Loading...
HomeMy WebLinkAboutContract 36316 l CITY OF FORT WORTH, TEXAS STANDARD AGREEMENT FOR ENGINEERING SERVICES This AGREEMENT is between the City of Fort Worth the "CITY"), and DMJM Aviation, inc., (the "'ENGINEER"), for a PROJECT generally described as: Consulting . y 9 Services with DMJM Aviation, Inc. for Fort Worth Alliance Article I Scope of Services A. The Scope of Services is set forth in Attachment A. Article 11 Compensation A. The ENGINEER's compensation is set forth in Attachment B. Article III Terms of Payment Payments to the ENGINEER will be made as follows: A. Invoice and Payment (1) The Engineer shall provide the City sufficient documentation to reasonably substantiate the invoices. (2) The ENGINEER will issue monthly invoices for all work performed under this AGREEMENT. Invoices are due and payable within 30 days of receipt. (3) Upon completion of services enumerated in Article I, the final payment of any balance will be due within 30 days of receipt of the final invoice. (4) In the event of a disputed or contested billing, only that portion so contested will be withheld from payment, and the undisputed portion will be paid. The CITY will exercise reasonableness in contesting any bill or portion thereof. No interest will accrue on any contested portion of the billing until mutually resolved. (5) If the CITY fails to make payment in full to ENGINEER for billings contested in good faith within 60 days of the amount due, the ENGINEER nay, after giving 7 days' written notice to CITY, suspend services under this AGREEMENT until paid in full, including interest. In the event of suspension of services, the ENGINEER shall have no liability to CITY for delays or damages caused the CITY because of such suspension of services. STANDARD ENGINEERING AGREEMENT REV 10/06/05 Page I of 18 ORIGINAL 5 C Flo tM� k V.Hf ErUQ Article IV Obligations of the Engineer Amendments to Article IV, if any, are included in Attachment C. A. General The ENGINEER will serve as the CITY's professional engineering representative under this Agreement, providing professional engineering consultation and advice and furnishing customary services incidental thereto. B. Standard of Care The standard of care applicable to the ENGINEER's services will be the degree of skill and diligence normally employed in the State of Texas by professional engineers or consultants performing the same or similar services at the time such services are performed. C. Subsurface Investigations (1) The ENGINEER shall advise the CITY with regard to the necessity for subcontract work such as special surveys, tests, test borings, or other subsurface investigations in connection with design and engineering work to be performed hereunder. The ENGINEER shall also advise the CITY concerning the results of same. Such surveys, tests, and investigations shall be furnished by the CITY, unless otherwise specified in Attachment A. (2) In soils, foundation, groundwater, and other subsurface investigations, the actual characteristics may vary significantly between successive test points and sample intervals and at locations other 'than where observations, exploration, and investigations have been made. Because of the inherent uncertainties in subsurface evaluations, changed or unanticipated underground conditions may occur that could affect the total PROTECT cost and/or execution. These conditions and cost/execution effects are not the responsibility of the ENGINEER. D. Preparation of Engineering Drawings The ENGINEER will provide to the CITY the original drawings of all plans in ink on reproducible plastic film sheets, or as otherwise approved by CITY, which shall become the property of the CITY. CITY may use such drawings in any manner it desires; provided, however, that the ENGINEER shall not be liable for the use of such drawings for any project other than the PROJECT described herein. STANDARD ENGINEERING AGREEMENT(REV 10/06/05) Page 2 of 18 E. Engineer's Personnel at Construction Site (1) The presence or duties of the ENGINEER's personnel at a construction site whether as on-site representatives or otherwise, do not make the ENGINEER or its personnel in any way responsible for those duties that belong to the CITY and/or the CITY's construction contractors or other entities, and do not relieve the construction contractors or any other entity of their obligations, duties, and responsibilities, including, but not limited to, all construction methods, means, techniques, sequences, and procedures necessary for coordinating and completing all portions of the construction work in accordance with the Contract Documents and any health or safety precautions required by such construction work. The ENGINEER and its personnel have no authority to exercise any control over any construction contractor or other entity or their employees in connection with their work or any health or safety precautions. (2) Except to the extent of specific site visits expressly detailed and set forth in Attachment A, the ENGINEER or its personnel shall have no obligation or responsibility to visit the construction site to become familiar with the progress or quality of the completed work on the PROJECT or to determine, in general, if the work on -the PROJECT is being performed in a manner indicating that the PROJECT, when completed, will be in accordance with the Contract Documents, nor shall anything in the Contract Documents or the agreement between CITY and ENGINEER be construed as requiring ENGINEER to make exhaustive or continuous on-site inspections to discover latent defects in the work or otherwise check the quality or quantity of the work on the PROJECT. If, for any reason, the ENGINEER should make an on-site observation(s), on the basis of such on-site observations, if any, the ENGINEER shall endeavor to keep the CITY informed of any deviation from the Contract Documents coming to the actual notice of ENGINEER regarding the PROJECT. (3) When professional certification of performance or characteristics of materials, systems or equipment is reasonably required to perform the services set forth in the Scope of Services, the ENGINEER shall be entitled to rely upon such certification to establish materials, systems or equipment and performance criteria to be required in the Contract Documents. F. Opinions of Probable Cost, Financial Considerations, and Schedules (1) The ENGINEER shall provide opinions of probable costs based on the current available information at the time of preparation, in accordance with Attachment A. (2) In providing opinions of cost, financial analyses, economic feasibility projections, and schedules for the PROJECT, the ENGINEER has no control over cost or price of labor and materials; unknown or latent conditions of existing equipment or structures that may affect operation or maintenance costs; competitive bidding procedures and market STANDARD ENGINEERING AGREEMENT(REV 10106105) Page 3 of 18 conditions; time or quality of performance by third parties; ualit , type, q Y Yp , management, or direction of operating personnel; and other economic and operational factors that may materially affect the ultimate PROJECT cost or schedule. Therefore, the ENGINEER makes no warranty that the CITYs actual PROJECT costs, financial aspects, economic feasibility, or schedules will not vary from the ENGINEER's opinions, analyses, . Y projections, or estimates. G. Construction Progress Payments Recommendations by the ENGINEER to the CITY for periodic construction progress payments to the construction contractor will be based on the ENGINEER's knowledge, information, and belief from selective sampling and observation that the work has progressed to the point indicated. Such recommendations do not represent that continuous or detailed examinations have been made by the ENGINEER to ascertain that -the construction contractor has completed the work in exact accordance with the Contract Documents; that the final work will be acceptable in all respects; that the ENGINEER has made an examination to ascertain how or for what purpose the construction contractor has used the moneys paid; that title to any of the work, materials, or equipment has passed to the CITY free and clear of liens, claims, security interests, or encumbrances; or that there are not other matters at issue between 'the CITY and the construction contractor that affect the amount that should be paid. H. Record Drawings Record drawings, if required, will be prepared, in part, on the basis of information compiled and furnished by others, and may not always represent the exact location, type of various components, or exact manner in which the PROJECT was finally constructed. The ENGINEER is not responsible for any errors or omissions in the information from others that is incorporated into the record drawings. I. Minority and Woman Business Enterprise (MIWBE) Participation In accord with City of Fort Worth Ordinance No. 15530, the City has goals for the participation of minority business enterprises and woman business enterprises in City contracts. Engineer acknowledges the M/WBE goal established for this contract and its commitment to meet that goal. Any misrepresentation of facts (other than a negligent misrepresentation) and/or the commission of fraud by the Engineer may result in the termination of this agreement and debarment from participating in City contracts for a period of time of not less than three (3) years. J. Right to Audit (1) ENGINEER agrees that the CITY shall, until the expiration of three (3) years STANDARD ENGINEERING AGREEMENT(REV 10106105) Page 4 of 18 after final payment under this contract, have access to and the right to examine and photocopy any directly pertinent books, documents, papers and records of the ENGINEER involving transactions relating to this contract. ENGINEER agrees that the CITY shall have access during normal working hours to all necessary ENGINEER facilities and shall be provided adequate and appropriate work space in order to conduct audits in compliance with the provisions of this section. The CITY shall give ENGINEER reasonable advance notice of intended audits. (2) ENGINEER further agrees to include in all its subconsultant agreements hereunder a provision to the effect that the subconsultant agrees that the CITY shall, until the expiration of three (3) years after final payment under the subcontract, have access to and the right to examine and photocopy any directly pertinent books, documents, papers and records of such subconsultant, involving transactions to the subcontract, and further, that the CITY shall have access during normal working hours to all subconsultant facilities, and shall be provided adequate and appropriate work space, in order to conduct audits in compliance with the provisions of this article together with subsection (3)hereof. CITY shall give subcon-sultant reasonable advance notice of intended audits. (3) ENGINEER and subconsultant agree to photocopy such documents as may be requested by the CITY. The CITY agrees to reimburse ENGINEER for the cost of copies at the rate published in the Texas Administrative Code in effect as of the time copying is performed. K. ENGINEER's Insurance (1) Insurance coverage and limits: ENGINEER shall provide to the City certificate(s) of insurance documenting policies of the following coverage at minimum limits that are to be in effect prior to commencement of work on the PROJECT: Commercial General Liability $1,000,000 each occurrence $2,000,000 aggregate Automobile Liability $1,000,000 each accident on a combined single limit or $250,000 Property Damage $500,000 Bodily Injury per person per occurrence A commercial business policy shall provide coverage on "Any Auto", defined as autos owned, hired and non-owned when said vehicle is used in the STANDARD ENGINEERING AGREEMENT(REV 10/06105) Page 5 of 18 course of the PROJECT. Worker's Compensation Coverage A: Statutory limits Coverage B: Employer's Liability $100,000 each accident $500,000 disease - policy limit $100,000 disease - each employee Professional Liability $1,000,000 each claim $2,000,000 aggregate Professional liability shall be written on a claims-made basis and shall contain a retroactive date prior to the date of the contract or the first date of services to be performed, whichever is earlier. Coverage shall be maintained for a period of 5 years following the completion of the contract. An annual certificate of insurance specifically referencing 'this project shall be submitted to the City for each year following completion of the contract. (2) Certificates of insurance evidencing that the ENGINEER has obtained all required insurance shall be delivered to the CITY prior to ENGINEER proceeding with the PROJECT. (a) Applicable policies shall be endorsed to name the CITY an Additional Insured thereon, as its interests may appear. The term CITY shall include its employees, officers, officials, agents, and volunteers as respects the contracted services. (b) Certificate(s) of insurance shall document that insurance coverage specified in this agreement are provided under applicable policies documented thereon. (c) Any failure on part of the CITY to request required insurance documentation shall not constitute a waiver of the insurance requirements. (d) A minimum of forty-five (45) days notice of cancellation or material change in coverage shall be provided to the CITY. A ten (10) days notice shall be acceptable in the event of non-payment of premium. Such terms shall be endorsed onto ENGINEER's insurance policies. Notice shall be sent to the respective Department Director (by name), City of Fort Worth, 1 000 Throckmorton, Fort Worth, Texas 76102. (e) Insurers for all policies must be authorized to do business in the State of STANDARD ENGINEERING AGREEMENT(REV 10106105) Page 6of18 Texas and have a minimum rating of A: VII in the current A.M. Best Key Rating Guide or have reasonably equivalent financial strength and solvency to the satisfaction of Risk Management. (f) Deductible limits, or self insured retentions, affecting insurance required herein shall be acceptable to the CITY in its sole discretion; and, in lieu of traditional insurance, any alternative coverage maintained through insurance pools or risk retention groups must be also approved. Dedicated financial resources or letters of credit may also be acceptable to -the City. (g) Applicable policies shall each be endorsed with a waiver of subrogation in favor of-the CITY as respects the PROJECT. (h) The City shall be entitled, upon its request and without incurring expense, to review the ENGINEER's insurance policies including endorsements thereto and, at the CITY's discretion, the ENGINEER may be required to provide proof of insurance premium payments. (i) The Commercial General Liability insurance policy shall have no exclusions by endorsements unless the CITY approves such exclusions in writing. (j} For all lines of coverage underwritten on a claims-made basis, other than Professional Liability, the retroactive date shall be coincident with or prior to the date of the contractual agreement. The certificate of insurance shall state both the retroactive date and that 'the coverage is claims- made. (k) The CITY shall not be responsible for the direct payment of any insurance premiums required by this agreement and all insurance required in this section, with the exception of Professional Liability, shall be written on an occurrence basis. (1) Sub consultants and subcontractors to/of -the ENGINEER shall be required by the ENGINEER to maintain the same or reasonably equivalent insurance coverage as required for the ENGINEER. When sub consultants/subcontractors maintain insurance coverage, ENGINEER shall provide CITY with documentation thereof on a certificate of insurance. L. Independent Consultant The ENGINEER agrees to perform all services as an independent consultant and not as a subcontractor, agent, or employee of the CITY. STANDARD ENGINEERING AGREEMENT(REV 10/06/05) Page 7 of 18 M. Disclosure The ENGINEER acknowledges to the CITY that it has made full disclosure in writing of any existing conflicts of interest or potential conflicts of interest, including personal financial interest, direct or indirect, in property abutting the proposed PROJECT and business relationships with abutting property cities. The ENGINEER further acknowledges that it will make disclosure in writing of any conflicts of interest that develop subsequent to the signing of this contract and prior to final payment under the contract. N. Asbestos or Hazardous Substances (1) If asbestos or hazardous substances in any form are encountered or suspected, the ENGINEER will stop its own work in the affected portions of the PROJECT to permit testing and evaluation. (2) If asbestos or other hazardous substances are suspected, the ENGINEER Willi if requested, assist -the CITY in obtaining the services of a qualified subcontractor to manage the remediation activities of the PROJECT. o. Permitting Authorities - Design Changes If permitting authorities require design changes so as to comply with published design criteria and/or current engineering practice standards which the ENGINEER should have been aware of at the time this Agreement was executed, the ENGINEER shall revise plans and specifications, as required, at its own cost and expense. However, if design changes are required due to the changes in the permitting authorities' published design criteria and/or practice standards criteria which are published after the date of this Agreement which the ENGINEER could not have been reasonably aware of, the ENGINEER shall notify the CITY of such changes and an adjustment in compensation will be made through an amendment to this AGREEMENT. Article V Obligations of the City Amendments to Article V, if any, are included in Attachment C. A. City-Furnished Data ENGINEER may rely upon the accuracy, timeliness, and completeness of the information provided by the CITY. B. Access to Facilities and Property The CITY will make its facilities accessible to -the ENGINEER as required for the ENGINEER's performance of its services and will provide labor and safety STANDARD ENGINEERING AGREEMENT(REV 10106105) Page 8 of 18 equipment as required by the ENGINEER for such access. The CITY will perform, at no cost to the ENGINEER, such tests of equipment, machinery, pipelines, and other components of the CITY's facilities as may be required in connection with the ENGINEER's services. The CITY will be responsible for all acts of the CITY's personnel. C. Advertisements, Permits, and Access Unless otherwise agreed to in the Scope of Services, the CITY will obtain, arrange, and pay for all advertisements for bids; permits and licenses required by local, state, or federal authorities; and land, easements, rights-of-way, and access necessary for the ENGINEER's services or PROJECT construction. D. Timely Review The CITY will examine the ENGINEER's studies, reports, sketches, drawings, specifications, proposals, and other documents; obtain advice of an attorney, insurance counselor, accountant, auditor, bond and financial advisors, and other consultants as the CITY deems appropriate; and render in writing decisions required by the CITY in a timely manner in accordance with the project schedule in Attachment A. E. Prompt Notice The CITY will give prompt written notice to the ENGINEER whenever CITY observes or becomes aware of any development that affects the scope or timing of the ENGINEER's services or of any defect in 'the work of the ENGINEER or construction contractors. F. Asbestos or Hazardous Substances Release. (1) CITY acknowledges ENGINEER will perform part of the work at CITY's facilities that may contain hazardous materials, including asbestos containing materials, or conditions, and that ENGINEER had no prior role in the generation, treatment, storage, or disposition of such materials. In consideration of the associated risks that may give rise to claims by third parties or employees of City, City hereby releases ENGINEER from any damage or liability related to the presence of such materials. (2) The release required above shall not apply in the event -the discharge, release or escape of hazardous substances, contaminants, or asbestos is a result of ENGINEER's negligence or if ENGINEER brings such hazardous substance, contaminant or asbestos onto the project. G. Contractor Indemnification and Claims The CITY agrees to include in all construction contracts the provisions of Article W.E. regarding the ENGINEER's Personnel at Construction Site, and STANDARD ENGINEERING AGREEMENT(REV 10106105) Page 9 of 18 provisions providing contractor indemnification of the CITY and 'the ENGINEER for contractor's negligence. H. Contractor Claims and Third-Party Beneficiaries (1) The CITY agrees to include the following clause in all contracts with construction contractors and equipment or materials suppliers: "Contractors, subcontractors and equipment and materials suppliers on the PROJECT, or their sureties, shall maintain no direct action against the ENGINEER, its officers, employees, and subcontractors, for any claim arising out of, in connection with, or resulting from the engineering services performed. Only the CITY will be the beneficiary of any undertaking by the ENGINEER." (2) This AGREEMENT gives no rights or benefits to anyone other than the CITY and the ENGINEER and there are no third-party beneficiaries. (3) The CITY will include in each agreement it enters into with any other entity or person regarding the PROJECT a provision that such entity or person shall have no third-party beneficiary rights under this Agreement. (4) Nothing contained in this section V.H. shall be construed as a waiver of any right the CITY has to bring a claim against ENGINEER. I. CITY's Insurance (1) The CITY may maintain property insurance on certain pre-existing structures associated with the PROJECT. (2) The CITY will ensure that Builders Risk/Installation insurance is maintained at the replacement cost value of the PROJECT. The CITY may provide ENGINEER a copy of the policy or documentation of such on a certificate of insurance. (3) The CITY will specify that the Builders Risk/installation insurance shall be comprehensive in coverage appropriate to the PROJECT risks. J. Litigation Assistance The Scope of Services does not include costs of the ENGINEER for required or requested assistance to support, prepare, document, bring, defend, or assist in litigation undertaken or defended by the CITY. In the event CITY requests such services of the ENGINEER, this AGREEMENT shall be amended or a separate agreement will be negotiated between the parties. STANDARD ENGINEERING AGREEMENT(REV 10/06/05) Page 10 of 18 K. Changes The CITY may make or approve changes within the general Scope of Services in this AGREEMENT. If such changes affect the ENGINEER's cost of or time required for performance of the services, an equitable adjustment will be made through an amendment to this AGREEMENT with appropriate CITY approval. Article VI General Legal Provisions Amendments to Article VI, if any, are included in Attachment C. A. Authorization to Proceed ENGINEER shall be authorized to proceed with this AGREEMENT upon receipt of a written Notice to Proceed From the CITY. B. Reuse of Project Documents All designs, drawings, specifications, documents, and other work products of the ENGINEER, whether in hard copy or in electronic form, are instruments of service for this PROJECT, whether -the PROJECT is completed or not. Reuse, change, or alteration by the CITY or by others acting through or on behalf of the CITY of any such instruments of service without the written permission of the ENGINEER will be at the CITY's sole risk. The CITY shall own the final designs, drawings, specifications and documents. C. Force Majeure The ENGINEER is not responsible for damages or delay in performance caused by acts of God, strikes, lockouts, accidents, or other events beyond the control of the ENGINEER. D. Termination (1) This AGREEMENT may be terminated only by the City for convenience on 30 days' written notice. This AGREEMENT may be terminated by either the CITY or the ENGINEER for cause if either party fails substantially to perform through no fault of the other and does not commence correction of such nonperformance with 5 days of written notice and diligently complete the correction thereafter. (2) If this AGREEMENT is terminated for the convenience of the City, the ENGINEER will be paid for termination expenses as follows: a.) Cost of reproduction of partial or complete studies, plans, specifications or other forms of ENGINEER'S work product; STANDARD ENGINEERING AGREEMENT(REV 10/06/05) Page 11 of 18 b.) Out-of-pocket expenses for purchasing storage containers, microfilm, electronic data files, and other data storage supplies or services; C.) The time requirements for the ENGINEER'S personnel to document the work underway at the time the CITY'S termination for convenience so that-the work effort is suitable for long time storage. (3) Prior to proceeding with termination services, the ENGINEER will submit to the CITY an itemized statement of all termination expenses. The CITY'S approval will be obtained in writing prior to proceeding with termination services. E. Suspension, Delay, or Interruption to Work The CITY may suspend, delay, or interrupt the services of the ENGINEER for the convenience of the CITY. In the event of such suspension, delay, or interruption, an equitable adjustment in -the PROJECT's schedule, commitment and cost of the ENGINEER's personnel and subcontractors, and ENGINEER's compensation will be made. F. Indemnification (1) The ENGINEER agrees to indemnify and defend the CITY from any loss, cost, or expense claimed by third parties for property damage and bodily injury, including death, caused solely by -the negligence or willful misconduct of the ENGINEER, its employees, officers, and subcontractors in connection with the PROJECT. (2) if the negligence or willful misconduct of both the ENGINEER and the CITY (or a person identified above for whom each is liable) is a cause of such damage or injury, -the loss, cost, or expense shall be shared between the ENGINEER and the CITY in proportion to their relative degrees of negligence or willful misconduct as determined pursuant to T.C.P. & R. Code, section 33.011(4) (Vernon Supplement 1996). G. Assignment Neither party shall assign all or any part of this AGREEMENT without the prior written consent of-the other party. H. Interpretation Limitations on liability and indemnities in this AGREEMENT are business understandings between the parties and shall apply to all the different theories of recovery, including breach of contract or warranty, tort including negligence, strict or statutory liability, or any other cause of action, except for willful misconduct or gross negligence for limitations of liability and sole negligence for indemnification. Parties mean the CITY and the ENGINEER, and their STANDARD ENGINEERING AGREEMENT(REV 10106105) Page 12 of 18 officers, employees, agents, and subcontractors. I. Jurisdiction The law of the State of Texas shall govern the validity of this AGREEMENT, its interpretation and performance, and any other claims related to it. The venue for any litigation related to this AGREEMENT shall be Tarrant County, Texas. J. Alternate Dispute Resolution (1) All claims, disputes, and other matters in question between the CITY and ENGINEER arising out of, or in connection with this Agreement or the PROJECT, or any breach of any obligation or duty of CITY or ENGINEER hereunder, will be submitted to mediation. If mediation is unsuccessful, the claim, dispute or other matter in question shall be submitted to arbitration if both parties acting reasonably agree that the amount of the dispute is likely to be less than $50,000, exclusive of attorney's fees, costs and expenses. Arbitration shall be in accordance with the Construction Industry Arbitration Rules of the American Arbitration Association or other applicable rules of the Association then in effect. Any award rendered by the arbitrators less than $50,000, exclusive of attorney's fees, costs and expenses, will be final, judgment may be entered thereon in any court having jurisdiction, and will not be subject to appeal or modification except to the extent permitted by Sections 10 and 11 of the Federal Arbitration Act (9 U.S.C. Sections 10 and 11). (2) Any award greater than $50,000, exclusive of attorney's fees, costs and expenses, may be litigated by either party on a de novo basis. The award shall become final ninety (90) days from the date same is issued. If litigation is filed by either party within said ninety (90) day period, the award shall become null and void and shall not be used by either party for any purpose in the litigation. K. Severability and Survival If any of the provisions contained in this AGREEMENT are held for any reason to be invalid, illegal, or unenforceable in any respect, such invalidity, illegality, or unenforceability will not affect any other provision, and this AGREEMENT shall be construed as if such invalid, illegal, or unenforceable provision had never been contained herein. Articles V.F., VI.B., VI.D., VI.H., VI.I., and VI.J. shall survive termination of this AGREEMENT for any cause. L. Observe and Comply ENGINEER shall at all -times observe and comply with all federal and State laws and regulations and with all City ordinances and regulations which in any way affect this AGREEMENT and the work hereunder, and shall observe and comply with all orders, laws ordinances and regulations which may exist or may be enacted later by governing bodies having jurisdiction or authority for such enactment. No plea of misunderstanding or ignorance thereof shall be STANDARD ENGINEERING AGREEMENT(REV 10106105) Page 13 of 18 considered. ENGINEER agrees to defend, indemnify and hold harmless CITY and all of its officers, agents and employees from and against all claims or liability arising out of the violation of any such order, law, ordinance, or regulation, whether it be by itself or its employees. Article vii Attachments, Schedules, and Signatures This AGREEMENT, including its attachments and schedules, constitutes the entire AGREEMENT, supersedes all prior written or oral understandings, and may only be changed by a written amendment executed by both parties. The following attachments and schedules are hereby made a part of this AGREEMENT: Attachment A - Scope of Services Attachment B — Compensation Attachment C -Amendments to Standard Agreement for Engineering Services Attachment D - Project Schedule Attachment E - Location Map Executed this the Jqhday of , 200J.7 ATTEST: CITY OF FORT WORTH By: M - Marty Hendrib Marc A. Ott -µ-- City Secretary Assistant City Manager APPROVAL RECOMMENDED - �- A. Douglas Rademaker, P.E. Director, Engineering Department APPROV AS TO R ND LEGALITY Assi nt't#Aorn6y DMJ M Aviation, Inc. ENGINEER ATTEST: "'~ By. NAM : erat n P.E. TITLE: Sr. Vice President and CAO STANDARD ENGINEERING AGREEMENT(REV 10/06/05) �^' r-'l Page 14 of 18 CITY w• a f ATTACHMENT"A" General Scope of Services "Scope of Services set forth herein can only be modified by additions, clarifications, and/or deletions set forth in the supplemental Scope of Services. In cases of conflict between the Supplemental Scope of Services and the General Scope of Services, the Supplemental Scope of Services shall have precedence over the General Scope of Services.If GENERAL 1) Preliminary Conference with City The Engineer shall attend preliminary conferences with authorized representatives of the City regarding the scope of project so that the plans and specifications which are to be developed hereunder by the Engineer will result in providing facilities which are economical in design and conform to the City's requirements and budgetary constraints. 2) Coordination with Outside Agencies/Public Entities The Engineer shall coordinate with officials of other outside agencies as may be necessary for the design of the proposed street, and storm drain and/or water and wastewater facili- ties/improvements. it shall be the Engineer's duty hereunder to secure necessary information from such outside agencies, to meet their requirements. 3) Geotechnical Investigations The Engineer shall advise the City of test borings, and other subsurface investigations that may be needed. In the event it is determined necessary to make borings or excavate test holes or pits, the Engineer shall in coordination with -the City and the City's geotechnical engineering consultant, draw up specifications for such testing program. The cost of the borings or excavations shall be paid for by the City. 4) Agreements and Permits The Engineer shall complete all forms/applications to allow the City of Fort Worth to obtain any and all agreements and/or permits normally required for a project of this size and type. The Engineer will be responsible for negotiating and coordinating to obtain approval of the agency issuing the agreement and/or permits and will make any revisions necessary to bring the plans into compliance with the requirements of said agency, including but not limited to highways, railroads, water authorities, Corps of Engineers and other utilities. 5) Design Changes Relating to Permitting Authorities If permitting authorities require design changes, the Engineer shall revise the plans and specifications as required at the Engineers own cost and expense, unless such changes are required due to changes in the design of the facilities made by the permitting authority. If STANDARD ENGINEERING AGREEMENT(REV 10106/05) Page 15 of 18 such changes are required, the Engineer shall notify the City and an amendment to the contract shall be made if the Engineer incurs additional cost. If there are unavoidable delays, a mutually agreeable and reasonable time extension shall be negotiated. 6) Plan Submittal Copies of the original plans shall be provided on reproducible mylar or approved plastic film sheets, or as otherwise approved by the Department of Engineering and shall become the property of the City. City may use such drawings in any manner it desires; provided, however that -the Engineer shall not be liable for the use of such drawings for any project other than the project described herein; and further provided, that the Engineer shall not be liable for the consequences of any changes that are made to the drawings or changes that are made in the implementation of the drawings without the written approval of the Engineer. PHASE 1 7) Right-of-Way, Easement and Land Acquisition Needs The Engineer shall determine the rights-of-way, easement needs for the construction of the project. Engineer shall determine ownership of such land and furnish the City with the necessary right-of-way sketches, prepare necessary easement descriptions for acquiring the rights-of-way and/or easements for -the construction of this project. Sketches and easement descriptions are to be presented in form suitable for direct use by the Department of Engineering in obtaining rights-of-way, easements, permits and licensing agreements. All materials shall be furnished on the appropriate City forms in a minimum of four (4) copies each. 8) Design Survey The Engineer shall provide necessary field survey for use in the preparation of Plans and Specifications. The Engineer shall furnish the City certified copies of the field data. g) Utility Coordination The Engineer shall coordinate with a,ll utilities, including utilities owned by the City, as to any proposed utility liens or adjustment to existing utility lines within the project limits. The information obtained shall be shown on the conceptual plans. The Engineer shall show on the preliminary and final plans the location of the proposed utility lines, existing utility lines, based on the information provided by the utility, and any adjustments and/or relocation of the existing lines within -the project limits. The Engineer shall also evaluate the phasing of the water, wastewater, street and drainage work, and shall submit such evaluation in writing to the City as part of this phase of the project. 10) Conceptual Plans The Engineer shall furnish four (4) copies of the Phase 1 concept engineering plans which include layouts, preliminary right-of-way needs and preliminary estimates of probable construction costs for -the Engineer's recommended plan. For all submittals, the Engineer shall submit plans and documents for street/storm drain and water/wastewater facilities. The Engineer shall receive written approval of the Phase 1 Plans from the City's project manager before proceeding with Phase 2. STANDARD ENGINEERING AGREEMENT(REV 10106105) Page 16 of 18 PHASE 2 11) Design Data The Engineer shall provide design data, reports, cross-sections, profiles, drainage calculations, and preliminary estimates of probable construction cost. 12) Preliminary Construction Plans and Technical Specifications The Engineer shall submit twenty (20) copies of Phase 2 preliminary construction plans and five (5) copies of the preliminary technical specifications for review by the City and for submission to utility companies and other agencies for the purposes of coordinating work with existing and proposed utilities. The preliminary construction plans shall indicate location of existing/proposed utilities and storm drain lines. The Engineer shall receive written approval of the Phase 2 plans from -the City's project manager before proceeding with Phase 3. PHASE 3 13) Final Construction Plans The Engineer shall furnish five (5) copies of the final construction plans and contract specifications for review by the City. 14) Detailed Cost Estimate The Engineer shall furnish four(4) copies of detailed estimates of probable construction costs for the authorized construction project, which shall include summaries of bid items and quantities. 15) Plans and Specification Approval The Engineer shall furnish an original cover mylar for the signatures of authorized City officials. The Contract Documents shall comply with applicable local, state and federal laws and with applicable rules and regulations promulgated by local, state and national boards, bureaus and agencies. The Engineer shall receive written approval of the Phase 3 plans from the City's project manager before proceeding with Phase 4. PHASE 4 16) Final Approved Construction Plans The Engineer shall furnish 45 bound copies of Phase 4 final approved construction plans and contract specifications. The approved plans and contract specifications shall be used as authorized by the City for use in obtaining bids, awarding contracts, and constructing the project. 17) Bidding Assistance The Engineer shall issue addenda as appropriate to interpret, clarify, or expand the bidding documents, and assist the owner in determining the qualifications and acceptability of prospective constructors, subcontractors, and suppliers. When substitution prior to the award STANDARD ENGINEERING AGREEMENT(REV 10106105) Page 17 of 18 of contracts is allowed by the bidding documents, the Engineer will advise the owner as to the acceptability of alternate materials and equipment proposed by the prospective constructors. 18) Recommendation of Award The Engineer shall assist in the tabulation and review of all bids received for the construction of the project and shall make a recommendation of award to the City. 19) Prebid Conference The Engineer shall attend the prebid conference and the bid opening, prepare bid tabulation sheets and provide assistance to the owner in evaluating bids or proposals and in assembling and awarding contracts for construction, materials, equipment, and services. PHASE 5 20) Preconstruction Conference The Engineer shall attend the preconstruction conference. 21) Construction Survey The Engineer shall be available to the City on matters concerning the layout of the project during its construction and will set control points in the field to allow City survey crews to stake the project. The setting of line and grade stakes and route inspection of construction will be performed by the City. 22) Site Visits The Engineer shall visit the project site at appropriate intervals as construction proceeds to observe and report on the progress and the quality of the executed work. 23) Shop Drawing Review The Engineer shall review shop and erection drawings submitted by the contractor for compliance with design concepts. The Engineer shall review laboratory, shop, and mill test reports on materials and equipment. 24) Instructions to Contractor The Engineer shall provide necessary interpretations and clarifications of contract documents, review change orders and make recommendations as to the acceptability of the work, at the request of the City. 25) Differing Site Conditions The Engineer shall prepare sketches required to resolve problems due to actual field conditions encountered. 26) Record Drawings The Engineer shall prepare record drawings from information submitted by the contractor. STANDARD ENGINEERING AGREEMENT(REV 10/06105) Page 18 of 18 ATTACHMENT"A-1'l DOE NO. Supplemental Scope of Services The following is a clarification of the tasks that the ENGINEER will perform under ATTACHMENT `A" Work under this attachment includes engineering design services: The engineering contract will encompass all project related services involved in the design and construction administration of federally funded airport improvement projects at Fort Worth Alliance Airport for Phase 6 On--Call Engineering Services for design of Electrical Improvements and bid phase services for Airport Beacon Relocation, Airfield Lighting Control & Monitoring System (ACLMS), and Airfield Signage Improvements Phase I and Phase II. The ENGINEER will provide design and engineering for the following projects. Part A: Services to be provided by the Engineer. Design Services for: 1. Airport Beacon Relocation — Relocate existing airport beacon to a new location on a new tower. 2. Installation of New Airfield Lighting Control & Monitoring System (ACLMS) — Install new Airfield Lighting Control & Monitoring System (ACLMS) system in FAA ATCT Control Tower. 3. Airfield Signage Improvements Phase I — Replace approximately 20 old-style airfield guidance signs. 4. Airfield Signage Improvements Phase Il — Replace approximately 15 old-style airfield guidance signs The scope of work will include, but not be limited to the following: 1. Coordination with FAA Southwest Region, if required; 2. Prepare four separate bid packages to maximize funding opportunities; 3. No construction Phase Services, inspection or as-builts are included as part of this contract. Part B: Services to be provided by the Engineer. Construction Support and Inspection Services for: 1. Airport Beacon Relocation — Relocate existing airport beacon to a new location on a new tower. 2. Installation of New Airfield Lighting Control & Monitoring System (ACLMS) — Install new Airfield Lighting Control & Monitoring System (ACLMS) system in FAA ATCT Control Tower. 3. Airfield Signage Improvements Phase I — Replace approximately 20 old-style airfield guidance signs. 4. Airfield Signage Improvements Phase II — Replace approximately 15 old-style airfield guidance signs. A-1-1 5. Shoulder Rehabilitation Phase 1 --- Rehabilitation of Asphalt Shoulders on Taxiway Wand Taxiway`H' and Runway Joint sealing and Repair. The scope of work will include, but not be limited to the following: 1. Coordination with FAA Southwest Region, if required; 2. Inspection and coordination of construction activities and materials testing; 3. Review of acceptance tests; 4. Review and approval of Contractor's Pay Request; 5. Review Shop Drawings, Submittals and answer request for Information; and 6. Prepare Closeout documents and Record Drawings. 2. Modifications to Work Authorizations Either the CITY or the ENGINEER may initiate a written request for a Modification to a Work Authorization when, in the opinion of the requesting party, the needs and conditions of the project warrant a modification. Approval of a modification shall be in the form of a written Modification of Work Authorization, which clearly defines the changes in scope, fee and completions date to the previously approved Work Authorization. The Modification to Work Authorization will not take effect until it is executed by the CITY and the ENGINEER. The ENGINEER shall not perform any work affected by the Modification to Work Authorization prior to the execution, by both parties, of -the Modification to Work Authorization. 3. Requests for Information The CITY shall provide timely responses to ENGINEER's reasonable requests for information to avoid delays in completion of ENGINEER's services by the Completion Date stated in the Work Authorization. 4. Work Progress Notification The ENGINEER shall promptly advise the CITY in writing of events which have a significant impact upon the progress of the work, including: favorable developments of events which enable meeting the work schedule goals sooner than anticipated; problems, delays, or adverse conditions which will materially affect the ability to attain contract objectives, prevent the meeting of time schedules and goals, or preclude the attainment of project work units by established time periods. This disclosure will be accompanied by a statement of the action taken, or contemplated, and any CITY assistance needed to resolve the situation. A 1-2 ATTACHMENT "B" DoE NO. COMPENSATION AND PAYMENT Part A-Compensation 1. For and in consideration of the satisfactory performance and completion of the Services hereunder, The CITY agrees to pay ENGINEER a Lump Sum of: A. Thirty-One Thousand Eight Hundred Seventy-Six Dollars and Ninety- Five Cents ($31,876.95) for Design Services Associated with Airport Beacon Relocation. B. Forty-One Thousand Six Hundred Twelve Dollars and Fifty-Five Cents ($41, 612.55) for Design Services Associated with Installation of New Airfield Lighting Control & Monitoring System (ACLMS). C. Thirty-Eight Thousand Five Hundred Fifty-Five Dollars and Fifty-Five Cents ($38,555.55)for Design Services Associated with Airfield Signage Improvements Phase I and Il. D. Eleven Thousand Four Hundred Sixty-Three Dollars and no Cents ($11,463.00) for Construction Support and Inspection Services Associated with Airfield Beacon Relocation, Installation of New Airfield Lighting Control & Monitoring system (ACLMS), Airfield Signage Improvements Phase 'I and Airfield Signage Improvements Phase II. 2. ENGINEER shall not perform any additional service, or incur any additional expense in the performance of this Agreement without the prior written approval of The CITY. 3. The CITY shall not be responsible for payment or reimbursement of monies for services performed without the prior written approval of The CITY. 4. Should a change of scope or additional Services be required, payment for such Services will be determined at the time of The CITY written approval, and such shall be amended to this Agreement. 5. In order to obtain payment for the work performed and accepted by The CITY, ENGINEER must submit one (1) signed original invoice, including appropriate documentation/description of work performed, if required by the Agreement. 6. The ENGINEER's invoice must: show percent(s) complete and, if required by this Agreement, percent(s) complete by task; application of that percent to the lump sum price(s) and, the total amount of the invoice; include as a separate invoice item total percent(s) completed to date and total amount(s) invoiced (including current invoice). 7. All pricing set forth in this Agreement is firm, fixed, and not subject to escalation (except B-1 as may be specifically set forth elsewhere in this Agreement). 8. Clearly state the total amount of-the invoice. 9. ENGINEER's invoice must reflect a unique Invoice Number, the above Agreement Number, and the ENGINEER's Federal ID Number. Part C-- Method of Payment Partial payment shall be made to the ENGINEER monthly upon City's approval of an invoice from the ENGINEER outlining 'the estimated current percent complete of the total project. B-2 ATTACHMENT"C" DoE NO. AMENDMENTS TO STANDARD AGREEMENT FOR ENGINEERING SERVICES NONE G1 ATTACHMENT"D" DoE NO. PROJECT SCHEDULE A project schedule will be provided with each work authorization. Part A— Period of Agreement 1. Initial Period This agreement becomes effective when fully executed by the ENGINEER and CITY (the "Effective Date"). The initial period of the contract shall terminate one year following the EFFECTIVE DATE of the agreement, unless termination occurs as otherwise provided in the agreement. 2. optional Periods The CITY, in its sole discretion, shall have the right, but not the obligation, to renew this agreement for four additional periods of one year each following the Initial Period of the agreement. The CITY shall notify the ENGINEER in writing of its decision to exercise its option to extend the agreement. 3. Work Authorization Completion Work Authorizations shall be executed before the termination date of this agreement as stipulated in paragraphs 1 and 2 above. If the completion date of individual Work Authorizations extends beyond the termination date of this agreement as stipulated in paragraphs 1 and 2 above, 'then the terms and conditions this agreement shall remain in full force and effect until the completion date of all individual Work Authorizations. Part B—Timing of Individual Work Authorizations 1. Time for Negotiations It is clearly understood that rapid response is in the best interest of the CITY and the ENGINEER. The ENGINNER shall respond in an expeditious manner to any Work Authorization negotiation initiated by the CITY. It is anticipated that the maximum time required for each work order negotiation will be no more than forty-eight (48) business hours. 2, Commence Services Upon the execution of a Work Authorization, the ENGINEER shall commence to provide services within a reasonable time, and will diligently provide services until completion of the services identified in the Work Authorization. D-1 3. Complete Services The ENGINEER shall complete all services for each Work Authorization by the completion date stated in the Work Authorization. D-2 ATTACHMENT "E" DOE NO. LOCATION MAPS Airport Beacon Relocation, Airfield Lighting Control & Monitoring System (ALCMS) & Airfield Signage Improvements Areas Shown Below, Ej WA N 0 Q � � o _ „" \ X 3 3 -�- 01 as -- A o / -� r BEACON —� I� — laI"amp" FM ATCT �= CONTROL.TOWER I SIGW�E u s IMI'ROYElrI JAW i Fu 1 L_ Aft Wage 1 ot'2 City of fort Worth,, Texas Mayor and C unication COUNCIL ACTION: Approved on 11/27/2007 DATE: Tuesday, November 27, 2007 LOG NAME: 30DMJM PHASE6 REFERENCE No.: **C-22531 SUBJECT: Approve Phase 6 Under On-Call Engineering Services Contract with DMJM Aviation for Design of Airfield Signs, Airport Beacon Relocation, Airfield Lighting Control and Monitoring System and Construction Phase Services for Projects at Fort(North Alliance Airport RECOMMENDATION: it is recommended that the City Council approve Phase 6 fee to DMJM Aviation under their tin-cal' Consulting Agreement, in the amount of $123,508.05, to provide design of airfield signs, airport beacon relocation, airfield lighting control and monitoring system and construction phase services for these projects at Fort Worth Alliance Airport. DISCUSSION: On August 24, 11,017+ (RA&C V r`�-I UUU ), the City Co.in�I authorized the execution of a contract for consult" services with DMJM Aviation for a five year period to provide engineering services for projects funded by Federal Aviation Administration (FAA) Non-Primary Airport Grants and Cargo Entitlement Grants. It is anticipated that this requirements contract would provide professional services for multiple phases. Five phases have been undertaken to date. On Ivi'arch 24, 20051 (MOOCC C-20820) the City Council authorized the initial phase (chase 1) of this contract with DMJM Aviation for the preparation of a Preliminary Engineering Report to assess and make recommendations on certain necessary improvements and to design the rehabilitation of the northeast taxiway access to FedEx at Fort Worth Alliance Airport. vlI July 5, 2005, (MO&C 20836] the ^ity Council' authorized Phase 2 of this contract with DMJM Aviation for the design of replacement wind cones and 23 runway/taxiway guidance signs. On September 6, 2005, (M&C C-20965) the City Council authorize Phase 3 of this contract with DMJM Aviation to design runway safety area, rehabilitate deicing containment facility, conduct pavement management study and to purchase hardware and software for ongoing pavement management. On May 2, 2006, (M&C C-21434) the City Council authorized Phase 4 of this contract with DMJM Aviation to provide construction administration and inspection Services for pavement rehabilitation at Taxiway "H" at the FedEx entrance. On July 25 2006, (M&C C-21580) the City Council authorized Phase 5 of this contract with DMJM Aviation to design runway rehabilitation, taxiway shoulder rehabilitation and design and bid phase services for an independent circuit for runway guard lights. Phase 6 will provide for Airfield Signage Improvements, relocate an existing airport beacon to a new location on a new tower and replace the Airfield Lighting Control Systems (ALCS). The funds for this project will come from FAA Grant 3-48-0296-32-2007. The City's 5 percent share will come from land credit. http://www.cfwnet.org/council_Packet/Reports/mc_print.asp 11125/2007 Wage 2 of 2 Dw1JM Aviation is in compliance with the City's DBE Ordinance by committing to 20 percent "'BEE participation. The City's goal on this project is 20 percent. This project is located in COUNCIL DISTRICT 2, Mapsco 7P. FISCAL INFORIIAATIONICERTIFICATION: The Finance Director certifies that funds are available in the current operating budget, as appropriated, of the Grants Fund. TO Fund/Account/Centers FROM Fund/Account/Centers G R 14 539120 055218186300 $123,508.05 Submitted for Citv Manager's office b Marc A. Cott (8476) Originating Department Head: A. Douglas Rademaker (6157) Additional Information Contact: Gopal Sahu (7949) http://www.cfwnet.org/council_packet/Reports/mc_print.asp 11/28/2007