Loading...
HomeMy WebLinkAboutContract 35552CITY SiFORETARY CITY OF FORT WORTH, TEXAS COt� i ';°,CT NO. STANDARD AGREEMENT FOR ENGINEERING SERVICES This AGREEMENT is between the Gity of Fort Worth (the "CITY and Stream Water Group, Inc., (the "ENGINEER"), for a PROJECT generally described as: Storm Water Utility Project — 9100 Trinity Blvd. (Walker Branch) Culvert improvements Article I Scope of Services A. The Scope of Services is set forth in Attachment A. Article II Compensation A. The ENGINEER's compensation is set forth in Attachment B. Article III Terms of Payment Payments to the ENGINEER will be made as follows: A. Invoice and Payment (1) The Engineer shall provide the City sufficient documentation to reasonably substantiate the invoices. (�) The ENGINEER will issue monthly invoices for all work performed under this AGREEMENT. Invoices are due and payable within 30 days of receipt. (3) Upon completion of services enumerated in Article I, the final payment of any balance will be due wn 30 days of receipt of the final invoice. (4) In the event of a disputed or contested billing_, only that portion so contested will be withheld from payment, and the undisputed portion will be_ paid. The CITY will exercise reasonableness in contesting any bill or portion thereof. No interest will accrue on any contested portion of the billing until mutually resolved. (5) If the CITY fails to make payment in full to ENGINEER for billings contested in good faith within 60 days of the amount due, the ENGINEER may, after giving 7 days' written notice to CITY, suspend services under this AGREEMENT until paid in full, including interest. In the event of suspension of services, the ENGINEER shall have no liability to CITY for delays or damages caused the CITY because of such suspension of services. STANDARD ENGINEERING AGREEMENT (REV 10/06/05) Page 1 of 20 ORIGINAL Article IV Obligations of the Engineer Amendments to Article IV, if any, are included in. Attachment C. A. General The ENGINEER will serve as the CITY's professional engineering representative under this Agreement, providing professional engineering consultation and advice and furnishing customary services incidental thereto. B. Standard of Care The standard of care applicable to the ENGINEER's services wi{I be the degree of skill and diligence normally employed in the State of Texas by professional engineers or consultants performing the same or similar services at the time --such services are performed. C. Subsurface Investigations (1) The ENGINEER shall advise the CITY with regard to the necessity for subcontract work such as special surveys, tests, test borings, or other subsurface investigations in connection with design and engineering work to be performed hereunder. The ENGINEER shall also advise the CITY concerning the results of same. Such surveys, tests, and investigations shall be furnished by the CITY, unless otherwise specified in Attachment A. (2) In soils, foundation, groundwater, and other subsurface investigations, the -actual characteristics may vary significantly between successive test points and sample intervals and at locations other than where observations, exploration, and investigations have been made. Because of the inherent uncertainties in subsurface evaluations, changed or unanticipated underground conditions may occur that could affect the total 0 PROJECT cost and/or execution. These conditions and cost/execution effects are not the responsibility of the ENGINEER. D. Preparation of Engineering Drawings The ENGINEER will provide to the CITY the original drawings of all plans in ink on reproducible plastic film sheets, or as otherwise approved by CITY, which shall become the property of the CITY. CITY may use such drawings in any manner it desires; provided, however, that the ENGINEER shall not be liable for the use of such drawings for any project other than the PROJECT described herein. STANDARD ENGINEERING AGREEMENT (REV 10/06/05) Page 2 of 20 E. Engineer's Personnel at Construction_Site (1) The presence or duties of the ENGINEER's personnel at a construction site, whether as on -site representatives or otherwise, do not make the ENGINEER or its personnel in any way responsible for those duties that belong to the CITY and/or the CITY's construction contractors or other entities, and do not relieve -the construction contractors or any other entity of their obligations, duties, and responsibilities, including, but not limited to, all construction methods, means, techniques, sequences, and procedures necessary for coordinating and completing all portions of the construction work in accordance with the Contract Documents and any health or safety precautions required by such construction work. The ENGINEER and its personnel have no authority to exercise any control over any construction contractor or other entity or their employees in connection with their work or any health or safety precautions. (2) Except- to the extent of specific site visits expressly detailed and set forth in Attachment A, the ENGINEER or its personnel shall have no obligation or responsibility to visit the construction site to become familiar with the progress or quality of the completed work on the PROJECT or to determine, in general, if the work on the PROJECT is being performed in a manner indicating that the PROJECT, when completed, will be in accordance with the Contract Documents, nor shall anything in the Contract Documents or the agreement between CITY and ENGINEER be construed as requiring ENGINEER to make exhaustive or continuous on -site inspections to discover latent defects in the work or otherwise check the quality or quantity of the work on the PROJECT. If, for any reason, the ENGINEER should make an on -site observation(s), on the basis of such on -site observations, if any, the ENGINEER shall endeavor to keep the CITY informed of any deviation from the Contract Documents coming to the actual notice of ENGINEER regarding the PROJECT. (3) When professional certification of performance or characteristics of materials, systems or equipment is reasonably required to perform the services set forth in the Scope of Services, the ENGINEER shall be entitled to rely upon such certification to establish materials, systems or equipment and performance criteria to be required in the Contract Documents. F. Opinions of Probable Cost, Financial Considerations, and Schedules (1) The ENGINEER shall provide opinions of probable costs based on the current available information at the time of preparation, in accordance with Attachment A. (2) In providing opinions of cost, financial analyses, economic feasibility projections, and schedules for the PROJECT, the ENGINEER has no control over cost or price of labor and materials; unknown or latent conditions of existing equipment or structures that may affect operation or maintenance costs; competitive bidding procedures and market STANDARD ENGINEERING AGREEMENT (REV 10/06/O5) Page 3 of 20 conditions; time or quality of performance by third parties; quality, type, management, or direction of operating personnel; and other economic and operational factors that may materially affect -the ultimate PROJECT cost or schedule. Therefore, the ENGINEER makes no warranty -that the CITY's actual PROJECT costs, -financial aspects, economic feasibility, or schedules will not vary- from the ENGINEER's opinions, analyses, projections, or estimates. G. Construction Progress Payments Recommendations by the ENGINEER to the CITY for periodic construction progress payments to the construction contractor will be based on the ENGINEER's knowledge, information, and belief from selective sampling and observation that the work has progressed to the point indicated. Such recommendations do not represent that continuous or detailed examinations have been made by the ENGINEER to ascertain that the construction contractor has completed the work in exact accordance with the Contract Documents; that the final work will be acceptable in all respects; that the ENGINEER has made an examination to ascertain how or for what purpose the construction contractor has used the moneys paid; that title to any of the work, materials, or equipment has passed to the CITY free and clear of liens, claims, security interests, or encumbrances; or that there are not other matters at issue between the CITY and the construction contractor that affect the amount that should be paid. H. Record Drawings Record drawings, if required, will- be prepared, in part, on the basis of information compiled and furnished by others, and may not always represent the exact location, type of various components, or exact manner in which the PROJECT was finally constructed. The ENGINEER is not responsible for any errors or omissions in the information from others that is incorporated into the record drawings. I. Minority and Woman Business Enterprise (M/WBE) Participation In accord with City of Fort Worth Ordinance No. 15530, the City has -goals for the participation of minority business enterprises and woman business enterprises in City contracts. Engineer acknowledges- the M/WBE goal established for this contract and its commitment to meet that goal. Any misrepresentation of facts (other than a negligent misrepresentation) and/or the commission of fraud by the Engineer may result in the termination of this agreement and debarment from participating in City contracts for a period of time of not less than three (3) years. STANDARD ENGINEERING AGREEMENT (REV 10/06/05) Page 4 of 20 J. Right to Audit (1) ENGINEER agrees that the CITY shall, until the expiration of three (3) years after final payment under this contract, h-ave access to and the right to examine and photocopy any directly pertinent books, documents, papers and records of the ENGINEER involving transactions relating- to this contract. ENGINEER agrees that the CITY shall have access- during normal- working hours to all necessary ENGINEER facilities and- shall be provided adequate and appropriate work -space in order to conduct audits in compliance with the provisions of this section. The CITY shall give ENGINEER reasonable advance notice of intended audits. (2) ENGINEER further agrees to include in all its subconsultant agreements hereunder a provision to the effect that the subconsultant agrees that the CITY shall, until the expiration of three (3) years after final payment under the subcontract, have access to and the right to examine and photocopy any directly pertinent books, documents, papers and- records of such subconsultant, involving transactions to the subcontract, and further, that the CITY shall have access during normal working hours to all subconsultant facilities, and shall be provided adequate and appropriate work space, in order to conduct audits in compliance with the provisions of this article together with subsection (3)hereof. CITY shall give subcon-sultant reasonable advance notice of intended audits. (3) ENGINEER and subconsultant agree to photocopy such documents as may be requested by the CITY. The CITY agrees to reimburse ENGINEER for the cost of copies at the rate published in the Texas Administrative Code in effect as of the time copying is performed. K. ENGINEER's Insurance (1) Insurance coverage and limits: ENGINEER shall .provide to the City certificates) of insurance documenting policies of the following coverage at minimum limits that are to be in effect prior to commencement of work on the PROJECT: Commercial General- Liability $1,000,000 each occurrence $2,000,000 aggregate Automobile Liability $1,000,000 each accident on a combined single limit or $250,000 Property Damage $500,000 Bodily Injury per person per occurrence STANDARD ENGINEERING AGREEMENT (REV 10/06/05) Page 5 of 20 A commercial business policy shall provide coverage on "Any Auto", defined as autos owned, hired and non -owned when said vehicle is used in the course of the PROJECT. Worker's Compensation Coverage A:_ Statutory limits Coverage B: Employer's Liability $100,000 each accident '500,000 disease - policy limit $100,000 disease - each employee Professina!-Liability $1,000,000 each claim $2,000,000 aggregate Professional liability shall be written on a claims -made basis and shall contain a retroactive date prior to the date of the contract or the first date of services to be performed, whichever is earlier. Coverage shall be maintained for a period of 5 years following the completion of the contract. An annual certificate of insurance specifically referencing this project shall be submitted to the City for each year following completion of the contract. (2) Certificates of insurance evidencing that the ENGINEER has obtained all required insurance shall be delivered to the CITY prior to ENGINEER proceeding with the PROJECT. STANDARD Page 6 of 20 (a) Applicable policies shall be endorsed to name the CITY an Additional Insured thereon, as its interests may appear. The term CITY shall include its employees, officers, officials, agents, and volunteers as respects the contracted services. (b) Certificate(s) of insurance shall document that insurance coverage specified in this agreement are provided under applicable policies documented thereon. (c) Any failure on part of the CITY to request required insurance documentation shall not constitute a waiver of the insurance requirements. (d) A minimum of forty-five (45) days notice of cancellation or material change in coverage shall be provided to the CITY. A ten (10) days notice shall be acceptable in the event of non-payment of premium. Such terms shall be endorsed onto ENGINEER's insurance policies. Notice shall be sent to the respective Department Director (by name), City of Fort Worth, 1000 Throckmorton, Fort Worth, Texas 76102. AGREEMENT (REV 10/O6/OS) (e) Insurers for all policies must be authorized to do business in the State of Texas and have a minimum rating of A: VII in the current A.M. Best Key Rating Guide or have reasonably equivalent financial strength and solvency to the satisfaction of Risk Management. (f) Deductible limits, or self insured retentions, affecting insurance required herein shall be acceptable -to the_CITY in its sole discretion; a-nd, in lieu of traditional insurance, any alternative coverage maintained through insurance pools or risk retention groups must be also approved. Dedicated financial resources or letters of credit may also be acceptable to the City. (g) Applicable policies shall each be endorsed with a waiver of subrogation in favor of the CITY as respects the PROJECT. (h) The City shall be entitled, upon -its request and without incurring expense, to review the ENGINEER's insurance policies including endorsements thereto and, at the CITY's discretion, the ENGINEER may be required to provide proof of insurance premium payments. (j) For all lines of coverage underwritten on a claims -made basis, other than Professional Liability, the retroactive date shall be coincident with or prior to the date of the contractual agreement.- The certificate of insurance shall state both the retroactive date and- that the coverage is claims - made. (k) The CITY shall not be responsible for the direct payment of any insurance premiums required by this agreement and all insurance required in this section, with the exception of Professional Liability, shall be written on an occurrence basis. (i) Sub consultants and subcontractors to/of the ENGINEER shall be required by the ENGINEER to maintain the same or reasonably equivalent insurance coverage as required for the ENGINEER. When sub consultants/subcontractors maintain insurance coverage, ENGINEER shall provide CITY with documentation thereof on a certificate of insurance. L. Independent Consultant The ENGINEER agrees to perform all services as an independent consultant and not as a subcontractor, agent, or employee of the CITY. STANDARD ENGINEERING AGREEMENT (REV 10/O6/05) Page 7 of 20 !VI. Disclosure The ENGINEER acknowledges to the CITY that it has made full disclosure in writing of any existing conflicts of interest or potential conflicts of interest, including personal financial interest, direct or indirect, in property abutting the proposed PROJECT and business relationships with abutting property cities. The ENGINEER further acknowledges that it will- make disclosure in writing of any conflicts of interest that develop subsequent to the signing of this contract and prior to -final payment under the contract. N. Asbestos or Hazardous Substances (1) If asbestos or hazardous substances in any form are encountered or suspected, the ENGINEER will stop its own work in the affected -portions of the PROJECT to permit testing and evaluation. (2) If asbestos or other hazardous substances are suspected, the ENGINEER will, if requested, assist the CITY in obtaining the services of a qualified subcontractor to manage the remediation activities of the PROJECT. O. Permitting Authorities -Design Changes If permitting authorities require design changes so as to comply with published design criteria and/or current engineering practice standards which the ENGINEER should have been aware of at the time this Agreement was executed, the ENGINEER shall revise plans and specifications, as required, at its own cost and expense. However, if design changes are required due to the changes in the permitting authorities' p_ublished design criteria and/or practice standards- criteria which are published after the date of this Agreement which the ENGINEER could not have been reasonably aware of, the ENGINEER shall notify the CITY of suchchangesand an adjustment in compensation will be made through an amendment to this AGREEMENT. Article V Obligations of the City Amendments to Article V, if any, are included in Attachment C. A. City -Furnished Data ENGINEER may rely upon the accuracy, timeliness, and completeness of the information provided by the CITY. STANDARD ENGINEERING AGREEMENT (REV 10/O6/OS) Page 8 of 20 B. Access to Facilities -and Property The CITY will make its facilities accessible to the ENGINEER as required for the ENGINEER's performance -of its services and will provide -labor and safety equipment as required by the ENGINEER for such access. The CITY will perform, at no cost to the ENGINEER, such tests of equipment, machinery, pipelines, and -other components of the CITY's facilities as may be required in connection with the ENGINEER's services. The CITY will be responsible for all acts of the CITY's personnel. C. Advertisements, Permits, aru! Access Unless otherwise agreed to in the Scope of Services, the CITY will obtain, arrange, and pay -for all advertisements for bids; permits and licenses required by local, state, or federal authorities; and land, easements, rights-ofwway, -and access necessary for the ENGINEER's services or PROJECT construction. D. Timely Review The CITY will examine the ENGINEER's studies, reports, sketches, drawings, specifications, proposals, and other documents; obtain advice of an attorney, insurance counselor, accountant, auditor, bond and financial advisors, and other consultants as the CITY deems appropriate; and render in writing decisions required by the CITY in a timely manner in accordance with the project schedule in Attachment A. E. Prompt Notice The CITY will give _prompt written notice to the ENGINEER whenever CITY observes or becomes aware of any development that affects the scope or timing of the ENGINEER's services or of any defect in the work of the ENGINEER or construction contractors. F. Asbestos or Hazardous Substances Release. (1) CiTY acknowledges ENGINEER will perform part of the work at CITY's faces that may contain hazardous materials, including asbestos containing materials, or conditions, and that ENGINEER had no prior role in the generation, treatment, storage, or disposition of such materials. In consideration of the associated risks that may give rise to claims by third parties or employees of City, City hereby releases ENGINEER from any damage or liability related to the presence of such materials. (2) The release required above shall not apply in the event the discharge, reIease or escape of hazardous substances, contaminants, or asbestos is a result of ENGINEER's negligence or if ENGINEER brings such hazardous substance, contaminant or asbestos onto the project. STANDARD ENGINEERING AGREEMENT (REV 1min 6Inc) Page 9 of 20 G. Contractor Indemnification and Claims The CITY agrees to include in all construction contracts the provisions of Article IV.E. regarding the ENGINEER'-s Personnel at Construction Site, and provisions providing contractor indemnification of the CITY and the ENGINEER_for contractor's negligence. H. Contractor Cl42111er-011d Third -Party Beneficiaries (1) The CITY agrees to -1"%u a the following clause in aIF contracts with construction contractors and equipmentormateriels suppliers: "Contractors, subcontractors and equipment and materials suppliers on the PROJECT, or their sureties, shall maintain no direct action against the ENGINEER, its officers, employees, and subcontractors, for any claim arising out of, in connection with, or resulting from the engineering services performed. Only the CITY will be the beneficiary of any undertaking by the ENGINEER." (2) This AGREEMENT gives no rights or benefits to anyone other than the CITY and the ENGINEER and there are no third -party beneficiaries. (3) The CITY will include in each agreement it enters into with any other entity or person regarding the PROJECT a provision that such entity or person shall have no third -party beneficiary rights under this Agreement. (4) Nothing contained in this section V.H. shall be construed as a waiver of any right the CITY has to bring a claim against ENGINEER. I. CITY's Insurance (1) The CITY may maintain property insurance on certain pre-existing structures associated with the PROJECT. (2) The CITY will ensure that Builders Risk/knstallation insurance is maintained at the replacement cost value of the PROJECT. The CITY may provide ENGINEER a copy of the policy or documentation of such on a certificate of insurance. (3) The CITY will specify that the Builders Risk/Installation insurance shall be comprehensive in coverage appropriate to the PROJECT risks. J. Litigation Assistance The Scope of Services does not include costs of the ENGINEER for required or requested assistance to support, prepare, document, bring, defend, or assist in litigation undertaken or defended by the CITY. In the event CITY STANDARD ENGINEERING AGREEMENT (REV 10l06/05) Page 10 of 20 requests such services of the ENGINEER, this AGREEMENT shall be amended or a separate agreement will be negotiated between the parties. K. Changes The CITY may make or approve changes within -the general Scope of Services in this AGREEMENT. If such changes affect the ENGINEER's cost of or time required for performance of the services, an equitable adjustment will be made through an amendment to this AGREEMENT with appropriate CITY approval. Article Vt General Legal Provisions Amendments to Article VI, if any, are included in Attachment C. A. Authorization to Proceed ENGINEER shall be authorized to proceed with this AGREEMENT upon receipt of a written Notice to Proceed from the CITY. B. Reuse of Project Documents C. fa (1) All designs, drawings, specifications, documents, and other work products of the ENGINEER, whether in hard copy or in electronic form, are instruments of service for this PROJECT, whether the PROJECT is completed or not. Reuse, change, or alteration by the CITY or by others acting through or on behalf of the CITY of any such instruments of service without the written permission of the ENGINEER will beatthe CITY's-sole risk. The CITY shall own the final designs, drawings, specifications and documents. Force Majeure The ENGINEER is not responsible for damages or delay in performance caused by acts of God, strikes, lockouts, accidents, or ether events beyond the control of the ENGINEER. Termination This AGREEMENT may be 30 days' written notice. This CITY or the ENGINEER through no fault of the nonperformance with 5 correction thereafter. STANDARD ENGINEERING AGREEMENT (REV 10/06/05) Page 11 of 20 terminated only by the City for convenience on AGREEMENT may be terminated by either the for cause if either party fails substantially to perform other and does not commence correction of such days of written notice and diligently complete the (2) If this AGREEMENT is terminated for the convenience of the City, the ENGINEER will be paid for termination expenses as follows: a.) Cost of reproduction of partial or complete studies, plans, specifications or other forms of ENGINEER'S work product; b.) Out-of-pocket expenses for purchasing storage containers, microfilm, electronic data files, and other data storage supplies or services; c.) The time requirements for the ENGINEER'S personnel to document_the work underway at the time the CITY'S termination for convenience so that the work effort is suitable for long time storage_ (3) Prior to proceeding with termination services, the ENGINEER will submit to the CITY an itemized statement of all termination expenses. The CITY'S approval will be obtained in writing prior to proceeding with termination services. E. Suspension, Delay, or Interruption to Work The CITY may suspend, delay, or interrupt the services of the ENGINEER for the convenience of the CITY. In the event of such suspension, delay, or interruption, an equitable adjustment in the PROJECT's schedule, commitment and cost of the ENGINEER' personnel and subcontractors, and ENGINEER's compensation will be made. F. Indemnification (1} The ENGINEER agrees to indemnify and defend the CITY from any loss, cost, or expense claimed by third parties for property damage and bodily injury, including death, caused solely by the negligence or willful misconduct of the ENGINEER, its employees, officers, and subcontractors in connection with the PROJECT. (2) If the negligence -or willful misconduct of both the ENGINEER and the CITY (or a person identified above for whom each is liable) is a cause of such damage or injury, the loss, cost, or expense shall be shared between the ENGINEER and the CITY in proportion to their relative degrees of negligence or willful misconduct as determined pursuant to T.C.P. & R. Code, section 33.011(4) (Vernon Supplement 1996). G. Assignment Neither party shall assign all or any part of this AGREEMENT without the prior written consent of the other party. STANDARD ENGINEERING AGREEMENT (REV 10/O6/OS) Page 12 of 20 H. Interpretation Limitations on liability and indemnities in this AGREEMENT are business understandings between the parties and shall apply to all the different theories of recovery, including breach -of contract or warranty, tort including negligence, strict or statutory liability, or any other cause of action, except for willful misconduct or gross negligence for limitations of liability and sole negligence for indemnification. Parties mean the CITY and the ENGINEER, and their officers, employees, agents,_ and subcontractors. I. Jurisdicfwn The law of the S#ate of Texas shall govern the validity of this AGREEMENT, its interpretation and performance, and any other -claims related to it. The venue for any litigation related to this AGREEMENT shall be Tarrant County, Texas. J. Alternate Dispute Resolution (1) All claims, disputes, and other matters in question between the CITY and ENGINEER arising out of, or in connection with this Agreement or the PROJECT, or any breach of any obligation or duty of CITY or ENGINEER hereunder, will be submitted to mediation. If mediation is unsuccessful, the claim, dispute or other matter in question shall be submitted to arbitration if both parties acting reasonably agree that the amount of the dispute is likely to be less than $50,000, exclusive of attorney's fees, costs and expenses. Arbitration shall be in accordance with the Construction Industry Arbitration Rules of the American Arbitration Association or other applicable rules of the Association then in effect. Any award rendered by the arbitrators less than $50,000, exclusive of attorney's fees, costs and expenses, will be final, judgment may be entered thereon in any court having jurisdiction, and will not be subject to appeal or modification except to the extent permitted by Sections 10 and 11 of the Federal Arbitration Act (9 U.S.C. Sections 10 and 11). (2) Any award greater -than $50,000, exclusive- of attorneys fees, costs and expenses, may be litigated by either party on a de novo basis. The award shall become final ninety (90) days from the date same is issued. If litigation is filed by either party within said ninety (90) day period, the award shall become null and void and shall not be- used by either party for any purpose in the litigation. K. Severability and Survival If any of the provisions contained in this AGREEMENT are held for any reason to be invalid, illegal, or unenforceable in any respect, such invalidity, illegality, or unenforceability will not affect any other provision, and this AGREEMENT shall be construed as if such invalid, illegal, or unenforceable provision had never been contained herein. Articles V.F., VI.B., VI.D., VI.H., VI.I., and VI.J. shall survive termination of this AGREEMENT for any cause. STANDARD ENGINEERING AGREEMENT (REV 10/06/05) Page 13 of 20 L. Observe and Comply ENGINEER sbail at all times observe and comply with all federal and State laws and regulations and with all City ordinances and regulations which in any way -affect this AGREEMENT and the work hereunder, and shall observe and comply with all orders, laws- ordinances and regulations which may -exist- or may be enacted during_ the term of this AGREEMENT by governing bodies having jurisdiction or authority for such enactment. No plea of misunderstanding or ignorance thereof shall be considered. ENGINEER agrees to defend, indemnify and hold harmless CITY and all of its officers, agents and employees from and against all claims or liability arising out of the violation of any such order, law, ordinance, or regulation, whether it be by itself or its employees. STANDARD ENGINEERING AGREEMENT (REV 10/06/05) Page 14 of 20 Article VII Attachments, Schedules, and Signatures This AGREEMENT, including its attachments and schedules, constitutes the entire AGREEMENT, supersedes all prior written or oral understandings, and may only be changed by a written amendment executed by both parties. The following attachments and schedules are hereby made a part of this AGREEMENT: Attachment A -Scope of Services Attachment B — Compensation Attachment C - Amendments to Standard Agreement for Engineering Services Attachment D - Project Schedule Attachment E - Location ap Executed this the Lq day o , 2001. ATTEST: � CITY OF FORT WORTH Marty Hendrix 0 City Secretary contract Au o izatio31 ATTEST: STANDARD ENGINEERING AGREEMENT (REV 10/06/05) Page 15 of 20 Marc A. Ott Assistant City Manager FPRO RECOMMEND A. Douglas Rademaker, P.E. Director, Engineering Department By: TITLE: President y�4 'lot IYt ATTACHMENT "A" 'Scope of Services set forth herein can- only be mod►llud by additions, clarifications, and/or deletions set forth in the supplemental Scope of Services. In cases of conflict between the- Supplemental Scope of Services and the General Scope of Services, the Supplemental Scope of Services shall have precedence over the General Scope of Services. " 1) Preliminary Conference with City The Engineer shall attend preliminary conferences with authorized representatives of the City regarding the scope of project so that the plans and specifications which are to be developed hereunder by the Engineer will result in providing facilities which are economical in design and conform to the City's requirements and budgetary constraints. 2) Coordination with Outside Agencies/Public Entities The Engineer shah coordinate with officials of other outside agencies as may be necessary for the design of the proposed street, and storm drain and/or water and wastewater facilk ties/improvements. It shall be the Engineer's duty hereunder to secure necessary information from such outside agencies, to meet their requirements. 3) Geotechnicallnvestigations The Engineer shall advise the City of test borings, and other subsurface investigations that may be needed. In the -event it- is determined necessary to make borings or excavate test holes or pits, the- Engineer shall in coordination with the City and the City's geoteohnical engineering consultant, draw up specifications for such testing program. The cost of the borings or excavations shall -be paid for by the City. 4) Agreements and Permits The Engineer shall complete- ail forms/applications to allow the City of Fort Worth to obtain ary and all agreements and/or permits normally required for a project of this size and type. The Engineer will be responsible for negotiating and coordinating to obtain approval of the agency issuing the agreement and/or permits and will make any revisions necessary to bring the plans into compliance with the requirements of said agency, including but not limited to highways, railroads, water authorities, Corps of Engineers and other utilities. 5) Design Changes Relating to Permitting Authorities If permitting authorities require design changes, the Engineer shall revise the plans and specifications as required at the Engineers own cost and expense, unless such changes are required due to changes in the design of the facilities made by the permitting authority. If such changes are required, the Engineer shall notify the City and an amendment to the contract shall be made if the Engineer incurs additional cost. If there are unavoidable delays, a mutually agreeable and reasonable time extension shall be negotiated. STANDARD ENGINEERING AGREEMENT (REV 10/06/05) Page 16 of 20 6) Plan Submittal Copies of the original plans shall- be provided -on reproducible mylar or approved plastic IIlm sheets, or as otherwise approved by the Department of_ -Engineering and shall become the property of the City. City may use such drawings in any manner it desires; provided, however that the Engineer shall not be liable for the use of such drawings- for any project other than the project described herein; and further provided; that the Engineer shall not be liable for the consequences of any changes that are made to the drawings or changes that are made in the implementation of the drawings without the written approval of the Engineer. PHASE 1 7) Right -of -Way, Easement and. Land Acquisition Needs The Engineer shall determine the rights -of -way, easement needs for the construction of the project. Engineer shall determine ownership of such land and furnish the City with the necessary right-of-way sketches, prepare necessary easement descriptions for acquiring the rights -of -way and/or easements for the construction of this project. Sketches and easement descriptions are to be presented in form suitable for direct use by the Department of Engineering in obtaining rights -of -way, easements, permits and licensing agreements. All materials shall be furnished on the appropriate City forms in a minimum of four (4) copies each. 8) Design Survey The Engineer shall provide necessary field survey for use in the preparation of Plans and Specifications. The Engineer shall furnish the City certified copies of the field data. 9) Utility Coordination The Engineer shall coordinate with all utilities; including utilities owned by the City, as to any proposed utility liens or adjustment to existing utility lines within the project limits. The information obtained shall be shown on the conceptual plans. The Engineer shall show on the preliminary and final plans the location of the proposed utility lines, existing -utility lines, based on the information provided by the utility, and any adjustments and/or relocation of the existing lines within the project limits. The Engineer shall also evaluate the phasing of the water, wastewater, street and drainage work, and shall submit such evaluation in writing to the City as part of this phase of the project. STANDARD ENGINEERING AGREEMENT (REV 10/06l05) Page 17 of 20 10) Conceptual Plans The Engineer- shall furnish four (4) copies of the Phase 1 concept engineering plans which include layouts, -preliminary right-of-way needs and preliminary estimates of probable construction costs for the Engineer's recommended plan. For- all submittals, the Engineer shall submit plans and documents for street/storm drain and water/wastewater facilities. The Engineer shall receive written approval of the Phase -Plans from the City's project manager before proceeding with Phase 2. PHASE 2 11) Design Data The Engineer shall provide design data, reports, cross -sections, profiles, drainage calculations, and preliminary estimates of probable construction cost. 12) Preliminary Construction Plans and Technical Specifications The Engineer shall submit twenty (20) copies of Phase 2 preliminary construction plans and five (5) copies of the preliminary technical specifications for review by the City and for submission to utility companies and other agencies for the purposes of coordinating work with existing and proposed utilities. The preliminary construction plans shall indicate location of existing/proposed utilities and storm drain lines. The Engineer shall receive written approval of the Phase 2 plans from the City's project manager before proceeding with Phase 3. PHASE 3 13) Final Construction Plans The Engineer shall furnish five (5) copies of the final construction plans and contract specifications for review by the City. 14) Detailed Cost Estimate The Engineer shall furnish four (4) copies of detailed- estimates of probable construction costs for the authorized construction project, which shall include summaries of bid items and quantities. 15) Plans and Specification Approval The Engineer shall furnish an original cover mylar for the signatures of authorized City officials. The Contract Documents shall comply with applicable local, state and federal laws and with applicable rules and regulations promulgated by local, state and national boards, bureaus and agencies. The Engineer shall receive written approval of the Phase 3 plans from the City's project manager before proceeding with Phase 4. STANDARD ENGINEERING AGREEMENT (REV 10/06/05) Page 18 of 20 PHASE 4 16) Final Approved Construction Plans The Engineer shall furnish 45 bound copies of Phase 4 final approved construction plans and contract specifications. The approved plans and contract specifications shall- be used as authorized by the City for use in obtaining bids, awarding contracts, and constructing the project. 17I Bidding Assistance The Engineer hall issue addenda as appropriate to interpret, clarify, or expand the bidding documents, and assist the owner in determining the qualifications and acceptability of prospective constructors, subcontractors, and suppliers. When substitution prior to the award of contracts is allowed by the bidding documents, the Engineer will advise the owner as to the acceptability of alternate materials and equipment proposed by the prospective constructors. 18) Recommendation of Award The Engineer shall assist in the tabulation and review of all bids received for the construction of the project and shall make a recommendation of award to the City. 19) Prebid Conference The Engineer shall attend the Prebid conference and the bid opening, prepare bid tabulation sheets and provide assistance to the owner in evaluating bids or proposals and in assembling and awarding contracts for construction, materials, equipment, and services. PHASE v 20) Preconstruction Conference The Engineer shall attend the preconstructlon conference. 21) Construction Survey The Engineer shall be available to the City on matters during its construction and will set control points in th stake the -project. The _setting of line and grade stakes will be performed by the City. 22) Site Visits concerning the layout of the project e field to allow City survey crews to and The Engineer STANDARD ENGINEERING AGREEMENT (REV 10/06/05) Page 19 of 20 23) Shop Drawing Review The Engineer shall review shop and- erection drawings submitted by the contractor for compliance with design concepts. The Engineer shall review laboratory, shop, and mill test reports on materials and equipment. 241 Instructions to Contractor The Engineer shall provide necessary interpretations and clarifications of contract documents, review change orders and make recommendations as to the acceptability of the work, at the request of the City. 25) Differing Sate Conditions The Engineer shall prepare sketches required to resolve problems due to actual field conditions encountered. 26) Record Drawings The Engineer shall prepare record drawings from information submitted by the contractor. STANDARD ENGINEERING AGREEMENT (REV 10/06/05) Page 20 of 20 EXHIBIT "Awl" SUPPLEMENTAL SCOPE OF SERVICES (SUPPLEMENT TO ATTACHMENT "A") PROFESSIONAL SERVICES: DRAINAGE STUDY FOR FUTURE STORM DRAIN IMPROVEMENTS TO 9100 TRINITY BLVD (WALKER BRANCH AND LOREAN BRANCH) CULVERT IMPROVEMENTS. City Project No. 00627 DOE No. 5559 The following is a clarification of the tasks that the ENGINEER will perform under ATTACHMENT "A". Work under this attachment includes the preparation of -a drainage -study for the project area described below and shown graphically an Attachment E: This Drainage Improvements Project consists of providing improvements to the Trinity Boulevard crossings of Walker and Lorean Branches in east central Fort Worth. Since no- concept level studies have been performed the project is proposed to be performed in phases with the first phase (PART A) being to inventory available information and perform a feasibility study to identify the type and size of structure and the extent of adjacent roadway to be improved. Upon receipt of notice to proceed, the ENGINEER will perform the following tasks: PART A — Da#a Acquisition, Collection and Inventory The data collected for this project includes existing information possessed by CITY in the form of studies, maps, engineering construction plans, and digital files as well as information generated in the field specifically for this project. 1. Data Collection a. Obtain available topographic maps, zoning maps, -land use maps, and thoroughfare plans within the study Ilm(ts from CITY. b. Obtain "As -Built" plans for existing bridges, culverts, paving, grading and drainage construction within UQUtudy limits from CITY: c. Obtain digital copies of latest versions of digital aerial topographic and photographic.data from CITY. d. If necessary for the project obtain effective LOMR and- all documentation, luding hydrologic and hydraulic models, from CITY for area immediately upstream of this Q�n9iQ� Scope -of Services project area. If information is unavailable from CITY, ENGINEER will request information from FEMA. 2. Fietd Wor-K a: Ped°orm two (2j engineering site =lists to verify the study limits, delineate subwatershed boundaries, and identify hydraulic parameters including existing flooding and erosion problems, condition of pipe outfalls, and- potential structural - improvement locations. b. Field surveys will be obtained as necessary forthe project, including cross -sections as appropriate: If necessary, engineer will notify residents via mail outs to be approved by city. The mail out -shall be on company letter head and shall include the following project name-, limits, DOE project no., brief description of project, the consultant's project manager and phone no. PAFcT B — Hydr+�iogic Analysis This scope includes the tasks necessary to develop hydrologic models of the study areas. Study discharges will be obtained for a range of return events, assuming fully -developed watershed conditions. Existing conditions hydrologic models for contributing watersheds for applicable projects are available in either HEG1 or HE -HMS format, either from CITY or FEMA. Hydrologic Analysis a. When necessary, prepare a drainage area map of 1" = 200 scale from available contour maps. b. Delineate sub -watersheds as necessary to analyze existing drainage .patterns within the May area, as well as to identify and denne proposed improvements. c. Obtain hydrologic parameters for -each subwatershed including precipitation data, time of concentration, and land use category: d. Create a fully developed hydrologic condition land use map based on aerial photography and the City's land use�zoning maps. PART C'—Hydraulic Analysis Recommended Improvements EAl-2 ai/19/U7 Scope of Services a. Assess available previous studies and modeling to provide the basis for the models to be used in evaluating improvements to the two structures. Coordinate field survey with Survey subcontractors. lJ. Determine design -flows at the two structures separately and -In combination. No -new watershed hydrology modeling is proposed in this scope -of work. Previous watershed studies by the U.S. Army Corps of Engineers will be interpreted for an estimate of- fully developed watershed flows. Flows from the effective Tarrant County Flood Insurance Study (FIS) will be used for existing conditions. o, Develop base condition HEC-RAS hydraulic models of Walker Branch and Loreari Branch in the vicinity of the proposed crossings. The models will consist of available previously developed hydraulic models supplemented by field surveys obtained for this -project. Compute flood profiles -for the 10-year, 50-year, 100-year and 500-year storms under _existing (FIS) conditions and the- 2-year, 10-year, 25 year, and 100-year storms under fully developed watershed conditions. Plot floodplains for the existing and fully developed 100-year storms using these profiles in combination with available topography. d. Use the HEC-RAS models developed in Task c above to size structures for the proposed crossings and assess requirements for adjacent roadway improvements. Potential improvement options considered will include separate culverts or bridges at each stream and a single bridge spanning both streams at the existing location. A maximum of three (3) alternatives will be investigated.. e. Develop order of magnitude probable construction costs for each improvement alternative. f, in coordination with City staff select an alternative for design.. In addition to cons ruction costs, the selection Of an alternative will also consider environmental concerns to be investigated under a separate subcontract. g. Provide CI T Y with results of analysis in both digital and hard copy format. Up to three (3) concept and preliminary revisions sets will be prepared for OWNER review and comment in preparation of final exhibits, report and documents. Opinions of Probable Construction Cost will be provided for the selected recommended improvement option. h. Prepare a request for Conditional- Letter of Map Revision (CLOMR) covering the selected alternative. ..Include calculations and exhibits required by the Federal Emergency EAl-3 Scopeof 3exvicee Management Agency (FEMA). Coordinate with the City and FEMA to obtain approval. This task does not include obtaining a final LOMR, which should be scheduled and obtained following construction of the improvements. PAR1 D =Project Development This scope includes coordination and communication procedures to -be implemented between OWNER and ENGINEER in completion of this project. 1. Project �aordination a. Conduct up to four (4) project status meetings with. CITY. Meeting shall be used to update CITY as to status of project and to determine CITY preference in recommended improvement option. b. Conduct up to -two (2) site visits to project site vrith CITY, upon. CITY request. c. In coordination with CITY, conduct.. one (1 j public involvement meeting. to supply project information, goals and schedule to the surrounding residential community. ENGINEER will prepare up to two (2) graphical exhibits for use in public presentations. d. Prepare monthly updates for CITY identifying what work was accomplished, what items are pending and what outstanding issues need immediate attention. 2. Report Prepare written concept, preliminary and final reports. detailing the- assurriptions made in the study, the results of the investigates and the options of probable cost for recommended: improvements. The reports will contain results of computer models created in support of the study in both digital and hard copy format. EAl-4 O1J19/07 Scope of Seiv3cea ATTACHMENT "B" COMPENSATION Pt SE Drainage Study: 31U0 Trinity-3ibd (Walker Branch and LOrean Branch) Cuivert improvements Cuivert and Channel improvements Contract 2006 City Project No.: 00627 DOE Na. 5559 1. Compensation A. The Engineer shall be compensated a tofaE lump sum fee of $92,135 as summarised in Exhibit "B- 3". Payment of the total lump sum fee shall be considered full compensation for the services described in Attachment "A" and Exhibit "A-1" for all labor materials, supplies and equipment necessary to complete the project. B. The Engineer shall be paid in four partial payments as described in Exhibit "B-1"upon receipt. of four individual invoices from the Engineer. In this regard, the engineer shall submit invoices for four partial payments as described in Exhibit "B-1 Section 1- Method of Payment. II. Schedule Final Report shall be submitted within 360 calendar days after the "Notice to Proceed" letier is. issued. A. Conceptual Engineering Plans — 60 Calendar Days B. Preliminary Drainage Study Report-180 Calendar Days C. Final Drainage Study Report —120 Calendar Days EXHIBIT "MWI tSUPP_LEMEN I TO ATTACHMENT "B")- METHOD OF PAYMENT Drainage Studye 9100 Trinity BlV %-WVC1 ker Branch and Lorean Branch) Culvert Improvements. r✓uivert-and Channel Pmprovemen#s Contract 2006 City Project No.. 00627 DOE No. 5559 I. Method of Payment Partial Payment shall be made to the Engineer monthly upon City's approval of an invoice from the Engineer outlining the estimated current percent complete of the total project. The aggregate of such monthly partial fee payments shall not exceed the following: Until satisfactory completion of Exhibit "A-1", Conceptual Engineering plans submittal and approval by the City, a sum not to exceed 30 percent of the total lump sum fee. iJntli satisfactory completion of Exhibit W1", Preliminary Drainage Study Report submittal and approval by the City, a sum not to exceed 60 percent of the total lump sum fee, less previous payments. Until satisfactory completion of Exhibit "A-1", Final Drainage Study Report submittal and approval by the City, a sum not to exceed 100 percent of the total lump sum fee, less previous payments. 1(. Progress Reports A. The Engineers submit to the designated representative of the Director of the. Departm$nt of Engineering. monthly progress reports covering all phases of design by the 15�h of every month in the format required by the City_. EXHIBIT B-2 (SUPPLEMENT Ta Al I ACHiVfENT B) F1 UI-LX KATE SCHECULE Drainage Siudya 9100 Trinity Blvd -(Walker Branch and Lorean Branch) Culvert Improvements Culvert and Charsel Improvements Contract 2006 -City Project No.: 00627 ROE No. 5559 Employee classification Rate/Hour Principal $135 Senior Professional $130 Registered Professional $13Q Professional $120 Designer $105 Technical Support $75 ClericallAdministrative Support $45 EXHIBIT 13-3 (SUPPLEfiIEENT TO ATTACHMENTB) 9100 Trinity$im ;�.Aa'aiker Braneh and Lorean Branch) Culve# Improve ents Culvert and Channel Improvements Contract 2006- City Project No.# 00627 DnE No. 5559 Prime Consultant Scope of Services- Fee % of Contract Siream Water Group, Inc. Study & Proj. Mgmt Non MlWBE Sub Cosultant: None Proposed MNUBE Subconsultiants Spooner 8 Associates, Inc. Survey $ 801835 87.52% $ 11,500 12.48% Total For Professional Services $ 92,135 100% Project Descriutiort &code of Services. Total Fee rag Eng(rieering Services Drainage Study 'l . MtWBE Fee $11,fi00 Actual M/WBE Citv's MJWBE Percent Percent Goal 10% Gt'ou� EXHiBI<T B-3e (SUPPLEMENT TO ATTACHMENT R) SUMMt�RY OF DESIGN FEES Drainage Study; 9100 Trinity Blvd (Walker Branch and Lorean Branch) Culvert Improvements. Culvert and Channel Improvements Contract 2006 City Project No.. 00627 DOE No. 5559 May 9, 2007 Ms. Dena Johnson, P.E. Department of Engineering City of Fort Worth 1000 Throckmorton St. Fort Worth, TX 76102-6311 Reference: Drainage Studyc 9100 Trinity Blvd (Walker Branch and Lorean Branch} Culvert Imps©vements. Culvert and. Channel Improvements Contract 2006 City Project No.. 00627 DOE No. 5559 Dear N1s: Johnson; We appreciate the cpportunity to present this proposal and fee. schedule for your consideratcn. Attached please find construction cost estimates, schedule, and exhibits depicting the scope of work. We propose to complete the proposed work in accordance with the following fee schedule: b737 Btenta�nod $tnii� Rd• Suite ?311• Dort 1Vnrtli. TX 7G112 Pli,�ic'. Y,17.-1=1t�.=1171 •Fax: h17.�Id6.A33i u��+°xz'. strrunn�atergroup.cont Exhibit B-3A lv1s. Dena Johnson, P.E. May 9, 2007 Page 2 Basic Services $79,485 Drainage Study $795485 (17,625 acres) Special Services $125650 Surveys $111500 10%for M/WBE Subcontractors $1,150 TOTAL LUMP SUM $92,135 Total Lump Sum Fee for Drainage Study $92,135 We will. be using Spooner & Assoca#es, Inc: (�=11,500Zfor surveying. This will result in an 12.4870 portion -of the contract that will be performed by approved MUWLE firm which will meet or exceed the target of 10%. If you. have any questions or require additional information, Please give me a Ball, Sincerely, 'Stream Water group, Inc: Shamsul Arefi'n, P,E. President 6737 i3mnttt•iind Stair Rd• Sitite 7311. Port 11'ttrth;'1'X 7fi1 I? 1'hcinci R17.4�(i.-1I71 Faz: R17.4dG.�13�i t�'«it°. stre:untatttcr�raup.com m k m 1= ea E D D C _CL E m O " a E� d N 7 U U w G O N m y4O7 m Eon y c °Z 0 cCL Z E a�i ro- O� IL ccacl m U U as �. 'Y m a m� 'c F 0 0 rn 0 tl1 tf} rn N d0 m U EXHIBIT B-3C (SUPPLEMENT TO ATTACHMENT B) 9100 Trinity Blvd Culvert Improvements= Waiker Branch -and Lorear: Branch Culvert and Channel Improvements Contract 2001 Cif Project No.: 00627 DOE No. 5559 Task Description Priclpai QA/QC Project= Manager Praj Eng CAD Clerical l7ireet Cosf _ Total Fee Drainage Study Part A 1 lCoordination Mtgs 1 70 20 l a 3,835 2 Research and Data Collection 4 40. 20 $ 250 . $ 61470 CoordinationWith OtherRgencies- 2 4 8 4 $ 150_ $ 2,200 Schedule Submittal 8 Monthly Progress Report 1 16 12 $ 3,655 Part B 3 Conduct Site Visit and Analyze Improvements 32 48 $ 175 $ 11),095 -4 HEC-HMS Model Preparation and Run 2 25 30 $ 5,520 5 HEC-RES Model Preparation and Run 2 140 45 $ 20,445 6 Prepare and Coord CLOMR/LOMR 1 8. 30 40 24 $ 4,700 $ 13,555 7 Alternative Cost Analysis 8 32 $ 41880 8 Draft (4 copy) and Final (4 copy) Report 16 30 30 $ 900 $ 8,83D Subtotal - Drainage Study $ 79,485 Additional Services 1 Surveys (along existing creek and x-section) $ 11,50D 2 Administrative (10%) Fee on MMBE Finns $ 16150 Subtotal - AdditionalSurvices $ 12,650 Total Project $ 92,135 ATTACHMENT to CMANGES.AND Annr=NQMENTS TO STANDARD GREEIVIENT ANt)_a I I ACFINIENT A WATER 1A1vD SANITARY SEWER REPLACMENT CONTRACT E,rainage Study . 9100 Trinity Blvd-(vt(alker Branch and Larean Branch) Cuivert Improvements. Culvert and Channel Improvements Contract 2006 City Project No.: 00627 DOE No. 5669 There are nochanges anc� amendments to Standard Agreement -and Attachment A. road. � Im q D) QI o w n m. Oc m m N 'o a o m to 4q n I FROM dow;7 " `r O T m FIT I ad tiVivo M _add N add) U7 aco bare .090 i m m Oaks C add 0 la AD O Cis Ql1at daemon m Oak door O eNV col)m N N �f oPat _ 10906,00 S a = led c m N OQ c m legalo is I N m CL' la OF tN 14', €'rw%d � i € Wilson; ON � O "IF ;O addle, mAdds ormoo � L Nofood N =N told Ndo E t glade, O m mPoll t , so load r � LL O W W O 11 H 3 UP,?tL ML €up, ;'� � I cc ?t� land t wIm n n n n n n In m Ico jm m m m 0 0 0 0 0 0 0 €0 0 0 (0 j0 0 askedio €n � m n I� 1a m Ailing N N N N 3N N !O N took. N of F-SR& 1' m tD ifD. t0 m 3to IP tr to co .- c (c c c c lc o ;� m a O rn jti is �` io r Fee 3 tL- 0 T I Qcdo T EmT T tT6 T D 9 d -V aSO a 0 so do edge,o eager:C0 cc-E -to! � flood €goo o �T t € Image adeadeb O alro'll War east Ideal a o. 3 *460 stag SO ON + goal I 44 kegs Me am ( dead — a ii Ad I Zoe f .data ! €ZN i3 ( c i 4= d jU ro jC ( ��� is C I F E�: E d 3 Y leader Cl 'O. 1 �O i , ake •a Q T €� 0 �m m 1- Cl) a do 3 U o s W x �at m v rn 3 ID U) OFF m. I i goo v 1� m m o c o. deal�� d °.c added E � VIDPAP � � iD € � 2 cmi IU3 'Mm ,E va"alaa)i I�mc4m a w a o x a a is LL ill a` m m ! 2 z ( F z d c - € iCD c Coal N U r N M 7 to n to O O CoalPlead Mgrad" CC Tell 3 UU m - _ 1 c � aw I0 w m co co co CO CO m (D r; t` t` co co 000 00 O.O cocl .�Cn-NN mc s-NNOOO N •G cotyr�Ne-NOye-O QO r O t't�r r .... tOOrOcpt� � C C C LL C J 7 *a •L 'C 'C 'C 'rr O O O� tU U t- f- U. LL LL LL LL LL 212 F— a)F- .f dy n h t- N co co co co O m �' O ti �� 00000ocpOr 0 r00�Lf O W`(D(_0 QON NNNNNNONgr O t�0 (1D N N N is to r In t0 Fz t) CO !D iD C C C `C C C QJ N tU O O O O O O F- LL. tL E :R 12 :2 2 1f- !- E- C 00 �= rn I rn U) `� >, m u� rn co co cccn o mco do m•070Lo-o-o mNoNo m r � r � r CO M r (OQ �� � r too r z C O O N C .> co � ma�CL .0)3m p atII O r =`CC .fO p mU aU 1Q W o r. N O tch N DtLG3 vV=�om C C (DNQ U ill— O CO L COmimaC za4l aaa an EL G .- N c) d to to ti c0 rn O cm th SW 't vY. rFA,, A" 5toA 0, w•,, r r r . _ , i ; X•. 'i.—+�4_'c. t'a.-. 'i `' too a. of AT, r l ybAl � 1 f_' 4; S�'�Ir�,+. r i.j ,•i t tri 'h, - �' 2 -T:� A -' •2 r { ^sit Ads I t ,� Sf x,. '�,' y ',16 y r 1 t aj� f t T'r'! Ir -,r I r ..�_ �! �` r . i~ y { +'• o it.. r `_,,. N'AYn� , A as �,,,,. r�. ~;+` 3i. - f{ {milAll' j, Itf7. �;'� iit'� i" t .-a.� . { - '� ,V IT�•�'`r-.. jAT a 2 ,�: - • ` Zy y FAdsr `t all, VIA r-V �.WB , fi Y ATV I �u.�.�,,, Al! Yt- ` �L �, t A It i• /'t7 tip s ar r �_ war -It a iba { s Tyt. - n aft } ' 1'+�i r : r 4 • >t All-y t-I '...) i'_ - is I ,2w. 'Y" r`rr { : ! £or S i 41 Ads ti Ad �ti7 also IIasi 0 Ef•�c.,rj ta.. r. )'{ i. t r + r...i IT .. 1 an as sbo ; •, -t ) <r ,y �r eeee•- �i f jj{'''�+`"'" - t� r •' S�fit of, Ad's•'y �l I& l t .ppppi 'y-i yy_� . i l.. - s'' \ + J S4 t; �ff1 1 IT OL Also.. �. �0`7 y f 'AT 4 •. t }; ` �,r l i� ti r rt J{� e - m eT �4- 1. + +Kt I �. 1 . � :�- is r r y r � Vd., 1°, r` , i `s i - -.f+- , - x 'c c + a rt C .' ter• �••F'#"Z., r •r. t 1, ly . • .y "-:r <t f S Y ;-y-•. a ". F t2 i_2 h r I :s � �iRr of ram. 2 is 1� • i All TV 'r�t r It r tax%yr�2Y t rc�- t. s yr 4 .. 5. i. r fi r r. y r Sr [ i VA {& r �C1,' �at.€ t to 6 i y !j A IT r I• f+2 f t j f+65 y+4r �1y�j .x Its `10 _a ;a �t If I� r i r j w { < +71 �y + _s. - ,}t2( •�E ,*.�.. . r r r. �.,r-• •n i•¢�lF+"odall Tom, AVIT A .R � i Y[t r^ l Sxi .. ' assV. *44 `{rr, '7 ,•i f } _ 2 a '' 1 -^�. - '� 2 .x`.y odoroust L..'• y [ ' } ( Y`f h.'.-'`'`'� xi I y� l{Lll � ff i i'+i key it I1�• a I ool t.- S1i i +:<r : i3 S _ rr g N'i or 2 5 S'� . t w\y't'l"4t r :,}•of od AA 2'. . • 1i /� [�,5 r{1i,� raye•s=�iEa{,� E.h '`y ..f'. ^ �5 • TOP 1 y , [r yf» 1 V- all Is II add ` �*60 TV aso [ `�' �htS r r r� + n AR ti n t+ T 3} C T r `�!• . 2 t 'ram Tribalr 4i: r I. ,'... r� t µR ` -'� rt , �• I. F *r r �{• z F VIA ads . � _r �- , a.� ost 11! 41j� jt.i • • :.1;0, a + ,.t IL r 's .,' �i•�w `_ y f rr £mists '�, ! \. 5 �'r hr }."�y^�r i r F S . t,y2 -'3 .p!pitt , y .. .1 , fool,t1'•.. + Sow so VAN Ill 2 i✓:• Y �F'• �-yn. - .M .some •!Y'7t•-V j µ• ai' yc� - ',1 •r' jVIA : s1: y *, Yboo_+ maTooS'-r ■. '` t ' +a r w' , •:Icy �:.i� 1 -_ Iti-tril�• t.ty1. �'&i i•' >.:i., n�•[�a�' •t - �.,ac• 4'•. = t. r -,, �_. {t S R t off i�h�'�1•• '[. +FY-r� tSl}S,•r.'c Y�7+t ? t a.... 'fir t'�� F_ta-• to 'a< '' a T%yr''y Ra rj "yTV Is as, r •,1.; t ,'t'J- ' . =1'1 +"i?: '' j ib'x'1 6•.-t it Z r• M L 1 j'. a Y tt 4 �'riif�f f y iyk,•yw L I T• c ,_ rr�'y�r'7 Lao Il.,- .� il;slb Y'wit' r. r J'FIT i '1 r••r s- •} "�' F ark{r c: ' . , to .3` i.a R• 1- t y�'� T='1A ils� is C \s.:�5y�{1 , .-. 't = ! t• ;,. } - $1 .trir 1+' rr 1 l abob"Ir. ., t +Sra WAli __ _ aM YA V rA Lr tr "� � yy' ,� 1�To t 1 4 as'7 T ¢` .Z, �, 11 all .i4 ✓ a �.,.'� {3 [`Yv To —f-�'a' `. J ,�,.1 {. or I 4I ar t 11 v Tr, fir: r:%•, r• A ; .. �F rfim �so ol 1 % i t[ ' 4 � Slat* , I; ham., men ;' `: � }' r 144 1 k sib �, +ref r\ . t R "y . , �J r f' f y la ' }Fi A ={Ila �� tik•l soPTIVIll �„R `� r ;y�•I y .rrtc a -y �•2. r �, �r n ir'•Al a : C ^� ' ; ,'�'. 'iall A `{'�taL}ti. - '}> �,�'' f•S•w�ft ��.� j x6 Ii ;2�-s.s VoiffP �{I "- c f 1 �i rso r 1n?�.� v`"• .r.- 14. foA tt' w o 1 i ��..5 . i I= �a a'r�l i�so a�SY {S t!�i.tS�'"5, ,w -aS t 'a+ , rYTor'i`(�n'�r: All �ssc �_•( •I_ I �sa.c�.l ;,___,,,,� ``r V -1. "t",.. '�+ �'+r't��"(i'.: k <;'[ tr,�: t'ss_..{.1• ,� j� } ��`qi. 't:+hF' I ( \ •{r'f-, 1' r r [ .s t vita 64 Py ,1""' .ice r.s Ibw nr{?t .4•r tl�*Tma� T'_; orw I, !i iAV A `t i` t; r 2, r r f1 rga { ivj`'tty milk 5 Ago .i r_ i 7t .tom, a,flr �.p ir. �.e'• 4 �'rl +v �t{'[�::1 �I,R„t i' �r w' • : • t , :;•+t .. 99 � all All A IT 9 ,? y'�-' - '.'. ..,L t !VA, r s Y':r '{{�t•1 r�, La r '0 •mot 34 t• �' • at W h-• t•r +{-)yam' S• { •PTA �y eye' 1- F-,-':'y 9Y. Tall ,i, •t 17. 1"Y 1r '-' . r �,Vp .y< t r• [ x? t -• , , { F wa As ` ' E iv; # ur t" a� Y s , f** it IIca .i.}. , 2. ['-'� r ri ca aril . ( r A r� is + , .. ♦ -.JF* i.r*•, s �L .ar A* do Sao,i,a �~ {14 •i r+s 1- R r_ 3 - n.. ta• I■ �I i x i ?. T r r '- y r7 acis e. a S' �~ 2, f ,Nai - A �('S' .N-t,,r�i .As .vl 'a. Ij Y~ ~ �.�rr. v}• [ r y-. �"` if' S`.ar;, R - �?-,i rs��" .,,a2t �y-r„y W t I �. Too i e t`y3r�i, 5+.�_ f'-" i. • y -1 {, y. -fi - Lr• frvF`X S i Lt vi i ryjR V ?fx� 5 tS t�04 1,_ lq, ! �v.�ti 4 7 tV-11om` .a' ' wTV •t ..� ♦ SF 3 y-'4 -} Lip, Aid = 2 ' • LE G E-N D tau,,, �l �_ ::r,ks Two IAV +o � - `-i- Y .Y 3 w n sb aI og, t. 1 ta�5 R #•2 a-- - t� .tr ..Ar � 0 so , - +b} r . Vol"so go, tt ?A M5�"; . r ( tATI2 a. III; — { .iAT A"{w Ads A III b_ 'z i ., �`''r ''F'nt ay+. a'.ry2, '—'4Y DRAINAGE �!S�`�—,+L,.r= _ �' f va"-x: , i MAIN1 .TV,'�'r:*,, T' 2 y1 it eG V Ly .' c,�- r-szl 1 rrl t Y ' +-"'ma y,� ' I ! , •etc Ir` B QUNDARu �. Y •�li., =,'d �', y7�`J�'te;tab ;'-::+,!TV s •t �.�-,s`'rart,. STORM DRAIN +t lot h2 s . . ro1,Y $ l ,, r �%� met;r 1 r t+: V T, Iif,yT��r lb,laffan#' veI ~i IV A,i + All,�r ttR J ar, air {• . Llio�v�} t279 itfitt'[�-t -' 2all}�a4114 Vita ' xK {'� a FLOW DIRECTION —► Y-a z I �•<' .. �; *A f- +,,i�"wl�;i�i},t�`ljet2 r•• s� pv I �, a ` ' }T+ a4�`%j�li+`"r 'p Fq s99 7 i i � _ a� "rY'`'1rp.ri�1•,.,slat VIA, Is I_ IolarrAds ob i Lj} .inoi,� _Y ? '%ivi. r moll,f is xr f Via d r f i SS u i� it < t '�k�:• Fi? i f = ry 'c .__.2'� T 4 �..a4 i..,_ v at FX- Ii 5 f i • `l }ti`Y1r y.'7` Y t y Yu.: t uT✓)/N•I f-.y .'f ryy U lf!lr, a .agetee' •c4'aad •fi'•a :"cks-on .r - f r`3 1�.•�'r k i Y"•i -•s.• �" Sbat tx tT,{ v{,+"IT ' s r �s it" r�i, + '1�• L' t� ti . zi t - 4 j ir°'t a.. y : t ri so i t #$ A 2ti . LY fa,�.in FIII�#r �wil +y]i2 "b. ra i5 jo;, pAllr�tbp a 1 Vr door[ : •V f I; a�+S' Fl f': 4 , #t-}5'1•Smmm- i i -nt S` a 3.3r. E4 t� .a r I ,; `e .e:+t'-{ �.'„ �j4-• 6•M': q.rw,'�, .[".•'YH s; �}. .yet s.<•h�,:..t. ,•�il I •,.•ti.?}�%:+;• :7l.ra,;..,i, t.� `s �.. .-k. ATTACHMENT E-2 PROJECT LOCATION MAP (COUNCIL DISTRICT 5) CULVERT AND CHANNEL IMPROVEMENTS, CONTRACT 2005 9100 TRINITY BLVD. CULVERTS (WALKER BRANCH AND LOREAN BRANCH) CITY PROJECT NO, 00627 DOE NO.5559 STREAM WATER GROUP, INC. FORT WORTH SEWER a WATER ENGINEERS # PLANNERS • SURVEYORS MAP: 2096412 MAPSCO 67A SCALE :1" = 6000' pity of Fort Worth, �Exas • _� • _ ,_ � DATE: Tuesday, June 19, 2007 LOG NAME: 30TRlNIT1(00627 REFERENCE NO.: *�C-22195 SUBJECT: Authorize Execution of an Engineering Agreement with Stream- Water Cr-oup, Inc., for the 9100 Trinity Boulevard Culvert Improvements (Project N_o. 00627) and Adopt Appropriation Ordinance RECOMMENDATION: It is recommended that the City Council: 1. Authorize the transfer of $105,957.00 from the Storm Water Utility Fund to the Storm Water Capital Projects Fund; 2. Adopt the attached appropriation ordinance increasing estimated receipts and appropriations in the Storm Water Capital Projects Fund in the amount of $105,957.00 from available funds; and 3. Authorize the City Manager to execute an engineering agreement with Stream Water Group, Inc., in the amount of $92,135.00 for a drainage study for the 9100 Trinity Boulevard (Walker Branch and Lorean Branch) Culvert Improvements. DISCUSSION: The Storm Water Management Program- was established b reduce flooding in Fort Worth, preserve streams, minimize water pollution and to operate the storm :eater system in a more effective manner to fully campiy with state and federal regulatory requirements. This will be accomplished bye infrastructure reconstruction and system maintenance, master planning, enhanced development review, and increased public education and outreach. The scope of this agreement consists of the preparation of a drainage study for culvert and channel improvements for both Walker Branch and Lorean Branch in order to convey the 100 year storm underneath the roadway at 9100 Trinity Boulevard. Stream Water Group, Inc., proposes to conduct the necessary study for a lump sum fee of $92,155.00. City Staff considers this to be fair and reasonable for the scope of services proposed. In addition to the contract amount, $13,822.00 is required by the Engineering Department for project management. Stream Water Group, Inc., is in compliance with the City's M/WBE Ordinance by committing to 12 percent M/WBE participation. The City's goal on this project is 10 percent. This project is located in COUNCIL DISTRICT 2. Logname: 30TRINITY00627 Page 1 of 2 FISCAL INFORMATION/CERTIFICATION: The Finance Director certifies that upon approval of the above recommendations and adoption of the attached appropriation ordinance, funds wiil -be available in the current capital- budget; as appropriated, of the Storm V1{ater Capital Projects Fund. TO -Fund/A�count/Genters FROFM=Fund/Aecount/Centers 1&2)P228 472069 2052800627ZZ $105.957A0 �PE69 538070 0209206 $105,957.00 �P228 531350 205280062710 2 304.00 3)P228 531200 205280062716-$92.135.00 2)P228 531200 205280062716 $92,1"s5.00 �P228 531350 205280062716 9 214�00 �P228 531350 205280062720 2 304.OG Submitted for City Manager's Office by: Marc Ott (8476) Originating Department Head: A. Douglas Rademaker (6157) Additional Information Contact: Dena Johnson (7866) Logname: 30TRINITY00627 Page 2 of 2