HomeMy WebLinkAboutContract 42489 (2)CITY EC EiAP
CONTRACT NO, rift
STATE OF TEXAS
KNOW ALL BY THESE PRESENTS
COUNTY OF TARRANT
THIS AGREEMENT is between the City of Fort Worth, Texas, a Texas municipal corporation ("City"),
acting by and through its duly authorized Assistant City Manager, and Quorum Architects, Inc., authorized
to do business in Texas, acting herein by and through David G Duman, AIA, its duly authorized
representative ("Architect").
WITNESSETH
That for and in consideration of the mutual covenants and agreements herein contained, the parties
hereto do hereby covenant and agree as follows:
SECTION I - SERVICES OF THE ARCHITECT
1.1
The City hereby contracts with Architect as an independent contractor, and the Architect hereby
agrees to perform, within the professional standards normally accepted in the State of Texas,
professional services associated with individual assignments in connection with the following
basic services:
Perform architectural investigation, programming, design, and construction administration
services for improvements to facilities/buildings on behalf of the City Fort Worth. Individual project
assignments will generally be in the $10,000 to $100,000 range in construction cost and require a
multi -disciplinary design effort ("Project"). The Agreement is for a five-year period. Each project
assignment will be executed using Attachment "A" (Multi -Year Architect/Engineer Delivery
Order).
SECTION II - CHARACTER AND EXTENT OF ARCHITECT'S SERVICES
2.1 Architect shall consult with the City to clarify and define City's requirements relative to the Projects
and review available data.
2.2 Architect agrees to commit the personnel to each Project as necessary in order to complete the
Project in an expeditious manner.
2.3 The Architect shall advise City as to the necessity of City's providing or obtaining from others
services and data required in connection with the Project at City's cost and expense (which
services and data Architect is not to provide hereunder but on which Architect may rely in
performing services hereunder), and act as City's representative in connection with any such
services of others.
2.4 Architect agrees that architectural services will be managed and performed in its Fort Worth
office, except work done by contracted consultants.
2.5 If at any time in the course of the design, the City expands the scope of services, or the Architect
believes the City has requested services that are beyond the scope of this Agreement, the
Architect shall submit a proposal for additional fees and a written agreement shall be reached on
said proposal prior to the Architect proceeding with the work considered to be beyond the scope
of this Agreement. Architect shall not perform any additional services without a written agreement
with City. Any services provided prior to reaching an agreement on additional fees will be non-
com pensable.
2.6 Architect shall apply for building permits and provide such service as may ie necessary for the
building permits to be issued. The City shall pay any fees for such Building P aOliVICIAL RECORD
CITY SECRETARY
Multi -Year Architectural Agreement, Quorum Architects, Inc. (October 2011) FTo ge`;1'i-+ . iOTX
10-24 1 1 P1d-_.• IO
SECTION III - SPECIAL SERVICES OF ARCHITECT
3.1 If authorized in writing by City, Architect shall furnish or obtain from other special services
necessary to complete the Projects. These special services are not included as part of the Basic
Services. These special services will be paid for by City as indicated in Section IV.
SECTION IV - COMPENSATION TO ARCHITECT
4.1 The total compensation for all of the Project assignments to be performed by Architect as
described in Section II - CHARACTER AND EXTENT of ARCHITECT'S SERVICES and subject
to the limits found in Section IX — TERM AND TERMINATION hereof shall not exceed
$1,500,000 00 for the five-year Agreement (the "Contract Limits'), unless modified by an
amendment hereto authorized in writing by the parties.
4.2 Labor Expenses:
4.2.1 Architect shall be compensated for actual hours worked by and paid to the employees engaged in
performing the individual Project scope of work at the actual hourly rates plus an overhead factor
and a profit factor. Salary rates are contained in Attachment B below, which is made a part of
this Agreement.
4.2.2 Overhead factors:
4.2.2.1 The labor multiplier is the product of the direct overhead factor and the profit factor and is 2.75.
4.2.2.2 Labor multiplier rates for subconsultants shall be 1.1 or less.
4.2.3 The actual hourly rate of an employee is to be established by the employee's yearly compensation
in effect at the time of the invoice divided by the total work hours in a year based on a salaried
employee.
4.2.4 Out of pocket Expenses that are incurred during the progress of the work will be reimbursed at
Architect's cost plus 10% The actual out-of-pocket expenses include: air fare automobile rental
if required, mileage charges, parking, tolls, taxi, meals, lodging, telephone, printing and
reproduction costs, and other miscellaneous costs incurred specifically for this project.
4.2.5 The established overhead rates are inclusive of all employee benefits, all fringes and overhead
costs, general and administrative costs and all other allowable indirect costs except reimbursable
expenses.
4.2.6 Salary schedules and overhead rates are included in Attachment "B" (Basis for Professional
Fees and Charges), attached hereto and made a part of this Agreement
4.2.7 Invoice Format:
4.2.7.1 Monthly invoices shall be broken down by Project, and include a list containing the name of each
employee engaged on each Project, the total time each employee worked during the invoice
period and the hourly rate of each employee The City may require a signed time report for any
employee engaged in work on this project.
4.2.7.2 Description and costs of reimbursable expenses being billed shall be shown clearly on each
invoice accompanied by documentation substantiating each charge. Documentation to
substantiate subcontract charges shall also be submitted with each invoice.
4.2.7.3 Architect shall be reimbursed for work actually performed by contracted consultants at a multiple
of 1.1 times the actual cost of such services. Where the term "contracted consultants' is used in
this document, it is understood to refer to all consultants and other parties rendering services to
the Architect under a written agreement for the execution of the Project.
4.2.7.4 The City and the Architect shall agree in writing on the scope and compensation for the
performance of special services prior to the commencement of such special services.
Multi -Year Architectural Agreement, Quorum Architects, Inc. (October 2011) Page 2 of 10
SECTION V - METHOD OF PAYMENT
5.1 The Architect shall be paid not more frequently than twice per month on the basis of statements
prepared from the books and records of account of the Architect, such statements to be verified
as to accuracy and compliance with the terms of this Agreement by an officer of the Architect
Payment according to statements will be subject to certification by the Director, Transportation
and Public Works Department or his duly authorized representative that such work has been
performed.
5.2 The above charges are on the basis of prompt payment of bills rendered and continuous progress
of the work on the Project until completion If City fails to make uncontested payment due
Architect for services and out-of-pocket expenses within sixty (60) days after Architect's statement
thereof is submitted to City, Architect may, after giving seven days' written notice to City, suspend
services under this Agreement until Architect has been paid in full all amounts due for services
actually performed and reimbursable expenses incurred. In the event of a disputed or contested
billing only that portion so contested will be withheld from payment, and the undisputed portion
will be paid within such sixty (60) day period. The City will exercise reasonableness in contesting
any bill or portion thereof. No interest will accrue on any contested portion of the billing until
mutually resolved. In the event of suspension of services, the Architect shall have no liability to
City for delays or damages caused the City because of such suspension of services.
SECTION VI - PROCEDURES FOR PROVIDING ARCHITECTURAL SERVICES
6.1 Design Phase, as necessary, as determined by the City for each Project:
6.1.1 City shall notify the Architect when it is appropriate to proceed with the services.
6.1.2 The Architect shall visit the site and make itself familiar with the scope of the Project.
6.1.3 The Architect shall estimate the fees and construction cost for the Project.
6.1.4 Upon approval of the estimated costs, the Architect shall perform all services to complete the
design. The design shall include all site work, design and coordination of utilities, landscaping and
facility design required for a complete and functional project.
6.1.5 Architect shall prepare the design in phases. Upon completion of a phase by Architect City shall
notify the Architect of its approval of the phase, at which time the Architect will proceed to the next
design phase. The design phases are as follows:
6.1.5.1 Schematic Design Preparation of alternative floor and site plans, architectural concepts and
principal equipment and finish plans and budget cost estimates.
6.1.5.2 Construction Documents: Preparation of details, mechanical, electrical, and plumbing plans, finish
schedules, detailed specifications, and cost estimates.
6.1.6 Architect shall prepare ' Elimination of Architectural Barriers Registration" and submit the
applications to the Texas Department of Licensing and Regulation or to a licensed provider. All
designs shall be in conformance with the Elimination of Barriers Act, State of Texas, City of Fort
Worth Building Codes and the Texas Accessibility Standards (TAS).
6.1.7 The Architect shall include procedures for mitigating environmental impact, use of recycled
building materials, and sustainable construction, in the design of the project
6.1.8 The Architect shall submit an estimate of probable construction cost and scope for review and
acknowledgement in writing at the completion of the Construction Documents
6.1.9 Upon written approval of the Construction Documents, the Architect shall make whatever final
changes are necessary and submit the drawings and technical specifications to the City for use in
bidding.
6.1.10 The Architect shall provide electronic files in PDF or DWF format for posting to the Internet.
Multi -Year Architectural Agreement, Quorum Architects, Inc. (October 2011) Page 3 of 10
6.2 Construction Advertisement:
6.2.1 The Architect shall respond to Contractors' inquiries, prepare necessary addenda and conduct
the Pre -Proposal Conference
6.2.2 Following construction advertisement, the Architect shall investigate the qualifications of the
apparent low Offeror and make recommendations concerning award of the contract.
6 2 3 If the Construction Budget is exceeded by the lowest bona fide bid, the City may (1) award the
contract, (2 abandon the project and terminate this agreement, or (3) cooperate in the reduction of
the Project Scope and features as required to stay within the Construction Budget in order to rebid
the Project. If the City decides to reduce the scope of the project and rebid the Architect shall
modify the Drawings and Specifications as necessary to stay within the Construction Budget. In
the event the City abandons the project, the City may terminate this Agreement, and the Architect
shall be entitled to compensation as set forth in Section IX hereof
6.3 Construction Services:
6.3.1 The Architect shall assist the City, upon request, in approving submittals, observing construction
procedures and results, reviewing methods and costs associated with proposed change orders,
and resolving construction problems. However, neither the Professional activities of the Design
Professional, nor the presence of the Design Professional or its employees and subconsultants at
a construction site shall relieve the General Contractor and any other entity of its obligations,
duties and responsibilities including, but not limited to, construction means, methods, sequence,
techniques or procedures necessary for performing superintending or coordinating all portions of
the Work of construction in accordance with the contract documents and any health or safety
precautions required by any regulatory agencies. The Design Professional and its personnel have
no authority to exercise any control over any construction contractor or other entity or their
employees in connection with their work or any health or safety precautions. The City agrees that
the General Contractor is solely responsible for jobsite safety, and warrants that this intent shall
be made evident in the City's agreement with the General Contractor.
6.3.2 Architect shall attend periodic job site meetings as required by the City, prepare meeting notes
and distribute them to all participants and key project personnel.
6.3.3 At the completion of construction, the Architect shall conduct and document the final inspection
and assist the City on the resolution of construction or design deficiencies.
6.3.4 The Architect shall prepare "Record Drawings" on a disk and one set of reproducible medium
based on inspection notes, Contractor's marked up field drawings and the Architect's
observations.
6.4 Post Construction:
6.4.1 All project information and designs shall become the property of the City and may be used by the
City in any manner it wishes. The Architect shall not be liable for the use of such design
information on other projects.
6.4.2 Architect shall assist the City in the resolution of post construction and warranty issues for a
period of one year past issuance of Occupancy Permit or final payment to contractor.
6.5 Other Professional Services: Architect shall assist the City on other Project assignments as
requested.
SECTION VII - CITY RESPONSIBILITIES
7.1 Provide all criteria and full information as to City's requirements and designate a person with
authority to act on City's behalf on all matters concerning the Project.
7.2 Assist Architect in obtaining existing studies, reports and other available data and services of
others pertinent to the Project and in obtaining additional reports and data as required.
7.3 Upon reasonable notice arrange for access to and make all provisions for Architect to enter upon
public and private property as may be required for Architect to perform services hereunder.
Multi -Year Architectural Agreement, Quorum Architects, Inc. (October 2011) Page 4 of 10
7.4 Designate in writing qualified persons who will act as City's representatives with respect to a
Project for the purposes of transmitting instructions, receiving information, interpreting and
defining City's policies and decisions with respect to Architect's services.
7.5 Review all reports, recommendations and other documents and provide written decisions
pertaining thereto within a reasonable time.
7.6 Upon reasonable notice provide labor and safety equipment to expose structural elements and
temporarily repair same, and to operate mechanical and electrical systems as required by the
Architect in the development of the design.
7.7 Examine all studies, reports, sketches, drawings, specifications, proposals and other documents
presented by Architect, obtain advice of an attorney, insurance counselor and other consultants as
it deems appropriate for such examination and render in writing decisions pertaining thereto within
a reasonable time so as not to delay the services of Architect.
7.8 Prepare easements and right-of-way acquisition conveyance documents, from description
provided by Architect, contact owners, negotiate for or condemn all easements and right-of-way,
pay all filing and legal fees associated therewith.
7.9 Provide such legal, accounting, insurance and other counseling services to City as may be
required for the Project.
7.10 Pay all permit and review fees.
7.11 Distribute bid documents and addenda to plan houses, contractors and suppliers.
7.12 Collect and administer plan deposits.
7.13 Bear all costs incidental to compliance with this Section.
SECTION VIII - OBSERVE AND COMPLY
8.1 Architect shall prepare "Elimination of Architectural Barriers Registration" and submit the
applications to the Texas Department of Licensing and Regulation or Independent Contract
Provider. All designs shall be in conformance with the Elimination of Barriers Act, State of Texas
City of Fort Worth Building Codes and the Texas Accessibility Standards (TAS) in effect as of the
date such design is delivered to City by the Architect.
8.1.1 Architect shall at all times observe and materially comply with all Federal and State laws and
regulations and with all City ordinances and regulations which in any way affect this Agreement
and the work hereunder, and shall observe and materially comply with all orders, laws ordinances
and regulations which may exist (on the date of execution of this Agreement) or may be enacted
later by governing bodies having jurisdiction or authority for such enactment. No plea of
misunderstanding or ignorance thereof shall be considered.
8.2 The Architect shall reimburse the City for all damages incurred as a result of the failure of a
facility's design as prepared by Architect to conform to all applicable State rules and regulations,
Federal law, and municipal ordinances in effect as of the date such design is delivered to City by
the Architect, including but not limited to the cost to modify the facility to conform to all such
applicable State rules and regulations, Federal law, and municipal ordinances.
8.2.1 Architect shall assess the facility to determine the effect of the proposed improvements on the
compliance with building codes in effect as of the date of such assessment
8.2.2 The scope of the Architect's services shall include design of improvements, including those lying
outside the principal area of improvement, required by building codes in effect as of the date such
design is delivered to City by the Architect.
8.2.3 Should failure to meet the building code criteria ( in effect as of the date such design is delivered
to City by the Architect) require removal of facilities constructed under the design documents to
meet the Code, the Architect shall prepare remedial designs and reimburse the City for the cost of
the original construction and the removal of the affected features.
Multi -Year Architectural Agreement, Quorum Architects, Inc. (October 2011) Page 5 of 10
8.2.4 Should failure to meet building code criteria (in effect as of the date such design is delivered to
City by the Architect) require construction of additional features not included in the original design,
the Architect shall prepare additional designs required to meet the building code at no additional
cost to the City. The cost of the additional construction, less bidding costs and contractor's
mobilization and demobilization costs, will be born by the City. The bidding, mobilization and
demobilization costs will be borne by the Architect.
SECTION IX — TERM AND TERMINATION
9.1 This Agreement shall commence on the date of its execution by both parties and remain in effect
for five (5) years or until the expenditure of $1,500,000.00 (the "Contract Limits"), whichever
occurs first. Provided however, the term and/or Contract Limits may be extended by an executed
written amendment authorized by the parties.
9.2 The Agreement may be terminated prior to its expiration as follows:
9.2.1 The City may terminate this Agreement at any time for convenience, non -appropriation of funds,
or for any cause by notice in writing to the Architect. Upon receipt of such notice, the Architect
shall immediately discontinue all services and work and the placing of all orders or the entering
into Contracts for supplies, assistance, facilities and materials in connection with the performance
of this Agreement and shall proceed to cancel promptly all existing contracts insofar as they are
chargeable to this Agreement.
9.2.2 Either City or the Architect may terminate this Agreement for cause if either party fails
substantially to perform through no fault of the other and does not commence correction of such
nonperformance with 5 days of written notice and diligently complete the correction thereafter.
9.2.3
9.3 In the event of a termination or expiration of this Agreement under the foregoing Section 9.1 or
9.2, the City shall pay the Architect for services performed in accordance herewith prior to such
expiration or termination, less such payments having been previously made. Such payment shall
be based upon the work completed up to the date of termination of the Agreement in accordance
with the method of compensation prescribed in Sections V and VI hereof. Architect shall also be
compensated for all expiration or termination related expenses such as meeting attendance,
document reproduction, transfer of records, etc.
9.4 Upon termination or expiration of this Agreement, the Architect shall provide the City reproducible
copies of all completed or partially completed Architectural documents prepared under this
Agreement which shall become the property of the City and may be used by the City in any
manner it desires. The Architect shall not be liable for the use of such materials for any project
other than the projects described in this Agreement.
SECTION X - INDEMNITY AND INSURANCE
10.1 Approval by the City of contract documents shall not constitute or be deemed to be a release of
the responsibility and liability of the Architect, its officers, agents employees and subconsultants,
for the accuracy and competency of the services performed under this Agreement, including but
not limited to surveys, location of subsurface investigations, designs, working drawings and
specifications and other engineering documents.
10.2 Such approval shall not be deemed to be an assumption of such responsibility and liability by the
City for any negligent act, error or omission in the conduct or preparation of the subsurface
investigations, surveys, designs, working drawings and specifications and other engineering
documents by the Architect, its officers, agents, employees and subconsultants it being the intent
of the parties that approval by the City signifies the City's approval of only the general design
concept of the improvements to be constructed.
Multi -Year Architectural Agreement, Quorum Architects, Inc. (October 2011) Page 6 of 10
10.3 The Architect shall indemnify and hold harmless, the City and all its officers, agents, servants and
employees from any loss, damage liability or expenses, on account of (i) damage to a third
party's property and (ii) injuries, including death, to all third parties, which may arise out of (i) any
negligent act, error or omission in the performance of the Architect's professional services or in
the preparation of designs, working drawings, specifications and other documents by Architect or
(ii) a violation of an order, law, ordinance, or regulation applicable to Architect pursuant to Section
8.1.1 above. For purposes of this Agreement, third parties include but are not limited to officers,
agents or employees of the Architect or subconsultant, and all other persons performing any part
of the work and improvements.
10.4 Notwithstanding anything herein to the contrary, no indemnification provision in this Agreement
shall be construed as requiring the Architect to indemnify or hold the City or any of its officers,
agents, servants or employees harmless from any loss, damages, liability or expense, on account
of damage to property or injuries to person caused directly or indirectly by (i) defects or
deficiencies in design criteria and information provided to Architect by City (ii) any deviation in
construction from Architect's designs, working drawings, specifications or other documents; (iii)
any act or omission of the City, its employees or agents.
10.5 Without limiting the above indemnity, Architect shall maintain the following insurance coverage
with carriers acceptable to City, such insurance to be in at least the following amounts:
Commercial General Liability $1,000,000 Per Occurrence
Workers Compensation
Coverage A: Statutory limits
Coverage B Employers Liability
Business Automobile
Combination Single limits
Professional Liability Insurance
(Errors and Omissions)
$2,000,000 Aggregate
$100,000
$500,000
$100,000
Each Accident
Disease - Policy limit
Disease - Each Employee
$1,000,000 Each Accident
$1,000,000 Per Claim
$1,000,000 Aggregate
10.6 General Insurance Requirements
10.6.1 Commercial General Liability coverage shall be endorsed to name the City an Additional Insured
thereon. The term "City" shall include its employees, officers, officials, agents, and volunteers as
respects the contracted services.
10.6.2 Architect shall furnish City a Certificate(s) of insurance stating that insurance coverage in at least
the limits specified are provided under applicable policies documented thereon.
10.6.3 Any failure on part of the City to request required insurance documentation shall not constitute a
waiver of the insurance requirements.
10.6.4 A minimum of thirty (30) days notice of cancellation, non -renewal or material change in coverage
shall be provided to the City. A ten days notice shall be acceptable in the event of non-payment of
premium. Such terms shall be endorsed onto Architect's insurance policies. Notice shall be sent to
the Facilities Manager, Transportation and Public Works Department, 1000 Throckmorton, Fort
Worth, TX 76102.
Multi -Year Architectural Agreement, Quorum Architects, Inc. (October 2011) Page 7 of 10
10.6.5 The City shall not be responsible for the direct payment of any insurance premiums required by this
Agreement. It is understood that insurance cost is an allowable component of the Architect's general
overhead. Deductible limits or self -funded retention limits, on each policy must not exceed
$25,000.00 per claim or occurrence unless otherwise approved by the City.
10.6.6 The City reserves the right to revise insurance requirements specified in this agreement according
to the best interests of the City. In the event the City so revises the insurance requirements
hereunder, this Agreement will be amended by the parties to adjust the overhead and profit
factors and multiplier rates payable hereunder such that the Architect will be in the same or
substantially similar position with regard to profit on each Project, as before any such adjustment
of the insurance requirements by City.
10.6.7 Workers' compensation insurance policy(s) covering employees directly employed by Architect on
the Project shall be endorsed with a waiver of subrogation providing rights of recovery in favor of
the City. Architect makes no representations or warranties regarding and will not have any
liability for damages or claims related to, the insurance or lack of insurance coverage of any
persons other than Architect.
10.6.8 Insurers for all policies must be authorized to do business in the state of Texas or be otherwise
approved by the City; and, such insurers shall be acceptable to the City in terms of their financial
strength and solvency.
10.6.9 Deductible limits, or self -insured retentions, affecting insurance required herein may be acceptable to
the City at its sole discretion; and, in lieu of traditional insurance, any alternative coverage maintained
through insurance pools or risk retention groups must be also approved. Dedicated financial
resources or letters of credit may also be acceptable to the City.
10.6.10 The City shall be entitled, upon its request and without incurring expense, to review the Architect's
insurance policies including endorsements thereto and, at the City's discretion, the Architect may be
required to provide proof of insurance premium payments
10.6.11 All insurance, except for the Professional Liability insurance policy, shall be written on an occurrence
basis. Architect's liability shall not be limited to the specified amounts of insurance required herein.
10.6.12 The Professional Liability Policy shall be written on a "claims made" and shall be in effect for the
duration of this Agreement and for a period of ten years following the issuance of the Certificate of
Substantial Completion by the Architect. The City shall be provided a current Certificate of
Insurance annually, and be notified at least 30 days prior to cancellation or substantial change in
coverage.
10.6.13 The City shall require its General Contractor to include the Architect as an additional insured on its
general liability insurance.
SECTION XI - INDEMNITY PERTAINING TO HAZARDOUS MATERIALS
11.1 City acknowledges Architect will perform part of the work at City's facilities that may contain
hazardous materials, including asbestos containing materials or conditions, and that Architect
had no prior role in the generation, treatment, storage, or disposition of such materials In
consideration of the associated risks that may give rise to claims by third parties or employees of
City, City hereby releases Architect from any damage or liability related to the presence of such
materials
11.2 The release required above shall not apply in the event the discharge, release, or escape of
hazardous substances, contaminants, or asbestos is a result of Architect's gross negligence or if
Architect brings such hazardous substance, contaminant, or asbestos onto the Projects.
SECTION XII - RIGHT TO AUDIT
12.1 Architect agrees that the City shall, until the expiration of three (3) years after final payment under
this Agreement, have access to and the right to examine any directly pertinent books, documents,
papers and records of the Architect involving transactions relating to this Agreement Architect
Multi -Year Architectural Agreement, Quorum Architects, Inc. (October 2011) Page 8 of 10
agrees that the City shall have access during normal working hours to all necessary Architect
facilities and shall be provided adequate and appropriate work space in order to conduct audits in
compliance with the provisions of this section. The City shall give Architect reasonable advance
notice of intended audits.
12.2 Architect further agrees to include in all its subcontracts hereunder a provision to the effect that
the subconsultant agrees that the City shall, until the expiration of three (3) years after final
payment under the subcontract, have access to and the right to examine any directly pertinent
books, documents, papers and records of such subconsultant, involving transactions to the
subcontract, and further, that City shall have access during normal working hours to all
subconsultant facilities, and shall be provided adequate and appropriate work space, in order to
conduct audits in compliance with the provisions of this article. City shall give subconsultant
reasonable advance notice of intended audits.
12.3 Architect and contracted consultants agree to photocopy such documents as may be requested
by the City. The City agrees to reimburse Architect and contracted consultants for the costs of
copies at the rate published in the Texas Administrative Code.
SECTION XIII - SUCCESSORS AND ASSIGNS
13.1 The City and the Architect each bind themselves, their successors and assigns, to the other party
to this Agreement and to the successors and assigns of each other party in respect to all
covenants of this Agreement.
SECTION XIV -ASSIGNMENT
14.1 Neither party hereto shall assign, sublet or transfer its interest herein without prior written consent
of the other party, and any attempted assignment, sublease or transfer of all or any part hereof
without such prior written consent shall be void.
SECTION XV - INDEPENDENT ARCHITECT
15.1 Architect shall perform all work and services hereunder as an independent Architect, and not as
an officer, agent, servant or employee of the City. Architect shall have exclusive control of, and
the exclusive right to control the details of the work performed hereunder, and all persons
performing same, and shall be solely responsible for the acts and omissions of its officers, agents,
employees and contracted consultants. Nothing herein shall be construed as creating a
partnership or joint venture between the City and the Architect, its officers, agents, employees and
contracted consultants, and doctrine of respondent superior has no application as between the
City and the Architect.
SECTION XVI - M/WBE GOALS
16.1 In accordance with City of Fort Worth Ordinance No. 15530, as amended, the City has goals for
the participation of minority and .woman business enterprises in City contracts. Architect
acknowledges the M/WBE goal of 20% established for this Agreement and its commitment to
meet that goal. Analysis of whether such M/WBE goal is met will be measured on an aggregate
basis for the entire term of the Agreement; the M/WBE goal is not required to be met on each
individual Project. Any misrepresentation of facts (other than a negligent misrepresentation)
and/or the commission of fraud by Architect may result in termination of this Agreement and
debarment from participating in City contracts for a period of time not less than three years.
Multi -Year Architectural Agreement, Quorum Architects, Inc. (October 2011) Page 9 of 10
SECTION XVII - MISCELLANEOUS
17.1 If any action, whether real or asserted, at law or in equity, arises on the basis of any provision of
this Agreement, venue for such action shall lie in state courts located in Tarrant County, Texas or
the United States District Court for the Northern District of Texas — Fort Worth Division. This
Agreement shall be construed in accordance with the laws of the State of Texas.
17.2 The parties acknowledge that each party and, if it so chooses, its counsel have reviewed and
revised this Agreement and that the normal rule of construction to the effect that any ambiguities
are to be resolved against the drafting party must not be employed in the interpretation of this
Agreement or any amendments or exhibits hereto.
17.3 This Agreement shall inure only to the benefit of the parties hereto and third persons not privy
hereto shall not, in any form or manner, be considered a third party beneficiary of this Agreement.
Each party hereto shall be solely responsible for the fulfillment of its own contracts or
commitments.
17.4 This Agreement shall be signed and executed in triplicate copies, each of which is deemed an
original.
AGREED TO AND EXECUTED BY:
QUORUM ARCHITECTS, INC.
By: •
David G Duman, AIA
Principal
co
CITY OF FORT WORTH:
innettA, /0'240 By: calintagtai
Date Fernando Costa
Assistant City Manager
APPROVAL RECOMMENDED°
By:
Douglas CPU. Wiersig, PE
Director, Transportation & Public Works Department
APPROVED AS TO FORM AND LEGALITY:
M1
By:
Dougras W.\B1ac
Assistant City Attorney
RECORDED:
By:,�
Marty Hendrix
City Secretary
ate t< Otoo00oo, �l''ll
Date Executed: tb\a‘S\ ")--0 Li
Authorization: M&C C-25235 (October 18, 2011)
The Texas Board of Architectural Examiners, 8213 Shoal Creek Boulevard, Suite 107, Austin, Texas, 78758, telephone (512) 305-
9000, has jurisdiction over individuals licensed under the Architects' Registration Law, Texas Civil Statures, Article 249a.
Multi -Year Architectural Agreement, Quorum Architects, Inc. (October 2011)
OFFICIAL RECORD
CITY SECRETARY
FT. W9ipett,ops
FORT WORTH
ATTACHMENT "A"
MULTI -YEAR ARCHITECTURALSERVICES DELIVERY ORDER
This Annual Architect/Engineer Agreement for professional services is governed by all terms and
conditions of the Contract referenced below which is hereby incorporated by reference
S ponsoring (Client) Department:
City's Contract No.•
Delivery Order No.:
P roject Name:
P rofessional Services Firm:
Date of Contract:
Delivery Order Date:
City's Project Architect or Manager:
Dept
City Secretary Contract No.
2011-16-2011-
Quorum Architects, Inc.
S ummary and Description of Statement of Work attached hereto:
Scope of Work and fee proposal per Quorum Architects, Inc. letter dated
subject: (attached).
Fund/Account/Center No.:
Design Fees: $ (Schematics Design or Other Phase)
Reimbursable Expenses: Not -to -Exceed $
Notice -to -Proceed Date for this Delivery Order:
Completion Date for this Delivery Order:
TRANSPORTATION & PUBLIC WORKS DEPT
ARCHITECTURAL SERVICES DIVISION
By:
Dalton Murayama, AIA
Architectural Services Manager
Date:
CC: Sponsoring Dept (
M/WBE (
Arch Svcs Project Architect or Manager (
Arch Svcs Admin (Vicki McDonald)
Arch Svcs Mgr (Dalton Murayama)
QUORUM ARCHITECTS, INC.
By:
David Duman, AIA
Principal
Multi -Year Architectural Agreement, Quorum Architects, Inc.(October 2011)
Attachment A
Page 1 of 1
ATTACHMENT B
ANNUAL ARCHITECTE NGINEER AGREEMENT
BETWEEN CITY OF FORT WORTH
AND QUORUM ARCHITECTS, INC.
BASIS FOR PROFESSIONAL FEES AND CHARGES
OCTOBER 2011
Projects indicated to be performed on a "Time and Materials" basis will be invoiced
monthly using actual raw salary cost for the persons working on the project times a
multiplier which is an overhead factor, including profit The current year multiplier is
2.75. The general ranges of raw salary costs per your for the various employees are as
follows:
Senior Officer, Principal
Project Architect/Engineer, Officer
Architect/Engineer
Designer
CADD Technician
Project Support: Includes Clerical, Computer Systems,
Document Control, and Accounting Support
$76.00 to $79.00
$29.00 to $37.00
$30.00 to $44.00
$25.00 to $30.00
N/A
$29.00 to $29.00
REIMBURSABLE EXPENSES WILL BE INVOICED AS FOLLOWS:
In -House Blue Prints
In -House Photocopies
Outside Printing (Large Format)
Outside Printing (Small Format)
Outside Services
Mileage (Same as Authorized to City Staff)
$0.80 Per SF
$0.18 Per Page
$0.15 Per SF + 10%
$0.08 Per SF + 10%
Actual Cost + 10%
$0.555 Per Mile
Multi -Year Architectural Agreement, Quorum Architects, Inc. (October 2011)
Attachment B
Page 1 of 1
ACORD
CERTIFICATE OF LIABILITY INSURANCE
I DATE (MM/DD/YYYY)
10/19/2011
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS
CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES
BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED
REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER
IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to
the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the
certificate holder in lieu of such endorsement(s).
PRODUCER
McLaughlin Brunson Insurance Agency, LLP
6600 LBJ Freeway, Suite 220
Dallas TX 75240
INSURED
Quorum Architects, Inc.
707 W. Vickery Blvd., #101
Fort Worth TX 761041142
COVERAGES
CONTACT
NAME:
PHONE
(A/C, No. Extl:
E-MAIL
ADDRESS:
PRODUCER
CUSTOMER ID #:
(214) 503-1212
FAX
(A/C. No):
INSURER(S) AFFORDING COVERAGE
INSURERA:XL Specialty Insurance Company
INSURERB:Travelers Lloyds Ins. Company
INSURERC:Charter Oak Fire Insurance Co.
INSURERD:Travelers Indemnity Company
INSURER E :
INSURER F :
CERTIFICATE NUMBER: Cert ID 11512
REVISION NUMBER:
NAIC #
37885
41262
25615
25658
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
INSR TYPE OF INSURANCE ADDL SUBR POLICY EFF POLICY EXP LIMITS
LTRINSR AND POLICY NUMBER (MM/DD/YYYYI (MM/DD/YYYYI
GENERAL LIABILITY
B
C
D
X COMMERCIAL GENERAL LIABILITY
CLAIMS -MADE X OCCUR
GEN'L AGGREGATE LIMIT APPLIES PER:
POLICY I X I PET I LOC
AUTOMOBILE LIABILITY
X ANY AUTO
ALL OWNED AUTOS
SCHEDULED AUTOS
HIRED AUTOS
NON -OWNED AUTOS
UMBRELLA LIAB
EXCESS LIAB
DEDUCTIBLE
OCCUR
CLAIMS -MADE
RETENTION $
WORKERS COMPENSATION
AND EMPLOYERS' LIABILITY
ANY PROPRIETOR/PARTNER/EXECUTIVE
OFFICER/MEMBER EXCLUDED?
(Mandatory in NH)
If yes, describe under
DESCRIPTION OF OPERATIONS below
A Professional Liab
Y/N
Y Y PACP4331L779
Y Y BA4333L109
Y
N/A
8/25/2011 8/25/2012
8/25/2011 8/25/2012
UB5771Y404 4/20/2011 4/20/2012
N Y DPR9693328
EACH OCCURRENCE
DAMAGE TO RENTED
PREMISES (Ea occurrence)
MED EXP (Any one person)
PERSONAL & ADV INJURY
GENERAL AGGREGATE
PRODUCTS - COMP/OP AGG
COMBINED SINGLE LIMIT
(Ea accident)
BODILY INJURY (Per person)
I BODILY INJURY (Per accident)
PROPERTY DAMAGE
(Per accident)
EACH OCCURRENCE
AGGREGATE
X TORY LIAMITS I I OER
2,000,000
2,000,000
10,000
2,000,000
4,000,000
4,000,000
2,000,000
E.L. EACH ACCIDENT $ 1,000,000
E.L. DISEASE - EA EMPLOYEE $ 1,000,000
E.L. DISEASE -POLICY LIMIT $ 1,000,000
3/27/2011 3/27/2012 $1,000,000 Per Claim /
$2,000,000 Annual Aggregate
DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (Attach ACORD 101, Additional Remarks Schedule, if more space is required)
The claims made professional liability coverage is the total aggregate limit for all claims
presented within the policy period and is subject to a deductible. Thirty(30) day notice of
cancellation in favor of the certificate holder on all policies. City of Fort Worth is named
additional insured with waiver of subrogation on the general & auto liability as required by
contract. A waiver of subrogation is shown in favor of the City of Fort Worth on the workers
CERTIFICATE HOLDER CANCELLATION
City of Fort Worth
1000 Throckmorton
Fort Worth TX 76102
ACORD 25 (2009/09)
as
comp.
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE
THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN
ACCORDANCE WITH THE POLICY PROVISIONS.
AUTHORIZED REPRESENTATIVE
1988-2009 ACORD CORPORATION. All rights reserved.
The ACORD name and logo are registered marks of ACORD
Page 1 of 2
DESCRIPTION OF OPERATIONS SECTION CONT INUED
CERTIFICATE HOLDER: INSURED:
City of Fort Worth Quorum Architects, Inc.
1000 Throckmorton
Fort Worth TX 76102
DESCRIPTION OF OPERATIONS CONTINUED:
coverage.
DOC (10/2003)
707 W. Vickery Blvd., #101
Fort Worth TX 761041142
DATE
10/19/2011
Page 2 of 2
City of Fort Worth, Texas
Mayor and Council Communication
COUNCIL ACTION: Approved on 10/18/2011
DATE: Tuesday, October 18, 2011
LOG NAME: 20ANNUALAEFIRMS
SUBJECT:
REFERENCE NO.: C-25235
Authorize Execution of Two Multi -Year Architectural Design Agreements for Small Multi -Disciplinary
Projects with Elements of Architecture, Inc , and Quorum Architects, Inc., on an As -Needed Basis for a
Total Fee Not to Exceed $1,500,000.00 Over the Five -Year Period for Each Agreement (ALL COUNCIL
DISTRICTS)
RECOMMENDATION:
It is recommended that the City Council authorize the execution of two multi -year Architectural Design
Agreements with Elements of Architecture, Inc,. and Quorum Architects, Inc., for a total fee not to exceed
$1,500,000.00 over the five-year period of each Agreement.
DISCUSSION:
This M&C will authorize the execution of two multi -year Architectural Design Agreements in the amount of
$1,500,000.00 each.
The City of Fort Worth requires architectural assistance for small multi -disciplinary projects on an as -
needed -basis. A Request for Statement of Qualification (RFQ) was advertised in the Fort Worth Star -
Telegram on July 14 2011 and July 21, 2011, 30 firms responded. The selection panel shortlisted and
interviewed six firms and recommended Elements of Architecture, Inc., and Quorum Architects Inc., as
the best qualified firms.
Both of these firms will assist City Staff in the design of small renovation and expansion projects that
require the assistance of civil, landscaping structural, mechanical, and electrical consultants in preparing
project and construction documents. The architectural firms will also assist Staff with structural,
mechanical and electrical assessments, cost estimating, space needs evaluations, conceptual site and
floor plans for review, and designs for emergency repairs of damaged facilities.
All expenditures for the project assignments will be made through allocations from capital and
departmental budgets.
The current annual Architectural Design Agreement with Elements of Architecture, Inc., (M&C C-21667,
September 12, 2006) expires October 2011.
Elements of Architecture, Inc., and Quorum Architects, Inc., are in compliance with the City's M/WBE
Ordinance by committing to 20 percent M/WBE participation. The City's goal on these agreements is 20
percent.
FISCAL INFORMATION / CERTIFICATION:
The Financial Management Services Director certifies that funds are available in the current operating and
capital budgets, as appropriated, of the participating funds.
FUND CENTERS:
TO Fund/Account/Centers FROM Fund/Account/Centers
CERTIFICATIONS:
Submitted for City Manaaer's Office bv:
Oriainatina Department Head:
Additional Information Contact:
ATTACHMENTS
No attachments found.
Fernando Costa (6122)
Douglas W. Wiersig (7801)
Dalton Murayama (8088)