
Printing & Reproduction:
Transportation & Public Works and Water Department:
Conceptual Design Report
4 sets of Report $.10Pg X 45 Pg/Report X 4 =$ 18.00
Preliminary & Utility Clearance Plans
16 sets of Constr. Plans $.72/Sht X 45 Sht/Plan X 16 =$ 518.40
2 Sets of Specifications $.10/image X 400 image/Spec X 2 =$ 80.00
Final Plans
5 Sets of Constr. Plans $.72/Sht X 45 Sht/Plan X 5 =$ 162.00
5 Sets of Specifications $.10/image X 400 image/Spec X 5 =$ 200.00
10 Half Size Constr. Plans $.18/Sht. X 45 Sht/Plan X 10 =$ 81.00
Bid Documents
50 Sets of Constr. Plans $.72/Sht X 45Sht/Plan X 50 =$ 1,620.00
50 Sets of Specifications $.10/image X 400 image/Spec X 50 =$ 2,000.00
Mounted Exhibits for Public Meetings
1 Drawings $ 4/Sht X 24 Each
Final Mylars for Record Purposes
1 Set of Plans $ 9.00/Sht X 45 ShfilPlan X 1
Printing & Reproduction Subtotal
B-3 E
TOTAL
_ $ 96.00
_ $ 405.00
_ $ 5,180.40
=$5,180
.��
4 .j -� ����� ' �:�
���;��i �����,1 � � a,:����U�
11^ J1�" �� ��,����;_y��`t.S��
,. �r 4;;�,�� J�'1 � al�� � ��5�`''
, �: ..
EXHIBIT "B-3F1
(SUPPLEMENT TO ATTACHMENT B)
FEE FOR ROUTE STUDY AND SERVICE AREA STUDY
Water and Sanitarv Sewer Improvements to Serve Hicks Industriai Park
D.O.E. No.: 5580
Citv Proiect No.: 00367
Hicks Industrial Park
HOURLY RATE WORK Total
Estimated Manhours Cost
Proj. Proj. Design CADD Survey RPLS Estimate
Prinicipal Mgr. Engr. Engr. Tech. Crew Clerical ($)
220.00 150.00 120.00 110.00 98.00 125.00 105.00 55.00
A General
Review City Service Plan and Annexation 2 4 $ 780.00
Review CityZoning and Landuse 1 8 $ 1,110.00
Develop ultimate population projections 4 16 $ 2,520.00
Determine Property Ownerships 8 12 $ 2,044.00
MeetingswithCity 8 8 $ 2,160.00
F�chibits 2 8 40 $ 5,180.00
Preparation of Report 4 12 20 24 $ 6,400.00
sub-total $ 20,194.00
B Sewer
Determine Service Area 2 8 $ 1,260.00
Drainage Basin Analysis 3 12 $ 1,890.00
Sanitary Sewer Sizing 3 12 $ 1,890.00
Opinions of Probable Cost 2 8 $ 1,260.00
ProRata Calculations 4 12 8 $ 2,360.00
sub-total $ 8,660.00
C Water
Determine Service Area 2 8 $ 1,260.00
Dtermine Water Demands 3 12 $ 1,890.00
Water line Sizing 4 8 $ 1,560.00
Opinions of Probable Cost 4 8 $ 1,560.00
ProRata Calculations 4 12 8 $ 2,360.00
sub-total $ 8,630.00
D Preliminary Route Study
Base Map 16 $ 1,568.00
Preliminary Research (Field Visits, Records, Utilities) 4 16 16 $ 5,200.00
Route Map 2 4 8 24 $ 4,3�2.00
sub-total $ 11,120.00
Total $ 48,604.00
* Fee does not include:
Surve ing of Existing Sewer Mains
_ "�;11.'J;'1 •��;�;i�
J! � � -.� .�S ..
` �`;i",j r; C,; I r5',+1i_.
u � � ��l'tl'
�,:��u � J�`::1.L�w—.szU
; ?l� ,,,—�,�U f�—f�,�
� �il� ,,.`J',.�iit I,c_.,
r
PAGE] .. __. ...: . �»__. _ . .
EXHIBIT "B-3F2
(SUPPLEMENT TO ATTACHMENT B)
ENVIRONMENTAL SITE ASSESSMENT - OFFSITE SEWER ALIGNMENT
Water and Sanitarv Sewer Improvements to Serve Hicks Industrial Park
D.O.E. No.: 5580
Citv Proiect No.: U0367
Hicks Industrial Park
HOURLY RATE WORK Total
Estimated Manhours Cost
Proj. Proj. Design CADD Estimate
Prinicipal Mgr. Engr. Engr. Tech. Clerical ($)
220.00 150.00 120.00 110.00 78.00 55.00
Comprehensive
Environmental Data Base Research 2 8 2 $ 1,290.00
Historical Property Deed Research 2 2 16 2 $ 1,878.00
Historical Aerial Photo Research 1 8 1 $ 1,085.00
Site Reconnaissance 8 8 $ 2,080.00
Report Preparation 2 2 16 8 8 $ 3,564.00
$ -
Sub-Total $ 9,897.00
Mileage $ 50.00
Exhibits / Reproduction $ 360.00
Sub-Total $ 410.00
Total $ 10,307.00
,_��_..�. �.._.
� �
j���.��, i � 1"L J � f���7
,. :�, � i5�'�� i
�; � ; ,� ;
� `v��,� 1� c,�S���,lt�� i;;;�"`• !•
,,� �-.�;�.���1 ���'-,(
':� �:
PAGEl . i, '.:,;;,I';;� ....�
�
EXHIBIT "B-3F3
(SUPPLEMENT TO ATTACHMENT B)
PERMITTING
Water and Sanitarv Sewer Improvements to Serve Hicks Industrial Park
D.O.E. No.: 5580
Citv Proiect No.: 00367
Hicks Industrial Park
HOURLY RATE WORK Total
Estimated Manhours Cost
Proj. Proj. Design CADD Survey RPLS Estimate
Prinicipal Mgr. Engc Engc Tech. Crew Clerical ($)
220.00 150.00 120.00 110.00 78.00 125.00 105.00 55.00
COMPREHENSIVE
Corps of Engineers Permit Application 2 20 24 2 $ 5,422.00
Wetlands Delineation (Sub-Consultant) $ 4,500.00
TxDOT Permit Application 2 12 12 2 $ 3,286.00
BNSF Permit Application 2 12 12 2 $ 3,286.00
sub-total $ 16,494.00
� ��_�_
� i � r[: ��I��
t�'t , , 'u
� •.� ��'! i `� 1. .� . ��.� �� �J h :7
-n��; � c.
�" 1 � �',� �, �?:. S U:��'; ?'! 1�
VJ1 6 u":`•`�
-,� F ;�,�`(I �i.�L�i�
7 Jc .+�:i'J:6 ��1 U Lvo
PAGE 1
EXHIBIT B-4
OPINION OF PROBABLE CONSTRUCTION COSTS
HICKS INDUSTRIAL PARK WATER AND SANITARY SEWER
Fort Worth, Texas
Date; 11-May-06
ITEM DESCRIPTION QUANTITY UNIT UNIT COST EXTENSION
Section A - Water
1 16" Water Main 3100 LF $56.00 173,600
2 12" Water Main 5500 LF $45.00 247,500
3 6" Water Line 560 LF $34.00 19,040
4 36" Steel Encasement (by bore) 100 LF $575.00 57,500
5 16" Gate Valve and Box 1 EA $3,800.00 3,800
6 12" Gate Valve and Box 3 EA $1,450.00 4,350
7 6" Gate Valve and Box 18 EA $650.00 11,700
8 Fire Hydrant 18 EA $1,970.00 35,460
9 2" Air Release Valve 2 EA $2,800.00 5,600
10 6" Blow-Off Assembly 2 EA $3,500.00 7,000
11 Concrete Blocking (Type E) 22 CY $55.00 1,210
12 2" Service 10 EA $375.00 3,750
13 2" Service Line 1000 LF $30.00 30,000
14 1" Service 16 EA $250.00 4,000
15 1" Service Line 1600 LF $20.00 32,000
16 Water Meter and Box 26 EA $242.00 6,292
17 Permanent Pavement Repair 7200 LF $55.00 396,000
18 Crushed Limestone 50 CY $22.00 1,100
Sub-Total 1,039,902
10% Contingency 103,990
Total Water Cost 1,143,892
Section B - Sewer
1 Connecting Junction Structure 1 LS $25,000.00 25,000
2 21" Sanita Sewer 4600 LF $62.00 285,200
3 15" Sanitary Sewer 2000 LF $52.00 104,000
4 12" Sanitary Sewer 4500 LF $46.00 207,000
5 10" Sanitary Sewer 5400 LF $52.00 280,800
6 8" Sanitary Sewer 1000 LF $36.00 36,00�
7 36" Steel Encasement (by bore) 80 LF $575.00 46,000
8 5' Dia. Manhole 13 EA $2,500.00 32,500
9 Extra Depth - 5' Manhole 26 VF $180.00 4,680
10 4' Dia. Manhole 21 EA $2,130.00 44,730
11 Extra Depth - 4' Manhole 42 VF $191.00 8,022
12 Manhole Insert 21 EA $100.00 2,100
13 Concrete Collar 34 EA $433.00 14,722
14 Vacuum Test (MH, JB) 35 EA $150.00 5,250
15 6" Sewer Service 26 EA $400.00 10,400
16 6" Service Line 2600 LF $45.00 117,000
17 2-Wa Cleanout 26 EA $180.00 4,680
18 Crushed Limestone 100 CY $22.00 2,200
19 Post N Inspecfion 15300 LF $1.50 22,950
20 Trench Excavation Protection 12500 LF $1.00 12,500
21 Permanent Pavement Repair 6200 LF $55.00 341,000
22 Concrete Encasement 200 LF $45.00 9,000
23 Rock Riprap 400 CY $60.00 24,000
24 Hydromulch Seeding 16500 LF $2.25 37,125
Sub-Total 1,676,859
10% Contingency 167,686
Total Sewer Cost 1,844,545
�e3
i `U'
TOTAL ESTIMATED CONSTRUCTION COST 2;988,437 `;
:, i
, i�
;�
. .. ._ .,,.�. ��,:s+�.e
f__._�.._ --a-
ATTACHMENT "C"
CHANGES AND AMENDMENTS TO STANDARD AGREEMENT
AND
ATTACHMENT "A"
Water and Sanitary Sewer Improvements to Serve Hicks Industrial Park
D.O.E. No.: 5580
City Project No. 00367
ADMENDMENTS TO ARTICLES IV, V, AND VI AND ATTACHMENT "A"
Article IV.K.(2)(i):
Endorsements are noted on the Certificate of Insurance provided to the City for
this project.
Article IV.K.(2) (I):
Business automobile insurance is written on an accident basis.
Article VI.L., line 4:
Remove the following: "or may be enacted later"
Attachment A, Item 26:
Delete this item, the Engineer will not prepare "record drawings" for this project.
�`� i'' ;:: 1 � .��,,lj�;;jj�
�_ ry• ,,.:r ;,.� ��,2 ;!,t :�h9
�i. � L' �>5 '�' l; L��1.. �
�� � ��, j ,,
, �
K:�Proposals�F't. Worth Office�.Sector 2- DOT-Municipali6es�,Sector 2- Municipal\City-Fort Worth�2006�B202060287 - CFW Hicks Industrial
Park Water & Sewer Main Exten. Design\contract documents�Attachment C.doc C-1
�
� ,
� ------------------------------------------------------------- �
� �
0
� � �
o� �
M ((^^^^�� � �
� � f0
��'.
� � �� �
0
� �
��
� o�
� N =----- ; �---"--'----------'--"'--------'----"'--'---"'------"-
d
G1 a'Y.. d' �
o� oa � �
� ` •;:
F- .c Q- �a
Z���� (� (O f� 1� I` t� I` f� !� f� t� h t� f� h h 1� c0 �e0 00
W�—+-' o 0 0 0,o 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
_��� N (��7 (D � c- O O M (D C�O O c�- � � � � � �
�',� r N N � i j N N N .� N N ` r- r' N � 0 r�.. � N
� fn c- � r � 00 f�7 M � (O (O 1` � � � � � O
() C d C' v `" a� a� 7 a> a� a� � a� a� a� N N a� u> a� � � r"
Q ' fn ii a� a� � � �-- > > > I- > > > > > � 3 � F- F- �
E- .� Z,,Y �� t- f- F- f- F- �- �- �- t- �- �- f- �-- �
a �,�°•`-'
�' �_ _ (O (D (O (O h t� h ti h h 1� h I� I` h I` f� 1� e0 a0
� O O O O O O O O O O O O O O O O O O O O
� ` � O d`�' � V' O d' (`D 1� � c�- � (O � O N
� N N �. � � N N d. N N c- i-- c- N � � � �
"Ci y r � � C� .� .� C7 (�7 -0 (O � h � m m r- O N 'O
_ 'O 'O N N '� � 'D � N "O '� N U 'D N 7 N
� � � � � � � � � �' � � �' � � �' � � �' � ~ �
�
�
� � �/7 N Ul N � tn � fn Vl � N N tq t/1 N fn N N � �
C >, T T T >+ T T T >. T T >+ >, T >+ T T T >. T
� (6 (V (V (II (U (D (4 (6 (9 fU @ f0 (D (0 (0 (0 f9 (D (9 [0
- 'D 'D 'O 'D 'D � "a '0 '� 'D 'O � � � 'O V '� 'O 'O "O
mo 0 0 0 0 0 0 0 0 0 0 0�n o 0 0 0 0 0 0,
N <F N N o0 'd' �- c� .- �t �- <- cD
❑ N I
U (/) U� U) (n
N t/� C � C �C �C 'D
�n � o m ro m m �
� � � � � � � �
v 2
a> � �> j c�a m c�o m ¢
U C � � U O' O.. a. � d � d (6 C (D
a� ����� Q o� 3 0� 3 0� 3 0�°� o
� � N � C C C U � •� U � � U � •j U � N � U
Z � � N N ` � � 2 � � ` � � � � N U �
a� � o E E �n � cn � v) � �C �
� o m o � m c�v o o�' o o�' o o� o �� 3 0
�— Z 0�� W W U M U U cD U U rn U U u.. Q Q U
� � �
� N ch d� U") c0 I� eo O) � `- N c7 t � cD � oo rn o
r- � � � �- � N
��
�
�
� O
Y �
N �
f -' �
m �o c
c c •
� � �
ca
W W �
a�i
t
U
�
U
N
�O
�.
O
a� �o
�o
U�
N�
Q �
7
U ~
N dj
�O �
a`o
CITY OF FORT WORTH
FORT WORTH
ATTACHMENT E-1
WATER AND SEWER IMPROVEMENTS --
TO SERVE ��.. J ! ':';�..,.1 �� i;r,1t✓',:, .,
HICKS INDUSTRIAL PARK <:�5�;,,• :�:s�,i;;�5�, ;'
; �� I: �s :: �i� �'���:i. .
_ � L r,
�
�`i�;;:,;lli��l ���;�
, .. ,:, .. � r�; � . . ,
m • Systems
�i31dM „9� 1SIX3
v
WW
zz
J �
��
W W
Q Q
� � �
Z ��
� O�
w �x
J � W
-,`1.
'>!- -.. 1;_ .
� ;,� �.,�,.�; -
c � ,::'�
,,; �,� 5,,,
`r:�r ! �
�": . .. �
N
�
d'
O
t�NN
N�O�
Z X
�F-�
U
°25��
��
d'�O
d'� Z
OJ�
�UU
N��
� O �
� �
W �'
Z z
J �J
N � Y
i w w �
W ¢ > �
I-- � � .�
Z _ Q
w � ��
� � �
_ �s �
U _ zo
Q N Q?
� � �
� o �
a �w � �
o �'-� _
a �
o Q
� �
a
.
.
.
.
.
.
.
wW
zz
J —J
��
W w
� �
W W
� (/') �
Z ��
� O�
W �X
J O_ W
,=�, � =; ,,,
`;:,�,�,, `:.
�
�-
d-
c�
r'')
O
N
�
o2f
N
�NN
�O?-
O Z X
�
O�-�
N U
���
_ �.
��
� Q O
O=�O
r7 U U
OZ(/')
N��
O Q
CnU�
�
I--
� Z
w W
Z �
J W
�
� W O �
W w � �
� a'
z= �Q
�
W N � �
� � W tn
'._, '— � o
w
Q � �z
�
Q �w >- Y
o a=
a �
� z
a Q
�
City of Fort Worth, Texas
Mayor and Council Communication
COUNCIL ACTION: Approved on 5/22/2007
DATE: Tuesday, May 22, 2007
LOG NAME: 30HICKSREC-TS
rage 1 or .
REFERENCE NO.: **C-22125
SUBJECT:
Rescind Authorization to Execute Agreement with TranSystems Corporation and Authorize an
Engineering Agreement with TranSystems Corporation d/b/a TranSystems Corporation Consultants
for Water and Sanitary Sewer Extensions to Serve Hicks Industrial Park
RECOMMENDATION:
It is recommended that the City Council:
1. Rescind authorization to enter into an engineering agreement with TranSystems Corporation, in the
amount of $348,032.00 forwater and sanitary sewer extensions to serve Hicks Industrial Park; and
2. Authorize the City Manager to execute
TranSystems Corporation Consultants, i
extension to serve Hicks Industrial Park.
DISCUSSION:
an engineering agreement with TranSystems Corporation d/b/a
n the amount of $348,032.00 for water and sanitary sewer
On April 3, 2007, (M&C C-22036) the City Council authorized the City Manager to execute an engineering
agreement with TranSystems Corporation in the amount of $348,032.00 for water and sanitary sewer
extensions to serve Hicks Industrial Park.
Subsequent to Council approval, it was determined that City staff had inadvertently listed the name of the
engineer as TranSystems Corporation, instead of TranSystems Corporation d/b/a TranSystems Corporation
Consultants.
This project is located in COUNCIL DISTRICT 7, Mapsco 19 W, X, Y and Z.
FISCAL INFORMATION/CERTIFICATION:
The Finance Director certifies that this action will have no material effect on City funds.
TO FundlAccount/Centers
Submitted for City Manager's Office by:
Originating Department Head:
Additional Information Contact:
FROM Fund/Account/Centers
Marc A. Ott (8476)
A. Douglas Rademaker (6157)
Liam Conlon (6824)
http://www. cfwnet. org/council_packet/Reports/mc_print. asp 5/22/200'
Page 2
http ://www. cfwnet. org/council_packet/Reports/mc_print. asp 5/2�/200'
Page 1 of
City of Fort Worth, Texas
Mayor and Council Communication
- -- -- --- - _ -- - - - : - -
COUNCIL ACTION: Approved on 4/3/2007 - Ordinance No. 17473-04-2007
- -----___- - --- --- — - -
DATE: Tuesday, April 03, 2007
LOG NAME: 30HICKS TSC REFERENCE NO.: *�`C-22036
SUBJECT:
Authorize Execution of an Engineering Agreement with TranSystems Corporation, for Water and
Sanitary Sewer Extensions to Serve Hicks Industrial Park and Adopt Appropriation Ordinance
-- -- --- --- -- — --- - — — ----
- ----,
RECOMMENDATION:
It is recommended that the City Council:
1. Authorize the transfer of $400,042.00 from the Water and Sewer Operating Fund to the Water Capital
Project Fund in the amount of $153,056.00 and Sewer Capital Projects Fund in the amount of $246,986.00;
2. Adopt the attached appropriation ordinance increasing estimated receipts and appropriation in the Water
Capital Projects Fund in the amount of $153,056.00 and the Sewer Capital Projects Fund in the amount of
$246,986.00, from available funds; and
3. Authorize the City Manager to execute an engineering agreement with TranSystems Corporation in the
amount of $348,032.00 for Water and Sanitary Sewer Extensions to Serve Hicks Industrial Park.
DISCUSSION:
On October 29, 2002; (M&C PZ-2420R) the City Council adopted Resolution 2884 placing approximately
7,000 acres into an annexation plan, which included the Hicks Industrial Park. A service plan for the
annexation area was developed and approved by City Council on March 30, 2004 (M&C PZ-2525). On
November 9, 2005, (M&C PZ-2648) the City Council adopted an ordinance for the annexation of
approximately 6,698 acres of land that included the Hicks Industrial Park.
The service plan requires that the water and sanitary sewer mains be installed respectively within two and a
half years and four and a half years from the effective date of annexation.
The City received proposals from twenty-two local engineering firms, in response to a request for proposals
for the design of this project. A selection committee comprised of Water and Engineering Department staff
reviewed the proposals and determined Trans Systems Corporation to be the most qualified for the design
of this particular project.
TranSystems Corporation proposes to perform the necessary design work for a lump sum fee of
$348,032.00. City staff considers this fee to be fair and reasonable for the scope of services proposed.
In addition to the contract amount, $52,010.00 (water: $20,766.00 and sewer: $31,244) is required for
project management by the Engineering Department.
TranSystems Corporation is in compliance with the City's M/WBE Ordinance by committing to 26 percent
http://www.cfwnet.org/council_packetlReports/mc_print.asp 5/1 �/2007
Page 2 of
M/V1/BE participation. The City's goal on the project is 26 percent.
This project is located in COUNCIL DISTRICT 7, Mapsco 19 W, X, Y and Z.
FISCAL INFORMATION/CERTIFICATION:
The Finance Director certifies that upon approval of the above recommendations and adoption of the
attached appropriation ordinance, funds will be available in the current capital budgets, as appropriated, of
the Water and the Sewer Capital Project Funds.
TO Fund/Account/Centers
� &2� $153,056.00
P264 472045 6071700367ZZ
� &� $246,986.00
P274 472045 7071700367ZZ
� $1,143.00
P264 531350 607170036710
� $4,286.00
P264 531350 607170036731
P264 531200 607170036731 $34,575.00
�
P264 531350 607170036732
�
P264 531200 607170036732
�
P264 531350 607170036733
�
P264 531200 607170036733
�
P264 531350 607170036742
�
P264 531200 607170036751
�
P264 531350 607170036773
�
P264 533010 607170036781
�
P274 531350 707170036710
�
P274 531350 707170036720
�
P274 531350 707170036731
�
P274 531200 707170036731
�
P274 531350 707170036732
�
P274 531200 707170036732
$8,572.00
$69,151.00
$1,429.00
$11,525.00
$2,000.00
$17,039.00
$1,000.00
$50.00
$1,819.00
$1,819.00
$6,821.00
$56,412.00
$13,642.00
$112,825.00
http://www. cfwnet. org/council_packet/Reports/mc_print. asp
FROM Fund/Account/Centers
� $34,575.00
P264 531200 607170036731
� $69,151.00
P264 531200 607170036732
� $11,525.00
P264 531200 607170036733
� $17,039.00
P264 531200 607170036751
� $56,412.00
P274 531200 707170036731
� $112,825.00
P274 531200 707170036732
�
P274 531200 707170036733
�
P274 531200 707170036751
$18,804.00
$27,701.00
1)PE45 538070 0709020 $246,986.00
1)PE45 538070 0609020 $153,056.00
5/1$/20q7
�
P274 531350 707170036733
�
P274 531200 707170036733
�
P274 531350 707170036742
�
P274 531200 707170036751
�
P274 531350 707170036760
�
P274 531350 707170036773
�
P274 533010 707170036781
�
P264 531350 607170036720
�
P264 531350 607170036760
$2,274.00
$18,804.00
$2,000.00
$27,701.00
$1,819.00
$1,000.00
$50.00
$1,143.00
$1,143.00
Submitted for City Manager's Office b�
Originating Department Head:
Additional Information Contact:
Marc A. Ott (8467)
A. Douglas Rademaker (6157)
Liam Conlon (6824)
Page 3 of
http://www. cfwnet. org/council_packet/Reports/mc_print. asp 5/1$/2007