HomeMy WebLinkAboutContract 39095 COMMUNITY FACILITIES AGREEMENT
THE STATE OF TEXAS § City Secretary (� G
COUNTY OF TARRANT § Contract No. l 1
WHEREAS,the undersigned"Developer"desires to make certain improvements(refer
to the name of the project at the bottom of the page)an addition to the City of Fort Worth,
Texas;and 1
WHEREAS,the said Developer has requested the City of Fort Worth,a home-rule I
municipal corporation situated in Tarrant,Denton,Parker,and Wise Counties,Texas,hereinafter
called"City",to do certain work in connection with said improvements.
Developer Information:
Developer Company Name: CVS Pharmacy,Inc.,a Rhode Island Corporation
Authorized Signatory: Michael B.Nulman j
Title: Assistant Secretary Senior Legal Counsel
Project Name: CVS Pharmacy-Longhorn Crossing Addition
Project Location: Southeast Corner of Longhorn&Marine Creek
Additional Streets:
Plat Case No. FP 009-017 Plat Name: Longhorn Crossing Addition
Mapsco: 47B Council District: 7 City Project No:01390&01377
To be completed b taff, l
Received by: Date: �[',�` 2� vQ
CFA: DOE:6262&5290
OFFiGIAL RECORD'
1 CITY SECRETARY
FT WORTH., TX
L
NOW,THEREFORE,KNOW ALL BY THESE PRESENTS:
For and in consideration of the covenants and conditions contained herein,the City and the
Developer do hereby agree as follows:
General Requirements
A. The Policy for the Installation of Community Facilities ("Policy") dated
March 2001, approved by the City Council of the City of Fort Worth and
subsequently amended from time to time via a Mayor and Council
Communication adopted by the City Council of the City of Fort Worth, is
hereby incorporated into this Community Facilities Agreement("CFA") as
if copied herein verbatim. Developer agrees to comply with all provisions
of said Policy in the performance of its duties and obligations hereunder
and to cause all contractors hired by Developer to comply with the Policy
in connection with the work performed by said contractors.
B. Developer shall provide financial security in conformance with paragraph
6, Section II, of the Policy and recognizes that there shall be no reduction
in the collateral until the Project has been completed and the City has
officially accepted the infrastructure. Developer further acknowledges
that said process requires the contractor to submit an Affidavit of Bills
paid signed by its contractor and Consent of Surety signed by its surety
to ensure the contractor has paid the sub-contractor and suppliers in full.
Additionally, the contractor will provide in writing that the contractor
has been paid in full for all the services provided under this contract.
C. Developer agrees to cause the construction of the improvements
contemplated by this Agreement and that said construction shall be
completed in a good and workmanlike manner and in accordance with all
City standards and the City-approved construction plans, specifications and
cost estimates provided for the Project and the exhibits attached hereto.
D. The following checked exhibits are made a part hereof: Water (A) X
Sewer (A-1) _A_,, Paving (B) Storm Drain (B-1) , Street
Lights&Signs(C)—
E. The Developer shall award all contracts for the construction of community
facilities in accordance with Section II, paragraph 7 of the Policy and the
contracts for the construction of the public infrastructure shall be
administered in conformance with paragraph 8, Section II,of the Policy.
Combined CFA final Sept 12,2008 2
F. For all infrastructure included in this Agreement for which the Developer
awards construction contract(s), Developer agrees to the following:
i. To employ a construction contractor who is approved by the director of
the department having jurisdiction over the infrastructure to be
constructed, said contractor to meet City's requirements for being
insured, licensed and bonded to do work in public streets and/or
prequalified to perform water/waste water construction as the case may
be.
ii. To require its contractor to furnish to the City a payment and
performance bond in the names of the City and the Developer for one
hundred percent (100%) of the contract price of the infrastructure, and a
maintenance bond in the name of the City for one hundred percent
(100%) of the contract price of the infrastructure for a period of two (2)
years insuring the maintenance and repair of the constructed
infrastructure during the term of the maintenance bond. All bonds to be
furnished before work is commenced and to meet the requirements of
Chapter 2253,Texas Government Code.
iii. To require the contractor(s) it hires to perform the construction work
contemplated herein to provide insurance equal to or in excess of the
amounts required by the City's standard specifications and contract
documents for developer-awarded infrastructure construction contracts.
The City shall be named as additional insured on all insurance required
by said documents and same will be evidenced on the ACORD
Certificate of Insurance supplied by the contractor's insurance provider
and bound in the construction contract book.
iv. To require its contractor to give 48 hours notice to the City's
Construction Services Division of intent to commence construction so
that City inspection personnel will be available; and to require the
contractor to allow the construction to be subject to inspection at any
and all times by City inspection forces, and not to install or relocate any
sanitary sewer, storm drain, or water pipe unless a responsible City
inspector is present and gives his consent to proceed, and to make such
laboratory tests of materials being used as may be required by the City,
v. To require its contractor to have fully executed contract documents
submitted to the City to schedule a Pre-Construction Meeting, The
3
submittal should occur no less than 10 working days prior to the desired
date of the meeting. No construction will commence without a City-
issued Notice to Proceed to the Developer's contractor.
vi. To delay connections of buildings to service lines of sewer and water
mains constructed under this Agreement until said sewer and water
mains and service lines have been completed to the satisfaction of the
Water Department,
G. Developer agrees to provide, at its expense, all engineering drawings and
documents necessary to construct the improvements required by this
Agreement.
H. Developer shall cause the installation or adjustment of the required utilities
to serve the development or to construct the improvements required herein.
I. City shall not be responsible for any costs that may be incurred by
Developer in the relocation of any utilities that are or may be in conflict
with any of the community facilities to be installed hereunder.
J. Developer hereby releases and agrees to indemnify, defend and hold the
City harmless for any inadequacies in the preliminary plans, specifications
and cost estimates supplied by the Developer for this Agreement.
K. Developer agrees to provide, at its expense, all necessary rights of way and
easements across property owned by Developer and required for the
construction of the current and future improvements provided for by this
Agreement.
L. The Developer further covenants and agrees to, and by these presents does
hereby, fully indemnify, hold harmless and defend the City, its officers,
agents and employees from all suits, actions or claims of any character,
whether real or asserted, brought for or on account of any injuries or
damages sustained by any persons (including death) or to any property,
resulting from or in coimection with the construction, design, performance
or completion of any work to be performed by said Developer, his
contractors, subcontractors, officers, agents or employees, or in
consequence of any failure to properly safeguard the work, or on account
of any act, intentional or otherwise, neglect or misconduct of said
DEVELOPER, his contractors, sub-contractors, officers, agents or
employees, whether or not such inIm les, death or damages are
caused, in whole or in part, by the alleged negligence of the City of
Combined CFA final Sept 12,2008 4
Fort Wodlo, its o frcers,servants, or employees. I
M. Developer will further require its contractors to indemnify, defend and
hold harmless the City, its officers,agents and employees from and against
any and all claims, suits or causes of action of any nature whatsoever,
whether real or asserted, brought for or on account of any injuries or
damages to persons or property, including death, resulting from, or in any
way connected with, the construction of the infrastructure contemplated
herein, whether or not such injuries, death or damages are caused, In
whole or in mart, by the alleeed neelikence of the City of Fort
Worth, its officers,servants, or employees. Further,Developer will require
its contractors to indemnify, and hold harmless the City for any losses,
damages, costs or expenses suffered by the City or caused as a result of
said contractor's failure to complete the work and construct the
improvements in a good and workmanlike manner, free from defects, in
conformance with the Policy, and in accordance with all plans and
specifications and shall cause to be executed and delivered to the City an
indemnity agreement from such contractors on a form to be promulgated
by the City.
N. Upon completion of all work associated with the construction of the
infrastructure and improvements, Developer will assign to the City a non-
exclusive right to enforce the contracts entered into by the Developer with
its contractor along with an assignment of all warranties given by the
contractor, whether express or implied. Further, Developer agrees that all
contracts with any contractor shall include provisions granting to the City
the right to enforce such contracts as an express intended thud party
beneficiary of such contracts.
O. Inspection and material testing fees are required as follows:
i. Developer shall pay in cash water and wastewater inspection fees and
material testing fees equal to two percent (2%) for a total of 4% of the
developer's share of the total construction cost as stated in the construction
contract.
ii. Developer shall pay in cash paving and storm drain inspection fees equal
to four percent (4%) and material testing fees equal to two percent (2%)
for a total of 6% of the developer's share of the total construction cost as
stated in the construction contract.
5
iii. Developer shall pay in cash the total cost of streetlights or if the city is
not installing the streetlights, inspection fees equal to four percent(4%) of
the developer's share of the streetlight construction cost as stated in the
construction contract.
iv. Developer shall pay in cash the total cost of street signs.
P. COMPLETION WITHIN 2 YEARS
i, The City's obligation to participate (exclusive of front foot charges) in
the cost of the community facilities shall terminate if the facilities are
not completed within two (2) years; provided, however, if construction
of the community facilities has started within the two year period, the
developer may request that the CFA be extended for one year. If the
community facilities are not completed within such extension period,
there will be no further obligation of the City to participate. City
participation in a CFA shall be subject to the availability of City funds
and approval by the Fort Worth City Council.
ii. Nothing contained herein is intended to limit the Developer's
obligations under the Policy,this Agreement, its financial guarantee,
its agreement with its contractor or other related agreements.
iii. The City may utilize the Developer's financial guarantee submitted for
this Agreement to cause the completion of the construction of the
community facilities if at the end of two (2) years from the date of this
Agreement the community facilities have not been completed and
accepted.
iv. The City may utilize the Developer's financial guarantee to cause the
completion of the construction of the community facilities or to cause
the payment of costs for construction of same before the expiration of
two (2) years if the Developer breaches this Agreement, becomes
insolvent or fails to pay costs of construction and the financial guarantee
is not a Completion Agreement. If the financial guarantee is a
Completion Agreement and the Developer's contractors and/or suppliers
are not paid for the costs of supplies and/or construction,the contractors
and/or suppliers may put a lien upon the property which is the subject of
the Completion Agreement.
Combined CFA final Sept 12,2008 6
Cost Summary Sheet
Project Name: CVS Pharmacy-Longhorn Crossing Addition
CFA No.: DOE No.:
An Engineer's Estimate of Probable Cost is acceptable. However, the construction contract
price will ultimately determine the amount of CFA fees and financial guarantee. The bid price
and any additional CFA payments will be required prior to scheduling a pre-construction
meeting.
An itemized estimate corresponding to each project-specific exhibit is required to support the
following information.
Items Developer's Cost
A. Water and Sewer Construction
1. Water Construction $ 26,250.00
2.Sewer Construction $ 130.367,00
a. Water and Sewer Construction Total $ 155,607.00
B. TPW Construction
1.Street $ -
2.Storm Drain $ 64050.00
TPW Construction Cost Sub-Total $ e,0%oo
Total Construction Cost(excluding the fees): $ 181,867.00
Construction Fees:
C. Water/Sewer Inspection Fee(2%) $ 3,112.14
D. Water/Sewer Material Testing Fee(2%) $ 3,112.14
Sub-Total for WaterlSewer Construction Fees $ e,224.28
E. TPW Inspection Fee(4%) $ 242.00
F. TPW Material Testing(2%) $ 121.00
G. Street Light Installation/inspsec8on Cost
H. Street Signs Installation Cost
Sub-Total for TPW Construction Fees $ 363.00
Total Construction Fees: $ 8,687.26
Choice
Financial Guarantee Options,choose one Amount ck one
Bond=100% $ 161 657.00
Completion Agreement=100%/Holds Plat $ 161,657.00
Cash Escrow Water/Sanity Sewer-125% $ 194 508,75
Cash Escrow Paving/Storm Drain r-125% $ 7,562.60
Letter of Credit=125%w/2yr expiration period $ 202 071.25 1 --=-
7
IN TESTIMONY WHEREOF,the City of Fort Worth has caused this instrument to be
executed in quadruplicate in its name and on its behalf by its Assistant City Manager,attested
by its City Secretary,with the corporate seal of the City affixed,and said Developer has
executed this instrument in quadruplicate,at Fort Worth,Texas this = day
of 200 I _.
CITY OF FORT WORTH-Recommended by:
Water Department Transportation & Public Works Department
� 0lzzai
Wendy C - abulal,EMBA,P.E. William A Ve•lcest,P.E
Develop m Engineering Manager DIrector
Approved as to Form&Le lity.• Approved by City Manager's Ofj?ce
Ck11
Amy J.kj1nisey Fernando Costa
AssistantiCity Attorney Assistant City Manager
i
1
ATTES
u f,n
arty Hendrix NO M&C REQUIRED
�ity Secretary
ATTEST CVS Pharmacy,Inc.
SignaNgianie K. Luker Signature
(Print)Name: Assistant Secretary Print Name:Michael B.Nulman
Title:Assistant Secretary
Combined CFA final Sept 12,2008 8
Check items associated with the project being undertaken; checked items must be
included as Attachments to this Agreement
Included Attachment
® Location Map
® Exhibit A:Water Improvements
® Water Estimate
® Exhibit A-1: Sewer Improvements
® Sewer Estimate
❑ Exhibit B:Paving Improvements
❑ Paving Estimate
® Exhibit 13-1: Storm Drain Improvements
® Storm Drain Estimate
❑ Exhibit C: Street Lights and Signs Improvements
❑ Street Lights and Signs Estimate
(Remainder of Page Intentionally Left Blank)
9
O�
C�
y S I T E
�? LOCATION
LOCAU ON Map
MAPSCO 47B
NOT TO SCALE
wgffiIk3Rmmm mlm
& A0000A 3tse, Hm e.
CANSUUING CIVIL ENGINEERS ■ SURVEYORS
( 972 ) 490•-7090 FAX (972 ) 490-7099
A.F. ALBRIGHT SURVEY, ABST. NO. 1849 LOCATION MAP SHEET
Scale : N.T.S. CITY OF FORT WORTH ®NGH® N CR®SSENG '
Pate :08/04/09 TARRANT COUNTY, TEXAS
r onnata: ARMSTRONG DEVELOPMENT L®4® BLOCK �
Dwg. Fite : 4389�CFAEXH.OWG OF
222 W. LAS COLfNAS BLVD., SUITE 3610
FEEL No. : 43895.01(10) IRVING, TEXAS 75039 FORT TORTH, TARRANT COUNTY, TEXAS
,
P w —
- — — — — — — — — — — — — — — — — — — — — — —
.� t Ex. 16" RCCP Wtr F-628
=733.5 SIGN
WTR
2A� I n
L ONGHO RN RD.
�y •PcA TELE OR
VA LT Ex. 24" Wtr F-187————————————— —— —————————--
TTI
—— — ————————--
�
�
- � R I
0o N
CONNECT TO EX. x
•�T I
rn 16" WATER N
Z CMpharmacy 0' 30' 60'
12,900 SF
' 1.877 AC.81,775 S.F. Scale: 1"=60'
I. F.F.E.= 663.00
SERVICE
CONNECTIONS 2
II ASPHALT f 0 T:
PROPOSED CLASS
'A' & 'B' METER
BOXES I
6" FIRE LINE — — — —
I I\
CONNECTION \ \
I \
PROPOSED FIRE \ \
HYDRANT
6" FIRE HYDRANT
ICONNECTON INSTALL 12"
GATE VALVE \ \
11 rn INSTALL \
112- PLUG I \
1 PERMANENT 35' SEWER FACILITY EASEMENT
t (BY SEPARATE INSTRUMENT) ( \
1 1 �
"� � Aoo®c$a�moo II>mc.
A.F. ALBRIGHT SURVEY, ABST. NO. 1849 EXHIBIT 'A' SHEET
CITY OF FORT WORTH WATER IMPROVEMENTS
TARRANT COUNTY, TEXAS LONGHORN CROSSING
ARMSTRONG DEVELOPMENT ADDITION OF
222 W. LAS COLINAS BLVD.. SUITE 1610 LOT 1. ®LOCI( I
IRVING, TEXAS 75039 FORT WORTH, TARRANT COUNTY, TEXAS 7
WWinkeimann
&Associates, Inc.
CONSUITOO CNl ENGSIEEM■SUNVETORS
Longhorn Crossing Addition
Community Facilities Agreement
Water Estimate
August 4,2009
Item Description Quantity U/M Unit Total
A. Connect to Existing 16"Water 1 Ea. $3,500.00 $3,500.00
B. 12" PVC Water Line 236 L.F. $24.00 $5,664.00
C. 12"Gate Valve 2 Ea. $1,200.00 $2,400.00
D. 6"PVC Water Line 20 L.F. $20.00 $400.00
E. 6"Gate Valve 2 Ea. $800.00 $1,600.00
F. Fire Hydrant 1 Ea. $3,200.00 $3,200.00
G. Fittings 0.5 Tons $3,500.00 $1,750.00
H. 2"Domestic Service connection 1 Ea. $1,000.00 $1,000.00
I. Class"B"Meter Box 1 Ea. $500.00 $500.00
J. 1"Irrigation Service Connection 1 Ea. $1,000.00 $1,000.00
K. Class"A"Meter Box 1 Ea. $500.00 $500.00
L. Traffic Control 1 L.S. $2,000.00 $2,000.00
M. Trench Safety 236 L.F. $1.00 $236.00
N. Testing 1 L.S. $1,500.00 $1,500.00
Total Water $25,250.00
* Since there is no control over the cost of labor,materials,and equipment or over
contractor's method of determining prices,or over competitor's bidding or market
conditions,this estimate of probable cost is made on the basis of our professional
experience and represents our best judgment as a firm familiar with the construction
industry. We cannot and do not guarantee proposals,bids on the project costs will not
vary from the above estimate.
Prepared by: � f
Michael T. r' ett, P.E.
Winkelmann&Associates, Inc.
6750 Hillcrest Plaza Dr.,Ste.325
Dallas,TX 75230
(972)490-7090
(972)490-7099 fax
mdoggett@winkelmann.com
1S
6750 Hilicrest Plaza Drive,Suite W Dallas,Texas 75230 (972)490-7090 Fax(972)490-7099
N
0' 100' 200'
MARINE CREEK OF TEXAS
IR JOINT VENTURE Scale: 1"--2 0 0'
PARCEL N.4
VOL 11431.PG 293)
I I LONGHORN RD.
' ; --- _— __-- _
a Utt Itf1 ICI ————————
C,
PROP. 4' DIA. WASTEWATER
I " MANHOLES (3) w/1-8"
STUBOUT & PLUG AND
m
MARINE CREEK OF TEXAS 1-10" STUBOUT & PLUG
JOINT VENTURE
(VOL 11431,PG 29J) I a.,....,..,.n I
OANMONT13986,LAND FOUR,LP. I
I — — (VOL P0.0 )
! \ \(VOL 14306.PG 0080080)
\I \ 11G6G.ACRES I
I \ \ YAWN-CPLIIf OF lf]IA]
PARQL—
Ha
('0.11 ut,PC 7AT)
PROP. 4' DIA. WASTEWATER
Ism MANHOLE w/2-8" STUBOUTS
& PLUGS
I A I I 938 L.F. PROP.
I 10" WASTEWATER
m PIPE
MATCH LINE
�nffi1�c�Il��ffiffi
"'
CONSULTING CIVIL ENGINEERS INSURVEYORS
( 972 ) 490-7090 FAX ( 972 ) 490-7099
A.F. ALBRIGHT SURVEY, ABST. NO. 1849 EXHIBIT A-l' SHEET
CITY OF FORT WORTH SEWER IMPROVEMENTS y
TARRANT COUNTY, TEXAS LONGHORN CROSSING
).,g. i ilo 4�8RK FA:XH.D'IJG DEVELOPER: ARMSTRONG DEVELOPMENT ADDITION OF
222 W. LAS COLINAS BLVD., SUITE 1610 LOT 1, BLOCK I
"ojec- 'I. : = S5_•.0' iJl IRVING, TEXAS 75039 FORT WORTH, TARRANT COUNTY, TEXAS 2
MATCH LINE
II
PROP. 4' DIA. WASTEWATER
MANHOLES (2) w/2-8"
STUBOUTS & CLEANOUTS.
vm _
86 L.F. 8" BORE _ '�
UNDER EXISTING \ w`r°.' 1001 L.F. PROP.
GAS MAIN ` 8" WASTEWATER I 1
�\ PIPE 1
PROP. 4' DIA.
WASTEWATER \ F4hjyE 1 '' II
MANHOLES (2) \ — ftOQRA C40pO%�L _
20 L.F. 8 WASTEWATER \
PIPE WITH CEMENT \
STABILIZED BACKFILL
G
\ 9
4" SEWER SERVICES
WITH PLUGS TO
FUTURE LOTS (30) \ \\
PROP. 4' DIA.
WASTEWATER +
MANHOLE \ \
20 L.F. 8" WASTEWATER \
PIPE WITH CEMENT \ \ �
STABILIZED BACKFILL ` \
\ an m
0' 100' 200' \ \
Scale: 1"-200' CONNECT TO EXISTING \ -
SEWER. \
�Ilffi��Il��1ffiffi
cis A®®®can tso, Ema.
CONSULTING CIVIL ENGINEERS ■ SURVE"ORS
972 ) 490-7090 FAX ( 972 ) 690-7099
A.F. ALBRIGHT SURVEY, ABST. NO. 1849 EXHIBIT A-1' SHEET
1'•->I; CITY OF FORT WORTH SEWER IMPROVEMENTS 2
^y 3/ ;/C TARRANT COUNTY, TEXAS LONGb0RN CROSSING
nP9:L,t,�. il:-; 4'BD�:,^.FAEXN.D')JG AS DEVELOPMENT ADDITION OF
LA COLIN
222 W. LAS COLINAS BLVD., SUITE 1610 d0`I� 1, BLOCK I
',ojec: IRVING, TEXAS 75039 FORT WORTH, TARRANT COUNTY, TEXAS 2
Winkelmann
&Associates, Inc.
CONSULTING CNII ENGMSRf■SURWYOU
CVS Pharmacy-Longhorn Crossing Addition
Community Facilities Agreement
Sanitary Sewer Estimate
August 4,2009
Revised August 20,2009
Item Description Quantity U/M Unit Total
A. Trench Safety 1979 L.F. $1.00 $2,979.00
B. Standard 4'Manhole 9 Ea. $2,500.00 $22,500.00
C. 4"Sewer Service with Plug 18 Ea. $475.00 $8,550.00
D. 4"Sewer Service with Cement Stabilized backfiil with Plug 12 Ea. $625.00 $7,500.00
E. Double Sanitary Sewer Cleanout 2 Ea. $675.00 $1,350.00
F. 10"SDR 26 PVC Pipe 938 L.F. $28.00 $26,264.00
G. 8"SDR 26 PVC Pipe 1001 L.F. $24.00 $24,024.00
H. 16"Ductile Iron Casing Pipe for Bore under Gas 86 L.F. $150.00 $12,900.00
1. 8"Ductile Iron Carrier Pipe for Bore under Gas 86 L.F. $50.00 $4,300.00
J. 8"SDR 26 PVC Pipe with Cement Stabilized backfill 40 L.F. $35.00 $2,400.00
K. Connect to Existing Main 1 L.S. $6,000.00 $6,000.00
L. Clay Dam 9 Ea. $100.00 $900.00
N. Erosion Control 1 L.S. $6,000.00 $6,000.00
o. Vacuum Testing 1 L.S. $4,000.00 $4,000.00
P. TV Inspection 2065 L.F. $1.00 $2,065.00
Q. 10"Plug 1 Ea. $175.00 $175.00
R. 8"Plug 3 Ea. $150.00 $450.00
Total Sewer $130,357.00
Since there is no control over the cost of labor,materials,and equipment or over
contractor's method of determining prices,or over competitor's bidding or market
conditions,this estimate of probable cost is made on the basis of our professional
experience and represents our best judgment as a firm familiar with the construction
industry. We cannot and do not guarantee proposals,bids on the project costs will not
vary from the above estimate.
Prepared by:
Michae T.Do tt,P.E.
Winkelmann&Associates,Inc.
6750 Hillcrest Plaza Dr.,Ste.325
Dallas,TX 75230
(972)490-7090
(972)490-7099 fax
mdoggett@winkelmann.com
6750 Hillcrest Plaza Drive,Suite 100 Dallas,Texas 75230 (972)490-7090 Fax(972)490-7099
---------------
:s
4. — — — — — —
Ex. 16" RCCP WtrF-62fl — — — —
=733.51 sD 4SIGN
WTR _--
{D INSTALL LONGHORN RD.
x DROP INLEETT �,
INSTALL 30 L.F. - rELE
IoR —
VAULT 24" RCP STORM wtr F-4 V
f /
J-1-1-4d -- -- — _-------- --
fl
Zo
L N
CVS/pharmacy 0' 30' 60'
12,900 SF -_.-__�■
t� -- — .1,77 AC,
775 S.F. Scale: 'I"=60'
F.F.E.= 663.00
ASPHALT -t"D.
P
I
1 � \
PERMANENT 35 SEWER FACUTY EASEMENT--�I\� \
1 (BY SEPARATE INSTRUMENT)
�I17Il�®Ilffi�lI'D1ffi
�,� � Aga®c�nffi�®�➢ IIffi�"
CONSUL1114G CIVIL ENGINEERS ■ SURVS:1'ORS
(�7x ) .9o--70e0 rnx (e7z )00-7009
A.F. ALBRIGHT SURVEY, ABST. NO. 1849 EXHIBIT 'B-1' SHEET
Scole : 1"=60' CITY OF FORT WORTH STORM IMPROVEMENTS y
TARRANT COUNTY, TEXAS
Dote :08/04/09 LONGHORN CROSSING
uEVZLOPM ARMSTRONG DEVELOPMENT A®®0TION Or
Ov+g. File 43895CFAEXIi.UWG 222 W. LAS COLINAS BLVD., SUITE 1610 LOT 1, BLOCK I
Project No. : 43895.01(10) IRVING, TEXAS 75039 FORT WORTH, TARRANT COUNTY, TEXAS
,e Winkelmann
&Associates, Inc.
CONSUITNO CML ENCPMEM■SURVEYORS
Longhorn Crossing Addition
Community Facilities Agreement
Storm Drain Estimate
August 4,2009
Item Description Quantity U/M Unit Total
A. SYS'Drop Inlet 1 Ea. $4,000.00 $4,000.00
B. 24"Reinf.Concrete Pipe 30 L.F. $34.00 $1,020.00
C. Erosion Control 1 L.S. $500.00 $500.00
D. Trench Safety 30 L.F. $1.00 $30.00
E. Traffic Control 1 L.S. $500.00 $500.00
Total Paving $6,050.00
*Since there is no control over the cost of labor,materials,and equipment or over
contractor's method of determining prices,or over competitor's bidding or market
conditions,this estimate of probable cost is made on the basis of our professional
experience and represents our best judgment as a firm familiar with the construction
industry. We cannot and do not guarantee proposals,bids on the project costs will not
vary from the above estimate.
Prepared by: /l
Michael T.r&Associates,
.E.
Winkelma Inc.
6750 Hiilcrest Plaza Dr.,Ste.325
Dallas,TX 75230
(972)490-7090
(972)490-7099 fax
mdoggett@winkelmann.com
6750 Hillcrest Plaza Drive,Suite W* Dallas,Texas 75230 (972)490-7090 Fax(972)490-7099