HomeMy WebLinkAboutContract 57494 Received Date: May 4,2022
Received Time: 9:31 AM
Developer and Project Information Cover Sheet:
Developer Company Name: GBTM Sendera,LLC
Address, State,Zip Code: 2805 North Dallas Parkway, Suite 400,Plano,TX 75093
Phone &Email: 469-573-6755,bsamuel(cgreenbrickpartners.com
Authorized Signatory,Title: Bobby Samuel,Development Manager
Project Name: Madero Phase 1
Brief Description: Water, Sewer,Paving, Storm Drain and Street Lights
Project Location: East of Sendera Ranch Blvd, South of Rancho Canyon Way
Plat Case Number: FP-22-022 Plat Name: Madero Phase 1
Mapsco: Council District: 7
CFA Number: CFA22-0008 City Project Number: 103479
OFFICIAL RECORD
CITY SECRETARY
FT. WORTH, TX
City of Fort Worth,Texas Page 1 of 22
Standard Community Facilities Agreement
Rev.9/21
City Contract Number: 57494
STANDARD COMMUNITY FACILITIES AGREEMENT
This COMMUNITY FACILITIES AGREEMENT("Agreement") is made and entered into by
and between the City of Fort Worth ("City"), a home-rule municipal corporation of the State of Texas,
acting by and through its duly authorized Assistant City Manager, and GBTM Sendera, LLC
("Developer"),acting by and through its duly authorized representative.City and Developer are referred to
herein individually as a"party" and collectively as the"parties."
WHEREAS, Developer is constructing private improvements or subdividing land within the
corporate limits of Fort Worth, Texas or its extraterritorial jurisdiction, for a project known as Madero
Phase 1 ("Project"); and
WHEREAS, the City desires to ensure that all developments are adequately served by public
infrastructure and that the public infrastructure is constructed according to City standards; and
WHEREAS, as a condition of approval of the Project, Developer is required to bear a portion of
the costs of municipal infrastructure by constructing the public infrastructure necessary for the Project as
described in this Agreement("Community Facilities"or"Improvements");and
WHEREAS,as a condition of approval of the Project,Developer is required to meet the additional
obligations contained in this Agreement,and Developer may be required to make dedications of land,pay
fees or construction costs,or meet other obligations that are not a part of this Agreement; and
WHEREAS,the City is not participating in the cost of the Improvements or Project;and
WHEREAS, the Developer and the City desire to enter into this Agreement in connection with
the collective Improvements for the Project;
NOW,THEREFORE,for and in consideration of the covenants and conditions contained herein,
the City and the Developer do hereby agree as follows:
1.
CFA Ordinance
The Community Facilities Agreements Ordinance("CFA Ordinance"),as amended,is incorporated
into this Agreement by reference, as if it was fully set out herein. Developer agrees to comply with all
provisions of the CFA Ordinance in the performance of Developer's duties and obligations pursuant to this
Agreement and to cause all contractors hired by Developer to comply with the CFA Ordinance in
connection with the work performed by the contractors. If a conflict exists between the terms and conditions
of this Agreement and the CFA Ordinance,the CFA Ordinance shall control.
City of Fort Worth,Texas Page 2 of 22
Standard Community Facilities Agreement
Rev.9/21
2.
Incorporation of Engineering Plans
The engineering plans for the Improvements that have been approved by the City ("Engineering
Plans")are incorporated into this Agreement by reference as if fully set out herein. Developer shall provide
at its expense, unless otherwise agreed to by City, all engineering drawings and documents necessary to
construct the Improvements required by this Agreement.
3.
Description of Improvements; Exhibits and Attachments
The following exhibits describe the general location, nature and extent of the Improvements that
are the subject of this Agreement and are attached hereto and incorporated herein by reference:
❑x Exhibit A: Water
❑x Exhibit A-1: Sewer
❑x Exhibit B: Paving
❑x Exhibit B-1: Storm Drain
❑x Exhibit C: Street Lights & Signs
The Location Map and Cost Estimates are also attached hereto and incorporated herein by
reference. To the extent that Exhibits A, A-1, B, B-1, C, the Location Map, or the Cost Estimates
conflict with the Engineering Plans, the Engineering Plans shall control. If applicable,Attachment 1 —
Changes to Standard Community Facilities Agreement, Attachment 2 — Phased CFA Provisions, and
Attachment 3 — Concurrent CFA Provisions, are attached hereto and incorporated herein for all
purposes.
4.
Construction of Improvements
Developer agrees to cause the construction of the Improvements contemplated by this Agreement
and that said construction shall be completed in a good and workmanlike manner and in accordance with
all City standards and specifications, the Engineering Plans, the Cost Estimates provided for the
Improvements,and this Agreement. Developer acknowledges that City will not accept the Improvements
until the City receives affidavits and lien releases signed by Developer's contractors verifying that the
contractors, and all subcontractors and material suppliers, have been paid in full for constructing the
Improvements, and consent of the surety on payment and performance bonds provided for the
Improvements.
5.
Financial Guarantee
Developer has provided the City with a financial guarantee in the form and amounts set forth in
this Agreement which guarantees the construction of the Improvements and payment by Developer of
all contractors, subcontractors, and material suppliers for the Improvements ("Financial Guarantee").
Developer shall keep the Financial Guarantee in full force and effect until released by the City and shall
not reduce the amount of the Financial Guarantee unless authorized by the City in accordance with the
CFA Ordinance.
City of Fort Worth,Texas Page 3 of 22
Standard Community Facilities Agreement
Rev.9/21
6.
Completion Deadline; Extension Periods
This Agreement shall be effective on the date this Agreement is executed by the City's Assistant
City Manager ("Effective Date"). Developer shall complete construction of the Improvements and
obtain the City's acceptance of the Improvements within two (2)years of the Effective Date ("Term").
If construction of the Improvements has started during the Term, the Developer may request that this
Agreement be extended for an additional period of time ("Extension Period"). All Extension Periods shall
be agreed to in writing by the City and the Developer as set forth in a written amendment to this Agreement.
In no event shall the Term of this Agreement plus any Extension Periods be for more than three years.
7.
Failure to Construct the Improvements
(a) The City may utilize the Developer's Financial Guarantee to cause the completion of the
construction of the Improvements if at the end of the Term, and any Extension Periods, the
Improvements have not been completed and accepted by the City.
(b) The City may utilize the Developer's Financial Guarantee to cause the completion of the
construction of the Improvements or to cause the payment of costs for construction of the
Improvements before the expiration of the Term, and any Extension Period, if the Developer
breaches this Agreement,becomes insolvent,or fails to pay costs of construction.
(c) If the Financial Guarantee is a Completion Agreement and the Developer's contractors or suppliers
are not paid for construction costs or materials supplied for the Improvements the contractors and
suppliers may place a lien upon any property which the City does not have an ownership interest
that is the subject of the Completion Agreement.
(d) Nothing contained herein is intended to limit the Developer's obligations under the CFA
Ordinance, this Agreement, the Financial Guarantee, Developer's agreements with Developer's
contractors,or other related agreements.
8.
Termination
If Developer desires to terminate this Agreement before Developer's contractors begin
constructing the Improvements, Developer agrees to the following:
(a) that Developer and City must execute a termination of this Agreement in writing;
(b) that Developer will vacate any final plats that have been filed with the county where the Project
is located; and
(c) to pay to the City all costs incurred by the City in connection with this Agreement, including
time spent by the City's inspectors at preconstruction meetings.
9.
Award of Construction Contracts
City of Fort Worth,Texas Page 4 of 22
Standard Community Facilities Agreement
Rev.9/21
(a) Developer will award all contracts for the construction of the Improvements and cause the
Improvements to be constructed in accordance with the CFA Ordinance.
(b) Developer will employ construction contractors who meet the requirements of the City to construct
the Improvements including,but not limited,to being prequalified,insured,licensed and bonded to
construct the Improvements in the City.
(c) Developer will require Developer's contractors to provide the City with payment and performance
bonds naming the City and the Developer as dual obligees, in the amount of one hundred percent
(100%) of the cost of the Improvements as required by the CFA Ordinance. The payment and
performance bonds shall guarantee construction of the Improvements and payment of all
subcontractors and material suppliers. Developer agrees to require Developer's contractors to
provide the City with a maintenance bond naming the City as an obligee, in the amount of one
hundred percent(100%) of the cost of the Improvements, that guarantees correction of defects in
materials and workmanship for the Improvements by the contractor and surety for a period of two
(2)years after completion and final acceptance of the Improvements by the City. All bonds must
be provided to the City before construction begins and must meet the requirements of the City's
Standard Conditions,Chapter 2253 of the Texas Government Code,and the Texas Insurance Code.
(d) Developer will require Developer's contractors to provide the City with insurance equal to or in
excess of the amounts required by the City's standard specifications and contract documents for
developer-awarded infrastructure construction contracts. The City must be named as an additional
insured on all insurance policies. The Developer must provide the City with a Certificate of
Insurance (ACORD or form approved by the State of Texas), supplied by each contractor's
insurance provider,which shall be made a part of the Project Manual.
(e) Developer will require the Developer's contractors to give forty-eight(48)hours' advance notice
of their intent to commence construction of the Improvements to the City's Construction Services
Division so that City inspection personnel will be available. Developer will require Developer's
contractors to allow construction of the Improvements to be subject to inspection at any and all
times by the City's inspectors. Developer will require Developer's contractors to not install or
relocate any sanitary sewer, storm drain,or water pipe unless a City inspector is present and gives
consent to proceed, and to allow such laboratory tests as may be required by the City.
(f) Developer will not allow Developer's contractors to begin construction of the Improvements until
a notice to proceed to construction is issued by the City.
(g) Developer will not allow Developer's contractors to connect buildings to service lines of sewer and
water mains constructed pursuant to this Agreement, if any, until said sewer, water mains and
service lines have been completed to the satisfaction of the City.
10.
Utilities
Developer shall cause the installation or adjustment of utilities required to: (1) serve the Project;
and (2) to construct the Improvements required herein. City shall not be responsible for payment of any
costs that may be incurred by Developer in the relocation of any utilities that are or may be in conflict with
any of the Improvements to be constructed pursuant to this Agreement.
City of Fort Worth,Texas Page 5 of 22
Standard Community Facilities Agreement
Rev.9/21
11.
Easements and Rights-of-Way
Developer agrees to provide,at its expense,all necessary rights-of-way and easements required for
the construction and dedication to the City of the Improvements provided for by this Agreement.
12.
Liability and Indemnification
(a) DEVELOPER HEREBY RELEASES AND AGREES TO INDEMNIFY, DEFEND AND
HOLD THE CITY HARMLESS FOR ANY INADEQUACIES IN THE PRELIMINARY
PLANS, SPECIFICATIONS, ENGINEERING PLANS, AND COST ESTIMATES
SUPPLIED BY THE DEVELOPER FOR THIS AGREEMENT.
(b) THE DEVELOPER COVENANTS AND AGREES TO,AND BY THESE PRESENTS DOES
HEREBY FULLY INDEMNIFY, HOLD HARMLESS AND DEFEND THE CITY, ITS
OFFICERS,AGENTS AND EMPLOYEES FROM ALL SUITS,ACTIONS OR CLAIMS OF
ANY CHARACTER, WHETHER REAL OR ASSERTED,BROUGHT FOR OR ONACCOUNT
OFANYINJURIES OR DAMAGES SUSTAINED B YANY PERSONS,INCL UDING DEATH,
OR TO ANY PROPERTY, RESULTING FROM OR IN CONNECTION WITH THE
CONSTRUCTION,DESIGN, PERFORMANCE OR COMPLETION OF ANY WORK TO BE
PERFORMED BY SAID DEVELOPER, ITS CONTRACTORS, SUBCONTRACTORS,
OFFICERS, AGENTS OR EMPLOYEES, OR IN CONSEQUENCE OF ANY FAILURE TO
PROPERL Y SAFEGUARD THE WORK, OR ONACCOUNT OF ANY ACT,INTENTIONAL
OR OTHERWISE, NEGLECT OR MISCONDUCT OF SAID DEVELOPER, ITS
CONTRACTORS, SUB-CONTRACTORS, OFFICERS, AGENTS OR EMPLOYEES,
WHETHER OR NOT SUCHINJURIES,DEATH OR DAMAGESARE CAUSED,IN WHOLE
OR IN PART, BY THE ALLEGED NEGLIGENCE OF THE CITY OF FORT WORTH, ITS
OFFICERS,SERVANTS, OR EMPLOYEES.
(c) DEVELOPER WILL REQUIRE ITS CONTRACTORS TO INDEMNIFY, DEFEND AND
HOLD HARMLESS THE CITY, ITS OFFICERS, AGENTS AND EMPLOYEES FROM
AND AGAINST ANY AND ALL CLAIMS, SUITS OR CAUSES OF ACTION OF ANY
NATURE WHATSOEVER, WHETHER REAL OR ASSERTED, BROUGHT FOR OR ON
ACCOUNT OF ANY INJURIES OR DAMAGES TO PERSONS OR PROPERTY,
INCLUDING DEATH,RESULTING FROM, OR INANY WAY CONNECTED WITH, THE
CONSTRUCTION OF THE IMPROVEMENTS CONTEMPLATED HEREIN, WHETHER
OR NOT SUCH INJURIES, DEATH OR DAMAGES ARE CAUSED, IN WHOLE OR IN
PART, BY THE ALLEGED NEGLIGENCE OF THE CITY OF FORT WORTH, ITS
OFFICERS, SERVANTS, OR EMPLOYEES. FURTHER, DEVELOPER WILL REQUIRE
ITS CONTRACTORS TO INDEMNIFY, DEFEND, AND HOLD HARMLESS THE CITY
FOR ANY LOSSES, DAMAGES, COSTS OR EXPENSES SUFFERED BY THE CITY OR
CAUSED AS A RESULT OF SAID CONTRACTORS' FAILURE TO COMPLETE THE
WORK AND CONSTRUCT THE IMPROVEMENTS IN A GOOD AND WORKMANLIKE
MANNER, FREE FROM DEFECTS,IN CONFORMANCE WITH THE CFA ORDINANCE,
AND INACCORDANCE WITH ALL PLANS AND SPECIFICATIONS.
13.
Right to Enforce Contracts
City of Fort Worth,Texas Page 6 of 22
Standard Community Facilities Agreement
Rev.9/21
Upon completion of all work associated with the construction of the Improvements,Developer will
assign to the City a non-exclusive right to enforce the contracts entered into by Developer with its
contractors,along with an assignment of all warranties given by the contractors,whether express or implied.
Further,Developer agrees that all contracts with any contractor shall include provisions granting to the City
the right to enforce such contracts as an express intended third party beneficiary of such contracts.
14.
Estimated Fees Paid by Developer; Reconciliation
Prior to execution of this Agreement, Developer has paid to the City the estimated cost of
administrative material testing service fees, construction inspection service fees,and water testing lab fees
in the amounts set forth in the Cost Summary section of this Agreement. Upon completion of the
construction of the Improvements, the City will reconcile the actual cost of administrative material testing
service fees, construction inspection service fees, and water testing lab fees with the estimated fees paid
by Developer. If the actual costs of the fees are more than the estimated payments made by the Developer,
the Developer must pay the difference to the City before the Improvements will be accepted by the City. If
the actual costs of the fees are less than the estimated payments made by the Developer,the City will refund
the difference to the Developer.If the difference between the actual costs and the estimated payments made
by the Developer is less than fifty dollars($50.00),the City will not issue a refund and the Developer will
not be responsible for paying the difference. The financial guarantee will not be released by the City or
returned to the Developer until reconciliation has been completed by the City and any fees owed to the City
have been paid by the Developer.
15.
Material Testing
The City maintains a list of pre-approved material testing laboratories. The Developer must
contract with material testing laboratories on the City's list. Material testing laboratories will provide copies
of all test results directly to the City and the Developer. If the Improvements being constructed fail a test,
the Developer must correct or replace the Improvements until the Improvements pass all retests. The
Developer must pay the material testing laboratories directly for all material testing and retesting. The City
will obtain proof from the material testing laboratories that the material testing laboratories have been
paid in full by the Developer before the City will accept the Improvements.
16.
Notices
All notices required or permitted under this Agreement may be given to a party by hand-
delivery or by mail, addressed to such party at the address stated below. Any notice so given shall be
deemed to have been received when deposited in the United States mail so addressed with postage
prepaid:
CITY: DEVELOPER:
Development Coordination Office GBTM Sendera, LLC
City of Fort Worth 2805 North Dallas Parkway
200 Texas Street Suite 400
Fort Worth, Texas 76102 Plano, TX 75093
City of Fort Worth,Texas Page 7 of 22
Standard Community Facilities Agreement
Rev.9/21
With copies to:
City Attorney's Office
City of Fort Worth
200 Texas Street
Fort Worth, Texas 76102
and
City Manager's Office
City of Fort Worth
200 Texas Street
Fort Worth, Texas 76102
Or to such other address one party may hereafter designate by notice in writing addressed and
mailed or delivered to the other party hereto.
17.
Right to Audit
Developer agrees that, until the expiration of three (3) years after acceptance by the City of the
Improvements constructed pursuant to this Agreement, that the City shall have access to and the right to
examine any directly pertinent books, documents, papers and records of the Developer involving
transactions relating to this Agreement. Developer agrees that the City shall have access during normal
working hours to all necessary Developer facilities and shall be provided adequate and appropriate
workspace in order to conduct audits in compliance with the provisions of this section. The City shall give
Developer reasonable advance notice of intended audits.
Developer further agrees to include in all contracts with Developer's contractors for the
Improvements a provision to the effect that the contractor agrees that the City shall,until the expiration of
three (3)years after final payment under the contract,have access to and the right to examine any directly
pertinent books, documents,papers and records of such contractor, involving transactions to the contract,
and further,that City shall have access during normal working hours to all of the contractor's facilities,and
shall be provided adequate and appropriate work space in order to conduct audits in compliance with the
provisions of this section. City shall give Developer's contractors reasonable advance notice of intended
audits.
18.
Independent Contractor
It is expressly understood and agreed that Developer and its employees, representative, agents,
servants,officers,contractors,subcontractors,and volunteers shall operate as independent contractors as to
all rights and privileges and work performed under this Agreement, and not as agents, representatives or
employees of the City. Subject to and in accordance with the conditions and provisions of this Agreement,
Developer shall have the exclusive right to control the details of its operations and activities and be solely
responsible for the acts and omissions of its employees, representatives, agents, servants, officers,
contractors, subcontractors, and volunteers. Developer acknowledges that the doctrine of respondeat
superior shall not apply as between the City and its officers, representatives, agents, servants and
employees, and Developer and its employees, representatives, agents, servants, officers, contractors,
City of Fort Worth,Texas Page 8 of 22
Standard Community Facilities Agreement
Rev.9/21
subcontractors, and volunteers. Developer further agrees that nothing herein shall be construed as the
creation of a partnership or joint enterprise between City and Developer. It is further understood that the
City shall in no way be considered a co-employer or a joint employer of Developer or any employees,
representatives, agents, servants, officers, contractors, subcontractors, and volunteers of Developer.
Neither Developer,nor any officers,agents, servants,employees or subcontractors of Developer shall be
entitled to any employment benefits from the City. Developer shall be responsible and liable for any and
all payment and reporting of taxes on behalf of itself, and any of employees, representatives, agents,
servants,officers,contractors, subcontractors,and volunteers.
The City,through its authorized representatives and employees, shall have the sole and exclusive
right to exercise jurisdiction and control over City employees.
19.
Applicable Law; Venue
This Agreement shall be construed under and in accordance with Texas law. Venue shall be in
the state courts located in Tarrant County, Texas or the United States District Court for the Northern
District of Texas,Fort Worth Division.
20.
Non-Waiver
The failure of the City to insist upon the performance of any term or provision of this Agreement
or to exercise any right herein conferred shall not be construed as a waiver or relinquishment to any extent
of City's right to assert or rely on any such term or right on any future occasion.
21.
Governmental Powers and Immunities.
It is understood that by execution of this Agreement, the City does not waive or surrender
any of its governmental powers or immunities.
22.
Headings
The paragraph headings contained herein are for the convenience in reference and are not intended
to define or limit the scope of any provision of this Agreement.
23.
Severability
In the event that any clause or provision of this Agreement shall be held to be invalid by any
court of competent jurisdiction, the invalidity of such clause or provision shall not affect any of the
remaining provisions hereof.
24.
Review of Counsel
City and Developer, and if they so choose,their attorneys, have had the opportunity to review
City of Fort Worth,Texas Page 9 of 22
Standard Community Facilities Agreement
Rev.9/21
and comment on this document;therefore any rule of contract construction or interpretation that would
normally call for the document to be interpreted as against the drafting party shall not apply in
interpretation of this Agreement, and each section, portion, and provision of this Agreement shall be
construed solely on the basis of the language contained therein, regardless of who authored such
language.
25.
Prohibition on Boycotting Israel
Developer acknowledges that in accordance with Chapter 2271 of the Texas Government Code,
the City is prohibited from entering into a contract with a company with 10 or more full-time employees
that has a value of$100,000 or more that is to be paid wholly or partly from public funds of the City for
goods or services unless the contract contains a written verification from the company that it: (1) does not
boycott Israel; and (2) will not boycott Israel during the term of the contract. The terms "boycott Israel"
and"company"have the meanings ascribed to those terms by Chapter 2271 of the Texas Government Code.
To the extent that Chapter 2271 of the Government Code is applicable to this Agreement,by signing this
Agreement, Developer certifies that Developer's signature provides written verification to the City that
Developer: (1)does not boycott Israel;and(2)will not boycott Israel during the term of this Agreement.
26.
Prohibition on Boycotting Energy Companies
Developer acknowledges that in accordance with Chapter 2274 of the Texas Government Code,as
added by Acts 2021, 87th Leg., R.S., S.B. 13, § 2,the City is prohibited from entering into a contract for
goods or services that has a value of$100,000 or more that is to be paid wholly or partly from public funds
of the City with a company with 10 or more full-time employees unless the contract contains a written
verification from the company that it: (1) does not boycott energy companies; and (2) will not boycott
energy companies during the term of the contract. The terms "boycott energy company" and "company"
have the meanings ascribed to those terms by Chapter 2274 of the Texas Government Code, as added by
Acts 2021, 87th Leg., R.S., S.B. 13, § 2. To the extent that Chapter 2274 of the Government Code is
applicable to this Agreement, by signing this Agreement, Developer certifies that Developer's signature
provides written verification to the City that Developer: (1) does not boycott energy companies; and (2)
will not boycott energy companies during the term of this Agreement.
27.
Prohibition on Discrimination Against Firearm and Ammunition Industries
Developer acknowledges that except as otherwise provided by Chapter 2274 of the Texas
Government Code,as added by Acts 2021,87th Leg.,R.S.,S.B. 19, § 1,the City is prohibited from entering
into a contract for goods or services that has a value of$100,000 or more that is to be paid wholly or partly
from public funds of the City with a company with 10 or more full-time employees unless the contract
contains a written verification from the company that it: (1) does not have a practice,policy, guidance, or
directive that discriminates against a firearm entity or firearm trade association;and(2)will not discriminate
during the term of the contract against a firearm entity or firearm trade association. The terms
"discriminate," "firearm entity" and "firearm trade association"have the meaning ascribed to those terms
by Chapter 2274 of the Texas Government Code,as added by Acts 2021, 87th Leg.,R.S., S.B. 19, § 1. To
the extent that Chapter 2274 of the Government Code is applicable to this Agreement, by signing this
Agreement, Developer certifies that Developer's signature provides written verification to the City that
Developer: (1) does not have a practice,policy, guidance, or directive that discriminates against a firearm
City of Fort Worth,Texas Page 10 of 22
Standard Community Facilities Agreement
Rev.9/21
entity or firearm trade association; and (2) will not discriminate against a firearm entity or firearm trade
association during the term of this Agreement.
28.
Immigration and Nationality Act
Developer shall verify the identity and employment eligibility of its employees who perform work
under this Agreement, including completing the Employment Eligibility Verification Form (I-9). Upon
request by City, Developer shall provide City with copies of all I-9 forms and supporting eligibility
documentation for each employee who performs work under this Agreement. Developer shall adhere to all
Federal and State laws as well as establish appropriate procedures and controls so that no services will be
performed by any Developer employee who is not legally eligible to perform such services.DEVELOPER
SHALL INDEMNIFY CITY AND HOLD CITY HARMLESS FROM ANY PENALTIES,
LIABILITIES, OR LOSSES DUE TO VIOLATIONS OF THIS PARAGRAPH BY DEVELOPER,
DEVELOPER'SEMPLOYEES,SUBCONTRACTORS,AGENTS,OR LICENSEES. City,upon written
notice to Developer, shall have the right to immediately terminate this Agreement for violations of this
provision by Developer.
29.
Amendment
No amendment,modification, or alteration of the terms of this Agreement shall be binding unless
the same is in writing,dated subsequent to the date hereof, and duly executed by the City and Developer.
30.
Assignment and Successors
Developer shall not assign or subcontract all or any part of its rights,privileges,or duties under this
Agreement without the prior written consent of City. Any attempted assignment or subcontract without the
City's prior written approval shall be void and constitute a breach of this Agreement.
31.
No Third-Party Beneficiaries
The provisions and conditions of this Agreement are solely for the benefit of the City and
Developer, and any lawful assign or successor of Developer, and are not intended to create any rights,
contractual or otherwise,to any other person or entity.
32.
Compliance with Laws,Ordinances,Rules and Regulations
Developer, its officers, agents, servants, employees, and contractors, shall abide by and comply
with all laws, federal, state and local, including all ordinances, rules and regulations of City. It is agreed
and understood that,if City calls to the attention of Developer any such violation on the part of Developer
or any of its officers, agents, servants, employees, or subcontractors, then Developer shall immediately
desist from and correct such violation.
33.
Signature Authority
City of Fort Worth,Texas Page 11 of 22
Standard Community Facilities Agreement
Rev.9/21
The person signing this Agreement on behalf of Developer warrants that he or she has the legal
authority to execute this Agreement on behalf of the Developer, and that such binding authority has been
granted by proper order,resolution,ordinance or other authorization of the entity. The City is fully entitled
to rely on this warranty and representation in entering into this Agreement.
34.
Counterparts
This Agreement may be executed in multiple counterparts, each of which will be deemed an
original, but which together will constitute one instrument.
35.
Entire Agreement
This written instrument, together with any attachments, exhibits, and appendices, constitutes the
entire understanding between the City and Developer concerning the work to be performed hereunder, and
any prior or contemporaneous, oral or written agreement that purports to vary from the terms hereof shall
be void.
[REMAINDER OF PAGE INTENTIONALLY BLANK]
City of Fort Worth,Texas Page 12 of 22
Standard Community Facilities Agreement
Rev.9/21
36.
Cost Summary Sheet
Pro]ect Name: Madero Phase 1
CFA No.: CFA22-0008 City Project No.: 103479 IPRC No.: IPRC21-0172
Items Developer's Cost
A. Water and Sewer Construction
1. Water Construction $ 1,897,805.00
2.Sewer Construction $ 1,314,398.00
Water and Sewer Construction Total $ 3,212,203.00
B. TPW Construction
1.Street $ 5,050,653.00
2.Storm Drain $ 2,494,596.00
3.Street Lights Installed by Developer $ 593,532.00
4. Signals $ -
TPW Construction Cost Total $ 8,138,781.00
Total Construction Cost(excluding the fees): $ 11,360,984.00
Estimated Construction Fees:
C. Construction Inspection Service Fee $109,500.00
D. Administrative Material Testing Service Fee $46,060.00
E. Water Testing Lab Fee $2,790.00
Total Estimated Construction Fees: $ 168,360.00
Choice
Financial Guarantee Options,choose one Amount (Mark one)
Bond = 100% $ 11,350,984.00 X
Completion Agreement= 100%/Holds Plat $ 11,350,984.00
Cash Escrow Water/Sanitary Sewer= 125% $ 4,015,253.75
Cash Escrow Paving/Storm Drain = 125% $ 10,173,476.25
Letter of Credit= 125% $ 14,188,730.00
City of Fort Worth,Texas Page 13 of 22
Standard Community Facilities Agreement
Rev.9/21
IN WITNESS WHEREOF,the City and Developer have each executed this Agreement by their
duly authorized signatories to be effective on the date executed by the City's Assistant City Manager.
CITY OF FORT WORTH DEVELOPER
GBTM Sendera,LLC
bay B��Gu7�f �
Dana Burghdoff(Pray 4,20 08:52 CDT) Bobby Samuel(May 3,202216:36 CDT)
Dana Burghdoff Bobby Samuel
Assistant City Manager Development Manager
Date: May 4,2022 Date: May 3,2022
Recommended by:
����ut�L�iz. �e2�:��cr✓
J fifer Ezern?I May 3,202 :47 CDT)
Jennifer Ezernack
Contract Compliance Specialist
Planning and Development
Approved as to Form &Legality:
Contract Compliance Manager:
Richard A.McCracken(May 4,2022 08:51 CDT)
Richard A.McCracken By signing, I acknowledge that I am the person
Sr.Assistant City Attorney responsible for the monitoring and
M&C No. administration of this contract,including
Date: May 4,2022 ensuring all performance and reporting
requirements.
Form 1295:
r 7�l'IIP. c�G�'lP.l`l`/�ID�GZGP,I
ATTEST: Janie Scarlett Morales(May 4,2022 08:37 CDT)
Janie Scarlett Morales
Development Manager
J ette S.Goodall(May4,2022 09: DT)
Jannette S. Goodall/Ronald P. Gonzales
City Secretary Assistant City Secretary
,aa4�an
a
pF*-0�1F�%
40
0v0o=d
°°° °° �`� OFFICIAL RECORD
da��0E000000
CITY SECRETARY
FT. WORTH, TX
City of Fort Worth,Texas Page 14 of 22
Standard Community Facilities Agreement
Rev.9/21
The following attachments are incorporated into this Agreement. To the extent a
conflict exists between the main body of this Agreement and the following attachments, the
language in the main body of this Agreement shall be controlling.
Included Attachment
0 Attachment 1 -Changes to Standard Community Facilities Agreement
0 Attachment 2—Phased CFA Provisions
0 Attachment 3 —Concurrent CFA Provisions
0 Location Map
0 Exhibit A: Water Improvements
0 Exhibit A-1: Sewer Improvements
0 Exhibit B: Paving Improvements
0 Exhibit B-1: Storm Drain Improvements
0 Exhibit C: Street Lights and Signs Improvements
0 Cost Estimates
(Remainder of Page Intentionally Left Blank)
City of Fort Worth,Texas Page 15 of 22
Standard Community Facilities Agreement
Rev.9/21
ATTACHMENT"1"
Changes to Standard Community Facilities Agreement
City Project No. 103479
None
City of Fort Worth,Texas Page 16 of 22
Standard Community Facilities Agreement
Rev.9/21
ATTACHMENT "2"
Phased CFA Provision
City Project No. 103479
Developer intends to construct a 30 inch public water main pursuant to a separate
community facilities agreement (City Project Number 104078, IPRC22-0062) that will run
underneath portions of the paving Improvements for Rancho Canyon Way being constructed
pursuant to this Agreement as shown in the engineering plans. Therefore,this Agreement shall be
considered a "Phased CFA" and the provisions contained in this section shall apply to this
Agreement.
The improvements being constructed by Developer under the separate community facilities
agreement, City Project Number 104078, IPRC22-0062, shall be defined as the "Parent Project."
The improvements being constructed by Developer under this Agreement shall be defined as the
"Child Project."
Developer acknowledges and agrees that due to Developer's election to construct a Phased
CFA,the potential exists for technical, delivery, acceptance or performance problems (hereinafter
"Construction Problems"). Construction Problems may include, but are not limited to: failure of
the improvements to comply with the approved plans or City Specifications; failure of the
improvements in the Parent Project and the Child Project to properly connect to each other;
changes to the design or construction of the improvements in the Parent Project that impact the
design and construction of the improvements in the Child Project; construction delays, delay
claims, or claims for liquidated damages; increased costs for the Developer; failure of the
improvements to pass inspection or material testing; or rejection by the City of some or all of the
improvements and Developer having to remove and reconstruct the improvements at Developer's
expense. In addition, Developer understands and agrees that disputes may arise between
Developer's contractors or their subcontractors relating to responsibility for the Construction
Problems. Developer shall be solely responsible for resolving disputes between contractors or
disputes between contractors and subcontractors.
Developer further acknowledges and agrees that Developer has notified all of Developer's
contractors for the Project that Developer has elected to construct a Phased CFA, the provisions
of this section, the risks associated with a Phased CFA, and that the City shall not bear any
responsibility for Developer's decision to proceed with a Phased CFA.
Developer shall not construct any paving Improvements for Rancho Canyon Way pursuant
to this Agreement until the 30 inch water main in the Parent Project is constructed. If Developer
chooses to construct the paving Improvements for Rancho Canyon Way before the 30 inch water
main in the Parent Project is accepted by the City, acceptance being evidenced by execution of a
Notice of Project Completion by the City (commonly referred to as a green sheet), Developer
City of Fort Worth,Texas Page 17 of 22
Standard Community Facilities Agreement
Rev.9/21
understands and agrees that Developer is assuming all risks and the City shall not be liable for or
bear any responsibility for the paving Improvements having to be removed and reconstructed if
any problems are discovered with the 30 inch water line before the 30 inch water line is accepted
by the City. Developer further understands that letters of no objector other consent for the 30 inch
water main crossing natural gas lines are also necessary and have not been obtained by Developer
at the time this Agreement is executed. City shall not be responsible for Developer proceeding
with construction of the Improvements in this Agreement prior to Developer obtaining such letters
or consent from the gas line operators and City shall not be responsible for any delays this may
cause to Developer's project.
Developer agrees that if this Agreement is for improvements relating to the construction,
renovation or modification of one or more single family residential homes or structures, the City
will not record the plat related to the Project until the improvements in the Parent Project are
constructed and accepted by the City. Developer agrees that if this Agreement is for improvements
relating to the construction, renovation or modification of one or more commercial buildings or
structures, the Developer shall not receive a Certificate of Occupancy from the City for the
building(s) related to the Project until the improvements in the Parent Project are constructed and
accepted by the City. Developer further understands and agrees that completion of the
improvements under this Agreement does not entitle Developer to obtain a final plat of the property
until all other requirements of Federal law, State law, or the City Code relating to the filing and
recording of a final plat have been met by Developer.
BY CHOOSING TO CONSTRUCT A PHASED CFA, DEVELOPER ASSUMES ALL
RISKS AND DEVELOPER SHALL BE LIABLE AND RESPONSIBLE FOR ANYAND ALL
DAMA GES,INCL UDING B UT NOT LIMITED TO ANYAND ALL ECONOMIC DAMA GES
PROPERTY LOSS, PROPERTY DAMAGES AND PERSONAL INJURY, (INCLUDING
DEATH), OF ANY KIND OR CHARACTER, WHETHER REAL OR ASSERTED.
DEVELOPER HEREBY EXPRESSLY RELEASES AND DISCHARGES CITY FROM ANY
AND ALL LIABILITYFOR DAMAGES, INCLUDING, BUT NOT LIMITED TO ANYAND
ALL ECONOMIC DAMAGES,PROPERTYLOSS,PROPERTYDAMAGE AND PERSONAL
INJURY (INCLUDING DEATH) ARISING OUT OF OR IN CONNECTION WITH,
DIRECTLY OR INDIRECTLY, THE CONSTRUCTION OF THE IMPROVEMENTS OR
DEVELOPER'S DECISION TO CONSTRUCT A PHASED CFA. DEVELOPER, AT ITS
SOLE COST AND EXPENSE,AGREES TO AND DOES HEREBY INDEMNIFY,DEFEND
PROTECT, AND HOLD HARMLESS CITY, AND CITY'S OFFICERS,
REPRESENTATIVES, AGENTS, EMPLOYEES, AND SERVANTS FOR, FROM AND
AGAINST ANYAND ALL CLAIMS(WHETHER AT LAW OR IN EQUITI), LIABILITIES,
DAMAGES (INCLUDING ANY AND ALL ECONOMIC DAMAGES, PROPERTY LOSS,
PROPERTY DAMAGES AND PERSONAL INJURIES INCLUDING DEATH), LOSSES,
LIENS, CAUSES OFACTION,SUITS,JUDGMENTS AND EXPENSES(INCLUDING,BUT
City of Fort Worth,Texas Page 18 of 22
Standard Community Facilities Agreement
Rev.9/21
NOT LIMITED TO, COURT COSTS, ATTORNEYS' FEES AND COSTS OF
INVESTIGATION), OFANYNATURE,KIND OR DESCRIPTIONARISING OR ALLEGED
TO ARISE BY OR IN ANY WAY RELATED TO (1) CONSTRUCTION OF THE
IMPROVEMENTS OR DEVELOPER'S CHOICE TO CONSTRUCTA PHASED CFA, OR(2)
BY REASON OF ANY OTHER CLAIM WHATSOEVER OF ANY PERSON OR PARTY
OCCASIONED OR ALLEGED TO BE OCCASIONED IN WHOLE OR IN PART BY THE
CONSTRUCTIONS OF THE IMPROVEMENTS OR DEVELOPER'S CHOICE TO
CONSTRUCT A PHASED CFA WHETHER OR NOT SUCH INJURIES, DEATH OR
DAMAGES ARE CAUSED, IN WHOLE OR IN PART, BY THE ALLEGED NEGLIGENCE
OF THE CITY OF FORT WORTH,ITS OFFICERS, SERVANTS, OR EMPLOYEES.
By signing below, Developer certifies that all statements contained in this Attachment"T'
Phased CFA Provision are true and correct.
DEVELOPER:
GBTM Sendera,LLC
Bobby Samuel(May 3,2022 16:36 CDT)
Name: Bobby Samuel
Title: Development Manager
City of Fort Worth,Texas Page 19 of 22
Standard Community Facilities Agreement
Rev.9/21
ATTACHMENT "3"
Concurrent CFA Provision
City Project No. 103479
The improvements being constructed by Developer pursuant to this Agreement will
connect to improvements being constructed by Lennar Homes of Texas Land and Construction,
Ltd. under a separate Community Facilities Agreement, City Secretary Contract No. 56053
(Hereinafter the "Separate CFA"). Developer has requested and the City has agreed to allow
Developer to begin the construction of the improvements contained in this Agreement before the
improvements being constructed under City Secretary Contract No. 56053 are completed and
accepted by the City. Therefore, this Agreement shall be considered a"Concurrent CFA" and the
provision contained in this Attachment shall apply to this Agreement.
The improvements being constructed under the Separate CFA shall be defined as the
"Primary Project." The improvements being constructed by Developer under this Agreement shall
be defined as the "Secondary Project."
Developer acknowledges and agrees that due to Developer's election to construct a
Concurrent CFA, the potential exists for technical, delivery, acceptance or performance problems
(hereinafter "Construction Problems"). Construction Problems may include, but are not limited
to: failure of the improvements to comply with the approved plans or City Specifications; failure
of the improvements in the Primary Project and the Secondary Project to properly connect to each
other;changes to the design or construction of the improvements in the Primary Project that impact
the design and construction of the improvements in the Secondary Project; construction delays,
delay claims, or claims for liquidated damages; increased costs for the Developer or the developer
of the Primary Project; failure of the improvements to pass inspection or material testing; or
rejection by the City of some or all of the improvements and Developer or the developer of the
Primary Project having to remove and reconstruct the improvements at the expense of Developer,
developer of the Primary Project, or both. In addition, Developer understands and agrees that
disputes may arise between the contractors or subcontractors for the Primary Project and the
contractors or subcontractors for the Secondary Project relating to responsibility for the
Construction Problems. Developer shall be solely responsible for resolving disputes between
contractors, disputes between contractors and subcontractors and disputes between Developer and
the developer of the Primary Project.
Developer acknowledges and certifies that Developer has entered into a written agreement
with the developer of the Primary Project and said agreement: (1) provides Developer with any
access needed through property owned by the developer of the Primary Project; (2)that Developer
and the developer of the Primary Project shall resolve all disputes regarding the design and
construction of the Primary Project and the Secondary Project;and(3)the developer of the Primary
City of Fort Worth,Texas Page 20 of 22
Standard Community Facilities Agreement
Rev.9/21
Project will notify Developer of any all changes to the design or construction of the improvements
in the Primary Project, including any field changes.
Developer further acknowledges and agrees that Developer has notified all of Developer's
contractors for the Project that Developer has elected to construct a Concurrent CFA, the
provisions of this Attachment, the risks associated with a Concurrent CFA, and that the City shall
not bear any responsibility for construction of the improvements or Developer's decision to
proceed with a Concurrent CFA.
Developer shall not make the final connection of the improvements in the Secondary
Project to the improvements in the Primary Project until the improvements in the Primary Project
have been constructed and accepted by the City and the City has consented to Developer making
the connection.
Developer agrees that if this Agreement is for improvements relating to the construction,
renovation or modification of one or more single family residential homes or structures, the City
will not record the plat related to the Project until the improvements are constructed and accepted
by the City. Developer agrees that if this Agreement is for improvements relating to the
construction, renovation or modification of one or more commercial buildings or structures, the
Developer shall not receive a Certificate of Occupancy from the City for the building(s)related to
the Project until the improvements in this Agreement are constructed and accepted by the City.
Developer further understands and agrees that completion of the improvements under this
Agreement does not entitle Developer to obtain a final plat of the property until all other
requirements of Federal law, State law, or the City Code relating to the filing and recording of a
final plat have been met by Developer.
B Y CHOOSING TO CONSTR UCT A CONCURRENT CFA,DE VELOPER ASSUMES
ALL RISKS AND DEVELOPER SHALL BE LIABLE AND RESPONSIBLE FOR ANYAND
ALL DAMAGES, INCLUDING BUT NOT LIMITED TO, ANY AND ALL ECONOMIC
DAMAGES, PROPERTY LOSS, PROPERTY DAMAGES AND PERSONAL INJURY
(INCLUDING DEATH), OF ANY KIND OR CHARACTER, WHETHER REAL OR
ASSERTED. DEVELOPER HEREBYEXPRESSLYRELEASES AND DISCHARGES CITY
FROM ANY AND ALL LIABILITY FOR DAMAGES, INCLUDING, BUT NOT LIMITED
TO, ANY AND ALL ECONOMIC DAMAGES, PROPERTY LOSS, PROPERTY DAMAGE
AND PERSONAL INJURY (INCLUDING DEATH) ARISING OUT OF OR IN
CONNECTION WITH, DIRECTLY OR INDIRECTLY, THE CONSTRUCTION OF THE
IMPROVEMENTS OR DEVELOPER'S DECISION TO CONSTRUCT A CONCURRENT
CFA. DEVELOPER, AT ITS SOLE COST AND EXPENSE, AGREES TO AND DOES
HEREBY INDEMNIFY, DEFEND, PROTECT, AND HOLD HARMLESS CITY, AND
CITY'S OFFICERS, REPRESENTATIVES, AGENTS, EMPLOYEES, AND SERVANTS
City of Fort Worth,Texas Page 21 of 22
Standard Community Facilities Agreement
Rev.9/21
FOR, FROM AND AGAINST ANY AND ALL CLAIMS (WHETHER AT LAW OR IN
EQUITI), LIABILITIES, DAMAGES (INCLUDING ANY AND ALL ECONOMIC
DAMAGES, PROPERTY LOSS, PROPERTY DAMAGES AND PERSONAL INJURIES
INCLUDING DEATH), LOSSES, LIENS, CAUSES OF ACTION, SUITS, JUDGMENTS
AND EXPENSES (INCLUDING, BUT NOT LIMITED TO, COURT COSTS, ATTORNEYS'
FEES AND COSTS OF INVESTIGATION), OF ANY NATURE, KIND OR DESCRIPTION
ARISING OR ALLEGED TO ARISE BY OR IN ANY WAY RELEATED TO
CONSTRUCTION OF THE IMPROVEMENTS OR DEVELOPER'S CHOICE TO
CONSTRUCT A CONCURRENT CFA, OR (2) BY REASON OF ANY OTHER CLAIM
WHATSOEVER OF ANY PERSON OR PARTY OCCASIONED OR ALLEGED TO BE
OCCASIONED IN WHOLE OR IN PART BY THE CONSTRUCTION OF THE
IMPROVEMENTS OR DEVELOPER'S CHOICE TO CONSTRUCTA CONCURRENT CFA,
WHETHER OR NOTSUCHINJURIES,DEATH OR DAMAGESARE CAUSED,IN WHOLE
OR IN PART, BY THE ALLEGED NEGLIGENCE OF THE CITY OF FORT WORTH, ITS
OFFICERS, SERVANTS, OR EMPLOYEES.
By signing below, Developer certifies that all statements contained in this Attachment"Y'
Concurrent CFA Provision are true and correct.
DEVELOPER:
GBTM Sendera,LLC
Bobby Samuel(May 3,2022 16:36 CDT)
Name: Bobby Samuel
Title: Development Manager
Date: May 3,2022
City of Fort Worth,Texas Page 22 of 22
Standard Community Facilities Agreement
Rev.9/21
O CD (.0
O00
4 CD co
=�� N Li-
li,i z
J � �
a Li-
V)
r o
o �
Q ~
cu
o Uaa =
HH JSVN8
> �a) w CD
*(18 kVC1 NHo v 4 0
_ LO
v cu
a
W o o
a CD
2
3 (DCO0
a �o
Q
Zt
o U O (D U
a � �� o
� o 00 ��0 o �
2L p2L z 0
J C) J
aC)
Z a � 20
N U
� � o
G
�P s
r
m Y
J %
O Q ap M
LL1 W
> ¢^ u^i
J
fn WLLJ i--�
w Z
0 V) o�Nv
W� Z o,i;i
�m 0000�om
OCR Ndmd
S-OIJ 01a00 `Wd bl:£ ZZOZ/l/b `6MP'Zd—dour 'C}iuiO!A —yd0\Z 9s0yd 0Japoy4\yd0 g9ti\ONbI 004\ZlLO\ONHI—X1N\:S
CO
Ld
z
NOT EXISTING
16 NSIII WL2 ()
INFRASTRUCTURE Q
MADERO PHASE 2 RANCHO CANYON WAY
CPN 103676 SCALE:1" = 500'
PROJECT IN DESIGN EXISTING
24" NSIV WL
Sll Z. NOT EXISTING
EXISTING INFRASTRUCTURE
30" NSIII WL MADERO PHASE 3
CPN 103480
CONNECT TO (PROJECT HAS
30" WL RECEIVED IPRC PLAN
m CPN101500 PER APPROVAL)
N Z APPROVED PLAN —
w J RANCHO CANYON WAY
18 NSIII Wl2
> MATCH LINE A Q Q N
m LLLLL Ld Ld
W O
Q \ L J U Q z
MATCH LINE A V) Q a_
Z 2 ] 4 5 8 8 9
I O
N r 19 2° xl 1x 2}
e.,
SAN CLEMENTE
17
1 1e 1 1° s ,} ,z m <z
1s 2 6 }
Z
Z 4 BE7EN BRONCO DRIVE
ai rn z�
0O } a5 0 0
2) n
m8 9 '
a m 2 2° x ]8
`0
�1
U 10 }
za J!
zx }2
21 .�° ao
nj .JPp ° 20 }1
N �P� 10 1e
N 12 " °" 5���0 ° xe LEGEND
] ' s 0 11
2 xa x PROPOSED WATER LINE
25
EXISTING WATER LINE
3
LIMITS OF PROJECT
� 2G 2 '1
211 T^
3
I 5 a C
CONNECT TO 'x 8 ,
N SENDERA RANCH �2F ° ° '_ " 12<
WATER
rPHASE III-313 NUEVE RANCHO LANE
n. CPN 103121\ ����� x } . 5 6 ' ° ' 0 EXHIBIT 'A'
12
L)
U
LO
(O
O
Z
g MADERO
0
OWNED/DEVELOPED BY: PHASE I
GBTM SENDERA, LLC CITY PROJECT NO. 103479
2805 North Dallas Parkway, Suite 400
Z Plano, Texas 75093 ALA
SAMUEL
I PHONE: (469) 573-6755 LJA Engineering, Inc.
i 6060 North Central Expressway Phone 469.621.0710
Suite 400
Dallas, Texas 75206 FRN - F-1386
N
m
w SCALE:1" = 500'
z
8'SS14 8'SS13 W SS12 J
RANCHO CANYON WAY
2
i�
e•s515—/� MATCH LINE Q A <
I N z NOT EXISTING
� Ld co U) INFRASTRUCTURE
zD cn LIJ
(0 o \ \� MADERO PHASE 3
_V) CPN 103480
—Xn
�
w r m (PROJECT HAS
__— cn O Z � RECEIVED IPRC PLAN
o Ld
z [If
o J APPROVAL)
o— — —
Q RANCHO CANYON WAY SS11
MATCH LINE A N
Of Q N
bi LLJ W O
O = b
LZLWUQZ
Zcn
2
<
MATCH LINE A
U
F2 } 4 5 a J a 9
19 10 21 22 ] I F
le SAN CLEMENTE z
IJ 1 H
N r 18 1J IB 15 14 I] Ix I 10 Z
N x 6 1] O
O
�A 1S 3 12 I 2 } s 8 J 9 9
BETTEN BRONCO DRIVE
O
0 xJ
8 g
m2 28 2 36
a a 25 ] ]5
0 3
M xa
JF- a
N a O ID 5 x} 5 }]
N a a��� a 22 32 LEGEND
p JP J 21
N 4° GAO e s 10 J ]I
PROPOSED SAN SEWER
�F x a Ro '° 26
6 FLOW DIRECTION
<). Is g.5
3 xJ
GO ,x 2a
18
w e"SS2 a 15'° v 23 '4a��P EXISTING SAN SEWER
f�` n
V) IJ 21 IS 2�°
a 'a 2°�PGZG LIMITS OF PROJECT — —
I41]
cV 12
a y
f�/) J 2�y4 110
p °s
r
a 3 � <9 a a
a x O 2< ]
{� J 8 IB 15 I] 12
'a V� 4.
SENDERA y�P{ NUEVE RANCHO LANE
RANCH ���� ° 5 a J a a WASTEWATER
LO PHASE III-3B ° II
ID CPN 103121/ EXHIBIT A-1
g MADERO
OWNED/DEVELOPED BY: ooNNEc r 70 � ��� PHASE I
e SS GBTM SENDERA, LLC X20232 - CITY PROJECT NO. 103479
2805 North Dallas Parkway, Suite 40 DOSING 18'SS PER PUN
Z Plano, Texas 75093 ���
BOBBY SAMUEL
I PHONE: (469) 573-6755 LJA Engineering, Inc.
i 6060 North Central Expressway Phone 469.621.0710
vi Suite 400
Dallas, Texas 75206 FRN - F-1386
N
m
w SCALE:1" = 500'
z_
RANCHO CANYON WAY J
2
NOT EXISTING
z INFRASTRUCTURE
I w N MADERO PHASE 3
� � <Ld o CPN 103480
Q (PROJECT HAS
w � n z RECEIVED IPRC PLAN
m_� Q o Z v m APPROVAL)
<to � � U � z
w z :2 ry J RANCHO CANYON WAY
Z a_
</ U ,
F .
a MATCH LINE A
N
O < LIJ
Q N
\ C> W Ld O
MATCH LINE A z z U Q
Z w z 2/'� z
19 2° 21 2x 23 O � Q a-
I6 r /\ N
-SAN CLEMENTE a l/ I..L
„
I6 I) la 15 I. 13 Ix 1° LEGEND
, �
s z O
2 ] 5 6 9 Q
" BET TEN BRONCO DRIVE 3 PROPOSED 29'B—B
37 ROADWAY/50'ROW
8 " �': a 25 ]5 PROPOSED 23'B—B
ROADWAY/55'ROW
9 ° 5 (HALF SECTION)
a � zx 3z
20 ,°J1 PROPOSED 55'B—B
o �I 6 �`° x9 ROADWAY/100'ROW
N x 6 O 26
25 PROPOSED SIDEWALK __________J
] " �c
RP\� .:.
a PFF� a 15" x x`�� (BY HOMEBUILDER)
21
N '� xa?APO°�"' 15 `'o PROPOSED SIDEWALK t ��.��--•s„�_,
2 �F (BY DEVELOPER)
Z PROPOSED ADA RAMPS p
a BY DEVELOPER
Q 6 9 1
1< ] O 6 9
N CONNECT TO a a 15 I „ „ LIMITS OF PROJECT —
N
SENDERA
NUEVE RANCHO LANE:':::
RANCH J B
PHASE III-313
Fes...::..
0 CPN 103121 PAVING
EXHIBIT B
(a
0
Z
g MADERO
0
OWNED/DEVELOPED BY: PHASE I
GBTM SENDERA, LLC CITY PROJECT NO. 103479
2805 North Dallas Parkway, Suite 400
z Plano, Texas 75093 ALA
SAMUEL
I PHONE: (469) 573-6755 LJA Engineering, Inc.
i 6060 North Central Expressway Phone 469.621.0710
V) Suite 400
Dallas, Texas 75206 FRN - F-1386
SD19 m
3-4'X4' RCB N
W 1,
Z_
RANCHO CANYON WAY J
I J So SD-2 =
33" RC 24" RC
Q SCALE:1" = 500'
Z
W U
o U cn
bj
z N NOT EXISTING
icn
t — D w CD z INFRASTRUCTURE
xa� cf)
w w I-- Q MADERO PHASE 3
Q a- w CPN 103480
U 0z � U o (PROJECT HAS
z ry RECEIVED IPRC PLAN
" w m APPROVAL)
W SD-5
Z 30" RCP
J RANCHO CANYON WAY SD-13
SD17 =
4-10'X5' RCB U
< SD-12
'-�z :2 a MATCH LINE A 24" RCP
SD-17 SD-11 N
5I : 24" RCP Q m � -
< Q N ro
MATCH LINE A w w O
7 / w
19 10 11 12 13 O = m
1° L2RF. CP (n Q a U
1, 4 a N C M N z (Y
IB I IS I, 18 15 14 13 11 11 111 K
1 13� r
15 3 11� NI 1 3 5 8 8 9 0
rn BE-TEN+ RO C RI a
d 3
`O 13 5 4
u- 17 ' " LEGEND
o ® a 1 1a 1 38 SD-2
SD-3 a ° 3 25 ] ]5 24" RCP PROPOSED STORM
24" RCP 14 SD-2 DRAIN LINE
d of 1] 33
CP
SD-1 ° �.�° 11 5 ,1 30" RCP PROPOSED 10' INLET
N36" RCP ��o aPa ' ° 10 21 ° 30" PROPOSED 15' INLET T
O17 B 8 19
N ° a 1a PROPOSED 3' DROP INLET 4
1,
13 I S 12
PROPOSED 4' DROP INLET
1
a s,G1�R1 5 2°0 24" RCP STORM DRAIN HEADWALL
o SD-4 5 �] 1 �� EXISTING STORM
v~i 36' RCP ° " �n9 SD-8 DRAIN LINE
a \ 05 24" RCP EXISTING INLET /
(„) SD-6 ] (9 9
N42" RCP 1 F , 8 1. 15 ' 13 11
N �Py LIMITS OF PROJECT —
r \ o U R N H
SENDERA N 1
ID
RANCH �PG��F� SD_8 STORM DRAINAGE
PHASE III-3B 30" RCP
CPN 103121 EXHIBIT 'B-l'
LO
ID
00
Z ��0 N
g MADERO
0
OWNED/DEVELOPED BY: PHASE I
GBTM SENDERA, LLC CITY PROJECT NO. 103479
2805 North Dallas Parkway, Suite 400
Z Plano, Texas 75093 ALA
SAMUEL
I PHONE: (469) 573-6755 LJA Engineering, Inc.
i 6060 North Central Expressway Phone 469.621.0710
Suite 400
Dallas, Texas 75206 FRN - F-1386
NOT EXISTING
INFRASTRUCTURE
\ MADERO PHASE 3 N
( CPN 103480
(PROJECT HAS
RECEIVED IPRC PLAN SCALE:1" = 500'
00 APPROVAL)
Ld
z
J RANCHO CANYON WAY
U
MATCH LINE A SENDERA
RANCH EAST
PHASE 24
CPN 103162
m
Ld
z
RANCHO CANYON WAY J
U
Q
MATCH LINE A
1 2 ] 4 5 5 J 9 9 LEGEND
19 90 21 22 ]
Z IB
�—�I� LNv INI /0 17 SAN CLEMENTE STOP SIGN & STREET NAME SIGNS
- D 01. Ld IVf,I 16 ' 4 IB 1J IB 15 I I] 12 I 10
U-z � CO � Lj - 2 6 13 4
—� Q 5 3 2 4 5 5 5 a STREET NAME BLADES ONLY
—(n U = 14z 4 BETTEN BRONCO DRIVE
O w— � (Z � z ,] m s 1a
Z—w 27 ]J PROPOSED STREET LIGHT
10 // O (Z/'� ~ 2 9 2 'e 2 38 (TYPE 11 POLE, TYPE 1
/ Q I..L 9 25 ]5 O
C. LLI U w FOUNDATION)
O LL Li 10 , 3 24 Q
23
°o Z z • 9 ��o 5 2 " 95 ]z PROPOSED STREET LIGHT
M J�Poo9 J „ 20 05�� ]1 (TYPE 18 POLE, TYPE 3
C14ID s �....�./
N ��'�o ' 1B e�5`� 9 '°
0 \ P 1 J�G� 9 29 FOUNDATION)
N
C. 1 z 15 I 10 2B
°°�° „ 14 12" H 2J EXISTING STREET �--
13
25 LIGHT
24
18 2]
IJ 21 22 2
_ 19 10 15
a
F1
14 s LIMITS OF PROJECT
2 13 �9
J
Ld
6
J
Q y
N SENDERA 2 0�2� . 16 15 l4 1] 2 STREET NAME SIGNS &
0) 4.
RANCH
�P{ - , 1 1 1 1 STREET LIGHT
��� NzEVE RANCHO LAN e
PHASE III-313 IMPROVEMENTS
CPN 103121
�P EXHIBIT 'C-l'
L)
U
LO
(O
O
Z
g MADERO
0
OWNED/DEVELOPED BY: PHASE I
GBTM SENDERA, LLC CITY PROJECT NO. 103479
2805 North Dallas Parkway, Suite 400
Z Plano, Texas 75093 ALA
SAMUEL
I PHONE: (469) 573-6755 LJA Engineering, Inc.
i 6060 North Central Expressway Phone 469.621.0710
Suite 400
Dallas, Texas 75206 FRN - F-1386
0042 43
DAP-BID PROPOSAL
Page 1 of4
SECTION 00 42 43
Developer Awarded Projects-PROPOSAL FORM
Madero,Phase 1
UNIT PRICE BID Bidder's Application
Project Item Information Bidder's Proposal
BidlistItem Unit of
Description Specification Section No. Bid Quantity Unit Price Bid Value
No. Measure
UNIT I:WATER IMPROVEMENTS
1 3305.0109 Trench Safety 33 05 10 LF 14930 $1.00 $14,930.00
2 3311.0001 Ductile Iron Water Fittings w/Res 3311 11 TON 10.68 $9,500.00 $101,460.00
3 3311.0241 8"Water Pipe 33 11 10,33 11 12 LF 8929 $46.00 $410,734.00
4 3311.0264 8"PVC Water Pipe,CLSM Backfill 33 11 12 LF 726 $66.00 $47,916.00
5 3311.0541 16"Water Pipe 33 11 10,33 11 12 LF 4699 $120.00 $563,880.00
6 3311.0547 16"Water Pipe,CLSM Backfill 33 11 10,33 11 12 LF 341 $140.00 $47,740.00
7 3311.0551 16"DIP Water 3311 10 LF 1 118 $180.00 $21,240.00
8 3311.0761 30"Steel AWWA C200 Water Pipe 3311 14 LF 117 $465.00 $54,405.00
9 3312.0001 Fire Hydrant 33 1240 EA 21 $4,500.00 $94,500.00
10 3312.3003 8"Gate Valve 33 1220 EA 36 $1,450.00 $52,200.00
11 3312.3006 16"Gate Valve w/Vault 33 1220 EA 10 $18,500.00 $185,000.00
12 3312.1002 2"Combination Air Valve Assembly for Water 33 1230 EA 2 $7,500.00 $15,000.00
13 3312.6002 6"Blow Off Valve 33 1260 EA 2 $12,500.00 $25,000.00
14 3312.4209 24"x 8"Tapping Sleeve&Valve 33 1225 EA 1 1 $10,500.00 $10,500.00
15 3312.4306 30"x 16"Tapping Sleeve&Valve 33 1225 EA 1 $34,500.00 $34,500.00
16 3312.2003 1"Water Service 33 12 10 EA 159 $1,100.00 $174,900.00
17 3312.0107 Connection to Existing 20"Water Main 33 1225 EA 1 $7,500.00 $7,500.00
18 9999.0001 Connection to Existing 8"Water Main 00 00 00 EA 1 $1,000.00 $1,000.00
19 9999.0002 Flush Point 00 00 00 EA 6 $2,500.00 $15,000.00
20 9999.0003 1"Irrigation Service 00 00 00 EA 1 $3,000.00 $3,000.00
21 9999.0004 1.5"Water Service 00 00 00 EA 1 $3,800.00 $3,800.00
22 9999.0005 2"Irrigation Service 00 00 00 EA 1 $4,000.00 $4,000.00
23 9999.0006 4"Irrigation sleeves 00 00 00 EA 12 $800.00 $9,600.00
TOTAL UNIT I:WATER IMPROVEMENTS $1,897,805.00
UNIT II:SANITARY SEWER IMPROVEMENTS
1 3301.0002 Post-CCTV Inspection 3301 31 LF 12163 $4.00 $48,652.00
2 3301.0101 Manhole Vacuum Testing 3301 30 EA 54 $150.00 $8,100.00
3 3305.0109 Trench Safety 3305 10 LF 12163 $2.00 $24,326.00
4 3331.3101 4"Sewer Service 3331 50 EA 160 $800.00 $128,000.00
5 3331.4115 8"Sewer Pipe-SDR 26 33 11 10,3331 12,3331 20 LF 7892 $52.00 $410,384.00
6 3331.4116 8"Sewer Pipe,CSS Backfill 33 11 10,3331 12,3331 20 LF 704 $62.00 $43,648.00
7 3331.4215 10"Sewer Pipe-SDR 26 33 11 10,3331 12,3331 20 LF 1 2709 $60.00 $162,540.00
8 3331.4205 10"DIP Sewer 33 11 10 LF 158 $140.00 $22,120.00
9 3331.4202 10"Sewer Pipe,CSS Backfill 33 11 10,3331 12,3331 20 LF 154 $70.00 $10,780.00
10 3331.4208 12"Sewer Pipe-SDR 26 33 11 10,3331 12,3331 20 LF 524 $68.00 $35,632.00
11 3331.4209 12"Sewer Pipe,CSS Backfill 33 11 10,3331 12,3331 20 LF 22 $78.00 $1,716.00
12 3339.0001 Epoxy Manhole Liner 33 39 60 VF 186 $385.00 $71,610.00
13 3339.1001 4'Manhole 33 39 10,33 39 20 EA 42 $4,000.00 $168,000.00
14 3339.1002 4'Drop Manhole 33 39 10,33 39 20 EA 4 $5,000.00 $20,000.00
15 3339.1003 4'Extra Depth Manhole 33 39 10,33 39 20 VF 244 $195.00 $47,580.00
16 3305.0113 Trench Water Stops 33 05 15 EA 35 $250.00 $8,750.00
17 9990.0008 4'Manhole With Hydraulic Slide 33 39 10 EA 6 $5,500.00 $33,000.00
18 9990.0009 4'Gasketed Manhole With Water-Tight Hinged Cover 33 39 10 EA 2 $6,500.00 $13,000.00
19 9999.0010 Connect to Existing 8"Sewer Main System 00 00 00 EA 1 $2,500.001 $2,500.00
20 9999.0011 Connect to Existing 12"Sewer Main System 00 00 00 EA 1 $3,500.001 $3,500.00
21 9999.0012 Steel Encasement 33 05 24 LF 158 $320.001 $50,560.00
22
TOTAL UNIT II:SANITARY SEWER IMPROVEMENTS $1,314,398.00
CITY OF FORT WORTH
STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS-DEVELOPER AWARDED PROJECTS
Fo=Version May 22,2019 42 43 Bid Proposal_Madero_Phasel(22.4.7)_SIGNED.xlsx
0042 43
DAP-BID PROPOSAL
Page'of 4
SECTION 00 42 43
Developer Awarded Projects-PROPOSAL FORM
Madero,Phase 1
UNIT PRICE BID Bidder's Application
Project Item Information Bidder's Proposal
BidlistItem Unit of
Description Specification Section No. Bid Quantity Unit Price Bid Value
No. Measure
UNIT III:DRAINAGE IMPROVEMENTS
1 3305.0109 Trench Safety 3305 10 LF 9406 $1.00 $9,406.00
2 3305.0112 Concrete Collar 33 05 17 EA 2 $500.00 $1,000.00
3 3341.0201 21"RCP,Class III 3341 10 LF 1108 $60.00 $66,480.00
4 3341.0205 24"RCP,Class III 3341 10 LF 3743 $70.00 $262,010.00
5 3341.0208 27"RCP,Class III 3341 10 LF 254 $75.00 $19,050.00
6 13341.0302 30"RCP,Class III 3341 10 LF 782 $80.00 $62,560.00
7 3341.0302 33"RCP,Class III 3341 10 LF 1 903 $100.00 $90,300.00
8 3341.0302 36"RCP,Class III 3341 10 LF 849 $115.00 $97,635.00
9 3341.0302 42"RCP,Class III 3341 10 LF 79 $145.00 $11,455.00
10 3341.1102 4x3 Box Culvert 3341 10 LF 789 $215.00 $169,635.00
11 3341.1103 4x4 Box Culvert 3341 10 LF 357 $245.00 $87,465.00
12 3341.1501 8x4 Box Culvert 3341 10 LF 228 $475.00 $108,300.00
13 3341.1602 9x5 Box Culvert 3341 10 LF 114 $600.00 $68,400.00
14 3341.2002 10x5 Box Culvert 3341 10 LF 1 200 $700.00 $140,000.00
15 3349.5001 10'Curb Inlet 33 49 20 EA 22 $3,400.00 $74,800.00
16 3349.6001 10'Recessed Inlet 33 49 20 EA 18 $4,400.00 $79,200.00
17 3349.5002 15'Curb Inlet 33 49 20 EA 6 $4,400.00 $26,400.00
18 3349.5003 20'Curb Inlet 33 49 20 EA 2 $5,400.00 $10,800.00
19 9999.00XX 3'Drop Inlet 00 00 00 EA 2 $5,000.00 $10,000.00
20 3349.7001 4'Drop Inlet 33 49 20 EA 1 $5,500.00 $5,500.00
21 3349.0001 4'Storm Junction Box 33 49 10 EA 20 $4,500.00 $90,000.00
22 3349.0002 5'Storm Junction Box 33 49 10 EA 3 $6,000.00 $18,000.00
23 3137.0102 Large Stone Type"A"Dry Rip Rap(12"Deep) 31 3700 Sy 1473 $105.00 $154,665.00
24 3137.0102 Large Stone Type"A"Dry Rip Rap(24"Deep) 31 3700 Sy 3787 $155.00 $586,985.00
25 19999.0013 24"4:1 Sloped End Headwall 00 00 00 EA 2 $3,500.00 $7,000.00
26 9999.0014 30"4:1 Sloped End Headwall 00 00 00 EA 2 $4,500.00 $9,000.00
27 9999.0015 36"4:1 Sloped End Headwall 00 00 00 EA 1 $5,500.00 $5,500.00
28 9999.0016 42"4:1 Sloped End Headwall 00 00 00 EA 1 $6,500.00 $6,500.00
29 9999.0017 33"6:1 Sloped End Headwall 00 00 00 EA 1 $5,000.00 $5,000.00
30 9999.0018 TXDOT PW-1 Wingwall 00 00 00 EA 2 $31,000.00 $62,000.00
31 9999.0019 TXDOT PW-1 Wingwall With 3.9'Extended Curb 00 00 00 EA 2 $48,000.00 $96,000.00
32 9999.0020 TXDOT SW-0 Wingwall 00 00 00 EA 3 $14,500.00 $43,500.00
33 9999.0021 Inlet Protection 00 00 00 EA 51 $150.00 $7,650.00
34 9999.0022 Remove 21"RCP 00 00 00 LF 2 $25.00 $50.00
35 9999.0023 Remove 10'Inlet 00 00 00 EA 1 $1,500.00 $1,500.00
36 9999.0024 Remove RIP RAP 00 00 00 Sy 34 $25.001 $850.00
TOTAL UNIT III:DRAINAGE IMPROVEMENTS $2,494,596.00
CITY OF FORT WORTH
STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS-DEVELOPER AWARDED PROJECTS
Fo=Version May 22.2019 42 43 Bid Proposal_Madero_Phasel(22.4.7)_SIGNED.xlsx
00 42 43
DAP-BID PROPOSAL
Page 3 of4
SECTION 00 42 43
Developer Awarded Projects-PROPOSAL FORM
Madero,Phase 1
UNIT PRICE BID Bidder's Application
Project Item Information Bidder's Proposal
Bidlist Item Description Specification Section No. Unit of Bid Quantity Unit Price Bid Value
No. Measure
UNIT IV:PAVING IMPROVEMENTS
1 0241.1000 Remove Conc Pvmt 0241 15 SY 522 $20.00 $10,440.00
2 3211.0400 Hydrated Lime(30 Ibs/sy) 32 11 29 TN 486.18 $190.00 $92,374.20
3211.0400 Hydrated Lime(36 Ibs/sy)(Sendera Ranch Blvd& 32 11 29
3 Rancho Canyon way) TN 644.27 $190.00 $122,411.30
4 3211.0501 6"Lime Treatment 3211 29 SY 32412 $3.50 $113,442.00
5 3211.0502 8"Lime Treatment(Sendera Ranch Blvd&Rancho 32 11 29 SY
Canyon Way) 35793 $4.00 $143,172.00
6 13212.0101 6"Conc Pvmt 32 13 13 SY 1 30402 $39.50 $1,200,879.00
3213.0105 10"Conc Pvmt(Sendera Ranch Blvd&Rancho Canyon 32 13 13
7 SY Way) 34350 $68.00 $2,335,800.00
8 3213.0301 4"Conc Sidewalk 32 13 20 SF 122939 $3.50 $430,286.50
9 3213.0501 Barrier Free Ramp,Type R-1 32 13 20 EA 6 $1,800.00 $10,800.00
10 3213.0506 Barrier Free Ramp,Type P-1 32 13 20 EA 38 $1,500.00 $57,000.00
11 3291.0100 Topsoil 3291 19 CY 3664 $24.00 $87,936.00
12 3292.0100 Block Sod Placement 32 92 13 SY 1 21985 $8.00 $175,880.00
13 9999.0025 Construct Type III Barricade 00 00 00 EA 5 $500.00 $2,500.00
14 9999.0026 Construct Std.Pvmt.Header 00 00 00 LF 163 $20.00 $3,260.00
15 9999.0027 Stop Signs(R1-1) 00 00 00 EA 20 $750.00 $15,000.00
16 9999.0028 Street Name Blade(133-1) 00 00 00 EA 38 $200.00 $7,600.00
17 9999.0029 Street Sign Pole 00 00 00 EA 22 $250.00 $5,500.00
18 9999.0030 Remove Barricade&Connect to Existing Pavement 00 00 00 EA 2 $500.00 $1,000.00
19 9999.0031 Remove Abandoned Gas line 00 00 00 LF 1 3738 $40.00 $149,520.00
20 9999.0032 Lane Legend Arrows 00 00 00 EA 23 $450.00 $10,350.00
21 9999.0033 TYPEII-A-A 4"RPM 00 00 00 EA 216 $5.00 $1,080.00
22 9999.0034 TYPE I-C 4"RPM 00 00 00 EA 262 $5.00 $1,310.00
23 9999.0035 REFL PAV MIRK TY I(W)(6")(SNG)(SLD) 00 00 00 LF 950 $4.00 $3,800.00
24 9999.0036 REFL PAV MIRK TY I(Y)(6")(SNG)(SLD) 00 00 00 LF 5483 $4.00 $21,932.00
25 9999.0037 REFL PAV MIRK TY I(Y)(6")(DBL)(SLD) 00 00 00 LF 3140 $6.00 $18,840.00
26 9999.0038 REFL PAV MIRK TY I(W)(6")(SNG)(BRK) 00 00 00 1 LF 2060 $4.00 $8,240.00
27 9999.0038 REFL PAV MIRK TY I(Y)(6")(SNG)(BRK) 00 00 00 LF 1320 $4.00 $5,280.00
9999.0039 REFL PAV MIRK TY I(W)(24")(SNG)(SLD)With 00 00 00
28 I(B)(6")(DBL)(SLD)Crosswalk EA 8 $1,800.00 $14,400.00
29 9999.0040 REFL PAV MIRK TY I(W)(24"(SNG)(SLD)Stop Bar 00 00 00 LF 31 $20.00 $620.00
TOTAL UNIT IV:PAVING IMPROVEMENTS $5,050,653.)0
CITY OF FORT WORTH
STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS-DEVELOPER AWARDED PROJECTS
Form Version May 22,2019 42 43_Bid Proposal_Madero_Phmel(22.4.7)_SIGNED.xlsx
0042 43
DAP-BID PROPOSAL
Page 4 of 4
SECTION 00 42 43
Developer Awarded Projects-PROPOSAL FORM
Madero,Phase 1
UNIT PRICE BID Bidder's Application
Project Item Hrforalation Bidder's Proposal
BidlistItem Unit of
Description Specification Section No. Bid Quantity Unit Price Bid Value
No. Measure
UNIT V:STREET LIGHTING IMPROVEMENTS
1 2605.3015 2"CONDT PVC SCH 80(T) 26 05 33 LF 9484 $12.00 $113,808.00
2 3441.3201 LED Lighting Fixture(50W) 3441 20 EA 47 $600.00 $28,200.00
3 3441.3201 LED Lighting Fixture 138W 3441 20 EA 34 $800.00 $27,200.00
4 3441.1633 Install Type 33B Arm 3441 20 EA 47 $500.00 $23,500.00
5 3441.1632 Install Type 33A Arm 3441 20 EA 34 $450.00 $15,300.00
6 3441.3002 Rdwy Ilium Assembly TY 8,11,D-25,and D-30 3441 20 EA 47 $2,200.00 $103,400.00
7 3441.3003 Rdwy Ilium Assembly TY 18,18A,19,and D-40 3441 20 EA 34 $3,400.00 $115,600.00
8 3441.3301 Rdwy Ilium Foundation TY 1,2,and 4 3441 20 EA 47 $1,000.00 $47,000.00
9 3441.3302 Rdwy Ilium Foundation TY 3,5,6,and 8 3441 20 EA 34 $1,500.00 $51,000.00
10 9999.0041 Ground Box 00 00 00 EA 19 $950.00 $18,050.00
11 9999.0042 3-#10 Copper Wire 00 00 00 LF 3215 $4.00 $12,860.00
12 9999.0043 3-#2 Copper Wire 00 00 00 LF 6269 $6.00 $37,614.00
TOTAL UNIT V:STREET LIGHTING IMPROVEMENTS $593,532.00
Bid Summary
UNIT I:WATER IMPROVEMENTS $1,897,805.00
UNIT II:SANITARY SEWER IMPROVEMENTS $1,314,398.00
UNIT III:DRAINAGE IMPROVEMENTS $2,494,596.00
UNIT IV:PAVING IMPROVEMENTS $5,050,653.00
UNIT V:STREET LIGHTING IMPROVEMENTS $593,532.00
Total Construction Bid $11,350,984.00
This Bid is submitted by the entity named below:
BIDDER: BY:BRO(K IP-;GINS
(ONATSER(ONSTRV(TION TX,L.P.
-327 RI(HITA ST. y,WA==
FORT R ORTH,TT 76119 TITLE:PRESIDENT
DATE:
Contractor agrees to complete WORK for FINAL ACCEPTANCE within 350 working days after the date when the
CONTRACT commences to run as provided in the General Conditions.
END OF SECTION
CITY OF FORT WORTH
STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS-DEVELOPER AWARDED PROJECTS
Fonn Version May 22,2019 42 43 Bid Proposal_Madero_Phasel(22.4.7)_SIGNED.xlsx