Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
Contract 53482-PM1
RECEIVED APR 2 12020 CITYOF FORT WORTH CITYSECRETARY C6TY SECRETARY lITRACT NO. 5 3q ? 9 ) FORT WORTH PROJECT MANUAL FOR THE CONSTRUCTION OF DRAINAGE &PAVING IMPROVEMENTS TO SERVE TEXAS HEAL TH HARRIS METHODIST HOSPITAL FORT WORTH "X" No. X-26075 City Project No. 102109 Betsy Price David Cooke Mayor City Manager David Magana, P.E. Director, Transportation and Public Works Department Prepared for The City of Fort Worth 00 p teague nall & perkins 5237 N. Riverside Drive, Suite Fort Worth, TX 76137 .. ............... SCOTT A. GIBSON j Awl 89290 VID ? so ���� ,1 I0NAL:�� XWN x 817.336.5773 ph 817.336.2813 f TBPE Registration No. F-230 www.tnpinc.com wommomm THR 18335 00 00 10- 1 TABLE OF CONTENTS FOR DEVELOPER AWARDED PROJECTS Page 1 of 4 CITY OF FORT WORTH STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS – DEVELOPER AWARDED PROJECTS Revised September 1, 2015 TH Harris Hosp. FTW City Project No. 102109 SECTION 00 00 10 TABLE OF CONTENTS DEVELOPER AWARDED PROJECTS Division 00 - General Conditions 00 11 13 Invitation to Bidders 00 21 13 Instructions to Bidders 00 41 00 Bid Form 00 42 43 Proposal Form Unit Price 00 43 13 Bid Bond 00 45 11 Bidders Prequalification’s 00 45 12 Prequalification Statement 00 45 13 Bidder Prequalification Application 00 45 26 Contractor Compliance with Workers' Compensation Law 00 45 40 Minority Business Enterprise Goal 00 52 43 Agreement 00 61 25 Certificate of Insurance 00 62 13 Performance Bond 00 62 14 Payment Bond 00 62 19 Maintenance Bond 00 72 00 General Conditions 00 73 00 Supplementary Conditions 1 73 10 Standard City Conditions of the Construction Contract for Developer Awarded Projects Division 01 - General Requirements 2 11 00 Summary of Work 01 25 00 Substitution Procedures 01 31 19 Preconstruction Meeting 01 31 20 Project Meetings 01 32 16 Construction Progress Schedule 01 32 33 Preconstruction Video 01 33 00 Submittals 01 35 13 Special Project Procedures 01 45 23 Testing and Inspection Services 01 50 00 Temporary Facilities and Controls 01 55 26 Street Use Permit and Modifications to Traffic Control 01 57 13 Storm Water Pollution Prevention Plan 01 58 13 Temporary Project Signage 01 60 00 Product Requirements 01 66 00 Product Storage and Handling Requirements 01 70 00 Mobilization and Remobilization 01 71 23 Construction Staking 01 74 23 Cleaning 01 77 19 Closeout Requirements 01 78 23 Operation and Maintenance Data 01 78 39 Project Record Documents CITY OF FORT WORTH STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS – DEVELOPER AWARDED PROJECTS Revised September 1, 2015 TH Harris Hosp. FTW City Project No. 102109 00 00 10- 2 TABLE OF CONTENTS FOR DEVELOPER AWARDED PROJECTS Page 2 of 4 Technical Specifications which have been modified by the Engineer specifically for this Project; hard copies are included in the Project’s Contract Documents 00 11 13 Notice to Bidders Technical Specifications listed below are included for this Project by reference and can be viewed/downloaded from the City’s Buzzsaw site at: htps://projectpoint.buzzsaw.com/client/fortworthgov/Resources/02%20- %20Construction%20Documents/Specifications Division 02 - Existing Conditions 02 41 13 Selective Site Demolition 02 41 14 Utility Removal/Abandonment 2 41 15 Paving Removal Division 03 - Concrete 3 30 00 Cast-In-Place Concrete 03 34 13 Controlled Low Strength Material (CLSM) 03 34 16 Concrete Base Material for Trench Repair 03 80 00 Modifications to Existing Concrete Structures Division 26 - Electrical 26 05 00 Common Work Results for Electrical 26 05 10 Demolition for Electrical Systems 26 05 33 Raceway and Boxes for Electrical Systems 26 05 43 Underground Ducts and Raceways for Electrical Systems Division 31 - Earthwork 31 10 00 Site Clearing 31 23 16 Unclassified Excavation 31 23 23 Borrow 31 24 00 Embankments 31 25 00 Erosion and Sediment Control 31 36 00 Gabions 31 37 00 Riprap Division 32 - Exterior Improvements 32 01 17 Permanent Asphalt Paving Repair 32 01 18 Temporary Asphalt Paving Repair 32 01 29 Concrete Paving Repair 32 11 23 Flexible Base Courses 32 11 29 Lime Treated Base Courses 32 11 33 Cement Treated Base Courses 32 12 16 Asphalt Paving 32 12 73 Asphalt Paving Crack Sealants 32 13 13 Concrete Paving 32 13 20 Concrete Sidewalks, Driveways and Barrier Free Ramps 32 13 73 Concrete Paving Joint Sealants CITY OF FORT WORTH STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS – DEVELOPER AWARDED PROJECTS Revised September 1, 2015 TH Harris Hosp. FTW City Project No. 102109 00 00 10- 3 TABLE OF CONTENTS FOR DEVELOPER AWARDED PROJECTS Page 3 of 4 32 14 16 Brick Unit Paving 32 16 13 Concrete Curb and Gutters and Valley Gutters 32 17 23 Pavement Markings 32 31 13 Chain Link Fences and Gates 32 31 26 Wire Fences and Gates 32 31 29 Wood Fences and Gates 32 32 13 Cast-in-Place Concrete Retaining Walls 32 91 19 Topsoil Placement and Finishing of Parkways 32 92 13 Hydro-Mulching, Seeding, and Sodding 32 93 43 Trees and Shrubs Division 33 - Utilities 3301 30 Sewer and Manhole Testing 33 01 31 Closed Circuit Television (CCTV) Inspection 33 03 10 Bypass Pumping of Existing Sewer Systems 33 04 10 Joint Bonding and Electrical Isolation 33 04 11 Corrosion Control Test Stations 33 04 12 Magnesium Anode Cathodic Protection System 33 04 30 Temporary Water Services 33 04 40 Cleaning and Acceptance Testing of Water Mains 33 05 10 Utility Trench Excavation, Embedment, and Backfill 33 05 12 Water Line Lowering 33 05 13 Frame, Cover and Grade Rings 33 05 14 Adjusting Manholes, Inlets, Valve Boxes, and Other Structures to Grade 33 05 16 Concrete Water Vaults 33 05 17 Concrete Collars 33 05 20 Auger Boring 33 05 21 Tunnel Liner Plate 33 05 22 Steel Casing Pipe 33 05 23 Hand Tunneling 33 05 24 Installation of Carrier Pipe in Casing or Tunnel Liner Plate 33 05 26 Utility Markers/Locators 33 05 30 Exploratory Excavation for Existing Utilities 33 11 10 Ductile Iron Pipe 33 11 11 Ductile Iron Fittings 33 11 12 Polyvinyl Chloride (PVC) Pressure Pipe 33 11 13 Concrete Pressure Pipe, Bar-Wrapped, Steel Cylinder Type 33 11 14 Buried Steel Pipe and Fittings 33 11 15 Pre-stressed Concrete Cylinder Pipe 33 12 10 Water Services 1-inch to 2-inch 33 12 11 Large Water Meters 33 12 20 Resilient Seated Gate Valve 33 12 21 AWWA Rubber-Seated Butterfly Valves 33 12 25 Connection to Existing Water Mains 33 12 30 Combination Air Valve Assemblies for Potable Water Systems 33 12 40 Dry-Barrel Fire Hydrants 33 12 50 Water Sample Stations 33 12 60 Blow-off Valves 33 31 12 Cured in Place Pipe (CIPP) 33 31 13 Fiberglass Reinforced Pipe for Gravity Sanitary Sewers CITY OF FORT WORTH STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS – DEVELOPER AWARDED PROJECTS Revised September 1, 2015 TH Harris Hosp. FTW City Project No. 102109 00 00 10- 4 TABLE OF CONTENTS FOR DEVELOPER AWARDED PROJECTS Page 4 of 4 33 31 15 HDPE Pipe For Sanitary Sewers (Gravity and Force Mains) 33 31 20 Polyvinyl Chloride (PVC) Gravity Sanitary Sewer Pipe 33 31 21 Polyvinyl Chloride (PVC) Closed Profile Gravity Sanitary Sewer Pipe 33 31 22 Sanitary Sewer Slip Lining 33 31 23 Sanitary Sewer Pipe Enlargement 33 31 50 Sanitary Sewer Service Connections and Service Line 33 31 70 Combination Air Valve for Sanitary Sewer Force Mains 33 39 10 Cast-in-Place Concrete Manholes 33 39 20 Precast Concrete Manholes 33 39 30 Fiberglass Manholes 33 39 40 Wastewater Access Chamber (WAC) 33 39 60 Epoxy Liners for Sanitary Sewer Structures 33 41 10 Reinforced Concrete Storm Sewer Pipe/Culverts 33 41 11 HDPE Storm Sewer Pipe 33 46 00 Sub drainage 33 46 01 Slotted Storm Drains 33 46 02 Trench Drains 33 49 10 Cast-in-Place Manholes and Junction Boxes 33 49 20 Curb and Drop Inlets 3349 40 Storm Drainage Headwalls and Wingwalls Division 34 – Transportation 3441 10 Traffic Signals 34 41 13 Removing Traffic Signals 34 41 20 Roadway Illumination Assemblies 34 41 30 Aluminum Signs 34 71 13 Traffic Control Appendix GC-4.01 Availability of Lands GC-4.02 Subsurface and Physical Conditions GC-4.04 Underground Facilities GC-4.06 Hazardous Environmental Condition at Site GC-6.06.D Minority and Women Owned Business Enterprise Compliance GC-6.07 Wage Rates GC-6.09 Permits and Utilities GC-6.24 Nondiscrimination GR-01 60 00 Product Requirements END OF SECTION 00 21 13 - 1 INSTRUCTIONS TO BIDDERS Page 1 of 5 TH Harris Hosp. FTW CITY PROJECT NO. 102109 1 SECTION 00 21 13 2 INSTRUCTIONS TO BIDDERS 3 4 1. DEFINED TERMS 5 6 Terms used in these Instructions to Bidders which are defined in the General Conditions of the 7 Agreement and Standard City Condition for Developer Awarded Project have the meanings 8 assigned to them in the General Conditions. 9 10 2. COPIES OF BIDDING DOCUMENTS 11 12 2.1.Complete sets of the Bidding Documents in the number and for the deposit sum, if any, 13 stated in the Advertisement or Invitation to Bid may be obtained from Owner/Engineer. The 14 deposit for the Bidding Documents is non-refundable. 15 16 2.2.Complete sets of Bidding Documents must be used in preparing Bids; neither Owner nor 17 Engineer assumes any responsibility for errors or misinterpretations resulting from the use of 18 incomplete sets of Bidding Documents. 19 20 2.3. Owner and Engineer in making copies of Bidding Documents available on the above 21 terms do so only for the purpose of obtaining Bids on the Work and do not confer a license or 22 grant for any other use. 23 24 3. QUALIFICATIONS OF BIDDER 25 26 The successful Bidder will be required to be prequalified by the City of Fort Worth as set forth in 27 Section 00 45 12. 28 29 4. EXAMINATION OF CONTRACT DOCUMENTS AND SITE 30 31 4.1.It is the responsibility of each Bidder before submitting a bid to (1) examine the Contract 32 Documents thoroughly, (2) visit the site to become familiar with local conditions that may affect 33 cost, progress, performance or furnishing of the work, (3) consider federal, state and local laws 34 and regulations that may affect cost, progress, performance or furnishing of the work, (4) study 35 and carefully correlate Bidder’s observations with the Contract Documents and (5) notify 36 Engineer or Owner of all conflicts, errors or discrepancies in the Contract Documents. 37 38 4.2.Information and data reflected in the Contract Documents with respect to underground 39 facilities at or contiguous to the site is based upon information and data furnished to Owner by 40 owners of such underground facilities or other, and Owner does not assume responsibility for the 41 accuracy or completeness thereof. 42 43 4.3.Before submitting a bid each Bidder will, at Bidder’s own expense, make or obtain any 44 additional examinations, investigations, explorations, tests and studies and obtain any additional 45 information and data which pertain to the physical conditions (surface, subsurface and 46 underground facilities) at or contiguous to the site or otherwise which may affect cost, progress, 47 performance or furnishing of the work and which Bidder deems necessary to determine its bid for 48 performing and furnishing the work in accordance with the time, price and other terms and 49 conditions of the Contact Documents. 50 00 21 13 - 2 INSTRUCTIONS TO BIDDERS Page 2 of 5 TH Harris Hosp. FTW CITY PROJECT NO. 102109 51 4.4.On request in advance Owner will provide each Bidder access to the site to conduct such 52 explorations and tests, as each Bidder deems necessary for submission of a bid. Bidder shall fill 53 all holes, clean up and restore the site to its former condition upon completion of such 54 explorations. 55 56 4.5.The lands upon which the work is to be performed, right-of-way and easements for 57 access thereto and other lands designated for use by Contractor in performing the work are 58 identified in the Contract Documents. All additional lands and access thereto required for 59 temporary construction facilities or storage of materials and equipment are to be provided by 60 Contractor. Easements for permanent structures or permanent changes in existing structures are 61 to be obtained and paid for by Owner. 62 63 4.6.The submission of a bid will constitute an incontrovertible representation by Bidder that 64 Bidder has complied with every requirement of Item 4, that without exception the bid is premised 65 upon performing and furnishing the work required by the Contract Documents and such means, 66 methods, techniques, sequences or procedures of construction as may be indicated in or required 67 by the Contract Documents, and that the Contract Documents are sufficient in scope and detail to 68 indicate and convey understanding of all terms and conditions for performance and furnishing of 69 the work. 70 71 4.7.Reference is made to the Supplementary Conditions for identification of: 72 73 a). Those reports or explorations and tests of subsurface conditions at the site which have 74 been utilized by Owner in preparation of the Contract Documents. Bidder may rely upon 75 the accuracy of the technical data contained in such reports, except as qualified in the 76 report, but not upon nontechnical data, interpretations or opinions contained therein or for 77 the completeness thereof for the purposes of bidding or construction. Contractor is 78 alerted to the fact that certain subsurface conditions may change (such as groundwater 79 levels) and that borings provide isolated information at the specific bore location only. 80 81 b). Those drawings of physical conditions in or relating to existing surface and subsurface 82 conditions (except underground facilities) which are at or contiguous to the site which 83 have been utilized by Owner in preparation of the Contract Documents. Bidder may rely 84 upon the accuracy of the technical data contained in such drawings but not upon the 85 completeness thereof for the purposes of bidding or construction. 86 87 Copies of such reports and drawings will be made available by Owner to any Bidder on 88 request. Those reports and drawings are not part of the contract documents, but the 89 technical data contained therein upon which Bidder is entitled to rely as provided in 90 Paragraphs a). and b). are incorporated therein by reference. Such technical data has 91 been identified and established in the Supplementary Conditions. 92 93 5. INTERPRETATIONS AND ADDENDA 94 95 5.1.All questions about the meaning or intent of the Contract Documents are to be directed to 96 Owner or Engineer. Interpretations or clarifications considered necessary by Owner or Engineer 97 in response to such questions will be issued by addenda and mailed or delivered to all parties 98 recorded by Engineer as having received the bidding documents. Questions received less than 48 99 hours prior to the time for opening bids may not be answered. Any addenda issued prior to the 100 opening of bids will be electronically transmitted by facsimile or electronic mail to each 101 contractor contemplating the submission of a proposal on this work. The Contractor will be 102 notified by phone of the issuance of the addenda. The proposal as submitted by the Contractor 103 will be so constructed as to include any addenda if such are issued by the Owner prior to twenty- 00 21 13 - 3 INSTRUCTIONS TO BIDDERS Page 3 of 5 TH Harris Hosp. FTW CITY PROJECT NO. 102109 104 four (24) hours of the opening of bids. Only questions answered by formal written addenda will 105 be binding. Oral and other interpretations or clarifications will be without legal effect. 106 107 5.2.Addenda may also be issued to modify the Bidding Documents as deemed advisable by 108 Owner or Engineer. 109 110 6. BID SECURITY – NOT APPLICABLE 111 112 7. LIQUIDATED DAMAGES 113 114 The time of completion is the essence of this Contract. For each day that any work shall remain 115 uncompleted after the time specified in the proposal and the Contract, or the increased time 116 granted by the Owner, $500 per day shall be assessed as Liquidated Damages. Liquidated 117 damages shall be deducted from the monies due to the Contractor. 118 119 8. SUBCONTRACTORS, SUPPLIERS AND OTHERS 120 121 8.1. If the Supplementary Conditions require the identity of certain Subcontractors, Suppliers and 122 other persons and organizations including those who are to furnish the principle items of 123 materials and equipment) to be submitted to Owner in advance of the specified date prior to the 124 Effective Date of the Agreement, the apparent Successful Bidder, and any other bidder so 125 requested, shall within seven days after the bid opening submit to Owner a list of all such 126 Subcontractors, Suppliers and other persons and organizations proposed for those portions of the 127 Work for which such identification is required. Such list shall be accompanied by an experience 128 statement with pertinent information regarding similar projects and other evidence of 129 qualification for each such Subcontractor, Supplier, person or organization if requested by 130 Owner. If Owner or Engineer after due investigation has reasonable objection to any proposed 131 Subcontractor, Supplier, other person or organization, either may before the Notice of Award is 132 given request the apparent Successful Bidder to submit an acceptable substitute, in which case the 133 apparent Successful Bidder shall submit an acceptable substitute, that Bidder’s Bid price will be 134 increased (or decreased) by the difference in cost occasioned by such substitution and Owner may 135 consider such price adjustment in evaluating Bids and making the contract award. 136 137 If apparent Successful Bidder declines to make any such substitutions, Owner may award the 138 contract to the next lowest Bidder that proposes to use acceptable Subcontractors, Suppliers and 139 other persons and organizations. The declining to make requested substitutions will not constitute 140 grounds for sacrificing the Bid security of any Bidder. Any subcontractor, Supplier, other person 141 or organization listed and to whom Owner or Engineer does not make written objection prior to 142 the giving of the Notice of Award will be deemed acceptable to Owner and Engineer subject to 143 revocation of such acceptance after the Effective Date of the Agreement. 144 145 8.2. No Contractor shall be required to employ any Subcontractor, Supplier, other person or 146 organization against whom Contractor has reasonable objection. 147 148 9. PROPOSAL 149 150 9.1. The proposal is included in the Bidding Documents and additional copies may be obtained 151 from Owner or Engineer. All bids must be submitted on the Proposal Form. 152 153 9.2. The Bidder shall use the original Proposal forms included in these bid documents. The 154 Proposal must be completed in ink or by typewriter. 155 00 21 13 - 4 INSTRUCTIONS TO BIDDERS Page 4 of 5 TH Harris Hosp. FTW CITY PROJECT NO. 102109 156 9.3. Bids by corporations must be executed in the corporate name by the president or a vice- 157 president (or other corporate officer accompanied by evidence of authority to sign) and the 158 corporate seal must be affixed and attested by the secretary or an assistant secretary. The 159 corporate address and state of incorporation must be shown below the signature. 160 161 9.4. Bids by partnerships must be executed in the partnership name and signed by a partner, 162 whose title must appear under the signature and the official address of the partnership must be 163 shown below the signature. 164 165 9.5 All names must be typed or printed below the signature. 166 167 9.6. The Bid shall contain an acknowledgment of receipt of all Addenda (the numbers of which 168 must be filled in on the Proposal). 169 170 9.7. The address and telephone number for communications regarding the Bid must be shown. 171 172 9.8.The entire proposal must be completed for the entire scope of work. If the bidder does 173 not provide one of the track options, strike through that option. All other components of the bid 174 proposal must be filled in. 175 176 10. MODIFICATION AND WITHDRAWAL OF BIDS 177 178 Bids may be modified or withdrawn by an appropriate document duly executed (in the manner 179 that a bid must be executed) and delivered to the place where Bids are to be submitted at any time 180 prior to the opening of Bids. 181 182 11. BIDS TO REMAIN SUBJECT TO ACCEPTANCE 183 184 All bids will remain subject to acceptance for sixty (60) days after the day of the Bids opening, 185 but OWNER may, in its sole discretion, release any Bid prior to that date. 186 187 12. AWARD OF CONTRACT 188 189 12.1 Owner reserves the right to reject any and all Bids, to waive any and all formalities, and 190 the right to disregard all nonconforming, nonresponsive, unbalanced or conditional Bids. Also, 191 Owner reserves the right to reject the Bid of any Bidder if Owner believes that it would not be in 192 the best interest of the Project to make an award to that Bidder, whether because the Bid is not 193 responsible or the Bidder is unqualified or of doubtful financial ability or fails to meet any other 194 pertinent standard or criteria established by Owner. Discrepancies in the multiplication of units 195 of Work and unit prices will be resolved in favor of the unit prices. Discrepancies between the 196 unit price in words and the unit price in figures will be resolved in favor of the price in words. 197 Discrepancies between the indicated sum of any column of figures and the correct sum thereof 198 will be resolved in favor of the correct Sum. 199 200 12.2 In evaluating Bids, Owner will consider the qualifications of the Bidders, whether or not the 201 Bids comply with the prescribed requirements, and such alternates, unit prices and other data, as 202 may be requested in the Bid Form or prior to the Notice of Award. 203 204 12.3 Owner may consider the qualifications and experience of Subcontractors, Suppliers, and 205 other persons and organizations proposed for those portions of the Work as to which the identity 206 of Subcontractors, Suppliers, and other persons and organizations must be submitted as provided 207 in the Supplementary Conditions. Owner also may consider the operating costs, maintenance 208 requirements, performance data and guarantees of major items of materials and equipment 00 21 13 - 5 INSTRUCTIONS TO BIDDERS Page 5 of 5 TH Harris Hosp. FTW CITY PROJECT NO. 102109 209 proposed for incorporation in the Work when such data is required to be submitted prior to the 210 Notice of Award. 211 212 12.4 Owner may conduct such investigations as Owner deems necessary to assist in the 213 evaluation of any Bid and to establish the responsibility, qualifications and financial ability of 214 bidders, proposed Subcontractors, Suppliers, and other persons and organizations to perform and 215 furnish the Work in accordance with the Contract Documents to Owner’s satisfaction within the 216 prescribed time. 217 218 12.5 If the contract is to be awarded, Owner will give the Successful Bidder a Notice of Award 219 within sixty (60) days after the day of the Bid opening. 220 221 13. CONTRACT SECURITY 222 223 Article 4 of the Standard City Conditions for Developer Awarded Projects set forth Owner’s 224 requirements as to maintenance, performance and payment Bonds. When the Successful Bidder 225 delivers the executed Agreement to Owner, it must be accompanied by the required maintenance, 226 performance and payment Bonds. 227 228 14. TRENCH SAFETY 229 230 The successful Bidder will be required to provide a trench safety plan at the time contracts are 231 signed and within the 15-day time period after Notice of Award. All cost for providing and 232 implementing the trench safety plan shall be included in the bid item for trench safety. 233 234 15. SIGNING OF AGREEMENT 235 236 When Owner gives a Notice of Award to the Successful Bidder, it will be accompanied by the 237 required number of unsigned counterparts of the Agreement with all other written Contract 238 Documents attached. Within fifteen days, thereafter Contractor shall sign and deliver the 239 required number of counterparts of the Agreement and attached documents to Owner with the 240 required Bonds. Within ten days, thereafter Owner shall deliver one fully signed counterpart to 241 Contractor. 242 243 16. RETAINAGE 244 245 Retainage of all partial construction pay estimates, where the total contract amount is less than 246 $400,000.00 (Four Hundred Thousand Dollars) shall be ten (10) percent of the amount due for 247 work performed. Retainage on all partial construction pay estimates where the total contract 248 amount is $400,000 or more, shall be ten (10) percent of the amount due for work performed. 249 250 251 END OF SECTION 00 42 43 DAP - BID PROPOSAL Page 1 of 1 CITY OF FORT WORTH STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS - DEVELOPER AWARDED PROJECTS Form Version September 1, 2015 SECTION 00 42 43 Developer Awarded Projects - PROPOSAL FORM UNIT PRICE BID Bidder's Application Drainage & Paving Improvements to Serve Texas Health Harris Methodist Hospital Fort Worth Bidder's Proposal Bidlist Item No.Description Specification Section No.Unit of Measure Bid Quantity Unit Price Bid Value UNIT III: DRAINAGE IMPROVEMENTS 1 3201.0122 5' Wide Asphalt Pvmt Repair, Arterial 32 01 17 LF 717 $124.00 $88,908.00 2 3305.0001 4" Waterline Lowering 33 05 12 EA 1 $19,680.00 $19,680.00 3 3305.0003 8" Waterline Lowering 33 05 12 EA 1 $20,553.00 $20,553.00 4 3305.0109 Trench Safety 33 05 10 LF 717 $15.00 $10,755.00 5 3305.0116 Concrete Encasement for Utility Pipes 33 05 10 CY 1.35 $3,300.00 $4,455.00 6 3341.0302 30" RCP, Class III 33 41 10 LF 717 $243.00 $174,231.00 7 3349.0001 4' Storm Junction Box 33 49 10 EA 3 $9,530.00 $28,590.00 8 9999.0001 Connect to Existing Storm Drain Manhole 00 00 00 EA 1 $2,650.00 $2,650.00 TOTAL UNIT III: DRAINAGE IMPROVEMENTS $349,822.00 UNIT IV: PAVING IMPROVEMENTS 1 0241.0100 Remove Sidewalk 02 41 13 SF 2,221 $5.00 $11,105.00 2 0241.0300 Remove ADA Ramp 02 41 13 EA 3 $866.00 $2,598.00 3 0241.1100 Remove Asphalt Pavement 02 41 15 SY 203 $71.00 $14,413.00 4 0241.1300 Remove Concrete Curb & Gutter 02 41 15 LF 325 $37.00 $12,025.00 5 0241.1000 Remove Conc Pvmt 02 41 15 SY 50 $74.00 $3,700.00 6 3213.0102 7" Conc Pvmt 32 13 13 SY 129 $315.00 $40,635.00 7 3213.0301 4" Conc Sidewalk 32 13 20 SF 2,515 $16.00 $40,240.00 8 3213.0402 7" Concrete Driveway 32 13 20 SF 2,616 $19.00 $49,704.00 9 3213.0501 Barrier Free Ramp, Type R-1 32 13 20 EA 1 $3,715.00 $3,715.00 10 3213.0506 Barrier Free Ramp, Type P-1 32 13 20 EA 2 $3,550.00 $7,100.00 11 3216.0101 6" Conc Curb and Gutter 32 16 13 LF 153 $57.00 $8,721.00 12 3441.4006 Install Alum Sign Ground Mount 34 41 30 EA 3 $975.00 $2,925.00 13 9999.0002 Pavement Markings 32 17 23 LS 1 $4,400.00 $4,400.00 14 9999.0003 1' Wide Asphalt Pvmnt Repair, Arterial 32 01 17 LF 378 $35.00 $13,230.00 TOTAL UNIT IV: PAVING IMPROVEMENTS $214,511.00 Bid Summary UNIT III: DRAINAGE IMPROVEMENTS $349,822.00 UNIT IV: PAVING IMPROVEMENTS $214,511.00 Total Construction Bid $564,333.00 Contractor agrees to complete WORK for FINAL ACCEPTANCE within 115 calendar days after the date when the CONTRACT commences to run as provided in the General Conditions. END OF SECTION 00 45 11 - 1 BIDDERS PREQUALIFICATIONS Page 1 of 3 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS City Project No. 102109 Revised April 2, 2014 SECTION 00 45 11 BIDDERS PREQUALIFICATIONS 1. Summary. All contractors are required to be prequalified by the City prior to submitting bids. To be eligible to bid the contractor must submit Section 00 45 12, Prequalification Statement for the work type(s) listed with their Bid. Any contractor or subcontractor who is not prequalified for the work type(s) listed must submit Section 00 45 13, Bidder Prequalification Application in accordance with the requirements below. The prequalification process will establish a bid limit based on a technical evaluation and financial analysis of the contractor. The information must be submitted seven (7) days prior to the date of the opening of bids. For example, a contractor wishing to submit bids on projects to be opened on the 7th of April must file the information by the 31st day of March in order to bid on these projects. In order to expedite and facilitate the approval of a Bidder’s Prequalification Application, the following must accompany the submission. a. A complete set of audited or reviewed financial statements. (1) Classified Balance Sheet (2) Income Statement (3) Statement of Cash Flows (4) Statement of Retained Earnings (5) Notes to the Financial Statements, if any b. A certified copy of the firm’s organizational documents (Corporate Charter, Articles of Incorporation, Articles of Organization, Certificate of Formation, LLC Regulations, Certificate of Limited Partnership Agreement). c. A completed Bidder Prequalification Application. (1) The firm’s Texas Taxpayer Identification Number as issued by the Texas Comptroller of Public Accounts. To obtain a Texas Taxpayer Identification number visit the Texas Comptroller of Public Accounts online at the following web address www.window.state.tx.us/taxpermit/ and fill out the application to apply for your Texas tax ID. (2) The firm’s e-mail address and fax number. (3) The firm’s DUNS number as issued by Dun & Bradstreet. This number is used by the City for required reporting on Federal Aid projects. The DUNS number may be obtained at www.dnb.com. d. Resumes reflecting the construction experience of the principles of the firm for firms submitting their initial prequalification. These resumes should include the size and scope of the work performed. e. Other information as requested by the City. 2. Prequalification Requirements a.Financial Statements. Financial statement submission must be provided in accordance with the following: (1) The City requires that the original Financial Statement or a certified copy be submitted for consideration. 00 45 11 - 2 BIDDERS PREQUALIFICATIONS Page 2 of 3 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS City Project No. 102109 Revised April 2, 2014 (2) To be satisfactory, the financial statements must be audited or reviewed by an independent, certified public accounting firm registered and in good standing in any state. Current Texas statues also require that accounting firms performing audits or reviews on business entities within the State of Texas be properly licensed or registered with the Texas State Board of Public Accountancy. (3) The accounting firm should state in the audit report or review whether the contractor is an individual, corporation, or limited liability company. (4) Financial Statements must be presented in U.S. dollars at the current rate of exchange of the Balance Sheet date. (5) The City will not recognize any certified public accountant as independent who is not, in fact, independent. (6) The accountant’s opinion on the financial statements of the contracting company should state that the audit or review has been conducted in accordance with auditing standards generally accepted in the United States of America. This must be stated in the accounting firm’s opinion. It should: (1) express an unqualified opinion, or (2) express a qualified opinion on the statements taken as a whole. (7) The City reserves the right to require a new statement at any time. (8) The financial statement must be prepared as of the last day of any month, not more than one year old and must be on file with the City 16 months thereafter, in accordance with Paragraph 1. (9) The City will determine a contractor’s bidding capacity for the purposes of awarding contracts. Bidding capacity is determined by multiplying the positive net working capital (working capital = current assets – current liabilities) by a factor of 10. Only those statements reflecting a positive net working capital position will be considered satisfactory for prequalification purposes. (10) In the case that a bidding date falls within the time a new financial statement is being prepared, the previous statement shall be updated with proper verification. b.Bidder Prequalification Application. A Bidder Prequalification Application must be submitted along with audited or reviewed financial statements by firms wishing to be eligible to bid on all classes of construction and maintenance projects. Incomplete Applications will be rejected. (1) In those schedules where there is nothing to report, the notation of “None” or “N/A” should be inserted. (2) A minimum of five (5) references of related work must be provided. (3) Submission of an equipment schedule which indicates equipment under the control of the Contractor and which is related to the type of work for which the Contactor is seeking prequalification. The schedule must include the manufacturer, model and general common description of each piece of equipment. Abbreviations or means of describing equipment other than provided above will not be accepted. 3. Eligibility to Bid a. The City shall be the sole judge as to a contractor’s prequalification. b. The City may reject, suspend, or modify any prequalification for failure by the contractor to demonstrate acceptable financial ability or performance. c. The City will issue a letter as to the status of the prequalification approval. 00 45 11 - 3 BIDDERS PREQUALIFICATIONS Page 3 of 3 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS City Project No. 102109 Revised April 2, 2014 d. If a contractor has a valid prequalification letter, the contractor will be eligible to bid the prequalified work types until the expiration date stated in the letter. END OF SECTION 0045 12 DAP PREQUALIFICATION STATEMENT Page I of 1 SECTION 00 45 12 DAP PREQUALIFICATION STATEMENT Each Bidder is required to complete the information below by identifying the prequalified contractors and/or subcontractors whom they intend to utilize for the major work type(s) listed. In the "Major Work Type" box provide the complete maior work type and actual description as provided by the Water Department for water and sewer and TPW for paving_ Major Work Type Contractor 'Subcontractor Company Name Prequalification Expiration Date Drainage Improvements Fort Worth Civil Constructors, LLC 04/30/2020 The undersigned hereby certifies that the contractors and/or subcontractors described in the table above are currently prequalified for the work types listed. BIDDER: Fort Worth Civil Constructors, LLC BY: 1=7 AUs ' I mbaugh 4860 Mark IV Parkway Fort Worth, Texas 76106 n TITLE: kxx�beo gXX Pre ent DATE: 0 3/�z�zoZo END OF SECTION CITY OF FORT WORTH TH Harris Hosp. F7'W STANDARD CONSTRUCTION PREQUALIFICATION STATEMENT — DEVELOPER AWARDED PROJECTS CITY PROJECT NO. 102109 Revised September 1, 2015 SECTION 00 45 13 BIDDER PREQUALIFICATION APPLICATION Date of Balance Sheet , Mark only one: Individual Limited Partnership General Partnership Corporation Limited Liability Company Post Office Box City State Zip Code Street Address (required) City State Zip Code ( ) ( ) Telephone Fax Email Texas Taxpayer Identification No. Federal Employers Identification No. DUNS No. (if applicable) MAIL THIS QUESTIONAIRE ALONG WITH FINANCIAL STATEMENTS TO: CITY OF FORT WORTH TEXAS 1000 THROCKMORTON STREET FORT WORTH, TEXAS 76102-6311 AND MARK THE ENVELOPE: “BIDDER PREQUALIFICATION APPLICATION” Name under which you wish to qualify 00 45 13 - 2 BIDDER PREQUALIFICATION APPLICATION Page 2 of 8 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS City Project No. 102109 Revised December 20, 2012 BUSINESS CLASSIFICATION The following should be completed in order that we may properly classify your firm: (Check the block(s) which are applicable – Block 3 is to be left blank if Block 1 and/or Block 2 is checked) Has fewer than 100 employees and/or Has less than $6,000,000.00 in annual gross receipts OR Does not meet the criteria for being designated a small business as provided in Section 2006.001 of the Texas Government Code. The classification of your firm as a small or large business is not a factor in determining eligibility to become prequalified. MAJOR WORK CATEGORIES Water Department Augur Boring - 24-inch diameter casing and less Augur Boring - Greater than 24-inch diameter casing and greater Tunneling – 36-Inches – 60 –inches, and 350 LF or less Tunneling - 36-Inches – 60 –inches, and greater than 350 LF Tunneling – 66” and greater, 350 LF and greater Tunneling – 66” and greater, 350 LF or Less Cathodic Protection Water Distribution, Development, 8-inch diameter and smaller Water Distribution, Urban and Renewal, 8-inch diameter and smaller Water Distribution, Development, 12-inch diameter and smaller Water Distribution, Urban and Renewal, 12-inch diameter and smaller Water Transmission, Development, 24-inches and smaller Water Transmission, Urban/Renewal, 24-inches and smaller Water Transmission, Development, 42-inches and smaller Water Transmission, Urban/Renewal, 42-inches and smaller Water Transmission, Development, All Sizes Water Transmission, Urban/Renewal, All Sizes Sewer Bypass Pumping, 18-inches and smaller Sewer Bypass Pumping, 18-inches – 36-inches Sewer Bypass Pumping 42-inches and larger CCTV, 8-inches and smaller CCTV, 12-inches and smaller CCTV, 18-inches and smaller CCTV, 24-inches and smaller CCTV, 42-inches and smaller CCTV, 48-inches and smaller 00 45 13 - 3 BIDDER PREQUALIFICATION APPLICATION Page 3 of 8 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS City Project No. 102109 Revised December 20, 2012 MAJOR WORK CATEGORIES, CONTINUED Sewer CIPP, 12-inches and smaller Sewer CIPP, 24-inches and smaller Sewer CIPP, 42-inches and smaller Sewer CIPP, All Sizes Sewer Collection System, Development, 8-inches and smaller Sewer Collection System, Urban/Renewal, 8-inches and smaller Sewer Collection System, Development, 12-inches and smaller Sewer Collection System, Urban/Renewal, 12-inches and smaller Sewer Interceptors, Development, 24-inches and smaller Sewer Interceptors, Urban/Renewal, 24-inches and smaller Sewer Interceptors, Development, 42-inches and smaller Sewer Interceptors, Urban/Renewal, 42-inches and smaller Sewer Interceptors, Development, 48-inches and smaller Sewer Interceptors, Urban/Renewal, 48-inches and smaller Sewer Pipe Enlargement 12-inches and smaller Sewer Pipe Enlargement 24-inches and smaller Sewer Pipe Enlargement, All Sizes Sewer Cleaning , 24-inches and smaller Sewer Cleaning , 42-inches and smaller Sewer Cleaning , All Sizes Sewer Cleaning, 8-inches and smaller Sewer Cleaning, 12-inches and smaller Sewer Siphons 12-inches or less Sewer Siphons 24-inches or less Sewer Siphons 42-inches or less Sewer Siphons All Sizes Transportation Public Works Asphalt Paving Construction/Reconstruction (LESS THAN 15,000 square yards) Asphalt Paving Construction/Reconstruction (15,000 square yards and GREATER) Asphalt Paving Heavy Maintenance (UNDER $1,000,000) Asphalt Paving Heavy Maintenance ($1,000,000 and OVER) Concrete Paving Construction/Reconstruction (LESS THAN 15,000 square yards) Concrete Paving Construction/Reconstruction (15,000 square yards and GREATER) Roadway and Pedestrian Lighting 00 45 13 - 4 BIDDER PREQUALIFICATION APPLICATION Page 4 of 8 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS City Project No. 102109 Revised December 20, 2012 1. List equipment you do not own but which is available by renting DESCRIPTION OF EQUIPMENT NAME AND DETAILED ADDRESS OF OWNER 2. How many years has your organization been in business as a general contractor under your present name? List previous business names: 3. How many years of experience in construction work has your organization had: (a) As a General Contractor: (b) As a Sub-Contractor: 4. *What projects has your organization completed in Texas and elsewhere? CONTRACT AMOUNT CLASS OF WORK DATE COMPLETED LOCATION CITY-COUNTY- STATE NAME AND DETAILED ADDRESS OF OFFICIAL TO WHOM YOU REFER *If requalifying only show work performed since last statement. 5.Have you ever failed to complete any work awarded to you? If so, where and why? 6.Has any officer or owner of your organization ever been an officer of another organization that failed to complete a contract? If so, state the name of the individual, other organization and reason. 7.Has any officer or owner of your organization ever failed to complete a contract executed in his/her name? If so, state the name of the individual, name of owner and reason. 00 45 13 - 5 BIDDER PREQUALIFICATION APPLICATION Page 5 of 8 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS City Project No. 102109 Revised December 20, 2012 8. In what other lines of business are you financially interested? 9. Have you ever performed any work for the City? If so, when and to whom do you refer? 10. State names and detailed addresses of all producers from whom you have purchased principal materials during the last three years. NAME OF FIRM OR COMPANY DETAILED ADDRESS 11. Give the names of any affiliates or relatives currently debarred by the City. Indicate your relationship to this person or firm. 12. What is the construction experience of the principal individuals in your organization? NAME PRESENT POSITION OR OFFICE YEARS OF EXPERIENCE MAGNITUDE AND TYPE OF WORK IN WHAT CAPACITY 13. If any owner, officer, director, or stockholder of your firm is an employee of the City, or shares the same household with a City employee, please list the name of the City employee and the relationship. In addition, list any City employee who is the spouse, child, or parent of an owner, officer, stockholder, or director who does not live in the same household but who receives care and assistance from that person as a direct result of a documented medical condition. This includes foster children or those related by adoption or marriage. 00 45 13 - 6 BIDDER PREQUALIFICATION APPLICATION Page 6 of 8 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS City Project No. 102109 Revised December 20, 2012 CORPORATION BLOCK PARTNERSHIP BLOCK If a corporation:If a partnership: Date of Incorporation State of Organization Charter/File No.Date of organization President Is partnership general, limited, or registered limited liability partnership? Vice Presidents File No. (if Limited Partnership) General Partners/Officers Secretary Limited Partners (if applicable) Treasurer LIMITED LIABILITY COMPANY BLOCK If a corporation: State of Incorporation Date of organization File No.Individuals authorized to sign for Partnership Officers or Managers (with titles, if any) Except for limited partners, the individuals listed in the blocks above are presumed to have full signature authority for your firm unless otherwise advised. Should you wish to grant signature authority for additional individuals, please attach a certified copy of the corporate resolution, corporate minutes, partnership agreement, power of attorney or other legal documentation which grants this authority. 00 45 13 - 7 BIDDER PREQUALIFICATION APPLICATION Page 7 of 8 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS City Project No. 102109 Revised December 20, 2012 14. Equipment $_______________ TOTAL ITEM QUANTITY ITEM DESCRIPTION BALANCE SHEET VALUE 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 Various- TOTAL Similar types of equipment may be lumped together. If your firm has more than 30 types of equipment, you may show these 30 types and show the remainder as "various". The City, by allowing you to show only 30 types of equipment, reserves the right to request a complete, detailed list of all your equipment. The equipment list is a representation of equipment under the control of the firm and which is related to the type of work for which the firm is seeking qualification. In the description include, the manufacturer, model, and general common description of each. 00 45 13 - 8 BIDDER PREQUALIFICATION APPLICATION Page 8 of 8 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS City Project No. 102109 Revised December 20, 2012 BIDDER PREQUALIFICATION AFFIDAVIT STATE OF COUNTY OF The undersigned hereby declares that the foregoing is a true statement of the financial condition of the entity herein first named, as of the date herein first given; that this statement is for the express purpose of inducing the party to whom it is submitted to award the submitter a contract; and that the accountant who prepared the balance sheet accompanying this report as well as any depository, vendor or any other agency herein named is hereby authorized to supply each party with any information, while this statement is in force, necessary to verify said statement. _______________________________________________, being duly sworn, deposes and says that he/she is the __________________________________ of ___________________________, the entity described in and which executed the foregoing statement that he/she is familiar with the books of the said entity showing its financial condition; that the foregoing financial statement taken from the books of the said entity as of the date thereof and that the answers to the questions of the foregoing Bidder Prequalification Application are correct and true as of the date of this affidavit. Firm Name: Signature: Sworn to before me this day of , Notary Public Notary Public must not be an officer, director, or stockholder or relative thereof. 00 45 26 - 1 CONTRACTOR COMPLIANCE WITH WORKER'S COMPENSATION LAW Page I of 1 SECTION 00 45 26 CONTRACTOR COMPLIANCE WITH WORKER'S COMPENSATION LAW Pursuant to Texas Labor Code Section 406.096(a), as amended, Contractor certifies that it provides worker's compensation insurance coverage for all of its employees employed on City Project No. 102109. Contractor further certifies that, pursuant to Texas Labor Code, Section 406.096(b), as amended, it will provide to City its subcontractor's certificates of compliance with worker's compensation coverage. CONTRACTOR: Fort Worth Civil Constructors, LLC Company 4860 Mark IV Parkway Address Fort Worth, Texas 76106 City/State/Zip THE STATE OF TEXAS COUNTY OF TARRANT By: ;XgN tgK� Austin Alumbaugh (Please,Print) Signature: Title: kxxxxicveadmgm President (Please Print) BEFORE ME, the undersigned authority, on this day personally appeared Austin A1umbaugh;X9NLGWgh9VtK_ , known to me to be the person whose name is subscribed to the foregoing instrument, and acknowledged to me that he she executed the same as the act and deed of Fort Worth Civil Constructors, LLC for the purposes and consideration therein expressed and in the capacity therein stated. N UNDER MY HAND AND SEAL OF OFFICE this r 1 _ day of 2( ,o - ,a���w, MANDI EVEN Y PLe��� Notary Public, State of Texas -Comm. Expires 08-28 2022 ublic in and for the State of Texas 11";Q r .,`.'�t�;\ Notary ID 12431710 4 END OF SECTION CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS City Project No. 102109 Revised April 2. 2014 00 52 43 - 1 Developer Awarded Project Agreement Page 1 of 4 SECTION 00 52 43 AGREEMENT THIS AGREEMENT, authorized on / 11Zire-,h 12, 1-010 is made by and between the Developer, Texas Health Resources , authorized to do business in Texas ("Developer"), and Fort Worth Civil Constructors, LLC, authorized to do business in Texas, acting by and through its duly authorized representative, ("Contractor"). Developer and Contractor, in consideration of the mutual covenants hereinafter set forth, agree as follows: Article 1. WORK Contractor shall complete all Work as specified or indicated in the Contract Documents for the Project identified herein. Article 2. PROJECT The project for which the Work under the Contract Documents may be the whole or only a part is generally described as follows: Drainage Improvements to Serve: Texas Health Resources New Patient Tower City Proiect No. 102109 Article 3. CONTRACT TIME 3.1 Time is of the essence. All time limits for Milestones, if any, and Final Acceptance as stated in the Contract Documents are of the essence to this Contract. 3.2 Final Acceptance. The Work will be complete for Final Acceptance within 115 calendar days after the date when the Contract Time commences to run as provided in Paragraph 12.04 of the Standard City Conditions of the Construction Contract for Developer Awarded Projects. 3.3 Liquidated damages Contractor recognizes that time is of the essence of this Agreement and that Developer will suffer financial loss if the Work is not completed within the times specified in Paragraph 3.2 above, plus any extension thereof allowed in accordance with Article 10 of the Standard City Conditions of the Construction Contract for Developer Awarded Projects. The Contractor also recognizes the delays, expense and difficulties involved in proving in a legal proceeding the actual loss suffered by the Developer if the Work is not completed on time. Accordingly, instead of requiring any such proof, Contractor agrees that as liquidated damages for delay (but not as a penalty), Contractor shall pay Developer Five Hundred Dollars ($ 500.00 ) for each day that expires after the time specified in Paragraph 3.2 for Final Acceptance until the City issues the Final Letter of Acceptance. CITY OF FORT WORTH TH Hams Hosp. F-TFf' STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 102109 Revised June 16, 2016 005243-2 Developer Awarded Project Agreement Page 2 of 4 Article 4. CONTRACT PRICE Developer agrees to pay Contractor for performance of the Work in accordance with the Contract Documents an amount in current funds of Five Hundred Sixty -Four Thousand Three Hundred Thirty Three and no. 100 ($564,333.00). Article 5. CONTRACT DOCUMENTS 5.1 CONTENTS: A. The Contract Documents which comprise the entire agreement between Developer and Contractor concerning the Work consist of the following: 1. This Agreement. 2. Attachments to this Agreement: a. Bid Form (As provided by Developer) 1) Proposal Form (DAP Version) 2) Prequalification Statement 3) State and Federal documents (project specific) b. Insurance ACORD Form(s) c. Payment Bond (DAP Version) d. Performance Bond (DAP Version) e. Maintenance Bond (DAP Version) f. Power of Attorney for the Bonds g. Worker's Compensation Affidavit h. MBE and/or SBE Commitment Form (If required) 3. Standard City General Conditions of the Construction Contract for Developer Awarded Projects. 4. Supplementary Conditions. 5. Specifications specifically made a part of the Contract Documents by attachment or, if not attached, as incorporated by reference and described in the Table of Contents of the Project's Contract Documents. 6. Drawings. 7. Addenda. 8. Documentation submitted by Contractor prior to Notice of Award. 9. The following which may be delivered or issued after the Effective Date of the Agreement and, if issued, become an incorporated part of the Contract Documents: a. Notice to Proceed. b. Field Orders. c. Change Orders. d. Letter of Final Acceptance. CITY OF FORT WORTH THHarris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS - DEVELOPER AWARDED PROJECTS City Project No. 102109 Revised June 16, 2016 005243-3 Developer Awarded Project Agreement Page 3 of 4 Article 6. INDEMNIFICATION 6.1 Contractor covenants and agrees to indemnify, hold harmless and defend, at its own expense, the city, its officers, servants and employees, from and against any and all claims arising out of, or alleged to arise out of, the work and services to be performed by the contractor, its officers, agents, employees, subcontractors, licenses or invitees under this contract. This indemnification provision is specifically intended to operate and be effective even if it is alleged or proven that all or some of the damages being sought were caused, in whole or in part, by any act, omission or negligence of the city. This indemnity provision is intended to include, without limitation, indemnity for costs, expenses and legal fees incurred by the city in defending against such claims and causes of actions. 6.2 Contractor covenants and agrees to indemnify and hold harmless, at its own expense, the city, its officers, servants and employees, from and against any and all loss, damage or destruction of property of the city, arising out of, or alleged to arise out of, the work and services to be performed by the contractor, its officers, agents, employees, subcontractors, licensees or invitees under this contract. This indemnification provision is specifically intended to operate and be effective even if it is alleged or proven that all or some of the damages being sought were caused, in whole or in part by any act, omission or negligence of the city. Article 7. MISCELLANEOUS 7.1 Terms. Terms used in this Agreement are defined in Article 1 of the Standard City Conditions of the Construction Contract for Developer Awarded Projects. 7.2 Assignment of Contract. This Agreement, including all of the Contract Documents may not be assigned by the Contractor without the advanced express written consent of the Developer. 7.3 Successors and Assigns. Developer and Contractor each binds itself, its partners, successors, assigns and legal representatives to the other party hereto, in respect to all covenants, agreements and obligations contained in the Contract Documents. 7.4 Severability. Any provision or part of the Contract Documents held to be unconstitutional, void or unenforceable by a court of competent jurisdiction shall be deemed stricken, and all remaining provisions shall continue to be valid and binding upon DEVELOPER and CONTRACTOR. 7.5 Governing Law and Venue. This Agreement, including all of the Contract Documents is performable in the State of Texas. Venue shall be Tarrant County, Texas, or the United States District Court for the Northern District of Texas, Fort Worth Division. CITY OF FORT WORTH rH Harris Hosp. MV STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS DEVELOPER AWARDED PROJECTS City Project No. 102109 Revised June 16, 2016 005243-4 Developer Awarded Project Agreement Page 4 of 4 7.6 Authority to Sign. Contractor shall attach evidence of authority to sign Agreement, if other than duly authorized signatory of the Contractor. IN WITNESS WHEREOF, Developer and Contractor have executed this Agreement in multiple counterparts. This Agreement is effective as of the last date signed by the Parties ("Effective Date"). Contractor: Developer: Fort Worth Civil Constructors, LLC Texas Health B B (Signature) ignature) pagxkkwAx cch Austin Alumbaugh Brian Holmes (Printed Name) (Printed Name) Title: yxxmAvo&j=xxmx President Title: Senior Vice President Company Name: Company Name: Fort Worth Civil Constructors, LLC Texas Health Resources Address: Address: 4860 Mark IV Pkwy. 251 Westpark Way, Suite 200 76106 �Cyity/State'Zip: Fort Worth, Tx. 70M City State'Zip: Euless, Tx 76040 y A rC%1 I Z., Z a Z. b M 2,1 Date Date CITY OF FORT WORTH TH Harris Hasp. FT Y STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS - DEVELOPER AWARDED PROJECTS City Project No. 102109 Revised June 16,2016 0062 13- 1 PERFORMANCE BOND Page 1 of 2 SECTION 00 62 13 PERFORMANCE BOND Bond #SUR0058777 THE STATE OF TEXAS § § KNOW ALL BY THESE PRESENTS: COUNTY OF TARRANT § That we, _Fort Worth Civil Constructors. LLC_, known as "Principal' herein and Argonaut Insurance Company , a corporate surety (sureties, if more than one) duly authorized to do business in the State of Texas, known as "Surety" herein (whether one or more), are held and firmly bound unto the Developer, Texas Health Resources , authorized to do business in Texas ("Developer") and the City of Fort Worth, a Texas municipal corporation ("City"), in the penal sum of, Five Hundred Sixty -Four Thousand Three Hundred Thirty Three and no/100 ($564,333.00), lawful money of the United States, to be paid in Fort Worth, Tarrant County, Texas for the payment of which sum well and truly to be made jointly unto the Developer and the City as dual obligees, we bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, Developer and City have entered into an Agreement for the construction of community facilities in the City of Fort Worth by and through a Community Facilities Agreement, CFA Number 19-0053, and WHEREAS, the Principal has entered into a certain written contract with the Developer awarded the I �— day of n?A r C,, 20 Z_C� which Contract is hereby referred to and made a part hereof for all purposes as if fully set forth herein, to furnish all materials, equipment labor and other accessories defined by law, in the prosecution of the Work, including any Change Orders, as provided for in said Contract designated as Drainage Improvements to serve Texas Health Resources New Patient Tower. NOW, THEREFORE, the condition of this obligation is such that if the said Principal shall faithfully perform it obligations under the Contract and shall in all respects duly and faithfully perform the Work, including Change Orders, under the Contract, according to the plans, specifications, and contract documents therein referred to, and as well during any period of extension of the Contract that may be granted on the part of the Developer and/or City, then this obligation shall be and become null and void, otherwise to remain in full force and effect. CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CITY CONDITIONS - DEVELOPER AWARDED PROJECTS City Project No. /02109 Revised January 31, 2012 006213-2 PERFORMANCE BOND Page 2 of 2 PROVIDED FURTHER, that if any legal action be filed on this Bond, venue shall lie in Tarrant County, Texas or the United States District Court for the Northern District of Texas, Fort Worth Division. This bond is made and executed in compliance with the provisions of Chapter 2253 of the Texas Government Code, as amended, and all liabilities on this bond shall be determined in accordance with the provisions of said statue. IN WITNESS WHEREOF, the Principal and the Surety have SIGNED and SEALED this instrument by duly authorized agents and officers on this the 2- day of 20 Z.Q ATTEST: (Principal) Secretary kto fitnessas Principal (h �AA�� Wi ess as to urety PRINCIPAL: Fort Worth Civil Constructors LLC BY: Signature Austin Alumbauah, President Name and Title Address: 4860 Mark IV Parkway Fort Worth, Texas 76106 SURETY: Argonaut insurance Company BY: -� ignature Linda Michelle Stalder, Attorney -in -Fact Name and Title Address: 13100 Wortham Center Drive Suite 290 Houston. TX 77065 Telephone Number: 800470-7958 *Note: If signed by an officer of the Surety Company, there must be on file a certified extract from the by-laws showing that this person has authority to sign such obligation. If Surety's physical address is different from its mailing address, both must be provided. The date of the bond shall not be prior to the date the Contract is awarded. CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CITY CONDITIONS - DEVELOPER AWARDED PROJECTS Cite Project No. 102/09 Revised January 31, 2012 SECTION 00 62 14 PAYMENT BOND 006214.1 PAYMENT BOND Page 1 of 2 Bond #SUR0058777 THE STATE OF TEXAS § § KNOW ALL BY THESE PRESENTS: COUNTY OF TARRANT § That we, Fort Worth Civil Constructors. LLC , known as "Principal' herein, and Argonaut Insurance Company a corporate surety ( or sureties if more than one), duly authorized to do business in the State of Texas, known as "Surety" herein (whether one or more), are held and finely bound unto the Developer, Texas Health Resources , authorized to do business in Texas "(Developer"), and the City of Fort Worth, a Texas municipal corporation ("City"), in the penal sum of Five Hundred Sixty -Four Thousand Three Hundred Thirty Three and no/100 ($564,333.00), lawful money of the United States, to be paid in Fort Worth, Tarrant County, Texas, for the payment of which sum well and truly be made jointly unto the Developer and the City as dual obligees, we bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents: WHEREAS, Developer and City have entered into an Agreement for the construction of community facilities in the City of Fort Worth, by and through a Community Facilities Agreement, CFA Number 19-0053: and WHEREAS, Principal has entered into a certain written Contract with Developer, awarded the I ?- day of "OLV bil1 , 20 2D , which Contract is hereby referred to and made a part hereof for all purposes as if fully set forth herein, to furnish all materials, equipment, labor and other accessories as defined by law, in the prosecution of the Work as provided for in said Contract and designated as Drainage Improvements to serve Texas Health Resources New Patient Tower. NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION is such that if Principal shall pay all monies owing to any (and all) payment bond beneficiary (as defined in Chapter 2253 of the Texas Government Code, as amended) in the prosecution of the Work under the Contract, then this obligation shall be and become null and void; otherwise to remain in full force and effect. CITY OF FORT WORTH STANDARD CITY CONDITIONS - DEVELOPER AWARDED PROJECTS Revised January 31, 2012 TH Harris Hosp. FTW Cuy Project No. 102109 006214-2 PAYMENT BOND Page 2 of 2 This bond is made and executed in compliance with the provisions of Chapter 2253 of the Texas Government Code, as amended, and all liabilities on this bond shall be determined in accordance with the provisions of said statute. IN WITNESS WHEREOF, the Principal and Surety have each SIGNED and SEALED this instrument by duly authorized agents and officers on this the ��� day of 20 Z,D . ATTEST: (Principal) Secretary ss as to Principal PRINCIPAL: Fort Worth Civil Constructors.J-LC BY: ' Signature Austin Alumbaugh, President Name and Title Address: _ 4860 Mark IV Parkway Fort Worth, Texas 76106W SURETY: Argonaut Insurance Company ATTEST: BY: 14 Si ature Linda Michelle Stalder, Attorne -in-Fact (Surety) Secretary Name and Title II { !2 Witness as to Surety Address: 13100 Wortham Center Drive Suite 290 Houston, TX 77065 Telephone Number: 800470-7958 Note: If signed by an officer of the Surety, there must be on file a certified extract from the bylaws showing that this person has authority to sign such obligation. If Surety's physical address is different from its mailing address, both must be provided. The date of the bond shall not be prior to the date the Contract is awarded. END OF SECTION CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CITY CONDITIONS DEVELOPER AWARDED PROJECTS City Project No. 102109 Revised January 31, 2012 006219-1 MAINTENANCE BOND Page 1 of 3 SECTION 00 62 19 MAINTENANCE BOND Bond #SUR0058777 THE STATE OF TEXAS § § KNOW ALL BY THESE PRESENTS: COUNTY OF TARRANT § That we Fort Worth Civil Constructors, LLC , known as "Principal' herein and Argonaut Insurance Company , a corporate surety (sureties, if more than one) duly authorized,to do business in the State of Texas, known as "Surety" herein (whether one or more), are held and firmly bound unto the Developer, Texas Health Resources , authorized to do business in Texas ("Developer") and the City of Fort Worth, a Texas municipal corporation ("City"), in the sum of Five Hundred Sixty -Four Thousand Three Hundred Thirty Three and no/100 ($564,333.00), lawful money of the United States, to be paid in Fort Worth, Tarrant County, Texas, for payment of which sum well and truly be made jointly unto the Developer and the City as dual obligees and their successors, we bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, Developer and City have entered into an Agreement for the construction of community facilities in the City of Fort Worth by and through a Community Facilities Agreement, CFA Number 19-0053; and WHEREAS, the Principal has entered into a certain written contract with the Developer awarded the day of 9M �( r 6h , 20 1b , which Contract is hereby referred to and a made part hereof for all purposes as if fully set forth herein, to furnish all materials, equipment labor and other accessories as defined by law, in the prosecution of the Work, including any Work resulting from a duly authorized Change Order (collectively herein, the "Work") as provided for in said Contract and designated as Drainage bnprovements to serve Texas Health Resource New Patient Tower; and WHEREAS, Principal binds itself to use such materials and to so construct the Work in accordance with the plans, specifications and Contract Documents that the Work is and will remain free from defects in materials or workmanship for and during the period of two (2) years after the date of Final Acceptance of the Work by the City ("Maintenance Period"); and CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS City Project No. 102109 Revised January 31, 2012 006219-2 MAINTENANCE BOND Page 2 of 3 WHEREAS, Principal binds itself to repair or reconstruct the Work in whole or in part upon receiving notice from the Developer and/or City of the need thereof at any time within the Maintenance Period. NOW THEREFORE, the condition of this obligation is such that if Principal shall remedy any defective Work, for which timely notice was provided by Developer or City, to a completion satisfactory to the City, then this obligation shall become null and void; otherwise to remain in full force and effect. PROVIDED, HOWEVER, if Principal shall fail so to repair or reconstruct any timely noticed defective Work, it is agreed that the Developer or City may cause any and all such defective Work to be repaired and/or reconstructed with all associated costs thereof being borne by the Principal and the Surety under this Maintenance Bond; and PROVIDED FURTHER, that if any legal action be filed on this Bond, venue shall lie in Tarrant County, Texas or the United States District Court for the Northern District of Texas, Fort Worth Division; and PROVIDED FURTHER, that this obligation shall be continuous in nature and successive recoveries may be had hereon for successive breaches. CITY OF PORT WORTH TH Harris Hosp. FTW STANDARD CITY CONDITIONS DEVELOPER AWARDED PROJECTS City Project No. 102109 Revised January 31, 2012 006219-3 MAINTENANCE BOND Page 3 of 3 IN WITNESS WHEREOF, the Principal and the Surety have each SIGNED and SEALED this instrument by duly authorized agents and officers on this the �,�. day of I Iu ,2010. ATTEST: (Principal) Secretary nest as &tol'riZncipal Witness as to Surety PRINCIPAL: Fort Worth Civil Constructors LC BY: Signature Austin Alumbaugh, President Name and Title Address: 4860 Mark IV Parkway Fort Worth, Texas 76106 SURETY: Argonaut Insurance Company BY: ignature Linda Michelle Stalder, Attorney -in -Fact Name and Title Address: 13100 Wortham Center Drive Suite 290 Houston TX 77065 Telephone Number: 800470-7958 *Note: If signed by an officer of the Surety Company, there must be on file a certified extract from the by-laws showing that this person has authority to sign such obligation. If Surety's physical address is different from its mailing address, both must be provided. The date of the bond shall not be prior to the date the Contract is awarded. CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CITY CONDITIONS - DEVELOPER AWARDED PROJECTS City Project No. 102/09 Revised January 31, 2012 Argonaut Insurance Company Deliveries Only: 225 W. Washington, 24th Floor Chicago, IL 60606 United States Postal Service: P.O. Box 469011, San Antonio, TX 78246 POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS: That the Argonaut Insurance Company, a Corporation duly organized and existing under the laws of the State of Illinois and having its principal office in the County of Cook, Illinois does hereby nominate, constitute and appoint: Andrea Rose Crawford, Troy Russell Key. Debra Lee Moon, Sammy Joe Mullis Jr.. John William Newby. Sandra Lee Roney, Linda Michelle Stalder. Christopher Carl Sundbera Their true and lawful agent(s) and attorney(s)-in-fact, each in their separate capacity if more than one is named above, to make, execute, seal and deliver for and on its behalf as surety, and as its act and deed any and all bonds, contracts, agreements of indemnity and other undertakings in suretyship provided, however, that the penal sum of any one such instrument executed hereunder shall not exceed the sum of $50,000,000.00 This Power of Attomey is granted and is signed and sealed under and by the authority of the following Resolution adopted by the Board of Directors of Argonaut Insurance Company: "RESOLVED, That the President, Senior Vice President, Vice President, Assistant Vice President, Secretary, Treasurer and each of them hereby is authorized to execute powers of attorney. and such authority can be executed by use of facsimile signature, which may be attested or acknowledged by any officer or attorney, of the Company, qualifying the attorney or attorneys named in the given power of attomey, to execute in behalf of, and acknowledge as the act and deed of the Argonaut Insurance Company, all bond undertakings and contracts of suretyship, and to affix the corporate seal thereto." IN WITNESS WHEREOF, Argonaut Insurance Company has caused its official seal to be hereunto affixed and these presents to be signed by its duly authorized officer on the 8th day of May, 2017. URA ' °•SEAL f,: .> id.. ,saa : Y; by: ••'4 rNo1z .� STATE OF TEXAS COUNTY OF HARRIS SS: Argonaut Insurance Company Joshua C. Betz, Senior Vice President On this 8th day of May, 2017 A.D., before me, a Notary Public of the State of Texas, in and for the County of Hams, duly commissioned and qualified, came THE ABOVE OFFICER OF THE COMPANY, to me personally known to be the individual and officer described in, and who executed the preceding instrument, and he acknowledged the execution of same, and being by me duly sworn, deposed and said that he is the officer of the said Company aforesaid, and that the seal affixed to the preceding instrument is the Corporate Seal of said Company, and the said Corporate Seal and his signature as officer were duly affixed and subscribed to the said instrument by the authority and direction of the said corporation, and that Resolution adopted by the Board of Directors of said Company, referred to in the preceding instrument is now in force_ IN TESTIMONY WHEREOF, 1 have hereunto set my hand, and affixed my Official Seal at the County of Harris, the day and year first above written. P� KAI HLEEN h1 MtEKb b G Stnr« Uf Tox.e •n 07 15-7071 67902 9 (Notary Public) I, the undersigned Officer of the Argonaut Insurance Company, Illinois Corporation, do hereby certify that the original POWER OF ATTORNEY of which the foregoing is a full, true and correct copy is still in full force and effect and has not been revoked IN WITNESS WHEREOF, I have hereunto set my hand, and affixed the Seal of said Company, on the day of °' SEAL• �=—��-"`� �'�' i d': ,948 i 2t James Bluzard Vice President -Surety THIS DOCUMENT IS NOT VALID UNLESS THE WORDS ARGO POWER ARE IN BLUE. IF YOU HAVE QUESTIONS ON AUTHENTICITY OF THIS DOCUMENT CALL (210) 321 - 8400. IMPORTANT NOTICE To obtain information or make a complaint: You may call Argonaut Insurance Company and its affiliates by telephone for information or to make a complaint: ARGONAUT INSURANCE COMPANY Please send all notices of claim on this bond to: Argonaut Insurance Company Argo Surety Claims 225 W. Washington St., 24th Floor Chicago, IL 60606 (833) 820-9137 (toll -free) You may contact the Texas Department of Insurance to obtain information on companies, coverages, rights or complaints at: (512) 490-1007 You may write the Texas Department of Insurance: P. O. Box 149104 Austin, TX 78714-9104 Fax: (512) 475-1771 Web: http://www.tdi.state.tx.us E-mail: Cons umerProtection(cDtdi.state.tx.us PREMIUM OR CLAIM DISPUTES: Should you have a dispute concerning your premium or about a claim you should contact your agent or Argo Surety first. If the dispute is not resolved, you may contact the Texas Department of Insurance. ATTACH THIS NOTICE TO YOUR BOND: This notice is for information only and does not become a part or condition of the attached document and is given to comply with Texas legal and regulatory requirements. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. This document has important legal consequences; consultation with an attorney is encouraged with respect to its use or modification. This document should be adapted to the particular circumstances of the contemplated Project and the controlling Laws and Regulations. STANDARD GENERAL CONDITIONS OF THE CONSTRUCTION CONTRACT Prepared by ENGINEERS JOINT CONTRACT DOCUMENTS COMMITTEE and Issued and Published Jointly by AMERICAN COUNCIL OF ENGINEERING COMPANIES ASSOCIATED GENERAL CONTRACTORS OF AMERICA AMERICAN SOCIETY OF CIVIL ENGINEERS PROFESSIONAL ENGINEERS IN PRIVATE PRACTICE A Practice Division of the NATIONAL SOCIETY OF PROFESSIONAL ENGINEERS Endorsed by CONSTRUCTION SPECIFICATIONS INSTITUTE EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. These General Conditions have been prepared for use with the Suggested Forms of Agreement Between Owner and Contractor (EJCDC C-520 or C-525, 2007 Editions). Their provisions are interrelated and a change in one may necessitate a change in the other. Comments concerning their usage are contained in the Narrative Guide to the EJCDC Construction Documents (EJCDC C-001, 2007 Edition). For guidance in the preparation of Supplementary Conditions, see Guide to the Preparation of Supplementary Conditions (EJCDC C-800, 2007 Edition). Copyright © 2007 National Society of Professional Engineers 1420 King Street, Alexandria, VA 22314-2794 (703) 684-2882 www.nspe.org American Council of Engineering Companies 1015 15th Street N.W., Washington, DC 20005 (202) 347-7474 www.acec.org American Society of Civil Engineers 1801 Alexander Bell Drive, Reston, VA 20191-4400 (800) 548-2723 www.asce.org Associated General Contractors of America 2300 Wilson Boulevard, Suite 400, Arlington, VA 22201-3308 (703) 548-3118 www.agc.org The copyright for this EJCDC document is owned jointly by the four EJCDC sponsoring organizations and held in trust for their benefit by NSPE. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page i STANDARD GENERAL CONDITIONS OF THE CONSTRUCTION CONTRACT TABLE OF CONTENTS Page Article 1 – Definitions and Terminology............................................................................................................1 1.1 Defined Terms..........................................................................................................................1 1.2 Terminology....................................................................................................................................5 Article 2 – Preliminary Matters...........................................................................................................................6 2.1 Delivery of Bonds and Evidence of Insurance ..............................................................................6 2.2 Copies of Documents......................................................................................................................6 2.3 Commencement of Contract Times; Notice to Proceed................................................................6 2.4 Starting the Work............................................................................................................................7 2.5 Before Starting Construction..............................................................................................................7 2.6 Preconstruction Conference; Designation of Authorized Representatives.......................................7 2.7 Initial Acceptance of Schedules.....................................................................................................7 Article 3 – Contract Documents: Intent, Amending, Reuse..............................................................................8 3.1 Intent................................................................................................................................................8 3.2 Reference Standards...........................................................................................................................8 3.3 Reporting and Resolving Discrepancies........................................................................................8 3.4 Amending and Supplementing Contract Documents........................................................................9 3.5 Reuse of Documents.....................................................................................................................10 3.6 Electronic Data..............................................................................................................................10 Article 4 – Availability of Lands; Subsurface and Physical Conditions; Hazardous Environmental Conditions; Reference Points .....................................................................................................10 4.1 Availability of Lands....................................................................................................................10 4.2 Subsurface and Physical Conditions............................................................................................11 4.3 Differing Subsurface or Physical Conditions...............................................................................11 4.4 Underground Facilities.................................................................................................................13 4.5 Reference Points...........................................................................................................................14 4.6 Hazardous Environmental Condition at Site................................................................................14 Article 5 – Bonds and Insurance.......................................................................................................................16 5.1 Performance, Payment, and Other Bonds........................................................................................16 5.2 Licensed Sureties and Insurers.........................................................................................................16 5.3 Certificates of Insurance...................................................................................................................16 5.4 Contractor’s Insurance..................................................................................................................17 5.5 Owner’s Liability Insurance.........................................................................................................18 5.6 Property Insurance............................................................................................................................18 5.7 Waiver of Rights...........................................................................................................................20 5.8 Receipt and Application of Insurance Proceeds..........................................................................21 EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page ii 5.9 Acceptance of Bonds and Insurance; Option to Replace................................................................21 5.10 Partial Utilization, Acknowledgment of Property Insurer...........................................................21 Article 6 – Contractor’s Responsibilities..........................................................................................................22 6.1 Supervision and Superintendence....................................................................................................22 6.2 Labor; Working Hours .....................................................................................................................22 6.3 Services, Materials, and Equipment.................................................................................................22 6.4 Progress Schedule.............................................................................................................................23 6.5 Substitutes and “Or-Equals”.............................................................................................................23 6.6 Concerning Subcontractors, Suppliers, and Others.....................................................................25 6.7 Patent Fees and Royalties.................................................................................................................27 6.8 Permits...........................................................................................................................................27 6.9 Laws and Regulations.......................................................................................................................27 6.10 Taxes.............................................................................................................................................28 6.11Use of Site and Other Areas.............................................................................................................28 6.12Record Documents ...........................................................................................................................29 6.13Safety and Protection........................................................................................................................29 6.14Safety Representative.......................................................................................................................30 6.15Hazard Communication Programs..............................................................................................30 6.16 Emergencies..................................................................................................................................30 6.17Shop Drawings and Samples............................................................................................................30 6.18 Continuing the Work....................................................................................................................32 6.19Contractor’s General Warranty and Guarantee...............................................................................32 6.20 Indemnification.............................................................................................................................33 6.21Delegation of Professional Design Services....................................................................................34 Article 7 – Other Work at the Site.....................................................................................................................35 7.1 Related Work at Site.....................................................................................................................35 7.2 Coordination..................................................................................................................................35 7.3 Legal Relationships.......................................................................................................................36 Article 8 – Owner’s Responsibilities.................................................................................................................36 8.1 Communications to Contractor.....................................................................................................36 8.2 Replacement of Engineer..............................................................................................................36 8.3 Furnish Data..................................................................................................................................36 8.4 Pay When Due..............................................................................................................................36 8.5 Lands and Easements; Reports and Tests....................................................................................36 8.6 Insurance.......................................................................................................................................36 8.7 Change Orders ..............................................................................................................................36 8.8 Inspections, Tests, and Approvals................................................................................................37 8.9 Limitations on Owner’s Responsibilities.....................................................................................37 8.10 Undisclosed Hazardous Environmental Condition......................................................................37 8.11 Evidence of Financial Arrangements...........................................................................................37 8.12 Compliance with Safety Program ................................................................................................37 Article 9 – Engineer’s Status During Construction..........................................................................................37 9.01 Owner’s Representative................................................................................................................37 9.02 Visits to Site ................................................................................................................................ 37 EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page iii 9.3 Project Representative..................................................................................................................38 9.4 Authorized Variations in Work....................................................................................................38 9.5 Rejecting Defective Work................................................................................................................38 9.6 Shop Drawings, Change Orders and Payments...........................................................................38 9.7 Determinations for Unit Price Work............................................................................................39 9.8 Decisions on Requirements of Contract Documents and Acceptability of Work......................39 9.9 Limitations on Engineer’s Authority and Responsibilities..........................................................39 9.10 Compliance with Safety Program ................................................................................................40 Article 10 – Changes in the Work; Claims..................................................................................................40 10.1 Authorized Changes in the Work.................................................................................................40 10.2 Unauthorized Changes in the Work.............................................................................................40 10.3 Execution of Change Orders ........................................................................................................41 10.4 Notification to Surety.....................................................................................................................41 10.5 Claims.....................................................................................................................................41 Article 11 – Cost of the Work; Allowances; Unit Price Work.........................................................................42 11.1 Cost of the Work...........................................................................................................................42 11.2 Allowances....................................................................................................................................45 11.3 Unit Price Work............................................................................................................................45 Article 12 – Change of Contract Price; Change of Contract Times.................................................................46 12.1 Change of Contract Price..............................................................................................................46 12.2 Change of Contract Times............................................................................................................47 12.3 Delays............................................................................................................................................47 Article 13 – Tests and Inspections; Correction, Removal or Acceptance of Defective Work........................48 13.1 Notice of Defects............................................................................................................................48 13.2 Access to Work...............................................................................................................................48 13.3 Tests and Inspections......................................................................................................................48 13.4 Uncovering Work...........................................................................................................................49 13.5 Owner May Stop the Work...........................................................................................................50 13.6 Correction or Removal of Defective Work....................................................................................50 13.7 Correction Period............................................................................................................................50 13.8 Acceptance of Defective Work......................................................................................................51 13.9 Owner May Correct Defective Work.............................................................................................51 Article 14 – Payments to Contractor and Completion......................................................................................52 14.1 Schedule of Values.......................................................................................................................52 14.2 Progress Payments........................................................................................................................52 14.3 Contractor’s Warranty of Title.......................................................................................................55 14.4 Substantial Completion.................................................................................................................55 14.5 Partial Utilization............................................................................................................................56 14.6 Final Inspection ..............................................................................................................................56 14.7 Final Payment ...............................................................................................................................57 14.8 Final Completion Delayed............................................................................................................58 14.9 Waiver of Claims....................................................................................................................58 EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page iv Article 15 – Suspension of Work and Termination..........................................................................................58 15.1 Owner May Suspend Work..........................................................................................................58 15.2 Owner May Terminate for Cause.................................................................................................58 15.3 Owner May Terminate For Convenience ....................................................................................60 15.4 Contractor May Stop Work or Terminate....................................................................................60 Article 16 – Dispute Resolution........................................................................................................................61 16.01 Methods and Procedures...............................................................................................................61 Article 17 – Miscellaneous................................................................................................................................61 17.1 Giving Notice..................................................................................................................................61 17.2 Computation of Times....................................................................................................................61 17.3 Cumulative Remedies.....................................................................................................................62 17.4 Survival of Obligations...................................................................................................................62 17.5 Controlling Law............................................................................................................................62 17.6 Headings.........................................................................................................................................62 EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 1 of 62 ARTICLE 1 – DEFINITIONS AND TERMINOLOGY 1.1 Defined Terms A. Wherever used in the Bidding Requirements or Contract Documents and printed with initial capital letters, the terms listed below will have the meanings indicated which are applicable to both the singular and plural thereof. In addition to terms specifically defined, terms with initial capital letters in the Contract Documents include references to identified articles and paragraphs, and the titles of other documents or forms. 1.Addenda—Written or graphic instruments issued prior to the opening of Bids which clarify, correct, or change the Bidding Requirements or the proposed Contract Documents. 2.Agreement—The written instrument which is evidence of the agreement between Owner and Contractor covering the Work. 3.Application for Payment—The form acceptable to Engineer which is to be used by Contractor during the course of the Work in requesting progress or final payments and which is to be accompanied by such supporting documentation as is required by the Contract Documents. 4.Asbestos—Any material that contains more than one percent asbestos and is friable or is releasing asbestos fibers into the air above current action levels established by the United States Occupational Safety and Health Administration. 5.Bid—The offer or proposal of a Bidder submitted on the prescribed form setting forth the prices for the Work to be performed. 6.Bidder—The individual or entity who submits a Bid directly to Owner. 7.Bidding Documents—The Bidding Requirements and the proposed Contract Documents (including all Addenda). 8.Bidding Requirements—The advertisement or invitation to bid, Instructions to Bidders, Bid security of acceptable form, if any, and the Bid Form with any supplements. 9.Change Order—A document recommended by Engineer which is signed by Contractor and Owner and authorizes an addition, deletion, or revision in the Work or an adjustment in the Contract Price or the Contract Times, issued on or after the Effective Date of the Agreement. 10.Claim—A demand or assertion by Owner or Contractor seeking an adjustment of Contract Price or Contract Times, or both, or other relief with respect to the terms of the Contract. A demand for money or services by a third party is not a Claim. 11.Contract—The entire and integrated written agreement between the Owner and Contractor concerning the Work. The Contract supersedes prior negotiations, representations, or agreements, whether written or oral. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 2 of 62 12.Contract Documents—Those items so designated in the Agreement. Only printed or hard copies of the items listed in the Agreement are Contract Documents. Approved Shop Drawings, other Contractor submittals, and the reports and drawings of subsurface and physical conditions are not Contract Documents. 13.Contract Price—The moneys payable by Owner to Contractor for completion of the Work in accordance with the Contract Documents as stated in the Agreement (subject to the provisions of Paragraph 11.03 in the case of Unit Price Work). 14.Contract Times—The number of days or the dates stated in the Agreement to: (i) achieve Milestones, if any; (ii) achieve Substantial Completion; and (iii) complete the Work so that it is ready for final payment as evidenced by Engineer’s written recommendation of final payment. 15.Contractor—The individual or entity with whom Owner has entered into the Agreement. 16.Cost of the Work—See Paragraph 11.01 for definition. 17.Drawings—That part of the Contract Documents prepared or approved by Engineer which graphically shows the scope, extent, and character of the Work to be performed by Contractor. Shop Drawings and other Contractor submittals are not Drawings as so defined. 18.Effective Date of the Agreement—The date indicated in the Agreement on which it becomes effective, but if no such date is indicated, it means the date on which the Agreement is signed and delivered by the last of the two parties to sign and deliver. 19.Engineer—The individual or entity named as such in the Agreement. 20.Field Order—A written order issued by Engineer which requires minor changes in the Work but which does not involve a change in the Contract Price or the Contract Times. 21.General Requirements—Sections of Division 1 of the Specifications. 22.Hazardous Environmental Condition—The presence at the Site of Asbestos, PCBs, Petroleum, Hazardous Waste, or Radioactive Material in such quantities or circumstances that may present a substantial danger to persons or property exposed thereto. 23.Hazardous Waste—The term Hazardous Waste shall have the meaning provided in Section 1004 of the Solid Waste Disposal Act (42 USC Section 6903) as amended from time to time. 24.Laws and Regulations; Laws or Regulations—Any and all applicable laws, rules, regulations, ordinances, codes, and orders of any and all governmental bodies, agencies, authorities, and courts having jurisdiction. 25.Liens—Charges, security interests, or encumbrances upon Project funds, real property, or personal property. 26.Milestone—A principal event specified in the Contract Documents relating to an intermediate completion date or time prior to Substantial Completion of all the Work. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 3 of 62 27.Notice of Award—The written notice by Owner to the Successful Bidder stating that upon timely compliance by the Successful Bidder with the conditions precedent listed therein, Owner will sign and deliver the Agreement. 28.Notice to Proceed—A written notice given by Owner to Contractor fixing the date on which the Contract Times will commence to run and on which Contractor shall start to perform the Work under the Contract Documents. 29.Owner—The individual or entity with whom Contractor has entered into the Agreement and for whom the Work is to be performed. 30.PCBs—Polychlorinated biphenyls. 31.Petroleum—Petroleum, including crude oil or any fraction thereof which is liquid at standard conditions of temperature and pressure (60 degrees Fahrenheit and 14.7 pounds per square inch absolute), such as oil, petroleum, fuel oil, oil sludge, oil refuse, gasoline, kerosene, and oil mixed with other non-Hazardous Waste and crude oils. 32.Progress Schedule—A schedule, prepared and maintained by Contractor, describing the sequence and duration of the activities comprising the Contractor’s plan to accomplish the Work within the Contract Times. 33.Project—The total construction of which the Work to be performed under the Contract Documents may be the whole, or a part. 34.Project Manual—The bound documentary information prepared for bidding and constructing the Work. A listing of the contents of the Project Manual, which may be bound in one or more volumes, is contained in the table(s) of contents. 35.Radioactive Material—Source, special nuclear, or byproduct material as defined by the Atomic Energy Act of 1954 (42 USC Section 2011 et seq.) as amended from time to time. 36.Resident Project Representative—The authorized representative of Engineer who may be assigned to the Site or any part thereof. 37.Samples—Physical examples of materials, equipment, or workmanship that are representative of some portion of the Work and which establish the standards by which such portion of the Work will be judged. 38.Schedule of Submittals—A schedule, prepared and maintained by Contractor, of required submittals and the time requirements to support scheduled performance of related construction activities. 39.Schedule of Values—A schedule, prepared and maintained by Contractor, allocating portions of the Contract Price to various portions of the Work and used as the basis for reviewing Contractor’s Applications for Payment. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 4 of 62 40.Shop Drawings—All drawings, diagrams, illustrations, schedules, and other data or information which are specifically prepared or assembled by or for Contractor and submitted by Contractor to illustrate some portion of the Work. 41.Site—Lands or areas indicated in the Contract Documents as being furnished by Owner upon which the Work is to be performed, including rights-of-way and easements for access thereto, and such other lands furnished by Owner which are designated for the use of Contractor. 42.Specifications—That part of the Contract Documents consisting of written requirements for materials, equipment, systems, standards and workmanship as applied to the Work, and certain administrative requirements and procedural matters applicable thereto. 43.Subcontractor—An individual or entity having a direct contract with Contractor or with any other Subcontractor for the performance of a part of the Work at the Site. 44.Substantial Completion—The time at which the Work (or a specified part thereof) has progressed to the point where, in the opinion of Engineer, the Work (or a specified part thereof) is sufficiently complete, in accordance with the Contract Documents, so that the Work (or a specified part thereof) can be utilized for the purposes for which it is intended. The terms “substantially complete” and “substantially completed” as applied to all or part of the Work refer to Substantial Completion thereof. 45.Successful Bidder—The Bidder submitting a responsive Bid to whom Owner makes an award. 46.Supplementary Conditions—That part of the Contract Documents which amends or supplements these General Conditions. 47.Supplier—A manufacturer, fabricator, supplier, distributor, materialman, or vendor having a direct contract with Contractor or with any Subcontractor to furnish materials or equipment to be incorporated in the Work by Contractor or Subcontractor. 48.Underground Facilities—All underground pipelines, conduits, ducts, cables, wires, manholes, vaults, tanks, tunnels, or other such facilities or attachments, and any encasements containing such facilities, including those that convey electricity, gases, steam, liquid petroleum products, telephone or other communications, cable television, water, wastewater, storm water, other liquids or chemicals, or traffic or other control systems. 49.Unit Price Work—Work to be paid for on the basis of unit prices. 50.Work—The entire construction or the various separately identifiable parts thereof required to be provided under the Contract Documents. Work includes and is the result of performing or providing all labor, services, and documentation necessary to produce such construction, and furnishing, installing, and incorporating all materials and equipment into such construction, all as required by the Contract Documents. 51.Work Change Directive—A written statement to Contractor issued on or after the Effective Date of the Agreement and signed by Owner and recommended by Engineer ordering an EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 5 of 62 addition, deletion, or revision in the Work, or responding to differing or unforeseen subsurface or physical conditions under which the Work is to be performed or to emergencies. A Work Change Directive will not change the Contract Price or the Contract Times but is evidence that the parties expect that the change ordered or documented by a Work Change Directive will be incorporated in a subsequently issued Change Order following negotiations by the parties as to its effect, if any, on the Contract Price or Contract Times. 1.2 Terminology A. The words and terms discussed in Paragraph 1.02.B through F are not defined but, when used in the Bidding Requirements or Contract Documents, have the indicated meaning. B.Intent of Certain Terms or Adjectives: 1. The Contract Documents include the terms “as allowed,” “as approved,” “as ordered,” “as directed” or terms of like effect or import to authorize an exercise of professional judgment by Engineer. In addition, the adjectives “reasonable,” “suitable,” “acceptable,” “proper,” “satisfactory,” or adjectives of like effect or import are used to describe an action or determination of Engineer as to the Work. It is intended that such exercise of professional judgment, action, or determination will be solely to evaluate, in general, the Work for compliance with the information in the Contract Documents and with the design concept of the Project as a functioning whole as shown or indicated in the Contract Documents (unless there is a specific statement indicating otherwise). The use of any such term or adjective is not intended to and shall not be effective to assign to Engineer any duty or authority to supervise or direct the performance of the Work, or any duty or authority to undertake responsibility contrary to the provisions of Paragraph 9.09 or any other provision of the Contract Documents. C.Day: 1. The word “day” means a calendar day of 24 hours measured from midnight to the next midnight. D.Defective: 1.The word “defective,” when modifying the word “Work,” refers to Work that is unsatisfactory, faulty, or deficient in that it: a.does not conform to the Contract Documents; or b.does not meet the requirements of any applicable inspection, reference standard, test, or approval referred to in the Contract Documents; or c.has been damaged prior to Engineer’s recommendation of final payment (unless responsibility for the protection thereof has been assumed by Owner at Substantial Completion in accordance with Paragraph 14.04 or 14.05). E.Furnish, Install, Perform, Provide: EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 6 of 62 1.The word “furnish,” when used in connection with services, materials, or equipment, shall mean to supply and deliver said services, materials, or equipment to the Site (or some other specified location) ready for use or installation and in usable or operable condition. 2.The word “install,” when used in connection with services, materials, or equipment, shall mean to put into use or place in final position said services, materials, or equipment complete and ready for intended use. 3.The words “perform” or “provide,” when used in connection with services, materials, or equipment, shall mean to furnish and install said services, materials, or equipment complete and ready for intended use. 4.When “furnish,” “install,” “perform,” or “provide” is not used in connection with services, materials, or equipment in a context clearly requiring an obligation of Contractor, “provide” is implied. F. Unless stated otherwise in the Contract Documents, words or phrases that have a well-known technical or construction industry or trade meaning are used in the Contract Documents in accordance with such recognized meaning. ARTICLE 2 – PRELIMINARY MATTERS 2.1 Delivery of Bonds and Evidence of Insurance A. When Contractor delivers the executed counterparts of the Agreement to Owner, Contractor shall also deliver to Owner such bonds as Contractor may be required to furnish. B.Evidence of Insurance: Before any Work at the Site is started, Contractor and Owner shall each deliver to the other, with copies to each additional insured identified in the Supplementary Conditions, certificates of insurance (and other evidence of insurance which either of them or any additional insured may reasonably request) which Contractor and Owner respectively are required to purchase and maintain in accordance with Article 5. 2.2 Copies of Documents A. Owner shall furnish to Contractor up to ten printed or hard copies of the Drawings and Project Manual. Additional copies will be furnished upon request at the cost of reproduction. 2.3 Commencement of Contract Times; Notice to Proceed A. The Contract Times will commence to run on the thirtieth day after the Effective Date of the Agreement or, if a Notice to Proceed is given, on the day indicated in the Notice to Proceed. A Notice to Proceed may be given at any time within 30 days after the Effective Date of the Agreement. In no event will the Contract Times commence to run later than the sixtieth day after the day of Bid opening or the thirtieth day after the Effective Date of the Agreement, whichever date is earlier. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 7 of 62 2.4 Starting the Work A. Contractor shall start to perform the Work on the date when the Contract Times commence to run. No Work shall be done at the Site prior to the date on which the Contract Times commence to run. 2.5 Before Starting Construction A.Preliminary Schedules: Within 10 days after the Effective Date of the Agreement (unless otherwise specified in the General Requirements), Contractor shall submit to Engineer for timely review: 1.a preliminary Progress Schedule indicating the times (numbers of days or dates) for starting and completing the various stages of the Work, including any Milestones specified in the Contract Documents; 2.a preliminary Schedule of Submittals; and 3.a preliminary Schedule of Values for all of the Work which includes quantities and prices of items which when added together equal the Contract Price and subdivides the Work into component parts in sufficient detail to serve as the basis for progress payments during performance of the Work. Such prices will include an appropriate amount of overhead and profit applicable to each item of Work. 2.6 Preconstruction Conference; Designation of Authorized Representatives A. Before any Work at the Site is started, a conference attended by Owner, Contractor, Engineer, and others as appropriate will be held to establish a working understanding among the parties as to the Work and to discuss the schedules referred to in Paragraph 2.05.A, procedures for handling Shop Drawings and other submittals, processing Applications for Payment, and maintaining required records. B. At this conference Owner and Contractor each shall designate, in writing, a specific individual to act as its authorized representative with respect to the services and responsibilities under the Contract. Such individuals shall have the authority to transmit instructions, receive information, render decisions relative to the Contract, and otherwise act on behalf of each respective party. 2.7 Initial Acceptance of Schedules A. At least 10 days before submission of the first Application for Payment a conference attended by Contractor, Engineer, and others as appropriate will be held to review for acceptability to Engineer as provided below the schedules submitted in accordance with Paragraph 2.05.A. Contractor shall have an additional 10 days to make corrections and adjustments and to complete and resubmit the schedules. No progress payment shall be made to Contractor until acceptable schedules are submitted to Engineer. 1. The Progress Schedule will be acceptable to Engineer if it provides an orderly progression of the Work to completion within the Contract Times. Such acceptance will not impose on Engineer responsibility for the Progress Schedule, for sequencing, scheduling, or progress of EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 8 of 62 the Work, nor interfere with or relieve Contractor from Contractor’s full responsibility therefor. 2. Contractor’s Schedule of Submittals will be acceptable to Engineer if it provides a workable arrangement for reviewing and processing the required submittals. 3. Contractor’s Schedule of Values will be acceptable to Engineer as to form and substance if it provides a reasonable allocation of the Contract Price to component parts of the Work. ARTICLE 3 – CONTRACT DOCUMENTS: INTENT, AMENDING, REUSE 3.1 Intent A. The Contract Documents are complementary; what is required by one is as binding as if required by all. B. It is the intent of the Contract Documents to describe a functionally complete project (or part thereof) to be constructed in accordance with the Contract Documents. Any labor, documentation, services, materials, or equipment that reasonably may be inferred from the Contract Documents or from prevailing custom or trade usage as being required to produce the indicated result will be provided whether or not specifically called for, at no additional cost to Owner. C. Clarifications and interpretations of the Contract Documents shall be issued by Engineer as provided in Article 9. 3.2 Reference Standards A.Standards, Specifications, Codes, Laws, and Regulations 1.Reference to standards, specifications, manuals, or codes of any technical society, organization, or association, or to Laws or Regulations, whether such reference be specific or by implication, shall mean the standard, specification, manual, code, or Laws or Regulations in effect at the time of opening of Bids (or on the Effective Date of the Agreement if there were no Bids), except as may be otherwise specifically stated in the Contract Documents. 2.No provision of any such standard, specification, manual, or code, or any instruction of a Supplier, shall be effective to change the duties or responsibilities of Owner, Contractor, or Engineer, or any of their subcontractors, consultants, agents, or employees, from those set forth in the Contract Documents. No such provision or instruction shall be effective to assign to Owner, Engineer, or any of their officers, directors, members, partners, employees, agents, consultants, or subcontractors, any duty or authority to supervise or direct the performance of the Work or any duty or authority to undertake responsibility inconsistent with the provisions of the Contract Documents. 3.3 Reporting and Resolving Discrepancies A.Reporting Discrepancies: EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 9 of 62 1.Contractor’s Review of Contract Documents Before Starting Work: Before undertaking each part of the Work, Contractor shall carefully study and compare the Contract Documents and check and verify pertinent figures therein and all applicable field measurements. Contractor shall promptly report in writing to Engineer any conflict, error, ambiguity, or discrepancy which Contractor discovers, or has actual knowledge of, and shall obtain a written interpretation or clarification from Engineer before proceeding with any Work affected thereby. 2.Contractor’s Review of Contract Documents During Performance of Work: If, during the performance of the Work, Contractor discovers any conflict, error, ambiguity, or discrepancy within the Contract Documents, or between the Contract Documents and (a) any applicable Law or Regulation , (b) any standard, specification, manual, or code, or (c) any instruction of any Supplier, then Contractor shall promptly report it to Engineer in writing. Contractor shall not proceed with the Work affected thereby (except in an emergency as required by Paragraph 6.16.A) until an amendment or supplement to the Contract Documents has been issued by one of the methods indicated in Paragraph 3.04. 3. Contractor shall not be liable to Owner or Engineer for failure to report any conflict, error, ambiguity, or discrepancy in the Contract Documents unless Contractor had actual knowledge thereof. B.Resolving Discrepancies: 1. Except as may be otherwise specifically stated in the Contract Documents, the provisions of the Contract Documents shall take precedence in resolving any conflict, error, ambiguity, or discrepancy between the provisions of the Contract Documents and: a. the provisions of any standard, specification, manual, or code, or the instruction of any Supplier (whether or not specifically incorporated by reference in the Contract Documents); or b. the provisions of any Laws or Regulations applicable to the performance of the Work (unless such an interpretation of the provisions of the Contract Documents would result in violation of such Law or Regulation). 3.4 Amending and Supplementing Contract Documents A. The Contract Documents may be amended to provide for additions, deletions, and revisions in the Work or to modify the terms and conditions thereof by either a Change Order or a Work Change Directive. B. The requirements of the Contract Documents may be supplemented, and minor variations and deviations in the Work may be authorized, by one or more of the following ways: 1.A Field Order; 2.Engineer’s approval of a Shop Drawing or Sample (subject to the provisions of Paragraph 6.17.D.3); or EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 10 of 62 3.Engineer’s written interpretation or clarification. 3.5 Reuse of Documents A. Contractor and any Subcontractor or Supplier shall not: 1. have or acquire any title to or ownership rights in any of the Drawings, Specifications, or other documents (or copies of any thereof) prepared by or bearing the seal of Engineer or its consultants, including electronic media editions; or 2. reuse any such Drawings, Specifications, other documents, or copies thereof on extensions of the Project or any other project without written consent of Owner and Engineer and specific written verification or adaptation by Engineer. B. The prohibitions of this Paragraph 3.05 will survive final payment, or termination of the Contract. Nothing herein shall preclude Contractor from retaining copies of the Contract Documents for record purposes. 3.6 Electronic Data A. Unless otherwise stated in the Supplementary Conditions, the data furnished by Owner or Engineer to Contractor, or by Contractor to Owner or Engineer, that may be relied upon are limited to the printed copies (also known as hard copies). Files in electronic media format of text, data, graphics, or other types are furnished only for the convenience of the receiving party. Any conclusion or information obtained or derived from such electronic files will be at the user’s sole risk. If there is a discrepancy between the electronic files and the hard copies, the hard copies govern. B. Because data stored in electronic media format can deteriorate or be modified inadvertently or otherwise without authorization of the data’s creator, the party receiving electronic files agrees that it will perform acceptance tests or procedures within 60 days, after which the receiving party shall be deemed to have accepted the data thus transferred. Any errors detected within the 60-day acceptance period will be corrected by the transferring party. C. When transferring documents in electronic media format, the transferring party makes no representations as to long term compatibility, usability, or readability of documents resulting from the use of software application packages, operating systems, or computer hardware differing from those used by the data’s creator. ARTICLE 4 – AVAILABILITY OF LANDS; SUBSURFACE AND PHYSICAL CONDITIONS; HAZARDOUS ENVIRONMENTAL CONDITIONS; REFERENCE POINTS 4.1 Availability of Lands A. Owner shall furnish the Site. Owner shall notify Contractor of any encumbrances or restrictions not of general application but specifically related to use of the Site with which Contractor must comply in performing the Work. Owner will obtain in a timely manner and pay for easements for permanent structures or permanent changes in existing facilities. If Contractor and Owner are unable to agree on entitlement to or on the amount or extent, if any, of any adjustment in the EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 11 of 62 Contract Price or Contract Times, or both, as a result of any delay in Owner’s furnishing the Site or a part thereof, Contractor may make a Claim therefor as provided in Paragraph 10.05. B. Upon reasonable written request, Owner shall furnish Contractor with a current statement of record legal title and legal description of the lands upon which the Work is to be performed and Owner’s interest therein as necessary for giving notice of or filing a mechanic’s or construction lien against such lands in accordance with applicable Laws and Regulations. C. Contractor shall provide for all additional lands and access thereto that may be required for temporary construction facilities or storage of materials and equipment. 4.2 Subsurface and Physical Conditions A.Reports and Drawings: The Supplementary Conditions identify: 1. those reports known to Owner of explorations and tests of subsurface conditions at or contiguous to the Site; and 2. those drawings known to Owner of physical conditions relating to existing surface or subsurface structures at the Site (except Underground Facilities). B.Limited Reliance by Contractor on Technical Data Authorized: Contractor may rely upon the accuracy of the “technical data” contained in such reports and drawings, but such reports and drawings are not Contract Documents. Such “technical data” is identified in the Supplementary Conditions. Except for such reliance on such “technical data,” Contractor may not rely upon or make any claim against Owner or Engineer, or any of their officers, directors, members, partners, employees, agents, consultants, or subcontractors with respect to: 1. the completeness of such reports and drawings for Contractor’s purposes, including, but not limited to, any aspects of the means, methods, techniques, sequences, and procedures of construction to be employed by Contractor, and safety precautions and programs incident thereto; or 2. other data, interpretations, opinions, and information contained in such reports or shown or indicated in such drawings; or 3. any Contractor interpretation of or conclusion drawn from any “technical data” or any such other data, interpretations, opinions, or information. 4.3 Differing Subsurface or Physical Conditions A.Notice: If Contractor believes that any subsurface or physical condition that is uncovered or revealed either: 1. is of such a nature as to establish that any “technical data” on which Contractor is entitled to rely as provided in Paragraph 4.02 is materially inaccurate; or 2. is of such a nature as to require a change in the Contract Documents; or EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 12 of 62 3. differs materially from that shown or indicated in the Contract Documents; or 4. is of an unusual nature, and differs materially from conditions ordinarily encountered and generally recognized as inherent in work of the character provided for in the Contract Documents; then Contractor shall, promptly after becoming aware thereof and before further disturbing the subsurface or physical conditions or performing any Work in connection therewith (except in an emergency as required by Paragraph 6.16.A), notify Owner and Engineer in writing about such condition. Contractor shall not further disturb such condition or perform any Work in connection therewith (except as aforesaid) until receipt of written order to do so. B.Engineer’s Review: After receipt of written notice as required by Paragraph 4.03.A, Engineer will promptly review the pertinent condition, determine the necessity of Owner’s obtaining additional exploration or tests with respect thereto, and advise Owner in writing (with a copy to Contractor) of Engineer’s findings and conclusions. C.Possible Price and Times Adjustments: 1. The Contract Price or the Contract Times, or both, will be equitably adjusted to the extent that the existence of such differing subsurface or physical condition causes an increase or decrease in Contractor’s cost of, or time required for, performance of the Work; subject, however, to the following: a. such condition must meet any one or more of the categories described in Paragraph 4.03.A; and b. with respect to Work that is paid for on a unit price basis, any adjustment in Contract Price will be subject to the provisions of Paragraphs 9.07 and 11.03. 2. Contractor shall not be entitled to any adjustment in the Contract Price or Contract Times if: a. Contractor knew of the existence of such conditions at the time Contractor made a final commitment to Owner with respect to Contract Price and Contract Times by the submission of a Bid or becoming bound under a negotiated contract; or b. the existence of such condition could reasonably have been discovered or revealed as a result of any examination, investigation, exploration, test, or study of the Site and contiguous areas required by the Bidding Requirements or Contract Documents to be conducted by or for Contractor prior to Contractor’s making such final commitment; or c. Contractor failed to give the written notice as required by Paragraph 4.03.A. 3. If Owner and Contractor are unable to agree on entitlement to or on the amount or extent, if any, of any adjustment in the Contract Price or Contract Times, or both, a Claim may be made therefor as provided in Paragraph 10.05. However, neither Owner or Engineer, or any of their officers, directors, members, partners, employees, agents, consultants, or subcontractors shall be liable to Contractor for any claims, costs, losses, or damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 13 of 62 professionals and all court or arbitration or other dispute resolution costs) sustained by Contractor on or in connection with any other project or anticipated project. 4.4 Underground Facilities A.Shown or Indicated: The information and data shown or indicated in the Contract Documents with respect to existing Underground Facilities at or contiguous to the Site is based on information and data furnished to Owner or Engineer by the owners of such Underground Facilities, including Owner, or by others. Unless it is otherwise expressly provided in the Supplementary Conditions: 1. Owner and Engineer shall not be responsible for the accuracy or completeness of any such information or data provided by others; and 2. the cost of all of the following will be included in the Contract Price, and Contractor shall have full responsibility for: a. reviewing and checking all such information and data; b. locating all Underground Facilities shown or indicated in the Contract Documents; c. coordination of the Work with the owners of such Underground Facilities, including Owner, during construction; and d. the safety and protection of all such Underground Facilities and repairing any damage thereto resulting from the Work. B.Not Shown or Indicated: 1. If an Underground Facility is uncovered or revealed at or contiguous to the Site which was not shown or indicated, or not shown or indicated with reasonable accuracy in the Contract Documents, Contractor shall, promptly after becoming aware thereof and before further disturbing conditions affected thereby or performing any Work in connection therewith (except in an emergency as required by Paragraph 6.16.A), identify the owner of such Underground Facility and give written notice to that owner and to Owner and Engineer. Engineer will promptly review the Underground Facility and determine the extent, if any, to which a change is required in the Contract Documents to reflect and document the consequences of the existence or location of the Underground Facility. During such time, Contractor shall be responsible for the safety and protection of such Underground Facility. 2. If Engineer concludes that a change in the Contract Documents is required, a Work Change Directive or a Change Order will be issued to reflect and document such consequences. An equitable adjustment shall be made in the Contract Price or Contract Times, or both, to the extent that they are attributable to the existence or location of any Underground Facility that was not shown or indicated or not shown or indicated with reasonable accuracy in the Contract Documents and that Contractor did not know of and could not reasonably have been expected to be aware of or to have anticipated. If Owner and Contractor are unable to agree on entitlement to or on the amount or extent, if any, of any such adjustment in Contract Price EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 14 of 62 or Contract Times, Owner or Contractor may make a Claim therefor as provided in Paragraph 10.05. 4.5 Reference Points A. Owner shall provide engineering surveys to establish reference points for construction which in Engineer’s judgment are necessary to enable Contractor to proceed with the Work. Contractor shall be responsible for laying out the Work, shall protect and preserve the established reference points and property monuments, and shall make no changes or relocations without the prior written approval of Owner. Contractor shall report to Engineer whenever any reference point or property monument is lost or destroyed or requires relocation because of necessary changes in grades or locations, and shall be responsible for the accurate replacement or relocation of such reference points or property monuments by professionally qualified personnel. 4.6 Hazardous Environmental Condition at Site A.Reports and Drawings: The Supplementary Conditions identify those reports and drawings known to Owner relating to Hazardous Environmental Conditions that have been identified at the Site. B.Limited Reliance by Contractor on Technical Data Authorized: Contractor may rely upon the accuracy of the “technical data” contained in such reports and drawings, but such reports and drawings are not Contract Documents. Such “technical data” is identified in the Supplementary Conditions. Except for such reliance on such “technical data,” Contractor may not rely upon or make any claim against Owner or Engineer, or any of their officers, directors, members, partners, employees, agents, consultants, or subcontractors with respect to: 1.the completeness of such reports and drawings for Contractor’s purposes, including, but not limited to, any aspects of the means, methods, techniques, sequences and procedures of construction to be employed by Contractor and safety precautions and programs incident thereto; or 2.other data, interpretations, opinions and information contained in such reports or shown or indicated in such drawings; or 3.any Contractor interpretation of or conclusion drawn from any “technical data” or any such other data, interpretations, opinions or information. C. Contractor shall not be responsible for any Hazardous Environmental Condition uncovered or revealed at the Site which was not shown or indicated in Drawings or Specifications or identified in the Contract Documents to be within the scope of the Work. Contractor shall be responsible for a Hazardous Environmental Condition created with any materials brought to the Site by Contractor, Subcontractors, Suppliers, or anyone else for whom Contractor is responsible. D. If Contractor encounters a Hazardous Environmental Condition or if Contractor or anyone for whom Contractor is responsible creates a Hazardous Environmental Condition, Contractor shall immediately: (i) secure or otherwise isolate such condition; (ii) stop all Work in connection with such condition and in any area affected thereby (except in an emergency as required by EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 15 of 62 Paragraph 6.16.A); and (iii) notify Owner and Engineer (and promptly thereafter confirm such notice in writing). Owner shall promptly consult with Engineer concerning the necessity for Owner to retain a qualified expert to evaluate such condition or take corrective action, if any. Promptly after consulting with Engineer, Owner shall take such actions as are necessary to permit Owner to timely obtain required permits and provide Contractor the written notice required by Paragraph 4.06.E. E. Contractor shall not be required to resume Work in connection with such condition or in any affected area until after Owner has obtained any required permits related thereto and delivered written notice to Contractor: (i) specifying that such condition and any affected area is or has been rendered safe for the resumption of Work; or (ii) specifying any special conditions under which such Work may be resumed safely. If Owner and Contractor cannot agree as to entitlement to or on the amount or extent, if any, of any adjustment in Contract Price or Contract Times, or both, as a result of such Work stoppage or such special conditions under which Work is agreed to be resumed by Contractor, either party may make a Claim therefor as provided in Paragraph 10.05. F. If after receipt of such written notice Contractor does not agree to resume such Work based on a reasonable belief it is unsafe, or does not agree to resume such Work under such special conditions, then Owner may order the portion of the Work that is in the area affected by such condition to be deleted from the Work. If Owner and Contractor cannot agree as to entitlement to or on the amount or extent, if any, of an adjustment in Contract Price or Contract Times as a result of deleting such portion of the Work, then either party may make a Claim therefor as provided in Paragraph 10.05. Owner may have such deleted portion of the Work performed by Owner’s own forces or others in accordance with Article 7. G. To the fullest extent permitted by Laws and Regulations, Owner shall indemnify and hold harmless Contractor, Subcontractors, and Engineer, and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to a Hazardous Environmental Condition, provided that such Hazardous Environmental Condition: (i) was not shown or indicated in the Drawings or Specifications or identified in the Contract Documents to be included within the scope of the Work, and (ii) was not created by Contractor or by anyone for whom Contractor is responsible. Nothing in this Paragraph 4.06.G shall obligate Owner to indemnify any individual or entity from and against the consequences of that individual’s or entity’s own negligence. H. To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless Owner and Engineer, and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to a Hazardous Environmental Condition created by Contractor or by anyone for whom Contractor is responsible. Nothing in this Paragraph 4.06.H shall obligate Contractor to indemnify any individual or entity from and against the consequences of that individual’s or entity’s own negligence. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 16 of 62 I. The provisions of Paragraphs 4.02, 4.03, and 4.04 do not apply to a Hazardous Environmental Condition uncovered or revealed at the Site. ARTICLE 5 – BONDS AND INSURANCE 5.1 Performance, Payment, and Other Bonds A. Contractor shall furnish performance and payment bonds, each in an amount at least equal to the Contract Price as security for the faithful performance and payment of all of Contractor’s obligations under the Contract Documents. These bonds shall remain in effect until one year after the date when final payment becomes due or until completion of the correction period specified in Paragraph 13.07, whichever is later, except as provided otherwise by Laws or Regulations or by the Contract Documents. Contractor shall also furnish such other bonds as are required by the Contract Documents. B. All bonds shall be in the form prescribed by the Contract Documents except as provided otherwise by Laws or Regulations, and shall be executed by such sureties as are named in the list of “Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsuring Companies” as published in Circular 570 (amended) by the Financial Management Service, Surety Bond Branch, U.S. Department of the Treasury. All bonds signed by an agent or attorney-in-fact must be accompanied by a certified copy of that individual’s authority to bind the surety. The evidence of authority shall show that it is effective on the date the agent or attorney-in-fact signed each bond. C. If the surety on any bond furnished by Contractor is declared bankrupt or becomes insolvent or its right to do business is terminated in any state where any part of the Project is located or it ceases to meet the requirements of Paragraph 5.01.B, Contractor shall promptly notify Owner and Engineer and shall, within 20 days after the event giving rise to such notification, provide another bond and surety, both of which shall comply with the requirements of Paragraphs 5.01.B and 5.02. 5.2 Licensed Sureties and Insurers A. All bonds and insurance required by the Contract Documents to be purchased and maintained by Owner or Contractor shall be obtained from surety or insurance companies that are duly licensed or authorized in the jurisdiction in which the Project is located to issue bonds or insurance policies for the limits and coverages so required. Such surety and insurance companies shall also meet such additional requirements and qualifications as may be provided in the Supplementary Conditions. 5.3 Certificates of Insurance A. Contractor shall deliver to Owner, with copies to each additional insured and loss payee identified in the Supplementary Conditions, certificates of insurance (and other evidence of insurance requested by Owner or any other additional insured) which Contractor is required to purchase and maintain. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 17 of 62 B. Owner shall deliver to Contractor, with copies to each additional insured and loss payee identified in the Supplementary Conditions, certificates of insurance (and other evidence of insurance requested by Contractor or any other additional insured) which Owner is required to purchase and maintain. C. Failure of Owner to demand such certificates or other evidence of Contractor's full compliance with these insurance requirements or failure of Owner to identify a deficiency in compliance from the evidence provided shall not be construed as a waiver of Contractor’s obligation to maintain such insurance. D. Owner does not represent that insurance coverage and limits established in this Contract necessarily will be adequate to protect Contractor. E.The insurance and insurance limits required herein shall not be deemed as a limitation on Contractor’s liability under the indemnities granted to Owner in the Contract Documents. 5.4 Contractor’s Insurance A. Contractor shall purchase and maintain such insurance as is appropriate for the Work being performed and as will provide protection from claims set forth below which may arise out of or result from Contractor’s performance of the Work and Contractor’s other obligations under the Contract Documents, whether it is to be performed by Contractor, any Subcontractor or Supplier, or by anyone directly or indirectly employed by any of them to perform any of the Work, or by anyone for whose acts any of them may be liable: 1. claims under workers’ compensation, disability benefits, and other similar employee benefit acts; 2. claims for damages because of bodily injury, occupational sickness or disease, or death of Contractor’s employees; 3. claims for damages because of bodily injury, sickness or disease, or death of any person other than Contractor’s employees; 4. claims for damages insured by reasonably available personal injury liability coverage which are sustained: a. by any person as a result of an offense directly or indirectly related to the employment of such person by Contractor, or b. by any other person for any other reason; 5. claims for damages, other than to the Work itself, because of injury to or destruction of tangible property wherever located, including loss of use resulting therefrom; and 6. claims for damages because of bodily injury or death of any person or property damage arising out of the ownership, maintenance or use of any motor vehicle. B. The policies of insurance required by this Paragraph 5.04 shall: EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 18 of 62 1. with respect to insurance required by Paragraphs 5.04.A.3 through 5.04.A.6 inclusive, be written on an occurrence basis, include as additional insureds (subject to any customary exclusion regarding professional liability) Owner and Engineer, and any other individuals or entities identified in the Supplementary Conditions, all of whom shall be listed as additional insureds, and include coverage for the respective officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of all such additional insureds, and the insurance afforded to these additional insureds shall provide primary coverage for all claims covered thereby; 2. include at least the specific coverages and be written for not less than the limits of liability provided in the Supplementary Conditions or required by Laws or Regulations, whichever is greater; 3. include contractual liability insurance covering Contractor’s indemnity obligations under Paragraphs 6.11 and 6.20; 4. contain a provision or endorsement that the coverage afforded will not be canceled, materially changed or renewal refused until at least 30 days prior written notice has been given to Owner and Contractor and to each other additional insured identified in the Supplementary Conditions to whom a certificate of insurance has been issued (and the certificates of insurance furnished by the Contractor pursuant to Paragraph 5.03 will so provide); 5. remain in effect at least until final payment and at all times thereafter when Contractor may be correcting, removing, or replacing defective Work in accordance with Paragraph 13.07; and 6. include completed operations coverage: a. Such insurance shall remain in effect for two years after final payment. b. Contractor shall furnish Owner and each other additional insured identified in the Supplementary Conditions, to whom a certificate of insurance has been issued, evidence satisfactory to Owner and any such additional insured of continuation of such insurance at final payment and one year thereafter. 5.5 Owner’s Liability Insurance A. In addition to the insurance required to be provided by Contractor under Paragraph 5.04, Owner, at Owner’s option, may purchase and maintain at Owner’s expense Owner’s own liability insurance as will protect Owner against claims which may arise from operations under the Contract Documents. 5.6 Property Insurance A. Unless otherwise provided in the Supplementary Conditions, Owner shall purchase and maintain property insurance upon the Work at the Site in the amount of the full replacement cost thereof (subject to such deductible amounts as may be provided in the Supplementary Conditions or required by Laws and Regulations). This insurance shall: EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 19 of 62 1.include the interests of Owner, Contractor, Subcontractors, and Engineer, and any other individuals or entities identified in the Supplementary Conditions, and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them, each of whom is deemed to have an insurable interest and shall be listed as a loss payee; 2.be written on a Builder’s Risk “all-risk” policy form that shall at least include insurance for physical loss or damage to the Work, temporary buildings, falsework, and materials and equipment in transit, and shall insure against at least the following perils or causes of loss: fire, lightning, extended coverage, theft, vandalism and malicious mischief, earthquake, collapse, debris removal, demolition occasioned by enforcement of Laws and Regulations, water damage (other than that caused by flood), and such other perils or causes of loss as may be specifically required by the Supplementary Conditions. 3.include expenses incurred in the repair or replacement of any insured property (including but not limited to fees and charges of engineers and architects); 4.cover materials and equipment stored at the Site or at another location that was agreed to in writing by Owner prior to being incorporated in the Work, provided that such materials and equipment have been included in an Application for Payment recommended by Engineer; 5.allow for partial utilization of the Work by Owner; 6.include testing and startup; and 7.be maintained in effect until final payment is made unless otherwise agreed to in writing by Owner, Contractor, and Engineer with 30 days written notice to each other loss payee to whom a certificate of insurance has been issued. B. Owner shall purchase and maintain such equipment breakdown insurance or additional property insurance as may be required by the Supplementary Conditions or Laws and Regulations which will include the interests of Owner, Contractor, Subcontractors, and Engineer, and any other individuals or entities identified in the Supplementary Conditions, and the officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them, each of whom is deemed to have an insurable interest and shall be listed as a loss payee. C. All the policies of insurance (and the certificates or other evidence thereof) required to be purchased and maintained in accordance with this Paragraph 5.06 will contain a provision or endorsement that the coverage afforded will not be canceled or materially changed or renewal refused until at least 30 days prior written notice has been given to Owner and Contractor and to each other loss payee to whom a certificate of insurance has been issued and will contain waiver provisions in accordance with Paragraph 5.07. D. Owner shall not be responsible for purchasing and maintaining any property insurance specified in this Paragraph 5.06 to protect the interests of Contractor, Subcontractors, or others in the Work to the extent of any deductible amounts that are identified in the Supplementary Conditions. The risk of loss within such identified deductible amount will be borne by Contractor, Subcontractors, or others suffering any such loss, and if any of them wishes property EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 20 of 62 insurance coverage within the limits of such amounts, each may purchase and maintain it at the purchaser’s own expense. E.If Contractor requests in writing that other special insurance be included in the property insurance policies provided under this Paragraph 5.06, Owner shall, if possible, include such insurance, and the cost thereof will be charged to Contractor by appropriate Change Order. Prior to commencement of the Work at the Site, Owner shall in writing advise Contractor whether or not such other insurance has been procured by Owner. 5.7 Waiver of Rights A. Owner and Contractor intend that all policies purchased in accordance with Paragraph 5.06 will protect Owner, Contractor, Subcontractors, and Engineer, and all other individuals or entities identified in the Supplementary Conditions as loss payees (and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them) in such policies and will provide primary coverage for all losses and damages caused by the perils or causes of loss covered thereby. All such policies shall contain provisions to the effect that in the event of payment of any loss or damage the insurers will have no rights of recovery against any of the insureds or loss payees thereunder. Owner and Contractor waive all rights against each other and their respective officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them for all losses and damages caused by, arising out of or resulting from any of the perils or causes of loss covered by such policies and any other property insurance applicable to the Work; and, in addition, waive all such rights against Subcontractors and Engineer, and all other individuals or entities identified in the Supplementary Conditions as loss payees (and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them) under such policies for losses and damages so caused. None of the above waivers shall extend to the rights that any party making such waiver may have to the proceeds of insurance held by Owner as trustee or otherwise payable under any policy so issued. B. Owner waives all rights against Contractor, Subcontractors, and Engineer, and the officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them for: 1. loss due to business interruption, loss of use, or other consequential loss extending beyond direct physical loss or damage to Owner’s property or the Work caused by, arising out of, or resulting from fire or other perils whether or not insured by Owner; and 2. loss or damage to the completed Project or part thereof caused by, arising out of, or resulting from fire or other insured peril or cause of loss covered by any property insurance maintained on the completed Project or part thereof by Owner during partial utilization pursuant to Paragraph 14.05, after Substantial Completion pursuant to Paragraph 14.04, or after final payment pursuant to Paragraph 14.07. C. Any insurance policy maintained by Owner covering any loss, damage or consequential loss referred to in Paragraph 5.07.B shall contain provisions to the effect that in the event of payment of any such loss, damage, or consequential loss, the insurers will have no rights of recovery EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 21 of 62 against Contractor, Subcontractors, or Engineer, and the officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them. 5.8 Receipt and Application of Insurance Proceeds A. Any insured loss under the policies of insurance required by Paragraph 5.06 will be adjusted with Owner and made payable to Owner as fiduciary for the loss payees, as their interests may appear, subject to the requirements of any applicable mortgage clause and of Paragraph 5.08.B. Owner shall deposit in a separate account any money so received and shall distribute it in accordance with such agreement as the parties in interest may reach. If no other special agreement is reached, the damaged Work shall be repaired or replaced, the moneys so received applied on account thereof, and the Work and the cost thereof covered by an appropriate Change Order. B. Owner as fiduciary shall have power to adjust and settle any loss with the insurers unless one of the parties in interest shall object in writing within 15 days after the occurrence of loss to Owner’s exercise of this power. If such objection be made, Owner as fiduciary shall make settlement with the insurers in accordance with such agreement as the parties in interest may reach. If no such agreement among the parties in interest is reached, Owner as fiduciary shall adjust and settle the loss with the insurers and, if required in writing by any party in interest, Owner as fiduciary shall give bond for the proper performance of such duties. 5.9 Acceptance of Bonds and Insurance; Option to Replace A. If either Owner or Contractor has any objection to the coverage afforded by or other provisions of the bonds or insurance required to be purchased and maintained by the other party in accordance with Article 5 on the basis of non-conformance with the Contract Documents, the objecting party shall so notify the other party in writing within 10 days after receipt of the certificates (or other evidence requested) required by Paragraph 2.01.B. Owner and Contractor shall each provide to the other such additional information in respect of insurance provided as the other may reasonably request. If either party does not purchase or maintain all of the bonds and insurance required of such party by the Contract Documents, such party shall notify the other party in writing of such failure to purchase prior to the start of the Work, or of such failure to maintain prior to any change in the required coverage. Without prejudice to any other right or remedy, the other party may elect to obtain equivalent bonds or insurance to protect such other party’s interests at the expense of the party who was required to provide such coverage, and a Change Order shall be issued to adjust the Contract Price accordingly. 5.10 Partial Utilization, Acknowledgment of Property Insurer A. If Owner finds it necessary to occupy or use a portion or portions of the Work prior to Substantial Completion of all the Work as provided in Paragraph 14.05, no such use or occupancy shall commence before the insurers providing the property insurance pursuant to Paragraph 5.06 have acknowledged notice thereof and in writing effected any changes in coverage necessitated thereby. The insurers providing the property insurance shall consent by endorsement on the policy or policies, but the property insurance shall not be canceled or permitted to lapse on account of any such partial use or occupancy. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 22 of 62 ARTICLE 6 – CONTRACTOR’S RESPONSIBILITIES 6.1 Supervision and Superintendence A. Contractor shall supervise, inspect, and direct the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with the Contract Documents. Contractor shall be solely responsible for the means, methods, techniques, sequences, and procedures of construction. Contractor shall not be responsible for the negligence of Owner or Engineer in the design or specification of a specific means, method, technique, sequence, or procedure of construction which is shown or indicated in and expressly required by the Contract Documents. B. At all times during the progress of the Work, Contractor shall assign a competent resident superintendent who shall not be replaced without written notice to Owner and Engineer except under extraordinary circumstances. 6.2 Labor; Working Hours A. Contractor shall provide competent, suitably qualified personnel to survey and lay out the Work and perform construction as required by the Contract Documents. Contractor shall at all times maintain good discipline and order at the Site. B. Except as otherwise required for the safety or protection of persons or the Work or property at the Site or adjacent thereto, and except as otherwise stated in the Contract Documents, all Work at the Site shall be performed during regular working hours. Contractor will not permit the performance of Work on a Saturday, Sunday, or any legal holiday without Owner’s written consent (which will not be unreasonably withheld) given after prior written notice to Engineer. 6.3 Services, Materials, and Equipment A. Unless otherwise specified in the Contract Documents, Contractor shall provide and assume full responsibility for all services, materials, equipment, labor, transportation, construction equipment and machinery, tools, appliances, fuel, power, light, heat, telephone, water, sanitary facilities, temporary facilities, and all other facilities and incidentals necessary for the performance, testing, start-up, and completion of the Work. B. All materials and equipment incorporated into the Work shall be as specified or, if not specified, shall be of good quality and new, except as otherwise provided in the Contract Documents. All special warranties and guarantees required by the Specifications shall expressly run to the benefit of Owner. If required by Engineer, Contractor shall furnish satisfactory evidence (including reports of required tests) as to the source, kind, and quality of materials and equipment. C. All materials and equipment shall be stored, applied, installed, connected, erected, protected, used, cleaned, and conditioned in accordance with instructions of the applicable Supplier, except as otherwise may be provided in the Contract Documents. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 23 of 62 6.4 Progress Schedule A. Contractor shall adhere to the Progress Schedule established in accordance with Paragraph 2.07 as it may be adjusted from time to time as provided below. 1.Contractor shall submit to Engineer for acceptance (to the extent indicated in Paragraph 2.07) proposed adjustments in the Progress Schedule that will not result in changing the Contract Times. Such adjustments will comply with any provisions of the General Requirements applicable thereto. 2.Proposed adjustments in the Progress Schedule that will change the Contract Times shall be submitted in accordance with the requirements of Article 12. Adjustments in Contract Times may only be made by a Change Order. 6.5 Substitutes and “Or-Equals” A. Whenever an item of material or equipment is specified or described in the Contract Documents by using the name of a proprietary item or the name of a particular Supplier, the specification or description is intended to establish the type, function, appearance, and quality required. Unless the specification or description contains or is followed by words reading that no like, equivalent, or “or-equal” item or no substitution is permitted, other items of material or equipment or material or equipment of other Suppliers may be submitted to Engineer for review under the circumstances described below. 1.“Or-Equal” Items: If in Engineer’s sole discretion an item of material or equipment proposed by Contractor is functionally equal to that named and sufficiently similar so that no change in related Work will be required, it may be considered by Engineer as an “or-equal” item, in which case review and approval of the proposed item may, in Engineer’s sole discretion, be accomplished without compliance with some or all of the requirements for approval of proposed substitute items. For the purposes of this Paragraph 6.05.A.1, a proposed item of material or equipment will be considered functionally equal to an item so named if: a.in the exercise of reasonable judgment Engineer determines that: 1)it is at least equal in materials of construction, quality, durability, appearance, strength, and design characteristics; 2)it will reliably perform at least equally well the function and achieve the results imposed by the design concept of the completed Project as a functioning whole; and 3)it has a proven record of performance and availability of responsive service. b.Contractor certifies that, if approved and incorporated into the Work: 1)there will be no increase in cost to the Owner or increase in Contract Times; and 2)it will conform substantially to the detailed requirements of the item named in the Contract Documents. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 24 of 62 2.Substitute Items: a.If in Engineer’s sole discretion an item of material or equipment proposed by Contractor does not qualify as an “or-equal” item under Paragraph 6.05.A.1, it will be considered a proposed substitute item. b.Contractor shall submit sufficient information as provided below to allow Engineer to determine if the item of material or equipment proposed is essentially equivalent to that named and an acceptable substitute therefor. Requests for review of proposed substitute items of material or equipment will not be accepted by Engineer from anyone other than Contractor. c.The requirements for review by Engineer will be as set forth in Paragraph 6.05.A.2.d, as supplemented by the General Requirements, and as Engineer may decide is appropriate under the circumstances. d.Contractor shall make written application to Engineer for review of a proposed substitute item of material or equipment that Contractor seeks to furnish or use. The application: 1)shall certify that the proposed substitute item will: a)perform adequately the functions and achieve the results called for by the general design, b)be similar in substance to that specified, and c)be suited to the same use as that specified; 2)will state: a)the extent, if any, to which the use of the proposed substitute item will prejudice Contractor’s achievement of Substantial Completion on time, b)whether use of the proposed substitute item in the Work will require a change in any of the Contract Documents (or in the provisions of any other direct contract with Owner for other work on the Project) to adapt the design to the proposed substitute item, and c)whether incorporation or use of the proposed substitute item in connection with the Work is subject to payment of any license fee or royalty; 3)will identify: a)all variations of the proposed substitute item from that specified, and b)available engineering, sales, maintenance, repair, and replacement services; and EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 25 of 62 4)shall contain an itemized estimate of all costs or credits that will result directly or indirectly from use of such substitute item, including costs of redesign and claims of other contractors affected by any resulting change. B.Substitute Construction Methods or Procedures:If a specific means, method, technique, sequence, or procedure of construction is expressly required by the Contract Documents, Contractor may furnish or utilize a substitute means, method, technique, sequence, or procedure of construction approved by Engineer. Contractor shall submit sufficient information to allow Engineer, in Engineer’s sole discretion, to determine that the substitute proposed is equivalent to that expressly called for by the Contract Documents. The requirements for review by Engineer will be similar to those provided in Paragraph 6.05.A.2. C.Engineer’s Evaluation: Engineer will be allowed a reasonable time within which to evaluate each proposal or submittal made pursuant to Paragraphs 6.05.A and 6.05.B. Engineer may require Contractor to furnish additional data about the proposed substitute item. Engineer will be the sole judge of acceptability. No “or equal” or substitute will be ordered, installed or utilized until Engineer’s review is complete, which will be evidenced by a Change Order in the case of a substitute and an approved Shop Drawing for an “or equal.” Engineer will advise Contractor in writing of any negative determination. D.Special Guarantee: Owner may require Contractor to furnish at Contractor’s expense a special performance guarantee or other surety with respect to any substitute. E.Engineer’s Cost Reimbursement: Engineer will record Engineer’s costs in evaluating a substitute proposed or submitted by Contractor pursuant to Paragraphs 6.05.A.2 and 6.05.B. Whether or not Engineer approves a substitute so proposed or submitted by Contractor, Contractor shall reimburse Owner for the reasonable charges of Engineer for evaluating each such proposed substitute. Contractor shall also reimburse Owner for the reasonable charges of Engineer for making changes in the Contract Documents (or in the provisions of any other direct contract with Owner) resulting from the acceptance of each proposed substitute. F.Contractor’s Expense: Contractor shall provide all data in support of any proposed substitute or “or-equal” at Contractor’s expense. 6.6 Concerning Subcontractors, Suppliers, and Others A. Contractor shall not employ any Subcontractor, Supplier, or other individual or entity (including those acceptable to Owner as indicated in Paragraph 6.06.B), whether initially or as a replacement, against whom Owner may have reasonable objection. Contractor shall not be required to employ any Subcontractor, Supplier, or other individual or entity to furnish or perform any of the Work against whom Contractor has reasonable objection. B. If the Supplementary Conditions require the identity of certain Subcontractors, Suppliers, or other individuals or entities to be submitted to Owner in advance for acceptance by Owner by a specified date prior to the Effective Date of the Agreement, and if Contractor has submitted a list thereof in accordance with the Supplementary Conditions, Owner’s acceptance (either in writing or by failing to make written objection thereto by the date indicated for acceptance or objection EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 26 of 62 in the Bidding Documents or the Contract Documents) of any such Subcontractor, Supplier, or EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 27 of 62 other individual or entity so identified may be revoked on the basis of reasonable objection after due investigation. Contractor shall submit an acceptable replacement for the rejected Subcontractor, Supplier, or other individual or entity, and the Contract Price will be adjusted by the difference in the cost occasioned by such replacement, and an appropriate Change Order will be issued. No acceptance by Owner of any such Subcontractor, Supplier, or other individual or entity, whether initially or as a replacement, shall constitute a waiver of any right of Owner or Engineer to reject defective Work. C. Contractor shall be fully responsible to Owner and Engineer for all acts and omissions of the Subcontractors, Suppliers, and other individuals or entities performing or furnishing any of the Work just as Contractor is responsible for Contractor’s own acts and omissions. Nothing in the Contract Documents: 1.shall create for the benefit of any such Subcontractor, Supplier, or other individual or entity any contractual relationship between Owner or Engineer and any such Subcontractor, Supplier or other individual or entity; nor 2.shall create any obligation on the part of Owner or Engineer to pay or to see to the payment of any moneys due any such Subcontractor, Supplier, or other individual or entity except as may otherwise be required by Laws and Regulations. D. Contractor shall be solely responsible for scheduling and coordinating the Work of Subcontractors, Suppliers, and other individuals or entities performing or furnishing any of the Work under a direct or indirect contract with Contractor. E.Contractor shall require all Subcontractors, Suppliers, and such other individuals or entities performing or furnishing any of the Work to communicate with Engineer through Contractor. F.The divisions and sections of the Specifications and the identifications of any Drawings shall not control Contractor in dividing the Work among Subcontractors or Suppliers or delineating the Work to be performed by any specific trade. G. All Work performed for Contractor by a Subcontractor or Supplier will be pursuant to an appropriate agreement between Contractor and the Subcontractor or Supplier which specifically binds the Subcontractor or Supplier to the applicable terms and conditions of the Contract Documents for the benefit of Owner and Engineer. Whenever any such agreement is with a Subcontractor or Supplier who is listed as a loss payee on the property insurance provided in Paragraph 5.06, the agreement between the Contractor and the Subcontractor or Supplier will contain provisions whereby the Subcontractor or Supplier waives all rights against Owner, Contractor, Engineer, and all other individuals or entities identified in the Supplementary Conditions to be listed as insureds or loss payees (and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them) for all losses and damages caused by, arising out of, relating to, or resulting from any of the perils or causes of loss covered by such policies and any other property insurance applicable to the Work. If the insurers on any such policies require separate waiver forms to be signed by any Subcontractor or Supplier, Contractor will obtain the same. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 28 of 62 6.7 Patent Fees and Royalties A. Contractor shall pay all license fees and royalties and assume all costs incident to the use in the performance of the Work or the incorporation in the Work of any invention, design, process, product, or device which is the subject of patent rights or copyrights held by others. If a particular invention, design, process, product, or device is specified in the Contract Documents for use in the performance of the Work and if, to the actual knowledge of Owner or Engineer, its use is subject to patent rights or copyrights calling for the payment of any license fee or royalty to others, the existence of such rights shall be disclosed by Owner in the Contract Documents. B. To the fullest extent permitted by Laws and Regulations, Owner shall indemnify and hold harmless Contractor, and its officers, directors, members, partners, employees, agents, consultants, and subcontractors from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals, and all court or arbitration or other dispute resolution costs) arising out of or relating to any infringement of patent rights or copyrights incident to the use in the performance of the Work or resulting from the incorporation in the Work of any invention, design, process, product, or device specified in the Contract Documents, but not identified as being subject to payment of any license fee or royalty to others required by patent rights or copyrights. C. To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless Owner and Engineer, and the officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to any infringement of patent rights or copyrights incident to the use in the performance of the Work or resulting from the incorporation in the Work of any invention, design, process, product, or device not specified in the Contract Documents. 6.8 Permits A. Unless otherwise provided in the Supplementary Conditions, Contractor shall obtain and pay for all construction permits and licenses. Owner shall assist Contractor, when necessary, in obtaining such permits and licenses. Contractor shall pay all governmental charges and inspection fees necessary for the prosecution of the Work which are applicable at the time of opening of Bids, or, if there are no Bids, on the Effective Date of the Agreement. Owner shall pay all charges of utility owners for connections for providing permanent service to the Work. 6.9 Laws and Regulations A. Contractor shall give all notices required by and shall comply with all Laws and Regulations applicable to the performance of the Work. Except where otherwise expressly required by applicable Laws and Regulations, neither Owner nor Engineer shall be responsible for monitoring Contractor’s compliance with any Laws or Regulations. B. If Contractor performs any Work knowing or having reason to know that it is contrary to Laws or Regulations, Contractor shall bear all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 29 of 62 court or arbitration or other dispute resolution costs) arising out of or relating to such Work. However, it shall not be Contractor’s responsibility to make certain that the Specifications and Drawings are in accordance with Laws and Regulations, but this shall not relieve Contractor of Contractor’s obligations under Paragraph 3.03. C. Changes in Laws or Regulations not known at the time of opening of Bids (or, on the Effective Date of the Agreement if there were no Bids) having an effect on the cost or time of performance of the Work shall be the subject of an adjustment in Contract Price or Contract Times. If Owner and Contractor are unable to agree on entitlement to or on the amount or extent, if any, of any such adjustment, a Claim may be made therefor as provided in Paragraph 10.05. 6.10 Taxes A. Contractor shall pay all sales, consumer, use, and other similar taxes required to be paid by Contractor in accordance with the Laws and Regulations of the place of the Project which are applicable during the performance of the Work. 6.11Use of Site and Other Areas A.Limitation on Use of Site and Other Areas: 1.Contractor shall confine construction equipment, the storage of materials and equipment, and the operations of workers to the Site and other areas permitted by Laws and Regulations, and shall not unreasonably encumber the Site and other areas with construction equipment or other materials or equipment. Contractor shall assume full responsibility for any damage to any such land or area, or to the owner or occupant thereof, or of any adjacent land or areas resulting from the performance of the Work. 2.Should any claim be made by any such owner or occupant because of the performance of the Work, Contractor shall promptly settle with such other party by negotiation or otherwise resolve the claim by arbitration or other dispute resolution proceeding or at law. 3.To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless Owner and Engineer, and the officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to any claim or action, legal or equitable, brought by any such owner or occupant against Owner, Engineer, or any other party indemnified hereunder to the extent caused by or based upon Contractor’s performance of the Work. B.Removal of Debris During Performance of the Work: During the progress of the Work Contractor shall keep the Site and other areas free from accumulations of waste materials, rubbish, and other debris. Removal and disposal of such waste materials, rubbish, and other debris shall conform to applicable Laws and Regulations. C.Cleaning: Prior to Substantial Completion of the Work Contractor shall clean the Site and the Work and make it ready for utilization by Owner. At the completion of the Work Contractor EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 30 of 62 shall remove from the Site all tools, appliances, construction equipment and machinery, and surplus materials and shall restore to original condition all property not designated for alteration by the Contract Documents. D.Loading Structures: Contractor shall not load nor permit any part of any structure to be loaded in any manner that will endanger the structure, nor shall Contractor subject any part of the Work or adjacent property to stresses or pressures that will endanger it. 6.12Record Documents A. Contractor shall maintain in a safe place at the Site one record copy of all Drawings, Specifications, Addenda, Change Orders, Work Change Directives, Field Orders, and written interpretations and clarifications in good order and annotated to show changes made during construction. These record documents together with all approved Samples and a counterpart of all approved Shop Drawings will be available to Engineer for reference. Upon completion of the Work, these record documents, Samples, and Shop Drawings will be delivered to Engineer for Owner. 6.13Safety and Protection A. Contractor shall be solely responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the Work. Such responsibility does not relieve Subcontractors of their responsibility for the safety of persons or property in the performance of their work, nor for compliance with applicable safety Laws and Regulations. Contractor shall take all necessary precautions for the safety of, and shall provide the necessary protection to prevent damage, injury or loss to: 1.all persons on the Site or who may be affected by the Work; 2.all the Work and materials and equipment to be incorporated therein, whether in storage on or off the Site; and 3.other property at the Site or adjacent thereto, including trees, shrubs, lawns, walks, pavements, roadways, structures, utilities, and Underground Facilities not designated for removal, relocation, or replacement in the course of construction. B. Contractor shall comply with all applicable Laws and Regulations relating to the safety of persons or property, or to the protection of persons or property from damage, injury, or loss; and shall erect and maintain all necessary safeguards for such safety and protection. Contractor shall notify owners of adjacent property and of Underground Facilities and other utility owners when prosecution of the Work may affect them, and shall cooperate with them in the protection, removal, relocation, and replacement of their property. C.Contractor shall comply with the applicable requirements of Owner’s safety programs, if any. The Supplementary Conditions identify any Owner’s safety programs that are applicable to the Work. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 31 of 62 D. Contractor shall inform Owner and Engineer of the specific requirements of Contractor’s safety program with which Owner’s and Engineer’s employees and representatives must comply while at the Site. E.All damage, injury, or loss to any property referred to in Paragraph 6.13.A.2 or 6.13.A.3 caused, directly or indirectly, in whole or in part, by Contractor, any Subcontractor, Supplier, or any other individual or entity directly or indirectly employed by any of them to perform any of the Work, or anyone for whose acts any of them may be liable, shall be remedied by Contractor (except damage or loss attributable to the fault of Drawings or Specifications or to the acts or omissions of Owner or Engineer or anyone employed by any of them, or anyone for whose acts any of them may be liable, and not attributable, directly or indirectly, in whole or in part, to the fault or negligence of Contractor or any Subcontractor, Supplier, or other individual or entity directly or indirectly employed by any of them). F.Contractor’s duties and responsibilities for safety and for protection of the Work shall continue until such time as all the Work is completed and Engineer has issued a notice to Owner and Contractor in accordance with Paragraph 14.07.B that the Work is acceptable (except as otherwise expressly provided in connection with Substantial Completion). 6.14Safety Representative A. Contractor shall designate a qualified and experienced safety representative at the Site whose duties and responsibilities shall be the prevention of accidents and the maintaining and supervising of safety precautions and programs. 6.15Hazard Communication Programs A. Contractor shall be responsible for coordinating any exchange of material safety data sheets or other hazard communication information required to be made available to or exchanged between or among employers at the Site in accordance with Laws or Regulations. 6.16 Emergencies A. In emergencies affecting the safety or protection of persons or the Work or property at the Site or adjacent thereto, Contractor is obligated to act to prevent threatened damage, injury, or loss. Contractor shall give Engineer prompt written notice if Contractor believes that any significant changes in the Work or variations from the Contract Documents have been caused thereby or are required as a result thereof. If Engineer determines that a change in the Contract Documents is required because of the action taken by Contractor in response to such an emergency, a Work Change Directive or Change Order will be issued. 6.17Shop Drawings and Samples A. Contractor shall submit Shop Drawings and Samples to Engineer for review and approval in accordance with the accepted Schedule of Submittals (as required by Paragraph 2.07). Each submittal will be identified as Engineer may require. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 32 of 62 1.Shop Drawings: a.Submit number of copies specified in the General Requirements. b.Data shown on the Shop Drawings will be complete with respect to quantities, dimensions, specified performance and design criteria, materials, and similar data to show Engineer the services, materials, and equipment Contractor proposes to provide and to enable Engineer to review the information for the limited purposes required by Paragraph 6.17.D. 2.Samples: a.Submit number of Samples specified in the Specifications. b.Clearly identify each Sample as to material, Supplier, pertinent data such as catalog numbers, the use for which intended and other data as Engineer may require to enable Engineer to review the submittal for the limited purposes required by Paragraph 6.17.D. B. Where a Shop Drawing or Sample is required by the Contract Documents or the Schedule of Submittals, any related Work performed prior to Engineer’s review and approval of the pertinent submittal will be at the sole expense and responsibility of Contractor. C.Submittal Procedures: 1.Before submitting each Shop Drawing or Sample, Contractor shall have: a.reviewed and coordinated each Shop Drawing or Sample with other Shop Drawings and Samples and with the requirements of the Work and the Contract Documents; b.determined and verified all field measurements, quantities, dimensions, specified performance and design criteria, installation requirements, materials, catalog numbers, and similar information with respect thereto; c.determined and verified the suitability of all materials offered with respect to the indicated application, fabrication, shipping, handling, storage, assembly, and installation pertaining to the performance of the Work; and d.determined and verified all information relative to Contractor’s responsibilities for means, methods, techniques, sequences, and procedures of construction, and safety precautions and programs incident thereto. 2.Each submittal shall bear a stamp or specific written certification that Contractor has satisfied Contractor’s obligations under the Contract Documents with respect to Contractor’s review and approval of that submittal. 3.With each submittal, Contractor shall give Engineer specific written notice of any variations that the Shop Drawing or Sample may have from the requirements of the Contract Documents. This notice shall be both a written communication separate from the Shop EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 33 of 62 Drawings or Sample submittal; and, in addition, by a specific notation made on each Shop Drawing or Sample submitted to Engineer for review and approval of each such variation. D.Engineer’s Review: 1.Engineer will provide timely review of Shop Drawings and Samples in accordance with the Schedule of Submittals acceptable to Engineer. Engineer’s review and approval will be only to determine if the items covered by the submittals will, after installation or incorporation in the Work, conform to the information given in the Contract Documents and be compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. 2.Engineer’s review and approval will not extend to means, methods, techniques, sequences, or procedures of construction (except where a particular means, method, technique, sequence, or procedure of construction is specifically and expressly called for by the Contract Documents) or to safety precautions or programs incident thereto. The review and approval of a separate item as such will not indicate approval of the assembly in which the item functions. 3.Engineer’s review and approval shall not relieve Contractor from responsibility for any variation from the requirements of the Contract Documents unless Contractor has complied with the requirements of Paragraph 6.17.C.3 and Engineer has given written approval of each such variation by specific written notation thereof incorporated in or accompanying the Shop Drawing or Sample. Engineer’s review and approval shall not relieve Contractor from responsibility for complying with the requirements of Paragraph 6.17.C.1. E.Resubmittal Procedures: 1.Contractor shall make corrections required by Engineer and shall return the required number of corrected copies of Shop Drawings and submit, as required, new Samples for review and approval. Contractor shall direct specific attention in writing to revisions other than the corrections called for by Engineer on previous submittals. 6.18 Continuing the Work A. Contractor shall carry on the Work and adhere to the Progress Schedule during all disputes or disagreements with Owner. No Work shall be delayed or postponed pending resolution of any disputes or disagreements, except as permitted by Paragraph 15.04 or as Owner and Contractor may otherwise agree in writing. 6.19Contractor’s General Warranty and Guarantee A. Contractor warrants and guarantees to Owner that all Work will be in accordance with the Contract Documents and will not be defective. Engineer and its officers, directors, members, partners, employees, agents, consultants, and subcontractors shall be entitled to rely on representation of Contractor’s warranty and guarantee. B.Contractor’s warranty and guarantee hereunder excludes defects or damage caused by: EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 34 of 62 1.abuse, modification, or improper maintenance or operation by persons other than Contractor, Subcontractors, Suppliers, or any other individual or entity for whom Contractor is responsible; or 2.normal wear and tear under normal usage. C. Contractor’s obligation to perform and complete the Work in accordance with the Contract Documents shall be absolute. None of the following will constitute an acceptance of Work that is not in accordance with the Contract Documents or a release of Contractor’s obligation to perform the Work in accordance with the Contract Documents: 1.observations by Engineer; 2.recommendation by Engineer or payment by Owner of any progress or final payment; 3.the issuance of a certificate of Substantial Completion by Engineer or any payment related thereto by Owner; 4.use or occupancy of the Work or any part thereof by Owner; 5.any review and approval of a Shop Drawing or Sample submittal or the issuance of a notice of acceptability by Engineer; 6.any inspection, test, or approval by others; or 7.any correction of defective Work by Owner. 6.20 Indemnification A. To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless Owner and Engineer, and the officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to the performance of the Work, provided that any such claim, cost, loss, or damage is attributable to bodily injury, sickness, disease, or death, or to injury to or destruction of tangible property (other than the Work itself), including the loss of use resulting therefrom but only to the extent caused by any negligent act or omission of Contractor, any Subcontractor, any Supplier, or any individual or entity directly or indirectly employed by any of them to perform any of the Work or anyone for whose acts any of them may be liable . B. In any and all claims against Owner or Engineer or any of their officers, directors, members, partners, employees, agents, consultants, or subcontractors by any employee (or the survivor or personal representative of such employee) of Contractor, any Subcontractor, any Supplier, or any individual or entity directly or indirectly employed by any of them to perform any of the Work, or anyone for whose acts any of them may be liable, the indemnification obligation under Paragraph 6.20.A shall not be limited in any way by any limitation on the amount or type of damages, compensation, or benefits payable by or for Contractor or any such Subcontractor, EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 35 of 62 Supplier, or other individual or entity under workers’ compensation acts, disability benefit acts, or other employee benefit acts. C. The indemnification obligations of Contractor under Paragraph 6.20.A shall not extend to the liability of Engineer and Engineer’s officers, directors, members, partners, employees, agents, consultants and subcontractors arising out of: 1.the preparation or approval of, or the failure to prepare or approve maps, Drawings, opinions, reports, surveys, Change Orders, designs, or Specifications; or 2.giving directions or instructions, or failing to give them, if that is the primary cause of the injury or damage. 6.21Delegation of Professional Design Services A. Contractor will not be required to provide professional design services unless such services are specifically required by the Contract Documents for a portion of the Work or unless such services are required to carry out Contractor’s responsibilities for construction means, methods, techniques, sequences and procedures. Contractor shall not be required to provide professional services in violation of applicable law. B. If professional design services or certifications by a design professional related to systems, materials or equipment are specifically required of Contractor by the Contract Documents, Owner and Engineer will specify all performance and design criteria that such services must satisfy. Contractor shall cause such services or certifications to be provided by a properly licensed professional, whose signature and seal shall appear on all drawings, calculations, specifications, certifications, Shop Drawings and other submittals prepared by such professional. Shop Drawings and other submittals related to the Work designed or certified by such professional, if prepared by others, shall bear such professional’s written approval when submitted to Engineer. C. Owner and Engineer shall be entitled to rely upon the adequacy, accuracy and completeness of the services, certifications or approvals performed by such design professionals, provided Owner and Engineer have specified to Contractor all performance and design criteria that such services must satisfy. D. Pursuant to this Paragraph 6.21, Engineer’s review and approval of design calculations and design drawings will be only for the limited purpose of checking for conformance with performance and design criteria given and the design concept expressed in the Contract Documents. Engineer’s review and approval of Shop Drawings and other submittals (except design calculations and design drawings) will be only for the purpose stated in Paragraph 6.17.D.1. E.Contractor shall not be responsible for the adequacy of the performance or design criteria required by the Contract Documents. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 36 of 62 ARTICLE 7 – OTHER WORK AT THE SITE 7.1 Related Work at Site A. Owner may perform other work related to the Project at the Site with Owner’s employees, or through other direct contracts therefor, or have other work performed by utility owners. If such other work is not noted in the Contract Documents, then: 1. written notice thereof will be given to Contractor prior to starting any such other work; and 2. if Owner and Contractor are unable to agree on entitlement to or on the amount or extent, if any, of any adjustment in the Contract Price or Contract Times that should be allowed as a result of such other work, a Claim may be made therefor as provided in Paragraph 10.05. B. Contractor shall afford each other contractor who is a party to such a direct contract, each utility owner, and Owner, if Owner is performing other work with Owner’s employees, proper and safe access to the Site, provide a reasonable opportunity for the introduction and storage of materials and equipment and the execution of such other work, and properly coordinate the Work with theirs. Contractor shall do all cutting, fitting, and patching of the Work that may be required to properly connect or otherwise make its several parts come together and properly integrate with such other work. Contractor shall not endanger any work of others by cutting, excavating, or otherwise altering such work; provided, however, that Contractor may cut or alter others' work with the written consent of Engineer and the others whose work will be affected. The duties and responsibilities of Contractor under this Paragraph are for the benefit of such utility owners and other contractors to the extent that there are comparable provisions for the benefit of Contractor in said direct contracts between Owner and such utility owners and other contractors. C. If the proper execution or results of any part of Contractor’s Work depends upon work performed by others under this Article 7, Contractor shall inspect such other work and promptly report to Engineer in writing any delays, defects, or deficiencies in such other work that render it unavailable or unsuitable for the proper execution and results of Contractor’s Work. Contractor’s failure to so report will constitute an acceptance of such other work as fit and proper for integration with Contractor’s Work except for latent defects and deficiencies in such other work. 7.2 Coordination A. If Owner intends to contract with others for the performance of other work on the Project at the Site, the following will be set forth in Supplementary Conditions: 1. the individual or entity who will have authority and responsibility for coordination of the activities among the various contractors will be identified; 2. the specific matters to be covered by such authority and responsibility will be itemized; and 3. the extent of such authority and responsibilities will be provided. B. Unless otherwise provided in the Supplementary Conditions, Owner shall have sole authority and responsibility for such coordination. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 37 of 62 7.3 Legal Relationships A. Paragraphs 7.01.A and 7.02 are not applicable for utilities not under the control of Owner. B. Each other direct contract of Owner under Paragraph 7.01.A shall provide that the other contractor is liable to Owner and Contractor for the reasonable direct delay and disruption costs incurred by Contractor as a result of the other contractor’s wrongful actions or inactions. C. Contractor shall be liable to Owner and any other contractor under direct contract to Owner for the reasonable direct delay and disruption costs incurred by such other contractor as a result of Contractor’s wrongful action or inactions. ARTICLE 8 – OWNER’S RESPONSIBILITIES 8.1 Communications to Contractor A. Except as otherwise provided in these General Conditions, Owner shall issue all communications to Contractor through Engineer. 8.2 Replacement of Engineer A. In case of termination of the employment of Engineer, Owner shall appoint an engineer to whom Contractor makes no reasonable objection, whose status under the Contract Documents shall be that of the former Engineer. 8.3 Furnish Data A. Owner shall promptly furnish the data required of Owner under the Contract Documents. 8.4 Pay When Due A. Owner shall make payments to Contractor when they are due as provided in Paragraphs 14.02.C and 14.07.C. 8.5 Lands and Easements; Reports and Tests A. Owner’s duties with respect to providing lands and easements and providing engineering surveys to establish reference points are set forth in Paragraphs 4.01 and 4.05. Paragraph 4.02 refers to Owner’s identifying and making available to Contractor copies of reports of explorations and tests of subsurface conditions and drawings of physical conditions relating to existing surface or subsurface structures at the Site. 8.6 Insurance A. Owner’s responsibilities, if any, with respect to purchasing and maintaining liability and property insurance are set forth in Article 5. 8.7 Change Orders A. Owner is obligated to execute Change Orders as indicated in Paragraph 10.03. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 38 of 62 8.8 Inspections, Tests, and Approvals A. Owner’s responsibility with respect to certain inspections, tests, and approvals is set forth in Paragraph 13.03.B. 8.9 Limitations on Owner’s Responsibilities A. The Owner shall not supervise, direct, or have control or authority over, nor be responsible for, Contractor’s means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the performance of the Work. Owner will not be responsible for Contractor’s failure to perform the Work in accordance with the Contract Documents. 8.10 Undisclosed Hazardous Environmental Condition A. Owner’s responsibility in respect to an undisclosed Hazardous Environmental Condition is set forth in Paragraph 4.06. 8.11 Evidence of Financial Arrangements A. Upon request of Contractor, Owner shall furnish Contractor reasonable evidence that financial arrangements have been made to satisfy Owner’s obligations under the Contract Documents. 8.12 Compliance with Safety Program A. While at the Site, Owner’s employees and representatives shall comply with the specific applicable requirements of Contractor’s safety programs of which Owner has been informed pursuant to Paragraph 6.13.D. ARTICLE 9 – ENGINEER’S STATUS DURING CONSTRUCTION 9.1 Owner’s Representative A. Engineer will be Owner’s representative during the construction period. The duties and responsibilities and the limitations of authority of Engineer as Owner’s representative during construction are set forth in the Contract Documents. 9.2 Visits to Site A. Engineer will make visits to the Site at intervals appropriate to the various stages of construction as Engineer deems necessary in order to observe as an experienced and qualified design professional the progress that has been made and the quality of the various aspects of Contractor’s executed Work. Based on information obtained during such visits and observations, Engineer, for the benefit of Owner, will determine, in general, if the Work is proceeding in accordance with the Contract Documents. Engineer will not be required to make exhaustive or continuous inspections on the Site to check the quality or quantity of the Work. Engineer’s efforts will be directed toward providing for Owner a greater degree of confidence that the completed Work will conform generally to the Contract Documents. On the basis of such visits EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 39 of 62 and observations, Engineer will keep Owner informed of the progress of the Work and will endeavor to guard Owner against defective Work. B. Engineer’s visits and observations are subject to all the limitations on Engineer’s authority and responsibility set forth in Paragraph 9.09. Particularly, but without limitation, during or as a result of Engineer’s visits or observations of Contractor’s Work, Engineer will not supervise, direct, control, or have authority over or be responsible for Contractor’s means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the performance of the Work. 9.3 Project Representative A. If Owner and Engineer agree, Engineer will furnish a Resident Project Representative to assist Engineer in providing more extensive observation of the Work. The authority and responsibilities of any such Resident Project Representative and assistants will be as provided in the Supplementary Conditions, and limitations on the responsibilities thereof will be as provided in Paragraph 9.09. If Owner designates another representative or agent to represent Owner at the Site who is not Engineer’s consultant, agent or employee, the responsibilities and authority and limitations thereon of such other individual or entity will be as provided in the Supplementary Conditions. 9.4 Authorized Variations in Work A. Engineer may authorize minor variations in the Work from the requirements of the Contract Documents which do not involve an adjustment in the Contract Price or the Contract Times and are compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. These may be accomplished by a Field Order and will be binding on Owner and also on Contractor, who shall perform the Work involved promptly. If Owner or Contractor believes that a Field Order justifies an adjustment in the Contract Price or Contract Times, or both, and the parties are unable to agree on entitlement to or on the amount or extent, if any, of any such adjustment, a Claim may be made therefor as provided in Paragraph 10.05. 9.5 Rejecting Defective Work A. Engineer will have authority to reject Work which Engineer believes to be defective, or that Engineer believes will not produce a completed Project that conforms to the Contract Documents or that will prejudice the integrity of the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. Engineer will also have authority to require special inspection or testing of the Work as provided in Paragraph 13.04, whether or not the Work is fabricated, installed, or completed. 9.6 Shop Drawings, Change Orders and Payments A. In connection with Engineer’s authority, and limitations thereof, as to Shop Drawings and Samples, see Paragraph 6.17. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 40 of 62 B. In connection with Engineer’s authority, and limitations thereof, as to design calculations and design drawings submitted in response to a delegation of professional design services, if any, see Paragraph 6.21. C. In connection with Engineer’s authority as to Change Orders, see Articles 10, 11, and 12. D. In connection with Engineer’s authority as to Applications for Payment, see Article 14. 9.7 Determinations for Unit Price Work A. Engineer will determine the actual quantities and classifications of Unit Price Work performed by Contractor. Engineer will review with Contractor the Engineer’s preliminary determinations on such matters before rendering a written decision thereon (by recommendation of an Application for Payment or otherwise). Engineer’s written decision thereon will be final and binding (except as modified by Engineer to reflect changed factual conditions or more accurate data) upon Owner and Contractor, subject to the provisions of Paragraph 10.05. 9.8 Decisions on Requirements of Contract Documents and Acceptability of Work A. Engineer will be the initial interpreter of the requirements of the Contract Documents and judge of the acceptability of the Work thereunder. All matters in question and other matters between Owner and Contractor arising prior to the date final payment is due relating to the acceptability of the Work, and the interpretation of the requirements of the Contract Documents pertaining to the performance of the Work, will be referred initially to Engineer in writing within 30 days of the event giving rise to the question. B. Engineer will, with reasonable promptness, render a written decision on the issue referred. If Owner or Contractor believes that any such decision entitles them to an adjustment in the Contract Price or Contract Times or both, a Claim may be made under Paragraph 10.05. The date of Engineer’s decision shall be the date of the event giving rise to the issues referenced for the purposes of Paragraph 10.05.B. C. Engineer’s written decision on the issue referred will be final and binding on Owner and Contractor, subject to the provisions of Paragraph 10.05. D. When functioning as interpreter and judge under this Paragraph 9.08, Engineer will not show partiality to Owner or Contractor and will not be liable in connection with any interpretation or decision rendered in good faith in such capacity. 9.9 Limitations on Engineer’s Authority and Responsibilities A. Neither Engineer’s authority or responsibility under this Article 9 or under any other provision of the Contract Documents nor any decision made by Engineer in good faith either to exercise or not exercise such authority or responsibility or the undertaking, exercise, or performance of any authority or responsibility by Engineer shall create, impose, or give rise to any duty in contract, tort, or otherwise owed by Engineer to Contractor, any Subcontractor, any Supplier, any other individual or entity, or to any surety for or employee or agent of any of them. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 41 of 62 B. Engineer will not supervise, direct, control, or have authority over or be responsible for Contractor’s means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the performance of the Work. Engineer will not be responsible for Contractor’s failure to perform the Work in accordance with the Contract Documents. C. Engineer will not be responsible for the acts or omissions of Contractor or of any Subcontractor, any Supplier, or of any other individual or entity performing any of the Work. D. Engineer’s review of the final Application for Payment and accompanying documentation and all maintenance and operating instructions, schedules, guarantees, bonds, certificates of inspection, tests and approvals, and other documentation required to be delivered by Paragraph 14.07.A will only be to determine generally that their content complies with the requirements of, and in the case of certificates of inspections, tests, and approvals that the results certified indicate compliance with, the Contract Documents. E. The limitations upon authority and responsibility set forth in this Paragraph 9.09 shall also apply to the Resident Project Representative, if any, and assistants, if any. 9.10 Compliance with Safety Program A. While at the Site, Engineer’s employees and representatives shall comply with the specific applicable requirements of Contractor’s safety programs of which Engineer has been informed pursuant to Paragraph 6.13.D. ARTICLE 10 – CHANGES IN THE WORK; CLAIMS 10.1 Authorized Changes in the Work A. Without invalidating the Contract and without notice to any surety, Owner may, at any time or from time to time, order additions, deletions, or revisions in the Work by a Change Order, or a Work Change Directive. Upon receipt of any such document, Contractor shall promptly proceed with the Work involved which will be performed under the applicable conditions of the Contract Documents (except as otherwise specifically provided). B. If Owner and Contractor are unable to agree on entitlement to, or on the amount or extent, if any, of an adjustment in the Contract Price or Contract Times, or both, that should be allowed as a result of a Work Change Directive, a Claim may be made therefor as provided in Paragraph 10.05. 10.2 Unauthorized Changes in the Work A. Contractor shall not be entitled to an increase in the Contract Price or an extension of the Contract Times with respect to any work performed that is not required by the Contract Documents as amended, modified, or supplemented as provided in Paragraph 3.04, except in the case of an emergency as provided in Paragraph 6.16 or in the case of uncovering Work as provided in Paragraph 13.04.D. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 42 of 62 10.3 Execution of Change Orders A. Owner and Contractor shall execute appropriate Change Orders recommended by Engineer covering: 1. changes in the Work which are: (i) ordered by Owner pursuant to Paragraph 10.01.A, (ii) required because of acceptance of defective Work under Paragraph 13.08.A or Owner’s correction of defective Work under Paragraph 13.09, or (iii) agreed to by the parties; 2. changes in the Contract Price or Contract Times which are agreed to by the parties, including any undisputed sum or amount of time for Work actually performed in accordance with a Work Change Directive; and 3. changes in the Contract Price or Contract Times which embody the substance of any written decision rendered by Engineer pursuant to Paragraph 10.05; provided that, in lieu of executing any such Change Order, an appeal may be taken from any such decision in accordance with the provisions of the Contract Documents and applicable Laws and Regulations, but during any such appeal, Contractor shall carry on the Work and adhere to the Progress Schedule as provided in Paragraph 6.18.A. 10.4 Notification to Surety A. If the provisions of any bond require notice to be given to a surety of any change affecting the general scope of the Work or the provisions of the Contract Documents (including, but not limited to, Contract Price or Contract Times), the giving of any such notice will be Contractor’s responsibility. The amount of each applicable bond will be adjusted to reflect the effect of any such change. 10.5 Claims A.Engineer’s Decision Required: All Claims, except those waived pursuant to Paragraph 14.09, shall be referred to the Engineer for decision. A decision by Engineer shall be required as a condition precedent to any exercise by Owner or Contractor of any rights or remedies either may otherwise have under the Contract Documents or by Laws and Regulations in respect of such Claims. B.Notice: Written notice stating the general nature of each Claim shall be delivered by the claimant to Engineer and the other party to the Contract promptly (but in no event later than 30 days) after the start of the event giving rise thereto. The responsibility to substantiate a Claim shall rest with the party making the Claim. Notice of the amount or extent of the Claim, with supporting data shall be delivered to the Engineer and the other party to the Contract within 60 days after the start of such event (unless Engineer allows additional time for claimant to submit additional or more accurate data in support of such Claim). A Claim for an adjustment in Contract Price shall be prepared in accordance with the provisions of Paragraph 12.01.B. A Claim for an adjustment in Contract Times shall be prepared in accordance with the provisions of Paragraph 12.02.B. Each Claim shall be accompanied by claimant’s written statement that the adjustment claimed is the entire adjustment to which the claimant believes it is entitled as a result of said event. The EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 43 of 62 opposing party shall submit any response to Engineer and the claimant within 30 days after receipt of the claimant’s last submittal (unless Engineer allows additional time). C.Engineer’s Action: Engineer will review each Claim and, within 30 days after receipt of the last submittal of the claimant or the last submittal of the opposing party, if any, take one of the following actions in writing: 1. deny the Claim in whole or in part; 2. approve the Claim; or 3. notify the parties that the Engineer is unable to resolve the Claim if, in the Engineer’s sole discretion, it would be inappropriate for the Engineer to do so. For purposes of further resolution of the Claim, such notice shall be deemed a denial. D. In the event that Engineer does not take action on a Claim within said 30 days, the Claim shall be deemed denied. E. Engineer’s written action under Paragraph 10.05.C or denial pursuant to Paragraphs 10.05.C.3 or 10.05.D will be final and binding upon Owner and Contractor, unless Owner or Contractor invoke the dispute resolution procedure set forth in Article 16 within 30 days of such action or denial. F. No Claim for an adjustment in Contract Price or Contract Times will be valid if not submitted in accordance with this Paragraph 10.05. ARTICLE 11 – COST OF THE WORK; ALLOWANCES; UNIT PRICE WORK 11.1 Cost of the Work A.Costs Included: The term Cost of the Work means the sum of all costs, except those excluded in Paragraph 11.01.B, necessarily incurred and paid by Contractor in the proper performance of the Work. When the value of any Work covered by a Change Order or when a Claim for an adjustment in Contract Price is determined on the basis of Cost of the Work, the costs to be reimbursed to Contractor will be only those additional or incremental costs required because of the change in the Work or because of the event giving rise to the Claim. Except as otherwise may be agreed to in writing by Owner, such costs shall be in amounts no higher than those prevailing in the locality of the Project, shall not include any of the costs itemized in Paragraph 11.01.B, and shall include only the following items: 1. Payroll costs for employees in the direct employ of Contractor in the performance of the Work under schedules of job classifications agreed upon by Owner and Contractor. Such employees shall include, without limitation, superintendents, foremen, and other personnel employed full time on the Work. Payroll costs for employees not employed full time on the Work shall be apportioned on the basis of their time spent on the Work. Payroll costs shall include, but not be limited to, salaries and wages plus the cost of fringe benefits, which shall include social security contributions, unemployment, excise, and payroll taxes, workers’ compensation, health and retirement benefits, bonuses, sick leave, vacation and holiday pay applicable thereto. The expenses of performing Work outside of regular working hours, on EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 44 of 62 Saturday, Sunday, or legal holidays, shall be included in the above to the extent authorized by Owner. 2. Cost of all materials and equipment furnished and incorporated in the Work, including costs of transportation and storage thereof, and Suppliers’ field services required in connection therewith. All cash discounts shall accrue to Contractor unless Owner deposits funds with Contractor with which to make payments, in which case the cash discounts shall accrue to Owner. All trade discounts, rebates and refunds and returns from sale of surplus materials and equipment shall accrue to Owner, and Contractor shall make provisions so that they may be obtained. 3. Payments made by Contractor to Subcontractors for Work performed by Subcontractors. If required by Owner, Contractor shall obtain competitive bids from subcontractors acceptable to Owner and Contractor and shall deliver such bids to Owner, who will then determine, with the advice of Engineer, which bids, if any, will be acceptable. If any subcontract provides that the Subcontractor is to be paid on the basis of Cost of the Work plus a fee, the Subcontractor’s Cost of the Work and fee shall be determined in the same manner as Contractor’s Cost of the Work and fee as provided in this Paragraph 11.01. 4. Costs of special consultants (including but not limited to engineers, architects, testing laboratories, surveyors, attorneys, and accountants) employed for services specifically related to the Work. 5. Supplemental costs including the following: a. The proportion of necessary transportation, travel, and subsistence expenses of Contractor’s employees incurred in discharge of duties connected with the Work. b. Cost, including transportation and maintenance, of all materials, supplies, equipment, machinery, appliances, office, and temporary facilities at the Site, and hand tools not owned by the workers, which are consumed in the performance of the Work, and cost, less market value, of such items used but not consumed which remain the property of Contractor. c. Rentals of all construction equipment and machinery, and the parts thereof whether rented from Contractor or others in accordance with rental agreements approved by Owner with the advice of Engineer, and the costs of transportation, loading, unloading, assembly, dismantling, and removal thereof. All such costs shall be in accordance with the terms of said rental agreements. The rental of any such equipment, machinery, or parts shall cease when the use thereof is no longer necessary for the Work. d. Sales, consumer, use, and other similar taxes related to the Work, and for which Contractor is liable, as imposed by Laws and Regulations. e. Deposits lost for causes other than negligence of Contractor, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable, and royalty payments and fees for permits and licenses. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 45 of 62 f. Losses and damages (and related expenses) caused by damage to the Work, not compensated by insurance or otherwise, sustained by Contractor in connection with the performance of the Work (except losses and damages within the deductible amounts of property insurance established in accordance with Paragraph 5.06.D), provided such losses and damages have resulted from causes other than the negligence of Contractor, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable. Such losses shall include settlements made with the written consent and approval of Owner. No such losses, damages, and expenses shall be included in the Cost of the Work for the purpose of determining Contractor’s fee. g. The cost of utilities, fuel, and sanitary facilities at the Site. h. Minor expenses such as telegrams, long distance telephone calls, telephone service at the Site, express and courier services, and similar petty cash items in connection with the Work. i. The costs of premiums for all bonds and insurance Contractor is required by the Contract Documents to purchase and maintain. B.Costs Excluded: The term Cost of the Work shall not include any of the following items: 1. Payroll costs and other compensation of Contractor’s officers, executives, principals (of partnerships and sole proprietorships), general managers, safety managers, engineers, architects, estimators, attorneys, auditors, accountants, purchasing and contracting agents, expediters, timekeepers, clerks, and other personnel employed by Contractor, whether at the Site or in Contractor’s principal or branch office for general administration of the Work and not specifically included in the agreed upon schedule of job classifications referred to in Paragraph 11.01.A.1 or specifically covered by Paragraph 11.01.A.4, all of which are to be considered administrative costs covered by the Contractor’s fee. 2. Expenses of Contractor’s principal and branch offices other than Contractor’s office at the Site. 3. Any part of Contractor’s capital expenses, including interest on Contractor’s capital employed for the Work and charges against Contractor for delinquent payments. 4. Costs due to the negligence of Contractor, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable, including but not limited to, the correction of defective Work, disposal of materials or equipment wrongly supplied, and making good any damage to property. 5. Other overhead or general expense costs of any kind and the costs of any item not specifically and expressly included in Paragraphs 11.01.A. C.Contractor’s Fee: When all the Work is performed on the basis of cost-plus, Contractor’s fee shall be determined as set forth in the Agreement. When the value of any Work covered by a Change Order or when a Claim for an adjustment in Contract Price is determined on the basis of Cost of the Work, Contractor’s fee shall be determined as set forth in Paragraph 12.01.C. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 46 of 62 D.Documentation: Whenever the Cost of the Work for any purpose is to be determined pursuant to Paragraphs 11.01.A and 11.01.B, Contractor will establish and maintain records thereof in accordance with generally accepted accounting practices and submit in a form acceptable to Engineer an itemized cost breakdown together with supporting data. 11.2 Allowances A. It is understood that Contractor has included in the Contract Price all allowances so named in the Contract Documents and shall cause the Work so covered to be performed for such sums and by such persons or entities as may be acceptable to Owner and Engineer. B.Cash Allowances: 1. Contractor agrees that: a. the cash allowances include the cost to Contractor (less any applicable trade discounts) of materials and equipment required by the allowances to be delivered at the Site, and all applicable taxes; and b. Contractor’s costs for unloading and handling on the Site, labor, installation, overhead, profit, and other expenses contemplated for the cash allowances have been included in the Contract Price and not in the allowances, and no demand for additional payment on account of any of the foregoing will be valid. C.Contingency Allowance: 1. Contractor agrees that a contingency allowance, if any, is for the sole use of Owner to cover unanticipated costs. D. Prior to final payment, an appropriate Change Order will be issued as recommended by Engineer to reflect actual amounts due Contractor on account of Work covered by allowances, and the Contract Price shall be correspondingly adjusted. 11.3 Unit Price Work A. Where the Contract Documents provide that all or part of the Work is to be Unit Price Work, initially the Contract Price will be deemed to include for all Unit Price Work an amount equal to the sum of the unit price for each separately identified item of Unit Price Work times the estimated quantity of each item as indicated in the Agreement. B. The estimated quantities of items of Unit Price Work are not guaranteed and are solely for the purpose of comparison of Bids and determining an initial Contract Price. Determinations of the actual quantities and classifications of Unit Price Work performed by Contractor will be made by Engineer subject to the provisions of Paragraph 9.07. C. Each unit price will be deemed to include an amount considered by Contractor to be adequate to cover Contractor’s overhead and profit for each separately identified item. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 47 of 62 D. Owner or Contractor may make a Claim for an adjustment in the Contract Price in accordance with Paragraph 10.05 if: 1. the quantity of any item of Unit Price Work performed by Contractor differs materially and significantly from the estimated quantity of such item indicated in the Agreement; and 2. there is no corresponding adjustment with respect to any other item of Work; and 3. Contractor believes that Contractor is entitled to an increase in Contract Price as a result of having incurred additional expense or Owner believes that Owner is entitled to a decrease in Contract Price and the parties are unable to agree as to the amount of any such increase or decrease. ARTICLE 12 – CHANGE OF CONTRACT PRICE; CHANGE OF CONTRACT TIMES 12.1 Change of Contract Price A. The Contract Price may only be changed by a Change Order. Any Claim for an adjustment in the Contract Price shall be based on written notice submitted by the party making the Claim to the Engineer and the other party to the Contract in accordance with the provisions of Paragraph 10.05. B. The value of any Work covered by a Change Order or of any Claim for an adjustment in the Contract Price will be determined as follows: 1. where the Work involved is covered by unit prices contained in the Contract Documents, by application of such unit prices to the quantities of the items involved (subject to the provisions of Paragraph 11.03); or 2. where the Work involved is not covered by unit prices contained in the Contract Documents, by a mutually agreed lump sum (which may include an allowance for overhead and profit not necessarily in accordance with Paragraph 12.01.C.2); or 3. where the Work involved is not covered by unit prices contained in the Contract Documents and agreement to a lump sum is not reached under Paragraph 12.01.B.2, on the basis of the Cost of the Work (determined as provided in Paragraph 11.01) plus a Contractor’s fee for overhead and profit (determined as provided in Paragraph 12.01.C). C.Contractor’s Fee: The Contractor’s fee for overhead and profit shall be determined as follows: 1. a mutually acceptable fixed fee; or 2. if a fixed fee is not agreed upon, then a fee based on the following percentages of the various portions of the Cost of the Work: a. for costs incurred under Paragraphs 11.01.A.1 and 11.01.A.2, the Contractor’s fee shall be 15 percent; b. for costs incurred under Paragraph 11.01.A.3, the Contractor’s fee shall be five percent; EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 48 of 62 c. where one or more tiers of subcontracts are on the basis of Cost of the Work plus a fee and no fixed fee is agreed upon, the intent of Paragraphs 12.01.C.2.a and 12.01.C.2.b is that the Subcontractor who actually performs the Work, at whatever tier, will be paid a fee of 15 percent of the costs incurred by such Subcontractor under Paragraphs 11.01.A.1 and 11.01.A.2 and that any higher tier Subcontractor and Contractor will each be paid a fee of five percent of the amount paid to the next lower tier Subcontractor; d. no fee shall be payable on the basis of costs itemized under Paragraphs 11.01.A.4, 11.01.A.5, and 11.01.B; e. the amount of credit to be allowed by Contractor to Owner for any change which results in a net decrease in cost will be the amount of the actual net decrease in cost plus a deduction in Contractor’s fee by an amount equal to five percent of such net decrease; and f. when both additions and credits are involved in any one change, the adjustment in Contractor’s fee shall be computed on the basis of the net change in accordance with Paragraphs 12.01.C.2.a through 12.01.C.2.e, inclusive. 12.2 Change of Contract Times A. The Contract Times may only be changed by a Change Order. Any Claim for an adjustment in the Contract Times shall be based on written notice submitted by the party making the Claim to the Engineer and the other party to the Contract in accordance with the provisions of Paragraph 10.05. B. Any adjustment of the Contract Times covered by a Change Order or any Claim for an adjustment in the Contract Times will be determined in accordance with the provisions of this Article 12. 12.3 Delays A. Where Contractor is prevented from completing any part of the Work within the Contract Times due to delay beyond the control of Contractor, the Contract Times will be extended in an amount equal to the time lost due to such delay if a Claim is made therefor as provided in Paragraph 12.02.A. Delays beyond the control of Contractor shall include, but not be limited to, acts or neglect by Owner, acts or neglect of utility owners or other contractors performing other work as contemplated by Article 7, fires, floods, epidemics, abnormal weather conditions, or acts of God. B. If Owner, Engineer, or other contractors or utility owners performing other work for Owner as contemplated by Article 7, or anyone for whom Owner is responsible, delays, disrupts, or interferes with the performance or progress of the Work, then Contractor shall be entitled to an equitable adjustment in the Contract Price or the Contract Times, or both. Contractor’s entitlement to an adjustment of the Contract Times is conditioned on such adjustment being essential to Contractor’s ability to complete the Work within the Contract Times. C. If Contractor is delayed in the performance or progress of the Work by fire, flood, epidemic, abnormal weather conditions, acts of God, acts or failures to act of utility owners not under the EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 49 of 62 control of Owner, or other causes not the fault of and beyond control of Owner and Contractor, then Contractor shall be entitled to an equitable adjustment in Contract Times, if such adjustment is essential to Contractor’s ability to complete the Work within the Contract Times. Such an adjustment shall be Contractor’s sole and exclusive remedy for the delays described in this Paragraph 12.03.C. D. Owner, Engineer, and their officers, directors, members, partners, employees, agents, consultants, or subcontractors shall not be liable to Contractor for any claims, costs, losses, or damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) sustained by Contractor on or in connection with any other project or anticipated project. E. Contractor shall not be entitled to an adjustment in Contract Price or Contract Times for delays within the control of Contractor. Delays attributable to and within the control of a Subcontractor or Supplier shall be deemed to be delays within the control of Contractor. ARTICLE 13 – TESTS AND INSPECTIONS; CORRECTION, REMOVAL OR ACCEPTANCE OF DEFECTIVE WORK 13.1 Notice of Defects A. Prompt notice of all defective Work of which Owner or Engineer has actual knowledge will be given to Contractor. Defective Work may be rejected, corrected, or accepted as provided in this Article 13. 13.2 Access to Work A. Owner, Engineer, their consultants and other representatives and personnel of Owner, independent testing laboratories, and governmental agencies with jurisdictional interests will have access to the Site and the Work at reasonable times for their observation, inspection, and testing. Contractor shall provide them proper and safe conditions for such access and advise them of Contractor’s safety procedures and programs so that they may comply therewith as applicable. 13.3 Tests and Inspections A. Contractor shall give Engineer timely notice of readiness of the Work for all required inspections, tests, or approvals and shall cooperate with inspection and testing personnel to facilitate required inspections or tests. B. Owner shall employ and pay for the services of an independent testing laboratory to perform all inspections, tests, or approvals required by the Contract Documents except: 1.for inspections, tests, or approvals covered by Paragraphs 13.03.C and 13.03.D below; 2.that costs incurred in connection with tests or inspections conducted pursuant to Paragraph 13.04.B shall be paid as provided in Paragraph 13.04.C; and 3.as otherwise specifically provided in the Contract Documents. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 50 of 62 C. If Laws or Regulations of any public body having jurisdiction require any Work (or part thereof) specifically to be inspected, tested, or approved by an employee or other representative of such public body, Contractor shall assume full responsibility for arranging and obtaining such inspections, tests, or approvals, pay all costs in connection therewith, and furnish Engineer the required certificates of inspection or approval. D. Contractor shall be responsible for arranging and obtaining and shall pay all costs in connection with any inspections, tests, or approvals required for Owner’s and Engineer’s acceptance of materials or equipment to be incorporated in the Work; or acceptance of materials, mix designs, or equipment submitted for approval prior to Contractor’s purchase thereof for incorporation in the Work. Such inspections, tests, or approvals shall be performed by organizations acceptable to Owner and Engineer. E.If any Work (or the work of others) that is to be inspected, tested, or approved is covered by Contractor without written concurrence of Engineer, Contractor shall, if requested by Engineer, uncover such Work for observation. F.Uncovering Work as provided in Paragraph 13.03.E shall be at Contractor’s expense unless Contractor has given Engineer timely notice of Contractor’s intention to cover the same and Engineer has not acted with reasonable promptness in response to such notice. 13.4 Uncovering Work A. If any Work is covered contrary to the written request of Engineer, it must, if requested by Engineer, be uncovered for Engineer’s observation and replaced at Contractor’s expense. B. If Engineer considers it necessary or advisable that covered Work be observed by Engineer or inspected or tested by others, Contractor, at Engineer’s request, shall uncover, expose, or otherwise make available for observation, inspection, or testing as Engineer may require, that portion of the Work in question, furnishing all necessary labor, material, and equipment. C. If it is found that the uncovered Work is defective, Contractor shall pay all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such uncovering, exposure, observation, inspection, and testing, and of satisfactory replacement or reconstruction (including but not limited to all costs of repair or replacement of work of others); and Owner shall be entitled to an appropriate decrease in the Contract Price. If the parties are unable to agree as to the amount thereof, Owner may make a Claim therefor as provided in Paragraph 10.05. D. If the uncovered Work is not found to be defective, Contractor shall be allowed an increase in the Contract Price or an extension of the Contract Times, or both, directly attributable to such uncovering, exposure, observation, inspection, testing, replacement, and reconstruction. If the parties are unable to agree as to the amount or extent thereof, Contractor may make a Claim therefor as provided in Paragraph 10.05. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 51 of 62 13.5 Owner May Stop the Work A. If the Work is defective, or Contractor fails to supply sufficient skilled workers or suitable materials or equipment, or fails to perform the Work in such a way that the completed Work will conform to the Contract Documents, Owner may order Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, this right of Owner to stop the Work shall not give rise to any duty on the part of Owner to exercise this right for the benefit of Contractor, any Subcontractor, any Supplier, any other individual or entity, or any surety for, or employee or agent of any of them. 13.6 Correction or Removal of Defective Work A. Promptly after receipt of written notice, Contractor shall correct all defective Work, whether or not fabricated, installed, or completed, or, if the Work has been rejected by Engineer, remove it from the Project and replace it with Work that is not defective. Contractor shall pay all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such correction or removal (including but not limited to all costs of repair or replacement of work of others). B. When correcting defective Work under the terms of this Paragraph 13.06 or Paragraph 13.07, Contractor shall take no action that would void or otherwise impair Owner’s special warranty and guarantee, if any, on said Work. 13.7 Correction Period A. If within one year after the date of Substantial Completion (or such longer period of time as may be prescribed by the terms of any applicable special guarantee required by the Contract Documents) or by any specific provision of the Contract Documents, any Work is found to be defective, or if the repair of any damages to the land or areas made available for Contractor’s use by Owner or permitted by Laws and Regulations as contemplated in Paragraph 6.11.A is found to be defective, Contractor shall promptly, without cost to Owner and in accordance with Owner’s written instructions: 1.repair such defective land or areas; or 2.correct such defective Work; or 3.if the defective Work has been rejected by Owner, remove it from the Project and replace it with Work that is not defective, and 4.satisfactorily correct or repair or remove and replace any damage to other Work, to the work of others or other land or areas resulting therefrom. B. If Contractor does not promptly comply with the terms of Owner’s written instructions, or in an emergency where delay would cause serious risk of loss or damage, Owner may have the defective Work corrected or repaired or may have the rejected Work removed and replaced. All claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 52 of 62 resolution costs) arising out of or relating to such correction or repair or such removal and replacement (including but not limited to all costs of repair or replacement of work of others) will be paid by Contractor. C. In special circumstances where a particular item of equipment is placed in continuous service before Substantial Completion of all the Work, the correction period for that item may start to run from an earlier date if so provided in the Specifications. D. Where defective Work (and damage to other Work resulting therefrom) has been corrected or removed and replaced under this Paragraph 13.07, the correction period hereunder with respect to such Work will be extended for an additional period of one year after such correction or removal and replacement has been satisfactorily completed. E.Contractor’s obligations under this Paragraph 13.07 are in addition to any other obligation or warranty. The provisions of this Paragraph 13.07 shall not be construed as a substitute for, or a waiver of, the provisions of any applicable statute of limitation or repose. 13.8 Acceptance of Defective Work A. If, instead of requiring correction or removal and replacement of defective Work, Owner (and, prior to Engineer’s recommendation of final payment, Engineer) prefers to accept it, Owner may do so. Contractor shall pay all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) attributable to Owner’s evaluation of and determination to accept such defective Work (such costs to be approved by Engineer as to reasonableness) and for the diminished value of the Work to the extent not otherwise paid by Contractor pursuant to this sentence. If any such acceptance occurs prior to Engineer’s recommendation of final payment, a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Work, and Owner shall be entitled to an appropriate decrease in the Contract Price, reflecting the diminished value of Work so accepted. If the parties are unable to agree as to the amount thereof, Owner may make a Claim therefor as provided in Paragraph 10.05. If the acceptance occurs after such recommendation, an appropriate amount will be paid by Contractor to Owner. 13.9 Owner May Correct Defective Work A. If Contractor fails within a reasonable time after written notice from Engineer to correct defective Work, or to remove and replace rejected Work as required by Engineer in accordance with Paragraph 13.06.A, or if Contractor fails to perform the Work in accordance with the Contract Documents, or if Contractor fails to comply with any other provision of the Contract Documents, Owner may, after seven days written notice to Contractor, correct, or remedy any such deficiency. B. In exercising the rights and remedies under this Paragraph 13.09, Owner shall proceed expeditiously. In connection with such corrective or remedial action, Owner may exclude Contractor from all or part of the Site, take possession of all or part of the Work and suspend Contractor’s services related thereto, take possession of Contractor’s tools, appliances, construction equipment and machinery at the Site, and incorporate in the Work all materials and EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 53 of 62 equipment stored at the Site or for which Owner has paid Contractor but which are stored elsewhere. Contractor shall allow Owner, Owner’s representatives, agents and employees, Owner’s other contractors, and Engineer and Engineer’s consultants access to the Site to enable Owner to exercise the rights and remedies under this Paragraph. C. All claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) incurred or sustained by Owner in exercising the rights and remedies under this Paragraph 13.09 will be charged against Contractor, and a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Work; and Owner shall be entitled to an appropriate decrease in the Contract Price. If the parties are unable to agree as to the amount of the adjustment, Owner may make a Claim therefor as provided in Paragraph 10.05. Such claims, costs, losses and damages will include but not be limited to all costs of repair, or replacement of work of others destroyed or damaged by correction, removal, or replacement of Contractor’s defective Work. D. Contractor shall not be allowed an extension of the Contract Times because of any delay in the performance of the Work attributable to the exercise by Owner of Owner’s rights and remedies under this Paragraph 13.09. ARTICLE 14 – PAYMENTS TO CONTRACTOR AND COMPLETION 14.1 Schedule of Values A. The Schedule of Values established as provided in Paragraph 2.07.A will serve as the basis for progress payments and will be incorporated into a form of Application for Payment acceptable to Engineer. Progress payments on account of Unit Price Work will be based on the number of units completed. 14.2 Progress Payments A.Applications for Payments: 1. At least 20 days before the date established in the Agreement for each progress payment (but not more often than once a month), Contractor shall submit to Engineer for review an Application for Payment filled out and signed by Contractor covering the Work completed as of the date of the Application and accompanied by such supporting documentation as is required by the Contract Documents. If payment is requested on the basis of materials and equipment not incorporated in the Work but delivered and suitably stored at the Site or at another location agreed to in writing, the Application for Payment shall also be accompanied by a bill of sale, invoice, or other documentation warranting that Owner has received the materials and equipment free and clear of all Liens and evidence that the materials and equipment are covered by appropriate property insurance or other arrangements to protect Owner’s interest therein, all of which must be satisfactory to Owner. 2. Beginning with the second Application for Payment, each Application shall include an affidavit of Contractor stating that all previous progress payments received on account of the EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 54 of 62 Work have been applied on account to discharge Contractor’s legitimate obligations associated with prior Applications for Payment. 3. The amount of retainage with respect to progress payments will be as stipulated in the Agreement. B.Review of Applications: 1. Engineer will, within 10 days after receipt of each Application for Payment, either indicate in writing a recommendation of payment and present the Application to Owner or return the Application to Contractor indicating in writing Engineer’s reasons for refusing to recommend payment. In the latter case, Contractor may make the necessary corrections and resubmit the Application. 2. Engineer’s recommendation of any payment requested in an Application for Payment will constitute a representation by Engineer to Owner, based on Engineer’s observations of the executed Work as an experienced and qualified design professional, and on Engineer’s review of the Application for Payment and the accompanying data and schedules, that to the best of Engineer’s knowledge, information and belief: a. the Work has progressed to the point indicated; b. the quality of the Work is generally in accordance with the Contract Documents (subject to an evaluation of the Work as a functioning whole prior to or upon Substantial Completion, the results of any subsequent tests called for in the Contract Documents, a final determination of quantities and classifications for Unit Price Work under Paragraph 9.07, and any other qualifications stated in the recommendation); and c. the conditions precedent to Contractor’s being entitled to such payment appear to have been fulfilled in so far as it is Engineer’s responsibility to observe the Work. 3. By recommending any such payment Engineer will not thereby be deemed to have represented that: a. inspections made to check the quality or the quantity of the Work as it has been performed have been exhaustive, extended to every aspect of the Work in progress, or involved detailed inspections of the Work beyond the responsibilities specifically assigned to Engineer in the Contract Documents; or b. there may not be other matters or issues between the parties that might entitle Contractor to be paid additionally by Owner or entitle Owner to withhold payment to Contractor. 4. Neither Engineer’s review of Contractor’s Work for the purposes of recommending payments nor Engineer’s recommendation of any payment, including final payment, will impose responsibility on Engineer: a. to supervise, direct, or control the Work, or EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 55 of 62 b. for the means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or c. for Contractor’s failure to comply with Laws and Regulations applicable to Contractor’s performance of the Work, or d. to make any examination to ascertain how or for what purposes Contractor has used the moneys paid on account of the Contract Price, or e. to determine that title to any of the Work, materials, or equipment has passed to Owner free and clear of any Liens. 5. Engineer may refuse to recommend the whole or any part of any payment if, in Engineer’s opinion, it would be incorrect to make the representations to Owner stated in Paragraph 14.02.B.2. Engineer may also refuse to recommend any such payment or, because of subsequently discovered evidence or the results of subsequent inspections or tests, revise or revoke any such payment recommendation previously made, to such extent as may be necessary in Engineer’s opinion to protect Owner from loss because: a. the Work is defective, or completed Work has been damaged, requiring correction or replacement; b. the Contract Price has been reduced by Change Orders; c. Owner has been required to correct defective Work or complete Work in accordance with Paragraph 13.09; or d. Engineer has actual knowledge of the occurrence of any of the events enumerated in Paragraph 15.02.A. C.Payment Becomes Due: 1. Ten days after presentation of the Application for Payment to Owner with Engineer’s recommendation, the amount recommended will (subject to the provisions of Paragraph 14.02.D) become due, and when due will be paid by Owner to Contractor. D.Reduction in Payment: 1. Owner may refuse to make payment of the full amount recommended by Engineer because: a. claims have been made against Owner on account of Contractor’s performance or furnishing of the Work; b. Liens have been filed in connection with the Work, except where Contractor has delivered a specific bond satisfactory to Owner to secure the satisfaction and discharge of such Liens; c. there are other items entitling Owner to a set-off against the amount recommended; or EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 56 of 62 d. Owner has actual knowledge of the occurrence of any of the events enumerated in Paragraphs 14.02.B.5.a through 14.02.B.5.c or Paragraph 15.02.A. 2. If Owner refuses to make payment of the full amount recommended by Engineer, Owner will give Contractor immediate written notice (with a copy to Engineer) stating the reasons for such action and promptly pay Contractor any amount remaining after deduction of the amount so withheld. Owner shall promptly pay Contractor the amount so withheld, or any adjustment thereto agreed to by Owner and Contractor, when Contractor remedies the reasons for such action. 3. Upon a subsequent determination that Owner’s refusal of payment was not justified, the amount wrongfully withheld shall be treated as an amount due as determined by Paragraph 14.02.C.1 and subject to interest as provided in the Agreement. 14.03 Contractor’s Warranty of Title A. Contractor warrants and guarantees that title to all Work, materials, and equipment covered by any Application for Payment, whether incorporated in the Project or not, will pass to Owner no later than the time of payment free and clear of all Liens. 14.4 Substantial Completion A. When Contractor considers the entire Work ready for its intended use Contractor shall notify Owner and Engineer in writing that the entire Work is substantially complete (except for items specifically listed by Contractor as incomplete) and request that Engineer issue a certificate of Substantial Completion. B. Promptly after Contractor’s notification, Owner, Contractor, and Engineer shall make an inspection of the Work to determine the status of completion. If Engineer does not consider the Work substantially complete, Engineer will notify Contractor in writing giving the reasons therefor. C. If Engineer considers the Work substantially complete, Engineer will deliver to Owner a tentative certificate of Substantial Completion which shall fix the date of Substantial Completion. There shall be attached to the certificate a tentative list of items to be completed or corrected before final payment. Owner shall have seven days after receipt of the tentative certificate during which to make written objection to Engineer as to any provisions of the certificate or attached list. If, after considering such objections, Engineer concludes that the Work is not substantially complete, Engineer will, within 14 days after submission of the tentative certificate to Owner, notify Contractor in writing, stating the reasons therefor. If, after consideration of Owner’s objections, Engineer considers the Work substantially complete, Engineer will, within said 14 days, execute and deliver to Owner and Contractor a definitive certificate of Substantial Completion (with a revised tentative list of items to be completed or corrected) reflecting such changes from the tentative certificate as Engineer believes justified after consideration of any objections from Owner. D. At the time of delivery of the tentative certificate of Substantial Completion, Engineer will deliver to Owner and Contractor a written recommendation as to division of responsibilities EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 57 of 62 pending final payment between Owner and Contractor with respect to security, operation, safety, and protection of the Work, maintenance, heat, utilities, insurance, and warranties and guarantees. Unless Owner and Contractor agree otherwise in writing and so inform Engineer in writing prior to Engineer’s issuing the definitive certificate of Substantial Completion, Engineer’s aforesaid recommendation will be binding on Owner and Contractor until final payment. E. Owner shall have the right to exclude Contractor from the Site after the date of Substantial Completion subject to allowing Contractor reasonable access to remove its property and complete or correct items on the tentative list. 14.5 Partial Utilization A. Prior to Substantial Completion of all the Work, Owner may use or occupy any substantially completed part of the Work which has specifically been identified in the Contract Documents, or which Owner, Engineer, and Contractor agree constitutes a separately functioning and usable part of the Work that can be used by Owner for its intended purpose without significant interference with Contractor’s performance of the remainder of the Work, subject to the following conditions: 1.Owner at any time may request Contractor in writing to permit Owner to use or occupy any such part of the Work which Owner believes to be ready for its intended use and substantially complete. If and when Contractor agrees that such part of the Work is substantially complete, Contractor, Owner, and Engineer will follow the procedures of Paragraph 14.04.A through D for that part of the Work. 2.Contractor at any time may notify Owner and Engineer in writing that Contractor considers any such part of the Work ready for its intended use and substantially complete and request Engineer to issue a certificate of Substantial Completion for that part of the Work. 3.Within a reasonable time after either such request, Owner, Contractor, and Engineer shall make an inspection of that part of the Work to determine its status of completion. If Engineer does not consider that part of the Work to be substantially complete, Engineer will notify Owner and Contractor in writing giving the reasons therefor. If Engineer considers that part of the Work to be substantially complete, the provisions of Paragraph 14.04 will apply with respect to certification of Substantial Completion of that part of the Work and the division of responsibility in respect thereof and access thereto. 4.No use or occupancy or separate operation of part of the Work may occur prior to compliance with the requirements of Paragraph 5.10 regarding property insurance. 14.6 Final Inspection A. Upon written notice from Contractor that the entire Work or an agreed portion thereof is complete, Engineer will promptly make a final inspection with Owner and Contractor and will notify Contractor in writing of all particulars in which this inspection reveals that the Work is incomplete or defective. Contractor shall immediately take such measures as are necessary to complete such Work or remedy such deficiencies. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 58 of 62 14.7 Final Payment A.Application for Payment: 1. After Contractor has, in the opinion of Engineer, satisfactorily completed all corrections identified during the final inspection and has delivered, in accordance with the Contract Documents, all maintenance and operating instructions, schedules, guarantees, bonds, certificates or other evidence of insurance, certificates of inspection, marked-up record documents (as provided in Paragraph 6.12), and other documents, Contractor may make application for final payment following the procedure for progress payments. 2. The final Application for Payment shall be accompanied (except as previously delivered) by: a. all documentation called for in the Contract Documents, including but not limited to the evidence of insurance required by Paragraph 5.04.B.6; b. consent of the surety, if any, to final payment; c. a list of all Claims against Owner that Contractor believes are unsettled; and d. complete and legally effective releases or waivers (satisfactory to Owner) of all Lien rights arising out of or Liens filed in connection with the Work. 3. In lieu of the releases or waivers of Liens specified in Paragraph 14.07.A.2 and as approved by Owner, Contractor may furnish receipts or releases in full and an affidavit of Contractor that: (i) the releases and receipts include all labor, services, material, and equipment for which a Lien could be filed; and (ii) all payrolls, material and equipment bills, and other indebtedness connected with the Work for which Owner might in any way be responsible, or which might in any way result in liens or other burdens on Owner's property, have been paid or otherwise satisfied. If any Subcontractor or Supplier fails to furnish such a release or receipt in full, Contractor may furnish a bond or other collateral satisfactory to Owner to indemnify Owner against any Lien. B.Engineer’s Review of Application and Acceptance: 1. If, on the basis of Engineer’s observation of the Work during construction and final inspection, and Engineer’s review of the final Application for Payment and accompanying documentation as required by the Contract Documents, Engineer is satisfied that the Work has been completed and Contractor’s other obligations under the Contract Documents have been fulfilled, Engineer will, within ten days after receipt of the final Application for Payment, indicate in writing Engineer’s recommendation of payment and present the Application for Payment to Owner for payment. At the same time Engineer will also give written notice to Owner and Contractor that the Work is acceptable subject to the provisions of Paragraph 14.09. Otherwise, Engineer will return the Application for Payment to Contractor, indicating in writing the reasons for refusing to recommend final payment, in which case Contractor shall make the necessary corrections and resubmit the Application for Payment. C.Payment Becomes Due: EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 59 of 62 1. Thirty days after the presentation to Owner of the Application for Payment and accompanying documentation, the amount recommended by Engineer, less any sum Owner is entitled to set off against Engineer’s recommendation, including but not limited to liquidated damages, will become due and will be paid by Owner to Contractor. 14.8 Final Completion Delayed A. If, through no fault of Contractor, final completion of the Work is significantly delayed, and if Engineer so confirms, Owner shall, upon receipt of Contractor’s final Application for Payment (for Work fully completed and accepted) and recommendation of Engineer, and without terminating the Contract, make payment of the balance due for that portion of the Work fully completed and accepted. If the remaining balance to be held by Owner for Work not fully completed or corrected is less than the retainage stipulated in the Agreement, and if bonds have been furnished as required in Paragraph 5.01, the written consent of the surety to the payment of the balance due for that portion of the Work fully completed and accepted shall be submitted by Contractor to Engineer with the Application for such payment. Such payment shall be made under the terms and conditions governing final payment, except that it shall not constitute a waiver of Claims. 14.9 Waiver of Claims A. The making and acceptance of final payment will constitute: 1. a waiver of all Claims by Owner against Contractor, except Claims arising from unsettled Liens, from defective Work appearing after final inspection pursuant to Paragraph 14.06, from failure to comply with the Contract Documents or the terms of any special guarantees specified therein, or from Contractor’s continuing obligations under the Contract Documents; and 2. a waiver of all Claims by Contractor against Owner other than those previously made in accordance with the requirements herein and expressly acknowledged by Owner in writing as still unsettled. ARTICLE 15 – SUSPENSION OF WORK AND TERMINATION 15.1 Owner May Suspend Work A. At any time and without cause, Owner may suspend the Work or any portion thereof for a period of not more than 90 consecutive days by notice in writing to Contractor and Engineer which will fix the date on which Work will be resumed. Contractor shall resume the Work on the date so fixed. Contractor shall be granted an adjustment in the Contract Price or an extension of the Contract Times, or both, directly attributable to any such suspension if Contractor makes a Claim therefor as provided in Paragraph 10.05. 15.2 Owner May Terminate for Cause A. The occurrence of any one or more of the following events will justify termination for cause: EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 60 of 62 1. Contractor’s persistent failure to perform the Work in accordance with the Contract Documents (including, but not limited to, failure to supply sufficient skilled workers or suitable materials or equipment or failure to adhere to the Progress Schedule established under Paragraph 2.07 as adjusted from time to time pursuant to Paragraph 6.04); 2. Contractor’s disregard of Laws or Regulations of any public body having jurisdiction; 3. Contractor’s repeated disregard of the authority of Engineer; or 4. Contractor’s violation in any substantial way of any provisions of the Contract Documents. B. If one or more of the events identified in Paragraph 15.02.A occur, Owner may, after giving Contractor (and surety) seven days written notice of its intent to terminate the services of Contractor: 1. exclude Contractor from the Site, and take possession of the Work and of all Contractor’s tools, appliances, construction equipment, and machinery at the Site, and use the same to the full extent they could be used by Contractor (without liability to Contractor for trespass or conversion); 2. incorporate in the Work all materials and equipment stored at the Site or for which Owner has paid Contractor but which are stored elsewhere; and 3. complete the Work as Owner may deem expedient. C. If Owner proceeds as provided in Paragraph 15.02.B, Contractor shall not be entitled to receive any further payment until the Work is completed. If the unpaid balance of the Contract Price exceeds all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) sustained by Owner arising out of or relating to completing the Work, such excess will be paid to Contractor. If such claims, costs, losses, and damages exceed such unpaid balance, Contractor shall pay the difference to Owner. Such claims, costs, losses, and damages incurred by Owner will be reviewed by Engineer as to their reasonableness and, when so approved by Engineer, incorporated in a Change Order. When exercising any rights or remedies under this Paragraph, Owner shall not be required to obtain the lowest price for the Work performed. D. Notwithstanding Paragraphs 15.02.B and 15.02.C, Contractor’s services will not be terminated if Contractor begins within seven days of receipt of notice of intent to terminate to correct its failure to perform and proceeds diligently to cure such failure within no more than 30 days of receipt of said notice. E. Where Contractor’s services have been so terminated by Owner, the termination will not affect any rights or remedies of Owner against Contractor then existing or which may thereafter accrue. Any retention or payment of moneys due Contractor by Owner will not release Contractor from liability. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 61 of 62 F. If and to the extent that Contractor has provided a performance bond under the provisions of Paragraph 5.01.A, the termination procedures of that bond shall supersede the provisions of Paragraphs 15.02.B and 15.02.C. 15.3 Owner May Terminate For Convenience A. Upon seven days written notice to Contractor and Engineer, Owner may, without cause and without prejudice to any other right or remedy of Owner, terminate the Contract. In such case, Contractor shall be paid for (without duplication of any items): 1. completed and acceptable Work executed in accordance with the Contract Documents prior to the effective date of termination, including fair and reasonable sums for overhead and profit on such Work; 2. expenses sustained prior to the effective date of termination in performing services and furnishing labor, materials, or equipment as required by the Contract Documents in connection with uncompleted Work, plus fair and reasonable sums for overhead and profit on such expenses; 3. all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) incurred in settlement of terminated contracts with Subcontractors, Suppliers, and others; and 4. reasonable expenses directly attributable to termination. B. Contractor shall not be paid on account of loss of anticipated profits or revenue or other economic loss arising out of or resulting from such termination. 15.4 Contractor May Stop Work or Terminate A. If, through no act or fault of Contractor, (i) the Work is suspended for more than 90 consecutive days by Owner or under an order of court or other public authority, or (ii) Engineer fails to act on any Application for Payment within 30 days after it is submitted, or (iii) Owner fails for 30 days to pay Contractor any sum finally determined to be due, then Contractor may, upon seven days written notice to Owner and Engineer, and provided Owner or Engineer do not remedy such suspension or failure within that time, terminate the Contract and recover from Owner payment on the same terms as provided in Paragraph 15.03. B. In lieu of terminating the Contract and without prejudice to any other right or remedy, if Engineer has failed to act on an Application for Payment within 30 days after it is submitted, or Owner has failed for 30 days to pay Contractor any sum finally determined to be due, Contractor may, seven days after written notice to Owner and Engineer, stop the Work until payment is made of all such amounts due Contractor, including interest thereon. The provisions of this Paragraph 15.04 are not intended to preclude Contractor from making a Claim under Paragraph 10.05 for an adjustment in Contract Price or Contract Times or otherwise for expenses or damage directly attributable to Contractor’s stopping the Work as permitted by this Paragraph. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 62 of 62 ARTICLE 16 – DISPUTE RESOLUTION 16.1 Methods and Procedures A. Either Owner or Contractor may request mediation of any Claim submitted to Engineer for a decision under Paragraph 10.05 before such decision becomes final and binding. The mediation will be governed by the Construction Industry Mediation Rules of the American Arbitration Association in effect as of the Effective Date of the Agreement. The request for mediation shall be submitted in writing to the American Arbitration Association and the other party to the Contract. Timely submission of the request shall stay the effect of Paragraph 10.05.E. B. Owner and Contractor shall participate in the mediation process in good faith. The process shall be concluded within 60 days of filing of the request. The date of termination of the mediation shall be determined by application of the mediation rules referenced above. C. If the Claim is not resolved by mediation, Engineer’s action under Paragraph 10.05.C or a denial pursuant to Paragraphs 10.05.C.3 or 10.05.D shall become final and binding 30 days after termination of the mediation unless, within that time period, Owner or Contractor: 1. elects in writing to invoke any dispute resolution process provided for in the Supplementary Conditions; or 2. agrees with the other party to submit the Claim to another dispute resolution process; or 3. gives written notice to the other party of the intent to submit the Claim to a court of competent jurisdiction. ARTICLE 17 – MISCELLANEOUS 17.1 Giving Notice A. Whenever any provision of the Contract Documents requires the giving of written notice, it will be deemed to have been validly given if: 1.delivered in person to the individual or to a member of the firm or to an officer of the corporation for whom it is intended; or 2.delivered at or sent by registered or certified mail, postage prepaid, to the last business address known to the giver of the notice. 17.2 Computation of Times A. When any period of time is referred to in the Contract Documents by days, it will be computed to exclude the first and include the last day of such period. If the last day of any such period falls on a Saturday or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction, such day will be omitted from the computation. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 63 of 62 17.3 Cumulative Remedies A. The duties and obligations imposed by these General Conditions and the rights and remedies available hereunder to the parties hereto are in addition to, and are not to be construed in any way as a limitation of, any rights and remedies available to any or all of them which are otherwise imposed or available by Laws or Regulations, by special warranty or guarantee, or by other provisions of the Contract Documents. The provisions of this Paragraph will be as effective as if repeated specifically in the Contract Documents in connection with each particular duty, obligation, right, and remedy to which they apply. 17.4 Survival of Obligations A. All representations, indemnifications, warranties, and guarantees made in, required by, or given in accordance with the Contract Documents, as well as all continuing obligations indicated in the Contract Documents, will survive final payment, completion, and acceptance of the Work or termination or completion of the Contract or termination of the services of Contractor. 17.5 Controlling Law A. This Contract is to be governed by the law of the state in which the Project is located. 17.06 Headings A. Article and paragraph headings are inserted for convenience only and do not constitute parts of these General Conditions. SUPPLEMENTARY CONDITIONS Page 1 of 10 TH Harris Hosp. FTW CITY PROJECT NO. 102109 SUPPLEMENTARY CONDITIONS Supplementary Conditions These Supplementary Conditions amend or supplement the Standard General Conditions of the Construction Contract, EJCDC C-700 (2007 Edition). All provisions which are not so amended or supplemented remain in full force and effect. The terms used in these Supplementary Conditions have the meanings stated in the General Conditions. Additional terms used in these Supplementary Conditions have the meanings stated below, which are applicable to both the singular and plural thereof. The address system used in these Supplementary Conditions is the same as the address system used in the General Conditions, with the prefix "SC" added thereto. SC1.01 DEFINED TERMS The terms used in these Supplementary Conditions which are defined in the Standard General Conditions of the Construction Contract, EJCDC C-700 (2007 Edition) have the meanings assigned to them in the General Conditions and the Standard City Conditions of the Construction Contract for Developer Awarded Project Amend the following definitions of 1.01 to read as follows: Contract – Refer to Standard City Condition of the Construction Contract for Developer Awarded Project. Contract Documents - Refer to Standard City Condition of the Construction Contract for Developer Awarded Project. Contract Times – is defined as a calendar day including weekends and holidays. Engineer - Refer to Standard City Condition of the Construction Contract for Developer Awarded Project. General Requirements - Refer to Standard City Condition of the Construction Contract for Developer Awarded Project. Milestone - Refer to Standard City Condition of the Construction Contract for Developer Awarded Project. Owner – as known as the developer in the Standard City Condition of the Construction Contract for Developer Awarded Project. Site - Refer to Standard City Condition of the Construction Contract for Developer Awarded Project. Specifications - Refer to Standard City Condition of the Construction Contract for Developer Awarded Project. SUPPLEMENTARY CONDITIONS Page 2 of 10 TH Harris Hosp. FTW CITY PROJECT NO. 102109 Work - Refer to Standard City Condition of the Construction Contract for Developer Awarded Project. SC1.02 TERMINOLOGY Delete Paragraph 1.02.D in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 1.02.B. Delete Paragraph 1.02.E in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 1.02.C. SC2.02 COPIES OF DOCUMENTS Amend the first sentence of Paragraph 2.02 to read as follows: “Owner shall furnish to Contractor up to three printed or hard copies of the Drawings and Project Manual.” SC2.03 COMMENCEMENT OF CONTRACT TIME; NOTICE TO PROCEED Delete Paragraph 2.03.A. of the General Conditions in its entirety and insert the following in its place: “Commencement of Contract Time shall begin on the date indicated during the pre- construction meeting with the City. The date indicated during the pre-construction meeting will be determined by the Owner, City and Contractor and as indicated in the Notice to Proceed.” SC2.05 BEFORE STARTING CONSTRUCTION Delete Paragraph 2.05 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 2.01. SC2.06 PRECONSTRUCTION CONFERENCE; DESIGNATION OF AUTHORIZED REPRESENTATIVE Delete Paragraph 2.06 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 2.02. SC3.01 INTENT Add the following language after the second sentence of Paragraph 3.01.B of the General Conditions: “In the event there are any conflicts between the plans, the specifications or other Contract Documents the priority of interpretation will be as follows: Signed Contract SUPPLEMENTARY CONDITIONS Page 3 of 10 TH Harris Hosp. FTW CITY PROJECT NO. 102109 Agreement, CONTRACTOR’S Proposal, Project Drawings or Plans, Standard City Conditions of the Construction Contract for Developer Awarded Projects, Supplementary Conditions, General Conditions, Project Specifications, Referenced Specifications.” SC3.02 REFERENCE STANDARDS Delete Paragraph 3.02 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 3.01. SC3.04 AMENDING AND SUPPLEMENTING CONTRACT DOCUMENTS Delete Paragraph 3.04 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 3.02. SC4.02 SUBSURFACE AND PHYSICAL CONDITION Add the following new paragraphs immediately after Paragraph 4.02.B: C. The following reports of explorations and tests of subsurface conditions at or contiguous to the Site are known to Owner: 1. Reports dated July 2014 (Amended December 2014), prepared by Alpha Testing entitled: “Final Geotechnical Exploration on Seventeen Lakes (Phases 3 and 4)”. a. All of the information in such drawings constitutes “technical data” on which Contractor may rely. D. The reports and drawings identified above are not part of the Contract Documents, but the “technical data” contained therein upon which Contractor may rely, as expressly identified and established above, are incorporated in the Contract Documents by reference. Contractor is not entitled to rely upon any other information and data known to or identified by Owner or Engineer. SC4.04 UNDERGROUND FACILITIES Add the following language to the beginning of Paragraph 4.04.B of the General Conditions: “Contractor shall contact the city water & sewer and public works departments and utility companies which have a franchise to operate in the area of the project site and shall determine the location of their facilities at or contiguous to the site and shall protect same from damage during construction.” SC4.06 HAZARDOUS ENVIRONMENTAL CONDITIONS Delete Paragraphs 4.06.A and 4.06.B in their entirety and insert the following: SUPPLEMENTARY CONDITIONS Page 4 of 10 TH Harris Hosp. FTW CITY PROJECT NO. 102109 A. No reports or drawings related to Hazardous Environmental Conditions at the Site are known to Owner. B. Not Used. SC5.01 PERFROMANCE, PAYMENT AND OTHER BONDS Delete Paragraph 5.01 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 4.02. SC5.02 LICENSED SURETIES AND INSURERS Delete Paragraph 5.02 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 4.01. SC5.03 CERTIFICATES OF INSURANCE Delete Paragraph 5.03 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 4.03. SC5.04 CONTRACTOR’S INSURANCE Add the following language at the end of the Paragraph 5.04.B.6.b: “Contractor shall include the Engineer and their designee as additional insured.” SC5.06 PROPERTY INSURANCE Delete Paragraph 5.06 in its entirety. SC5.09 ACCEPTANCE OF BONDS AND INSURANCE; OPTION TO REPLACE Delete Paragraph 5.09 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 4.05. SC6.01 SUPERVISION AND SUPERINTENDENCE Delete Paragraph 6.01 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 5.01. SC6.02 LABOR; WORKING HOURS Delete Paragraph 6.02 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 5.02. SC6.03 SERVICES, MATERIALS AND EQUIPMENT SUPPLEMENTARY CONDITIONS Page 5 of 10 TH Harris Hosp. FTW CITY PROJECT NO. 102109 Delete Paragraph 6.03 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 5.03. SC6.04 PROGRESS SCHEDULE Delete Paragraph 6.04 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 5.04. SC6.05 SUBSTITUTES AND “OR-EQUALS” Delete Paragraph 6.05 its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 5.05. SC6.06 CONCERNING SUBCONTRACTORS AND SUPPLIERS Delete Paragraph 6.06 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 5.07 and insert the following: “Owner may furnish to any such Subcontractor, Supplier or other person or organization, to the extent practicable, evidence of amounts paid to Contractor in accordance with Contractor’s application for payment.” SC6.07 PATENT FEES AND ROYALTIES Delete Paragraph 6.07 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 5.09. SC6.09 LAWS AND REGULATIONS Delete Paragraph 6.09 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 5.10. SC6.11 USE OF SITE AND OTHER AREAS Delete Paragraph 6.11 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 5.11. SC6.12 RECORD DOCUMENTS Delete Paragraph 6.12 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 5.12. SC6.13 SAFETY AND PROTECTION Delete Paragraph 6.13 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 5.13. SUPPLEMENTARY CONDITIONS Page 6 of 10 TH Harris Hosp. FTW CITY PROJECT NO. 102109 SC6.14 SAFETY REPRESENTATIVE Delete Paragraph 6.14 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 5.14. SC6.15 HAZARD COMMUNICATION PROGRAMS Delete Paragraph 6.15 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 5.15. SC6.17 SHOP DRAWINGS AND SAMPLES Delete Paragraph 6.17 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 5.16. SC6.19 CONTRACTOR’S GENERAL WARRANTY AND GUARANTEE Delete Paragraph 6.19 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 5.17. SC6.20 INDEMNIFICATION Delete Paragraph 6.20 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 5.18 and insert the following: CONTRACTOR ASSUMES ENTIRE RESPONSIBILITY AND LIABILITY FOR, AND AGREES TO RELEASE, DEFEND, INDEMNIFY AND HOLD OWNER, OWNER’S AGENTS, EMPLOYEES, REPRESENTATIVES AND INSURERS HARMLESS FROM, ANY AND ALL LIABILITIES, CLAIMS, COSTS, EXPENSES, JUDGMENTS, ATTORNEYS’ FEES, LITIGATION EXPENSES, CAUSES OF ACTION, DEMANDS, LOSSES AND/OR DAMAGES ARISING OUT OF, IN CONNECTION WITH, OR IN ANY WAY INCIDENTAL TO THE PERFORMANCE OF WORK OR SERVICES UNDER THIS CONTRACT BY CONTRACTOR, CONTRACTOR’S EMPLOYEES, AGENTS, REPRESENTATIVES AND INDEPENDENT CONTRACTORS. THIS PROVISION APPLIES WITH FULL FORCE AND EFFECT FOR ANY AND ALL CLAIMS, DEMANDS, ALLEGATIONS OR ACTIONS FOUNDED IN WHOLE OR IN PART FROM THE NEGLIGENCE, GROSS NEGLIGENCE, INTENTIONAL ACTS, OR ALLEGED NEGLIGENCE, GROSS NEGLIGENCE OR INTENTIONAL ACTS, OF OWNER, OWNER’S AGENTS, EMPLOYEES, REPRESENTATIVES, AND INDEPENDENT CONTRACTORS, AS WELL AS CONTRACTOR, CONTRACTOR’S AGENTS, EMPLOYEES, REPRESENTATIVES AND INDEPENDENT CONTRACTORS. THIS INDEMNITY PROVISION IS TO BE CONSTRUED AS BROADLY AS POSSIBLE TO INCLUDE ANY AND ALL LIABILITIES, CLAIMS, COSTS, EXPENSES, JUDGMENTS, CAUSES OF ACTIONS, DEMENDS, LOSSES, AND/OR WHATSOEVER, INCLUDING, BUT NOT LIMITED TO, CAUSES OR SUPPLEMENTARY CONDITIONS Page 7 of 10 TH Harris Hosp. FTW CITY PROJECT NO. 102109 ACTION AND DAMAGES SOUNDING IN TORT, PERSONAL INJURIES, CONTRACT DAMAGES, ECONOMIC DAMAGES, STRICT LIABILITY, STRICT PRODUCTS LIABILITY AND PRODUCTS LIABILITY, COMMON LAW NEGLIGENCE AND GROSS NEGLIGENCE, INTENTIONAL TORTS, FEDERAL AND STATE STATUTORY AND COMMON LAW PUNITIVE AND/OR MULTIPLIED DAMAGES, WORKERS’ COMPENSATION CLAIMS, CLAIMS UNDER THE TEXAS TORT CLAIMS ACT, EMPLOYMENT DISPUTES, WRONGFUL DISCHARGE, FEDERAL AND STATE CIVIL RIGHTS CLIAMS, CLAIMS FOUNDED IN CONTRACT OR QUASI- CONTRACT, BREACH OF WARRANTY, CLAIMS UNDER THE TEXAS DECEPTIVE TRADE PRACTICES-COMSUMER PROTECTION ACT, AND ANY AND ALL CLAIMS, CAUSES OF ACTION OR DEMANDS, WHEREBY ANY LOSS IS SOUGHT AND/OR INCURRED AND/OR PAYABLE BY OWNER, OWNER’S AGENTS, EMPLOYEES, REPRESENTATIVES, AND/OR INSURERS. THIS PROVISION IS TO BE CONSTRUED UNDER THE LAWS OF THE STATE OF TEXAS, AND IT IS EXPRESSLY RECOGNIZED BY ALL PARTIES TO THE CONSPICUOUSNESS REQUIREMENT AND THE EXPRESS NEGLIGENCE TEST, AND IS VALID AND ENFORCEABLE AGAINST CONTRACTOR, CONTRACTOR’S AGENTS, EMPLOYEES, REPRESENTATIVES, AND INDEPENDENT CONTRACTORS. CONTRACTOR HAS READ, FULLY UNDERSTANDS, AND AGREES TO BE BOUND BY THE TERMS AND CONDITIONS OF THIS PROVISION AND THE INDIVIDUAL SIGNING THIS CONTRACT ON BEHALF OF CONTRACTOR HAS FULL AUTHORITY TO BIND CONTRACTOR TO THIS CONTRACT AND THIS INDEMNITY PROVISION CONTAINED HEREIN. IT IS FURHTER RECOGNIZED AND AGREED THAT, SHOULD ANY PARTICULAR PORTION OR PROVISION OF THIS INDEMNITY PROVISION BE HELD INVALID, VOID AND/OR UNENFORCEABLE, IT SHALL NOT EFFECT THE VALIDITY AND ENFORCEABILITY OF THE REMAINDER OF THIS PROVISION. CONTRACTOR AGREES TO MAINTAIN AT CONTRACTOR’S SOLE COST AND EXPENSE, INSURANCE OF ANY AND ALL TYPE AND WITH MINIMUM LIMITS AS FOLLOWS, AND FURNISH CERTIFICATES TO OWNER EVIDENCING SUCH INSURANCE WITH INSURERS ACCEPTABLE TO OWNER: ALL INSURANCE COVERAGES CARRIED BY THE OWNER, WHETHER OR NOT REQUIRED HEREBY, SHALL EXTEND TO AN PROTECT OWNER, OWNER’S AGENTS, EMPLOYEES, REPRESENTATIVES, AND INDEPENDENT CONTRACTORS, TO THE FULL EXTENT OF SUCH COVERAGES AND CONTRACTOR AGREES TO NAME OWNER AS AN ADDITIONAL INSURED UNDER EACH SUCH INSURANCE COVERAGE. SAID INSURANCE SHALL APPLY TO ANY AND ALL LIABILITY OF THE CONTRACTOR, CONTRACTOR’S AGENTS, REPRESENTATIVES, EMPLOYEES, AND/OR INDEPENDENT CONTRACTORS, ARISING FROM THE INDEMNITY PROVISION IN THIS SECTION. SUPPLEMENTARY CONDITIONS Page 8 of 10 TH Harris Hosp. FTW CITY PROJECT NO. 102109 HOWEVER, LIABILITY OF THE CONTRACTOR, AS PROVIDED IN THIS SECTION SHALL NOT BE LIMITED BY THE INSURANCE COVERAGE REQUIRED OF CONTRACTOR IN THIS PROVISION. SC6.21 DELEGATION OF PROFESSIONAL DESIGN SERVICES Delete Paragraph 6.21 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 5.19. SC9.05 REJECTING DEFECTIVE WORK Delete Paragraph 9.05 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 8.03. SC10.04 NOTIFICATION TO SURETY Delete Paragraph 10.04 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 9.02. SC11.03 UNIT PRICE WORK Add the following new paragraph immediately after Paragraph 11.03.A: “Any and all Work specifically called for in the Contract Documents or which is required for the proper construction of items called for in the Contract Documents is to be performed by Contractor unless specifically indicated otherwise. The cost of all work for which there is no separate pay item in the proposal shall be included in the price for a related pay item such that work called for or required by the Contract Documents will be constructed for the Contract Price.” SC13.01 NOTICE OF DEFECTS Delete Paragraph 13.01 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 11.01. SC13.02 ACCESS TO WORK Delete Paragraph 13.02 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 11.02. SC13.03 TESTS AND INSPECTION Delete Paragraph 13.03 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 11.03. SUPPLEMENTARY CONDITIONS Page 9 of 10 TH Harris Hosp. FTW CITY PROJECT NO. 102109 SC13.04 UNCOVERING WORK Delete Paragraph 13.04 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 11.04. SC13.06 CORRECTION OR REMOVAL OF DEFECTIVE WORK Delete Paragraph 13.06 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 11.06. SC13.07 CORRECTION PERIOD Delete Paragraph 13.07 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 11.07. SC13.08 ACCEPTANCE OF DEFECTIVE WORK Delete Paragraph 13.08 in its entirety. SC13.09 OWNER MAY CORRECT DEFECTIVE WORK Delete Paragraph 13.09 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 11.08. SC14.02 PROGRESS PAYMENT Revise the first sentence of Paragraph 14.02.A.1 to read as follows: “At least thirty (30) days before each progress payment,….” SC14.03 CONTRACTOR’S WARRANTY OF TITLE Delete Paragraph 14.03 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 12.01. SC14.05 PARTIAL UTILIZATION Delete Paragraph 14.05 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 12.02. SC14.06 FINAL INSPECTION Delete Paragraph 14.05 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 12.03. SC17.01 GIVING NOTICE SUPPLEMENTARY CONDITIONS Page 10 of 10 TH Harris Hosp. FTW CITY PROJECT NO. 102109 Delete Paragraph 17.01 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 14.01. SC17.02 COMPUTATION OF TIMES Delete Paragraph 17.02 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 14.02. SC17.03 CUMULATIVE REMEDIES Delete Paragraph 17.03 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 14.03. SC17.04 SURVIVAL OF OBLIGATIONS Delete Paragraph 17.04 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 14.04 SC17.06 HEADINGS Delete Paragraph 17.06 in its entirety and refer to Standard City Condition of the Construction Contract for Developer Awarded Project Paragraph 14.05. CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 STANDARD CITY CONDITIONS OF THE CONSTRUCTION CONTRACT FOR DEVELOPER AWARDED PROJECTS CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 STANDARD CITY CONDITIONS OF THE CONSTRUCTION CONTRACT FOR DEVELOPER AWARDED PROJECTS TABLE OF CONTENTS Page Article 1 – Definitions and Terminology .......................................................................................................... 1 1.01 Defined Terms ............................................................................................................................... 1 1.02 Terminology .................................................................................................................................. 5 Article 2 – Preliminary Matters ......................................................................................................................... 6 2.01 Before Starting Construction ........................................................................................................ 6 2.02 Preconstruction Conference .......................................................................................................... 6 2.03 Public Meeting .............................................................................................................................. 6 Article 3 – Contract Documents and Amending ............................................................................................... 6 3.01 Reference Standards ..................................................................................................................... 6 3.02 Amending and Supplementing Contract Documents .................................................................. 6 Article 4 – Bonds and Insurance ....................................................................................................................... 7 4.01 Licensed Sureties and Insurers ..................................................................................................... 7 4.02 Performance, Payment, and Maintenance Bonds ........................................................................ 7 4.03 Certificates of Insurance ............................................................................................................... 7 4.04 Contractor’s Insurance .................................................................................................................. 9 4.05 Acceptance of Bonds and Insurance; Option to Replace ........................................................... 12 Article 5 – Contractor’s Responsibilities ........................................................................................................ 12 5.01 Supervision and Superintendent ................................................................................................. 12 5.02 Labor; Working Hours ................................................................................................................ 13 5.03 Services, Materials, and Equipment ........................................................................................... 13 5.04 Project Schedule .......................................................................................................................... 14 5.05 Substitutes and “Or-Equals” ....................................................................................................... 14 5.06 Pre-Qualification of Bidders (Prime Contractors and Subcontractors) ..................................... 16 5.07 Concerning Subcontractors, Suppliers, and Others ................................................................... 16 5.08 Wage Rates.................................................................................................................................. 18 5.09 Patent Fees and Royalties ........................................................................................................... 19 5.10 Laws and Regulations ................................................................................................................. 19 5.11 Use of Site and Other Areas ....................................................................................................... 19 5.12 Record Documents ...................................................................................................................... 20 5.13 Safety and Protection .................................................................................................................. 21 5.14 Safety Representative ................................................................................................................. 21 5.15 Hazard Communication Programs ............................................................................................. 22 5.16 Submittals .................................................................................................................................... 22 5.17 Contractor’s General Warranty and Guarantee .......................................................................... 23 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 5.18 Indemnification ........................................................................................................................... 24 5.19 Delegation of Professional Design Services .............................................................................. 24 5.20 Right to Audit: ............................................................................................................................ 25 5.21 Nondiscrimination....................................................................................................................... 25 Article 6 – Other Work at the Site ................................................................................................................... 26 6.01 Related Work at Site ................................................................................................................... 26 Article 7 – City’s Responsibilities................................................................................................................... 26 7.01 Inspections, Tests, and Approvals .............................................................................................. 26 7.02 Limitations on City’s Responsibilities ....................................................................................... 26 7.03 Compliance with Safety Program ............................................................................................... 27 Article 8 – City’s Observation Status During Construction ........................................................................... 27 8.01 City’s Project Representative ..................................................................................................... 27 8.02 Authorized Variations in Work .................................................................................................. 27 8.03 Rejecting Defective Work .......................................................................................................... 27 8.04 Determinations for Work Performed .......................................................................................... 28 Article 9 – Changes in the Work ..................................................................................................................... 28 9.01 Authorized Changes in the Work ............................................................................................... 28 9.02 Notification to Surety .................................................................................................................. 28 Article 10 – Change of Contract Price; Change of Contract Time ................................................................ 28 10.01 Change of Contract Price ............................................................................................................ 28 10.02 Change of Contract Time............................................................................................................ 28 10.03 Delays .......................................................................................................................................... 28 Article 11 – Tests and Inspections; Correction, Removal or Acceptance of Defective Work ...................... 29 11.01 Notice of Defects ........................................................................................................................ 29 11.02 Access to Work ........................................................................................................................... 29 11.03 Tests and Inspections .................................................................................................................. 29 11.04 Uncovering Work ....................................................................................................................... 30 11.05 City May Stop the Work ............................................................................................................. 30 11.06 Correction or Removal of Defective Work ................................................................................ 30 11.07 Correction Period ........................................................................................................................ 30 11.08 City May Correct Defective Work ............................................................................................. 31 Article 12 – Completion .................................................................................................................................. 32 12.01 Contractor’s Warranty of Title ................................................................................................... 32 12.02 Partial Utilization ........................................................................................................................ 32 12.03 Final Inspection ........................................................................................................................... 32 12.04 Final Acceptance ......................................................................................................................... 33 Article 13 – Suspension of Work .................................................................................................................... 33 13.01 City May Suspend Work ............................................................................................................ 33 Article 14 – Miscellaneous .............................................................................................................................. 34 14.01 Giving Notice .............................................................................................................................. 34 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 14.02 Computation of Times ................................................................................................................ 34 14.03 Cumulative Remedies ................................................................................................................. 34 14.04 Survival of Obligations ............................................................................................................... 35 14.05 Headings ...................................................................................................................................... 35 00 73 10- 1 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 1 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 ARTICLE 1 – DEFINITIONS AND TERMINOLOGY 1.01 Defined Terms A. Wherever used in these General Conditions or in other Contract Documents, the terms listed below have the meanings indicated which are applicable to both the singular and plural thereof, and words denoting gender shall include the masculine, feminine and neuter. Said terms are generally capitalized or written in italics, but not always. When used in a context consistent with the definition of a listed-defined term, the term shall have a meaning as defined below whether capitalized or italicized or otherwise. In addition to terms specifically defined, terms with initial capital letters in the Contract Documents include references to identified articles and paragraphs, and the titles of other documents or forms. 1. Agreement - The written instrument which is evidence of the agreement between Developer and Contractor covering the Work 2. Asbestos—Any material that contains more than one percent asbestos and is friable or is releasing asbestos fibers into the air above current action levels established by the United States Occupational Safety and Health Administration. 3. Business Day – A business day is defined as a day that the City conducts normal business, generally Monday through Friday, except for federal or state holidays observed by the City. 4. Buzzsaw – City’s on-line, electronic document management and collaboration system. 5. Calendar Day – A day consisting of 24 hours measured from midnight to the next midnight. 6. City— The City of Fort Worth, Texas, a Texas home-rule municipal corporation, acting by, its governing body through its City Manager, his designee, or agents authorized pursuant to its duly authorized charter on his behalf. 7. Community Facilities Agreement (CFA) -–A Contract between the Developer and the City for the Construction of one or more following public facilities within the City public right-of- way or easement: Water, Sanitary Sewer, Street, Storm Drain, Street Light, and Street Signs. A CFA may include private facilities within the right-of-way dedicated as private right-of- way or easement on a recorded plat. 8. Contract—The entire and integrated written document incorporating the Contract Documents between the Developer, Contractor, and/or City concerning the Work. The Contract supersedes prior negotiations, representations, or agreements, whether written or oral. 9. Contract Documents—Those items that make up the contract and which must include the Agreement, and it’s attachments such as standard construction specifications, standard City Conditions, other general conditions of the Developer, including: a. An Agreement 00 73 10- 2 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 2 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 b. Attachments to the Agreement i. Bid Form ii. Vendor Compliance with State Law Non-Resident Bidder iii. Prequalification Statement c. Current Prevailing Wage Rates Table (if required by City) d. Insurance Accord Form e. Payment Bond f. Performance Bond g. Maintenance Bond h. Power of Attorney for Bonds i. Workers Compensation Affidavit j. MWBE Commitment Form( If required by City) k. General Conditions l. Supplementary Conditions m. The Standard City Conditions n. Specifications specifically made part of the Contract Documents by attachment, if not attached, as incorporated by reference and described in the Table of Contents of the Project’s Contract Documents o. Drawings p. Documentation submitted by contractor prior to Notice of Award. q. The following which may be delivered or issued after the effective date if the Agreement and, if issued become an incorporated part of the Contract Documents i. Notice to Proceed ii. Field Orders iii. Change Orders iv. Letters of Final Acceptance r. Approved Submittals, other Contractor submittals, and the reports and drawings of subsurface and physical conditions are not Contract Documents. 10. Contractor—The individual or entity with whom Developer has entered into the Agreement. 11. Day or day – A day, unless otherwise defined, shall mean a Calendar Day. 12. Developer – An individual or entity that desires to make certain improvements within the City of Fort Worth 13. Drawings—That part of the Contract Documents prepared or approved by Engineer which graphically shows the scope, extent, and character of the Work to be performed by Contractor. Submittals are not Drawings as so defined. 14. Engineer—The licensed professional engineer or engineering firm registered in the State of Texas performing professional services for the Developer. 15. Final Acceptance – The written notice given by the City to the Developer and/or Contractor that the Work specified in the Contract Documents has been completed to the satisfaction of the City. 00 73 10- 3 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 3 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 16. Final Inspection – Inspection carried out by the City to verify that the Contractor has completed the Work, and each and every part or appurtenance thereof, fully, entirely, and in conformance with the Contract Documents. 17. General Requirements—A part of the Contract Documents between the Developer and a Contractor. 18. Laws and Regulations—Any and all applicable laws, rules, regulations, ordinances, codes, and orders of any and all governmental bodies, agencies, authorities, and courts having jurisdiction. 19. Liens—Charges, security interests, or encumbrances upon Project funds, real property, or personal property. 20. Milestone—A principal event specified in the Contract Documents relating to an intermediate Contract Time prior to Final Acceptance of the Work. 21. Non-Participating Change Order—A document, which is prepared for and reviewed by the City, which is signed by Contractor, and Developer, and authorizes an addition, deletion, or revision in the Work or an adjustment in the Contract Price or the Contract Time, issued on or after the Effective Date of the Agreement. 22. Participating Change Order—A document, which is prepared for and approved by the City, which is signed by Contractor, Developer, and City and authorizes an addition, deletion, or revision in the Work or an adjustment in the Contract Price or the Contract Time, issued on or after the Effective Date of the Agreement. 23. Plans – See definition of Drawings. 24. Project Schedule—A schedule, prepared and maintained by Contractor, in accordance with the General Requirements, describing the sequence and duration of the activities comprising the Contractor’s plan to accomplish the Work within the Contract Time. 25. Project—The Work to be performed under the Contract Documents. 26. Project Representative—The authorized representative of the City who will be assigned to the Site. 27. Public Meeting – An announced meeting conducted by the Developer to facilitate public participation and to assist the public in gaining an informed view of the Project. 28. Regular Working Hours – Hours beginning at 7:00 a.m. and ending at 6:00 p.m., Monday thru Friday (excluding legal holidays). 29. Samples—Physical examples of materials, equipment, or workmanship that are representative of some portion of the Work and which establish the standards by which such portion of the Work will be judged. 00 73 10- 4 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 4 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 30. Schedule of Submittals—A schedule, prepared and maintained by Contractor, of required submittals and the time requirements to support scheduled performance of related construction activities. 31. Site—Lands or areas indicated in the Contract Documents as being furnished by City or Developer upon which the Work is to be performed, including rights-of-way, permits, and easements for access thereto, and such other lands furnished by City or Developer which are designated for the use of Contractor. 32. Specifications—That part of the Contract Documents consisting of written requirements for materials, equipment, systems, standards and workmanship as applied to the Work, and certain administrative requirements and procedural matters applicable thereto. Specifications may be specifically made a part of the Contract Documents by attachment or, if not attached, may be incorporated by reference as indicated in the Table of Contents (Division 00 00 00) of each Project. 33. Standard City Conditions – That part of the Contract Documents setting forth requirements of the City. 34. Subcontractor—An individual or entity having a direct contract with Contractor or with any other Subcontractor for the performance of a part of the Work at the Site. 35. Submittals—All drawings, diagrams, illustrations, schedules, and other data or information which are specifically prepared or assembled by or for Contractor and submitted by Contractor to illustrate some portion of the Work. 36. Superintendent – The representative of the Contractor who is available at all times and able to receive instructions from the City and/or Developer and to act for the Contractor. 37. Supplementary Conditions—That part of the Contract Documents which amends or supplements the General Conditions. 38. Supplier—A manufacturer, fabricator, supplier, distributor, materialman, or vendor having a direct contract with Contractor or with any Subcontractor to furnish materials or equipment to be incorporated in the Work by Contractor or Subcontractor. 39. Underground Facilities—All underground pipelines, conduits, ducts, cables, wires, manholes, vaults, tanks, tunnels, or other such facilities or attachments, and any encasements containing such facilities, including but not limited to, those that convey electricity, gases, steam, liquid petroleum products, telephone or other communications, cable television, water, wastewater, storm water, other liquids or chemicals, or traffic or other control systems. 40. Weekend Working Hours – Hours beginning at 9:00 a.m. and ending at 5:00 p.m., Saturday, Sunday or legal holiday, as approved in advance by the City. 00 73 10- 5 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 5 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 41. Work—The entire construction or the various separately identifiable parts thereof required to be provided under the Contract Documents. Work includes and is the result of performing or providing all labor, services, and documentation necessary to produce such construction including any Participating Change Order, Non-Participating Change Order, or Field Order, and furnishing, installing, and incorporating all materials and equipment into such construction, all as required by the Contract Documents. 42. Working Day – A working day is defined as a day, not including Saturdays, Sundays, or legal holidays authorized by the City for contract purposes, in which weather or other conditions not under the control of the Contractor will permit the performance of the principal unit of work underway for a continuous period of not less than 7 hours between 7 a.m. and 6 p.m. 1.02 Terminology A. The words and terms discussed in Paragraph 1.02.B through D are not defined but, when used in the Bidding Requirements or Contract Documents, have the indicated meaning. B. Defective: 1. The word “defective,” when modifying the word “Work,” refers to Work that is unsatisfactory, faulty, or deficient in that it: a. does not conform to the Contract Documents; or b. does not meet the requirements of any applicable inspection, reference standard, test, or approval referred to in the Contract Documents; or c. has been damaged prior to City’s written acceptance. C. Furnish, Install, Perform, Provide: 1. The word “Furnish” or the word “Install” or the word “Perform” or the word “Provide” or the word “Supply,” or any combination or similar directive or usage thereof, shall mean furnishing and incorporating in the Work including all necessary labor, materials, equipment, and everything necessary to perform the Work indicated, unless specifically limited in the context used. D. Unless stated otherwise in the Contract Documents, words or phrases that have a well-known technical or construction industry or trade meaning are used in the Contract Documents in accordance with such recognized meaning. 00 73 10- 6 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 6 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 ARTICLE 2 – PRELIMINARY MATTERS 2.01 Before Starting Construction Baseline Schedules: Submit to City in accordance with the Contract Documents, and prior to starting the Work. New schedules will be submitted to City when Participating Change Orders or Non- Participating Change Orders occur. 2.02 Preconstruction Conference Before any Work at the Site is started, the Contractor shall attend a Preconstruction Conference as specified in the Contract Documents. 2.03 Public Meeting Contractor may not mobilize any equipment, materials or resources to the Site prior to Contractor attending the Public Meeting as scheduled by the City. ARTICLE 3 – CONTRACT DOCUMENTS AND AMENDING 3.01 Reference Standards A. Standards, Specifications, Codes, Laws, and Regulations 1. Reference to standards, specifications, manuals, or codes of any technical society, organization, or association, or to Laws or Regulations, whether such reference be specific or by implication, shall mean the standard, specification, manual, code, or Laws or Regulations in effect at the time of opening of Bids (or on the Effective Date of the Agreement if there were no Bids), except as may be otherwise specifically stated in the Contract Documents. 2. No provision or instruction shall be effective to assign to City, or any of its officers, directors, members, partners, employees, agents, consultants, or subcontractors, any duty or authority to supervise or direct the performance of the Work or any duty or authority to undertake responsibility inconsistent with the provisions of the Contract Documents. 3.02 Amending and Supplementing Contract Documents A. The Contract Documents may be amended to provide for additions, deletions, and revisions in the Work or to modify the terms and conditions thereof by a Participating Change Order or a Non-Participating Change Order. B. The requirements of the Contract Documents may be supplemented, and minor variations and deviations in the Work not involving a change in Contract Price or Contract Time, may be authorized, by one or more of the following ways: 1. A Field Order; 00 73 10- 7 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 7 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 1. City’s or Engineer’s review of a Submittal (subject to the provisions of Paragraph 5.16.C); or 2. City’s written interpretation or clarification. ARTICLE 4 – BONDS AND INSURANCE 4.01 Licensed Sureties and Insurers All bonds and insurance required by the Contract Documents to be purchased and maintained by Contractor shall be obtained from surety or insurance companies that are duly licensed or authorized in the State of Texas to issue bonds or insurance policies for the limits and coverage so required. Such surety and insurance companies shall also meet such additional requirements and qualifications as may be provided Section 4.04. 4.02 Performance, Payment, and Maintenance Bonds A. Contractor shall furnish performance and payment bonds in the name of Developer and City, in accordance with Texas Government Code Chapter 2253 or successor statute, each in an amount equal to the Contract Price as security for the faithful performance and payment of all of Contractor’s obligations under the Contract Documents. B. Contractor shall furnish maintenance bonds in the name of Developer and City in an amount equal to the Contract Price as security to protect the City against any defects in any portion of the Work described in the Contract Documents. Maintenance bonds shall remain in effect for two (2) years after the date of Final Acceptance by the City. C. All bonds shall be in the form prescribed by the Contract Documents except as provided otherwise by Laws or Regulations, and shall be executed by such sureties as are named in the list of “Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsuring Companies” as published in Circular 570 (amended) by the Financial Management Service, Surety Bond Branch, U.S. Department of the Treasury. All bonds signed by an agent or attorney-in-fact must be accompanied by a sealed and dated power of attorney which shall show that it is effective on the date the agent or attorney-in-fact signed each bond. D. If the surety on any bond furnished by Contractor is declared bankrupt or becomes insolvent or its right to do business is terminated in the State of Texas or it ceases to meet the requirements of Paragraph 4.02.C, Contractor shall promptly notify City and shall, within 30 days after the event giving rise to such notification, provide another bond and surety, both of which shall comply with the requirements of Paragraphs 4.01 and 4.02.C. 4.03 Certificates of Insurance Contractor shall deliver to Developer and City, with copies to each additional insured and loss payee identified in these Standard City Conditions certificates of insurance (and other evidence of insurance requested by City or any other additional insured) which Contractor is required to purchase and maintain. 00 73 10- 8 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 8 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 1. The certificate of insurance shall document the City, an as “Additional Insured” on all liability policies. 2. The Contractor’s general liability insurance shall include a, “per project” or “per location”, endorsement, which shall be identified in the certificate of insurance provided to the City. 3. The certificate shall be signed by an agent authorized to bind coverage on behalf of the insured, be complete in its entirety, and show complete insurance carrier names as listed in the current A.M. Best Property & Casualty Guide 4. The insurers for all policies must be licensed and/or approved to do business in the State of Texas. Except for workers’ compensation, all insurers must have a minimum rating of A-: VII in the current A. M. Best Key Rating Guide or have reasonably equivalent financial strength and solvency to the satisfaction of Risk Management. If the rating is below that required, written approval of City is required. 5. All applicable policies shall include a Waiver of Subrogation (Rights of Recovery) in favor of the City. In addition, the Contractor agrees to waive all rights of subrogation against the Engineer (if applicable), and each additional insured identified in these Standard City Conditions. Failure of the City to demand such certificates or other evidence of full compliance with the insurance requirements or failure of the City to identify a deficiency from evidence that is provided shall not be construed as a waiver of Contractor’s obligation to maintain such lines of insurance coverage. 6. If insurance policies are not written for specified coverage limits, an Umbrella or Excess Liability insurance for any differences is required. Excess Liability shall follow form of the primary coverage. 7. Unless otherwise stated, all required insurance shall be written on the “occurrence basis”. If coverage is underwritten on a claims-made basis, the retroactive date shall be coincident with or prior to the date of the effective date of the agreement and the certificate of insurance shall state that the coverage is claims-made and the retroactive date. The insurance coverage shall be maintained for the duration of the Contract and for three (3) years following Final Acceptance provided under the Contract Documents or for the warranty period, whichever is longer. An annual certificate of insurance submitted to the City shall evidence such insurance coverage. 8. Policies shall have no exclusions by endorsements, which, neither nullify or amend, the required lines of coverage, nor decrease the limits of said coverage unless such endorsements are approved in writing by the City. In the event a Contract has been bid or executed and the exclusions are determined to be unacceptable or the City desires additional insurance coverage, and the City desires the contractor/engineer to obtain such coverage, the contract price shall be adjusted by the cost of the premium for such additional coverage plus 10%. 9. Any self-insured retention (SIR), in excess of $25,000.00, affecting required insurance coverage shall be approved by the City in regards to asset value and stockholders' equity. In 00 73 10- 9 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 9 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 lieu of traditional insurance, alternative coverage maintained through insurance pools or risk retention groups, must also be approved by City. 10. Any deductible in excess of $5,000.00, for any policy that does not provide coverage on a first-dollar basis, must be acceptable to and approved by the City. 11. City, at its sole discretion, reserves the right to review the insurance requirements and to make reasonable adjustments to insurance coverage’s and their limits when deemed necessary and prudent by the City based upon changes in statutory law, court decision or the claims history of the industry as well as of the contracting party to the City. The City shall be required to provide prior notice of 90 days, and the insurance adjustments shall be incorporated into the Work by Change Order. 12. City shall be entitled, upon written request and without expense, to receive copies of policies and endorsements thereto and may make any reasonable requests for deletion or revision or modifications of particular policy terms, conditions, limitations, or exclusions necessary to conform the policy and endorsements to the requirements of the Contract. Deletions, revisions, or modifications shall not be required where policy provisions are established by law or regulations binding upon either party or the underwriter on any such policies. 13. City shall not be responsible for the direct payment of insurance premium costs for Contractor’s insurance. 4.04 Contractor’s Insurance A. Workers Compensation and Employers’ Liability. Contractor shall purchase and maintain such insurance coverage with limits consistent with statutory benefits outlined in the Texas Workers’ Compensation Act (Texas Labor Code, Ch. 406, as amended), and minimum limits for Employers’ Liability as is appropriate for the Work being performed and as will provide protection from claims set forth below which may arise out of or result from Contractor’s performance of the Work and Contractor’s other obligations under the Contract Documents, whether it is to be performed by Contractor, any Subcontractor or Supplier, or by anyone directly or indirectly employed by any of them to perform any of the Work, or by anyone for whose acts any of them may be liable: 1. claims under workers’ compensation, disability benefits, and other similar employee benefit acts; 2. claims for damages because of bodily injury, occupational sickness or disease, or death of Contractor’s employees. 3. The limits of liability for the insurance shall provide the following coverages for not less than the following amounts or greater where required by Laws and Regulations a. Statutory limits b. Employer's liability 00 73 10- 10 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 10 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 1) $100,000 each accident/occurrence 2) $100,000 Disease - each employee 3) $500,000 Disease - policy limit B. Commercial General Liability. Coverage shall include but not be limited to covering liability (bodily injury or property damage) arising from: premises/operations, independent contractors, products/completed operations, personal injury, and liability under an insured contract. Insurance shall be provided on an occurrence basis, and as comprehensive as the current Insurance Services Office (ISO) policy. This insurance shall apply as primary insurance with respect to any other insurance or self-insurance programs afforded to the City. The Commercial General Liability policy, shall have no exclusions by endorsements that would alter of nullify premises/operations, products/completed operations, contractual, personal injury, or advertising injury, which are normally contained with the policy, unless the City approves such exclusions in writing. 1. For construction projects that present a substantial completed operation exposure, the City may require the contractor to maintain completed operations coverage for a minimum of no less than three (3) years following the completion of the project 2. Contractor's Liability Insurance under this Section which shall be on a per project basis covering the Contractor with minimum limits of: a. $1,000,000 each occurrence b. $2,000,000 aggregate limit 3. The policy must have an endorsement (Amendment – Aggregate Limits of Insurance) making the General Aggregate Limits apply separately to each job site. 4. The Commercial General Liability Insurance policies shall provide “X”, “C”, and “U” coverage’s. Verification of such coverage must be shown in the Remarks Article of the Certificate of Insurance. C. Automobile Liability. A commercial business auto policy shall provide coverage on “any auto”, defined as autos owned, hired and non-owned and provide indemnity for claims for damages because bodily injury or death of any person and or property damage arising out of the work, maintenance or use of any motor vehicle by the Contractor, any Subcontractor or Supplier, or by anyone directly or indirectly employed by any of them to perform any of the Work, or by anyone for whose acts any of them may be liable. 1. Automobile Liability, Contractor’s Liability Insurance under this Section, which shall be in an amount not less than the following amounts: a. Automobile Liability - a commercial business policy shall provide coverage on "Any Auto", defined as autos owned, hired and non-owned. 00 73 10- 11 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 11 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 1) $1,000,000 each accident on a combined single limit basis. Split limits are acceptable if limits are at least: 2) $250,000 Bodily Injury per person 3) $500,000 Bodily Injury per accident / 4) $100,000 Property Damage D. Railroad Protective Liability. If any of the work or any warranty work is within the limits of railroad right-of-way, the Contractor shall comply with the following requirements: 1. The Contractor’s construction activities will require its employees, agents, subcontractors, equipment, and material deliveries to cross railroad properties and tracks owned and operated by: ____________________________________________________________ Write the name of the railroad company. (If none, then write none) 2. The Contractor shall conduct its operations on railroad properties in such a manner as not to interfere with, hinder, or obstruct the railroad company in any manner whatsoever in the use or operation of its/their trains or other property. Such operations on railroad properties may require that Contractor to execute a “Right of Entry Agreement” with the particular railroad company or companies involved, and to this end the Contractor should satisfy itself as to the requirements of each railroad company and be prepared to execute the right-of-entry (if any) required by a railroad company. The requirements specified herein likewise relate to the Contractor’s use of private and/or construction access roads crossing said railroad company’s properties. 3. The Contractual Liability coverage required by Paragraph 5.04D of the General Conditions shall provide coverage for not less than the following amounts, issued by companies satisfactory to the City and to the Railroad Company for a term that continues for so long as the Contractor’s operations and work cross, occupy, or touch railroad property: a. General Aggregate: _____________________________________ Enter limits provided by Railroad Company (If none, write none) b. Each Occurrence: : _____________________________________ Enter limits provided by Railroad Company (If none, write none) 4. With respect to the above outlined insurance requirements, the following shall govern: a. Where a single railroad company is involved, the Contractor shall provide one insurance policy in the name of the railroad company. However, if more than one grade separation or at-grade crossing is affected by the Project at entirely separate locations on the line or lines of the same railroad company, separate coverage may be required, each in the amount stated above. b. Where more than one railroad company is operating on the same right-of-way or where several railroad companies are involved and operated on their own separate rights-of- 00 73 10- 12 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 12 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 way, the Contractor may be required to provide separate insurance policies in the name of each railroad company. c. If, in addition to a grade separation or an at-grade crossing, other work or activity is proposed on a railroad company’s right-of-way at a location entirely separate from the grade separation or at-grade crossing, insurance coverage for this work must be included in the policy covering the grade separation. d. If no grade separation is involved but other work is proposed on a railroad company’s right-of-way, all such other work may be covered in a single policy for that railroad, even though the work may be at two or more separate locations. 5. No work or activities on a railroad company’s property to be performed by the Contractor shall be commenced until the Contractor has furnished the City with an original policy or policies of the insurance for each railroad company named, as required above. All such insurance must be approved by the City and each affected Railroad Company prior to the Contractor’s beginning work. 6. The insurance specified above must be carried until all Work to be performed on the railroad right-of-way has been completed and the grade crossing, if any, is no longer used by the Contractor. In addition, insurance must be carried during all maintenance and/or repair work performed in the railroad right-of-way. Such insurance must name the railroad company as the insured, together with any tenant or lessee of the railroad company operating over tracks involved in the Project. E. Notification of Policy Cancellation: Contractor shall immediately notify City upon cancellation or other loss of insurance coverage. Contractor shall stop work until replacement insurance has been procured. There shall be no time credit for days not worked pursuant to this section. 4.05 Acceptance of Bonds and Insurance; Option to Replace If City has any objection to the coverage afforded by or other provisions of the bonds or insurance required to be purchased and maintained by the Contractor in accordance with Article 5 on the basis of non-conformance with the Contract Documents, the Developer and City shall so notify the Contractor in writing within 10 Business Days after receipt of the certificates (or other evidence requested). Contractor shall provide to the City such additional information in respect of insurance provided as the Developer or City may reasonably request. If Contractor does not purchase or maintain all of the bonds and insurance required by the Contract Documents, the Developer or City shall notify the Contractor in writing of such failure prior to the start of the Work, or of such failure to maintain prior to any change in the required coverage. ARTICLE 5 – CONTRACTOR’S RESPONSIBILITIES 5.01 Supervision and Superintendent A. Contractor shall supervise, inspect, and direct the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the 00 73 10- 13 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 13 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 Work in accordance with the Contract Documents. Contractor shall be solely responsible for the means, methods, techniques, sequences, and procedures of construction. B. At all times during the progress of the Work, Contractor shall assign a competent, English- speaking, Superintendent who shall not be replaced without written notice to City. The Superintendent will be Contractor’s representative at the Site and shall have authority to act on behalf of Contractor. All communication given to or received from the Superintendent shall be binding on Contractor. C. Contractor shall notify the City 24 hours prior to moving areas during the sequence of construction. 5.02 Labor; Working Hours A. Contractor shall provide competent, suitably qualified personnel to perform construction as required by the Contract Documents. Contractor shall at all times maintain good discipline and order at the Site. B. Except as otherwise required for the safety or protection of persons or the Work or property at the Site or adjacent thereto, and except as otherwise stated in the Contract Documents, all Work at the Site shall be performed during Regular Working Hours. Contractor will not permit the performance of Work beyond Regular Working Hours or for Weekend Working Hours without City’s written consent (which will not be unreasonably withheld). Written request (by letter or electronic communication) to perform Work: 1. for beyond Regular Working Hours request must be made by noon at least two (2) Business Days prior 2. for Weekend Working Hours request must be made by noon of the preceding Thursday 3. for legal holidays request must be made by noon two Business Days prior to the legal holiday. 5.03 Services, Materials, and Equipment A. Unless otherwise specified in the Contract Documents, Contractor shall provide and assume full responsibility for all services, materials, equipment, labor, transportation, construction equipment and machinery, tools, appliances, fuel, power, light, heat, telephone, water, sanitary facilities, temporary facilities, and all other facilities and incidentals necessary for the performance, Contractor required testing, start-up, and completion of the Work. B. All materials and equipment incorporated into the Work shall be as specified or, if not specified, shall be of good quality and new, except as otherwise provided in the Contract Documents. All special warranties and guarantees required by the Specifications shall expressly run to the benefit of City. If required by City, Contractor shall furnish satisfactory evidence (including reports of required tests) as to the source, kind, and quality of materials and equipment. 00 73 10- 14 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 14 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 C. All materials and equipment to be incorporated into the Work shall be stored, applied, installed, connected, erected, protected, used, cleaned, and conditioned in accordance with instructions of the applicable Supplier, except as otherwise may be provided in the Contract Documents. 5.04 Project Schedule A. Contractor shall adhere to the Project Schedule established in accordance with Paragraph 2.01 and the General Requirements as it may be adjusted from time to time as provided below. 1. Contractor shall submit to City for acceptance (to the extent indicated in Paragraph 2.01 and the General Requirements) proposed adjustments in the Project Schedule. 2. Proposed adjustments in the Project Schedule that will change the Contract Time shall be submitted in accordance with the requirements of Article 9. Adjustments in Contract Time for projects with City participation shall be made by participating change orders. 5.05 Substitutes and “Or-Equals” A. Whenever an item of material or equipment is specified or described in the Contract Documents by using the name of a proprietary item or the name of a particular Supplier, the specification or description is intended to establish the type, function, appearance, and quality required. Unless the specification or description contains or is followed by words reading that no like, equivalent, or “or-equal” item or no substitution is permitted, other items of material or equipment of other Suppliers may be submitted to City for review under the circumstances described below. 1. “Or-Equal” Items: If in City’s sole discretion an item of material or equipment proposed by Contractor is functionally equal to that named and sufficiently similar so that no change in related Work will be required, it may be considered by City as an “or-equal” item, in which case review and approval of the proposed item may, in City’s sole discretion, be accomplished without compliance with some or all of the requirements for approval of proposed substitute items. For the purposes of this Paragraph 5.05.A.1, a proposed item of material or equipment will be considered functionally equal to an item so named if: a. City determines that: 1) it is at least equal in materials of construction, quality, durability, appearance, strength, and design characteristics; 2) it will reliably perform at least equally well the function and achieve the results imposed by the design concept of the completed Project as a functioning whole; and 3) it has a proven record of performance and availability of responsive service; and b. Contractor certifies that, if approved and incorporated into the Work: 1) there will be no increase in cost to the City or increase in Contract Time; and 00 73 10- 15 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 15 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 2) it will conform substantially to the detailed requirements of the item named in the Contract Documents. 2. Substitute Items: a. If in City’s sole discretion an item of material or equipment proposed by Contractor does not qualify as an “or-equal” item under Paragraph 5.05.A.1, it may be submitted as a proposed substitute item. b. Contractor shall submit sufficient information as provided below to allow City to determine if the item of material or equipment proposed is essentially equivalent to that named and an acceptable substitute therefor. Requests for review of proposed substitute items of material or equipment will not be accepted by City from anyone other than Contractor. c. Contractor shall make written application to City for review of a proposed substitute item of material or equipment that Contractor seeks to furnish or use. The application shall comply with Section 01 25 00 and: 1) shall certify that the proposed substitute item will: i. perform adequately the functions and achieve the results called for by the general design; ii. be similar in substance to that specified; iii. be suited to the same use as that specified; and 2) will state: i. the extent, if any, to which the use of the proposed substitute item will prejudice Contractor’s achievement of final completion on time; ii. whether use of the proposed substitute item in the Work will require a change in any of the Contract Documents (or in the provisions of any other direct contract with City for other work on the Project) to adapt the design to the proposed substitute item; iii. whether incorporation or use of the proposed substitute item in connection with the Work is subject to payment of any license fee or royalty; and 3) will identify: i. all variations of the proposed substitute item from that specified; ii. available engineering, sales, maintenance, repair, and replacement services; and 00 73 10- 16 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 16 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 4) shall contain an itemized estimate of all costs or credits that will result directly or indirectly from use of such substitute item, including costs of redesign and Damage Claims of other contractors affected by any resulting change. B. Substitute Construction Methods or Procedures: If a specific means, method, technique, sequence, or procedure of construction is expressly required by the Contract Documents, Contractor may furnish or utilize a substitute means, method, technique, sequence, or procedure of construction approved by City. Contractor shall submit sufficient information to allow City, in City’s sole discretion, to determine that the substitute proposed is equivalent to that expressly called for by the Contract Documents. Contractor shall make written application to City for review in the same manner as those provided in Paragraph 5.05.A.2. C. City’s Evaluation: City will be allowed a reasonable time within which to evaluate each proposal or submittal made pursuant to Paragraphs 5.05.A and 5.05.B. City may require Contractor to furnish additional data about the proposed substitute. City will be the sole judge of acceptability. No “or-equal” or substitute will be ordered, installed or utilized until City’s review is complete, which will be evidenced by a Change Order in the case of a substitute and an accepted Submittal for an “or-equal.” City will advise Contractor in writing of its determination. D. Special Guarantee: City may require Contractor to furnish at Contractor’s expense a special performance guarantee, warranty, or other surety with respect to any substitute. Contractor shall indemnify and hold harmless City and anyone directly or indirectly employed by them from and against any and all claims, damages, losses and expenses (including attorneys fees) arising out of the use of substituted materials or equipment. E. City’s Cost Reimbursement: City will record City’s costs in evaluating a substitute proposed or submitted by Contractor pursuant to Paragraphs 5.05.A.2 and 5.05.B. Whether or not City approves a substitute so proposed or submitted by Contractor, Contractor may be required to reimburse City for evaluating each such proposed substitute. Contractor may also be required to reimburse City for the charges for making changes in the Contract Documents. F. Contractor’s Expense: Contractor shall provide all data in support of any proposed substitute or “or-equal” at Contractor’s expense. G. Substitute Reimbursement: Costs (savings or charges) attributable to acceptance of a substitute shall be incorporated to the Contract by Participating Change Order. 5.06 Pre-Qualification of Bidders (Prime Contractors and Subcontractors) A. The Contractor and any subcontractors are required to be prequalified for the work types requiring pre-qualification 5.07 Concerning Subcontractors, Suppliers, and Others A. Minority and Women Owned Business Enterprise Compliance: 00 73 10- 17 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 17 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 Required for this Contract. (Check this box if there is any City Participation) Not Required for this Contract. It is City policy to ensure the full and equitable participation by Minority and Women Business Enterprises (MWBE) in the procurement of goods and services on a contractual basis. If the Contract Documents provide for a MWBE goal, Contractor is required to comply with the intent of the City’s MWBE Ordinance (as amended) by the following: 1.Contractor shall, upon request by City, provide complete and accurate information regarding actual work performed by a MWBE on the Contract and payment therefor. 2.Contractor will not make additions, deletions, or substitutions of accepted MWBE without written consent of the City. Any unjustified change or deletion shall be a material breach of Contract and may result in debarment in accordance with the procedures outlined in the Ordinance. 3.Contractor shall, upon request by City, allow an audit and/or examination of any books, records, or files in the possession of the Contractor that will substantiate the actual work performed by an MWBE. Material misrepresentation of any nature will be grounds for termination of the Contract. Any such misrepresentation may be grounds for disqualification of Contractor to bid on future contracts with the City for a period of not less than three years. B. Contractor shall be fully responsible to City for all acts and omissions of the Subcontractors, Suppliers, and other individuals or entities performing or furnishing any of the Work just as Contractor is responsible for Contractor’s own acts and omissions. Nothing in the Contract Documents: 1.shall create for the benefit of any such Subcontractor, Supplier, or other individual or entity any contractual relationship between City and any such Subcontractor, Supplier or other individual or entity; nor 2.shall create any obligation on the part of City to pay or to see to the payment of any moneys due any such Subcontractor, Supplier, or other individual or entity except as may otherwise be required by Laws and Regulations. C. Contractor shall be solely responsible for scheduling and coordinating the Work of Subcontractors, Suppliers, and other individuals or entities performing or furnishing any of the Work under a direct or indirect contract with Contractor. D. All Subcontractors, Suppliers, and such other individuals or entities performing or furnishing any of the Work shall communicate with City through Contractor. E. All Work performed for Contractor by a Subcontractor or Supplier will be pursuant to an appropriate agreement between Contractor and the Subcontractor or Supplier which specifically binds the Subcontractor or Supplier to the applicable terms and conditions of these Contract x 00 73 10- 18 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 18 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 Documents, Contractor shall provide City contract numbers and reference numbers to the Subcontractors and/or Suppliers. 5.08 Wage Rates Required for this Contract. Not Required for this Contract. A. Duty to pay Prevailing Wage Rates. The Contractor shall comply with all requirements of Chapter 2258, Texas Government Code (as amended), including the payment of not less than the rates determined by the City Council of the City of Fort Worth to be the prevailing wage rates in accordance with Chapter 2258. Such prevailing wage rates are included in these Contract Documents. B. Penalty for Violation. A Contractor or any Subcontractor who does not pay the prevailing wage shall, upon demand made by the City, pay to the City $60 for each worker employed for each calendar day or part of the day that the worker is paid less than the prevailing wage rates stipulated in these contract documents. This penalty shall be retained by the City to offset its administrative costs, pursuant to Texas Government Code 2258.023. C. Complaints of Violations and City Determination of Good Cause. On receipt of information, including a complaint by a worker, concerning an alleged violation of 2258.023, Texas Government Code, by a Contractor or Subcontractor, the City shall make an initial determination, before the 31st day after the date the City receives the information, as to whether good cause exists to believe that the violation occurred. The City shall notify in writing the Contractor or Subcontractor and any affected worker of its initial determination. Upon the City’s determination that there is good cause to believe the Contractor or Subcontractor has violated Chapter 2258, the City shall retain the full amounts claimed by the claimant or claimants as the difference between wages paid and wages due under the prevailing wage rates, such amounts being subtracted from successive progress payments pending a final determination of the violation. D. Arbitration Required if Violation Not Resolved. An issue relating to an alleged violation of Section 2258.023, Texas Government Code, including a penalty owed to the City or an affected worker, shall be submitted to binding arbitration in accordance with the Texas General Arbitration Act (Article 224 et seq., Revised Statutes) if the Contractor or Subcontractor and any affected worker does not resolve the issue by agreement before the 15th day after the date the City makes its initial determination pursuant to Paragraph C above. If the persons required to arbitrate under this section do not agree on an arbitrator before the 11th day after the date that arbitration is required, a district court shall appoint an arbitrator on the petition of any of the persons. The City is not a party in the arbitration. The decision and award of the arbitrator is final and binding on all parties and may be enforced in any court of competent jurisdiction. E. Records to be Maintained. The Contractor and each Subcontractor shall, for a period of three (3) years following the date of acceptance of the work, maintain records that show (i) the name and x 00 73 10- 19 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 19 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 occupation of each worker employed by the Contractor in the construction of the Work provided for in this Contract; and (ii) the actual per diem wages paid to each worker. The records shall be open at all reasonable hours for inspection by the City. The provisions of Paragraph 6.23, Right to Audit, shall pertain to this inspection. F. Progress Payments. With each progress payment or payroll period, whichever is less, the Contractor shall submit an affidavit stating that the Contractor has complied with the requirements of Chapter 2258, Texas Government Code. G. Posting of Wage Rates. The Contractor shall post prevailing wage rates in a conspicuous place at all times. H. Subcontractor Compliance. The Contractor shall include in its subcontracts and/or shall otherwise require all of its Subcontractors to comply with Paragraphs A through G above. 5.09 Patent Fees and Royalties A. To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless City, from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to any infringement of patent rights or copyrights incident to the use in the performance of the Work or resulting from the incorporation in the Work of any invention, design, process, product, or device not specified in the Contract Documents. 5.10 Laws and Regulations A. Contractor shall give all notices required by and shall comply with all Laws and Regulations applicable to the performance of the Work. Except where otherwise expressly required by applicable Laws and Regulations, the City shall not be responsible for monitoring Contractor’s compliance with any Laws or Regulations. B. If Contractor performs any Work knowing or having reason to know that it is contrary to Laws or Regulations, Contractor shall bear all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such Work. However, it shall not be Contractor’s responsibility to make certain that the Specifications and Drawings are in accordance with Laws and Regulations, but this shall not relieve Contractor of Contractor’s obligations under Paragraph 3.01. 5.11 Use of Site and Other Areas A. Limitation on Use of Site and Other Areas: 1.Contractor shall confine construction equipment, the storage of materials and equipment, and the operations of workers to the Site and other areas permitted by Laws and Regulations, and shall not unreasonably encumber the Site and other areas with construction equipment or 00 73 10- 20 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 20 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 other materials or equipment. Contractor shall assume full responsibility for any damage to any such land or area, or to the owner or occupant thereof, or of any adjacent land or areas resulting from the performance of the Work. 2.At any time when, in the judgment of the City, the Contractor has obstructed or closed or is carrying on operations in a portion of a street, right-of-way, or easement greater than is necessary for proper execution of the Work, the City may require the Contractor to finish the section on which operations are in progress before work is commenced on any additional area of the Site. 3.Should any Damage Claim be made by any such owner or occupant because of the performance of the Work, Contractor shall promptly attempt to resolve the Damage Claim. 4.Pursuant to Paragraph 5.18, Contractor shall indemnify and hold harmless City, from and against all claims, costs, losses, and damages arising out of or relating to any claim or action, legal or equitable, brought by any such owner or occupant against City. B. Removal of Debris During Performance of the Work: During the progress of the Work Contractor shall keep the Site and other areas free from accumulations of waste materials, rubbish, and other debris. Removal and disposal of such waste materials, rubbish, and other debris shall conform to applicable Laws and Regulations. C. Site Maintenance Cleaning: 24 hours after written notice is given to the Contractor that the clean-up on the job site is proceeding in a manner unsatisfactory to the City or Developer, if the Contractor fails to correct the unsatisfactory procedure, the City may take such direct action as the City deems appropriate to correct the clean-up deficiencies cited to the Contractor in the written notice (by letter or electronic communication), and shall be entitled to recover its cost in doing so. The City may withhold Final Acceptance until clean-up is complete and cost are recovered. D. Final Site Cleaning: Prior to Final Acceptance of the Work Contractor shall clean the Site and the Work and make it ready for utilization by City or adjacent property owner. At the completion of the Work Contractor shall remove from the Site all tools, appliances, construction equipment and machinery, and surplus materials and shall restore to original condition or better all property disturbed by the Work. E. Loading Structures: Contractor shall not load nor permit any part of any structure to be loaded in any manner that will endanger the structure, nor shall Contractor subject any part of the Work or adjacent property to stresses or pressures that will endanger it. 5.12 Record Documents A. Contractor shall maintain in a safe place at the Site or in a place designated by the Contractor and approved by the City, one (1) record copy of all Drawings, Specifications, Addenda, Change Orders, Field Orders, and written interpretations and clarifications in good order and annotated to show changes made during construction. These record documents together with all approved 00 73 10- 21 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 21 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 Samples and a counterpart of all accepted Submittals will be available to City for reference. Upon completion of the Work, these record documents, any operation and maintenance manuals, and Submittals will be delivered to City prior to Final Inspection. Contractor shall include accurate locations for buried and imbedded items. 5.13 Safety and Protection A. Contractor shall be solely responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the Work. Such responsibility does not relieve Subcontractors of their responsibility for the safety of persons or property in the performance of their work, nor for compliance with applicable safety Laws and Regulations. Contractor shall take all necessary precautions for the safety of, and shall provide the necessary protection to prevent damage, injury or loss to: 1. all persons on the Site or who may be affected by the Work; 2. all the Work and materials and equipment to be incorporated therein, whether in storage on or off the Site; and 3. other property at the Site or adjacent thereto, including trees, shrubs, lawns, walks, pavements, roadways, structures, utilities, and Underground Facilities not designated for removal, relocation, or replacement in the course of construction. B. Contractor shall comply with all applicable Laws and Regulations relating to the safety of persons or property, or to the protection of persons or property from damage, injury, or loss; and shall erect and maintain all necessary safeguards for such safety and protection. Contractor shall notify owners of adjacent property and of Underground Facilities and other utility owners when prosecution of the Work may affect them, and shall cooperate with them in the protection, removal, relocation, and replacement of their property. C. Contractor shall comply with the applicable requirements of City’s safety programs, if any. D. Contractor shall inform City of the specific requirements of Contractor’s safety program, if any, with which City’s employees and representatives must comply while at the Site. E. All damage, injury, or loss to any property referred to in Paragraph 5.13.A.2 or 5.13.A.3 caused, directly or indirectly, in whole or in part, by Contractor, any Subcontractor, Supplier, or any other individual or entity directly or indirectly employed by any of them to perform any of the Work, or anyone for whose acts any of them may be liable, shall be remedied by Contractor. F. Contractor’s duties and responsibilities for safety and for protection of the Work shall continue until such time as all the Work is completed and City has accepted the Work. 5.14 Safety Representative Contractor shall inform City in writing of Contractor’s designated safety representative at the Site. 00 73 10- 22 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 22 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 5.15 Hazard Communication Programs Contractor shall be responsible for coordinating any exchange of material safety data sheets or other hazard communication information required to be made available to or exchanged between or among employers in accordance with Laws or Regulations. 5.16 Submittals A. Contractor shall submit required Submittals to City for review and acceptance. Each submittal will be identified as required by City. 1. Submit number of copies specified in the General Requirements. 2. Data shown on the Submittals will be complete with respect to quantities, dimensions, specified performance and design criteria, materials, and similar data to show City the services, materials, and equipment Contractor proposes to provide and to enable City to review the information for the limited purposes required by Paragraph 5.16.C. 3. Submittals submitted as herein provided by Contractor and reviewed by City for conformance with the design concept shall be executed in conformity with the Contract Documents unless otherwise required by City. 4. When Submittals are submitted for the purpose of showing the installation in greater detail, their review shall not excuse Contractor from requirements shown on the Drawings and Specifications. 5. For-Information-Only submittals upon which the City is not expected to conduct review or take responsive action may be so identified in the Contract Documents. 6. Submit required number of Samples specified in the Specifications. 7. Clearly identify each Sample as to material, Supplier, pertinent data such as catalog numbers, the use for which intended and other data as City may require to enable City to review the submittal for the limited purposes required by Paragraph 5.16.C. B. Where a Submittal is required by the Contract Documents or the Schedule of Submittals, any related Work performed prior to City’s review and acceptance of the pertinent submittal will be at the sole expense and responsibility of Contractor. C. City’s Review: 1. City will provide timely review of required Submittals in accordance with the Schedule of Submittals acceptable to City. City’s review and acceptance will be only to determine if the items covered by the submittals will, after installation or incorporation in the Work, conform to the information given in the Contract Documents and be compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. 00 73 10- 23 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 23 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 2.City’s review and acceptance will not extend to means, methods, techniques, sequences, or procedures of construction (except where a particular means, method, technique, sequence, or procedure of construction is specifically and expressly called for by the Contract Documents) or to safety precautions or programs incident thereto. The review and acceptance of a separate item as such will not indicate approval of the assembly in which the item functions. 3.City’s review and acceptance shall not relieve Contractor from responsibility for any variation from the requirements of the Contract Documents unless Contractor has complied with the requirements of Section 01 33 00 and City has given written acceptance of each such variation by specific written notation thereof incorporated in or accompanying the Submittal. City’s review and acceptance shall not relieve Contractor from responsibility for complying with the requirements of the Contract Documents. 5.17 Contractor’s General Warranty and Guarantee A. Contractor warrants and guarantees to City that all Work will be in accordance with the Contract Documents and will not be defective. City and its officers, directors, members, partners, employees, agents, consultants, and subcontractors shall be entitled to rely on representation of Contractor’s warranty and guarantee. B. Contractor’s warranty and guarantee hereunder excludes defects or damage caused by: 1.abuse, modification, or improper maintenance or operation by persons other than Contractor, Subcontractors, Suppliers, or any other individual or entity for whom Contractor is responsible; or 2.normal wear and tear under normal usage. C. Contractor’s obligation to perform and complete the Work in accordance with the Contract Documents shall be absolute. None of the following will constitute an acceptance of Work that is not in accordance with the Contract Documents or a release of Contractor’s obligation to perform the Work in accordance with the Contract Documents: 1.observations by City; 2.recommendation or payment by City or Developer of any progress or final payment; 3.the issuance of a certificate of Final Acceptance by City or any payment related thereto by City; 4.use or occupancy of the Work or any part thereof by City; 5.any review and acceptance of a Submittal by City; 6.any inspection, test, or approval by others; or 00 73 10- 24 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 24 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 7. any correction of defective Work by City. D. The Contractor shall remedy any defects or damages in the Work and pay for any damage to other work or property resulting therefrom which shall appear within a period of two (2) years from the date of Final Acceptance of the Work unless a longer period is specified and shall furnish a good and sufficient maintenance bond, complying with the requirements of Article 4.02.B. The City will give notice of observed defects with reasonable promptness. 5.18 Indemnification A. Contractor covenants and agrees to indemnify, hold harmless and defend, at its own expense, the City, its officers, servants and employees, from and against any and all claims arising out of, or alleged to arise out of, the work and services to be performed by the Contractor, its officers, agents, employees, subcontractors, licenses or invitees under this Contract. THIS INDEMNIFICATION PROVISION IS SPECIFICALLY INTENDED TO OPERATE AND BE EFFECTIVE EVEN IF IT IS ALLEGED OR PROVEN THAT ALL OR SOME OF THE DAMAGES BEING SOUGHT WERE CAUSED, IN WHOLE OR IN PART, BY ANY ACT, OMISSION OR NEGLIGENCE OF THE CITY. This indemnity provision is intended to include, without limitation, indemnity for costs, expenses and legal fees incurred by the City in defending against such claims and causes of actions. B. Contractor covenants and agrees to indemnify and hold harmless, at its own expense, the City, its officers, servants and employees, from and against any and all loss, damage or destruction of property of the City, arising out of, or alleged to arise out of, the work and services to be performed by the Contractor, its officers, agents, employees, subcontractors, licensees or invitees under this Contract. THIS INDEMNIFICATION PROVISION IS SPECIFICALLY INTENDED TO OPERATE AND BE EFFECTIVE EVEN IF IT IS ALLEGED OR PROVEN THAT ALL OR SOME OF THE DAMAGES BEING SOUGHT WERE CAUSED, IN WHOLE OR IN PART, BY ANY ACT, OMISSION OR NEGLIGENCE OF THE CITY. 5.19 Delegation of Professional Design Services A. Contractor will not be required to provide professional design services unless such services are specifically required by the Contract Documents for a portion of the Work or unless such services are required to carry out Contractor’s responsibilities for construction means, methods, techniques, sequences and procedures. B. If professional design services or certifications by a design professional related to systems, materials or equipment are specifically required of Contractor by the Contract Documents, City will specify all performance and design criteria that such services must satisfy. Contractor shall cause such services or certifications to be provided by a properly licensed professional, whose signature and seal shall appear on all drawings, calculations, specifications, certifications, and Submittals prepared by such professional. Submittals related to the Work designed or certified by such professional, if prepared by others, shall bear such professional’s written approval when submitted to City. 00 73 10- 25 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 25 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 C. City shall be entitled to rely upon the adequacy, accuracy and completeness of the services, certifications or approvals performed by such design professionals, provided City has specified to Contractor performance and design criteria that such services must satisfy. D. Pursuant to this Paragraph 5.19, City’s review and acceptance of design calculations and design drawings will be only for the limited purpose of checking for conformance with performance and design criteria given and the design concept expressed in the Contract Documents. City’s review and acceptance of Submittals (except design calculations and design drawings) will be only for the purpose stated in Paragraph 5.16.C. 5.20 Right to Audit: A. The City reserves the right to audit all projects utilizing City funds B. The Contractor agrees that the City shall, until the expiration of three (3) years after final payment under this Contract, have access to and the right to examine and photocopy any directly pertinent books, documents, papers, and records of the Contractor involving transactions relating to this Contract. Contractor agrees that the City shall have access during Regular Working Hours to all necessary Contractor facilities and shall be provided adequate and appropriate work space in order to conduct audits in compliance with the provisions of this Paragraph. The City shall give Contractor reasonable advance notice of intended audits. C. Contractor further agrees to include in all its subcontracts hereunder a provision to the effect that the subcontractor agrees that the City shall, until the expiration of three (3) years after final payment under this Contract, have access to and the right to examine and photocopy any directly pertinent books, documents, papers, and records of such Subcontractor, involving transactions to the subcontract, and further, that City shall have access during Regular Working Hours to all Subcontractor facilities, and shall be provided adequate and appropriate work space in order to conduct audits in compliance with the provisions of this Paragraph. The City shall give Subcontractor reasonable advance notice of intended audits. D. Contractor and Subcontractor agree to photocopy such documents as may be requested by the City. The City agrees to reimburse Contractor for the cost of the copies as follows at the rate published in the Texas Administrative Code in effect as of the time copying is performed. 5.21 Nondiscrimination A. The City is responsible for operating Public Transportation Programs and implementing transit- related projects, which are funded in part with Federal financial assistance awarded by the U.S. Department of Transportation and the Federal Transit Administration (FTA), without discriminating against any person in the United States on the basis of race, color, or national origin. B. Title VI, Civil Rights Act of 1964 as amended: Contractor shall comply with the requirements of the Act and the Regulations as further defined in the Supplementary Conditions for any project receiving Federal assistance. 00 73 10- 26 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 26 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 ARTICLE 6 – OTHER WORK AT THE SITE 6.01 Related Work at Site A. City may perform other work related to the Project at the Site with City’s employees, or other City contractors, or through other direct contracts therefor, or have other work performed by utility owners. If such other work is not noted in the Contract Documents, then written notice thereof will be given to Contractor prior to starting any such other work; and B. Contractor shall afford each other contractor who is a party to such a direct contract, each utility owner, and City, if City is performing other work with City’s employees or other City contractors, proper and safe access to the Site, provide a reasonable opportunity for the introduction and storage of materials and equipment and the execution of such other work, and properly coordinate the Work with theirs. Contractor shall do all cutting, fitting, and patching of the Work that may be required to properly connect or otherwise make its several parts come together and properly integrate with such other work. Contractor shall not endanger any work of others by cutting, excavating, or otherwise altering such work; provided, however, that Contractor may cut or alter others' work with the written consent of City and the others whose work will be affected. C. If the proper execution or results of any part of Contractor’s Work depends upon work performed by others under this Article 7, Contractor shall inspect such other work and promptly report to City in writing any delays, defects, or deficiencies in such other work that render it unavailable or unsuitable for the proper execution and results of Contractor’s Work. Contractor’s failure to so report will constitute an acceptance of such other work as fit and proper for integration with Contractor’s Work except for latent defects in the work provided by others. ARTICLE 7 – CITY’S RESPONSIBILITIES 7.01 Inspections, Tests, and Approvals City’s responsibility with respect to certain inspections, tests, and approvals is set forth in Paragraph 11.03. 7.02 Limitations on City’s Responsibilities A. The City shall not supervise, direct, or have control or authority over, nor be responsible for, Contractor’s means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the performance of the Work. City will not be responsible for Contractor’s failure to perform the Work in accordance with the Contract Documents. B. City will notify the Contractor of applicable safety plans pursuant to Paragraph 5.13. 00 73 10- 27 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 27 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 7.03 Compliance with Safety Program While at the Site, City’s employees and representatives shall comply with the specific applicable requirements of Contractor’s safety programs of which City has been informed pursuant to Paragraph 5.13. ARTICLE 8 – CITY’S OBSERVATION STATUS DURING CONSTRUCTION 8.01 City’s Project Representative City will provide one or more Project Representative(s) during the construction period. The duties and responsibilities and the limitations of authority of City’s representative during construction are set forth in the Contract Documents. A. City’s Project Representative will make visits to the Site at intervals appropriate to the various stages of construction as City deems necessary in order to observe the progress that has been made and the quality of the various aspects of Contractor’s executed Work. Based on information obtained during such visits and observations, City’s Project Representative will determine, in general, if the Work is proceeding in accordance with the Contract Documents. City’s Project Representative will not be required to make exhaustive or continuous inspections on the Site to check the quality or quantity of the Work. City’s Project Representative’s efforts will be directed toward providing City a greater degree of confidence that the completed Work will conform generally to the Contract Documents. B. City’s Project Representative’s visits and observations are subject to all the limitations on authority and responsibility in the Contract Documents. 8.02 Authorized Variations in Work City’s Project Representative may authorize minor variations in the Work from the requirements of the Contract Documents which do not involve an adjustment in the Contract Price or the Contract Time and are compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. These may be accomplished by a Field Order and will be binding on City Developer, and also on Contractor, who shall perform the Work involved promptly. 8.03 Rejecting Defective Work City will have authority to reject Work which City’s Project Representative believes to be defective, or will not produce a completed Project that conforms to the Contract Documents or that will prejudice the integrity of the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. City will have authority to conduct special inspection or testing of the Work as provided in Article 11, whether or not the Work is fabricated, installed, or completed. 00 73 10- 28 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 28 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 8.04 Determinations for Work Performed Contractor will determine the actual quantities and classifications of Work performed. City’s Project Representative will review with Contractor the preliminary determinations on such matters before rendering a written recommendation. City’s written decision will be final (except as modified to reflect changed factual conditions or more accurate data). ARTICLE 9 – CHANGES IN THE WORK 9.01 Authorized Changes in the Work A. Without invalidating the Contract and without notice to any surety, City may, at any time or from time to time, order Extra Work. Upon notice of such Extra Work, Contractor shall promptly proceed with the Work involved which will be performed under the applicable conditions of the Contract Documents (except as otherwise specifically provided). Extra Work shall be memorialized by a Participating Change Order which may or may not precede an order of Extra work. B. For minor changes of Work not requiring changes to Contract Time or Contract Price on a project with City participation, a Field Order may be issued by the City. 9.02 Notification to Surety If the provisions of any bond require notice to be given to a surety of any change affecting the general scope of the Work or the provisions of the Contract Documents (including, but not limited to, Contract Price or Contract Time), the giving of any such notice will be Contractor’s responsibility. The amount of each applicable bond will be adjusted by the Contractor to reflect the effect of any such change. ARTICLE 10 – CHANGE OF CONTRACT PRICE; CHANGE OF CONTRACT TIME 10.01 Change of Contract Price A. The Contract Price may only be changed by a Participating Change Order for projects with City participation. 10.02 Change of Contract Time A. The Contract Time may only be changed by a Participating Change Order for projects with City participation. 10.03 Delays A. If Contractor is delayed, City shall not be liable to Contractor for any claims, costs, losses, or damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) sustained by Contractor on or in connection with any other project or anticipated project. 00 73 10- 29 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 29 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 ARTICLE 11 – TESTS AND INSPECTIONS; CORRECTION, REMOVAL OR ACCEPTANCE OF DEFECTIVE WORK 11.01 Notice of Defects Notice of all defective Work of which City has actual knowledge will be given to Contractor. Defective Work may be rejected, corrected, or accepted as provided in this Article 13. 11.02 Access to Work City, independent testing laboratories, and governmental agencies with jurisdictional interests will have access to the Site and the Work at reasonable times for their observation, inspection, and testing. Contractor shall provide them proper and safe conditions for such access and advise them of Contractor’s safety procedures and programs so that they may comply therewith as applicable. 11.03 Tests and Inspections A. Contractor shall give City timely notice of readiness of the Work for all required inspections, tests, or approvals and shall cooperate with inspection and testing personnel to facilitate required inspections or tests. B. If Contract Documents, Laws or Regulations of any public body having jurisdiction require any of the Work (or part thereof) to be inspected, tested, or approved, Contractor shall assume full responsibility for arranging and obtaining such independent inspections, tests, retests or approvals, pay all costs in connection therewith, and furnish City the required certificates of inspection or approval; excepting, however, those fees specifically identified in the Supplementary Conditions or any Texas Department of Licensure and Regulation (TDLR) inspections, which shall be paid as described in the Supplementary Conditions. C. Contractor shall be responsible for arranging and obtaining and shall pay all costs in connection with any inspections, tests, re-tests, or approvals required for City’s acceptance of materials or equipment to be incorporated in the Work; or acceptance of materials, mix designs, or equipment submitted for approval prior to Contractor’s purchase thereof for incorporation in the Work. Such inspections, tests, re-tests, or approvals shall be performed by organizations approved by City. D. City may arrange for the services of an independent testing laboratory (“Testing Lab”) to perform any inspections or tests (“Testing”) for any part of the Work, as determined solely by City. 1.City will coordinate such Testing to the extent possible, with Contractor; 2.Should any Testing under this Section 11.03 D result in a “fail”, “did not pass” or other similar negative result, the Contractor shall be responsible for paying for any and all retests. Contractor’s cancellation without cause of City initiated Testing shall be deemed a negative result and require a retest. 00 73 10- 30 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 30 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 3. Any amounts owed for any retest under this Section 11.03 D shall be paid directly to the Testing Lab by Contractor. City will forward all invoices for retests to Developer/Contractor. 4. If Contractor fails to pay the Testing Lab, City will not issue a letter of Final Acceptance until the Testing Lab is Paid E. If any Work (or the work of others) that is to be inspected, tested, or approved is covered by Contractor without written concurrence of City, Contractor shall, if requested by City, uncover such Work for observation. 11.04 Uncovering Work A. If any Work is covered contrary to the Contract Documents or specific instructions by the City, it must, if requested by City, be uncovered for City’s observation and replaced at Contractor’s expense. 11.05 City May Stop the Work If the Work is defective, or Contractor fails to supply sufficient skilled workers or suitable materials or equipment, or fails to perform the Work in such a way that the completed Work will conform to the Contract Documents, City may order Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, this right of City to stop the Work shall not give rise to any duty on the part of City to exercise this right for the benefit of Contractor, any Subcontractor, any Supplier, any other individual or entity, or any surety for, or employee or agent of any of them. 11.06 Correction or Removal of Defective Work A. Promptly after receipt of written notice, Contractor shall correct all defective Work pursuant to an acceptable schedule, whether or not fabricated, installed, or completed, or, if the Work has been rejected by City, remove it from the Project and replace it with Work that is not defective. Contractor shall pay all claims, costs, additional testing, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such correction or removal (including but not limited to all costs of repair or replacement of work of others). Failure to require the removal of any defective Work shall not constitute acceptance of such Work. B. When correcting defective Work under the terms of this Paragraph 11.06 or Paragraph 11.07, Contractor shall take no action that would void or otherwise impair City’s special warranty and guarantee, if any, on said Work. 11.07 Correction Period A. If within two (2) years after the date of Final Acceptance (or such longer period of time as may be prescribed by the terms of any applicable special guarantee required by the Contract 00 73 10- 31 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 31 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 Documents), any Work is found to be defective, or if the repair of any damages to the land or areas made available for Contractor’s use by City or permitted by Laws and Regulations as contemplated in Paragraph 5.10.A is found to be defective, Contractor shall promptly, without cost to City and in accordance with City’s written instructions: 1. repair such defective land or areas; or 2. correct such defective Work; or 3. if the defective Work has been rejected by City, remove it from the Project and replace it with Work that is not defective, and 4. satisfactorily correct or repair or remove and replace any damage to other Work, to the work of others or other land or areas resulting therefrom. B. If Contractor does not promptly comply with the terms of City’s written instructions, or in an emergency where delay would cause serious risk of loss or damage, City may have the defective Work corrected or repaired or may have the rejected Work removed and replaced. All claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or other dispute resolution costs) arising out of or relating to such correction or repair or such removal and replacement (including but not limited to all costs of repair or replacement of work of others) will be paid by Contractor. C. Where defective Work (and damage to other Work resulting therefrom) has been corrected or removed and replaced under this Paragraph 11.07, the correction period hereunder with respect to such Work may be required to be extended for an additional period of one year after the end of the initial correction period. City shall provide 30 days written notice to Contractor and Developer should such additional warranty coverage be required. Contractor’s obligations under this Paragraph 11.07 are in addition to any other obligation or warranty. The provisions of this Paragraph 11.07 shall not be construed as a substitute for, or a waiver of, the provisions of any applicable statute of limitation or repose. 11.08 City May Correct Defective Work A. If Contractor fails within a reasonable time after written notice from City to correct defective Work, or to remove and replace rejected Work as required by City in accordance with Paragraph 11.06.A, or if Contractor fails to perform the Work in accordance with the Contract Documents, or if Contractor fails to comply with any other provision of the Contract Documents, City may, after seven (7) days written notice to Contractor and the Developer, correct, or remedy any such deficiency. B. In exercising the rights and remedies under this Paragraph 11.09, City shall proceed expeditiously. In connection with such corrective or remedial action, City may exclude Contractor from all or part of the Site, take possession of all or part of the Work and suspend Contractor’s services related thereto, and incorporate in the Work all materials and equipment incorporated in the Work, stored at the Site or for which City has paid Contractor but which are 00 73 10- 32 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 32 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 stored elsewhere. Contractor shall allow City, City’s representatives, agents, consultants, employees, and City’s other contractors, access to the Site to enable City to exercise the rights and remedies under this Paragraph. C. All claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or other dispute resolution costs) incurred or sustained by City in exercising the rights and remedies under this Paragraph 13.09 will be charged against Contractor, and a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Work; and City shall be entitled to an appropriate decrease in the Contract Price. D. Contractor shall not be allowed an extension of the Contract Time because of any delay in the performance of the Work attributable to the exercise of City’s rights and remedies under this Paragraph 11.09. ARTICLE 12 – COMPLETION 12.01 Contractor’s Warranty of Title Contractor warrants and guarantees that title to all Work, materials, and equipment covered by any Application for Payment will pass to City no later than the time of Final Acceptance and shall be free and clear of all Liens. 12.02 Partial Utilization A. Prior to Final Acceptance of all the Work, City may use or occupy any substantially completed part of the Work which has specifically been identified in the Contract Documents, or which City, determines constitutes a separately functioning and usable part of the Work that can be used by City for its intended purpose without significant interference with Contractor’s performance of the remainder of the Work. City at any time may notify Contractor in writing to permit City to use or occupy any such part of the Work which City determines to be ready for its intended use, subject to the following conditions: 1. Contractor at any time may notify City in writing that Contractor considers any such part of the Work ready for its intended use. 2. Within a reasonable time after notification as enumerated in Paragraph 14.05.A.1, City and Contractor shall make an inspection of that part of the Work to determine its status of completion. If City does not consider that part of the Work to be substantially complete, City will notify Contractor in writing giving the reasons therefor. 3. Partial Utilization will not constitute Final Acceptance by City. 12.03 Final Inspection A. Upon written notice from Contractor that the entire Work is complete in accordance with the Contract Documents: 00 73 10- 33 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 33 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 1.within 10 days, City will schedule a Final Inspection with Contractor. 2.City will notify Contractor in writing of all particulars in which this inspection reveals that the Work is incomplete or defective. Contractor shall immediately take such measures as are necessary to complete such Work or remedy such deficiencies. 12.04 Final Acceptance A. Upon completion by Contractor to City’s satisfaction, of any additional Work identified in the Final Inspection, City will issue to Contractor a letter of Final Acceptance upon the satisfaction of the following: 1.All documentation called for in the Contract Documents, including but not limited to the evidence of insurance required by Paragraph 5.03; 2.consent of the surety, if any, to Final Acceptance; 3.a list of all pending or released Damage Claims against City that Contractor believes are unsettled; and 4.affidavits of payments and complete and legally effective releases or waivers (satisfactory to City) of all Lien rights arising out of or Liens filed in connection with the Work. 5.after all Damage Claims have been resolved: a.directly by the Contractor or; b.Contractor provides evidence that the Damage Claim has been reported to Contractor’s insurance provider for resolution. 6.Issuing Final Acceptance by the City shall not relieve the Contractor of any guarantees or other requirements of the Contract Documents which specifically continue thereafter. ARTICLE 13 – SUSPENSION OF WORK 13.01 City May Suspend Work A. At any time and without cause, City may suspend the Work or any portion thereof by written notice to Contractor and which may fix the date on which Work will be resumed. Contractor shall resume the Work on the date so fixed. During temporary suspension of the Work covered by these Contract Documents, for any reason, the City will stop contract time on City participation projects. B. Should the Contractor not be able to complete a portion of the Project due to causes beyond the control of and without the fault or negligence of the Contractor, and should it be determined by mutual consent of the Contractor and City that a solution to allow construction to proceed is not 00 73 10- 34 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 34 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 available within a reasonable period of time, Contractor may request an extension in Contract Time, directly attributable to any such suspension. C. If it should become necessary to suspend the Work for an indefinite period, the Contractor shall store all materials in such a manner that they will not obstruct or impede the public unnecessarily nor become damaged in any way, and he shall take every precaution to prevent damage or deterioration of the work performed; he shall provide suitable drainage about the work, and erect temporary structures where necessary. ARTICLE 14 – MISCELLANEOUS 14.01 Giving Notice A. Whenever any provision of the Contract Documents requires the giving of written notice, it will be deemed to have been validly given if: 1. delivered in person to the individual or to a member of the firm or to an officer of the corporation for whom it is intended; or 2. delivered at or sent by registered or certified mail, postage prepaid, to the last business address known to the giver of the notice. B. Business address changes must be promptly made in writing to the other party. C. Whenever the Contract Documents specifies giving notice by electronic means such electronic notice shall be deemed sufficient upon confirmation of receipt by the receiving party. 14.02 Computation of Times When any period of time is referred to in the Contract Documents by days, it will be computed to exclude the first and include the last day of such period. If the last day of any such period falls on a Saturday or Sunday or on a day made a legal holiday the next Working Day shall become the last day of the period. 14.03 Cumulative Remedies The duties and obligations imposed by these General Conditions and the rights and remedies available hereunder to the parties hereto are in addition to, and are not to be construed in any way as a limitation of, any rights and remedies available to any or all of them which are otherwise imposed or available by Laws or Regulations, by special warranty or guarantee, or by other provisions of the Contract Documents. The provisions of this Paragraph will be as effective as if repeated specifically in the Contract Documents in connection with each particular duty, obligation, right, and remedy to which they apply. 00 73 10- 35 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 35 of 35 CITY OF FORT WORTH STANDARD CITY CONDITIONS – DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 14.04 Survival of Obligations All representations, indemnifications, warranties, and guarantees made in, required by, or given in accordance with the Contract Documents, as well as all continuing obligations indicated in the Contract Documents, will survive final payment, completion, and acceptance of the Work or termination or completion of the Contract or termination of the services of Contractor. 14.05 Headings Article and paragraph headings are inserted for convenience only and do not constitute parts of these General Conditions. 01 11 00 - 1 SUMMARY OF WORK Page 1 of 3 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised December 20, 2012 1 SECTION 01 11 00 2 SUMMARY OF WORK 3 PART 1 - GENERAL 4 1.1 SUMMARY 5 A. Section Includes: 6 1. Summary of Work to be performed in accordance with the Contract Documents 7 B. Deviations from this City of Fort Worth Standard Specification 8 1. None. 9 C. Related Specification Sections include, but are not necessarily limited to: 10 1. Division 0 - Bidding Requirements, Contract Forms, and Conditions of the Contract 11 2. Division 1 - General Requirements 12 1.2 PRICE AND PAYMENT PROCEDURES 13 A. Measurement and Payment 14 1. Work associated with this Item is considered subsidiary to the various items bid. 15 No separate payment will be allowed for this Item. 16 1.3 REFERENCES [NOT USED] 17 1.4 ADMINISTRATIVE REQUIREMENTS 18 A. Work Covered by Contract Documents 19 1. Work is to include furnishing all labor, materials, and equipment, and performing 20 all Work necessary for this construction project as detailed in the Drawings and 21 Specifications. 22 B. Subsidiary Work 23 1. Any and all Work specifically governed by documentary requirements for the 24 project, such as conditions imposed by the Drawings or Contract Documents in 25 which no specific item for bid has been provided for in the Proposal and the item is 26 not a typical unit bid item included on the standard bid item list, then the item shall 27 be considered as a subsidiary item of Work, the cost of which shall be included in 28 the price bid in the Proposal for various bid items. 29 C. Use of Premises 30 1. Coordinate uses of premises under direction of the City. 31 2. Assume full responsibility for protection and safekeeping of materials and 32 equipment stored on the Site. 33 3. Use and occupy only portions of the public streets and alleys, or other public places 34 or other rights-of-way as provided for in the ordinances of the City, as shown in the 35 Contract Documents, or as may be specifically authorized in writing by the City. 36 a. A reasonable amount of tools, materials, and equipment for construction 37 purposes may be stored in such space, but no more than is necessary to avoid 38 delay in the construction operations. 01 11 00 - 2 SUMMARY OF WORK Page 2 of 3 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised December 20, 2012 1 b. Excavated and waste materials shall be stored in such a way as not to interfere 2 with the use of spaces that may be designated to be left free and unobstructed 3 and so as not to inconvenience occupants of adjacent property. 4 c. If the street is occupied by railroad tracks, the Work shall be carried on in such 5 manner as not to interfere with the operation of the railroad. 6 1) All Work shall be in accordance with railroad requirements set forth in 7 Division 0 as well as the railroad permit. 8 D. Work within Easements 9 1. Do not enter upon private property for any purpose without having previously 10 obtained permission from the owner of such property. 11 2. Do not store equipment or material on private property unless and until the 12 specified approval of the property owner has been secured in writing by the 13 Contractor and a copy furnished to the City. 14 3. Unless specifically provided otherwise, clear all rights-of-way or easements of 15 obstructions which must be removed to make possible proper prosecution of the 16 Work as a part of the project construction operations. 17 4. Preserve and use every precaution to prevent damage to, all trees, shrubbery, plants, 18 lawns, fences, culverts, curbing, and all other types of structures or improvements, 19 to all water, sewer, and gas lines, to all conduits, overhead pole lines, or 20 appurtenances thereof, including the construction of temporary fences and to all 21 other public or private property adjacent to the Work. 22 5. Notify the proper representatives of the owners or occupants of the public or private 23 lands of interest in lands which might be affected by the Work. 24 a. Such notice shall be made at least 48 hours in advance of the beginning of the 25 Work. 26 b. Notices shall be applicable to both public and private utility companies and any 27 corporation, company, individual, or other, either as owners or occupants, 28 whose land or interest in land might be affected by the Work. 29 c. Be responsible for all damage or injury to property of any character resulting 30 from any act, omission, neglect, or misconduct in the manner or method or 31 execution of the Work, or at any time due to defective work, material, or 32 equipment. 33 6. Fence 34 a. Restore all fences encountered and removed during construction of the Project 35 to the original or a better than original condition. 36 b. Erect temporary fencing in place of the fencing removed whenever the Work is 37 not in progress and when the site is vacated overnight, and/or at all times to 38 provide site security. 39 c. The cost for all fence work within easements, including removal, temporary 40 closures and replacement, shall be subsidiary to the various items bid in the 41 project proposal, unless a bid item is specifically provided in the proposal. 01 11 00 - 3 SUMMARY OF WORK Page 3 of 3 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised December 20, 2012 1 1.5 SUBMITTALS [NOT USED] 2 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 3 1.7 CLOSEOUT SUBMITTALS [NOT USED] 4 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 5 1.9 QUALITY ASSURANCE [NOT USED] 6 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] 7 1.11 FIELD [SITE] CONDITIONS [NOT USED] 8 1.12 WARRANTY [NOT USED] 9 PART 2 - PRODUCTS [NOT USED] 10 PART 3 - EXECUTION [NOT USED] 11 END OF SECTION 12 Revision Log DATE NAME SUMMARY OF CHANGE 13 01 31 19 - 1 PRECONSTRUCTION MEETING Page 1 of 3 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised August 17, 2012 1 SECTION 01 31 19 2 PRECONSTRUCTION MEETING 3 PART 1 - GENERAL 4 1.1 SUMMARY 5 A. Section Includes: 6 1. Provisions for the preconstruction meeting to be held prior to the start of Work to 7 clarify construction contract administration procedures 8 B. Deviations from this City of Fort Worth Standard Specification 9 1. None. 10 C. Related Specification Sections include, but are not necessarily limited to: 11 1. Division 0 – Bidding Requirements, Contract Forms and Conditions of the Contract 12 2. Division 1 – General Requirements 13 1.2 PRICE AND PAYMENT PROCEDURES 14 A. Measurement and Payment 15 1. Work associated with this Item is considered subsidiary to the various items bid. 16 No separate payment will be allowed for this Item. 17 1.3 REFERENCES [NOT USED] 18 1.4 ADMINISTRATIVE REQUIREMENTS 19 A. Coordination 20 1. Attend preconstruction meeting. 21 2. Representatives of Contractor, subcontractors and suppliers attending meetings 22 shall be qualified and authorized to act on behalf of the entity each represents. 23 3. Meeting administered by City may be tape recorded. 24 a. If recorded, tapes will be used to prepare minutes and retained by City for 25 future reference. 26 B. Preconstruction Meeting 27 1. A preconstruction meeting will be held within 14 days after the execution of the 28 Agreement and before Work is started. 29 a. The meeting will be scheduled and administered by the City. 30 2. The Project Representative will preside at the meeting, prepare the notes of the 31 meeting and distribute copies of same to all participants who so request by fully 32 completing the attendance form to be circulated at the beginning of the meeting. 33 3. Attendance shall include: 34 a. Project Representative 35 b. Contractor's project manager 36 c. Contractor's superintendent 37 d. Any subcontractor or supplier representatives whom the Contractor may desire 38 to invite or the City may request 01 31 19 - 2 PRECONSTRUCTION MEETING Page 2 of 3 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised August 17, 2012 1 e. Other City representatives 2 f. Others as appropriate 3 4. Construction Schedule 4 a. Prepare baseline construction schedule in accordance with Section 01 32 16 and 5 provide at Preconstruction Meeting. 6 b. City will notify Contractor of any schedule changes upon Notice of 7 Preconstruction Meeting. 8 5. Preliminary Agenda may include: 9 a. Introduction of Project Personnel 10 b. General Description of Project 11 c. Status of right-of-way, utility clearances, easements or other pertinent permits 12 d. Contractor’s work plan and schedule 13 e. Contract Time 14 f. Notice to Proceed 15 g. Construction Staking 16 h. Progress Payments 17 i. Extra Work and Change Order Procedures 18 j. Field Orders 19 k. Disposal Site Letter for Waste Material 20 l. Insurance Renewals 21 m. Payroll Certification 22 n. Material Certifications and Quality Control Testing 23 o. Public Safety and Convenience 24 p. Documentation of Pre-Construction Conditions 25 q. Weekend Work Notification 26 r. Legal Holidays 27 s. Trench Safety Plans 28 t. Confined Space Entry Standards 29 u. Coordination with the City’s representative for operations of existing water 30 systems 31 v. Storm Water Pollution Prevention Plan 32 w. Coordination with other Contractors 33 x. Early Warning System 34 y. Contractor Evaluation 35 z. Special Conditions applicable to the project 36 aa. Damages Claims 37 bb. Submittal Procedures 38 cc. Substitution Procedures 39 dd. Correspondence Routing 40 ee. Record Drawings 41 ff. Temporary construction facilities 42 gg. M/WBE or MBE/SBE procedures 43 hh. Final Acceptance 44 ii. Final Payment 45 jj. Questions or Comments 01 31 19 - 3 PRECONSTRUCTION MEETING Page 3 of 3 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised August 17, 2012 1 1.5 SUBMITTALS [NOT USED] 2 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 3 1.7 CLOSEOUT SUBMITTALS [NOT USED] 4 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 5 1.9 QUALITY ASSURANCE [NOT USED] 6 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] 7 1.11 FIELD [SITE] CONDITIONS [NOT USED] 8 1.12 WARRANTY [NOT USED] 9 PART 2 - PRODUCTS [NOT USED] 10 PART 3 - EXECUTION [NOT USED] 11 END OF SECTION 12 Revision Log DATE NAME SUMMARY OF CHANGE 13 01 33 00 - 1 SUBMITTALS Page 1 of 8 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised December 20, 2012 1 SECTION 01 33 00 2 SUBMITTALS 3 PART 1 - GENERAL 4 1.1 SUMMARY 5 A. Section Includes: 6 1. General methods and requirements of submissions applicable to the following 7 Work-related submittals: 8 a. Shop Drawings 9 b. Product Data (including Standard Product List submittals) 10 c. Samples 11 d. Mock Ups 12 B. Deviations from this City of Fort Worth Standard Specification 13 1. None. 14 C. Related Specification Sections include, but are not necessarily limited to: 15 1. Division 0 – Bidding Requirements, Contract Forms and Conditions of the Contract 16 2. Division 1 – General Requirements 17 1.2 PRICE AND PAYMENT PROCEDURES 18 A. Measurement and Payment 19 1. Work associated with this Item is considered subsidiary to the various items bid. 20 No separate payment will be allowed for this Item. 21 1.3 REFERENCES [NOT USED] 22 1.4 ADMINISTRATIVE REQUIREMENTS 23 A. Coordination 24 1. Notify the City in writing, at the time of submittal, of any deviations in the 25 submittals from the requirements of the Contract Documents. 26 2. Coordination of Submittal Times 27 a. Prepare, prioritize and transmit each submittal sufficiently in advance of 28 performing the related Work or other applicable activities, or within the time 29 specified in the individual Work Sections, of the Specifications. 30 b. Contractor is responsible such that the installation will not be delayed by 31 processing times including, but not limited to: 32 a) Disapproval and resubmittal (if required) 33 b) Coordination with other submittals 34 c) Testing 35 d) Purchasing 36 e) Fabrication 37 f) Delivery 38 g) Similar sequenced activities 39 c. No extension of time will be authorized because of the Contractor's failure to 40 transmit submittals sufficiently in advance of the Work. 01 33 00 - 2 SUBMITTALS Page 2 of 8 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised December 20, 2012 1 d. Make submittals promptly in accordance with approved schedule, and in such 2 sequence as to cause no delay in the Work or in the work of any other 3 contractor. 4 B. Submittal Numbering 5 1. When submitting shop drawings or samples, utilize a 9-character submittal cross- 6 reference identification numbering system in the following manner: 7 a. Use the first 6 digits of the applicable Specification Section Number. 8 b. For the next 2 digits number use numbers 01-99 to sequentially number each 9 initial separate item or drawing submitted under each specific Section number. 10 c. Last use a letter, A-Z, indicating the resubmission of the same drawing (i.e. 11 A=2nd submission, B=3rd submission, C=4th submission, etc.). A typical 12 submittal number would be as follows: 13 14 03 30 00-08-B 15 16 1) 03 30 00 is the Specification Section for Concrete 17 2) 08 is the eighth initial submittal under this Specification Section 18 3) B is the third submission (second resubmission) of that particular shop 19 drawing 20 C. Contractor Certification 21 1. Review shop drawings, product data and samples, including those by 22 subcontractors, prior to submission to determine and verify the following: 23 a. Field measurements 24 b. Field construction criteria 25 c. Catalog numbers and similar data 26 d. Conformance with the Contract Documents 27 2. Provide each shop drawing, sample and product data submitted by the Contractor 28 with a Certification Statement affixed including: 29 a. The Contractor's Company name 30 b. Signature of submittal reviewer 31 c. Certification Statement 32 1) “By this submittal, I hereby represent that I have determined and verified 33 field measurements, field construction criteria, materials, dimensions, 34 catalog numbers and similar data and I have checked and coordinated each 35 item with other applicable approved shop drawings." 36 D. Submittal Format 37 1. Fold shop drawings larger than 8 ½ inches x 11 inches to 8 ½ inches x 11inches. 38 2. Bind shop drawings and product data sheets together. 39 3. Order 40 a. Cover Sheet 41 1) Description of Packet 42 2) Contractor Certification 43 b. List of items / Table of Contents 44 c. Product Data /Shop Drawings/Samples /Calculations 45 E. Submittal Content 46 1. The date of submission and the dates of any previous submissions 01 33 00 - 3 SUBMITTALS Page 3 of 8 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised December 20, 2012 1 2. The Project title and number 2 3. Contractor identification 3 4. The names of: 4 a. Contractor 5 b. Supplier 6 c. Manufacturer 7 5. Identification of the product, with the Specification Section number, page and 8 paragraph(s) 9 6. Field dimensions, clearly identified as such 10 7. Relation to adjacent or critical features of the Work or materials 11 8. Applicable standards, such as ASTM or Federal Specification numbers 12 9. Identification by highlighting of deviations from Contract Documents 13 10. Identification by highlighting of revisions on resubmittals 14 11. An 8-inch x 3-inch blank space for Contractor and City stamps 15 F. Shop Drawings 16 1. As specified in individual Work Sections includes, but is not necessarily limited to: 17 a. Custom-prepared data such as fabrication and erection/installation (working) 18 drawings 19 b. Scheduled information 20 c. Setting diagrams 21 d. Actual shopwork manufacturing instructions 22 e. Custom templates 23 f. Special wiring diagrams 24 g. Coordination drawings 25 h. Individual system or equipment inspection and test reports including: 26 1) Performance curves and certifications 27 i. As applicable to the Work 28 2. Details 29 a. Relation of the various parts to the main members and lines of the structure 30 b. Where correct fabrication of the Work depends upon field measurements 31 1) Provide such measurements and note on the drawings prior to submitting 32 for approval. 33 G. Product Data 34 1. For submittals of product data for products included on the City’s Standard Product 35 List, clearly identify each item selected for use on the Project. 36 2. For submittals of product data for products not included on the City’s Standard 37 Product List, submittal data may include, but is not necessarily limited to: 38 a. Standard prepared data for manufactured products (sometimes referred to as 39 catalog data) 40 1) Such as the manufacturer's product specification and installation 41 instructions 42 2) Availability of colors and patterns 43 3) Manufacturer's printed statements of compliances and applicability 44 4) Roughing-in diagrams and templates 45 5) Catalog cuts 46 6) Product photographs 01 33 00 - 4 SUBMITTALS Page 4 of 8 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised December 20, 2012 1 7) Standard wiring diagrams 2 8) Printed performance curves and operational-range diagrams 3 9) Production or quality control inspection and test reports and certifications 4 10) Mill reports 5 11) Product operating and maintenance instructions and recommended 6 spare-parts listing and printed product warranties 7 12) As applicable to the Work 8 H. Samples 9 1. As specified in individual Sections, include, but are not necessarily limited to: 10 a. Physical examples of the Work such as: 11 1) Sections of manufactured or fabricated Work 12 2) Small cuts or containers of materials 13 3) Complete units of repetitively used products color/texture/pattern swatches 14 and range sets 15 4) Specimens for coordination of visual effect 16 5) Graphic symbols and units of Work to be used by the City for independent 17 inspection and testing, as applicable to the Work 18 I. Do not start Work requiring a shop drawing, sample or product data nor any material to 19 be fabricated or installed prior to the approval or qualified approval of such item. 20 1. Fabrication performed, materials purchased or on-site construction accomplished 21 which does not conform to approved shop drawings and data is at the Contractor's 22 risk. 23 2. The City will not be liable for any expense or delay due to corrections or remedies 24 required to accomplish conformity. 25 3. Complete project Work, materials, fabrication, and installations in conformance 26 with approved shop drawings, applicable samples, and product data. 27 J. Submittal Distribution 28 1. Electronic Distribution 29 a. Confirm development of Project directory for electronic submittals to be 30 uploaded to City’s Buzzsaw site, or another external FTP site approved by the 31 City. 32 b. Shop Drawings 33 1) Upload submittal to designated project directory and notify appropriate 34 City representatives via email of submittal posting. 35 2) Hard Copies 36 a) 3 copies for all submittals 37 b) If Contractor requires more than 1 hard copy of Shop Drawings 38 returned, Contractor shall submit more than the number of copies listed 39 above. 40 c. Product Data 41 1) Upload submittal to designated project directory and notify appropriate 42 City representatives via email of submittal posting. 43 2) Hard Copies 44 a) 3 copies for all submittals 45 d. Samples 46 1) Distributed to the Project Representative 47 2. Hard Copy Distribution (if required in lieu of electronic distribution) 01 33 00 - 5 SUBMITTALS Page 5 of 8 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised December 20, 2012 1 a. Shop Drawings 2 1) Distributed to the City 3 2) Copies 4 a) 8 copies for mechanical submittals 5 b) 7 copies for all other submittals 6 c) If Contractor requires more than 3 copies of Shop Drawings returned, 7 Contractor shall submit more than the number of copies listed above. 8 b. Product Data 9 1) Distributed to the City 10 2) Copies 11 a) 4 copies 12 c. Samples 13 1) Distributed to the Project Representative 14 2) Copies 15 a) Submit the number stated in the respective Specification Sections. 16 3. Distribute reproductions of approved shop drawings and copies of approved 17 product data and samples, where required, to the job site file and elsewhere as 18 directed by the City. 19 a. Provide number of copies as directed by the City but not exceeding the number 20 previously specified. 21 K. Submittal Review 22 1. The review of shop drawings, data and samples will be for general conformance 23 with the design concept and Contract Documents. This is not to be construed as: 24 a. Permitting any departure from the Contract requirements 25 b. Relieving the Contractor of responsibility for any errors, including details, 26 dimensions, and materials 27 c. Approving departures from details furnished by the City, except as otherwise 28 provided herein 29 2. The review and approval of shop drawings, samples or product data by the City 30 does not relieve the Contractor from his/her responsibility with regard to the 31 fulfillment of the terms of the Contract. 32 a. All risks of error and omission are assumed by the Contractor, and the City will 33 have no responsibility therefore. 34 3. The Contractor remains responsible for details and accuracy, for coordinating the 35 Work with all other associated work and trades, for selecting fabrication processes, 36 for techniques of assembly and for performing Work in a safe manner. 37 4. If the shop drawings, data or samples as submitted describe variations and show a 38 departure from the Contract requirements which City finds to be in the interest of 39 the City and to be so minor as not to involve a change in Contract Price or time for 40 performance, the City may return the reviewed drawings without noting an 41 exception. 42 5. Submittals will be returned to the Contractor under 1 of the following codes: 43 a. Code 1 44 1) "NO EXCEPTIONS TAKEN" is assigned when there are no notations or 45 comments on the submittal. 46 a) When returned under this code the Contractor may release the 47 equipment and/or material for manufacture. 48 b. Code 2 01 33 00 - 6 SUBMITTALS Page 6 of 8 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised December 20, 2012 1 1) "EXCEPTIONS NOTED". This code is assigned when a confirmation of 2 the notations and comments IS NOT required by the Contractor. 3 a) The Contractor may release the equipment or material for manufacture; 4 however, all notations and comments must be incorporated into the 5 final product. 6 c. Code 3 7 1) "EXCEPTIONS NOTED/RESUBMIT". This combination of codes is 8 assigned when notations and comments are extensive enough to require a 9 resubmittal of the package. 10 a) The Contractor may release the equipment or material for manufacture; 11 however, all notations and comments must be incorporated into the 12 final product. 13 b) This resubmittal is to address all comments, omissions and 14 non-conforming items that were noted. 15 c) Resubmittal is to be received by the City within 15 Calendar Days of 16 the date of the City's transmittal requiring the resubmittal. 17 d. Code 4 18 1) "NOT APPROVED" is assigned when the submittal does not meet the 19 intent of the Contract Documents. 20 a) The Contractor must resubmit the entire package revised to bring the 21 submittal into conformance. 22 b) It may be necessary to resubmit using a different manufacturer/vendor 23 to meet the Contract Documents. 24 6. Resubmittals 25 a. Handled in the same manner as first submittals 26 1) Corrections other than requested by the City 27 2) Marked with revision triangle or other similar method 28 a) At Contractor’s risk if not marked 29 b. Submittals for each item will be reviewed no more than twice at the City’s 30 expense. 31 1) All subsequent reviews will be performed at times convenient to the City 32 and at the Contractor's expense, based on the City's or City 33 Representative’s then prevailing rates. 34 2) Provide Contractor reimbursement to the City within 30 Calendar Days for 35 all such fees invoiced by the City. 36 c. The need for more than 1 resubmission or any other delay in obtaining City's 37 review of submittals, will not entitle the Contractor to an extension of Contract 38 Time. 39 7. Partial Submittals 40 a. City reserves the right to not review submittals deemed partial, at the City’s 41 discretion. 42 b. Submittals deemed by the City to be not complete will be returned to the 43 Contractor, and will be considered "Not Approved" until resubmitted. 44 c. The City may at its option provide a list or mark the submittal directing the 45 Contractor to the areas that are incomplete. 46 8. If the Contractor considers any correction indicated on the shop drawings to 47 constitute a change to the Contract Documents, then written notice must be 48 provided thereof to the City at least 7 Calendar Days prior to release for 49 manufacture. 01 33 00 - 7 SUBMITTALS Page 7 of 8 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised December 20, 2012 1 9. When the shop drawings have been completed to the satisfaction of the City, the 2 Contractor may carry out the construction in accordance therewith and no further 3 changes therein except upon written instructions from the City. 4 10. Each submittal, appropriately coded, will be returned within 30 Calendar Days 5 following receipt of submittal by the City. 6 L. Mock ups 7 1. Mock Up units as specified in individual Sections, include, but are not necessarily 8 limited to, complete units of the standard of acceptance for that type of Work to be 9 used on the Project. Remove at the completion of the Work or when directed. 10 M. Qualifications 11 1. If specifically required in other Sections of these Specifications, submit a P.E. 12 Certification for each item required. 13 N. Request for Information (RFI) 14 1. Contractor Request for additional information 15 a. Clarification or interpretation of the contract documents 16 b. When the Contractor believes there is a conflict between Contract Documents 17 c. When the Contractor believes there is a conflict between the Drawings and 18 Specifications 19 1) Identify the conflict and request clarification 20 2. Use the Request for Information (RFI) form provided by the City. 21 3. Numbering of RFI 22 a. Prefix with “RFI” followed by series number, “-xxx”, beginning with “01” and 23 increasing sequentially with each additional transmittal. 24 4. Sufficient information shall be attached to permit a written response without further 25 information. 26 5. The City will log each request and will review the request. 27 a. If review of the project information request indicates that a change to the 28 Contract Documents is required, the City will issue a Field Order or Change 29 Order, as appropriate. 30 1.5 SUBMITTALS [NOT USED] 31 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 32 1.7 CLOSEOUT SUBMITTALS [NOT USED] 33 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 34 1.9 QUALITY ASSURANCE [NOT USED] 35 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] 36 1.11 FIELD [SITE] CONDITIONS [NOT USED] 37 1.12 WARRANTY [NOT USED] 01 33 00 - 8 SUBMITTALS Page 8 of 8 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised December 20, 2012 1 PART 2 - PRODUCTS [NOT USED] 2 PART 3 - EXECUTION [NOT USED] 3 END OF SECTION 4 Revision Log DATE NAME SUMMARY OF CHANGE 12/20/2012 D. Johnson 1.4.K.8. Working Days modified to Calendar Days 5 01 35 13 - 1 SPECIAL PROJECT PROCEDURES Page 1 of 8 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised December 20, 2012 1 SECTION 01 35 13 2 SPECIAL PROJECT PROCEDURES 3 4 PART 1 - GENERAL 5 1.1 SUMMARY 6 A. Section Includes: 7 1. The procedures for special project circumstances that includes, but is not limited to: 8 a. Coordination with the Texas Department of Transportation 9 b. Work near High Voltage Lines 10 c. Confined Space Entry Program 11 d. Air Pollution Watch Days 12 e. Use of Explosives, Drop Weight, Etc. 13 f. Water Department Notification 14 g. Public Notification Prior to Beginning Construction 15 h. Coordination with United States Army Corps of Engineers 16 i. Coordination within Railroad permits areas 17 j. Dust Control 18 k. Employee Parking 19 20 B. Deviations from this City of Fort Worth Standard Specification 21 1. None. 22 C. Related Specification Sections include, but are not necessarily limited to: 23 1. Division 0 – Bidding Requirements, Contract Forms and Conditions of the Contract 24 2. Division 1 – General Requirements 25 3. Section 33 12 25 – Connection to Existing Water Mains 26 1.2 PRICE AND PAYMENT PROCEDURES 27 A. Measurement and Payment 28 1. Coordination within Railroad permit areas 29 a. Measurement 30 1) Measurement for this Item will be by lump sum. 31 b. Payment 32 1) The work performed and materials furnished in accordance with this Item 33 will be paid for at the lump sum price bid for Railroad Coordination. 34 c. The price bid shall include: 35 1) Mobilization 36 2) Inspection 37 3) Safety training 38 4) Additional Insurance 39 5) Insurance Certificates 01 35 13 - 2 SPECIAL PROJECT PROCEDURES Page 2 of 8 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised December 20, 2012 1 6) Other requirements associated with general coordination with Railroad, 2 including additional employees required to protect the right-of-way and 3 property of the Railroad from damage arising out of and/or from the 4 construction of the Project. 5 2. Railroad Flagmen 6 a. Measurement 7 1) Measurement for this Item will be per working day. 8 b. Payment 9 1) The work performed and materials furnished in accordance with this Item 10 will be paid for each working day that Railroad Flagmen are present at the 11 Site. 12 c. The price bid shall include: 13 1) Coordination for scheduling flagmen 14 2) Flagmen 15 3) Other requirements associated with Railroad 16 3. All other items 17 a. Work associated with these Items is considered subsidiary to the various Items 18 bid. No separate payment will be allowed for this Item. 19 1.3 REFERENCES 20 A. Reference Standards 21 1. Reference standards cited in this Specification refer to the current reference 22 standard published at the time of the latest revision date logged at the end of this 23 Specification, unless a date is specifically cited. 24 2. Health and Safety Code, Title 9. Safety, Subtitle A. Public Safety, Chapter 752. 25 High Voltage Overhead Lines. 26 3. North Central Texas Council of Governments (NCTCOG) – Clean Construction 27 Specification 28 1.4 ADMINISTRATIVE REQUIREMENTS 29 A. Coordination with the Texas Department of Transportation 30 1. When work in the right-of-way which is under the jurisdiction of the Texas 31 Department of Transportation (TxDOT): 32 a. Notify the Texas Department of Transportation prior to commencing any work 33 therein in accordance with the provisions of the permit 34 b. All work performed in the TxDOT right-of-way shall be performed in 35 compliance with and subject to approval from the Texas Department of 36 Transportation 37 B. Work near High Voltage Lines 38 1. Regulatory Requirements 39 a. All Work near High Voltage Lines (more than 600 volts measured between 40 conductors or between a conductor and the ground) shall be in accordance with 41 Health and Safety Code, Title 9, Subtitle A, Chapter 752. 42 2. Warning sign 43 a. Provide sign of sufficient size meeting all OSHA requirements. 44 3. Equipment operating within 10 feet of high voltage lines will require the following 45 safety features 01 35 13 - 3 SPECIAL PROJECT PROCEDURES Page 3 of 8 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised December 20, 2012 1 a. Insulating cage-type of guard about the boom or arm 2 b. Insulator links on the lift hook connections for back hoes or dippers 3 c. Equipment must meet the safety requirements as set forth by OSHA and the 4 safety requirements of the owner of the high voltage lines 5 4. Work within 6 feet of high voltage electric lines 6 a. Notification shall be given to: 7 1) The power company (example: ONCOR) 8 a) Maintain an accurate log of all such calls to power company and record 9 action taken in each case. 10 b. Coordination with power company 11 1) After notification coordinate with the power company to: 12 a) Erect temporary mechanical barriers, de-energize the lines, or raise or 13 lower the lines 14 c. No personnel may work within 6 feet of a high voltage line before the above 15 requirements have been met. 16 C. Confined Space Entry Program 17 1. Provide and follow approved Confined Space Entry Program in accordance with 18 OSHA requirements. 19 2. Confined Spaces include: 20 a. Manholes 21 b. All other confined spaces in accordance with OSHA’s Permit Required for 22 Confined Spaces 23 D. Air Pollution Watch Days 24 1. General 25 a. Observe the following guidelines relating to working on City construction sites 26 on days designated as “AIR POLLUTION WATCH DAYS”. 27 b. Typical Ozone Season 28 1) May 1 through October 31. 29 c. Critical Emission Time 30 1) 6:00 a.m. to 10:00 a.m. 31 2. Watch Days 32 a. The Texas Commission on Environmental Quality (TCEQ), in coordination 33 with the National Weather Service, will issue the Air Pollution Watch by 3:00 34 p.m. on the afternoon prior to the WATCH day. 35 b. Requirements 36 1) Begin work after 10:00 a.m. whenever construction phasing requires the 37 use of motorized equipment for periods in excess of 1 hour. 38 2) However, the Contractor may begin work prior to 10:00 a.m. if: 39 a) Use of motorized equipment is less than 1 hour, or 40 b) If equipment is new and certified by EPA as “Low Emitting“, or 41 equipment burns Ultra Low Sulfur Diesel (ULSD), diesel emulsions, or 42 alternative fuels such as CNG. 43 E. TCEQ Air Permit 44 1. Obtain TCEQ Air Permit for construction activities per requirements of TCEQ. 45 F. Use of Explosives, Drop Weight, Etc. 46 1. When Contract Documents permit on the project the following will apply: 01 35 13 - 4 SPECIAL PROJECT PROCEDURES Page 4 of 8 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised December 20, 2012 1 a. Public Notification 2 1) Submit notice to City and proof of adequate insurance coverage, 24 hours 3 prior to commencing. 4 2) Minimum 24 hour public notification in accordance with Section 01 31 13 5 G. Water Department Coordination 6 1. During the construction of this project, it will be necessary to deactivate, for a 7 period of time, existing lines. The Contractor shall be required to coordinate with 8 the Water Department to determine the best times for deactivating and activating 9 those lines. 10 2. Coordinate any event that will require connecting to or the operation of an existing 11 City water line system with the City’s representative. 12 a. Coordination shall be in accordance with Section 33 12 25. 13 b. If needed, obtain a hydrant water meter from the Water Department for use 14 during the life of named project. 15 c. In the event that a water valve on an existing live system be turned off and on 16 to accommodate the construction of the project is required, coordinate this 17 activity through the appropriate City representative. 18 1) Do not operate water line valves of existing water system. 19 a) Failure to comply will render the Contractor in violation of Texas Penal 20 Code Title 7, Chapter 28.03 (Criminal Mischief) and the Contractor 21 will be prosecuted to the full extent of the law. 22 b) In addition, the Contractor will assume all liabilities and 23 responsibilities as a result of these actions. 24 H. Public Notification Prior to Beginning Construction 25 1. Prior to beginning construction on any block in the project, on a block by block 26 basis, prepare and deliver a notice or flyer of the pending construction to the front 27 door of each residence or business that will be impacted by construction. The notice 28 shall be prepared as follows: 29 a. Post notice or flyer 7 days prior to beginning any construction activity on each 30 block in the project area. 31 1) Prepare flyer on the Contractor’s letterhead and include the following 32 information: 33 a) Name of Project 34 b) City Project No (CPN) 35 c) Scope of Project (i.e. type of construction activity) 36 d) Actual construction duration within the block 37 e) Name of the contractor’s foreman and phone number 38 f) Name of the City’s inspector and phone number 39 g) City’s after-hours phone number 40 2) A sample of the ‘pre-construction notification’ flyer is attached as Exhibit 41 A. 42 3) Submit schedule showing the construction start and finish time for each 43 block of the project to the inspector. 44 4) Deliver flyer to the City Inspector for review prior to distribution. 45 b. No construction will be allowed to begin on any block until the flyer is 46 delivered to all residents of the block. 47 I. Public Notification of Temporary Water Service Interruption during Construction 01 35 13 - 5 SPECIAL PROJECT PROCEDURES Page 5 of 8 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised December 20, 2012 1 1. In the event it becomes necessary to temporarily shut down water service to 2 residents or businesses during construction, prepare and deliver a notice or flyer of 3 the pending interruption to the front door of each affected resident. 4 2. Prepared notice as follows: 5 a. The notification or flyer shall be posted 24 hours prior to the temporary 6 interruption. 7 b. Prepare flyer on the contractor’s letterhead and include the following 8 information: 9 1) Name of the project 10 2) City Project Number 11 3) Date of the interruption of service 12 4) Period the interruption will take place 13 5) Name of the contractor’s foreman and phone number 14 6) Name of the City’s inspector and phone number 15 c. A sample of the temporary water service interruption notification is attached as 16 Exhibit B. 17 d. Deliver a copy of the temporary interruption notification to the City inspector 18 for review prior to being distributed. 19 e. No interruption of water service can occur until the flyer has been delivered to 20 all affected residents and businesses. 21 f. Electronic versions of the sample flyers can be obtained from the Project 22 Construction Inspector. 23 J. Coordination with United States Army Corps of Engineers (USACE) 24 1. At locations in the Project where construction activities occur in areas where 25 USACE permits are required, meet all requirements set forth in each designated 26 permit. 27 K. Coordination within Railroad Permit Areas 28 1. At locations in the project where construction activities occur in areas where 29 railroad permits are required, meet all requirements set forth in each designated 30 railroad permit. This includes, but is not limited to, provisions for: 31 a. Flagmen 32 b. Inspectors 33 c. Safety training 34 d. Additional insurance 35 e. Insurance certificates 36 f. Other employees required to protect the right-of-way and property of the 37 Railroad Company from damage arising out of and/or from the construction of 38 the project. Proper utility clearance procedures shall be used in accordance 39 with the permit guidelines. 40 2. Obtain any supplemental information needed to comply with the railroad’s 41 requirements. 42 3. Railroad Flagmen 43 a. Submit receipts to City for verification of working days that railroad flagmen 44 were present on Site. 45 L. Dust Control 46 1. Use acceptable measures to control dust at the Site. 47 a. If water is used to control dust, capture and properly dispose of waste water. 01 35 13 - 6 SPECIAL PROJECT PROCEDURES Page 6 of 8 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised December 20, 2012 1 b. If wet saw cutting is performed, capture and properly dispose of slurry. 2 M. Employee Parking 3 1. Provide parking for employees at locations approved by the City. 4 N. {Coordination with North Central Texas Council of Governments (NCTCOG) Clean 5 Construction Specification [if required for the project – verify with City] 6 1. Comply with equipment, operational, reporting and enforcement requirements set 7 forth in NCTCOG’s Clean Construction Specification.} 8 1.5 SUBMITTALS [NOT USED] 9 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 10 1.7 CLOSEOUT SUBMITTALS [NOT USED] 11 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 12 1.9 QUALITY ASSURANCE [NOT USED] 13 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] 14 1.11 FIELD [SITE] CONDITIONS [NOT USED] 15 1.12 WARRANTY [NOT USED] 16 PART 2 - PRODUCTS [NOT USED] 17 PART 3 - EXECUTION [NOT USED] 18 END OF SECTION 19 Revision Log DATE NAME SUMMARY OF CHANGE 8/31/2012 D. Johnson 1.4.B – Added requirement of compliance with Health and Safety Code, Title 9. Safety, Subtitle A. Public Safety, Chapter 752. High Voltage Overhead Lines. 1.4.E – Added Contractor responsibility for obtaining a TCEQ Air Permit 01 35 13 - 7 SPECIAL PROJECT PROCEDURES Page 7 of 8 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised December 20, 2012 1 EXHIBIT A 2 (To be printed on Contractor’s Letterhead) 3 4 5 6 Date: 7 8 CPN No.: 9 Project Name: 10 Mapsco Location: 11 Limits of Construction: 12 13 14 15 16 17 THIS IS TO INFORM YOU THAT UNDER A CONTRACT WITH THE CITY OF FORT 18 WORTH, OUR COMPANY WILL WORK ON UTILITY LINES ON OR AROUND YOUR 19 PROPERTY. 20 21 CONSTRUCTION WILL BEGIN APPROXIMATELY SEVEN DAYS FROM THE DATE 22 OF THIS NOTICE. 23 24 IF YOU HAVE QUESTIONS ABOUT ACCESS, SECURITY, SAFETY OR ANY OTHER 25 ISSUE, PLEASE CALL: 26 27 28 Mr. <CONTRACTOR’S SUPERINTENDENT> AT <TELEPHONE NO.> 29 30 OR 31 32 Mr. <CITY INSPECTOR> AT < TELEPHONE NO.> 33 34 AFTER 4:30 PM OR ON WEEKENDS, PLEASE CALL (817) 392 8306 35 36 PLEASE KEEP THIS FLYER HANDY WHEN YOU CALL 01 35 13 - 8 SPECIAL PROJECT PROCEDURES Page 8 of 8 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised December 20, 2012 1 EXHIBIT B 2 3 4 01 45 23 - 1 TESTING AND INSPECTION SERVICES Page 1 of 2 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised July 1, 2011 1 SECTION 01 45 23 2 TESTING AND INSPECTION SERVICES 3 PART 1 - GENERAL 4 1.1 SUMMARY 5 A. Section Includes: 6 1. Testing and inspection services procedures and coordination 7 B. Deviations from this City of Fort Worth Standard Specification 8 1. None. 9 C. Related Specification Sections include, but are not necessarily limited to: 10 1. Division 0 – Bidding Requirements, Contract Forms and Conditions of the Contract 11 2. Division 1 – General Requirements 12 1.2 PRICE AND PAYMENT PROCEDURES 13 A. Measurement and Payment 14 1. Work associated with this Item is considered subsidiary to the various Items bid. 15 No separate payment will be allowed for this Item. 16 a. Contractor is responsible for performing, coordinating, and payment of all 17 Quality Control testing. 18 b. City is responsible for performing and payment for first set of Quality 19 Assurance testing. 20 1) If the first Quality Assurance test performed by the City fails, the 21 Contractor is responsible for payment of subsequent Quality Assurance 22 testing until a passing test occurs. 23 a) Final acceptance will not be issued by City until all required payments 24 for testing by Contractor have been paid in full. 25 1.3 REFERENCES [NOT USED] 26 1.4 ADMINISTRATIVE REQUIREMENTS 27 A. Testing 28 1. Complete testing in accordance with the Contract Documents. 29 2. Coordination 30 a. When testing is required to be performed by the City, notify City, sufficiently 31 in advance, when testing is needed. 32 b. When testing is required to be completed by the Contractor, notify City, 33 sufficiently in advance, that testing will be performed. 34 3. Distribution of Testing Reports 35 a. Electronic Distribution 36 1) Confirm development of Project directory for electronic submittals to be 37 uploaded to City’s Buzzsaw site, or another external FTP site approved by 38 the City. 01 45 23 - 2 TESTING AND INSPECTION SERVICES Page 2 of 2 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised July 1, 2011 1 2) Upload test reports to designated project directory and notify appropriate 2 City representatives via email of submittal posting. 3 3) Hard Copies 4 a) 1 copy for all submittals submitted to the Project Representative 5 b. Hard Copy Distribution (if required in lieu of electronic distribution) 6 1) Tests performed by City 7 a) Distribute 1 hard copy to the Contractor 8 2) Tests performed by the Contractor 9 a) Distribute 3 hard copies to City’s Project Representative 10 4. Provide City’s Project Representative with trip tickets for each delivered load of 11 Concrete or Lime material including the following information: 12 a. Name of pit 13 b. Date of delivery 14 c. Material delivered 15 B. Inspection 16 1. Inspection or lack of inspection does not relieve the Contractor from obligation to 17 perform work in accordance with the Contract Documents. 18 1.5 SUBMITTALS [NOT USED] 19 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 20 1.7 CLOSEOUT SUBMITTALS [NOT USED] 21 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 22 1.9 QUALITY ASSURANCE [NOT USED] 23 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] 24 1.11 FIELD [SITE] CONDITIONS [NOT USED] 25 1.12 WARRANTY [NOT USED] 26 PART 2 - PRODUCTS [NOT USED] 27 PART 3 - EXECUTION [NOT USED] 28 END OF SECTION 29 Revision Log DATE NAME SUMMARY OF CHANGE 30 01 50 00 - 1 TEMPORARY FACILITIES AND CONTROLS Page 1 of 4 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised July 1, 2011 1 SECTION 01 50 00 2 TEMPORARY FACILITIES AND CONTROLS 3 PART 1 - GENERAL 4 1.1 SUMMARY 5 A. Section Includes: 6 1. Provide temporary facilities and controls needed for the Work including, but not 7 necessarily limited to: 8 a. Temporary utilities 9 b. Sanitary facilities 10 c. Storage Sheds and Buildings 11 d. Dust control 12 e. Temporary fencing of the construction site 13 B. Deviations from this City of Fort Worth Standard Specification 14 1. None. 15 C. Related Specification Sections include, but are not necessarily limited to: 16 1. Division 0 – Bidding Requirements, Contract Forms and Conditions of the Contract 17 2. Division 1 – General Requirements 18 1.2 PRICE AND PAYMENT PROCEDURES 19 A. Measurement and Payment 20 1. Work associated with this Item is considered subsidiary to the various Items bid. 21 No separate payment will be allowed for this Item. 22 1.3 REFERENCES [NOT USED] 23 1.4 ADMINISTRATIVE REQUIREMENTS 24 A. Temporary Utilities 25 1. Obtaining Temporary Service 26 a. Make arrangements with utility service companies for temporary services. 27 b. Abide by rules and regulations of utility service companies or authorities 28 having jurisdiction. 29 c. Be responsible for utility service costs until Work is approved for Final 30 Acceptance. 31 1) Included are fuel, power, light, heat and other utility services necessary for 32 execution, completion, testing and initial operation of Work. 33 2. Water 34 a. Contractor to provide water required for and in connection with Work to be 35 performed and for specified tests of piping, equipment, devices or other use as 36 required for the completion of the Work. 37 b. Provide and maintain adequate supply of potable water for domestic 38 consumption by Contractor personnel and City’s Project Representatives. 39 c. Coordination 40 1) Contact City 1 week before water for construction is desired 01 50 00 - 2 TEMPORARY FACILITIES AND CONTROLS Page 2 of 4 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised July 1, 2011 1 d. Contractor Payment for Construction Water 2 1) Obtain construction water meter from City for payment as billed by City’s 3 established rates. 4 3. Electricity and Lighting 5 a. Provide and pay for electric powered service as required for Work, including 6 testing of Work. 7 1) Provide power for lighting, operation of equipment, or other use. 8 b. Electric power service includes temporary power service or generator to 9 maintain operations during scheduled shutdown. 10 4. Telephone 11 a. Provide emergency telephone service at Site for use by Contractor personnel 12 and others performing work or furnishing services at Site. 13 5. Temporary Heat and Ventilation 14 a. Provide temporary heat as necessary for protection or completion of Work. 15 b. Provide temporary heat and ventilation to assure safe working conditions. 16 B. Sanitary Facilities 17 1. Provide and maintain sanitary facilities for persons on Site. 18 a. Comply with regulations of State and local departments of health. 19 2. Enforce use of sanitary facilities by construction personnel at job site. 20 a. Enclose and anchor sanitary facilities. 21 b. No discharge will be allowed from these facilities. 22 c. Collect and store sewage and waste so as not to cause nuisance or health 23 problem. 24 d. Haul sewage and waste off-site at no less than weekly intervals and properly 25 dispose in accordance with applicable regulation. 26 3. Locate facilities near Work Site and keep clean and maintained throughout Project. 27 4. Remove facilities at completion of Project 28 C. Storage Sheds and Buildings 29 1. Provide adequately ventilated, watertight, weatherproof storage facilities with floor 30 above ground level for materials and equipment susceptible to weather damage. 31 2. Storage of materials not susceptible to weather damage may be on blocks off 32 ground. 33 3. Store materials in a neat and orderly manner. 34 a. Place materials and equipment to permit easy access for identification, 35 inspection and inventory. 36 4. Equip building with lockable doors and lighting, and provide electrical service for 37 equipment space heaters and heating or ventilation as necessary to provide storage 38 environments acceptable to specified manufacturers. 39 5. Fill and grade site for temporary structures to provide drainage away from 40 temporary and existing buildings. 41 6. Remove building from site prior to Final Acceptance. 42 D. Temporary Fencing 43 1. Provide and maintain for the duration or construction when required in contract 44 documents 45 E. Dust Control 01 50 00 - 3 TEMPORARY FACILITIES AND CONTROLS Page 3 of 4 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised July 1, 2011 1 1. Contractor is responsible for maintaining dust control through the duration of the 2 project. 3 a. Contractor remains on-call at all times 4 b. Must respond in a timely manner 5 F. Temporary Protection of Construction 6 1. Contractor or subcontractors are responsible for protecting Work from damage due 7 to weather. 8 1.5 SUBMITTALS [NOT USED] 9 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 10 1.7 CLOSEOUT SUBMITTALS [NOT USED] 11 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 12 1.9 QUALITY ASSURANCE [NOT USED] 13 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] 14 1.11 FIELD [SITE] CONDITIONS [NOT USED] 15 1.12 WARRANTY [NOT USED] 16 PART 2 - PRODUCTS [NOT USED] 17 PART 3 - EXECUTION [NOT USED] 18 3.1 INSTALLERS [NOT USED] 19 3.2 EXAMINATION [NOT USED] 20 3.3 PREPARATION [NOT USED] 21 3.4 INSTALLATION 22 A. Temporary Facilities 23 1. Maintain all temporary facilities for duration of construction activities as needed. 24 3.5 [REPAIR] / [RESTORATION] 25 3.6 RE-INSTALLATION 26 3.7 FIELD [OR] SITE QUALITY CONTROL [NOT USED] 27 3.8 SYSTEM STARTUP [NOT USED] 28 3.9 ADJUSTING [NOT USED] 29 3.10 CLEANING [NOT USED] 30 3.11 CLOSEOUT ACTIVITIES 31 A. Temporary Facilities 01 50 00 - 4 TEMPORARY FACILITIES AND CONTROLS Page 4 of 4 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised July 1, 2011 1 1. Remove all temporary facilities and restore area after completion of the Work, to a 2 condition equal to or better than prior to start of Work. 3 3.12 PROTECTION [NOT USED] 4 3.13 MAINTENANCE [NOT USED] 5 3.14 ATTACHMENTS [NOT USED] 6 END OF SECTION 7 Revision Log DATE NAME SUMMARY OF CHANGE 8 01 55 26 - 1 STREET USE PERMIT AND MODIFICATIONS TO TRAFFIC CONTROL Page 1 of 3 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised July 1, 2011 1 SECTION 01 55 26 2 STREET USE PERMIT AND MODIFICATIONS TO TRAFFIC CONTROL 3 PART 1 - GENERAL 4 1.1 SUMMARY 5 A. Section Includes: 6 1. Administrative procedures for: 7 a. Street Use Permit 8 b. Modification of approved traffic control 9 c. Removal of Street Signs 10 B. Deviations from this City of Fort Worth Standard Specification 11 1. None. 12 C. Related Specification Sections include, but are not necessarily limited to: 13 1. Division 0 – Bidding Requirements, Contract Forms and Conditions of the Contract 14 2. Division 1 – General Requirements 15 3. Section 34 71 13 – Traffic Control 16 1.2 PRICE AND PAYMENT PROCEDURES 17 A. Measurement and Payment 18 1. Work associated with this Item is considered subsidiary to the various Items bid. 19 No separate payment will be allowed for this Item. 20 1.3 REFERENCES 21 A. Reference Standards 22 1. Reference standards cited in this specification refer to the current reference standard 23 published at the time of the latest revision date logged at the end of this 24 specification, unless a date is specifically cited. 25 2. Texas Manual on Uniform Traffic Control Devices (TMUTCD). 26 1.4 ADMINISTRATIVE REQUIREMENTS 27 A. Traffic Control 28 1. General 29 a. When traffic control plans are included in the Drawings, provide Traffic 30 Control in accordance with Drawings and Section 34 71 13. 31 b. When traffic control plans are not included in the Drawings, prepare traffic 32 control plans in accordance with Section 34 71 13 and submit to City for 33 review. 34 1) Allow minimum 10 working days for review of proposed Traffic Control. 35 B. Street Use Permit 36 1. Prior to installation of Traffic Control, a City Street Use Permit is required. 37 a. To obtain Street Use Permit, submit Traffic Control Plans to City 38 Transportation and Public Works Department. 01 55 26 - 2 STREET USE PERMIT AND MODIFICATIONS TO TRAFFIC CONTROL Page 2 of 3 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised July 1, 2011 1 1) Allow a minimum of 5 working days for permit review. 2 2) Contractor’s responsibility to coordinate review of Traffic Control plans for 3 Street Use Permit, such that construction is not delayed. 4 C. Modification to Approved Traffic Control 5 1. Prior to installation traffic control: 6 a. Submit revised traffic control plans to City Department Transportation and 7 Public Works Department. 8 1) Revise Traffic Control plans in accordance with Section 34 71 13. 9 2) Allow minimum 5 working days for review of revised Traffic Control. 10 3) It is the Contractor’s responsibility to coordinate review of Traffic Control 11 plans for Street Use Permit, such that construction is not delayed. 12 D. Removal of Street Sign 13 1. If it is determined that a street sign must be removed for construction, then contact 14 City Transportation and Public Works Department, Signs and Markings Division to 15 remove the sign. 16 E. Temporary Signage 17 1. In the case of regulatory signs, replace permanent sign with temporary sign meeting 18 requirements of the latest edition of the Texas Manual on Uniform Traffic Control 19 Devices (MUTCD). 20 2. Install temporary sign before the removal of permanent sign. 21 3. When construction is complete, to the extent that the permanent sign can be 22 reinstalled, contact the City Transportation and Public Works Department, Signs 23 and Markings Division, to reinstall the permanent sign. 24 F. Traffic Control Standards 25 1. Traffic Control Standards can be found on the City’s Buzzsaw website. 26 1.5 SUBMITTALS [NOT USED] 27 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 28 1.7 CLOSEOUT SUBMITTALS [NOT USED] 29 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 30 1.9 QUALITY ASSURANCE [NOT USED] 31 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] 32 1.11 FIELD [SITE] CONDITIONS [NOT USED] 33 1.12 WARRANTY [NOT USED] 34 PART 2 - PRODUCTS [NOT USED] 35 PART 3 - EXECUTION [NOT USED] 36 END OF SECTION 01 55 26 - 3 STREET USE PERMIT AND MODIFICATIONS TO TRAFFIC CONTROL Page 3 of 3 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised July 1, 2011 1 Revision Log DATE NAME SUMMARY OF CHANGE 2 01 57 13 - 1 STORM WATER POLLUTION PREVENTION Page 1 of 3 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO.102109 Revised July 1, 2011 1 SECTION 01 57 13 2 STORM WATER POLLUTION PREVENTION 3 PART 1 - GENERAL 4 1.1 SUMMARY 5 A. Section Includes: 6 1. Procedures for Storm Water Pollution Prevention Plans 7 B. Deviations from this City of Fort Worth Standard Specification 8 1. None. 9 C. Related Specification Sections include, but are not necessarily limited to: 10 1. Division 0 – Bidding Requirements, Contract Forms and Conditions of the 11 Contract 12 2. Division 1 – General Requirements 13 3. Section 31 25 00 – Erosion and Sediment Control 14 1.2 PRICE AND PAYMENT PROCEDURES 15 A. Measurement and Payment 16 1. Construction Activities resulting in less than 1 acre of disturbance 17 a. Work associated with this Item is considered subsidiary to the various Items 18 bid. No separate payment will be allowed for this Item. 19 2. Construction Activities resulting in greater than 1 acre of disturbance 20 a. Measurement and Payment shall be in accordance with Section 31 25 00. 21 1.3 REFERENCES 22 A. Abbreviations and Acronyms 23 1. Notice of Intent: NOI 24 2. Notice of Termination: NOT 25 3. Storm Water Pollution Prevention Plan: SWPPP 26 4. Texas Commission on Environmental Quality: TCEQ 27 5. Notice of Change: NOC 28 A. Reference Standards 29 1. Reference standards cited in this Specification refer to the current reference 30 standard published at the time of the latest revision date logged at the end of this 31 Specification, unless a date is specifically cited. 32 2. Integrated Storm Management (iSWM) Technical Manual for Construction 33 Controls 34 1.4 ADMINISTRATIVE REQUIREMENTS 35 A. General 36 1. Contractor is responsible for resolution and payment of any fines issued associated 37 with compliance to Stormwater Pollution Prevention Plan. 01 57 13 - 2 STORM WATER POLLUTION PREVENTION Page 2 of 3 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO.102109 Revised July 1, 2011 1 B. Construction Activities resulting in: 2 1. Less than 1 acre of disturbance 3 a. Provide erosion and sediment control in accordance with Section 31 25 00 and 4 Drawings. 5 2. 1 to less than 5 acres of disturbance 6 a. Texas Pollutant Discharge Elimination System (TPDES) General Construction 7 Permit is required 8 b. Complete SWPPP in accordance with TCEQ requirements 9 1) TCEQ Small Construction Site Notice Required under general permit 10 TXR150000 11 a) Sign and post at job site 12 b) Prior to Preconstruction Meeting, send 1 copy to City Department of 13 Transportation and Public Works, Environmental Division, (817) 392- 14 6088. 15 2) Provide erosion and sediment control in accordance with: 16 a) Section 31 25 00 17 b) The Drawings 18 c) TXR150000 General Permit 19 d) SWPPP 20 e) TCEQ requirements 21 3. 5 acres or more of Disturbance 22 a. Texas Pollutant Discharge Elimination System (TPDES) General Construction 23 Permit is required 24 b. Complete SWPPP in accordance with TCEQ requirements 25 1) Prepare a TCEQ NOI form and submit to TCEQ along with required fee 26 a) Sign and post at job site 27 b) Send copy to City Department of Transportation and Public Works, 28 Environmental Division, (817) 392-6088. 29 2) TCEQ Notice of Change required if making changes or updates to NOI 30 3) Provide erosion and sediment control in accordance with: 31 a) Section 31 25 00 32 b) The Drawings 33 c) TXR150000 General Permit 34 d) SWPPP 35 e) TCEQ requirements 36 4) Once the project has been completed and all the closeout requirements of 37 TCEQ have been met a TCEQ Notice of Termination can be submitted. 38 a) Send copy to City Department of Transportation and Public Works, 39 Environmental Division, (817) 392-6088. 40 1.5 SUBMITTALS 41 A. SWPPP 42 1. Submit in accordance with Section 01 33 00, except as stated herein. 43 a. Prior to the Preconstruction Meeting, submit a draft copy of SWPPP to the City 44 as follows: 45 1) 1 copy to the City Project Manager 46 a) City Project Manager will forward to the City Department of 47 Transportation and Public Works, Environmental Division for review 01 57 13 - 3 STORM WATER POLLUTION PREVENTION Page 3 of 3 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO.102109 Revised July 1, 2011 1 B. Modified SWPPP 2 1. If the SWPPP is revised during construction, resubmit modified SWPPP to the City 3 in accordance with Section 01 33 00. 4 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 5 1.7 CLOSEOUT SUBMITTALS [NOT USED] 6 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 7 1.9 QUALITY ASSURANCE [NOT USED] 8 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] 9 1.11 FIELD [SITE] CONDITIONS [NOT USED] 10 1.12 WARRANTY [NOT USED] 11 PART 2 - PRODUCTS [NOT USED] 12 PART 3 - EXECUTION [NOT USED] 13 END OF SECTION 14 Revision Log DATE NAME SUMMARY OF CHANGE 15 01 60 00 - 1 PRODUCT REQUIREMENTS Page 1 of 2 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised December 20, 2012 1 SECTION 01 60 00 2 PRODUCT REQUIREMENTS 3 PART 1 - GENERAL 4 1.1 SUMMARY 5 A. Section Includes: 6 1. References for Product Requirements and City Standard Products List 7 B. Deviations from this City of Fort Worth Standard Specification 8 1. None. 9 C. Related Specification Sections include, but are not necessarily limited to: 10 1. Division 0 – Bidding Requirements, Contract Forms and Conditions of the Contract 11 2. Division 1 – General Requirements 12 1.2 PRICE AND PAYMENT PROCEDURES [NOT USED] 13 1.3 REFERENCES [NOT USED] 14 1.4 ADMINISTRATIVE REQUIREMENTS 15 A. A list of City approved products for use is located on Buzzsaw as follows: 16 1. Resources\02 - Construction Documents\Standard Products List 17 B. Only products specifically included on City’s Standard Product List in these Contract 18 Documents shall be allowed for use on the Project. 19 1. Any subsequently approved products will only be allowed for use upon specific 20 approval by the City. 21 C. Any specific product requirements in the Contract Documents supersede similar 22 products included on the City’s Standard Product List. 23 1. The City reserves the right to not allow products to be used for certain projects even 24 though the product is listed on the City’s Standard Product List. 25 D. Although a specific product is included on City’s Standard Product List, not all 26 products from that manufacturer are approved for use, including but not limited to, that 27 manufacturer’s standard product. 28 E. See Section 01 33 00 for submittal requirements of Product Data included on City’s 29 Standard Product List. 30 1.5 SUBMITTALS [NOT USED] 31 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 32 1.7 CLOSEOUT SUBMITTALS [NOT USED] 33 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 34 1.9 QUALITY ASSURANCE [NOT USED] 01 60 00 - 2 PRODUCT REQUIREMENTS Page 2 of 2 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised December 20, 2012 1 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] 2 1.11 FIELD [SITE] CONDITIONS [NOT USED] 3 1.12 WARRANTY [NOT USED] 4 PART 2 - PRODUCTS [NOT USED] 5 PART 3 - EXECUTION [NOT USED] 6 END OF SECTION 7 Revision Log DATE NAME SUMMARY OF CHANGE 10/12/12 D. Johnson Modified Location of City’s Standard Product List 8 01 66 00 - 1 PRODUCT STORAGE AND HANDLING REQUIREMENTS Page 1 of 4 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised July 1, 2011 1 SECTION 01 66 00 2 PRODUCT STORAGE AND HANDLING REQUIREMENTS 3 PART 1 - GENERAL 4 1.1 SUMMARY 5 A. Section Includes: 6 1. Scheduling of product delivery 7 2. Packaging of products for delivery 8 3. Protection of products against damage from: 9 a. Handling 10 b. Exposure to elements or harsh environments 11 B. Deviations from this City of Fort Worth Standard Specification 12 1. None. 13 C. Related Specification Sections include, but are not necessarily limited to: 14 1. Division 0 – Bidding Requirements, Contract Forms and Conditions of the Contract 15 2. Division 1 – General Requirements 16 1.2 PRICE AND PAYMENT PROCEDURES 17 A. Measurement and Payment 18 1. Work associated with this Item is considered subsidiary to the various Items bid. 19 No separate payment will be allowed for this Item. 20 1.3 REFERENCES [NOT USED] 21 1.4 ADMINISTRATIVE REQUIREMENTS [NOT USED] 22 1.5 SUBMITTALS [NOT USED] 23 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 24 1.7 CLOSEOUT SUBMITTALS [NOT USED] 25 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 26 1.9 QUALITY ASSURANCE [NOT USED] 27 1.10 DELIVERY AND HANDLING 28 A. Delivery Requirements 29 1. Schedule delivery of products or equipment as required to allow timely installation 30 and to avoid prolonged storage. 31 2. Provide appropriate personnel and equipment to receive deliveries. 32 3. Delivery trucks will not be permitted to wait extended periods of time on the Site 33 for personnel or equipment to receive the delivery. 01 66 00 - 2 PRODUCT STORAGE AND HANDLING REQUIREMENTS Page 2 of 4 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised July 1, 2011 1 4. Deliver products or equipment in manufacturer's original unbroken cartons or other 2 containers designed and constructed to protect the contents from physical or 3 environmental damage. 4 5. Clearly and fully mark and identify as to manufacturer, item and installation 5 location. 6 6. Provide manufacturer's instructions for storage and handling. 7 B. Handling Requirements 8 1. Handle products or equipment in accordance with these Contract Documents and 9 manufacturer’s recommendations and instructions. 10 C. Storage Requirements 11 1. Store materials in accordance with manufacturer’s recommendations and 12 requirements of these Specifications. 13 2. Make necessary provisions for safe storage of materials and equipment. 14 a. Place loose soil materials and materials to be incorporated into Work to prevent 15 damage to any part of Work or existing facilities and to maintain free access at 16 all times to all parts of Work and to utility service company installations in 17 vicinity of Work. 18 3. Keep materials and equipment neatly and compactly stored in locations that will 19 cause minimum inconvenience to other contractors, public travel, adjoining owners, 20 tenants and occupants. 21 a. Arrange storage to provide easy access for inspection. 22 4. Restrict storage to areas available on construction site for storage of material and 23 equipment as shown on Drawings, or approved by City’s Project Representative. 24 5. Provide off-site storage and protection when on-site storage is not adequate. 25 a. Provide addresses of and access to off-site storage locations for inspection by 26 City’s Project Representative. 27 6. Do not use lawns, grass plots or other private property for storage purposes without 28 written permission of owner or other person in possession or control of premises. 29 7. Store in manufacturers’ unopened containers. 30 8. Neatly, safely and compactly stack materials delivered and stored along line of 31 Work to avoid inconvenience and damage to property owners and general public 32 and maintain at least 3 feet from fire hydrant. 33 9. Keep public and private driveways and street crossings open. 34 10. Repair or replace damaged lawns, sidewalks, streets or other improvements to 35 satisfaction of City’s Project Representative. 36 a. Total length which materials may be distributed along route of construction at 37 one time is 1,000 linear feet, unless otherwise approved in writing by City’s 38 Project Representative. 01 66 00 - 3 PRODUCT STORAGE AND HANDLING REQUIREMENTS Page 3 of 4 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised July 1, 2011 1 1.11 FIELD [SITE] CONDITIONS [NOT USED] 2 1.12 WARRANTY [NOT USED] 3 PART 2 - PRODUCTS [NOT USED] 4 PART 3 - EXECUTION 5 3.1 INSTALLERS [NOT USED] 6 3.2 EXAMINATION [NOT USED] 7 3.3 PREPARATION [NOT USED] 8 3.4 ERECTION [NOT USED] 9 3.5 REPAIR / RESTORATION [NOT USED] 10 3.6 RE-INSTALLATION [NOT USED] 11 3.7 FIELD [OR] SITE QUALITY CONTROL 12 A. Tests and Inspections 13 1. Inspect all products or equipment delivered to the site prior to unloading. 14 B. Non-Conforming Work 15 1. Reject all products or equipment that are damaged, used or in any other way 16 unsatisfactory for use on the project. 17 3.8 SYSTEM STARTUP [NOT USED] 18 3.9 ADJUSTING [NOT USED] 19 3.10 CLEANING [NOT USED] 20 3.11 CLOSEOUT ACTIVITIES [NOT USED] 21 3.12 PROTECTION 22 A. Protect all products or equipment in accordance with manufacturer's written directions. 23 B. Store products or equipment in location to avoid physical damage to items while in 24 storage. 25 C. Protect equipment from exposure to elements and keep thoroughly dry if required by 26 the manufacturer. 27 3.13 MAINTENANCE [NOT USED] 28 3.14 ATTACHMENTS [NOT USED] 29 END OF SECTION 30 01 66 00 - 4 PRODUCT STORAGE AND HANDLING REQUIREMENTS Page 4 of 4 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised July 1, 2011 Revision Log DATE NAME SUMMARY OF CHANGE 1 01 74 23 - 1 CLEANING Page 1 of 4 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised July 1, 2011 1 SECTION 01 74 23 2 CLEANING 3 PART 1 - GENERAL 4 1.1 SUMMARY 5 A. Section Includes: 6 1. Intermediate and final cleaning for Work not including special cleaning of closed 7 systems specified elsewhere 8 B. Deviations from this City of Fort Worth Standard Specification 9 1. None. 10 C. Related Specification Sections include, but are not necessarily limited to: 11 1. Division 0 – Bidding Requirements, Contract Forms and Conditions of the Contract 12 2. Division 1 – General Requirements 13 3. Section 32 92 13 – Hydro-Mulching, Seeding and Sodding 14 1.2 PRICE AND PAYMENT PROCEDURES 15 A. Measurement and Payment 16 1. Work associated with this Item is considered subsidiary to the various Items bid. 17 No separate payment will be allowed for this Item. 18 1.3 REFERENCES [NOT USED] 19 1.4 ADMINISTRATIVE REQUIREMENTS 20 A. Scheduling 21 1. Schedule cleaning operations so that dust and other contaminants disturbed by 22 cleaning process will not fall on newly painted surfaces. 23 2. Schedule final cleaning upon completion of Work and immediately prior to final 24 inspection. 25 1.5 SUBMITTALS [NOT USED] 26 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 27 1.7 CLOSEOUT SUBMITTALS [NOT USED] 28 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 29 1.9 QUALITY ASSURANCE [NOT USED] 30 1.10 STORAGE, AND HANDLING 31 A. Storage and Handling Requirements 32 1. Store cleaning products and cleaning wastes in containers specifically designed for 33 those materials. 01 74 23 - 2 CLEANING Page 2 of 4 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised July 1, 2011 1 1.11 FIELD [SITE] CONDITIONS [NOT USED] 2 1.12 WARRANTY [NOT USED] 3 PART 2 - PRODUCTS 4 2.1 OWNER-FURNISHED [OR] OWNER-SUPPLIEDPRODUCTS [NOT USED] 5 2.2 MATERIALS 6 A. Cleaning Agents 7 1. Compatible with surface being cleaned 8 2. New and uncontaminated 9 3. For manufactured surfaces 10 a. Material recommended by manufacturer 11 2.3 ACCESSORIES [NOT USED] 12 2.4 SOURCE QUALITY CONTROL [NOT USED] 13 PART 3 - EXECUTION 14 3.1 INSTALLERS [NOT USED] 15 3.2 EXAMINATION [NOT USED] 16 3.3 PREPARATION [NOT USED] 17 3.4 APPLICATION [NOT USED] 18 3.5 REPAIR / RESTORATION [NOT USED] 19 3.6 RE-INSTALLATION [NOT USED] 20 3.7 FIELD [OR] SITE QUALITY CONTROL [NOT USED] 21 3.8 SYSTEM STARTUP [NOT USED] 22 3.9 ADJUSTING [NOT USED] 23 3.10 CLEANING 24 A. General 25 1. Prevent accumulation of wastes that create hazardous conditions. 26 2. Conduct cleaning and disposal operations to comply with laws and safety orders of 27 governing authorities. 28 3. Do not dispose of volatile wastes such as mineral spirits, oil or paint thinner in 29 storm or sanitary drains or sewers. 30 4. Dispose of degradable debris at an approved solid waste disposal site. 31 5. Dispose of nondegradable debris at an approved solid waste disposal site or in an 32 alternate manner approved by City and regulatory agencies. 01 74 23 - 3 CLEANING Page 3 of 4 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised July 1, 2011 1 6. Handle materials in a controlled manner with as few handlings as possible. 2 7. Thoroughly clean, sweep, wash and polish all Work and equipment associated with 3 this project. 4 8. Remove all signs of temporary construction and activities incidental to construction 5 of required permanent Work. 6 9. If project is not cleaned to the satisfaction of the City, the City reserves the right to 7 have the cleaning completed at the expense of the Contractor. 8 10. Do not burn on-site. 9 B. Intermediate Cleaning during Construction 10 1. Keep Work areas clean so as not to hinder health, safety or convenience of 11 personnel in existing facility operations. 12 2. At maximum weekly intervals, dispose of waste materials, debris and rubbish. 13 3. Confine construction debris daily in strategically located container(s): 14 a. Cover to prevent blowing by wind 15 b. Store debris away from construction or operational activities 16 c. Haul from site at a minimum of once per week 17 4. Vacuum clean interior areas when ready to receive finish painting. 18 a. Continue vacuum cleaning on an as-needed basis, until Final Acceptance. 19 5. Prior to storm events, thoroughly clean site of all loose or unsecured items, which 20 may become airborne or transported by flowing water during the storm. 21 C. Interior Final Cleaning 22 1. Remove grease, mastic, adhesives, dust, dirt, stains, fingerprints, labels and other 23 foreign materials from sight-exposed surfaces. 24 2. Wipe all lighting fixture reflectors, lenses, lamps and trims clean. 25 3. Wash and shine glazing and mirrors. 26 4. Polish glossy surfaces to a clear shine. 27 5. Ventilating systems 28 a. Clean permanent filters and replace disposable filters if units were operated 29 during construction. 30 b. Clean ducts, blowers and coils if units were operated without filters during 31 construction. 32 6. Replace all burned out lamps. 33 7. Broom clean process area floors. 34 8. Mop office and control room floors. 35 D. Exterior (Site or Right of Way) Final Cleaning 36 1. Remove trash and debris containers from site. 37 a. Re-seed areas disturbed by location of trash and debris containers in accordance 38 with Section 32 92 13. 39 2. Sweep roadway to remove all rocks, pieces of asphalt, concrete or any other object 40 that may hinder or disrupt the flow of traffic along the roadway. 41 3. Clean any interior areas including, but not limited to, vaults, manholes, structures, 42 junction boxes and inlets. 01 74 23 - 4 CLEANING Page 4 of 4 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised July 1, 2011 1 4. If no longer required for maintenance of erosion facilities, and upon approval by 2 City, remove erosion control from site. 3 5. Clean signs, lights, signals, etc. 4 3.11 CLOSEOUT ACTIVITIES [NOT USED] 5 3.12 PROTECTION [NOT USED] 6 3.13 MAINTENANCE [NOT USED] 7 3.14 ATTACHMENTS [NOT USED] 8 END OF SECTION 9 Revision Log DATE NAME SUMMARY OF CHANGE 10 01 77 19 - 1 CLOSEOUT REQUIREMENTS Page 1 of 3 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised July 1, 2011 1 SECTION 01 77 19 2 CLOSEOUT REQUIREMENTS 3 PART 1 - GENERAL 4 1.1 SUMMARY 5 A. Section Includes: 6 1. The procedure for closing out a contract 7 B. Deviations from this City of Fort Worth Standard Specification 8 1. None. 9 C. Related Specification Sections include, but are not necessarily limited to: 10 1. Division 0 – Bidding Requirements, Contract Forms and Conditions of the Contract 11 2. Division 1 – General Requirements 12 1.2 PRICE AND PAYMENT PROCEDURES 13 A. Measurement and Payment 14 1. Work associated with this Item is considered subsidiary to the various Items bid. 15 No separate payment will be allowed for this Item. 16 1.3 REFERENCES [NOT USED] 17 1.4 ADMINISTRATIVE REQUIREMENTS 18 A. Guarantees, Bonds and Affidavits 19 1. No application for final payment will be accepted until all guarantees, bonds, 20 certificates, licenses and affidavits required for Work or equipment as specified are 21 satisfactorily filed with the City. 22 B. Release of Liens or Claims 23 1. No application for final payment will be accepted until satisfactory evidence of 24 release of liens has been submitted to the City. 25 1.5 SUBMITTALS 26 A. Submit all required documentation to City’s Project Representative. 01 77 19 - 2 CLOSEOUT REQUIREMENTS Page 2 of 3 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised July 1, 2011 1 1.6 INFORMATIONAL SUBMITTALS [NOT USED] 2 1.7 CLOSEOUT SUBMITTALS [NOT USED] 3 PART 2 - PRODUCTS [NOT USED] 4 PART 3 - EXECUTION 5 3.1 INSTALLERS [NOT USED] 6 3.2 EXAMINATION [NOT USED] 7 3.3 PREPARATION [NOT USED] 8 3.4 CLOSEOUT PROCEDURE 9 A. Prior to requesting Final Inspection, submit: 10 1. Project Record Documents in accordance with Section 01 78 39 11 2. Operation and Maintenance Data, if required, in accordance with Section 01 78 23 12 B. Prior to requesting Final Inspection, perform final cleaning in accordance with Section 13 01 74 23. 14 C. Final Inspection 15 1. After final cleaning, provide notice to the City Project Representative that the Work 16 is completed. 17 a. The City will make an initial Final Inspection with the Contractor present. 18 b. Upon completion of this inspection, the City will notify the Contractor, in 19 writing within 10 business days, of any particulars in which this inspection 20 reveals that the Work is defective or incomplete. 21 2. Upon receiving written notice from the City, immediately undertake the Work 22 required to remedy deficiencies and complete the Work to the satisfaction of the 23 City. 24 3. Upon completion of Work associated with the items listed in the City's written 25 notice, inform the City, that the required Work has been completed. Upon receipt 26 of this notice, the City, in the presence of the Contractor, will make a subsequent 27 Final Inspection of the project. 28 4. Provide all special accessories required to place each item of equipment in full 29 operation. These special accessory items include, but are not limited to: 30 a. Specified spare parts 31 b. Adequate oil and grease as required for the first lubrication of the equipment 32 c. Initial fill up of all chemical tanks and fuel tanks 33 d. Light bulbs 34 e. Fuses 35 f. Vault keys 36 g. Handwheels 37 h. Other expendable items as required for initial start-up and operation of all 38 equipment 39 D. Notice of Project Completion 01 77 19 - 3 CLOSEOUT REQUIREMENTS Page 3 of 3 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised July 1, 2011 1 1. Once the City Project Representative finds the Work subsequent to Final Inspection 2 to be satisfactory, the City will issue a Notice of Project Completion (Green Sheet). 3 E. Supporting Documentation 4 1. Coordinate with the City Project Representative to complete the following 5 additional forms: 6 a. Final Payment Request 7 b. Statement of Contract Time 8 c. Affidavit of Payment and Release of Liens 9 d. Consent of Surety to Final Payment 10 e. Pipe Report (if required) 11 f. Contractor’s Evaluation of City 12 g. Performance Evaluation of Contractor 13 F. Letter of Final Acceptance 14 1. Upon review and acceptance of Notice of Project Completion and Supporting 15 Documentation, in accordance with General Conditions, City will issue Letter of 16 Final Acceptance and release the Final Payment Request for payment. 17 3.5 REPAIR / RESTORATION [NOT USED] 18 3.6 RE-INSTALLATION [NOT USED] 19 3.7 FIELD [OR] SITE QUALITY CONTROL [NOT USED] 20 3.8 SYSTEM STARTUP [NOT USED] 21 3.9 ADJUSTING [NOT USED] 22 3.10 CLEANING [NOT USED] 23 3.11 CLOSEOUT ACTIVITIES [NOT USED] 24 3.12 PROTECTION [NOT USED] 25 3.13 MAINTENANCE [NOT USED] 26 3.14 ATTACHMENTS [NOT USED] 27 END OF SECTION 28 Revision Log DATE NAME SUMMARY OF CHANGE 29 01 78 23 - 1 OPERATION AND MAINTENANCE DATA Page 1 of 5 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised December 20, 2012 1 SECTION 01 78 23 2 OPERATION AND MAINTENANCE DATA 3 PART 1 - GENERAL 4 1.1 SUMMARY 5 A. Section Includes: 6 1. Product data and related information appropriate for City's maintenance and 7 operation of products furnished under Contract 8 2. Such products may include, but are not limited to: 9 a. Traffic Controllers 10 b. Irrigation Controllers (to be operated by the City) 11 c. Butterfly Valves 12 B. Deviations from this City of Fort Worth Standard Specification 13 1. None. 14 C. Related Specification Sections include, but are not necessarily limited to: 15 1. Division 0 – Bidding Requirements, Contract Forms and Conditions of the Contract 16 2. Division 1 – General Requirements 17 1.2 PRICE AND PAYMENT PROCEDURES 18 A. Measurement and Payment 19 1. Work associated with this Item is considered subsidiary to the various Items bid. 20 No separate payment will be allowed for this Item. 21 1.3 REFERENCES [NOT USED] 22 1.4 ADMINISTRATIVE REQUIREMENTS 23 A. Schedule 24 1. Submit manuals in final form to the City within 30 calendar days of product 25 shipment to the project site. 26 1.5 SUBMITTALS 27 A. Submittals shall be in accordance with Section 01 33 00 . All submittals shall be 28 approved by the City prior to delivery. 29 1.6 INFORMATIONAL SUBMITTALS 30 A. Submittal Form 31 1. Prepare data in form of an instructional manual for use by City personnel. 32 2. Format 33 a. Size: 8 ½ inches x 11 inches 34 b. Paper 35 1) 40 pound minimum, white, for typed pages 36 2) Holes reinforced with plastic, cloth or metal 37 c. Text: Manufacturer’s printed data, or neatly typewritten 01 78 23 - 2 OPERATION AND MAINTENANCE DATA Page 2 of 5 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised December 20, 2012 1 d. Drawings 2 1) Provide reinforced punched binder tab, bind in with text 3 2) Reduce larger drawings and fold to size of text pages. 4 e. Provide fly-leaf for each separate product, or each piece of operating 5 equipment. 6 1) Provide typed description of product, and major component parts of 7 equipment. 8 2) Provide indexed tabs. 9 f. Cover 10 1) Identify each volume with typed or printed title "OPERATING AND 11 MAINTENANCE INSTRUCTIONS". 12 2) List: 13 a) Title of Project 14 b) Identity of separate structure as applicable 15 c) Identity of general subject matter covered in the manual 16 3. Binders 17 a. Commercial quality 3-ring binders with durable and cleanable plastic covers 18 b. When multiple binders are used, correlate the data into related consistent 19 groupings. 20 4. If available, provide an electronic form of the O&M Manual. 21 B. Manual Content 22 1. Neatly typewritten table of contents for each volume, arranged in systematic order 23 a. Contractor, name of responsible principal, address and telephone number 24 b. A list of each product required to be included, indexed to content of the volume 25 c. List, with each product: 26 1) The name, address and telephone number of the subcontractor or installer 27 2) A list of each product required to be included, indexed to content of the 28 volume 29 3) Identify area of responsibility of each 30 4) Local source of supply for parts and replacement 31 d. Identify each product by product name and other identifying symbols as set 32 forth in Contract Documents. 33 2. Product Data 34 a. Include only those sheets which are pertinent to the specific product. 35 b. Annotate each sheet to: 36 1) Clearly identify specific product or part installed 37 2) Clearly identify data applicable to installation 38 3) Delete references to inapplicable information 39 3. Drawings 40 a. Supplement product data with drawings as necessary to clearly illustrate: 41 1) Relations of component parts of equipment and systems 42 2) Control and flow diagrams 43 b. Coordinate drawings with information in Project Record Documents to assure 44 correct illustration of completed installation. 45 c. Do not use Project Record Drawings as maintenance drawings. 46 4. Written text, as required to supplement product data for the particular installation: 47 a. Organize in consistent format under separate headings for different procedures. 48 b. Provide logical sequence of instructions of each procedure. 01 78 23 - 3 OPERATION AND MAINTENANCE DATA Page 3 of 5 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised December 20, 2012 1 5. Copy of each warranty, bond and service contract issued 2 a. Provide information sheet for City personnel giving: 3 1) Proper procedures in event of failure 4 2) Instances which might affect validity of warranties or bonds 5 C. Manual for Materials and Finishes 6 1. Submit 5 copies of complete manual in final form. 7 2. Content, for architectural products, applied materials and finishes: 8 a. Manufacturer's data, giving full information on products 9 1) Catalog number, size, composition 10 2) Color and texture designations 11 3) Information required for reordering special manufactured products 12 b. Instructions for care and maintenance 13 1) Manufacturer's recommendation for types of cleaning agents and methods 14 2) Cautions against cleaning agents and methods which are detrimental to 15 product 16 3) Recommended schedule for cleaning and maintenance 17 3. Content, for moisture protection and weather exposure products: 18 a. Manufacturer's data, giving full information on products 19 1) Applicable standards 20 2) Chemical composition 21 3) Details of installation 22 b. Instructions for inspection, maintenance and repair 23 D. Manual for Equipment and Systems 24 1. Submit 5 copies of complete manual in final form. 25 2. Content, for each unit of equipment and system, as appropriate: 26 a. Description of unit and component parts 27 1) Function, normal operating characteristics and limiting conditions 28 2) Performance curves, engineering data and tests 29 3) Complete nomenclature and commercial number of replaceable parts 30 b. Operating procedures 31 1) Start-up, break-in, routine and normal operating instructions 32 2) Regulation, control, stopping, shut-down and emergency instructions 33 3) Summer and winter operating instructions 34 4) Special operating instructions 35 c. Maintenance procedures 36 1) Routine operations 37 2) Guide to "trouble shooting" 38 3) Disassembly, repair and reassembly 39 4) Alignment, adjusting and checking 40 d. Servicing and lubrication schedule 41 1) List of lubricants required 42 e. Manufacturer's printed operating and maintenance instructions 43 f. Description of sequence of operation by control manufacturer 44 1) Predicted life of parts subject to wear 45 2) Items recommended to be stocked as spare parts 46 g. As installed control diagrams by controls manufacturer 47 h. Each contractor's coordination drawings 48 1) As installed color coded piping diagrams 01 78 23 - 4 OPERATION AND MAINTENANCE DATA Page 4 of 5 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised December 20, 2012 1 i. Charts of valve tag numbers, with location and function of each valve 2 j. List of original manufacturer's spare parts, manufacturer's current prices, and 3 recommended quantities to be maintained in storage 4 k. Other data as required under pertinent Sections of Specifications 5 3. Content, for each electric and electronic system, as appropriate: 6 a. Description of system and component parts 7 1) Function, normal operating characteristics, and limiting conditions 8 2) Performance curves, engineering data and tests 9 3) Complete nomenclature and commercial number of replaceable parts 10 b. Circuit directories of panelboards 11 1) Electrical service 12 2) Controls 13 3) Communications 14 c. As installed color coded wiring diagrams 15 d. Operating procedures 16 1) Routine and normal operating instructions 17 2) Sequences required 18 3) Special operating instructions 19 e. Maintenance procedures 20 1) Routine operations 21 2) Guide to "trouble shooting" 22 3) Disassembly, repair and reassembly 23 4) Adjustment and checking 24 f. Manufacturer's printed operating and maintenance instructions 25 g. List of original manufacturer's spare parts, manufacturer's current prices, and 26 recommended quantities to be maintained in storage 27 h. Other data as required under pertinent Sections of Specifications 28 4. Prepare and include additional data when the need for such data becomes apparent 29 during instruction of City's personnel. 30 1.7 CLOSEOUT SUBMITTALS [NOT USED] 31 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 32 1.9 QUALITY ASSURANCE 33 A. Provide operation and maintenance data by personnel with the following criteria: 34 1. Trained and experienced in maintenance and operation of described products 35 2. Skilled as technical writer to the extent required to communicate essential data 36 3. Skilled as draftsman competent to prepare required drawings 01 78 23 - 5 OPERATION AND MAINTENANCE DATA Page 5 of 5 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised December 20, 2012 1 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] 2 1.11 FIELD [SITE] CONDITIONS [NOT USED] 3 1.12 WARRANTY [NOT USED] 4 PART 2 - PRODUCTS [NOT USED] 5 PART 3 - EXECUTION [NOT USED] 6 END OF SECTION 7 Revision Log DATE NAME SUMMARY OF CHANGE 8/31/2012 D. Johnson 1.5.A.1 – title of section removed 8 01 78 39 - 1 PROJECT RECORD DOCUMENTS Page 1 of 4 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised July 1, 2011 1 SECTION 01 78 39 2 PROJECT RECORD DOCUMENTS 3 PART 1 - GENERAL 4 1.1 SUMMARY 5 A. Section Includes: 6 1. Work associated with the documenting the project and recording changes to project 7 documents, including: 8 a. Record Drawings 9 b. Water Meter Service Reports 10 c. Sanitary Sewer Service Reports 11 d. Large Water Meter Reports 12 B. Deviations from this City of Fort Worth Standard Specification 13 1. None. 14 C. Related Specification Sections include, but are not necessarily limited to: 15 1. Division 0 – Bidding Requirements, Contract Forms and Conditions of the Contract 16 2. Division 1 – General Requirements 17 1.2 PRICE AND PAYMENT PROCEDURES 18 A. Measurement and Payment 19 1. Work associated with this Item is considered subsidiary to the various Items bid. 20 No separate payment will be allowed for this Item. 21 1.3 REFERENCES [NOT USED] 22 1.4 ADMINISTRATIVE REQUIREMENTS [NOT USED] 23 1.5 SUBMITTALS 24 A. Prior to submitting a request for Final Inspection, deliver Project Record Documents to 25 City’s Project Representative. 26 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 27 1.7 CLOSEOUT SUBMITTALS [NOT USED] 28 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 29 1.9 QUALITY ASSURANCE 30 A. Accuracy of Records 31 1. Thoroughly coordinate changes within the Record Documents, making adequate 32 and proper entries on each page of Specifications and each sheet of Drawings and 33 other Documents where such entry is required to show the change properly. 34 2. Accuracy of records shall be such that future search for items shown in the Contract 35 Documents may rely reasonably on information obtained from the approved Project 36 Record Documents. 01 78 39 - 2 PROJECT RECORD DOCUMENTS Page 2 of 4 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised July 1, 2011 1 3. To facilitate accuracy of records, make entries within 24 hours after receipt of 2 information that the change has occurred. 3 4. Provide factual information regarding all aspects of the Work, both concealed and 4 visible, to enable future modification of the Work to proceed without lengthy and 5 expensive site measurement, investigation and examination. 6 1.10 STORAGE AND HANDLING 7 A. Storage and Handling Requirements 8 1. Maintain the job set of Record Documents completely protected from deterioration 9 and from loss and damage until completion of the Work and transfer of all recorded 10 data to the final Project Record Documents. 11 2. In the event of loss of recorded data, use means necessary to again secure the data 12 to the City's approval. 13 a. In such case, provide replacements to the standards originally required by the 14 Contract Documents. 15 1.11 FIELD [SITE] CONDITIONS [NOT USED] 16 1.12 WARRANTY [NOT USED] 17 PART 2 - PRODUCTS 18 2.1 OWNER-FURNISHED [OR] OWNER-SUPPLIED PRODUCTS [NOT USED] 19 2.2 RECORD DOCUMENTS 20 A. Job set 21 1. Promptly following receipt of the Notice to Proceed, secure from the City, at no 22 charge to the Contractor, 1 complete set of all Documents comprising the Contract. 23 B. Final Record Documents 24 1. At a time nearing the completion of the Work and prior to Final Inspection, provide 25 the City 1 complete set of all Final Record Drawings in the Contract. 26 2.3 ACCESSORIES [NOT USED] 27 2.4 SOURCE QUALITY CONTROL [NOT USED] 28 PART 3 - EXECUTION 29 3.1 INSTALLERS [NOT USED] 30 3.2 EXAMINATION [NOT USED] 31 3.3 PREPARATION [NOT USED] 32 3.4 MAINTENANCE DOCUMENTS 33 A. Maintenance of Job Set 34 1. Immediately upon receipt of the job set, identify each of the Documents with the 35 title, "RECORD DOCUMENTS - JOB SET". 01 78 39 - 3 PROJECT RECORD DOCUMENTS Page 3 of 4 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised July 1, 2011 1 2. Preservation 2 a. Considering the Contract completion time, the probable number of occasions 3 upon which the job set must be taken out for new entries and for examination, 4 and the conditions under which these activities will be performed, devise a 5 suitable method for protecting the job set. 6 b. Do not use the job set for any purpose except entry of new data and for review 7 by the City, until start of transfer of data to final Project Record Documents. 8 c. Maintain the job set at the site of work. 9 3. Coordination with Construction Survey 10 a. At a minimum, in accordance with the intervals set forth in Section 01 71 23, 11 clearly mark any deviations from Contract Documents associated with 12 installation of the infrastructure. 13 4. Making entries on Drawings 14 a. Record any deviations from Contract Documents. 15 b. Use an erasable colored pencil (not ink or indelible pencil), clearly describe the 16 change by graphic line and note as required. 17 c. Date all entries. 18 d. Call attention to the entry by a "cloud" drawn around the area or areas affected. 19 e. In the event of overlapping changes, use different colors for the overlapping 20 changes. 21 5. Conversion of schematic layouts 22 a. In some cases on the Drawings, arrangements of conduits, circuits, piping, 23 ducts, and similar items, are shown schematically and are not intended to 24 portray precise physical layout. 25 1) Final physical arrangement is determined by the Contractor, subject to the 26 City's approval. 27 2) However, design of future modifications of the facility may require 28 accurate information as to the final physical layout of items which are 29 shown only schematically on the Drawings. 30 b. Show on the job set of Record Drawings, by dimension accurate to within 1 31 inch, the centerline of each run of items. 32 1) Final physical arrangement is determined by the Contractor, subject to the 33 City's approval. 34 2) Show, by symbol or note, the vertical location of the Item ("under slab", "in 35 ceiling plenum", "exposed", and the like). 36 3) Make all identification sufficiently descriptive that it may be related 37 reliably to the Specifications. 38 c. The City may waive the requirements for conversion of schematic layouts 39 where, in the City's judgment, conversion serves no useful purpose. However, 40 do not rely upon waivers being issued except as specifically issued in writing 41 by the City. 42 B. Final Project Record Documents 43 1. Transfer of data to Drawings 44 a. Carefully transfer change data shown on the job set of Record Drawings to the 45 corresponding final documents, coordinating the changes as required. 46 b. Clearly indicate at each affected detail and other Drawing a full description of 47 changes made during construction, and the actual location of items. 01 78 39 - 4 PROJECT RECORD DOCUMENTS Page 4 of 4 CITY OF FORT WORTH TH Harris Hosp. FTW STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 102109 Revised July 1, 2011 1 c. Call attention to each entry by drawing a "cloud" around the area or areas 2 affected. 3 d. Make changes neatly, consistently and with the proper media to assure 4 longevity and clear reproduction. 5 2. Transfer of data to other Documents 6 a. If the Documents, other than Drawings, have been kept clean during progress of 7 the Work, and if entries thereon have been orderly to the approval of the City, 8 the job set of those Documents, other than Drawings, will be accepted as final 9 Record Documents. 10 b. If any such Document is not so approved by the City, secure a new copy of that 11 Document from the City at the City's usual charge for reproduction and 12 handling, and carefully transfer the change data to the new copy to the approval 13 of the City. 14 3.5 REPAIR / RESTORATION [NOT USED] 15 3.6 RE-INSTALLATION [NOT USED] 16 3.7 FIELD [OR] SITE QUALITY CONTROL [NOT USED] 17 3.8 SYSTEM STARTUP [NOT USED] 18 3.9 ADJUSTING [NOT USED] 19 3.10 CLEANING [NOT USED] 20 3.11 CLOSEOUT ACTIVITIES [NOT USED] 21 3.12 PROTECTION [NOT USED] 22 3.13 MAINTENANCE [NOT USED] 23 3.14 ATTACHMENTS [NOT USED] 24 END OF SECTION 25 Revision Log DATE NAME SUMMARY OF CHANGE 26