HomeMy WebLinkAboutContract 42903COMMUNITY FACILITIES AGREEMENT
THE STATE OF TEXAS § City Secretary
COUNTY OF TARRANT §
Contract No.
WHEREAS, the undersigned "Developer" desires to make certain improvements (refer
to the name of the project at the bottom of the page) an addition to the City of Fort Worth,
Texas; and
WHEREAS, the said Developer has requested the City of Fort Worth, a home -rule
municipal corporation situated in Tarrant, Denton, Parker, and Wise Counties, Texas, hereinafter
called "City ", to do certain work in connection with said improvements.
Developer Information:
Developer Company Name: Speedway Distribution Center B, LLC
Authorized Signatory: Linda D. Booker
Title: Manager
Project Name: Speedway Distribution Center Phase 2
Project Location: North of Three Wide Drive in Speedway Distribution Center, Phase 1
Additional Streets: N/A
Plat Case No.: FP- 010 -026 Plat Name: Speedway Distribution Center
Mapsco: 642M Council District: 0 - ETJ City Project No: 01642
CFA: 2010 -066 DOE: 6577/6760
To be completed y staff.
Received by: Date:
OFFICIAL FAECORI)
CITY SLC,RE ARY
rT WORTH, TX.
NOW, THEREFORE, KNOW ALL BY THESE PRESENTS:
For and in consideration of the covenants and conditions contained herein, the City and the
Developer do hereby agree as follows:
General Requirements
A. The Policy for the Installation of Community Facilities ( "Policy ") dated
March 2001, approved by the City Council of the City of Fort Worth and
subsequently amended from time to time via a Mayor and Council
Communication adopted by the City Council of the City of Fort Worth, is
hereby incorporated into this Community Facilities Agreement ( "CFA ") as
if copied herein verbatim. Developer agrees to comply with all provisions
of said Policy in the performance of its duties and obligations hereunder
and to cause all contractors hired by Developer to comply with the Policy
in connection with the work performed by said contractors.
B. Developer shall provide financial security in conformance with paragraph
6, Section II, of the Policy and recognizes that there shall be no reduction
in the collateral until the Project has been completed and the City has
officially accepted the infrastructure. Developer further acknowledges
that said process requires the contractor to submit an Affidavit of Bills
paid signed by its contractor and Consent of Surety signed by its surety
to ensure the contractor has paid the sub - contractor and suppliers in full.
Additionally, the contractor will provide in writing that the contractor
has been paid in full for all the services provided under this contract.
C. Developer agrees to cause the construction of the improvements
contemplated by this Agreement and that said construction shall be
completed in a good and workmanlike manner and in accordance with all
City standards and the City- approved construction plans, specifications and
cost estimates provided for the Project and the exhibits attached hereto.
D. The following checked exhibits are made a part hereof: Water (A) X ,
Sewer (A -1) X Paving (B) X , Storm Drain (B -1) _X_, Street
Lights & Signs (C) C .
E. The Developer shall award all contracts for the construction of community
facilities in accordance with Section 11, paragraph 7 of the Policy and the
contracts for the construction of the public infrastructure shall be
administered in conformance with paragraph 8, Section 11, of the Policy.
Combined CFA final Sept 12, 2008 2
F. For all infrastructure included in this Agreement for which the Developer
awards construction contract(s), Developer agrees to the following:
i. To employ a construction contractor who is approved by the director of
the department having jurisdiction over the infrastructure to be
constructed, said contractor to meet City's requirements for being
insured, licensed and bonded to do work in public streets and /or
prequalified to perform water /waste water construction as the case may
be.
ii. To require its contractor to furnish to the City a payment and
performance bond in the names of the City and the Developer for one
hundred percent (100 %) of the contract price of the infrastructure, and a
maintenance bond in the name of the City for one hundred percent
(100 %) of the contract price of the infrastructure for a period of two (2)
years insuring the maintenance and repair of the constructed
infrastructure during the term of the maintenance bond. All bonds to be
furnished before work is commenced and to meet the requirements of
Chapter 2253, Texas Government Code.
iii. To require the contractor(s) it hires to perform the construction work
contemplated herein to provide insurance equal to or in excess of the
amounts required by the City's standard specifications and contract
documents for developer- awarded infrastructure construction contracts.
The City shall be named as additional insured on all insurance required
by said documents and same will be evidenced on the ACORD
Certificate of Insurance supplied by the contractor's insurance provider
and bound in the construction contract book.
iv. To require its contractor to give 48 hours notice to the City's
Construction Services Division of intent to commence construction so
that City inspection personnel will be available; and to require the
contractor to allow the construction to be subject to inspection at any
and all times by City inspection forces, and not to install or relocate any
sanitary sewer, storm drain, or water pipe unless a responsible City
inspector is present and gives his consent to proceed, and to make such
laboratory tests of materials being used as may be required by the City.
v. To require its contractor to have fully executed contract documents
submitted to the City to schedule a Pre - Construction Meeting. The
3
submittal should occur no less than 10 working days prior to the desired
date of the meeting. No construction will commence without a City -
issued Notice to Proceed to the Developer's contractor.
vi. To delay connections of buildings to service lines of sewer and water
mains constructed under this Agreement until said sewer and water
mains and service lines have been completed to the satisfaction of the
Water Department.
G. Developer agrees to provide, at its expense, all engineering drawings and
documents necessary to construct the improvements required by this
Agreement.
H. Developer shall cause the installation or adjustment of the required utilities
to serve the development or to construct the improvements required herein.
I. City shall not be responsible for any costs that may be incurred by
Developer in the relocation of any utilities that are or may be in conflict
with any of the community facilities to be installed hereunder.
J. Developer hereby releases and agrees to indemnify, defend and hold the
City harmless for any inadequacies in the preliminary plans, specifications
and cost estimates supplied by the Developer for this Agreement.
K. Developer agrees to provide, at its expense, all necessary rights of way and
easements across property owned by Developer and required for the
construction of the current and future improvements provided for by this
Agreement.
L. The Developer further covenants and agrees to, and by these presents does
hereby, fully indemnify, hold harmless and defend the City, its officers,
agents and employees from all suits, actions or claims of any character,
whether real or asserted, brought for or on account of any injuries or
damages sustained by any persons (including death) or to any property,
resulting from or in connection with the construction, design, performance
or completion of any work to be performed by said Developer, his
contractors, subcontractors, officers, agents or employees, or in
consequence of any failure to properly safeguard the work, or on account
of any act, intentional or otherwise, neglect or misconduct of said
DEVELOPER, his contractors, sub - contractors, officers, agents or
employees, whether or not such injuries, death or damages are
caused, in whole or in part, by the alleged negligence of the City of
Combined CFA final Sept 12, 2008 4
Fort Worth, its officers, servants, or employees.
M. Developer will further require its contractors to indemnify, defend and
hold harmless the City, its officers, agents and employees from and against
any and all claims, suits or causes of action of any nature whatsoever,
whether real or asserted, brought for or on account of any injuries or
damages to persons or property, including death, resulting from, or in any
way connected with, the construction of the infrastructure contemplated
herein, whether or not such injuries, death or damaues are caused, in
whole or in part, by the allezed nezlikence of the City of Fort
Worth, its officers, servants, or employees Further, Developer will require
its contractors to indemnify, and hold harmless the City for any losses,
damages, costs or expenses suffered by the City or caused as a result of
said contractor's failure to complete the work and construct the
improvements in a good and workmanlike manner, free from defects, in
conformance with the Policy, and in accordance with all plans and
specifications and shall cause to be executed and delivered to the City an
indemnity agreement from such contractors on a form to be promulgated
by the City.
N. Upon completion of all work associated with the construction of the
infrastructure and improvements, Developer will assign to the City a non-
exclusive right to enforce the contracts entered into by the Developer with
its contractor along with an assignment of all warranties given by the
contractor, whether express or implied. Further, Developer agrees that all
contracts with any contractor shall include provisions granting to the City
the right to enforce such contracts as an express intended third party
beneficiary of such contracts.
O. Inspection and material testing fees are required as follows:
i. Developer shall pay in cash water and wastewater inspection fees and
material testing fees equal to two percent (2 %) for a total of 4% of the
developer's share of the total construction cost as stated in the construction
contract.
ii. Developer shall pay in cash paving and storm drain inspection fees equal
to four percent (4 %) and material testing fees equal to two percent (2 %)
for a total of 6% of the developer's share of the total construction cost as
stated in the construction contract.
iii. Developer shall pay in cash the total cost of streetlights or if the city is
not installing the streetlights, inspection fees equal to four percent (4 %) of
the developer's share of the streetlight construction cost as stated in the
construction contract.
iv. Developer shall pay in cash the total cost of street signs.
P. COMPLETION WITHIN 2 YEARS
i. The City's obligation to participate (exclusive of front foot charges) in
the cost of the community facilities shall terminate if the facilities are
not completed within two (2) years; provided, however, if construction
of the community facilities has started within the two year period, the
developer may request that the CFA be extended for one year. If the
community facilities are not completed within such extension period,
there will be no further obligation of the City to participate. City
participation in a CFA shall be subject to the availability of City funds
and approval by the Fort Worth City Council.
ii. Nothing contained herein is intended to limit the Developer's
obligations under the Policy, this Agreement, its financial guarantee,
its agreement with its contractor or other related agreements.
iii. The City may utilize the Developer's financial guarantee submitted for
this Agreement to cause the completion of the construction of the
community facilities if at the end of two (2) years from the date of this
Agreement the community facilities have not been completed and
accepted.
iv. The City may utilize the Developer's financial guarantee to cause the
completion of the construction of the community facilities or to cause
the payment of costs for construction of same before the expiration of
two (2) years if the Developer breaches this Agreement, becomes
insolvent or fails to pay costs of construction and the financial guarantee
is not a Completion Agreement. If the financial guarantee is a
Completion Agreement and the Developer's contractors and /or suppliers
are not paid for the costs of supplies and /or construction, the contractors
and /or suppliers may put a lien upon the property which is the subject of
the Completion Agreement.
Combined CFA final Sept 12. 2008 6
Cost Summary Sheet
Project Name: Speedway Distribution Center, Phase 2
CFA No.: 2010 -066 DOE No.: 6577
An Engineer's Estimate of Probable Cost is acceptable. However, the construction contract
price will ultimately determine the amount of CFA fees and financial guarantee. The bid price
and any additional CFA payments will be required prior to scheduling a pre - construction
meeting.
An itemized estimate corresponding to each project- specific exhibit is required to support the
following information.
Items
$ 950,989.95
Developer's Cost
A. Water and Sewer Construction
$ 950,989.95
1. Water Construction
$
273,947.60
2. Sewer Construction
$
134,269.00
Water and Sewer Construction Total
$
408,216.60
B. TPW Construction
1. Street
$
476,412.35
2. Storm Drain
$
26,034.00
3. Street Lights Installed by Developer
$
40,327.00
TPW Construction Cost Sub -Total
$
542,773.35
Total Construction Cost (excluding the fees):
$
950,989.95
Construction Fees:
C. Water /Sewer Inspection Fee (2 %)
$
8,164.33
D. Water /Sewer Material Testing Fee (2 %)
$
8,164.33
Sub -Total for Water Construction Fees
$
16, 328.66
E. TPW Inspection Fee (4 %)
$
20,097.85
F. TPW Material Testing (2 %)
$
10,048.93
G. Street Light Inspsection Cost
$
1,613.08
H. Street Signs Installation Cost
$
245.00
Sub -Total for TPW Construction Fees
$
32, 004.86
Total Construction Fees:
Finanrial ruaranfoo nnfinnc rhnnco nno
$ 48,333.53
Choice
dmnnnt trk nna)
Bond = 100%
$ 950,989.95
Completion Agreement = 100% / Holds Plat
$ 950,989.95
Cash Escrow Water/Sanitary Sewer= 125%
$ 510,270.75
Cash Escrow Paving/Storm Drain = 125%
$ 678,466.69
Letter of Credit = 125% w/2 r expiration period
$ 1,188.737 44
7
IN TESTIMONY WHEREOF, the City of Fort Worth has caused this instrument to be
executed in quadruplicate in its name and on its behalf by its Assistant City Manager, attested
by its City Secretary, with the corporate seal of the City affixed, and said Developer has
execute4 this instrument in quadruplicate, at Fort Worth, Texas this /L$ day
of , 20�IA.
CITY OF FORT WORTH - Recommended by:
Water Department
Wendy Chi- abulal, EMBA, P.E.
Development Engineering Manager
Approved ad to Form &Legality:
X —
Douglas W. Black
Assistant City Attorney
& Public Works Department
Wt
Douglas 14. Wiersig, P.E.
Director
Approved by City Manager's Office
Fernando Costa
Assistant City Manager
M &C No. ;V 4 IF
Date: oo�OnpWO o 000000 o ATTEST: ln o
°a a 1°
� c�{ j
� c o�p x
° ° o
oSe � City on- -.0
Attest:
Signature
(Print) Name: M. Thomas Mayfield
Title: Assistant Secretary
Combined CFA final Sept 12. 2008 8
Developer:
SPEEDWAY DISTRIBUTION CENTER B, LLC,
a Delaware limited liability company
(By: ID International (Texas), Inc.
Georgia Corporation, its sole general partner
Signature
(Print) Name: Linda D. Booker
Title: Manager
OFFICIAL REXORD
CITY SECRETARY
rT: NORTH, TX
Check items associated with the project being undertaken; checked items must be
included as Attachments to this Agreement
Included Attachment
®
Location Map
®
Exhibit A: Water Improvements
®
Water Estimate
®
Exhibit A -1: Sewer Improvements
®
Sewer Estimate
®
Exhibit B: Paving Improvements
®
Paving Estimate
®
Exhibit 13-1: Storm Drain Improvements
®
Storm Drain Estimate
®
Exhibit C: Street Lights and Signs Improvements
®
Street Lights and Signs Estimate
(Remainder of Page Intentionally Left Blank)
9
ENGINEER'S OPINION OF PROBABLE COST
Project Speedway Distribution Center, Phase 2 -
Three Wide Drive
Date: December 19, 2011
Location: Fort Worth, TX
Job No. 10276 EZI
Page: 2 of 6
ITEM UNIT TOTAL
No. DESCRIPTION UNIT QUANTITY PRICE COST
Three Wide Drive Water Facilities
1.
16" DR -18 Class 150 PVC
L.F.
1,942
$50.00
$97,100.00
2.
12" DR -14 Class 150 PVC
L.F.
107
$45.00
$4,815.00
3.
16" Gate Valve & Vault
Ea.
4
$7,500.00
$30,000.00
4.
12" Gate Valve & Valve Box
Ea.
3
$1,925.00
$5,775.00
5.
Abandon Existing 12" Water Line
L.S.
1
$100.00
$100.00
6.
6" Blow Off Valve
Ea.
1
$4,900.00
$4,900.00
7.
Connect to Ex. 16" W.L. Stub -out
Ea.
1
$2,400.00
$2,400.00
8.
Std. Fire Hydrant Assembly
Ea.
2
$4,000.00
$8,000.00
w/ 6" Gate Valve & Box
9.
12 "x6" Tapping Sleeve & Valve
Ea.
1
$3,000.00
$3,000.00
10.
6" Water Domestic Service Tap
Ea.
1
$200.00
$200.00
11.
6" Domestic Meter Box, Type B
Ea.
1
$8,500.00
$8,500.00
12.
6" DIP Service Line
L.S.
1
$2,599.80
$2,599.80
13.
2" Water Irrigation Service Tap
Ea.
1
$850.00
$850.00
14.
2" Irrigation Meter Box, Type B
Ea.
1
$200.00
$200.00
15.
2" Copper Pipe, Type K
L.S.
1
$300.00
$300.00
16.
C.I.R.T. Fittings
Ton
1.8
$3,800.00
$6,840.00
17.
Thrust Blocks
L.S.
1
$400.00
$400.00
18.
End & Plug 16" WL
Ea.
3
$50.00
$150.00
19.
End & Plug 12" WL
Ea.
3
$50.00
$150.00
20.
Trench Safety
L.F.
2,049
$0.30
$614.70
21.
Water System Testing
L.F.
2,049
$0.50
$1,024.50
Three Wide Drive Water Subtotal
$177,919.00
This Engineer's opinion of probable construction cost is made on the basis of the Engineer's
experience and best judgment as a design professional. It must be recognized that any evaluation
of work to be performed to construct this project must by necessity be speculative in nature until
completion of its actual detailed design In addition the engineer has no control over the cost of
labor, material. or services to be furnished by others or over market conditions Accordingly ((' % „• �� 1�
Goodwin & Marshall, Inc can not guarantee that actual costs will not vary from the opinions a If ' 1
expressed here in T/,J .. P J H A I -I,
caves E WICEAS - R.*wMEas - SUFNEY0116
ENGINEER'S OPINION OF PROBABLE COST
Project Speedway Distribution Center, Phase 2 -
Three Wide Drive
Date: December 19, 2011 ED
Location: Fort Worth, TX
Job No. 10276
Page: 3 of 6
ITEM UNIT TOTAL
No. DESCRIPTION UNIT QUANTITY PRICE COST
Short Track Court Water Facilities
1.
16" DR -18 Class 150 PVC
L.F.
820
$56.00
$45,920.00
2.
16" Ductile Iron Pipe
L.F.
95
$65.00
$6,175.00
3.
10" DR -14 Class 150 PVC
L.F.
55
$26.00
$1,430.00
4.
30" Steel Carrier Pipe
L.F.
95
$140.00
$13,300.00
5.
Remove & Dispose 16" Water Line
L.F.
915
$10.00
$9,150.00
6.
Connect to Ex. 16" W.L.
Ea.
2
$1,235.00
$2,470.00
7.
C.I.R.T. Fittings
Ton
0.3
$18,283.33
$5,485.00
8.
Relocate Ex. Fire Hyd.
Ea.
1
$2,000.00
$2,000.00
9.
Std. Fire Hydrant Assembly
Ea.
1
$2,955.00
$2,955.00
w/ 6" Gate Valve & Box
10.
1" Combination Air & Vacuum
Ea.
1
$3,850.00
$3,850.00
Release Valve w/Vault
11.
End & Plug 10" WL
Ea.
1
$500.00
$500.00
12.
Trench Safety
L.F.
970
$1.00
$970.00
13.
Water System Testing
L.F.
970
$1.88
$1,823.60
Short Tract Court Water Subtotal
Water Total
$96,028.60
$273,947.60
This Engineer's opinion of probable construction cost is made on the basis of the Engineer's
experience and best judgment as a design professional It must be recognized that any evaluation of
work to be performed to construct this project must by necessity be speculative in nature until
completion of its actual detailed design In addition the engineer has no control over the cost of labor, S J G i\'
material, or services to be furnished by others or over market conditions Accordingly Goodwin & !y''(AP. —S, HALI��
Marshall, Inc can not guarantee that actual costs will not vary from the opinions expressed here in pvk ENIMINEEM — PLMMEAS - eurwEYORS
ENGINEER'S OPINION OF PROBABLE COST
Project Speedway Distribution Center, Phase 2 -
Three Wide Drive
Date: December 19, 2011 Cl
Location: Fort Worth, TX
Job No. 10276
Page: 4 of 6
ITEM UNIT TOTAL
No. DESCRIPTION UNIT QUANTITY PRICE COST
Sanitary Sewer Facilities
1. 10" SDR -26 PVC L.F. 45 $100.00 $4,500.00
2. 8" SDR -26 PVC L.F. 1,889 $43.00 $81,227.00
3. 6" S.S. Service L.F. 17 $25.00 $425.00
4. 6" S.S. Service Tap Ea. 1 $625.00 $625.00
5. 6" 2 -Way Clean -out Ea. 1 $507.75 $507.75
6. Abandon Existing 8" Sanitary Sewer L.S. 1 $3,000.00 $3,000.00
7. 5' Dia. Std. S.S. Manhole Ea. 4 $4,000.00 $16,000.00
8. 5' Dia. Drop S.S. Manhole Ea. 1 $4,690.00 $4,690.00
9. 5' Dia. Drop S.S. Manhole Lining Ea. 1 $4,000.00 $4,000.00
10. Extra Depth for 5' Dia. MH V.F. 36 $280.00 $10,080.00
11. Connect to Existing S.S.M.H. Ea. 1 $5,000.00 $5,000.00
12. End & Plug 8" S.S. Ea. 4 $20.00 $80.00
13. End & Plug 6" S.S. Ea. 1 $20.00 $20.00
14. Concrete Collar Ea. 1 $200.00 $200.00
15. S.S.M.H. Vacuum Test Ea. 5 $100.00 $500.00
16. Trench Safety L.F. 1,951 $0.75 $1,463.25
17. T.V. Sanitary Sewer Line L.F. 1,951 $1.00 $1,951.00
Sanitary Sewer Total $134,269.00
This Engineer's opinion of probable construction cost is made on the basis of the Engineer's
experience and best judgment as a design professional It must be recognized that any evaluation of
work to be performed to construct this project must by necessity be speculative in nature until
completion of its actual detailed design In addition the engineer has no control over the cost of Tabor.
material, or services to be furnished by others or over market conditions Accordingly Goodwin &r %l,^aL,1.a�
Marshall, Inc can not guarantee that actual costs will not vary from the opinions expressed here in CNIL ErxOW41EERS - PLANNERS - SLOWEVORS
ENGINEER'S OPINION OF PROBABLE COST
Project Speedway Distribution Center, Phase 2 -
Three Wide Drive
Date: December 19, 2011
Location: Fort Worth, TX
Job No. 10276
Page: 1 of 6
ITEM UNIT TOTAL
No. DESCRIPTION UNIT QUANTITY PRICE COST
Three Wide Drive Paving Facilities
1.
8" Reinforced Concrete Pvmt
S.Y.
9,746
$33.50
$326,491.00
2.
8" Subgrade Preparation
S.Y.
10,050
$2.50
$25,125.00
3.
Hydrated Lime 41 # /SY
Ton
206.0
$139.00
$28,634.00
4.
18" Curb & Gutter
L.F.
114
$30.00
$3,420.00
5.
Construct Concrete Header
L.F.
102
$10.00
$1,020.00
6.
Connect to Concrete Header
L.F.
49
$10.00
$490.00
7.
Connect to Exist. Asphalt Pvmt
L.F.
136
$5.00
$680.00
8.
Remove Exist. Concrete Pvmt
S.Y.
86
$7.45
$640.70
9.
Remove Exist. Asphalt Pvmt
S.Y.
684
$7.45
$5,095.80
10.
Pavement Markings & Signage
L.S.
1
$7,500.00
$7,500.00
11.
Traffic Control
L.S.
1
$1,000.00
$1,000.00
12.
4' Sidewalk
L.F.
1,582
$12.00
$18,984.00
13.
Barrier Free Ramps
Ea.
2
$750.00
$1,500.00
14.
Connect to Existing Concrete
L.F.
82
$10.00
$820.00
Three Wide Paving Subtotal
$421,400.50
Short Track Court Turn Lane
1.
8" Reinforced Concrete Pvmt
S.Y.
1,095
$24.30
$26,608.50
2.
8" Subgrade Preparation
S.Y.
1,165
$0.90
$1,048.50
3.
Hydrated Lime 41 # /SY
Ton
23.9
$330.00
$7,881.23
4.
7" Vertical Curb
L.F.
111
$5.75
$638.25
5.
Remove Exist. Concrete Pvmt
S.Y.
111
$5.25
$582.75
6.
Sawcut & Remove Curb & Gutter
L.F.
626
$6.62
$4,144.12
7.
Sawcut 8" Pavement
L.F.
195
$3.60
$702.00
8.
Remove & Dispose 4' Sidewalk
L.F.
565
$5.50
$3,107.50
9.
Pavement Markings & Signage
L.S.
1
$300.00
$300.00
10.
Traffic Control
L.S.
1
$500.00
$500.00
11.
4' Sidewalk
L.F.
485
$13.40
$6,499.00
12.
Barrier Free Ramps
Ea.
3
$1,000.00
$3,000.00
Short Track Court Paving Subtotal $55,011.85
Paving Total $476,412.35
This Engineer's opinion of probable construction cost is made on the basis of the Engineers
experience and best judgment as a design professional It must be recognized that any evaluation
of work to be performed to construct this project must by necessity be speculative in nature until a
completion of its actual detailed design In addition the engineer has no control over the cost of� v X ����
labor, material, or services to be furnished by others or over market conditions Accordingly .��:.HAl.Li
Goodwin & Marshall. Inc can not guarantee that actual costs will not vary from the opinions CML ENGINEERS - PLANNERS - SURVEYORS
expressed here in
ENGINEER'S OPINION OF PROBABLE COST
Project Speedway Distribution Center, Phase 2 -
Three Wide Drive
Date: December 19, 2011 I
Location: Fort Worth, TX
Job No. 10276
Page: 5 of 6
ITEM UNIT TOTAL
No. DESCRIPTION UNIT QUANTITY PRICE COST
Three Wide Drive Storm Drain Facilities
1. 10' Curb Inlet
Ea.
3
$2,500.00
$7,500.00
2. 21" R.C.P.
L.F.
17
$56.00
$952.00
3. 24" R.C.P.
L.F.
107
$61.00
$6,527.00
4. 24" Sloped End Headwall
Ea.
1
$2,000.00
$2,000.00
5. Connect to Existing 24" R.C.P.
Ea.
1
$2,500.00
$2,500.00
6. Gabion Mattress (6" Dia.)
S.F.
54
$25.00
$1,350.00
7. Trench Safety
L.F.
124
$1.00
$124.00
Three Wide Drive Storm Drain Subtotal
$20,953.00
Short Track Court Storm Drain Facilities
1. 24" R.C.P.
L.F.
12
$55.00
$660.00
2. 10' Curb Inlet
Ea.
1
$2,750.00
$2,750.00
3. Remove 18" R.C.P.
L.F.
12
$12.00
$144.00
4. Remove 10' Curb Inlet
Ea.
1
$395.00
$395.00
5. Connect to Existing 24" R.C.P.
Ea.
1
$560.00
$560.00
6. Connect to 10' Curb Inlet
Ea.
1
$560.00
$560.00
7. Trench Safety
L.F.
12
$1.00
$12.00
Short Track Court Storm Drain Subtotal
Storm Drain Total
$5,081.00
$26,034.00
This Engineer's opinion of probable construction cost is made on the basis of the Engineer's
experience and best judgment as a design professional It must be recognized that any evaluation of
work to be performed to construct this project must by necessity be speculative in nature until rr
completion of its actual detailed design In addition the engineer has no control over the cost of labor.
material. or services to be furnished by others or over market conditions Accordingly Goodwin & y � q S,HALI
Marshall. Inc can not guarantee that actual costs will not vary from the opinions expressed here in CAVIL ENCIIINEERB - PLAMERB - 8UFNEVORS
ENGINEER'S OPINION OF PROBABLE COST
Project
Speedway Distribution Center, Phase 2 -
Three Wide Drive
Date:
December 19, 2011
Location:
Fort Worth, TX
1:3
Job No.
10276
Page:
6 of 6
ITEM
UNIT
TOTAL
No.
DESCRIPTION UNIT QUANTITY
PRICE
COST
Three Wide Drive Street Lights
1.
Street Light Bases with Pole Ea. 8
$4,250.00
$34,000.00
2.
Street Light 2" Conduit L.F. 1,406
$4.50
$6,327.00
Three Wide Drive Street Lights Subtotal $40,327.00
Three Wide Drive Street Signs
Street Name Signs Ea. 1 $345.00 $345.00
Street Signs Total $345.00
This Engineer's opinion of probable construction cost is made on the basis of the Engineer's
experience and best judgment as a design professional It must be recognized that any evaluation of
work to be performed to construct this project must by necessity be speculative in nature until
completion of its actual detailed design In addition the engineer has no control over the cost of labor. l Sd Ni
material. or services to be furnished by others or over market conditions Accordingly Goodwin & A' ,f ,-� aF S,�"1ALI—i
Marshall. Inc can not guarantee that actual costs will not vary from the opinions expressed here in CMIL ENG NEERB PLANNERS SURVEYORS
VICINITY MAP
NTS
ownII�)I
cC= OF FORT WORTH., '1CILiXAS
O BY:
PREPARED BY:
Atlanta • Chicago • Cincinnati (' OODVaNI
Im Dallas • Ft. Lauderdale *Memphis ���
Los Angeles • Philadelphia
Two Llwoh Gnk*.�Swutte 1275 CIVIL ENGINEERS — PLANNERS — SURVEYORS
5420 LBJ Ddw, TX 75240 205pMetro ((817) 329-Q73 «r 7e061
Fax- (9722 0770 AUGUST, 2011
E; \10276 \GE \Plans \Three Wide Drive CFA. pro Mon Aug 08 17;29; 18 2011
B N S F
ti
Catherl�e
�Z-t
LOCA u 1L 1L®
PETTY
n
S H 114 �P�
TEXAS MOTOR
SPEEDWA Y
ti
E1'Zaoet
�
C�
eek
I35W
Nm
WE FORT
ff
S
CITY LIMIT
VICINITY MAP
NTS
ownII�)I
cC= OF FORT WORTH., '1CILiXAS
O BY:
PREPARED BY:
Atlanta • Chicago • Cincinnati (' OODVaNI
Im Dallas • Ft. Lauderdale *Memphis ���
Los Angeles • Philadelphia
Two Llwoh Gnk*.�Swutte 1275 CIVIL ENGINEERS — PLANNERS — SURVEYORS
5420 LBJ Ddw, TX 75240 205pMetro ((817) 329-Q73 «r 7e061
Fax- (9722 0770 AUGUST, 2011
E; \10276 \GE \Plans \Three Wide Drive CFA. pro Mon Aug 08 17;29; 18 2011
_N
S � � c
n • L
d • i: WWW
it a� fQN' U O N F
3
In
8
--
�Q�o
ug � -M A&
'rorQkro
AL1134 V1343 SAX
go *sd i"o "0'
ua wa jo
A \ A --
L
+�$ a ON
�• r3g
w Q J Q
3 _J >
a LF"-
0 0
we J� W
- V
g
0 r Li w
ZD
j
MO
Co (a
c E
(D
8
rnre
m 7N a.
0
m
;ID
0
w
S
El
Z W-
. . ..... ..... .
-i NOIS V
3i El ENIO-li�e 38pin3
C14
. . .......... ... . ..
i Z-Z U>j
CD
X Gi ui
FF7 -
jj
con
0 P: F-
�i So 0 Sa
WX x
Ld
U.I..
---- - ---------- --------- --- FU
— - - - - - ------------------
O ")Oo)ovdi Jack's
ui
0
o y
BErti
cma1Y $r
ir
W < HW Q U m W t7�
J •
z o
m a ��r
Q
z � •O�m
W
I
CL I Ow F
18 z
Ln u-I
io
C4
N � .1'7Ukfa
LL1 AH81 IIIAl31 AkH31
® W ZU 1 '1'7Q1f0
aw AW31 'KO
Li
6 C6 014
(!) J N
o F i
Q m Lim \1 N
I� ;o N m
N
I � r
eo U) _
i gg
i
.8 q
7NuY O v ky1 R
co
4 -2 1 _ >
W —
Y _
f
N
'L
rL
o C E L T Q
0 a 91 2S n
m o 8
i h N
CO y �. Sc U m o m
N mh
>+
o
tm
4W TZD
cr
m
9
El
N
1'7VHO
AU
MU
AI
'41 ' UM
lUK 91 IQA�1 6l
W
5d W
ow AUBi 'wo
�° 'i$ °• �IE�
N �s��
llga V
d
pad --
0
2
p a L
J C m CL 8h
J O
8
co
L — O O
s
(o °" m NOW
U � �
Cc
rya
LCL 'Bd 'OS '11
i AUBI WA-M AlfHl
W
Sd
um
au 'ad aro •M
Aow AWN wo
orM wei 'Ka
I I
Hwy(;
>n
/ o�
N
t- CL t
A a
c E t n O
U� m S2 S
o c •fir �r
~ ~ �(D
oa. V C
WE o CL CL 8 at on �ca�
3 N N N 44N
�
� •raawu
.w� "114
I wu� .wet
W
q fm I"
tuai tuai WM •w�
o wo
+v
_ u
= o
cl
Cq d o
of
tA
A2
L
CL ca
E L
cmE $n
C.) � -5 g
c • -0
_ I
° U 0 'R N
ov a O1
cm
• � L r
av
C •
W� E w o � •nr � � � PLO �p fly `�'
S Q in .m
Q 18
co -
RE
i
1' 1'
A»s� 'A'�ovo A-M W
M •t�
iaAai Auer
w
•roravo
S4 "a w 'ed WA •ion
AWNiH VIM-MM
_OM AWW3H 'WO
r
l'
i
0
N
v
v
Q
m
0
0)
a
C
0
0
L
a
Q
LL
U
N
.N
L
0
m
2
.N
3
L
L
N
C
ro
a
/
w
C)
/
lD
n
N
O
ti
Iii