HomeMy WebLinkAboutContract 51977 CITY SECRETARY
CONTRACT No. 519 7-7
CITY OF FORT WORTH, TEXAS
AGREEMENT FOR ARCHITECTURAL SERVICES
Fire Station 26
This AGREEMENT is between the City of Fort Worth, a Texas home-rule municipality (the
"CITY"), and Komatsu-Rangel, Inc., d/b/a Komatsu Architects, authorized to do
business in Texas, an independent contractor ("Architect"), for a PROJECT generally
described as: Architectural and Engineering services for the design of Fire Station
26.
The Agreement documents shall include the following:
1. This Standard Agreement for Professional Services;
2. Attachment "A"—Scope of Services;
3. Attachment"B"—Verification of Signature Authority Form.
Attachments "A" and "B", which are attached hereto and incorporated herein, are made a
part of this Agreement for all purposes. In the event of any conflict between the terms and
conditions of Attachments "A" or "B" and the terms and conditions set forth in the body of
this Agreement, the terms and conditions of this Agreement shall control.
Article I
Scope of Service
(1) Architect hereby agrees to perform as an independent contractor the services set
forth in the Scope of Services attached hereto as Attachment "A". These
services shall be performed in connection with Fire Station 26. Nothing in
Attachment "A" or any other Attachments to this Agreement shall be construed to
change or modify any of the terms and conditions set forth in this Agreement.
(2) If at any time in the course of the design, the City expands the scope of services, or
the Architect believes the City has requested services that are beyond the scope of
this Agreement, the Architect shall submit a proposal for additional fees and a
written agreement shall be reached on said proposal prior to the Architect
proceeding with the work considered to be beyond the scope of this Agreement.
The Architect shall not perform any additional services without a written agreement
with the City. Any services provided prior to reaching an agreement on additional
fees will be non-compensable.
(3) Additional services, if any, will be requested in writing by the City. City shall not
pay for any work performed by Architect or its sub-consultants, subcontractors
and/or suppliers that has not been ordered in writing. It is specifically agreed that
R...i"ard Architectural Agreement
FEB 2 8 2019 OFFICIAL RECORD
—T„ CITY SECRETARY
4
FT.WORTH,TX
Architect shall not be compensated for any alleged additional work resulting from
oral orders of any person.
(4) The Architect shall advise the City as to the necessity of the City's providing or
obtaining additional services and data from others required in connection with the
Project at the City's cost and expense (which services and data the Architect is not
to provide hereunder but on which the Architect may rely in performing services
hereunder), and act as the City's representative in connection with any such
services of others.
(5) The Construction Budget for this project shall be $4,264,273.00.
Article II
Compensation
(1) The Architect shall be compensated (Fee and Reimbursable Expenses) in
accordance with the Fee Schedule shown in section (3) of this article. As
described in Attachment "A". However the total fee paid by the City shall not
exceed a total of $419,138.00 unless the City and the Architect mutually agree
upon a fee amount for additional services and amend this Agreement
accordingly.
(2) Acceptance by Architect of said payment shall operate as and shall release the
city from all claims or liabilities under this Agreement for payment for the services
rendered and billed for which such payment is made, it being understood that
pending claims for additional compensation properly made by the Architect
pursuant to Article I shall not be encompassed by such release.
(3) The Architect shall be paid the following percentages of the total fee at the
following stages of the Project:
a. Completion of Programming and Schematic Design and Opinion of
Probable Construction Cost 20%
b. Completion of Design Development and Opinion of Probable
Construction Cost 40%
c. Completion of Construction Documents and Opinion of
Probable Construction Cost 75%
d. Action by City Council to accept bids 80%
e. Final acceptance of the Project by the City 100%
Standard Architectural Agreement 7/2/2018
2
However the total fee paid by the City shall not exceed a total as defined in Article
II, Compensation.
(4) Reimbursement of allowable expenses shall have prior approval of the City.
Allowable expenses include:
a. Printing Costs
b. Renderings or Models for Public and City meetings
c. Postage and Courier Expenses
d. Travel, Mileage Only
e. Other Costs with Prior Approval of the City.
(5) The Architect shall provide monthly invoices to the City. Payment for services
rendered shall be due within thirty (30) days of the uncontested performance of
the particular services so ordered and receipt by City of Architect's invoice for
payment of same.
(6) Acceptance by Architect of said payment shall operate as and shall release the
City from all claims or liabilities under this Agreement for anything related to,
done, or furnished in connection with the services for which payment is made,
including any act or omission of the City in connection with such services.
Article III
Term
Unless terminated pursuant to the terms herein, this Agreement shall be for a term of 30-
months, beginning upon the date of its execution, or until the completion of the subject
matter contemplated herein, whichever occurs first. In the event construction services
extends beyond the 18 months, an equitable adjustment to the Architectural Services
Contract Sum will be made by Amendment.
Article IV
Independent Contractor
Architect shall operate hereunder as an independent contractor, and not as an officer,
agent, servant, or employee of the City. Architect shall have exclusive control of and the
exclusive right to control the details of its work to be performed hereunder and all persons
performing same, and shall be solely responsible for the acts and omissions of its officers,
agents, employees, contractors and subcontractors. The doctrine of respondeat superior
Standard Architectural Agreement 7/2/2018
3
shall not apply as between City and Architect, its officers, agents, employees, consultant,
and sub-consultants, and nothing herein shall be construed as creating a partnership or
joint venture between City and Architect.
Article V
Professional Competence and Indemnification
(1) Work performed by Architect shall comply in all aspects with all applicable local,
state and federal laws and with all applicable rules and regulations promulgated
by the local, state and national boards, bureaus and agencies. Approval by the
City shall not constitute or be deemed to be a release of the responsibility and
liability of Architect or its officers, agents, employees, consultants and sub-
consultants for the accuracy and competency of its services performed
hereunder.
(2) In accordance with Texas Local Government Code Section 271.904, the
Architect shall indemnify, hold harmless, and defend the City against liability for
any damage caused by or resulting from an act of negligence, intentional tort,
intellectual property infringement, or failure to pay a consultant or sub-consultant
committed by the Architect or Architect's agent, Architect under contract, or
another entity over which the Architect's exercises control.
Article VI
Procedures for Providing Architectural Services
(1) The Architect agrees to commit the personnel to each assignment of the Project
as appropriate in order to complete the Project in an expeditious manner. The
Architect shall meet with the City's staff as required during the duration of the
project. The Architect will assign the following key personnel to this Project:
Principal in Charge: Carl Komatsu
Project Manager: Les Edmonds
Project Architect: Ryan Brantley
The Architect may not change key personnel without the City's written approval.
(2) Programming and Schematic Design Phase:
Standard Architectural Agreement 7/2/2018
4
a. The Architect shall become familiar with the site and scope of the Project.
b. The Architect shall consult with the City to clarify and define the City's
requirements relative to the Project and review available'data.
c. The Architect shall become familiar with the City's document "Facilities
Division DESIGN GUIDELINES for New and Existing Facilities" and
incorporate into all phases of the work.
d. The Architect shall prepare a written Program Design Manual defining project
goals, program, architectural concepts, site and floor plans, principal
equipment, finishes and area-based cost estimates.
e. The Architect shall pay for the printing of contract documents required for design
submittals and presentations as a part of the reimbursable allowance.
f. Architect shall not proceed to the Design Phase until the City has provided
written approved of the Program Design Manual.
(3) Design Phase:
a. The Architect shall perform all services necessary to complete the design and
secure a construction,permit, including all services necessary to survey, plat,
prepare and vacate easements and address any other property issues.
b. The design shall include all site work, design and coordination of utilities,
landscaping and facility design required for a complete and functional project.
c. The Architect shall prepare presentation graphics (plans, elevations, etc.) and
present at two (2) City meetings (if required) during the design of the project.
d. The Architect shall prepare the design in two stages as follows:
i. Design Development Phase: Preparation of architectural, civil, iSWM,
structural, MEP plans, principal elevations, site plans, cartoon set,
selection of principal equipment and finishes, and discipline-based
opinion of probable construction costs. Upon written approval of this
phase of the work, the Architect may proceed to the Construction
Document Phase.
ii. Construction Document Phase: Preparation of details, architectural,
structural, mechanical, electrical, and plumbing plans, finishes
schedules, detailed technical specifications, and detailed opinion of
probable construction costs.
e. Drawings at all stages of design will have the following characteristics: scale for
floor plans will be 1/8" or such other scale as may be agreed to in writing for all
disciplines, elevations will be at same scale as floor plans, area plans will have
same scale for all disciplines, site plans for all disciplines will be at same scale.
f. The Architect shall provide such service as may be necessary for the building
Standard Architectural Agreement 7/2/2018
5
permits to be issued. The City shall pay any fees for such Building Permits.
The City or contractor shall apply for building permits.
g. The Architect, at the Architect's sole cost and expense, shall engage a
Consultant to prepare "Elimination of Architectural Barriers Registration" and
submit the applications to the Texas Department of Licensing and Regulation
(TDLR). The Architect (if required) will pay all fees required for TDLR reviews
and inspections. All designs shall be in conformance with the Elimination of
Architectural Barriers Act, State of Texas, and the City of Fort Worth Building
Codes.
h. In the event the Project is constructed in accordance with the Architect's
designs and is subsequently determined to be in non-conformance with the
above Act, Codes or Texas Accessibility Standards, the City will bear the
construction costs associated with enhancements. The Architect will reimburse
the City for additional costs, charges or fees to replace or rework features that
were constructed in accordance with the design but fail to meet applicable
accessibility requirements or building codes in force at the time that the design
was performed.
i. The Architect shall upload the electronic files in PDF format to the City's online
bidding site (Autodesk Buzzsaw).
(4) Bidding Phase:
a. The Architect shall respond to Contractors' inquiries, prepare necessary
addenda, and conduct the Pre-Proposal Conference, and participate in the
General Contractor selection process.
b. Following bidding, the Architect shall investigate the qualifications of up to five
(5) bidders and make recommendations concerning the capability of the bidder
to satisfactorily perform the Contract.
(5) Responsibility for Construction Cost
a. The Construction Budget for the Project shall be defined by the City.
b. The Architect shall provide to the City an opinion of probable construction cost
at the submission of each phase. The City shall either approve the adjustment
of the Construction Budget or direct the Architect to adjust the Project design, at
no additional cost to the City, to stay within the previously approved
Construction Budget.
c. If the Construction Budget is exceeded by the lowest bona fide bid, the City may
(1) award the contract, (2) abandon the project and terminate this agreement, or
(3) cooperate in the reduction of the Project Scope and features as required to
stay within the Construction Budget in order to rebid the Project. If the City
Standard Architectural Agreement 7/2/2018
6
decides to reduce the scope of the project and rebid, the Architect shall, without
additional fee, modify the Drawings and Specifications as necessary to stay
within the Construction Budget. In the event the City abandons the project, the
City may terminate this Agreement in accordance with Article X, Termination of
Contract.
(6) Construction Phase:
a. The Architect shall assist the City with review and approval of submittals and
proposed change orders concerning the Contractor, and shall review and
advise the City with respect to the resolution of construction issues, including
Contractor Request for Information, Submittals, Change Orders, Contingency
Allowance Forms, Field Orders, etc. The Architect shall visit the site at interval
appropriate to the stage of construction to become generally familiar with the
progress and quality of the portion of the Work completed, and to determine, in
general, if the Work observed is being performed in a manner indicating that the
Work, when fully completed, will be in accordance with the Contract Documents.
However, the Architect shall not be required to make exhaustive of continuous
on-site inspection to check the quality or quantity of the Work. On the basis of
the site visits, the Architect will keep the city reasonably informed about the
progress and quality of the portion of the Work Completed and make written
report to the City (T) known deficiencies from the Contract Documents and from
the most recent construction schedule submitted by the Contractor, and (2)
defects and deficiencies observed in the Work.
b. The Architect shall attend progress meeting at the job site.
c. At the completion of construction, the Architect shall conduct and document the
final inspection and assist the City on the resolution of construction or design
deficiencies.
d. The Architect will review contractor's pay requests.
e. The Architect will conduct final acceptance and end of warranty inspections with
representatives of the City and issue AIA G704 Certificate of Substantial
Completion with City approval.
f. The Architect shall provide electronic copies of the drawings and specifications
in a format acceptable to the Contractor for the Contractor's preparation of
"Record Drawings"for the City's archives.
g. At the end of the project, the Architect use field notes, contractor provided
"Record Drawings" and other data will provide "As Built Drawings" in AutoCAD
LT 2010 format or other format as determined by the City.
Standard Architectural Agreement 7/2/2018
7
(7) All designs, drawings, specifications, documents, and other work products of the
Architect, whether in hard copy or in electronic form, are instruments of service for
this Project, whether the Project is completed or not. Reuse, change, or alteration
by the City or by others acting through or on behalf of the City of any such
instruments of service without the written permission of the Architect will be at the
City's sole risk. The City shall own the final designs, drawings, specifications and
documents. Transfer of ownership of the contract documents does not constitute
sale of the documents.
Article VII
City Responsibilities
(1) Ronnie Clements will act as the City's representative with respect to the Project
for the purposes of transmitting instructions, receiving information, interpreting
and defining City's policies and decisions with respect to the Architect's services.
(2) Provide criteria and information as to City's requirements.
(3) Assist the Architect in obtaining existing studies, reports and other available data
and services of others pertinent to the Project and in obtaining additional reports
and data as required.
(4) Upon reasonable notice arrange for access to and make all provisions for the
Architect to enter upon public and private property as may be required for the
Architect to perform services hereunder.
(5) Review all reports, recommendations and other documents and provide written
decisions pertaining thereto within a reasonable time.
(6) Examine all studies, reports, sketches, drawings, specifications, proposals and
other documents presented by Architect, obtain advice of an attorney, insurance
counselor and other architects as it deems appropriate for such examination and
render in writing decisions pertaining thereto within a reasonable time so as not
to delay the services of Architect.
(7) Provide "Instructions to Offerors" and "General Conditions" for use in assembling
the Project construction contract documents.
(8) Prepare easements and right-of-way acquisition conveyance documents, from
descriptions provided by the Architect, contact owners, negotiate for or condemn
all easements and right-of-way, pay all filing and legal fees associated therewith.
(9) Manage the advertisement and bidding of the project, issue addenda, distribute
bid documents, award contract, and execute the contracts.
(10) Administer the construction of the Project.
(11) Provide inspection and management services.
Standard Architectural Agreement 7/2/2018
8
(12) Provide contractors' prepared field drawings to the Architect for review.
(13) Pay all impact and utility fees and other fees not expressly assigned to the
Architect. This includes fees charged by Oncor for new or revised service.
(14) Bear all costs incident to compliance with this Article.
Article VIII
Insurance
(1) Architect shall not commence work under this Agreement until it has obtained all
insurance required under this Article and the City has approved such insurance,
nor shall Architect allow any subconsultants to commence work on its
subcontract until all similar insurance of the subconsultants has been so obtained
and approval given by the City; provided, however, Architect may elect to add
any subconsultant as an additional insured under its liability policies.
Commercial General Liability
$1,000,000 each occurrence
$2,000,000 general aggregate limit
Automobile Liability
$1,000,000 each accident (or reasonably equivalent limits
of coverage if written on a split limits basis). Coverage
shall be on any vehicle used in the course of the Project.
Worker's Compensation
Coverage A: statutory limits
Coverage B: $100,000 each accident
$500,000 disease-policy limit
$100,000 disease- each employee
Professional Liability Insurance
$1,000,000 Errors & Omissions
$2,000,000 Annual Aggregate
(2) Additional Insurance Requirements
a. Except for employer's liability insurance coverage under Architect's worker's
compensation insurance policy, the City, its officers, employees and servants
shall be endorsed as an additional insured on Architect's insurance policies.
Standard Architectural Agreement 7/2/2018
9
b. Certificates of insurance shall be delivered to the Property Management
Department, Attention: Brian R. Glass, AIA, Architectural Services
Manager, 401 West 13th Street, Fort Worth, Texas 76102, prior to
commencement of work.
c. Any failure on part of the City to request required insurance documentation
shall not constitute a waiver of the insurance requirements specified herein.
d. Each insurance policy shall be endorsed to provide the City a minimum thirty
days notice of cancellation, non-renewal, and/or material change in policy terms
or coverage. A ten days notice shall be acceptable in the event of non-payment
of premium.
e. Insurers must be authorized to do business in the State of Texas and have a
current A.M. Best rating of A: VII or equivalent measure of financial strength and
solvency.
f. Other than worker's compensation insurance, in lieu of traditional insurance,
City may consider alternative coverage or risk treatment measures through
insurance pools or risk retention groups. The City must approve in writing any
alternative coverage.
g. Workers' compensation insurance policy(s) covering employees employed on
the Project shall be endorsed with a waiver of subrogation providing rights of
recovery in favor of the City.
h. City shall not be responsible for the direct payment of insurance premium
costs for Architect's insurance.
i. Architect's insurance policies shall each be endorsed to provide that such
insurance is primary protection and any self-funded or commercial coverage
maintained by City shall not be called upon to contribute to loss recovery.
j. In the course of the Agreement, Architect shall report, in a timely manner, to
City's officially designated contract administrator any known loss occurrence
which could give rise to a liability claim or lawsuit or which could result in a
property loss.
k. Architect's liability shall not be limited to the specified amounts of insurance
required herein.
I. Upon the request of City, Architect shall provide complete copies of all
insurance policies required by these Agreement documents.
Standard Architectural Agreement 7/2/2018
10
Article IX
Transfer or Assignment
City and Architect each bind themselves, and their lawful successors and assigns, to this
Agreement. Architect, its lawful successors and assigns, shall not assign, sublet or
transfer any interest in this Agreement without prior written consent of the City.
Article X
Termination of Contract
(1) City may terminate this Agreement for its convenience on 30 days written notice.
Either the City or the Architect for cause may terminate this Agreement if either
Party fails substantially to perform through no fault of the other and does not
commence correction of such nonperformance with 5 days of written notice and
diligently complete the correction thereafter
(2) If City chooses to terminate this Agreement under Article IX, upon receipt of
notice of termination, Architect shall discontinue services rendered up to the date
of such termination and City shall compensate Architect based upon calculations
in Article II of this Agreement.
(3) All reports, whether partial or complete, prepared under this Agreement,
including any original drawings or documents, whether furnished by the City, its
officers, agents, employees, Architects, or contractors, or prepared by Architect,
shall be or become the property of the City, and shall be furnished to the City
prior to or at the time such services are completed, or upon termination or
expiration of this Agreement.
Article XI
Right to Audit
(1) Architect agrees that the City shall, until the expiration of three (3) years after final
payment under this Agreement, have access to and the right to examine any
directly pertinent books, documents, papers and records of Architect involving
transactions relating to this Agreement. Architect agrees that the City shall have
access during normal working hours to all necessary facilities and shall be provided
adequate and appropriate workspace in order to conduct audits in compliance with
the provisions of this section. City shall give Architect reasonable advance notice of
intended audits.
(2) Architect further agrees to include in all its subcontracts hereunder, a provision to
the effect that the subcontracting consultant agrees that the City shall, until the
Standard Architectural Agreement 7/2/2018
11
expiration of three (3) years after final payment under the subcontract, have
access to and the right to examine any directly pertinent books, documents,
papers and records of such sub-consultant, involving transactions to the
subcontract, and further, that City shall have access during normal working hours
to all sub-consultant facilities, and shall be provided adequate and appropriate
work space in order to conduct audits in compliance with the provisions of this
article. City shall give Architect and any sub-consultant reasonable advance
notice of intended audit.
(3) Architect and sub-consultants agree to photocopy such documents as may be
requested by the City. The City agrees to reimburse Architect for the cost of copies
at the rate published in the Texas Administrative Code in effect as of the time
copying is performed.
Article XII
Minority Business and Small Business Enterprise (MBE) (SBE) Participation
In accordance with the City's Business Diversity Enterprise Ordinance No. 20020-12-2011,
as amended, the City has goals for the participation of minority business enterprises
and/or small business enterprises in City contracts. Architect acknowledges the MBE and
SBE goals established for this Agreement and its accepted written commitment to MBE
and SBE participation. Any misrepresentation of facts (other than a negligent
misrepresentation) and/or the commission of fraud by the Architect may result in the
termination of this Agreement and debarment from participating in City contracts for a
period of time of not less than three (3) years.
Article XIII
Observe and Comply
Architect shall at all times observe and comply with all federal, state, and local laws and
regulations and with all City ordinances and regulations which in any way affect this
Agreement and the work hereunder, and shall observe and comply with all orders, laws
ordinances and regulations which may exist or may be enacted later by governing bodies
having jurisdiction or authority for such enactment. No plea of misunderstanding or
ignorance thereof shall be considered. Architect agrees to defend, indemnify and hold
harmless City and all of its officers, agents and employees from and against all claims or
liability arising out of the violation of any such order, law, ordinance, or regulation, whether
it be by itself or its employees.
Article XIV
Venue and Jurisdiction
Standard Architectural Agreement 7/2/2018
12
If any action, whether real or asserted, at law or in equity, arises on the basis of any
provision of this Agreement, venue for such action shall lie in state courts located in
Tarrant County, Texas or the United States District Court for the Northern District of
Texas — Fort Worth Division. This Agreement shall be construed in accordance with the
laws of the State of Texas.
Article XV
Contract Construction
The Parties acknowledge that each party and, if it so chooses, its counsel have
reviewed and revised this Agreement and that the normal rule of construction to the
effect that any ambiguities are to be resolved against the drafting party must not be
employed in the interpretation of this Agreement or any amendments or exhibits hereto.
Article XVI
Severability
The provisions of this Agreement are severable, and if any word, phrase, clause,
sentence, paragraph, section or other part of this Agreement or the application thereof
to any person or circumstance shall ever be held by any court of competent jurisdiction
to be invalid or unconstitutional for any reason, the remainder of this Agreement and the
application of such word, phrase, clause, sentence, paragraph, section, or other part of
this Agreement to other persons or circumstances shall not be affected thereby and this
Agreement shall be construed as if such invalid or unconstitutional portion had never
been contained therein.
Article XVII
Immigration Nationality Act
City actively supports the Immigration & Nationality Act (INA) which includes provisions
addressing employment eligibility, employment verification, and nondiscrimination. Vendor
shall verify the identity and employment eligibility of all employees who perform work under
this Agreement. Vendor shall complete the Employment Eligibility Verification Form (1-9),
maintain photocopies of all supporting employment eligibility and identity documentation
for all employees, and upon request, provide City with copies of all 1-9 forms and
supporting eligibility documentation for each employee who performs work under this
Agreement. Vendor shall establish appropriate procedures and controls so that no
services will be performed by any employee who is not legally eligible to perform such
services. Vendor shall provide City with a certification letter that it has complied with the
verification requirements required by this Agreement. Vendor shall indemnify City from any
penalties or liabilities due to violations of this provision. City shall have the right to
Standard Architectural Agreement 7/2/2018
13
immediately terminate this Agreement for violations of this provision by Vendor.
Article XVIII
House Bill 89
Contractor acknowledges that in accordance with Chapter 2270 of the Texas Government
Code, the City is prohibited from entering into a contract with a company for goods or
services unless the contract contains a written verification from the company that it: (1)
does not boycott Israel; and (2) will not boycott Israel during the term of the contract. The
terms "boycott Israel' and "company" shall have the meanings ascribed to those terms in
Section 808.001 of the Texas Government Code. By signing this contract, Contractor
certifies that Contractor's signature provides written verification to the City that Contractor:
(1) does not boycott Israel; and (2) will not boycott Israel during the term of the contract.
Article XIX
Notices
Notices to be provided hereunder shall be sufficient if forwarded to the other Party by
hand-delivery or via U.S. Postal Service certified mail return receipt requested, postage
prepaid, to the address of the other Party shown below:
City of Fort Worth:
Property Management Department
Attn: Brian R. Glass, AIA
Architectural Services Manager
401 West 13th Street
Fort Worth, Texas 76103
Architect:
Komatsu-Rangal, Inc., d/b/a Komatsu Architects
Attn: Les Edmonds, AIA
3880 Hulen Street, Suite 300
Fort Worth, Texas, 76107
Article XX
Headings
The headings contained herein are for the convenience in reference and are not
intended to define or limit the scope of any provision of this Agreement.
Standard Architectural Agreement 717.12018
14
Article XXI
Counterparts: This Agreement may be executed in one or more counterparts and each
counterpart shall, for all purposes, be deemed an original, but all such counterparts
shall together constitute but one and the same instrument.
Executed and effective this the �� of Fday ehr X2019.
BY: BY:
CITY OF FORT WORTH ARCHITECT
Komatsu-Rangal, Inc., d/b/a Komatsu
Architects
Jesus J. Chapa
Assistant City Manager
earl A Korrat
Date: d��try �I� President
Date:
AQCO MENDED:
og r na e , Interim Director
ropert Ma a ment Department
APPROVED AS TO FORM AND M&C No.: C-29026
LEGALITY
By: M&C Date: February 5, 2019
ohn B. tro
Assistant C ttorney. FORTS+
ATT ti
Mary J. K e
City Secretary
�XAS
CONTRACT COMPLIANCE MANAGER: ' y signing 1 acknowledge that I am the person responsible for the
monitoring and administrationof this contract,including ensuring all performance and reporting requirements.
By: &yi&4% R, G&O
Brian R.Glass,AIA
Architectural Services Manager
Standard Architectural Agreement OFFIC11iffltbRID
is CITY SECRETARY
FT.WORTH,TX
i
KOM ,
AT S U
RH
October 31, 2018
Ronald Clements
Registered Architect
Property Management Department
401 West 13"i Street
Fort Worth, Texas 76102
RE: Architectural and Engineering Fee Proposal for Fire Station No. 26
Dear Mr. Clements:
Komatsu Architecture is pleased to provide an Architectural and Engineering fee
proposal for the Replacement of Fire Station No. 26 in Fort Worth, Texas. The scope of
this fee is generally based on the two story concept floor plan and site plan attached and
discussions with the City and Fire staff. This project will be designed as an energy
conscious building; however LEED®certification is not included in this fee. This fee is
based on a competitive sealed proposal contract. The service of an independent cost
estimator is included in this fee. We propose to provide the following:
• Basic A/E Services for a lump sum fee of$373,062.00.
• Additional Services of$41,576.00.
• The total fee amount is $414,638.00 (excluding reimbursables listed below for
construction set printing).
Fire Station No. 26 Basic Service Fee:
Programming $ 9,065.00
Schematic $ 40,626.00
Design Development $ 80,675.00
Construction Documents $ 154,731.00
Construction Administration $ 89,964.00
Basic Service Total $ 373,062.00
Additional Services Fee: (not included in Basic Service)
Topographic Survey $ 11,801.00
Geotech Report $ 5,280.00
TAS registration, review and inspection $ 2,475.00
iSW M $ 5,500.00
Replat $ 5,357.00
Peer Reviews for the Safe Room $ 7,590.00
Additional Service Total $ 41,576.00
Total Fire Station No. 26 Fee $414,638.00
3880 HULEN STREET SUITE 300 • FORT WORTH,TX 76107-7274 • 817 332 1914 VOICE - 817 877 4754 FAX
Reimbursables (if required): (not included in above fees)
20 full size (22x34) plans and specs $ 4,500.00
This proposal includes the following:
• Review submittals will be provided at Schematic (30%), Design Development
(60%)and Construction Drawing (90%) levels. All electronic documents will be
posted to Komatsu's transfer site for use by the City.
• Cost estimates will be provided at Schematic, Design Development and
Construction Documents.
• Three half size (11x17) sets of drawings and one spec will be provided to the City
at each of the three submittal stages. Printing cost is included.
• Three full size (22x34)final sets of drawings and bound specs will be provided to
the City. Printing cost is included.
• One full size set of drawings and specs will be provided for Accessibility review.
Printing cost and postage is included. TDLR Accessibility registration, RAS
review and inspection fees are also included.
• Full size bidding documents for construction are not included in this fee proposal.
See reimbursable amount above.
• 24 on-site construction review meetings attended by the project architect are
included in this fee proposal.
This Proposal excludes the following:
• Any building permit or other fees required by the City.
• Material testing and inspections during construction.
• The services of a test and balance firm.
The following consultants are on the A/E Team:
• Civil Engineer: Carrillo Engineering, LLC
• Structural Engineer: R.L. Woods&Associates, LLC
• MEP Engineer:TLC Engineering for Architecture
• Landscape: Leeming Design Group
• Cost Estimation: Riddle& Goodnight, Inc.
• Surveyor and Replat: Gorrondona &Associates, Inc
• Geotech: CMJ
If you have any questions regarding this proposal please let me know. If this proposal
meets with your approval, Komatsu is prepared to start to work to meet your schedule
and expectations.We appreciate this opportunity to be working with the City of Fort
Worth on this Fire Department project. We look forward to hearing from you.
Sincerely,nc/
Les Edmonds, AIA
Komatsu Architecture
Attachments: Concept Plans
ro
N
tei
~ d
U o
Q°' o
OU
Mr
CL
Y t
a
S
CL
80
x
TT W-
a I � u
�a y
o
�e
[L�1 as
SE
�9of
s 6
�a
F
°
ba
r4 O
m
EO
a EO LL
� a
g
� 08
a ae
w
i �
_ �
�.._J
� .
.- _ �
I F
J� F
' •
� � 1
M
� ��i ,3
,�
r - �. �
^.
E � � (�+��
++ ,
i � � �_ � � `I� �J
� �►
_ � �'
: t „
��t:) I��I I:i t �;
��`Ir r ��� � K
�,. � ti
�N�t � ------
,rJ !i� ;rl
}_ � f
5 �+
I
. i J � ��F -
- • 1
�� �"'�
. ; � --
. __�_
�� � _ . _ .
- . �
-� ' •�
-t
� i
: y �- �
ATTACHMENT "B"
VERIFICATION OF SIGNATURE AUTHORITY
Komatsu Architecture
3880 Hulen Street guit_e '100
Fort Worth; Texas 76107
Consultant hereby agrees to provide City with independent audit basic financial statements, but
also the fair presentation of the financial statements of individual funds.
Execution of this Signature Verification Form ("Form") hereby certifies that the following
individuals and/or positions have the authority to legally bind Consultant and to execute any
agreement, amendment or change order on behalf of Consultant. Such binding authority has
been granted by proper order, resolution, ordinance or other authorization of Consultant. City is
fully entitled to rely on the warranty and representation set forth in this Form in entering into any
agreement or amendment with Consultant. Consultant will submit an updated Form within ten
(10) business days if there are any changes to the signatory authority. City is entitled to rely on
any current executed Form until it receives a revised Form that has been properly executed by
Consultant.
1. Name: Les Edmonds
Position: project Mana er
Signature
2. Name: Karl Komatsu
Position: president
Sign r
3. Name:
Position:
Signature
Name:
_���/X( -
Signat e of President TCEp
Other Title:
Date: February 15, 2019
Standard Architectural Agreement 7/2/2018
2
City of Fort Worth, Texas
Mayor and Council Communication
COUNCIL ACTION: Approved on 2/5/2019
DATE: Tuesday, February 5, 2019 REFERENCE NO.: **C-29026
LOG NAME: 21 FIRE STATION 26 DESIGN
SUBJECT:
Authorize Execution of an Architectural Design Contract in the Amount of$419,138.00, Including $4,500.00
of Reimbursable Expenses, with Komatsu-Rangal, Inc., d/b/a Komatsu Architects for Design and
Construction Administration Services for Fire Station No. 26 Located at 6124 South Hulen Street,
Estimated Total Cost for the Project, Including, Design, Construction, and Other Costs is $5,341,000.00
(2018 Bond Program) (COUNCIL DISTRICT 6)
RECOMMENDATION:
It is recommended that the City Council authorize execution of an architectural design contract in the
amount of$419,138.00, including $4,500.00 of reimbursable expenses, with Komatsu-Rangal, Inc., d/b/a
Komatsu Architects for design and construction administration services for Fire Station No. 26 located at
6124 South Hulen Street.
DISCUSSION:
The purpose of this M&C is to authorize execution of an architectural design contract in the amount of
$419,138.00, including $4,500.00 of reimbursable expenses, with Komatsu-Rangal, Inc., d/b/a Komatsu
Architects for design and construction administration services for Fire Station No. 26 located at 6124
South Hulen Street.
Proposition D, Fire Safety Improvements, of the 2018 Bond Program authorized the demolition of existing
Fire Station No. 26 and the design and construction of a new fire station on the same site, in the amount
of$5,341,000.00.
A request for Statements of Qualifications (SOQ) was advertised in the Fort Worth Star-Telegram on
August 2, 2018. The SOQs were due August 30, 2018. The City received 6 SOQs from qualified
architectural firms, however one firm withdrew its SOQ because of their recently increased work load. The
selection team included representatives of the City of Fort Worth Fire Department, M/WBE Office and
Property Management Department. The firms submitting SOQs were:
Brown Reynolds Waterford Architects, Inc.
GFF Architects
Komatsu-Rangel, Inc. dba Komatsu Architecture
RPGA Design Group, Inc.
Randal Scott Architects
VLK Architects, Inc.
After reviewing the SOQs, the selection team met and selected 3 of the 6 firms for interviews based on
their rankings in a qualifying matrix. The following is a summary of the results of the interview process:
Loanarne: 21FI STATION 25 DESIQN ' �'
Page o�
Criteria Komatsu-Rangel, Inc. dba RPGA DesignRandall Scott
Komatsu Architecture Group, Inc. Architects
Project 30 27 26
Management F
Technical Approach j� 40 38 �; 38
Qualifications & ( 10 ! 10 10
Experience
IExperience with City -� 8_ —_ i 10 5
SBE Score 5.5 � 6.0 5.0 �
�- TOTAL —� 93.5 91 j - - 84
Based on the review of SOQs and interviews, the selection team recommends that City Council authorize
execution of an Architectural Services Agreement with Komatsu-Rangel, Inc., d/b/a Komatsu Architecture
for design of the new Fire Station 26.
Estimated Costs: The estimated project costs for Fire Station 26 are as follows:
FIRE STATION 26 - PROJECT COSTS Cost
Design Fees $419,138.00
F
onstruction Fees (Inc. 7.5% Owner's $4,264,273.00
ontingency Allowance)
Project Management, Bid Advertisement,
Materials Inspection, Site Utilities, $653,089.00
Contingency, etc. i
rPROJECT TOTAL _ $5,341,000.00
This project is included in the 2018 Bond Program. Available resources within the General Fund will be
used to provide interim financing until debt is issued. Once debt associated with this project is sold, bond
proceeds will reimburse the General Fund in accordance with the statement expressing official Intent to
Reimburse that was adopted as part of the ordinance canvassing the bond election (M&C G-19306) and
subsequent events taken by the Mayor and Council.
Schedule - Construction is planned to begin during the fourth quarter of the calendar year of 2019 with an
anticipated completion date during the second quarter of the calendar year of 2021.
M/WBE Office - Komatsu/Rangel Inc., d/b/a Komatsu Architecture, Inc., is in compliance with the City's
BDE Ordinance by committing to 22.00% SBE participation on this project. The City's SBE goal on this
project is 15%. Additionally, Komatsu/Rangel Inc., d/b/a Komatsu Architecture, Inc., is a certified M/WBE
firm.
In accordance with Chapter 7, Article III, Section 7-47, Section 109.2.1 of the City Code, Building, Trade
Permit, Street Closure Fees and Urban Forestry Fees are waived for this project.
Fire Station 26 is located in COUNCIL DISTRICT 6.
I,eg�iame: 2ItHRE 'Olt ATI Ord 251E3ICN Page 2 of 3
FISCAL INFORMATION / CERTIFICATION:
The Director of Finance certifies that funds are available as appropriated of the 2018 Bond Fund. Prior to
an expenditure being incurred, the participating department has the responsibility to validate the
availability of funds.
FUND IDENTIFIERS (FIDs):
TO
Fund Department Accoun Project Program ctivity Budget Reference # moun
ID ID YearF (Chartfielid 2
FROM
Fund Department Accoun Project Program ctivity Budget Reference # moun
ID ID Year Chartfield 2
CERTIFICATIONS:
Submitted for City Manager's Office by: Jay Chapa (5804)
Originating Department Head: Roger Venables (6334)
Additional Information Contact: Brian Glass (8088)
ATTACHMENTS
1. 181210 Komatsu-SBE Compliance Memo.pdf (CFW Internal)
2. 21 FIRE STATION 26 DESIGN FID.pdf (CFW Internal)
3. Firestation 26.pdf (Public)
4. Form 1295 Certificate FS 26 - Komatsu Redacted.pdf (Public)
5. SAM Komatsu Rangel.pdf (CFW Internal)
Logname: 21FIRE NATION 26 i ESIGN Noe of