Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
Contract 45311 (2)
Oint OECRE Lmv worRe\r,Liii CITY OF FORT WORTH, TEXAS STANDARD AGREEMENT FOR ENGINEERING RELATED DESIGN SERVICES This AGREEMENT is between the City of Fort Worth, a Texas home -rule municipality (the "CITY"), and Garver, LLC, authorized to do business in Texas, (the "ENGINEER"), for a PROJECT generally described as: Texas Way Pavement Improvements. Article Scope of Services A. The Scope of Services is set forth in Attachment A. Article II Compensation A. The ENGINEER's compensation shall be in the amount of $12,600.00 as set forth in Attachment B. Article III Terms of Payment Payments to the ENGINEER will be made as follows: A. Invoice and Payment (1) The Engineer shall provide the City sufficient documentation, including but not limited to meeting the requirements set forth in Attachment D to this AGREEMENT, to reasonably substantiate the invoices. (2) The ENGINEER will issue monthly invoices for all work performed under this AGREEMENT. Invoices are due and payable within 30 days of receipt. (3) Upon completion of services enumerated in Article I, the final payment of any balance will be due within 30 days of receipt of the final invoice. City of Fort Worth, Texas Standard Agreement for Engineering Related Design Services PMO Official Release Date: 1/28/2013 Page 1 of 16 an' SE©f' 1118121 �,j i', -td cirr> K (4) In the event of a disputed or contested billing, only that portion so contested will be withheld from payment, and the undisputed portion will be paid. The CITY will exercise reasonableness in contesting any bill or portion thereof. No interest will accrue on any contested portion of the billing until mutually resolved. (5) If the CITY fails to make payment in full to ENGINEER for billings contested in good faith within 60 days of the amount due, the ENGINEER may, after giving 7 days' written notice to CITY, suspend services under this AGREEMENT until paid in full. In the event of suspension of services, the ENGINEER shall have no liability to CITY for delays or damages caused the CITY because of such suspension of services. Article IV Obligations of the Engineer Amendments to Article IV, if any, are included in Attachment C. A. General The ENGINEER will serve as the CITY's professional engineering representative under this Agreement providing professional engineering consultation and advice and furnishing customary services incidental thereto. Standard of Care The standard of care applicable to the ENGINEER s services will be the degree of skill and diligence normally employed in the State of Texas by professional engineers or consultants performing the same or similar services at the time such services are performed. C. Subsurface Investigations (1) The ENGINEER shall advise the CITY with regard to the necessity for subcontract work such as special surveys, tests, test borings, or other subsurface investigations in connection with design and engineering work to be performed hereunder. The ENGINEER shall also advise the CITY concerning the results of same. Such surveys, tests, and investigations shall be furnished by the CITY, unless otherwise specified in Attachment A. City of Fort Worth, Texas Standard Agreement for Engineering Related Design Services PMO Official Release Date: 1/28/2013 Page 2 of 16 (2) In soils, foundation, groundwater, and other subsurface investigations, the actual characteristics may vary significantly between successive test points and sample intervals and at locations other than where observations, exploration, and investigations have been made. Because of the inherent uncertainties in subsurface evaluations, changed or unanticipated underground conditions may occur that could affect the total PROJECT cost and/or execution These conditions and cost/execution effects are not the responsibility of the ENGINEER D Preparation of Engineering Drawings The ENGINEER will provide to the CITY the original drawings of all plans in ink on reproducible mylar sheets and electronic files in pdf format, or as otherwise approved by CITY, which shall become the property of the CITY. CITY may use such drawings in any manner it desires; provided, however, that the ENGINEER shall not be liable for the use of such drawings for any project other than the PROJECT described herein. E. Engineer's Personnel at Construction Site (1) The presence or duties of the ENGINEER's personnel at a construction site, whether as on -site representatives or otherwise, do not make the ENGINEER or its personnel in any way responsible for those duties that belong to the CITY and/or the CITY's construction contractors or other entities, and do not relieve the construction contractors or any other entity of their obligations, duties, and responsibilities, including, but not limited to, all construction methods, means, techniques, sequences, and procedures necessary for coordinating and completing all portions of the construction work in accordance with the Contract Documents and any health or safety precautions required by such construction work The ENGINEER and its personnel have no authority to exercise any control over any construction contractor or other entity or their employees in connection with their work or any health or safety precautions. (2) Except to the extent of specific site visits expressly detailed and set forth in Attachment A, the ENGINEER or its personnel shall have no obligation or responsibility to visit the construction site to become familiar with the progress or quality of the completed work on the PROJECT or to determine, in general if the work on the PROJECT is being performed in a manner indicating that the PROJECT, when completed, will be in accordance with the Contract Documents, nor shall anything in the Contract Documents or the agreement between CITY and ENGINEER be construed as requiring City of Fort Worth, Texas Standard Agreement for Engineering Related Design Services PMO Official Release Date: 1/28/2013 Page 3 of 16 (3) ENGINEER to make exhaustive or continuous on -site inspections to discover latent defects in the work or otherwise check the quality or quantity of the work on the PROJECT. If the ENGINEER makes on -site observation(s) of a deviation from the Contract Documents, the ENGINEER shall inform the CITY. When professional certification of performance or characteristics of materials, systems or equipment is reasonably required to perform the services set forth in the Scope of Services, the ENGINEER shall be entitled to rely upon such certification to establish materials, systems or equipment and performance criteria to be required in the Contract Documents. F. Opinions of Probable Cost, Financial Considerations, and Schedules (1) The ENGINEER shall provide opinions of probable costs based on the current available information at the time of preparation, in accordance with Attachment A. (2) In providing opinions of cost, financial analyses, economic feasibility projections, and schedules for the PROJECT, the ENGINEER has no control over cost or price of labor and materials; unknown or latent conditions of existing equipment or structures that may affect operation or maintenance costs; competitive bidding procedures and market conditions time or quality of performance by third parties; quality type, management, or direction of operating personnel; and other economic and operational factors that may materially affect the ultimate PROJECT cost or schedule. Therefore, the ENGINEER makes no warranty that the CITY's actual PROJECT costs financial aspects, economic feasibility or schedules will not vary from the ENGINEER's opinions, analyses, projections, or estimates. G. Construction Progress Payments Recommendations by the ENGINEER to the CITY for periodic construction progress payments to the construction contractor will be based on the ENGINEER's knowledge, information, and belief from selective sampling and observation that the work has progressed to the point indicated Such recommendations do not represent that continuous or detailed examinations have been made by the ENGINEER to ascertain that the construction contractor has completed the work in exact accordance with the Contract Documents; that the final work will be acceptable in all respects that the ENGINEER has made an examination to ascertain how or for what purpose the construction contractor has used the moneys paid; that title to any of the work, materials, or equipment has passed to the CITY free and clear of liens, claims, security interests, or encumbrances; or that there are not other City of Fort Worth, Texas Standard Agreement for Engineering Related Design Services PMO Official Release Date: 1/28/2013 Page 4 of 16 matters at issue between the CITY and the construction contractor that affect the amount that should be paid. Record Drawings Record drawings if required, will be prepared, in part on the basis of information compiled and furnished by others, and may not always represent the exact location, type of various components, or exact manner in which the PROJECT was finally constructed. The ENGINEER is not responsible for any errors or omissions in the information from others that is incorporated into the record drawings. I. Minority Business and Small Business Enterprise (MBE)(SBE) Participation In accord with the City of Fort Worth Business Diversity Ordinance No. 20020-12-2011, as amended, the City has goals for the participation of minority business enterprises and/or small business enterprises in City contracts Engineer acknowledges the MBE and SBE goals established for this contract and its accepted written commitment to MBE and SBE participation. Any misrepresentation of facts (other than a negligent misrepresentation) and/or the commission of fraud by the Engineer may result in the termination of this Agreement and debarment from participating in City contracts for a period of time of not less than three (3) years. J. Right to Audit (1) ENGINEER agrees that the CITY shall, until the expiration of five (5) years after final payment under this contract, have access to and the right to examine and photocopy any directly pertinent books, documents, papers and records of the ENGINEER involving transactions relating to this contract ENGINEER agrees that the CITY shall have access during normal working hours to all necessary ENGINEER facilities and shall be provided adequate and appropriate work space in order to conduct audits in compliance with the provisions of this section. The CITY shall give ENGINEER reasonable advance notice of intended audits. (2) ENGINEER further agrees to include in all its subconsultant agreements hereunder a provision to the effect that the subconsultant agrees that the CITY shall, until the expiration of five (5) years after final payment under the subcontract, have access to and the right to examine and photocopy any directly pertinent books, documents, papers and records of such subconsultant, involving transactions to the subcontract, and further, that the CITY shall have access during normal working hours to all subconsultant City of Fort Worth, Texas Standard Agreement for Engineering Related Design Services PMO Official Release Date: 1/28/2013 Page 5 of 16 (3) facilities, and shall be provided adequate and appropriate work space, in order to conduct audits in compliance with the provisions of this article together with subsection (3) hereof. CITY shall give subconsultant reasonable advance notice of intended audits. ENGINEER and subconsultant agree to photocopy such documents as may be requested by the CITY. The CITY agrees to reimburse ENGINEER for the cost of copies at the rate published in the Texas Administrative Code in effect as of the time copying is performed. K. INSURANCE (1) ENGINEER'S INSURANCE a. Commercial General Liability — the ENGINEER shall maintain commercial general liability (CGL) and, if necessary, commercial umbrella insurance with a limit of not less than $1,000,000 00 per each occurrence with a $2,000,000.00 aggregate. If such Commercial General Liability insurance contains a general aggregate limit, it shall apply separately to this PROJECT or location. i. The CITY shall be included as an insured under the CGL, using ISO additional insured endorsement or a substitute providing equivalent coverage, and under the commercial umbrella, if any This insurance shall apply as primary insurance with respect to any other insurance or self-insurance programs afforded to the CITY. The Commercial General Liability insurance policy shall have no exclusions by endorsements that would alter or nullify: premises/operations, products/completed operations, contractual, personal injury, or advertizing injury, which are normally contained within the policy, unless the CITY approves such exclusions in writing. ii ENGINEER waives all rights against the CITY and its agents, officers, directors and employees for recovery of damages to the extent these damages are covered by the commercial general liability or commercial umbrella liability insurance maintained in accordance with this agreement. b. Business Auto — the ENGINEER shall maintain business auto liability and, if necessary, commercial umbrella liability insurance with a limit of not less than $1 000,000 each accident. Such insurance shall cover liability arising out of 'any auto', including owned, hired, and non -owned autos, when said vehicle is used in the course of the PROJECT. If the engineer owns no vehicles, coverage for hired or non -owned is City of Fort Worth, Texas Standard Agreement for Engineering Related Design Services PMO Official Release Date: 1/28/2013 Page 6 of 16 acceptable. i ENGINEER waives all rights against the CITY and its agents, officers, directors and employees for recovery of damages to the extent these damages are covered by the business auto liability or commercial umbrella liability insurance obtained by ENGINEER pursuant to this agreement or under any applicable auto physical damage coverage. c. Workers' Compensation —ENGINEER shall maintain workers compensation and employers liability insurance and, if necessary commercial umbrella liability insurance with a limit of not less than $100,000.00 each accident for bodily injury by accident or $100,000.00 each employee for bodily injury by disease, with $500,000.00 policy limit. i ENGINEER waives all rights against the CITY and its agents, officers, directors and employees for recovery of damages to the extent these damages are covered by workers compensation and employer's liability or commercial umbrella insurance obtained by ENGINEER pursuant to this agreement. d. Professional Liability — the ENGINEER shall maintain professional liability a claims -made policy, with a minimum of $1,000,000.00 per claim and aggregate The policy shall contain a retroactive date prior to the date of the contract or the first date of services to be performed, whichever is earlier. Coverage shall be maintained for a period of 5 years following the completion of the contract. An annual certificate of insurance specifically referencing this project shall be submitted to the CITY for each year following completion of the contract. (2) GENERAL INSURANCE REQUIREMENTS a. Certificates of insurance evidencing that the ENGINEER has obtained all required insurance shall be delivered to the CITY pnor to ENGINEER proceeding with the PROJECT. b. Applicable policies shall be endorsed to name the CITY an Additional Insured thereon, as its interests may appear. The term CITY shall include its employees, officers, officials, agents, and volunteers as respects the contracted services. c. Certificate(s) of insurance shall document that insurance coverage specified in this agreement are provided under applicable policies documented thereon City of Fort Worth, Texas Standard Agreement for Engineering Related Design Services PMO Official Release Date: 1/28/2013 Page 7 of 16 d. Any failure on part of the CITY to request required insurance documentation shall not constitute a waiver of the insurance requirements. e. A minimum of thirty (30) days notice of cancellation or material change in coverage shall be provided to the CITY. A ten (10) days notice shall be acceptable in the event of non-payment of premium. Notice shall be sent to the respective Department Director (by name), City of Fort Worth, 1000 Throckmorton, Fort Worth, Texas 76102. f. Insurers for all policies must be authorized to do business in the State of Texas and have a minimum rating of A:V or greater, in the current A.M. Best Key Rating Guide or have reasonably equivalent financial strength and solvency to the satisfaction of Risk Management. g. Any deductible or self insured retention in excess of $25,000.00 that would change or alter the requirements herein is subject to approval by the CITY in writing, if coverage is not provided on a first -dollar basis. The CITY, at it sole discretion, may consent to alternative coverage maintained through insurance pools or risk retention groups. Dedicated financial resources or letters of credit may also be acceptable to the CITY. h. Applicable policies shall each be endorsed with a waiver of subrogation in favor of the CITY as respects the PROJECT. j• The CITY shall be entitled upon its request and without incurring expense, to review the ENGINEER's insurance policies including endorsements thereto and, at the CITY's discretion; the ENGINEER may be required to provide proof of insurance premium payments. Lines of coverage, other than Professional Liability, underwritten on a claims -made basis, shall contain a retroactive date coincident with or prior to the date of the contractual agreement The certificate of insurance shall state both the retroactive date and that the coverage is claims -made. k. Coverages, whether written on an occurrence or claims -made basis, shall be maintained without interruption nor restrictive modification or changes from date of commencement of the PROJECT until final payment and termination of any coverage required to be maintained after final payments. I. The CITY shall not be responsible for the direct payment of any insurance premiums required by this agreement. City of Fort Worth, Texas Standard Agreement for Engineering Related Design Services PMO Official Release Date: 1/28/2013 Page 8 of 16 m. Sub consultants and subcontractors to/of the ENGINEER shall be required by the ENGINEER to maintain the same or reasonably equivalent insurance coverage as required for the ENGINEER When sub consultants/subcontractors maintain insurance coverage, ENGINEER shall provide CITY with documentation thereof on a certificate of insurance. L. Independent Consultant The ENGINEER agrees to perform all services as an independent consultant and not as a subcontractor, agent, or employee of the CITY. M. Disclosure The ENGINEER acknowledges to the CITY that it has made full disclosure in writing of any existing conflicts of interest or potential conflicts of interest, including personal financial interest, direct or indirect, in property abutting the proposed PROJECT and business relationships with abutting property cities. The ENGINEER further acknowledges that it will make disclosure in writing of any conflicts of interest that develop subsequent to the signing of this contract and prior to final payment under the contract. N. Asbestos or Hazardous Substances (1) If asbestos or hazardous substances in any form are encountered or suspected, the ENGINEER will stop its own work in the affected portions of the PROJECT to permit testing and evaluation. (2) If asbestos or other hazardous substances are suspected, the CITY may request the ENGINEER to assist in obtaining the services of a qualified subcontractor to manage the remediation activities of the PROJECT. O. Permitting Authorities - Design Changes If permitting authorities require design changes so as to comply with published design criteria and/or current engineering practice standards which the ENGINEER should have been aware of at the time this Agreement was executed, the ENGINEER shall revise plans and specifications, as required at its own cost and expense. However, if design changes are required due to the changes in the permitting authorities' published design criteria and/or practice standards criteria which are published after the date of this Agreement which the ENGINEER could not have been reasonably aware of, the ENGINEER shall notify the CITY of such changes and an adjustment in compensation will be made through an City of Fort Worth, Texas Standard Agreement for Engineering Related Design Services PMO Official Release Date: 1/28/2013 Page 9 of 16 amendment to this AGREEMENT. P. Schedule ENGINEER shall manage the PROJECT in accordance with the schedule developed per Attachment D to this AGREEMENT. Article V Obligations of the City Amendments to Article V, if any, are included in Attachment C. A. City -Furnished Data ENGINEER may rely upon the accuracy, timeliness, and completeness of the information provided by the CITY. B Access to Facilities and Property The CITY will make its facilities accessible to the ENGINEER as required for the ENGINEER's performance of its services The CITY will perform, at no cost to the ENGINEER, such tests of equipment, machinery, pipelines, and other components of the CITY's facilities as may be required in connection with the ENGINEER's services. The CITY will be responsible for all acts of the CITY s personnel. C. Advertisements, Permits, and Access Unless otherwise agreed to in the Scope of Services, the CITY will obtain, arrange and pay for all advertisements for bids; permits and licenses required by local, state, or federal authorities; and land, easements, rights - of -way, and access necessary for the ENGINEER's services or PROJECT construction. City of Fort Worth, Texas Standard Agreement for Engineering Related Design Services PMO Official Release Date: 1/28/2013 Page 10 of 16 D Timely Review The CITY will examine the ENGINEER's studies, reports, sketches, drawings, specifications, proposals, and other documents; obtain advice of an attorney insurance counselor, accountant, auditor, bond and financial advisors, and other consultants as the CITY deems appropriate, and render in writing decisions required by the CITY in a timely manner in accordance with the project schedule prepared in accordance with Attachment D E. Prompt Notice The CITY will give prompt written notice to the ENGINEER whenever CITY observes or becomes aware of any development that affects the scope or timing of the ENGINEER's services or of any defect in the work of the ENGINEER or construction contractors. F. Asbestos or Hazardous Substances Release. (1) CITY acknowledges ENGINEER will perform part of the work at CITY's facilities that may contain hazardous materials, including asbestos containing materials, or conditions, and that ENGINEER had no prior role in the generation, treatment, storage, or disposition of such matenals. In consideration of the associated risks that may give rise to claims by third parties or employees of City City hereby releases ENGINEER from any damage or liability related to the presence of such materials. (2) The release required above shall not apply in the event the discharge, release or escape of hazardous substances, contaminants, or asbestos is a result of ENGINEER's negligence or if ENGINEER brings such hazardous substance, contaminant or asbestos onto the project. G. Contractor Indemnification and Claims The CITY agrees to include in all construction contracts the provisions of Article IV E regarding the ENGINEER's Personnel at Construction Site, and provisions providing contractor indemnification of the CITY and the ENGINEER for contractor's negligence. H. Contractor Claims and Third -Party Beneficiaries (1) The CITY agrees to include the following clause in all contracts with construction contractors and equipment or materials suppliers: "Contractors, subcontractors and equipment and materials suppliers on the PROJECT, or their sureties, shall maintain City of Fort Worth, Texas Standard Agreement for Engineering Related Design Services PMO Official Release Date: 1/28/2013 Page 11 of 16 no direct action against the ENGINEER, its officers, employees, and subcontractors, for any claim arising out of, in connection with, or resulting from the engineering services performed. Only the CITY will be the beneficiary of any undertaking by the ENGINEER " (2) This AGREEMENT gives no rights or benefits to anyone other than the CITY and the ENGINEER and there are no third -party beneficiaries. (3) The CITY will include in each agreement it enters into with any other entity or person regarding the PROJECT a provision that such entity or person shall have no third -party beneficiary rights under this Agreement. (4) Nothing contained in this section V.H. shall be construed as a waiver of any right the CITY has to bring a claim against ENGINEER I. CITY's Insurance (1) The CITY may maintain property insurance on certain pre-existing structures associated with the PROJECT. (2) The CITY will ensure that Builders Risk/Installation insurance is maintained at the replacement cost value of the PROJECT. The CITY may provide ENGINEER a copy of the policy or documentation of such on a certificate of insurance. (3) The CITY will specify that the Builders Risk/Installation insurance shall be comprehensive in coverage appropriate to the PROJECT risks. J. Litigation Assistance The Scope of Services does not include costs of the ENGINEER for required or requested assistance to support, prepare, document, bring, defend, or assist in litigation undertaken or defended by the CITY. In the event CITY requests such services of the ENGINEER this AGREEMENT shall be amended or a separate agreement will be negotiated between the parties. K. Changes The CITY may make or approve changes within the general Scope of Services in this AGREEMENT. If such changes affect the ENGINEER's cost of or time required for performance of the services, an equitable adjustment will be made through an amendment to this AGREEMENT with appropriate CITY approval. City of Fort Worth, Texas Standard Agreement for Engineering Related Design Services PMO Official Release Date: 1/28/2013 Page 12 of 16 Article VI General Legal Provisions Amendments to Article VI, if any, are included in Attachment C. A. Authorization to Proceed ENGINEER shall be authorized to proceed with this AGREEMENT upon receipt of a written Notice to Proceed from the CITY. B Reuse of Project Documents All designs, drawings, specifications documents, and other work products of the ENGINEER, whether in hard copy or in electronic form, are instruments of service for this PROJECT whether the PROJECT is completed or not. Reuse, change, or alteration by the CITY or by others acting through or on behalf of the CITY of any such instruments of service without the written permission of the ENGINEER will be at the CITY's sole risk. The CITY shall own the final designs, drawings, specifications and documents. C. Force Majeure The ENGINEER is not responsible for damages or delay in performance caused by acts of God, strikes, lockouts, accidents, or other events beyond the control of the ENGINEER that prevent ENGINEER's performance of its obligations hereunder. D Termination (1) This AGREEMENT may be terminated only by the City for convenience on 30 days' written notice. This AGREEMENT may be terminated by either the CITY or the ENGINEER for cause if either party fails substantially to perform through no fault of the other and does not commence correction of such nonperformance with in 5 days of written notice and diligently complete the correction thereafter. (2) If this AGREEMENT is terminated for the convenience of the City, the ENGINEER will be paid for termination expenses as follows: a.) Cost of reproduction of partial or complete studies, plans, specifications or other forms of ENGINEER'S work product; City of Fort Worth, Texas Standard Agreement for Engineering Related Design Services PMO Official Release Date: 1/28/2013 Page 13 of 16 b.) Out-of-pocket expenses for purchasing electronic data files and other data storage supplies or services; c.) The time requirements for the ENGINEER'S personnel to document the work underway at the time of the CITY'S termination for convenience so that the work effort is suitable for long time storage. (3) Prior to proceeding with termination services, the ENGINEER will submit to the CITY an itemized statement of all termination expenses. The CITY'S approval will be obtained in writing prior to proceeding with termination services. E. Suspension, Delay, or Interruption to Work The CITY may suspend delay, or interrupt the services of the ENGINEER for the convenience of the CITY. In the event of such suspension, delay, or interruption, an equitable adjustment in the PROJECT's schedule, commitment and cost of the ENGINEER's personnel and subcontractors, and ENGINEER's compensation will be made. F. Indemnification In accordance with Texas Local Government Code Section 271.904, the ENGINEER shall indemnify, hold harmless, and defend the CITY against liability for any damage caused by or resulting from an act of n egligence, intentional tort, intellectual property infringement, or failure to pay a subcontractor or supplier committed by the ENGINEER o r ENGINEER's agent, consultant under contract, or another entity over which the ENGINEER exercises control. G. Assignment Neither party shall assign all or any part of this AGREEMENT without the prior written consent of the other party H. Interpretation Limitations on liability and indemnities in this AGREEMENT are business u nderstandings between the parties and shall apply to all the different theories of recovery, including breach of contract or warranty, tort including n egligence, strict or statutory liability, or any other cause of action, except for willful misconduct or gross negligence for limitations of liability and sole negligence for indemnification. Parties mean the CITY and the ENGINEER, and their officers, employees, agents, and subcontractors. City of Fort Worth, Texas Standard Agreement for Engineering Related Design Services PMO Official Release Date: 1/28/2013 Page 14 of 16 I. Jurisdiction The law of the State of Texas shall govern the validity of this AGREEMENT, its interpretation and performance, and any other claims related to it. The venue for any litigation related to this AGREEMENT shall be Tarrant County, Texas. J. Severability and Survival If any of the provisions contained in this AGREEMENT are held for any reason to be invalid, illegal or unenforceable in any respect, such invalidity, illegality, or unenforceability will not affect any other provision, and this AGREEMENT shall be construed as if such invalid, illegal, or unenforceable provision had never been contained herein Articles V.F., VI B VI D , VI.F., VI.H., and VI.I. shall survive termination of this AGREEMENT for any cause. K. Observe and Comply ENGINEER shall at all times observe and comply with all federal and State laws and regulations and with all City ordinances and regulations which in any way affect this AGREEMENT and the work hereunder, and shall observe and comply with all orders, laws ordinances and regulations which may exist or may be enacted later by governing bodies having jurisdiction or authority for such enactment. No plea of misunderstanding or ignorance thereof shall be considered ENGINEER agrees to defend, indemnify and hold harmless CITY and all of its officers agents and employees from and against all claims or liability arising out of the violation of any such order, law, ordinance, or regulation, whether it be by itself or its employees. Article VII Attachments, Schedules, and Signatures This AGREEMENT, including its attachments and schedules, constitutes the entire AGREEMENT, supersedes all prior written or oral understandings, and may only be changed by a written amendment executed by both parties. The following attachments and schedules are hereby made a part of this AGREEMENT: Attachment A - Scope of Services Attachment B — Compensation Attachment C - Amendments to Standard Agreement for Engineering Services Attachment D - Project Schedule City of Fort Worth, Texas Standard Agreement for Engineering Related Design Services PMO Official Release Date: 1/28/2013 Page 15 of 16 Attachment E - Location Map Executed and effective this the aday o j / r BY: CITY OF FORT WORTH 7i/gageh Q Fernando Costa Assistant City Manager Date: APPROVAL RECOMMENDED: By: _./�-, rez Bill Welstead Director, Aviation Department APPROVED AS TO FORM LEGALITY By: /1/L4CkLiICU 1'vl citip Michelle Kretz Assistant City Attorney ATTEST: Mary J. IS City Secre ry City of Fort Worth, Texas Standard Agreement for Engineering Related Design Services PMO Official Release Date: 1/28/2013 Page 16 of 16 BY: ENGINE R Garver, LLC Frank McI Ilwain P.E. Vice President Date: AND M&C No.: //eA, CrZ(cS14t M&C Date: l I2.9 �1 � OFFICIAL WECARD PITY SKRETARY ;t'i, !'�''�: ATTACHMENT "A" Scope for Engineering Design Related Services for Airport Improvements The scope set forth herein defines the work to be performed by the ENGINEER in completing the project. Both the CITY and ENGINEER have attempted to clearly define the work to be performed and address the needs of the Project. OBJECTIVE This project is for engineering services to design the reconstruction of a portion of the street Texas Way. WORK TO BE PERFORMED Task 1. Plans and Specifications Task 2. Surveying Services TASK 1. Plans and Specifications (100%). ENGINEER will manage the work outlined in this scope to ensure efficient and effective use of ENGINEER's and CITY's time and resources. ENGINEER will manage change, communicate effectively, coordinate internally and externally as needed, and proactively address issues with the CITY's Project Manager and others as necessary to make progress on the work ENGINEER will identify, develop communicate through the defined deliverables, and recommend the design that successfully addresses the design problem, and to obtain the CITY's endorsement of this design. 1.1. Managing the Team • Lead, manage and direct design team activities • Ensure quality control is practiced in performance of the work • Communicate internally among team members • Task and allocate team resources 1.2. Communications and Reporting • Attend a pre -design project kickoff/chartering meeting with CITY staff to confirm and clarify scope, understand CITY objectives, and ensure economical and functional designs that meet CITY requirements • Conduct and document biweekly project update meetings with CITY Project Manager • Conduct review meetings with the CITY at the end of each design phase • Conduct and document biweekly design team meetings • Prepare invoices, in accordance with Attachment B to this Standard Agreement and submit monthly in the format requested by the CITY. • Prepare and submit monthly progress reports in the format provided by the respective CITY Department. City of Fort Worth, Texas Attachment A PMO Release Date: 06.19.2010 Page 1 of 5 • Prepare and submit baseline Project Schedule initially, and Project Schedule updates with a schedule narrative monthly, as required in Attachment D to this Standard Agreement and according to the City of Fort Worth s Schedule Guidance Document. • Complete Monthly M/WBE Report Form and Final Summary Payment Report Form at the end of the project • Coordinate with other agencies and entities as necessary for the design of the proposed infrastructure, and provide and obtain information needed to prepare the design • With respect to coordination with permitting authorities, ENGINEER shall communicate with permitting authorities such that their regulatory requirements are appropriately reflected in the designs ENGINEER shall work with regulatory authorities to obtain approval of the designs and make changes necessary to meet their requirements, as part of the design scope. • Personnel and Vehicle Identification: When conducting site visits to the project location, the ENGINEER or any of its sub -consultants shall carry readily visible information identifying the name of the company and the company representative. 1.3 The Plans and Specifications shall include the following: • Cover and index of sheets including project limits, area location map and beginning and end station limits. • Phasing Plan: Develop a phasing plan utilizing standard traffic reroute configurations posted as "Typicals' on the CITY's Buzzsaw website. The typicals need not be sealed individually, if included in the sealed contract documents. The phasing plan shall be incorporated into the design drawings and are to include road and taxiway and/or lane closures, limited access to adjacent properties, and limited access to pedestrian and bicycle traffic. Landside phasing shall be completed as required per the latest edition of the Texas Manual on Uniform Traffic Control Devices Airside phasing shall be completed as required per the latest edition of FAA AC 150/5370-2. • Proposed phasing of any drainage work that is included in this project documented in both the project schedule and narrative form. • Proposed typical sections which outline the proposed improvements. Typical sections shall include existing and proposed ROW, existing and proposed lane widths and direction arrows, existing and proposed curbs, and retaining walls. • Plan and profile sheets showing existing and proposed horizontal roadway and taxiway alignments, existing and proposed ROW, existing and proposed lane dimensions and lane arrows, existing drainage structures city owned and franchise utilities, and existing roadway vertical alignments (profiles). The plan and profile sheets shall display station and coordinate data for all horizontal alignment P.0 's P.T.'s, P.I 's; station and elevation data of all vertical profile P.C.'s P.T.'s, P.I.'s, low points, and high points; lengths of vertical curves, grades, K values, e, and vertical clearances where required. • A Project Control Sheet, showing all Control Points used or set while gathering data. Generally on a scale of not less than 1:400. The following information shall City of Fort Worth, Texas Attachment A PMO Release Date: 08.27.2010 Page 2 of 5 • • • be indicated for each Control Point: Identified (existing City Monument #8901, PK N ail, 5/8" Iron Rod); X Y and Z Coordinates, in an identified coordinate system, and a referred bearing base Z coordinate on City Datum only; descriptive location (Le. set in the centerline of the inlet in the South curb line of North Side Drive at the East end of radius at the Southeast corner of North Side Drive and N orth Main Street) ENGINEER will delineate the watershed based on contour data and field verification and document existing street, right-of-way and storm drain capacities for the subject site. A drainage area map will be drawn at maximum 1" = 200' scale from available 2-foot contour data with the contours labeled. Data source and year will be provided by the CITY Calculations regarding street and right-of- way capacities and design discharges (5-year and 100-year frequencies) at selected critical locations will be provided. Capacities of existing storm drain will be calculated and shown. All calculations shall conform to CITY criteria delineated in the CITY's Storm Water Management Design Manual. All locations in the project area where 100-year runoff exceeds available storm drain and right-of-way capacities shall be clearly identified. The ENGINEER's responsibility includes recommendations for improvements of the existing system as deemed reasonable and consistent with CITY standards. Storm drain layout sheets showing location and size of all inlets, manholes, junction boxes culverts and piping to include storm drain profiles showing existing and proposed flow lines, flows lengths and slopes of pipe, top of ground profile over pipe and connections to existing or proposed storm sewer systems Documentation of key design decisions. • Construction plans (100%) and specifications shall be submitted to CITY per the approved Project Schedule. • The ENGINEER shall submit Construction Plans (100%) to the CITY per the approved Project Schedule Each plan sheet shall be stamped, dated, and signed by the ENGINEER registered in State of Texas. • The ENGINEER shall submit a final design estimate of probable construction cost with the 100% design package. This estimate shall use standard CITY and FAA bid items. 1.4. Utility Clearance • The ENGINEER will consult with the CITY's Transportation and Public Works Department Water Department, and other CITY departments public utilities, private utilities, private utilities and government agencies to determine the approximate location of above and underground utilities, and other facilities (current and future) that have an impact or influence on the project ENGINEER will design CITY facilities to avoid or minimize conflicts with existing utilities, and where known and possible consider potential future utilities in designs. • The ENGINEER shall upload individual DWF files for each plan sheet of the approved preliminary plan set to the designated project folder in Buzzsaw for forwarding to all utility companies which have facilities within the limits of the project. The DWF files should be created directly from the CAD files as opposed to PDF files. City of Fort Worth, Texas Attachment A PMO Release Date: 08.27.2010 Page 3 of 5 DELIVERABLES A. Meeting summaries with action items B. Monthly invoices C. Monthly progress reports D. Baseline design schedule E Monthly schedule updates with schedule narrative describing any current or anticipated schedule changes F. Monthly M/WBE Report Form and Final Summary Payment Report Form ASSUMPTIONS • Two (2) sets of Half size drawings and One(1) specification will be delivered for the 100% Design package. • A DWF file for the 100% Design will be created from design CAD drawings and will be uploaded to the project folder in Buzzsaw. TASK 2. SURVEY SERVICES ENGINEER will provide survey support as follows. 2.1. Design Survey • • ENGINEER will perform field surveys to collect horizontal and vertical elevations and other information needed by ENGINEER in design and preparation of plans for the project Information gathered during the survey shall include topographic data, elevations of all sanitary and adjacent storm sewers, rim/invert elevations, location of buried utilities, structures, trees (measure caliper, identify overall canopy and have qualified arborist identify species of trees), and other features relevant to the final plan sheets. Existing drainage at intersections will be verified by field surveys Spot elevations will be shown on intersection layouts with cross slope to fit intersecting grade lines. The minimum survey information to be provided on the plans shall include the following: A Project Control Sheet showing ALL Control Points, used or set while gathering data Generally on a scale of not less than 1:400 The following information about each Control Point, a. Identified (Existing. CITY Monument #8901, PK Nail, 5/8" Iron Rod) b. X, Y and Z Coordinates, in an identified coordinate system, and a referred bearing base. Z coordinate on CITY Datum only. c. Descriptive Location (Ex. Set in the centerline of the inlet in the South curb line of North Side Drive at the East end of radius at the Southeast corner of North Side Drive and North Main Street). IIIMNIMIIIIIM City of Fort Worth, Texas Attachment A PMO Release Date: 08.27.2010 Page 4 of 5 Coordinates on all P.0 's, P.T.'s, P.I.'s, Manholes, Valves, etc., in the same coordinate system, as the Control. No less than two horizontal bench marks, per line or location. Bearings given on all proposed centerlines, or baselines. Station equations relating utilities to paving, when appropriate. 2.2. Temporary Right of Entry Preparation and Submittal • Prior to entering property, the ENGINEER shall prepare, mail and obtain Temporary Right of Entry from landowners. • The documentation shall be provided in conformance with the checklists and templates available on the CITY's Buzzsaw site DELIVERABLES A. Copies of field survey data and notes signed and sealed by a licensed surveyor. B. Drawing of the project layout with dimensions and coordinate list. Additional Services not included in the existing Scope of Services — CITY and ENGINEER agree that the following services are beyond the Scope of Services described in the tasks above. However, ENGINEER can provide these services if needed, upon the CITY's written request Any additional amounts paid to the ENGINEER as a result of any material change to the Scope of the Project shall be agreed upon in writing by both parties before the services are performed. These additional services include the following: • Negotiation of easements or property acquisition. • Services related to development of the CITY's project financing and/or budget. • Services related to disputes over pre -qualification, bid protests, bid rejection and re -bidding of the contract for construction. • Construction management and inspection services • Performance of materials testing or specialty testing services. • Services necessary due to the default of the Contractor • Services related to damages caused by fire, flood, earthquake or other acts of God. • Services related to warranty claims, enforcement and inspection after final completion. • Services to support, prepare, document, bring, defend, or assist in litigation undertaken or defended by the CITY. • Performance of miscellaneous and supplemental services related to the project as requested by the CITY. City of Fort Worth, Texas Attachment A PMO Release Date: 08.27.2010 Page 5 of 5 Task No. Task Description 1.0 Plans and Specifications 1.1 Managing the Team 1.1.1 Team Management 1 1 2 QA/QC 1.2 Communications and Reporting 1 2 1 Pre -Design Coordination Meeting 1.2.2 Design Submittal Review Meeting 1.2.3 Team Meetings 1.2.4 Prepare Baseline Schedule 1 2 5 Prepare Monthly MWBE Reports 1.2.6 Coordination with City and Agencies 1.3 Plans 1.3.1 General Notes 1.3.2 Safety Plan 1.3.3 Traffic Control Plan 1.3.4 Traffic Control Details 1.3.5 Demolition and Removal Plan 1.3.6 Paving Plan 1.3.7 Joint Plan 1.3.8 Joint Details 1.3.9 Typical Section 1.3.10 Miscellaneous Details 1.4 Specifications/ Contract Documents 1.5 Quantities 1.6 Opinion of Probable Construction Costs 2.0 'Survey Services 2.1 IMWBE Subconsultant - Design Survey City of Fort Worth, Texas Attachment B - Level of Effort Supplement PMO Official Release Date: 5.19 2010 Project Project Director Engineer Rate $244 $111 5 25 Totals' 1 1 1 1 1 01 s1 2 4 4 4 1 1 1 6 1 1 of 1 Level of Effort Spreadsheet TASK/HOUR BREAKDOWN Design Services for Texas Way Reconstruction City Project No. Labor(hours) EIT CADD Administrative RPR Total Labor Subconsultant Cost $51 $78 MWBE Non-MWBE $9,849 $97 $103 20 38 2 1 1 1 4 1 4 2 4 0 1 4 2 2 4 3 4 4 4 2 2 2 4 of 0 0 $466 $882 $444 $444 $555 $111 $111 $1,322 $303 $303 $1,044 $309 $412 $523 $412 $206 $206 01 01 251 20 381 01 0 I $303 $499 $606 $388 $01 $ol 9,849 1 $ Expense Travel $0 $0 $300 $2.000 $2.000 2„000 1 $ $100 $100 $100 se Reproduction $251 $251 Total Expense Task Sub Total Cost MINIM $551 $0 $0 $0 $0 $100 $100 $0 $0 $0 $100 $251 $0 $0 $0 $0 $0 $0 $0 $0 $0 $0 $0 $0 $0 $01 $01 $01 $2,000I I 1 1 $2,000I - I $ 300 ) $ 251 $ 2,551 1 $ Project Summary Total Hours Total Labor Total Expense MWBE Subconsultant Non-MWBE Subconsultant 10% Sub Markup MWBE Participation Total Project Cost $10,400 $0 $466 $882 $0 $544 $544 $555 $111 $111 $1,422 $251 $303 $303 $1,044 $309 $412 $523 $412 $206 $206 $303 $499 $606 $388 $2,000 $2,000 12,400 88 $9,849 $2,551 $2,000 $0 $200 15.9% $12,600 1 of 1 ATTACHMENT "C" CHANGES AND AMENDMENTS TO STANDARD AGREEMENT Design Services for Texas Way Reconstruction City Project No. <List any changes to the Standard Agreement> City of Fort Worth, Texas Attachment C PMO Release Date: 05.19.2010 Page 1 of l Consulting Contract Schedule Specifications City of Fort Worth Capital Improvement Program FORT WORTH, Attachment D - Project Schedule This PROTECT reauires a Tier 2 schedule as defined herein and in the Citiy's Schedule Guidance Document. D1. CONSULTING SERVICES SCHEDULE DEVELOPMENT: The CONSULTANT shall prepare schedules for consulting services that meet the requirements described in this specification, showing by Critical Path Method (CPM) the planned sequence and timing of the Work associated with the Agreement. All submittals shall be submitted in PDF format, and schedule files shall also be submitted in native file format (i.e. file formats associated with the scheduling software). The approved schedulmg software systems for creating the schedule files are: Primavera (Version 6.1 or later or approved by CITY) - Primavera Contractor (Version 6.1 or later or approved by CITY) D2. BASELINE CONSULTING SERVICES SCHEDULE: Following notice -to -proceed the CONSULTANT shall develop, submit and review the draft detailed baseline consulting services schedule with the CITY to demonstrate the CONSULTANT s understanding of the Agreement requirements and approach for performing the work. The CONSULTANT will prepare the final detailed baseline consulting services schedule based on CITY comments, if any, and submit to the CITY no later than the submittal of the first project invoice. The following guidelines shall be adhered to in preparing the baseline schedule, and as described in further detail in the CITY's Schedule Guidance Document. a. The scope shall be subdivided by work breakdown structure (WBS) representing the tasks, subtasks, and activities associated with delivering the work. b. The schedule shall accurately describe the major work activities, key milestones, and dependencies/relationships as appropriate to the work. c. The schedule should include appropriate meetings, review periods, critical decision points, including third party utility dependencies and reviewing agencies. D3. PROGRESS CONSULTING SERVICES SCHEDULE: The CONSULTANT shall prepare and submit monthly to the CITY for approval the updated schedule in accordance with D1 and D2 and the CITY's Schedule Guidance Document inclusive. As the Work progresses, the CONSULTANT shall enter into the schedule and record actual progress as described in the CITY's Schedule Guidance Document. The updated schedule submittal shall also include a concise schedule narrative that highlights the following, if appropriate and applicable: • Changes in the critical path, • Expected schedule changes, • Potential delays, • Opportunities to expedite the schedule, • Coordination issues the CITY should be aware of or can assist with, City of Fort Worth, Texas Attachment D PMO Release Date: 02.15.2011 Page 1 of 2 • Other schedule -related issues that the CONSULTANT wishes to communicate to the CITY. D4. PERFORMANCE AND CONSULTING SERVICES SCHEDULE: If the work accomplished falls behind that scheduled due to factors within the CONSULTANT's control, the CONSULTANT shall take such action as necessary to improve the progress of the Work In addition, the CITY may require the CONSULTANT to submit a revised schedule demonstrating the proposed plan to make up the delay in schedule progress and to ensure completion of the Work within the allotted Agreement time. D5. SCHEDULE TIERS SPECIAL INSTRUCTIONS: The requirements for the schedule are determined based on the nature and needs of the project. The schedule tier for this project is stated at the top of this document. CONSULTANT shall submit each schedule relying on the CITY's current Schedule Guidance Document. D6. SCHEDULE SUBMITTAL AND PAYMENT: As stated in III.A.(1). of the Agreement, CONSULTANT shall provide the information required by Attachment D. CONSULTANT's monthly invoices will not be accepted and processed for payment without monthly schedule updates that are submitted in the time and manner required by Attachment D and the CITY's current Schedule Guidance Document. City of Fort Worth, Texas Attachment D PMO Release Date: 02.15.2011 Page 2 of 2 ID 0 1 Task Name TW Texas Way Improvements 2 3 Notice to Proceed Duration 164 days? Start Mon 12/9/13. Research and Data Collection / Site Visits Pre -Development Meeting 0 days 5 days Mon 12/9/13 Mon 12/9/13 1 day? 5 .... :a:. 6 7 Preliminary Design Topographic Survey 30 days 20 days Mon 12/9/13 Mon 12/9/13 Meacham International Airport Texas Way Reconstruction Attachment D Finish 1 November 2013 I December 2013 Oanuary 2014 f February 2014 1 Ma ch 2014 Thu 7/24/14 Mon 12/9/13 Fri 12/13/13 Mon 12/9/13 Mon 12/9/13 Fri 1/17/14 Fri 1/3/14 9 TxDOT/City of Fort Worth Review Final Design TxDOT/City of Fort Worth Review 10 Bidding Documents 20 daysf Mon 1/20/14 15 days Mon 2/17/14 20 days Mon 3/10/14 Fri 2/14/14 Fri 3/7/14 Fri 4/4/14 10 days Mon 4/7/14 11 12 Preparation for Advertisement Advertisement Fri 4/18/14 23 days! Mon 4/21/14 23 days Thu 5/22/14 Wed 5/21/14 Mon 6/23/14 13 Bid Opening and Construction Contract Execution Project: FTW Texas Way Improvemen Date: Mon 11/18/13 Task Split 11111111111111111111111111111111 23 days Progress Milestone Tue 6/24/14 • • Thu 7/24/14 Summary Project Summary • • • p 12/9 a• External Tasks External Milestone Meacham International Airport Texas Way Reconstruction Page 1 i Deadline I April 2014 i Ma 2014 182124273012 1518 11141172023262912 [518 111141720232629 4 June 2014 1 14 17 1013116119222528 July 2014 IA 1 14 17 1013'1619222528311 File: L:\2011\11081210 — FTW On—Call\Drawings\PROJECTS\Texas Way\FTW_TEXAS WAY ATT—E.dwg Lost Sove: 8/14/2013 2:54 PM I nst snve by: Bcbeville Last plotted by: Beville, Brandon C. Plot Style: Garver Standard Half.ctb Plot Scale: 1:2 Plot Dote: 9/5/2013 8:49 AM Plotter used: \\gfyvdc02 Canon iR C4080 PS \ m \ \ \ 20811f1N 133HS m m \ \ L \ \ \ \ \ \ \ 0 CD z C C) w \ 808 :A8 43NoIS30 £LOZ '833 aLVCI 0121.901. L :'ON 90f \ \ \ \ i i \ \ \ \ \ i \ \ 39n \\ \ \ \\ \ _ \\ a \ \ \ \ \ \ 1 \ \ \ \ \ \ \ \ \ \ \ \ \ \ \ \ \ \ m MEACHAM INTERNATIONAL AIRPORT O FORT WORTH, TX m• 2 -< °D.71 ON CALL ORT WORT AVIATION \ i \ REV. DATE DESCRIPTION 30n BY / / / / / / / / / / 30n 30n zn SS 30n CJ SS r7 Son / / / / / 7 7 0 30r cn v City of Fort Worth, Texas Mayor and Council Communication COUNCIL ACTION: Approved on 10/29/2013 - Ordinance No. 21017-10-2013 DATE: Tuesday, October 29, 2013 REFERENCE NO.: **C-26541 LOG NAME* 55FTW TEXAS WAY PAVEMENT IMPROVEMENTS (02188) SUBJECT: Authorize Use of Revenue Derived from Mineral Leases on City -Owned Airports in the Amount Up to $80,000.00 for the Design and Construction of Texas Way Pavement Improvements at Fort Worth Meacham International Airport, Authorize Engineering Agreement with Garver LLC, in the Amount of $22,600.00 and Adopt Appropriation Ordinance (COUNCIL DISTRICT 2) RECOMMENDATION: It is recommended that the City Council: 1. Authorize the use of revenue derived from mineral leases on City -owned airports in the amount up to $80,000.00 for the design and construction of Texas Way pavement improvements at Fort Worth Meacham International Airport; 2. Adopt the attached appropriation ordinance increasing estimated receipts and appropriations of the Airports Gas Lease Project Fund in the amount of $80,000.00; and 3. Authorize the execution of an Engineering Agreement with Garver, LLC, in the amount of $22,600.00 for the design phase services of Texas Way Pavement Improvements project at Fort Worth Meacham International Airport. DISCUSSION: The City of Fort Worth Meacham International Airport (Meacham Airport) requires professional services for engineering projects on an as needed basis. In January 2010, the Aviation Department selected Garver, LLC (Garver), from among six qualified respondents to a Request for Qualifications for the purpose of providing engineering services for Meacham Airport. Garver has been asked to design improvements to Texas Way which is the primary entrance from North Main Street for numerous businesses at Meacham Airport. According to the Pavement Condition Index (PCI) reporting scale, the current condition of Texas Way is classified as very poor and is noticeably degrading. This portion of Texas Way was constructed of asphalt more than 30 years ago. In the last few years, the number of monthly maintenance requests for this portion of asphalt has significantly increased. In order to reduce the frequency of maintenance and to match the existing North Main Street connectors, the improvements to Texas Way will be constructed of concrete. Construction costs of the improvements are expected to be within the remainder of the transferred funds. This project will be funded by revenue derived from mineral leases on City -owned airport properties. Logname. 55FTW TEXAS WAY PAVEMENT IMPROVEMENTS (02188) Page 1 of 2