HomeMy WebLinkAboutContract 35387� 5 +�1� I
;i { � �_:( /�i��
� � " i � E : ' c %`i I�9� . ����� _�
CITY OF FORT WORTH, TEXAS
STANDARD AGREEMENT FOR ENGINEERING SERVICES
This AGREEMENT is between the City of Fort Worth (the "CITY"), and MJ Thomas
Engineering, LLC., (the "ENGINEER"), for a PROJECT generally described as:
GREENBRIAR PARK ROAD & PARKING REPLACEMENT
Article I
Scope of Services
A. The Scope of Services is set forth in Attachment A.
Article II
Compensation
A. The ENGINEER's compensation is set forth in Attachment B.
Article III
Terms of Payment
Payments to the ENGINEER will be made as follows:
Invoice and Payment
The Engineer shall provide the City sufficient documentation to reasonably
substantiate the invoices.
The ENGINEER will issue monthly invoices for all work perFormed under this
AGREEMENT. Invoices are due and payable within 30 days of receipt.
Upon completion of services enumerated in Article I, the final payment of any
balance will be due within 30 days of receipt of the final invoice.
(4) In the event of a disputed or contested billing, only that portion so contested
will be withheld from payment, and the undisputed portion will be paid. The
CITY will exercise reasonableness in contesting any bill or portion thereof. No
interest will accrue on any contested portion of the billing until mutually
resolved.
(5) If the CITY fails to make payment in full to ENGINEER for billings contested in
good faith within 60 days of the amount due, the ENGINEER may, after giving
7 days' written notice to CITY, suspend services under this AGREEMENT until
paid in full, including interest. In the event of suspension of services, the
ENGINEER shall have no liability to CITY for delays or damages caused the
CITY because of such suspension of services.
STANDARD ENGINEERING AGREEMENT (REV 10/06/05)
Page 1 of 14
+ � � � 1 �;, I � � � '�,. �;,� � J �,i, J i
. ,I;I I�+1 ':I��'rl^'(ll1l,'i �
! l? � D G t:�:� �;; J � U,'rd','�l �f , �
� Js l�� `?;;`,J�:' J J �"����Z
i U��.� �
.-� _... _ �
Article IV
Obligations of the Engineer
Amendments to Article IV, if any, are included in Attachment C.
A.
B
C.
I �a
General
The ENGINEER will serve as the CITY's professional engineering
representative under this Agreement, providing professional engineering
consultation and advice and furnishing customary services incidental thereto.
Standard of Care
The standard of care applicable to the ENGINEER's services will be the
degree of skill and diligence normally employed in the State of Texas by
professional engineers or consultants performing the same or similar services
at the time such services are perFormed.
Subsurface Investigations
(1) The ENGINEER shall advise the CITY with regard to the necessity for
subcontract work such as special surveys, tests, test borings, or other
subsurFace investigations in connection with design and engineering
work to be perFormed hereunder. The ENGINEER shall also advise the
CITY concerning the results of same. Such surveys, tests, and
investigations shall be furnished by the CITY, unless otherwise specified
in Attachment A.
(2) In soils, foundation, groundwater, and other subsurFace investigations,
the actual characteristics may vary significantly between successive test
points and sample intervals and at locations other than where
observations, exploration, and investigations have been made. Because
of the inherent uncertainties in subsurface evaluations, changed or
unanticipated underground conditions may occur that could affect the
total PROJECT cost and/or execution. These conditions and
cost/execution effects are not the responsibility of the ENGINEER.
Preparation of Engineering Drawings
The ENGINEER will provide to the CITY the original drawings of all plans in ink
on reproducible plastic film sheets, or as otherwise approved by CITY, which
shall become the property of the CITY. CITY may use such drawings in any
manner it desires; provided, however, that the ENGINEER shall not be liable
for the use of such drawings for any project other than the PROJECT
described herein.
STANDARD ENGINEERING AGREEMENT (REV 10/06/05)
Page 2 of 14
r
� � , rS , �., -�,�
, �t':��':;�.� .�::5�«�1!.[��
'�; J 6' C/ �'{�'��1� ���, �� C1
�; � �� �;.1;?
�� �...:�..-,p �,,
( f ,.,� ,�I (
��, .y..��l I�I��� i���1, f
-s._.�..-��.-.�.t
E. Engineer's Personnel at Construction Site
(1) The presence or duties of the ENGINEER's personnel at a construction site,
whether as on-site representatives or otherwise, do not make the ENGINEER
or its personnel in any way responsible for those duties that belong to the
CITY and/or the CITY's construction contractors or other entities, and do not
relieve the construction contractors or any other entity of their obligations,
duties, and responsibilities, including, but not limited to, all construction
methods, means, techniques, sequences, and procedures necessary for
coordinating and completing all portions of the construction work in
accordance with the Contract Documents and any health or safety precautions
required by such construction work. The ENGINEER and its personnel have
no authority to exercise any control over any construction contractor or other
entity or their employees in connection with their work or any health or safety
precautions.
(2) Except to the e�ent of specific site visits expressly detailed and set forth in
Attachment A, the ENGINEER or its personnel shall have no obligation or
responsibility to visit the construction site to become familiar with the progress
or quality of the completed work on the PROJECT or to determine, in general,
if the work on the PROJECT is being perFormed in a manner indicating that the
PROJECT, when completed, will be in accordance with the Contract
Documents, nor shall anything in the Contract Documents or the agreement
between CITY and ENGINEER be construed as requiring ENGINEER to make
exhaustive or continuous on-site inspections to discover latent defects in the
work or otherwise check the quality or quantity of the work on the PROJECT.
If, for any reason, the ENGINEER should make an on-site observation(s), on
the basis of such on-site observations, if any, the ENGINEER shall endeavor
to keep the CITY informed of any deviation from the Contract Documents
coming to the actual notice of ENGINEER regarding the PROJECT.
(3) When professional certification of performance or characteristics of materials,
systems or equipment is reasonably required to perform the services set forth
in the Scope of Services, the ENGINEER shall be entitled to rely upon such
certification to establish materials, systems or equipment and perFormance
criteria to be required in the Contract Documents.
F. Opinions of Probable Cost, Financial Considerations, and Schedules
(1) The ENGINEER shall provide opinions of probable costs based on the
current available information at the time of preparation, in accordance
with Attachment A.
(2) In providing opinions of cost, financial analyses, economic feasibility
projections, and schedules for the PROJECT, the ENGINEER has no
control over cost or price of labor and materials; unknown or latent
conditions of existing equipment or structures that may affect operation or
maintenance costs; competitive bidding procedures and market
STANDARD ENGINEERING AGREEMENT (REV 10/06/05)
Page 3 of 14
... _ .: _ i
� S; �,
r_, 'I 8
'u � i�'�� ;�i � I:; :�� lt,ti' f� L�
�� 'r( � `, �
? ��j n
r 7��e ..��✓'L!iJl(l�� �l�G�:�
�..��._..�
conditions; time or quality of performance by third parties; quality, type,
management, or direction of operating personnel; and other economic
and operational factors that may materially affect the ultimate PROJECT
cost or schedule. Therefore, the ENGINEER makes no warranty that the
CITY's actual PROJECT costs, financial aspects, economic feasibility, or
schedules will not vary from the ENGINEER's opinions, analyses,
projections, or estimates.
G. Construction Progress Payments
Recommendations by the ENGINEER to the CITY for periodic construction
progress payments to the construction contractor will be based on the
ENGINEER's knowledge, information, and belief from selective sampling and
observation that the work has progressed to the point indicated. Such
recommendations do not represent that continuous or detailed examinations
have been made by the ENGINEER to ascertain that the construction
contractor has completed the work in exact accordance with the Contract
Documents; that the final work will be acceptable in all respects; that the
ENGINEER has made an examination to ascertain how or for what purpose
the construction contractor has used the moneys paid; that title to any of the
work, materials, or equipment has passed to the CITY free and clear of liens,
claims, security interests, or encumbrances; or that there are not other matters
at issue between the CITY and the construction contractor that affect the
amount that should be paid.
H. Record Drawings
Record drawings, if required, will be prepared, in part, on the basis of
information compiled and furnished by others, and may not always represent
the exact location, type of various components, or exact manner in which the
PROJECT was finally constructed. The ENGINEER is not responsible for any
errors or omissions in the information from others that is incorporated into the
record drawings.
I. Minority and Woman Business Enterprise (MNVBE) Participation
In accord with City of Fort Worth Ordinance No. 15530, the City has goals for
the participation of minority business enterprises and woman business
enterprises in City contracts. Engineer acknowledges the M/WBE goal
established for this contract and its commitment to meet that goal. Any
misrepresentation of facts (other than a negligent misrepresentation) and/or
the commission of fraud by the Engineer may result in the termination of this
agreement and debarment from participating in City contracts for a period of
time of not less than three (3) years.
J. Right to Audit
(1) ENGINEER agrees that the CITY shall, until the expiration of three (3) years
STANDARD ENGINEERING AGREEMENT (REV 10/06/05)
Page 4 of 14
after final payment under this contract, have access to and the right to
examine and photocopy any directly pertinent books, documents, papers and
records of the ENGINEER involving transactions relating to this contract.
ENGINEER agrees that the CITY shall have access during normal working
hours to all necessary ENGINEER facilities and shall be provided adequate
and appropriate work space in order to conduct audits in compliance with the
provisions of this section. The CITY shall give ENGINEER reasonable
advance notice of intended audits.
(2) ENGINEER further agrees to include in all its subconsultant agreements
hereunder a provision to the effect that the subconsultant agrees that the CITY
shall, until the expiration of three (3) years after final payment under the
subcontract, have access to and the right to examine and photocopy any
directly pertinent books, documents, papers and records of such
subconsultant, involving transactions to the subcontract, and further, that the
CITY shall have access during normal working hours to all subconsultant
facilities, and shall be provided adequate and appropriate work space, in order
to conduct audits in compliance with the provisions of this article together with
subsection (3)hereof. CITY shall give subcon-sultant reasonable advance
notice of intended audits.
(3) ENGINEER and subconsultant agree to photocopy such documents as may
be requested by the CITY. The CITY agrees to reimburse ENGINEER for the
cost of copies at the rate published in the Texas Administrative Code in effect
as of the time copying is perFormed.
K. ENGINEER's Insurance
(1) Insurance coverage and limits:
ENGINEER shall provide to the City certificate(s) of insurance documenting
policies of the following coverage at minimum limits that are to be in effect
prior to commencement of work on the PROJECT:
Commercial General Liability
$1,000,000 each occurrence
$2,000,000 aggregate
Automobile Liability
$1,000,000 each accident on a combined single limit
or
$250,000 Property Damage
$500,000 Bodily Injury per person per occurrence
A commercial business policy shall provide coverage on "Any Auto", defined
as autos owned, hired and non-owned when said vehicle is used in the
STANDARD ENGINEERING AGREEMENT (REV 10/06/05)
Page 5 of 14
course of the PROJECT.
Worker's Compensation
Coverage A: Statutory limits
Coverage B: Employer's Liability
$100,000 each accident
$500,000 disease - policy limit
$100,000 disease - each employee
Professional Liability
$1,000,000 each claim
$2,000,000 aggregate
Professional liability shall be written on a claims-made basis and shall
contain a retroactive date prior to the date of the contract or the first date of
services to be performed, whichever is earlier. Coverage shall be maintained
for a period of 5 years following the completion of the contract. An annual
certificate of insurance specifically referencing this project shall be submitted
to the City for each year following completion of the contract.
(2) Certificates of insurance evidencing that the ENGINEER has obtained all
required insurance shall be delivered to the CITY prior to ENGINEER
proceeding with the PROJECT.
(a) Applicable policies shall be endorsed to name the CITY an Additional
Insured thereon, as its interests may appear. The term CITY shall include
its employees, officers, officials, agents, and volunteers as respects the
contracted services.
(b) Certificate(s) of insurance shall
specified in this agreement are
documented thereon.
document that insurance coverage
provided under applicable policies
(c) Any failure on part of the CITY to request required insurance
documentation shall not constitute a waiver of the insurance requirements.
(d) A minimum of forty-five (45) days notice of cancellation or material change
in coverage shall be provided to the CITY. A ten (10) days notice shall be
acceptable in the event of non-payment of premium. Such terms shall be
endorsed onto ENGINEER's insurance policies. Notice shall be sent to the
respective Department Director (by name), City of Fort Worth, 1000
Throckmorton, Fort Worth, Texas 76102.
(e) Insurers for all policies must be authorized to do business in the State of
STANDARD ENGINEERING AGREEMENT (REV 10/06/05)
Page 6 of 14
; -_
� i�7 � L..� h SV�_'�iU
'C:JJU�r \:��v'iD�iS �'`��;"�i
�� 1..,�1`c,�,tl}1.
r�% �;n^n on
I� �I •Lt?Jii I',1: � ti �! i �,.
� � �;J ifl, � J L`:Li:,
L.
M.
Texas and have a minimum rating of A: VII in the current A.M. Best Key
Rating Guide or have reasonably equivalent financial strength and
solvency to the satisfaction of Risk Management.
(fi� Deductible limits, or self insured retentions, affecting insurance required
herein shall be acceptable to the CITY in its sole discretion; and, in lieu of
traditional insurance, any alternative coverage maintained through
insurance pools or risk retention groups must be also approved.
Dedicated financial resources or letters of credit may also be acceptable
to the City.
(g) Applicable policies shall each be endorsed with a waiver of subrogation in
favor of the CITY as respects the PROJECT.
(h) The City shall be entitled, upon its request and without incurring expense,
to review the ENGINEER's insurance policies including endorsements
thereto and, at the CITY's discretion, the ENGINEER may be required to
provide proof of insurance premium payments.
(i) The Commercial General Liability insurance policy shall have no
exclusions by endorsements unless the CITY approves such exclusions
in writing.
(j) For all lines of coverage underwritten on a claims-made basis, other than
Professional Liability, the retroactive date shall be coincident with or prior
to the date of the contractual agreement. The certificate of insurance
shall state both the retroactive date and that the coverage is claims-
made.
(k) The CITY shall not be responsible for the direct payment of any
insurance premiums required by this agreement and all insurance
required in this section, with the exception of Professional Liability, shall
be written on an occurrence basis.
(I) Sub consultants and subcontractors to/of the ENGINEER shall be
required by the ENGINEER to maintain the same or reasonably
equivalent insurance coverage as required for the ENGINEER. When sub
consultants/subcontractors maintain insurance coverage, ENGINEER
shall provide CITY with documentation thereof on a certificate of
insurance.
Independent Consultant
The ENGINEER agrees to perform all services as an independent consultant
and not as a subcontractor, agent, or employee of the CITY.
Disclosure
STANDARD ENGINEERING AGREEMENT (REV 10/06/05)
Page 7 of 14
� I[ I� II '^--.� I� �'I_'` J 1r11. .
;.�, J..,J� � ������vA1�
i ; ('1' �:;iC„";o � n;l (4i ,j
�; i � �` �� �� �,� ��?L �,: �:��
i I�� +:;'i;'�;'L;C� �;i�' n'��`��'
�J .t r\1��:�U��� YLu�:�.�....�
The ENGINEER acknowledges to the CITY that it has made full disclosure in
writing of any existing conflicts of interest or potential conflicts of interest,
including personal financial interest, direct or indirect, in property abutting the
proposed PROJECT and business relationships with abutting property cities.
The ENGINEER further acknowledges that it will make disclosure in writing of
any conflicts of interest that develop subsequent to the signing of this contract
and prior to final payment under the contract.
N. Asbestos or Hazardous Substances
(1) If asbestos or hazardous substances in any form are encountered or
suspected, the ENGINEER will stop its own work in the affected portions of
the PROJECT to permit testing and evaluation.
(2) If asbestos or other hazardous substances are suspected, the ENGINEER
will, if requested, assist the CITY in obtaining the services of a qualified
subcontractor to manage the remediation activities of the PROJECT.
O. Permitting Authorities - Design Changes
If permitting authorities require design changes so as to comply with published
design criteria and/or current engineering practice standards which the
ENGINEER should have been aware of at the time this Agreement was
executed, the ENGINEER shall revise plans and specifications, as required, at
its own cost and expense. However, if design changes are required due to the
changes in the permitting authorities' published design criteria and/or practice
standards criteria which are published after the date of this Agreement which
the ENGINEER could not have been reasonably aware of, the ENGINEER
shall notify the CITY of such changes and an adjustment in compensation will
be made through an amendment to this AGREEMENT.
Article V
Obligations of the City
Amendments to Article V, if any, are included in Attachment C.
A. City-Furnished Data
ENGINEER may rely upon the accuracy, timeliness, and completeness of the
information provided by the CITY.
B. Access to Facilities and Property
The CITY will make its facilities accessible to the ENGINEER as required for
the ENGINEER's performance of its services and will provide labor and safety
equipment as required by the ENGINEER for such access. The CITY will
perForm, at no cost to the ENGINEER, such tests of equipment, machinery,
STANDARD ENGINEERING AGREEMENT (REV 10/06/05)
Page 8 of 14
C.
I �a
E.
F.
�
pipelines, and other components of the CITY's facilities as may be required in
connection with the ENGINEER's services. The CITY will be responsible for all
acts of the CITY's personnel.
Advertisements, Permits, and Access
Unless otherwise agreed to in the Scope of Services, the CITY will obtain,
arrange, and pay for all advertisements for bids; permits and licenses required
by local, state, or federal authorities; and land, easements, rights-of-way, and
access necessary for the ENGINEER's services or PROJECT construction.
Timely Review
The CITY will examine the ENGINEER's studies, reports, sketches, drawings,
specifications, proposals, and other documents; obtain advice of an attorney,
insurance counselor, accountant, auditor, bond and financial advisors, and
other consultants as the CITY deems appropriate; and render in writing
decisions required by the CITY in a timely manner in accordance with the
project schedule in Attachment A.
Prompt Notice
The CITY will give prompt written notice to the ENGINEER whenever CITY
observes or becomes aware of any development that affects the scope or
timing of the ENGINEER's services or of any defect in the work of the
ENGINEER or construction contractors.
Asbestos or Hazardous Substances Release.
(1) CITY acknowledges ENGINEER will perForm part of the work at CITY's
facilities that may contain hazardous materials, including asbestos
containing materials, or conditions, and that ENGINEER had no prior role
in the generation, treatment, storage, or disposition of such materials. In
consideration of the associated risks that may give rise to claims by third
parties or employees of City, City hereby releases ENGINEER from any
damage or liability related to the presence of such materials.
(2) The release required above shall not apply in the event the discharge,
release or escape of hazardous substances, contaminants, or asbestos is
a result of ENGINEER's negligence or if ENGINEER brings such
hazardous substance, contaminant or asbestos onto the project.
Contractor Indemnification and Claims
The CITY agrees to include in all construction contracts the provisions of
Article IV.E. regarding the ENGINEER's Personnel at Construction Site, and
provisions providing contractor indemnification of the CITY and the
ENGINEER for contractor's negligence.
STANDARD ENGINEERING AGREEMENT (REV 10/06/05)
Page 9 of 14
� ,
r i a J=: i. .� �..�� �J ��::,
'';I�J;, '?�Sr''!�',7�?ti � �(!�
:�: 'u� , � ��; U�S:�-�!1` I�
5j ';'i';;"''r, t� r,� ,�
� �, ...��J1':�a��� �,�'��'.��i.
L...�_. �_._o. o �._ _�-,.
H. Contractor Claims and Third-Party Beneficiaries
(1) The CITY agrees to include the following clause in all contracts with
construction contractors and equipment or materials suppliers:
"Contractors, subcontractors and equipment and materials
suppliers on the PROJECT, or their sureties, shall maintain no
direct action against the ENGINEER, its officers, employees,
and subcontractors, for any claim arising out of, in connection
with, or resulting from the engineering services perFormed.
Only the CITY will be the beneficiary of any undertaking by
the ENGINEER."
(2) This AGREEMENT gives no rights or benefits to anyone other than the CITY
and the ENGINEER and there are no third-party beneficiaries.
(3) The CITY will include in each agreement it enters into with any other entity or
person regarding the PROJECT a provision that such entity or person shall
have no third-party beneficiary rights under this Agreement.
(4) Nothing contained in this section V.H. shall be construed as a waiver of any
right the CITY has to bring a claim against ENGINEER.
CITY's Insurance
(1) The CITY may maintain property insurance on certain pre-existing structures
associated with the PROJECT.
(2) The CITY will ensure that Builders Risk/Installation insurance is maintained at
the replacement cost value of the PROJECT. The CITY may provide
ENGINEER a copy of the policy or documentation of such on a certificate of
insurance.
(3) The CITY will specify that the Builders Risk/Installation insurance shall be
comprehensive in coverage appropriate to the PROJECT risks.
J. Litigation Assistance
The Scope of Services does not include costs of the ENGINEER for required
or requested assistance to support, prepare, document, bring, defend, or
assist in litigation undertaken or defended by the CITY. In the event CITY
requests such services of the ENGINEER, this AGREEMENT shall be
amended or a separate agreement will be negotiated between the parties.
K. Changes
The CITY may make or approve changes within the general Scope of Services
STANDARD ENGINEERING AGREEMENT (REV 10/06/05)
Page 10 of 14
in this AGREEMENT. If such changes affect the ENGINEER's cost of or time
required for perFormance of the services, an equitable adjustment will be made
through an amendment to this AGREEMENT with appropriate CITY approval.
Article VI
General Legal Provisions
Amendments to Article VI, if any, are included in Attachment C.
A. Authorization to Proceed
ENGINEER shall be authorized to proceed with this AGREEMENT upon
receipt of a written Notice to Proceed from the CITY.
B. Reuse of Project Documents
All designs, drawings, specifications, documents, and other work products of
the ENGINEER, whether in hard copy or in electronic form, are instruments of
service for this PROJECT, whether the PROJECT is completed or not.
Reuse, change, or alteration by the CITY or by others acting through or on
behalf of the CITY of any such instruments of service without the written
permission of the ENGINEER will be at the CITY's sole risk. The CITY shall
own the final designs, drawings, specifications and documents.
C. Force Majeure
The ENGINEER is not responsible for damages or delay in perFormance
caused by acts of God, strikes, lockouts, accidents, or other events beyond the
control of the ENGINEER.
D. Termination
(1) This AGREEMENT may be terminated only by the City for convenience on
30 days' written notice. This AGREEMENT may be terminated by either the
CITY or the ENGINEER for cause if either party fails substantially to perForm
through no fault of the other and does not commence correction of such
nonperformance with 5 days of written notice and diligently complete the
correction thereafter.
(2) If this AGREEMENT is terminated for the convenience of the City, the
ENGINEER will be paid for termination expenses as follows:
a.) Cost of reproduction of partial or complete studies, plans, specifications
or other forms of ENGINEER'S work product;
b.) Out-of-pocket expenses for purchasing storage containers, microfilm,
electronic data files, and other data storage supplies or services;
STANDARD ENGINEERING AGREEMENT (REV 10/06/05) ' �� � ��, �; ��� ��` � j �;, ;� � �.(',!��� � � ��,
Page 11 of 14 3
� ; �:.,a�—.:� �. ��: J�.0
<' � � ' i; G� � � 2,� r �i
��tl�L'� =�sL�i �;�-,.U,1S'
L�. ��� '.`J``���'r'ill�u� �!�),(,
c.) The time requirements for the ENGINEER'S personnel to document the
work underway at the time the CITY'S termination for convenience so
that the work effort is suitable for long time storage.
(3) Prior to proceeding with termination services, the ENGINEER will submit to the
CITY an itemized statement of all termination expenses. The CITY'S approval
will be obtained in writing prior to proceeding with termination services.
E. Suspension, Delay, or Interruption to Work
The CITY may suspend, delay, or interrupt the services of the ENGINEER for
the convenience of the CITY. In the event of such suspension, delay, or
interruption, an equitable adjustment in the PROJECT's schedule,
commitment and cost of the ENGINEER's personnel and subcontractors, and
ENGINEER's compensation will be made.
F. Indemnification
(1) The ENGINEER agrees to indemnify and defend the CITY from loss,
cost, or expense claimed by third parties for property damage and bodily
injury, including death, caused solely by the negligence or willful
misconduct of the ENGINEER, its employees, officers, and
subcontractors in connection with the PROJECT.
(2) If the negligence or willful misconduct of both the ENGINEER and the
CITY (or a person identified above for whom each is liable) is a cause of
such damage or injury, the loss, cost, or expense shall be shared
between the ENGINEER and the CITY in proportion to their relative
degrees of negligence or willful misconduct as determined pursuant to
T.C.P. & R. Code, section 33.011(4) (Vernon Supplement 1996).
G. Assignment
Neither party shall assign all or any part of this AGREEMENT without the prior
written consent of the other party.
H. Interpretation
Limitations on liability and indemnities in this AGREEMENT are business
understandings between the parties and shall apply to all the different theories
of recovery, including breach of contract or warranty, tort including negligence,
strict or statutory liability, or any other cause of action, except for willful
misconduct or gross negligence for limitations of liability and sole negligence
for indemnification. Parties mean the CITY and the ENGINEER, and their
officers, employees, agents, and subcontractors.
Jurisdiction
STANDARD ENGINEERING AGREEMENT (REV 10/06/05)
Page 12 of 14
The law of the State of Texas shall govern the validity of this AGREEMENT, its
interpretation and perFormance, and any other claims related to it. The venue
for any litigation related to this AGREEMENT shall be Tarrant County, Texas.
J. Alternate Dispute Resolution
(1) All claims, disputes, and other matters in question between the CITY and
ENGINEER arising out of, or in connection with this Agreement or the
PROJECT, or any breach of any obligation or duty of CITY or ENGINEER
hereunder, will be submitted to mediation. If inediation is unsuccessful, the
claim, dispute or other matter in question shall be submitted to arbitration if
both parties acting reasonably agree that the amount of the dispute is likely to
be less than $50,000, exclusive of attorney's fees, costs and expenses.
Arbitration shall be in accordance with the Construction Industry Arbitration
Rules of the American Arbitration Association or other applicable rules of the
Association then in effect. Any award rendered by the arbitrators less than
$50,000, exclusive of attorney's fees, costs and expenses, will be final,
judgment may be entered thereon in any court having jurisdiction, and will not
be subject to appeal or modification except to the extent permitted by Sections
10 and 11 of the Federal Arbitration Act (9 U.S.C. Sections 10 and 11).
(2) Any award greater than $50,000, exclusive of attorney's fees, costs and
expenses, may be litigated by either party on a de novo basis. The award shall
become final ninety (90) days from the date same is issued. If litigation is filed
by either party within said ninety (90) day period, the award shall become null
and void and shall not be used by either party for any purpose in the litigation.
K. Severability and Survival
If any of the provisions contained in this AGREEMENT are held for any reason
to be invalid, illegal, or unenforceable in any respect, such invalidity, illegality,
or unenforceability will not affect any other provision, and this AGREEMENT
shall be construed as if such invalid, illegal, or unenforceable provision had
never been contained herein. Articles V.F., VI.B., VI.D., VI.H., VI.I., and VI.J.
shall survive termination of this AGREEMENT for any cause.
L. Observe and Comply
ENGINEER shall at all times observe and comply with all federal and State
laws and regulations and with all City ordinances and regulations which in any
way affect this AGREEMENT and the work hereunder, and shall observe and
comply with all orders, laws ordinances and regulations which may exist or
may be enacted later by governing bodies having jurisdiction or authority for
such enactment. No plea of misunderstanding or ignorance thereof shall be
considered. ENGINEER agrees to defend, indemnify and hold harmless CITY
and all of its officers, agents and employees from and against all claims or
liability arising out of the violation of any such order, law, ordinance, or
STANDARD ENGINEERING AGREEMENT (REV 10/06/05)
Page 13 of 14
regulation, whether it be by itself or its employees.
Article VII
Attachments, Schedules, and Signatures
This AGREEMENT, including its attachments and schedules, constitutes the entire
AGREEMENT, supersedes all prior written or oral understandings, and may only be
changed by a written amendment executed by both parties. The following attachments and
schedules are hereby made a part of this AGREEMENT:
Attachment A- Scope of Services
Attachment B — Compensation
Executed this the day of
ATTEST:
�Mart Hendrix
City Secretary
iV0 ��cC It�:�U�1��D
, 2007.
;''� CITY OF FORT WORTH
� -:'_
�- `
'/ / ---
B :', ��' � / � ,��,. �
Y
Libby Wafson
Assistant City Manager
APPR ED AS TO FO�BI�j ND LEGALITY
-��;_'� � - . %� - �r��-� � = z�
Assista ��ty�ttorney
ATTEST:
STANDARD ENGINEERING AGREEMENT (REV 10/06/05)
Page 14 of 14
APPROVAL RECOMMENDED
' �, ��/��>�_ �-}�/��,. �� (':�
Mel dy Mit ell, Acting Director
Parks and Community Services Department
� %� �
,
EN INEER: MJ Thomas Engineering, LLC
gy: /�.7Clii4�L %!G%�i�.5� �,�z�',Oc�•�"
� _-_ -_ _ - . __ , _
` i I' f
i� 1�1�,;�.;!.', .�5�i�'�,,'1,'•�
N`�';lii `j :�,;2r:i�i��,4%;u�q9
«7 J 9 ti C; ��ci l�. �S ::; I}
�;= J���] vi�1\l,� �ull� �'�u�:1 .�.�
�l
MJ Thomas Engineering, LLC.
ENGINEERS-PLANNERS
MJT No. 506-002
June 6, 2007 Revised E-Mail: joel.mcelhany@forfinrorthgov.org
City of Fort Worth
Parks and Community Services Department
4200 South Freeway, Suite 2200
Fort Worth, Texas 76115-1499
Attention: Mr. Joel L. McElhany, Senior Landscape Architect
Reference: Proposal for Professional On-Site Civil Engineering,
Geotechnical and Surveying Services For
Greenbrier Park Paving Improvements
City of Forth Worth
Dear Mr. McElhany:
MJ Thomas Engineering, LLC. (MJT) is pleased to present this letter contract for On-Site
Professional Civil Engineering, Geotechnical Engineering and Surveying Services for the site
additions on the above referenced project. Listed below is a breakdown of the services to be
provided:
A. PRIVATE ON-SITE CIVIL DRAWINGS
MJT will perform the necessary research and design to prepare the following requested
On-site Civil Drawings for the paving improvements to serve the existing Greenbrier Park in
South Fort Worth:
Desiqn Documents
MJT will design and prepare Construction Drawings and Specifications for the On-site
Improvements to serve the paving improvements to the Greenbrier Park for the City of
Fort Worth. The design improvements will include removal/ possible recycling of the
existing pavement and design of new paving improvements for the drives and parking
as delineated on the attached Exhibit `A'. These Construction Drawings will include
agreed improvements and shall conform to the City of Fort Worth Transportation and
Public Works and Parks Departments requirements.
After we receive an approved site plan, MJT will design and prepare bid documents
consisting of Construction Drawings and Contract Documents for the paving
improvements. The improvements include on-site paving, grading, driveways, and
ADA accessible parking. MJT has also included verification /design of sidewalks
adjacent to the existing building and parking so that they will conform to the new
grades and ADA requirements.
ATTACHMENT A r' ° ;i� �`�'�` � �"��' �
4150 International Plaza, Suite 600
Fort Worth, Texas 76109
Tel: 817.423.1142 • Fax: 817.423.1147
Proposal for Professional On-Site Civil Engineering,
Geotechnical and Surveying Services For
Greenbrier Park Paving Improvements
City of Forth Worth
May 15, 2007
Page 2
MJT will also prepare and provide paving details for the proposed parking areas. MJT
will prepare joint layouts for all drives and parking areas as required. We do not
anticipate the requirement for retaining walls at this site and MJT has not included
retaining wall design in our fee proposal. Design of improvements not specifically
identified in this proposal will be considered as additional services or completed under
separate contract.
2. Specifications
MJT will provide to the City of Fort Worth, standard specifications and contract
documents related to the site work for use in bidding the project.
3. Coordination
MJT will coordinate with the governing agencies on the interFace of the site work. Civil
services will include assistance in obtaining approvals from the City of Fort Worth
TPW for the site grading and paving. Also included is coordination and assistance in
meetings with the City of Fort Worth regarding site work services.
B. STORM WATER POLLUTION PREVENTION PLAN (SWPPP)
A SWPPP has not been included in this fee proposal. Typically, most owners have us include
this in the scope for the contractor. However, if at the request of the City of Fort Worth, MJT will
prepare a Storm Water Pollution Prevention Plan (SWPPP) in accordance with the City of Fort
Worth requirements. This plan will be sealed by a professional engineer licensed in the State of
Texas. This SWPPP would be a template to be used by the Owner's contractor in meeting the
minimum TPDES and City of Fort Worth requirements for this site. Completion, adherence to
and maintenance of the SWPPP will be the responsibility of the Owner's contractor. If elected to
proceed by the City of Fort Worth, the fee for the SWPPP will be $1,500 above and beyond the
fee proposal below.
C. GEOTECHNICAL INVESTIGATION
MJT has incfuded through a sub-consultant, a fee to provide geotechnical investigation of
the site improvement areas. The geotechnical engineer will provide pavement design
recommendations to MJT for final pavement design. The existing 1,600-foot two-lane road
will be upgraded to either a Portland Cement concrete road or re-constructed with Hot Mix
Asphaltic Concrete. This investigation is planned to meet the requirements of the City of
Fort Worth 2005 Pavement Standards Manual.
We have included a copy of this proposal as Exhibit "B" to this contract. If the scope is
acceptable to your requirements, please initial the exhibit and return with the executed
contract. This exhibit and language included is considered part of this contract.
Proposal for Professional On-Site Civil Engineering,
Geotechnical and Surveying Services For
Greenbrier Park Paving Improvements
City of Forth Worth
May 15, 2007
Page 3
�
E.
SURVEYING SERVICES
MJT will perForm the necessary fieldwork to prepare a topographic map of the site as
delineated on Exhibit "A" for use in the final design of all site improvements described
herein. MJT will provide a detailed topographic survey including existing surFace features
and trees from 2" diameter and larger within the limits as delineated. We will provide
approximate locations of existing underground utilities based off of public records including
size and depth where possible. All survey data will be indexed to the City of Fort Worth
vertical datum. A permanent benchmark and horizontal control monuments will be
established, marked, and noted on site and electronic files for future reference and
construction layout.
CONSTRUCTION PHASE
Contract Administration
a. MJT will assist in answering questions, preparation of addenda and attending
pre-bid conference during the bid process.
�
c.
Make visits to the site at appropriate construction phases to observe the
progress of work and attend site meetings. For budgetary purposes, we have
assumed two site visits and two meetings. Additional site visits and meetings
may require additional compensation and will be negotiated with the Owner at
that time. �
Assist in processing the shop drawings, reviewing pay applications and
answering questions during construction relating to the site work.
Due to the unknowns involved in the preparation of this proposal, we have made the following
assumptions. If these assumptions change, we may have to revise the represented fee. These
assumptions are:
2.
3.
�
There will be no requirements for water, sanitary sewer, detention, below grade
drainage, off-site drainage easement acquisition or grade-to drain permission.
Construction staking will be considered as additional services.
Any changes in the scope of work may require MJT to re-negotiate our compensation fee.
If required, topographic and boundary information beyond the scope noted above shall be
negotiated on an individual basis.
5. MJT and our sub-consultants assume no responsibility or liability for the accuracy or
the timeliness of third party marked utility locations.
6. Construction materials testing should be directly handled by the City of Fort Worth
and is not a part of this contract.
a .�� , . �
�vY; ,�! �:`�!� �..�.�'l��':J�'�:J
i;':��,I ',;;�i`';%;�`''; u�,
'��,� ��`:.�.,:�UL,�CJ
� ��..��� -.:,'.<�r�ou ?r; (
� :'� � � C�� iI I. � i
�- � i
� �� ;`,�;�.���y ���G�lo �
Proposal for Professional On-Site Civil Engineering,
Geotechnical and Surveying Services For
Greenbrier Park Paving Improvements
City of Forth Worth
May 15, 2007
Page 4
F. WORK NOT INCLUDED
■ Platting and Easement Services
■ FEMA Floodplain Amendments or Studies
■ Final (Post Construction) Topographic Maps
■ Retaining Wall Design unless it is a design-build
■ Design of Franchise Utilities (gas, electric, telephone)
■ Any off-site or on-site improvements not specifically defined in this proposal
■ Construction staking will be considered as additional services.
■ Inspections.
■ Landscape Irrigation Design
■ Water, Sanitary, Storm Sewer or Detention Design
■ Any off-site or on-site improvements not specifically defined in this proposal.
■ Completion of SWPPP template will be the responsibility of the Owner's Contractor.
■ Required inspections and maintenance of SWPPP will be the responsibility of the Contractor.
■ Boundary ALTA Surveys.
■ Any cha�ges in the scope of work may require MJT to re-negotiate our compensation fee.
■ If required, off-site topo and boundary information beyond the scope noted above shall be
negotiated on an individual basis.
■ Upon award of the contract, any additional services not listed in this contract that are
desired of MJT by the Client for Construction Administration will be done on an hourly
basis or negotiated for a lump sum fee.
1. Civil Engineering Services .._.__
2. Geotechnical Investigation_..,,._
3. Surveying Services___________________
----------------------------------
----------------------------------
$14,350.00 (lump sum)
. $5,150.00 (lump sum)
..$4,500.00 (lump sum)
MJT proposes to perForm all work outlined for the total lump sum fee of $24,000.00 Reimbursable
expenses will be billed as outlined on the accompanying "Basis of Compensation", and billed as an
additional item. Reimbursable expenses will be billed as outlined on the accompanying "Basis of
Compensation", and billed as an additional item. Reimbursable expenses consist of printing,
reproduction, filing fees required by/to the City, delivery charges, and CAD plotting cost. Monthly
statements for all work will be submitted to you by the 25th of each month, and are due by the 15th of
the following month. Monthly bills will be based upon the Engineer's estimate of percent completion
of the various work tasks.
ATTACHMENT B
,<, �
i r r .� �;- ;. . � ': �'', ; i;? e1:�
, .�_
-�,,`�.., �
q `y `;;IS ;";i �'57�1 'ila,
,�;��t C�'::.`1u�w�`I(IY
; '� ? �`;� ��:°'!' Ji�, ���i�i. �
1•� - •- __...�a
Proposal for Professional On-Site Civil Engineering,
Geotechnical and Surveying Services For
Greenbrier Park Paving Improvements
City of Forth Worth
May 15, 2007
Page 5
Additional services other than those outlined herein will also be accomplished on a Labor X 2.7
multiplier or lump sum, whichever is deemed to be the most appropriate. Items identified as
additional services will be authorized in writing by the Owner and confirmed by MJT via a
memorandum and a job initiation form. As a matter of convenience we will also identify the job
number which will bear the expense of additional services so all accounting can be appropriately
identified. We consider design changes required by others than MJT after plans are significantly
complete to be additional services. Alterations and modifications required as a normal course of
review are considered part of this agreement.
We appreciate your consideration of MJ Thomas Engineering, LLC. If this proposal meets with your
approval, please indicate by signing in the space provided, and return one copy for our files: Please
feel free to call if you have any questions concerning any of the scope of services or associated fees
presented herein and we will do our best to clarify any part of the proposal that may be unclear. We
appreciate the opportunity to assist you with this project and look forward to its success.
Respectfully submitted, Approved & Accepted:
MJ Thomas Engineering, LLC. City of Fort Worth
522 g�`�t�.a.'�r.�,J',� � 0
�, e,�.o2 � � �-��'�
ay:
c ael T oma , P. .
President Name:
Title:
Date:
MAT/mat
506-002_01 _PropLtr_J McE I h any_07-0515_MAT. doc
,
/�- �, ,
.
Exhibit "A"
Greenbriar Park Limits
: ,'� -_ .,F� . . ._...... .. t � �` � g.
�.'�' � � `p�'Si '� . . � F, � � '� ,� �a
� � ; _.. . � ��, � � ,,� � � �, � . .
�. t � ,
�d 4v, ��=_� � '� E i i �.
L�i ,�' �'' Y{ ( 3 k 1
�� t '' .r'� E'� . � , ( f _ . . . . , ��
yE I
� �� � � Y . .. � -- �.' - . F� �E� � ,. - �2
d . . ��,? j ` j . - � `,
g� ' � a. ._ �'•' . __ �r� �� �') �� �E �
; � � � f�. �� � _ .._, � `.
�'� i . _ .,.., . . .. . � � ' .r.. �:Y £� , � . �
? y
� r . �.1 - '� . � .. _ �
� � i . � �` . . . '� ; �
� �� � ' G �' . � � . � �' . �
.� :� �
� � �>#r
K . � t4 I
a "�
£ '' � �- �� � ��,� E
� _ _ a < . , {� #"�` ri ' � '�.' ' .. � � � � � — ra
�g, � �Y � � { ��. i
q@�'�$ -�AS ��,�� 1 r.: , e .
a {,, '
i.N.'�` i.Y- �f � �e.�l' �I. � � � tF
� �.y�, # �. !t i� � +.
� ..� � � 2 ��� d �.# i QF � � F � . , ' . � t:
t �i � , S� � �' i �y� . i
.i�� h � � '� �' � � , � .�� i � . . �
�. 4 ' 'i� `� �� �. d'y� "' . � S€
s .: �:�; � �' �, �, 3 .�. 1
. � : . � t � � . � r �
� �� � � � ��$ �� `'
�' q•j� �` � � �� ��� p i��a �" ( d �a � i 4:e
3 �y
�:� ,� �v �� i �* �� �fi '� � . ..� � .��� '� .� ��' 7 � �3� '��.z9, , . �� � i
i � � a r. �
� � � - F � .' L � � � �� ��� � � � � � � �
� .# `�. �'.�a_�. ����� . �a�.ir+�t:�a+t. � •_C�v'� ��e lt�,t.� . .� g��4. � �+. ������-� . _.. . ._.._ 3� .t�. g
__. _ _ � �.,.. b. <_ .... ..... �.. � � ... ,_ . ,��#
Preliminary Schedule
Greenbriar Park Parking Lot Improvements
1. Notice to Proceed June 11, 2007
2. Survey Start June 14-July 14, 2007
3. Design/Preparation of Construction
Document/Cost Estimate Mid July-Early November
4. City Review November 2007
5. Bid Advertisement Early Januar•y 2008
6. Bid Opening Early February 2008
7. Construction Award Early May 2008
8. Construction Start (40 Working Days) Early July 2008
9. Construction Completion Early October 2008