The URL can be used to link to this page

Home My WebLink AboutContract 56281-PM1CSC No. 56281-PM1 00 00 00 STANDARD CONSTRUCTION SPECIFICATION DOCUM�NTS SECTION 00 00 10 TABLE OI' CONTENTS DEVELOPER AWARDED PROJECTS Division 00 - General Conditions Page 1 of 6 Tact Reviserl nn�� r�.,:+.,,;,,r «,. �:,aa�„� n� i��n nn� n� ��mrcvrcozv 00 41 00 Bid Form 04/02/2014 00 42 43 Pro osal Form Unit Price OS/22/2019 00 43 13 Bid Bond d4/02/2014 00 45 11 Bidders Pre ualification's 04/02/2014 nnQ ��z nnin�� n� n� m�� 00 45 26 Contractor Com liance with Workers' Com ensation Law 04/02/2014 nn�9 �rnz'�-,�� 00 52 43 A reement 06/16/2016 00 61 25 Certificate of Insurance 07/O1/2011 00 62 13 Performance Bond O1/31/2012 00 62 14 Pa ment Bond O1/31/2012 00 62 19 Maintenance Bond O1/31/2012 00 72 00 General Couditions 11/15/2017 00 73 00 Su lementa Conditions 07/O1/2011 00 73 10 Standard City Conditions of the Construction Contract for Developer O1/10/2013 Awarded Pro�ects Division O1- General Re uirements Last Revised n ��no � � ��r�r�vrivii Ol 25 00 Substitution Procedures 08/30/2013 O1 31 19 Preconstruction Meetin 08/30/2013 n i� n� in��rr O1 32 33 Preconstruction Video 0$/30/2013 O1 33 00 Submittals 08/30/2013 ni� nQi�o nrn �� O1 45 23 Testin and Ins ection Services 03/20/2020 O1 50 QO Tem or Facilities and Controls 07/O1/2011 O1 55 26 Street Use Permit and Modifications to Traffic Control 07/OU2011 01 57 13 Storm Water Pollution Prevention Plan 07/O1/2011 Ol 60 00 Product Re uirernents 03/20/2020 O1 66 00 Product Stora e and Handlin Re uirements 04/07/2014 �,e� r�,.�.;i:,,,+:,.� ..�a n„w.,.i..:i:.,,.�:,,� nnin�T Ol 71 23 Construction Stakin 04/07/2014 O1 74 23 Cleanin 04/07/2014 U1 77 19 Closeout Re uirements 04/07/2414 n ioz-;-��',� �n in��, O1 78 39 Pro�ect Record Documents 04/07/2014 CI'TY OF FORT WOR'fH LA FRONTERA - PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS-DEVELOPER AWARDED PROJECT CITY PROJN0.:1028ll Revised March 20, 2020 00 00 00 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS Page 2 of 6 Technical Specifications which have been modified by the Engineer specifically for this Project; hard co�ies are included in the Project's Contract Documents NON]E CITY OP FOR7' WORTI-I LA FRONTERA - PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS—DEVELOPER AWARDED PRO.IECT CITY PROJN0.:102811 Revised March 20, 2020 00 00 00 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS Page 3 of 6 Technical Specifcations listed below are included for this Project by reference and can be viewed/downloaded from the City's website at: http://fortworthtexas.�ov/tpw/contractors/ or httns://at�ps.f��rt��orthtcxas.�ov/Nroiectltcsourccs/ Division 02 - Existin Conditions n��-^� vcicc� „ C'*o Tle ,.1'�:,... 02 41 14 Utili Removal/Abandonment 02 41 15 Pavin Removal Division 03 - Concrete Division 26 - Electrical Last Revised 77/7� 12/20/2012 02/02/2016 �b-A�-89 r,......,,.., �x�,...t. v„�..i«.. � _ �t,,,.«..:,.,,t > > i�-r-n- ��;� 26 OS 10 Demolition for Electrical S stems 12/20/2012 26 OS 33 Racewa s and Boxes for Electrical S stems 12/20/2012 26 OS 43 Under round Ducts and Racewa s for Electrical S stems 07/O1/2011 ��o r�,.....�.,..,:,.,,+:,.�� r�„t«; r�..,.� r,...a..:, n�i�o �� Division 31 - Earthwork 31 10 00 Site Clearin 12/20/2012 31 23 16 Unclassified Excavation O1/28/2013 31 23 23 Borrow O1/28/2013 31 24 00 Embankments O1/28/2013 3 I 25 00 Erosion and Sediment Control 12/20/2012 31 36 00 Gabions 12/20/2012 31 37 00 Ri ra 12/20/2012 Division 32 - Exterior Im rovements �--A-�-� , � ��-�;i �'� � � i�z��o.; i 32 O1 29 Concrete Pavin Re air 12/20/2012 �� io.,:wt„ n,.�„ r,,,,..�,.., i�i�z�i 32 11 29 Lime Treated Base Courses 12/20/2012 32 11 33 Cement Treated Base Courses 12/20/2012 32 11 37 Li uid Treated Soil Stabilizer 08/21/2015 � �� ,�.o , � �� ;z �� , -, ��z 32 13 13 Concrete Pavin 12/20/2012 32 13 20 Concrete Sidewalks, Drivewa s and Barrier Free Ram s 06/OS/2018 32 13 73 Concrete Pavin Joint Sealants 12/20/2012 �'� , � ��,z,�;''� 32 16 13 Concrete Curb and Gutters and Valle Gutters ]0/OS/2016 CITY OF FORT WORTH LA FRONTERA - PHASE 3 STANDARD CONS1'RIJCTION SPECIFICATION DOCUMF,NTS-DEVELOPER AWARDED PROJECT CITY PROJ.N0.:102811 Revised March 20, 2020 00 00 00 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS Page 4 of 6 32 17 23 Pavement Markin s 11/22/2013 2'��z. �T7 c� i 7 rn�z�_v�cvrl �� r�i.,,:� �,,.,,,,,n ,...a r +o., ,�»�z 27}z�Z—�i-Gv 'sx�;..o Re.,,.e� .,�,a r.,+�� 7h_rc,zv;i�iz 2'�� x7.....� L'.,.,..,�.� ...,..7 !'_..+.,.. 7 7/7�T Il /cvriv iz '2 ^f��, gti /!1 Svrv�iivi,4v 32 91 19 To soil Placement and Finishin of Parkwa s 12/20/2012 32 92 13 H dro-Mulchin , Seedin , and Soddin 12/20/2012 �,3� rr..,,�� .,�,a c�....,i.n i�i�rz,- ��z Division 33 - Utilities 33 Ol 30 Sewer and Manhole Testin 12/20/2012 33 O1 31 Closed Circuit Television CCTV Ins ection 03/03/2016 � ��o , � i�-�,zo�� o i � i��i ��- r�,,...-,,.,;�� r,.�+..,.� rr,,,,+c*.,�;,.,,� i�i��, n�? � ��z i � r��z 33 04 30 Tem ora Water Services 07/O1/2011 33 04 40 Cleanin and Acce tance Testin of Water Mains 02/06/2013 33 04 50 Cleanin of Sewer Mains 12/20/2012 33 OS 10 Utili Trench Excavation, Embedment, and Backfill 12/12/2016 33 OS 12 Water Line Lowerin 12/20/2012 33 OS 13 Frame, Cover and Grade Rin s- Cast Iron Ol/22/2016 33 OS 13.10 Frame, Cover and Grade Rin s- Com osite O1/22/2016 33 OS 14 Adjusting Manholes, Inlets, Valve Boxes, and Other Structures to 12/20/2012 Grade � �� r,.r,.v,+� «�.,+�.. t �...,i,.� i � i��i 33 OS 17 Concrete Collars 12/20/2012 �3-A�-�9 , � ��z 2'2� T,,...-..,1 T:«,.« D1.,4„ 7 7/'7�z 33 OS 22 Steel CasinQ Pi e 12/20/2012 �� n� , � i��i 33 OS 24 Installation of Carrier Pi e in Casin or Tunnel Liner Plate 06/19/2013 33 OS 26 Utili Markers/Locators 12/20/2012 33 OS 30 Location of Existin Utilities 12/20/2012 33 11 OS Bolts, Nuts, and Gaskets 12/20/2012 33 11 10 Ductile Iron Pi e 12/20/2012 33 11 11 Ductile Iron Fittin s 12/20/2012 33 11 12 Pol vin 1 Chloride PVC Pressure Pi e 11/16/2018 �� t t t� i�i�ni�ni� T�7 , , -rzravrco-rc 22� 17N�z 33 12 10 Water Services 1-inch to 2-inch 02/14/2017 2 �� ,�T , � ��,z,z�vzz 33 12 20 Resilient Seated Gate Valve 12/20/2012 33 12 21 AWWA Rubber-Seated Butterfl Valves 12/20/2012 33 12 25 Connection to Existin Water Mains 02/06/2013 33 12 30 Combination Air Valve Assemblies for Potable Water S stems 12/20/2012 33 12 40 Fire H drants O1/03/2014 33 12 50 Water Sam le Stations 12/20/2012 CI1'Y OF FORT WORTH LA PRONT�RA - PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS-DEVELOPER AWARDED PROJECT CITY PROJ.N0.:102811 Revised March 20, 2020 00 00 00 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS Page 5 of 6 CITY OF FOR"I' WORTH LA FRON'CGRA - PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS—DEVELOPER AWARDED PROJECT CITY PROJ.N0.:102811 Revised March 20, 2020 00 00 00 STANDARD CONSTRUCTION SPECIFICATION DOCUM�NTS Page 6 of 6 Appendix �r�-^�-. o o T� ,a sc�-�-m-�nne�1�-C-e��,-�� GC-6.09 Permits and Utilities (TXDOT — Right Turn Lane) r�'' b:z4—��e��c-�i�rixit�ie�r GR-01 60 00 Product Requirements END OF SECTION CITY OF FORT WORTH LA FRONTERA - PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS—DEVELOPER AWARDED PROJECT CITY PROJN0.:102811 Revised March 20, 2020 UTILITY/PAVING CONTRACT FORMS A'LURE GENERAL CONTRACTC�RS LLC 00 41 00 DAP BID FORM FOR PUBLICLY BID PROJECTS ONLY Page 1 of 3 SECTION 00 4100 DAP BID FORM FOR PUBLICLY F3ID PROJECTS ONLY TO: g.AFRONTERr� DEVELOPMEN�' I�I�C �000 lY`iAtili %1�Liic.p �Vld� boo GRAPEYIPTE, T"�Xt�S 76051 �. . � .. . . �. �,.. � � • , ,� • � �,• �, City Project 102811 No.. Units/Sections: PAVING, Dp2AINAGE, SEWER, WATEIt IlVIPROVEMENTS 1. Enter Into Agreement The undersigned Bidder proposes and agrees, if this Bid is accepted, to enter into an Agreement with Developer in the form included in the Bidding Documents to perform and furnish all Work as specified or indicated in the Contract Documents for the Bid Price and within the Contract Time indicated in this Bid and in accordance with the other terms and conditions of the Contract Documents. 2. BIDDER Acknowledgements and Certification 2.1. In submitting this Bid, Bidder accepts all of the terms and conditions of the INVITATION TO BIDDERS and INSTRUCTIONS TO BIDDERS, including without limitation those dealing with the disposition of Bid Bond. 22. Bidder is aware of all costs to provide the required insurance, will do so pendang contract award, and will provide a valid insurance certificate meeting all requirements in the construction contract. 23. Bidder certifies that this Bid is genuine and not made in the interest of or on behalf of any undisclosed individual or entity and is not submitted in conformity with any collusive agreement or rules of any group, association, organization, or corporation. 2.4. Bidder has not directly or indirectly induced or solicited any other Bidder to submit a false or sham Bid. 2.5. Bidder has not solicited or induced any individual or entity to refrain from bidding. 2.6. Bidder has not engaged in corrupt, fraudulent, collusive, or coercive practices in competing for the Contract. For the purpases of this Paragaph: a. "corrupt practice" means the oifering, giving, receiving, or soiiciting of anything of value likely to influence the action of a public official in the bidding process. b. °'fraudulent practice" means an intentional misrepresentation of facts made (a} to influence the bidding process to the detriment of Developer (b) to establish Bid prices at CITY OF FORT WORTH STANDARD CONSTRUCTION BID FORM — DEVELOPER AWARDED PROJECTS 0� 4100 Bid Form — DAP.docx Form Revised April 2, 2014 0o ai o0 DAP BID FORM FOR PUBLiCLY BID PROJECTS ONLY Page 2 of 3 artificial non-competitive levels, or (c) to deprive Developer of the benefits of free and open competition. c. "collusive practice" means a scheme or arrangement between two or more Bidders, with or without the knowledge of Developer, a purpose of which is to establish Bid prices at artifcial, non-competitive levels. d. "coercive practice" means harming or threatening to harm, directly or indirectly, persons or their property to influence their participation in the bidding process or affect ttie execution of the Contract. 3. PrequaLification The Bidder acknowledges that the following work types must be performed only by prequalified contractors and subcontractors: a. �VATER b. SAlYITARY SE�4'ER c. DRAIIVAGE d. STItEE1' P�iVENIENT 4. Time of Completion 4.1. The Work will be complete for Final Acceptance within 90 working days after the date when the Contract Time commences to run as provided in the General Conditions. 4.2. Bidder accepts the provisions of the Agreement to liquidated damages, if applicable, in the event of failure to cornplete the Work {and/or achieve�r►ent of Milestones} within the times specified in the Agreement. 5. Attached io #his Bid The following documents are attached to and made a part of this Bid: a. This Bid Form, Section 00 41 00 b. Bid Bond (if required), Section 00 43 13 issued by a surety meeting the requirements of the General Conditions. c. Proposal Form, Section 00 42 43 d. MBE Forms (if reyuired) e. Prequalification Statement, Section 00 45 12 f. Any additional documents that may be required by Section 12 of the Instructions to Bidders g. Bidder pre-qualification application (optional) 6. T'o#al Bid Amount 6.1. Bidder will complete the Work in accordance with the Contract Documents for the following bid amount. In the space provided below, please enter the total bid aznount for this project. Only this figure will be read publicly by the City at the bid opening. 6.2. It is understood and agreed by the Bidder in signing this proposal that the total bid amount entered below is subject to verification andlor modifcation by multiplying the unit bid prices for each pay item by the respective estimated quantities shown in this proposal and then totaling all of the extended amounts. 63. Evaluation of Alternate Bid Items <use this if applicable, otherwise delete> CITY OF FORT WORTH STANDARD CONSTRUCTION BID FORM— DEVEIOPER AWARDED PROIECTS 004100 Bid Form— DAP.docx Form Revised April 2, 2014 ' 00 4 { 00 DAr BIB FORPf f'(2R PUBLfC4Y BID PRQ/ECTS QVLY Page 3 of3 6.3. Evaluation of Alternate Bia lte�ns <use this ifapplicable, othenvise deleY� Total Base Bid $1,398,408.96 Alternate Bid Deductive Alternate Additive Alternate TOTAL �3�D $1,398,408.96 9> Bi� Suhmithl 'F7�is Bid is submitted on (Ni/23/2021 by the entity named belaw Respecifully submitted, By: (S�atu�C) '+r� �.� _ (Prnood Alame) Title: l�ft f��t�1.,1 �_ �'i"afe nr Offioe.� Co$►paay: A'�ur� General Contractors �� • Address: 6iiC1 Baulevard 26 <Addness > �ddress ifapplicaUle, od�r�vis� deiete> Rschland Hillt, TX 761�w1 �+h', Stste. Zip e'-ode> Siate of Texas Incorporation: �mai1: brad(aacadiatx.wiu ..�,._.e Phone; f 17-729-2581 END OF SECTION Receipt is acknowledged of Init�ial the foibwitig Adde�sdi: Addendum No. 1 AAdendtgt; No. 2 Addendum No. 3 Addendum No. 4 an ot wRr woxrN STANDAHD COWSjpUCT10N &D FORG9 — DEYEL09ER AWAROED 7AD1EC75 OD 6100 Bid Form — DA9,Aoc[ Fmm Nedsed Ayril 2, 2014 ' 00 42 43 BID PROP�SAL FORM 00 42 43 DAP - BID PROPOSAL Page I of 7 SECTION 00 42 43 Developer Awarded Projects - PROPOSAL FORM LA FRONTERA - PHASE 3 UNIT PRICE BID 7/7/2021 IPRC21-0004 CPN: 102811 Bidder's Application Project Item Information Bidder's Proposa] Bidlist Item Descri tion Specification Unit of Bid No. p Section No. Measure Quantity Unit Price Bid Value UNIT I: WATER IMPROVEMENTS I-1 331 LO161 6" Water Yipe 33 11 12 LF 32 � 38.52 $1,232.64 i-2 3311.0261 8" WaterPipe 33 11 12 LF 3,548 $ 46.01 $163,243.48 i-3 3311.0441 12" WaterPipe 33 11 12 LF 324 $ 77.04 $24,960.96 1-4 3312.3002 6" Gate Valve 33 12 20 EA 4 $ 1,189.84 $4,759.36 1-5 3312.3003 8" Gate Valve 33 12 20 EA 8 $ 1,979.50 $15,836.00 1-6 9999.0001 Remove existing 12" water line 33 1? 10 LF 20 $ 21.40 $428.00 1-7 3312.0117 Connect. to Existing 4"-12" Water Main 33 12 25 EA 3 $ 3,747.14 $11,241.42 1-8 3312.000] Fire Hydrant 33 12 40 EA 4 $ 4,202.96 $16,8] 1.84 1-9 331 I.0001 Ductile Iron Water Fittings 33 11 11 TON 3 $ ]0,029.11 $30,087.33 1-10 3305.0109 Trench Safery 33 OS 10 LF 3,904 $ 1.50 $5,856.00 1-11 3312.2003 I" WaterService 33 12 ]0 EA 80 $ 1,163.09 $93,04720 TOTAL UNIT I: WATER IMPROVEMENTS $367,504.23 CITY OF FORT WORTH STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS - DEVELOPER AWARDED PROJECTS Form Version April 2, 2014 00 42 43 - B1D IJNITS - PHASE 3- 07-07-21.x1s 00 42 43 DAP-BID PROPOSAL Page 2 of 7 SECTION 00 42 43 Developer Awarded Projects - PROPOSAL FORM LA FRONTERA - PHASE 3 UNIT PRICE BID 7/7/2021 IPRC21-0004 CPN: 102811 Bidder's Application Project Item Information Bidder's Proposal Bidlist Specification Unit of Bid Item Description Unit Price Bid Value No. Section No. Measure Quantity UNIT II: SANITARY SEWER IMPROVEMENTS 2-I 3331.41 I> 8" Sewer Yipe 33 31 20 LP' 3,035 $ 41.73 $126,650.55 2-2 3331.41 ] 6 S" Sewer Pipe, CSB Backfill 33 11 10 LF 90 $ 68.48 $6,163.20 2-3 3339.1001 4' Manhole 33 39 20 EA 17 $ 3,814.55 $64,847.35 2-4 3339. ]002 4' Drop Manhole 33 29 20 EA 2 $ 5,652.81 $11,305.62 2-5 3339.1003 4' Extra Depth Manhole 33 39 20 VF 39 $ 216.14 $8,429.46 2-6 33313101 4" Sewer Service, Two-way cleanout 33 31 50 EA 80 $ 73723 $58,978.40 2-7 3301.0002 Post-CCTV Inspection 33 O1 31 LF 3,125 $ 2.00 $6,250.00 2-8 3301.0101 Manhole Vacuum Testing 33 Ol 30 EA 19 $ ] 94.74 $3,700.06 2-9 3339.0001 Epoxy Manhole Liner 33 39 60 VF 56 $ 354.17 $19,833.52 2-10 3305.0109 Trench Safety 33 OS 10 LF 3,125 $ 1.50 $4,687.50 2-11 9999.0002 Connect to Existing Sanitary Sewer Main 33 I 1]0 EA 4 $ 1,926.00 $7,704.00 TOTAL UNIT II: SANITARY SEWER IMPROVEMENTS $318,549.66 CITY OF FORT WORTH STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS - DEVELOPER AWARDED PROJECTS Form Version April 2, 2014 00 42 43 - BID UMTS - PHASE 3- 07-07-21.x1s 00 42 43 DAP - BID PROPOSAL Page 3 of 7 SECTION 00 42 43 Developer Awarded Projects - PROPOSAL FORM I,A FRONTERA - PHASE 3 UNIT PRICE BID 7/7/zozl IPRC21-0004 CPN: ]02811 Bidder's Application Project Item Information Bidder's Proposal Bidlist [tem Description Specification Unit of B�d Unit Price Bid Value No. Section No. Measure Quantity UNIT III: DRAINAGE IMPROVEMENTS 3-I 9999A003 "french Safety 33 OS 10 LF 4U7 � 6.60 $2,68620 3-2 3341.0302 30 RCP, Class III 33 41 10 LF 1?� $ 137.00 $16,440.00 3-3 3341.0205 24" RCP, Class III 33 41 10 I.F ?87 $ 110.17 $31,618.79 3-4 3349.5003 20' Curb Inlet 33 49 20 EA ? $ 8,615.64 $17,231.28 3-5 3349.5001 10' Curb Inlet 33 49 20 EA ? $ 5,649.60 $11,299?0 3-6 3349.0001 4' S[onn Junction Box 33 49 ]0 EA ? $ 4,166.58 $8,333.16 3-7 3349.3005 30" CH-FW-Q TXDOT 33 49 40 EA � $ 2,259.84 $2,259.84 3-8 3137.0102 Large Stone, Riprap, dry (24"/6") 31 37 00 SY 8� $ 145.38 $11,630.40 TOTAL UNIT III: DRAINAGE IMPROVEMENTS $101,498.87 CITY OF FORT WORTH STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS • DEVELOPER AWARDED PROJECTS Form Version April ?, 2014 00 42 43 - BID UMTS - PHASE 3- 07-07-21 xls 00 42 43 DAP - Bm PROPOSAL Page 4 of 7 SECTION 00 42 43 Developer Awarded Projects - PROPOSAL FORM LA FRONTERA - PHASE 3 UNIT PRICE BID 7/7/2021 IPRC21-0004 CPN: 102811 Bidder's Application Project Item Information Bidders Proposal Bidlist Item Description Specification Unit of B�d Unit Price Bid Value No. Section No. Measure Quantity UNIT IV: PAVING IMPROVEMENTS d-1 3313.0101 6" Conc Yvmt 32 13 13 SY 6,880 �d1.2� �283,800.00 4-3 3211.0501 6" Lime Treatment 32 11 29 SY 7,314 $3.18 $23,258.52 4-3 3211.0400 Hydrate Lime 32 11 29 TN >> � $192.00 $21,120.00 4-4 3213.0102 7" Conc Pvmt 32 13 13 SY 4,838 $46.07 $222,886.66 4-5 3211.0502 8"LimeTreatment 321129 SY 5,�?� $3.73 $19,097.60 4-6 9999.0004 Hydrate Lime 32 I1 29 TN ��3 $192.04 $19,780.12 4-7 3213.0301 4" Concrete Sidewalk (5-foot width) 32 13 20 SF �5� $8.34 �1,251.00 4-8 3213.0506 Barrier Free Ramp - Type P-1 32 13 20 EA 4 $1,785.90 $7,143.60 4-9 9999.00OS Barrier Free Ramp - Type P-1 (Modified) 32 ] 3 ZO EA 4 $1,86024 $7,440.96 4-10 3441.4003 Fumish & Install Ground Mount post w/Stop & 34 41 30 EA 4 $416.09 $1,664.36 Directive Si ns 4-1 1 9999.0006 Street Name Plates for Street Intersection (4-blades) 34 41 30 EA � 6 $44.59 $713.44 4-12 9999.0007 Street barricade (street dead ends) 31 36 00 LF 90 $30.03 $2,702.70 TOTAL UNIT IV: PAVING IMPROVEMENTS $610,858.96 CITY OF PORT WORTH STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS - DEVELOPER AWARDED PROJEC7'S Form Version April 2, 2014 00 42 43 - BID UNITS - PHASE 3- 07-07-21.x1s 00 42 43 DAP - 61D HLOPOSAL Page I of I SECTIUN 04 42 43 Devebper Awarded Projects - PROPOSAL FORM LA FRQNI'ERA - PHASE 3 IPRC21-OOOd CPN: 10281i 7!7/ll �" Bid Summa UN1T I: WATER IMPROVEAREN'fS UN(T II: SANITARY SEWER IMPROVEMENTS UNIT ill: DRAI►JAGE IMPROVEMENTS UNIT IV; PAVING IMPROVEMENTS UN1T V: STREET LIGHTING IMPROVEMENTS �-;t'' . • • �,�' ._^ ,_ $367,504.23 $318,549.66 $101,496.11 Bid Conhactor agrees to complete WORK for 1FINAL ACCEPTANCE withio CONTRAGT commmces to nin as provided in /be G�eral Condilions. END OF SECTION CITY OFFORT WORTH SI'ANDARD CONStRUCC[ON SPE�FiCATlON �OCUMENTS • DEVELOPERAWARDED PRO1ECfS Form Vcrsion April 2, 2014 90 working days after the date wbm ffie Bid Units AZ.ure.x)s 00 45 72 DAP PREQUALIFiCA770N STATEMENT Pege 1 of 1 SECTION 00 4512 DAP — PREQUALIFICATION STATEMENT Each Bidder is required to complete the information below by identifying the prequalified contractors and/or subcontractors whom they intend to utilize for the major work type(s) listed. In the "Major Work Tvpe'° box vrovide the com leU te major work tvpe and actual description as provided bv the Water Deparhment for water and sewer and TPW for pavin�. � Major Work Type Contractor/Subcontractor Company Name Prequalification Ex iration Date Acadia Services, LLC 4/30/2022 Utilities — Water/Sewer/Storm Draina e Paving Lacy Construction Co. 4/30/2022 The undersigned hereby certifies that the contractors and/or subcontractors described in the table above are�cunently prequalified for the work types listed. BIDDER: A'Lure General Contractors LLC Company 6750 Boulevard 26 Address Richland Hills TX 76180 City/State/Zip BY � �ls�� LI --- (Please ' Sigr�aci ir�: Title: ��%`�_� (Please Print) Date: __�-�{�L END OF SECTION CI7Y Of FORT WORTH STANDARD CONSTRUCTION PREQUAIIFICATION STATEMENT— DEVELOPER AWARDED PRO)ECTS 0045 12 Prequalifiwtion Statement 2015 DAP[ij.doa Form Version Sepcember 1, 2015 p! i -1� ?b • 1 CON 1�R:ICTOR CU�IPLI;\�C[ �� 1TH b�c)RI�ER'S CU:�11'ENS.=� IlO� I_Aw Pa�r l of I � 3 =l ; G 7 8 9 10 il I? 13 14 iJ (b 17 18 l9 2U 2l » �; �� 26 �� ?s �9 30 31 3? 33 34 35 36 37 38 39 �30 SECTION 00 �i 26 CON�rIZAC"ITOR C0�IPLIANCE ��'(TH �b'ORKER'S C0�9PENSA"TIOv LA�V Pursuant to Te�as Labor Code Section 406.096(a), as amended, Cotztractor certifies that it provides ��orker's compensation ins�u�ance coverage for all of its employees empluyed on City Project �Io. 102811. Contractor furtlier certifies that, pursuar�t to �f�exas Labor Code, Section 406.09b(b), as aniended. it ��il( provide to City its subcontractor's certificates of camp(iance �� itli worker's compensation covera�e. CONTRACTOR: Acadia Ser��ices, LLC By: ^ �/'� ��tf Compan} (Please Print) 67�0 Boulevard 26 Address Richland Hills, TX 76180 City;'State,-Zip THE STATF, OF TEXAS COL?NTY OF TARRANT � `� Si<`nature: —`� ----- - -- 1'itle: —_—�/'v�ti4.�.,�_ (Please Print) BEFORE '�IE, the und�rsiy,ned aut3iority, an this da� personaliy appeared �� C�7��rT _ , kno��n to me to be the person �vi�ose name is subscribed to the iore��oin, instrtiment, and ackiio�r�fedoed to me that hz;'slie esecuted tlie sail�e as the act and deed of J A�a,�L�� c�_.�►-�_ for the purposes and cvnsideration ti�crein expressed and in the capacit}� therein stated. GIVEN U�DER �IY 4-�ANU �1ND SEAL, OE' OFF[CE this i_5 dav �f —�_'_ � � �� ..� ----._.. --- _ --- - _ � / � � / i i � �' s� �' ��YP�B ANDREW NORD Notar} Public in and for th � State of TeYas �' �' NOTARY PUBLIC * * STATE OF TEXAS ��OF'�P� MY COMM. IXP. 04-03- 024 NQTARY ID 12�� S CTION CI"1'Y' UF fURT WOR TH S"f:1�iDARU CUNS fRUC IION SPFC[FICA"rR��t DOC11bt(i1�TS Revised April 2. 201 � LA PRONTfiR:1- Pl l�1SL 3 CITY PRt)JF('T No.: 1028 f I 00 i2 43 - I Developer Awarded ProjCct Agreement Page 1 of 4 SECTION 00 52 43 AGREEMENT 3 TI3IS AGREEMENT, authorized on 6/23/2021 is made by and between the 4 Develop�r, LAFRONTERA DEVELOPMENT, LLC., authorized to do business in Texas 5 ("Developer"), and A'Lure General Contractors LLC •� 6 authorized to do business in Texas, acting by and through its duly authorized repressntative, 7 ("Contractor'). S Developer and �ontractor, in consideration flf the mutual covenants hereinafter set forth, agree as 9 follows: 10 Article 1. WORK 11 Contractor shall complete all Work as specified or indicated in the Contract Documents for the i2 Project identified herein. i 3 Article 2. PROJECT l4 The project for which the Work under the Contract Documents may b� the whole or only a part is l5 generally described as follows: l 6 LA FRONTERA — PAASE 3 17 CITY PROJEC'I' 1Y0.: 102811 18 19 Article 3. CONTRACT TIME 2Q 3. l Time is of the essence. 21 All time limits for Mitestones, if any, and Final Acceptance as stated in the Contract 22 Documents are of the essence to this Contract. 23 32 Final Acceptance. 24 TMe Worlc will be complete for Final Acceptance within �� working days after the date 25 when the Contract Time commences to run as provided in Paragraph 12.44 of the Standard 26 City Conditions ofthe Construction Contract for Developer Awarded Projects. 27 33 Liquidated damages 28 Contractor recognizes that time is of the essence of this Agreement and that Developer 29 will suffer financial loss if the Work is not completed within the times specified in 30 Paragraph 3.2 above, plus any extension thereof allowed in accordance with Article 10 of 31 the Standard City Conditions of the Construction Contract for Developer Awarded 32 Projects. The Coatractor also recognizes the delays, expense and difficulties involved in 33 proving in a legal proceeding the actual (oss suffered by the Developer if the Work is not 34 completed on time. Accordingly, instead of reyuiring any such proof, Contractor agrees 35 that as liquidated damages for delay (but �ot as a penalty), Contractor shall pay 36 Developer ONE THOUSAND DOLLARS, ($1,000) for each day that expires after the 37 time specified in Paragraph 3.2 for Final Acceptance until the City issues the Final Letter 38 of Acceptance. C[TY OF FOR'f WORTH LA FRONTERA - PHASE 3 STANDARD CONSTRUCTION SP£CIFICATION D�d1MENT'S - DEVELOPER AWARDED PROJEC"fS CITY PROlECT NU.: 10281 I Revised June 16, 2016 00 52 43 - 2 Deveioper Awarded Frojea Agceanrnt Pa�e 2 of 4 39 Article 4. CONB'RACT PRICE 4o Developer agrees to pay �ontractor for perfornYance of the Work in accordance with 4� the Contract Documents an amount in current funds of: ($1,398,408.9� 42 _ ,. 43 Artide 5. CONTRACi DOCUMENiS 44 5.1 CONTEN'i'S: 45 A. The Contract Documents whicli cflmprise the �ntire agreement b�ween Developer and 46 Contractor cor►cerning the Wo�1c consist of the following: 47 l . Ttus Agt�eerrient. 48 2. Attachmer�ts to this Agneement: 49 a. Bid Fam (As pnnvided by Developer) 50 1) Propc�sal Form (DAP Version) 5 i 2) PrequaliPication Statement 52 3) Sta�e and Federal documents (project specific) 53 b. (ns�uanc.e ACORD Foc�s) sa c. Payme�ar Bond (BAP Ve�sion) 55 d. Perfarna�e Sad {DAP Version) 5C+ e. �airrt�►arNoe Ba�d (D1� Version) 57 f. Pow� of Atkx��ey far the Bonds 38 g. 1A�+or�er°s Camp�on Affidavit 59 h. �'ISE and/or SBE Cauuc�ibmart �'om� (If r�quiredj GO �. S�d Ciiy Gem�al C.onditicxis of the Ccx�structian Conhad for Deveb�er b1 A�r��ded Pro�ects- 52 4. Suppian�anrary Condiri�. 53 5. S�ioms specifically made a pmi of die Co�d Docurt�s Iry attachment 6� ,�r, if nd attaclied, � inooipor�a2ed by reference and descnbed in tine Table of 55 G�nt�ts of the �inj�'s Conhact Docum�ents. S6 6. ��vittgs. 6� 7. Adde�da 68 8. Doawe�itataet submitfed by Cartrador pior tv d�ic�Lice oi Award. b9 9_ Tbe folbwiag which may be delivered � issued after the Et�i'ec#ive Date of t�e 7U Agaeaneimt and, if issuad, becwine an ir�cor�rared p�t of the Cartract Docrsmenis: 7 i a. Notice to Pc�ed. 12 b. �ield Orders. 73 c. Change Orders. 74 d. I..etter of F'u�al Acreptance. 75 76 CITY OF FORT WORTH LA FRONTERA - PHASfi 3 STANDARD CONSTRUC?ION SPECIFlCATION DOCUMEiViS - DE VELOPER A WARpED FROJECTS CITY PROJECT iVO.: 10287 I Revised June 16, 2016 00 52 �3 - 3 Developer Aw�ardeJ Project Agreement Page 3 of� 77 Article 6. INDEMNIFICAI'ION 78 79 84 SI 82 83 8� 8� 86 87 88 89 90 91 92 93 94 95 96 6.1 Contraetor covenants and agrees to indemnify, hold harmiess and defend, at its own expense, the caty, its offacers, seraants and emptoyees, from and against any and al( claims arising aut of, or alleged to arise out of, the work and serviees to be performed by the contractor, its officers, agents, employees, subcontractors, licenses or invitees under this contraci. This indernnification nrovision is saecificailv intended to operate a�d be effective even if it is atle�ed or nroven that all or some of the dama�es being soa�ht were caused, sn whole or in part, by anv act, oenissfon or ne�li�ence of the citv. This anderatnity provision is intended to inciude, witfiout ismitation, inelemnity for costs, expenses and lega8 fees incurred by the city in defending against sacb clai�s and causes of actions. 6.2 Contractor covenants and agrees to indemni4'y and hold harenless, at its own expense, the city, its officers, servants and employees, irom and against any and ail loss, damage or destruction of property of the city, arising out af, or alleged to arise out of, the work and services to be performed by the coaetractor, its officers, agents, eanptoyees, subcontractors, iicensees or 6nvitees under this contract. This indemnification Qrovision is specificalIy entended to operate and be effec9ave even if it is alle�ed or proven that all or sorne of the damases beins sou�i►t were caused, in whole or in part, bY anv act, omisseon or ne�ligence of the city. 9� 98 Article 7. MISCEI,LANEOUS 99 7.1 Terms. 100 Terms used in this Agreemer�t are defined in Article 1 of the Standard City Conditions of 101 the Construction Contract for Developer Awarded Projects. 102 72 Assignment of Contract. l03 This Agreement, including all of the Contract Documznts may not be assigned by the iO4 Gontractor without the advanced express written consent of the Developer. 105 7.3 Successors and Assigns. 106 Developer and Contractor each binds itself, its partners, successors, assigns and legal 107 representatives to the other party hereto, in respect to a!I covenants, agreements and 108 obligations contained in the Contract Documents. !09 7.4 Severability. i 10 Any provision or part of the Contract Documents held to be unconstitutional, void or I11 unenforceab[e by a court of competent jurisdiction shall be deemed strick�n, and all 112 remaining provisions shafl continue to be valid and binding upon DEVELOPER and I13 CONTRACTOR. 114 7.5 Governing Law and Venue. I 15 This Agreement, inciuding ali of the Contract Documents is performable in the 5tate of 116 Texas. Venue shall be Tarrant County, Texas, or the United States District Court for the t 17 Northern District of Texas, Fort Worth Division. CITI' QF FURT WORTH LA FRUN"fERA— Pi-?ASE 3 SI'ANDARD CUNSTRUCTION SPECIFICATION D(X.UMENTS — UEVELOPER AWARDED PROIECTS CITY PROIECT NO.: 10281 ] Revised Ji�ne 16, 2016 OG 52 �73 - i �e�eloper Auarded Project Agreement Pa�e �! of �i 118 119 120 121 122 123 124 125 126 I27 7.6 Authoritv to SiQn. Contractor silall attach evidence oi authority to sign Agreement, if other than duly authorized si�natory of the Contractor. (N WITNESS WHEREOF, Deve(oper and Contractor have executed this Agreemeizt in multiple counterparts. This Agreement is effective as of the last date signed by the Parties ("Effective Date"). Contractor: De��eloper: LAFRONTERA DEVELOPMENT, LLC. ------.-- --___-------- .—,, --, _ ; i }s ;: . ( Signatiire) __.___ __ _._. _ ____..__. .._ _. _ _. ._ Gi�.J�.-t'" ��t�'� -�'�_�1� � r�. •f _- (Printed Name) (Printed Name) Title: C��,�.1`a'� h/�.ibiJAG�,�i�._ Z�itle: (i{tl�� iiQi�iw'l,N�j L't-�7C-r" � Company Name: A'Lure General f'ompany name: LA ONTERA f'��ntractors, L1.0 lli �'�:LOP�IGNT, LLC. Address: PO13ox 19351 Add� e,;: 10001'EXAS 7RAll., Sl1ITT 200 «x Cit�/StateiZip: Halton City, 7'X 76117 _- � ` ' � ._(_ _ _ �-, I)•ite _- -- -- City/State/.7_ip: G12APEVIN}:, TEXAS 760�{1 Date---------�:�-��---- --- CITY OF FUR7 +�'OR'I'}i LA FRON'I'F.RA — PHASE 3 S1'ANDARD CUNSTRUCT[ON SPECIPICAI'!ON DCX'U�7i-:N't'S 3EVE1_<)PER AR''FIRDED PROJECTS Ct'1'Y PRUJECT NO. 102R1 ( Revised lune 16,2016 A'Lure General Contractors, LLC 006125-1 CERTIFICATE OF INSURANCE Page 1 of 1 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 ]7 18 19 20 21 22 23 24 SECTION 00 61 25 CERTIFTCATE OF INSURANCE INSERT CERTIFICATE OF INSURANCE DOCUM�NTS END OF SEC'I'IiDN CITY OF FORT WORTH STANDARD CONSTRUCTIdN SPECIFICATION DOCUMEN'1'S Revised July l, 2011 LAFRONTERA-PHASE3 C1TY PROJEC7' NO: 102811 0 X utua WORKERS' COMPENSATION INSURANCE Workers' Compensation and Employer's Liability Policy NCCI Carrier Code: 29939 Item 1 ACADIA SERVICES LLC Insured 6750 BOULEVARD 26 name and RICHLAND HILLS TX 76180-8838 address Other workplaces not shown above See Schedule of Operations attached. Producer I FROST INSURANCE AGENCY INC 04353 401 CONGRESS AVE SUITE 1400 AUSTIN TX 78701-3744 Safety Group TEXAS CONSTRUCTION SAFETY GROUP Certificate of Approval 016-009 item 2 I The policy period is from: 5/1/21 To: 5/1/22 12:01 a.m. standard time at the insured's mailing address Item 3 A. Workers' Compensation Insurance: Part One of the policy applies to the Workers' Compensation Law of the states listed here: Texas B. Employers Liability Insurance: Part Two of the policy applies to work in each state listed in item 3A. The Limits of our Liability under Part Two are: Bodily Injury by Accident $1,000,000.00 Each Accident Bodily Injury by Disease $1,000,000.00 Policy Limit Bodily Injury by Disease $1,000,000.00 Each Employee C. Other States Insurance: Part Three of the policy applies to the states, if any, listed here: None D. This policy includes these endorsements and schedules: see Schedule of Endorsements attached. Item 4 The premium for this policy will be determined by our manuals of Rules, Classifications, Rates and Rating Plans. All information required below is subject to verification and change by audit. Payroll Premium Total payroll and estimated manual premium Description Waiver of Subrogation Increased Limits Factor 1,000,000/1,000,000/1,000,000 Experience Modifier Schedule Modifier Healthcare Network Option Premium Discount Expense Constant Total estimated annual premium Minimum premium $250.00 Issue date: 4/30/21 %� �z�� Countersigned by Includes copyright material of the National Council on Compensation Insurance, Inc. used with its permission OOCopyright 2021 National Council of Compensation Insurance, Inc. All rights reserved. Information Page Insured copy Policy number 0002061806 Federal tax ID Entity 812437462 LLC Interim adjustment Bureau no. Monthly 15% - 11 Reports 421532184 PO Box 12058, Austin, TX 78711-2058 1 of 1 texasmutual.com �(800) 859-5995 ( Fax (800) 359-0650 WC 00 OQ 01 B � X utua WORKERS' COMPENSATION INSURANCE Workers' Compensation and Employer's Liability Policy Policy number Issue date Policy period 0002061806 4/30/21 5/1/21 to 5/1/22 State 42 42 42 42 42 42 42 42 42 42 42 42 42 42 42 42 42 Endorsement TM LRC 2008 TM MV 2011 TM PC 2003 WC 00 00 00 C WC 00 00 01 B WC 00 03 01 WC 00 04 06 WC 00 04 14 A WC 00 04 22 C WC 00 04 25 WC420301 J WC 42 03 04 B WC 42 03 08 WC420404A WC 42 04 07 WC420408A WC 42 06 01 Extension of Information Page Item 3: Endorsement Schedule Insured copy Description Limited Reimbursement for Texas Employees Injured in Other Jurisdictions Mutuals - Membership and Voting Notice Policy Conditions Endorsement Policy Conditions Form Policy Coverage Document (Declarations Page) Alternate Employer Endorsement Premium Discount Endorsement Notification of Change in Ownership Endorsement Terrorism Risk Insurance Act Coverage Endorsement Experience Rating Modification Factor Revision Endorsement Texas Amendatory Endorsement Blanket Texas Waiver of Our Right To Recover from Others Endorsement Partners, Officers and Others Exclusion Endorsement Group Purchase of Workers' Compensation Insurance Endorsement Texas- Audit Premium and Retrospective Premium Endorsemenf Network Discount Endorsement Blanket Texas Notice of Material Change Endorsement This endorsement changes the policy to which it is attached effective on the inception date of the policy unless a different date is indicated below. (The following "attaching clause" need be completed only when this endorsement is issued subsequent to preparation of the policy.) This endorsement, effective on 5/1/21 at 12:01 a.m. standard time, forms a part of: Policy no. 0002061806 of Texas Mutual Insurance Company effective on 5/1/21 Issued to: ACADIA SERVICES LLC NCCI Carrier Code: 29939 This is not a bill PO Box 12058, Austin, TX 78711-2058 1 of 1 texasmutual.com �(800) 859-5995 � Fax (800) 359-Q650 ��lz/�-� Authorized representative 4(30/21 WC 00 00 01 B-ENDS 006213-1 PERFORMANCE BOND Page 1 of 3 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 [F 20 THE STATE OF TEXAS CK�111►`�1ll�L�TOTI lI_��:7_7� 1� SECTION 00 62 13 PERFORMANCE BOND § § KNOW ALL BY THESE PRESENTS: § That we, A'Lure General Contractors , known as "Principal" herein and FCCI Insurance Company, a corporate surety(sureties, if more than one) duly authorized to do business in the State of Texas, known as "Surety" herein (whether one ar more), are held and finnly bound unto the Developer, LAFRONTERA DEVELOPMENT, LLC., authorized to do business in Texas {"Developer") and the City of Fort Worth, a Texas municipal corporation ("City"), in the penal sum of One Million Three Hundred Ninety Eight Thousand Four Hundred Eight and 96/100 ($1,398,408.9G), lawful money of the United States, to be paid in Fort Worth, Tarrant County, Texas for the payment of which sum well and truly to be made jointly unto the Developer and tlie City as dual obligees, we bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, Developer and City have entered into an Agreement for the construction of community facilities in the City of Fort Worth by and through a Community Facilities Agreement, CFA Number and 21 WHEREAS, the Principal has entered into a certain written contract with the Developer awarded 22 the �� day of �� y , 20 �/ , which Contract is hereby referred to and made a 23 part hereof for all purposes as if fully set forth herein, to furnish all materials, equipment labor 24 25 26 27 28 29 30 31 and other accessaries defined by law, in the prosecution of the Work, including any Change Orders, as provided for in said Contract designated as LA FRONTERA — PHASE 3. NOW, THEREFORE, the condition of this obligation is such that if the said Principal shall faithfully perform it obligations under the Contract and shall in all respects duly and faithfully perform the Work, including Change Orders, under the Contract, according to the plans, specifications, and contract documents therein referred to, and as well during any period of extension of the Contract that may be granted on the part of the Developer and/or City, then this obligation shall be and become null and void, otherwise to remain in full force and effect. C1TY OP FOR"t WORTH LA FRONTERA — PHASE 3 STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS CITY PROJECT NO. 10281 I Revised Ja��uary 31, 2012 006213-2 PERFORMANCE BOND Page 2 of 2 i PROVIDED FURTHER, that if any legal action be filed on this Bond, venue shall lie in 2 Tarrant County, Texas or the United States District Court for the Northern District of Texas, Fort 3 Worth Division. 4 This bond is made and executed in compliance with the provisions of Chapter 2253 of the 5 Texas Government Code, as amended, and all liabilities on this bond shall be determined in 6 accordance with the provisions of said statue. 7 IN WITNESS WHEREOF, the Principal and the Surety have SIGNED and SEALED 8 this instrument by duly authorized agents and oi�icers on this the �� day of 9 _ 7; �1�—,2021. io 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 �26 27 28 29 30 31 32 33 34 35 36 37 38 39 40 41 42 Y ptqR. W'� qly�5 { � icflin,:� _ �, ��' � •�'�� ( r1IS� f i�N'c7S �� h S �'`, ��V J . ( ; ��:�� !i� No. ?320:2249 ATTEST: (Principal) Se tary � r / a /vV Wimess as to Principal � Wime as to Surety � � PRINCIP : A'Lure en 1 Contractors, LLC . I � � BY. � , Signatiiii� �; �• - --, _ _ _ -�- `- --_ _ _- --- _ Name and Title Address: P.O. Box 14351 Haltom Cii,y, TX 76117 SURETY FCCI Insurance Company �` BY: Si atur Kaylee Parise, Attorney-in-Fact Name and Title Address: 6300 University Parkway Sarasota, FL 34240 Telephone Number: R(1�-22�-�224 43 *Note: If signed by an officer of the Surety Company, there must be on file a certified extract 44 from the by-laws showing that this person has authority to sign such obligation. If 45 Surety's physical address is different from its mailing address, both must be provided. 46 47 The date of the bond shall not be prior to the date the Contract is awarded. CITY OF FORT WORTH LA FRONTERA — PHASE 3 STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS CITY PROJECT NO. 102811 Revised January 31, 2012 006214-1 PAYMENTBOND Page 1 of 3 1 2 3 4 5 6 7 8 9 10 ll 12 13 THE STATE OF TEXAS ;1�111►`i111'(�7�IIIn:7:7�►1�11 SECTION 00 62 14 PAYMENT BOND § § KNOW ALL BY THESE PRESENTS: § That we, A'Lure General Contractors, LLC, known as "Principal" herein and FCCI Insurance Company, a corporate surety ( or sureties if more than one), duly authorized to do business in the State of Texas, known as "Surety" herein (whether one or more), are held and firmly bound unto the Developer, LAFRONTERA DEVELOPMENT, LLC., authorized to do business in Texas "(Developer"), and the City of Fort Worth, a Texas municipal corporation ("City"), in the penal sum of One Million Three Hundred Ninety Eight Thousand Four Hundred Eight and 96/100 ($1,398,408.96) , lawful money of the United States, to be paid in 14 Fort Worth, Tarrant County, Texas, for the payment of which suin well and truly be made jointly I S unto the Developer and the City as dual obligees, we bind ourselves, our heirs, executors, 16 administrators, successors and assigns, jointly and severally, frmly by these presents: 17 18 [E WHEREAS, Developer and City have entered into an Agreeinent for the construction of community facilities in the City of Fort Worth, by and through a Community Facilities Agreement, CFA Number ;and 20 WHEREAS, Principal has entered into a certain written Contract with Developer, 21 awarded the �day of fslJ�� , 20 �� , which Contract is hereby 22 referred to and made a part hereof for all purposes as if fully set forth herein, to furnish all 23 materials, equipment, labor and other accessories as defined by law, in the prosecution of the 24 Work as provided for in said Contract and designated as LaFrontera Development, LI�C. 25 26 NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION is such that if 27 Principal shall pay all monies owing to any (and all) payment bond beneficiary (as defined in 28 Chapter 2253 of the Texas Government Code, as amended) in the prosecution of the Work under 29 the Contract, then this obligation shall be and become null and void; otherwise to remain in ful] 30 force and effect. CITY OF PORT WORTH LA FRONTERA — PHASG 3 STANDARD CITY CONDITIONS — DEV�LOPER AWARDED PROJECTS CITY PROJECT NO.: ]02811 Revised January 31, 2012 006214-2 PAYMF,NT BnND Page 2 of 2 This bond is made and executed in compliance with the provisions of Chapter 2253 of the 2 R3 Texas Government Code, as amended, and all liabilities on this bond shall be determined in accordance with the provisions of said statute. 4 IN WITNESS WHEREOF, the Principal and Surety have each SIGNED and SEALED 5 this instrument by duly authorized agents and officers on this the �9� day of 6 _ � � �s.�i—, 20 �-- � _. J 7 �pi��F'G� i,'y�,ea HoKrna�� P�NC�f�.,: =��y. �� ,'��y �ommissior, Fx�'�'�s A'Lure General Contractors, LLC u^. �� g 05�14�2023 4� hr ID No 132012246 Of ATTEST: -- --�� (Principal) Se rctary °�A6 �� ►,_ �r��GC►�,� Witness as to Principal ATTEST: N/A (Surety) Secretary BY: Signature - —�_�1 r�,l,nulX c �L ----- -- - ------ - Name and Title Address: P.O. Box 14351 Haltom City, TX 76117 SURETY: FCCI Insurance Company BY: Signature Kaylee Parise, Attorney-in-Fact Name and Title , �.J Witnes to Surety 8 9 10 11 12 13 14 Address: 6300 University Parkwa� Sarasota, FL 34240 Telephone Number: 800-226-3224 Note: If signed by an o�cer of the Surety, there must be on file a certified extract from the bylaws showing that this person has authority to sign such obligation. If Surety's physical address is different from its mailing address, both must be provided. The date of the bond sha ll not be prior to the date the Contract is awarded. END OF SECTION Cl'I'Y UF FOR'1' WOR'1'H LA FRONTER.A— PHASE 3 STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS CITY PROJECT NO.: 102811 Revised January 31, 2012 006219-1 MAINTENANCE BOND Page 1 of 3 1 2 3 4 5 6 7 8 9 10 11 SECTION 00 62 19 MAINTENANCE BOND THE STATE 4F TEXAS COUNTY OF TARRANT � � KNOW ALL BY THESE PRESENTS: That we A'Lure General Contractors, LLC, known as "Principal" herein and FCCI Insurance Company, a corporate surety (sureties, if more than one) duly authorized to do business in the State of Texas, known as "Surety" herein (whether one or more), are held and firmly bound unto the Developer, LAFRONTERA DEVELOPMENT, LLC., authorized to do 12 business in Texas ("Developer") and the City of Fort Worth, a Texas municipal corporation 13 ("City"), in the surn of One Million Three Hundred Ninety Eight Thousand Four Hundred 14 Eight and 96/100 ($1,398,408.96), lawfW money of the United States, to be paid in Fort Worth, 15 16 r� 1s 19 20 Tarrant County, Texas, for payment of which sum well and truly be made jointly unto the Developer and the City as dual obligees and their successors, we bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, Developer and City have entered into an Agreement for the construction of community facilities in the City of Fort Worth by and through a Community Facilities 21 Agreement, CFA Number 22 23 24 ;and WHEREAS, the Principal has entered into a certain written contract with the Developer awarded the �� day of �(1�.°1 , 20 �� , which Contract is hereby referred to and a made part hereof for all purposes as if fully set forth herein, to furnish all 25 materials, equipment labor and other accessories as defined by law, in the prosecution of the 26 Work, including any Work resulting from a duly authorized Change Order (collectively herein, 27 the "Work") as provided for in said Contract and designated as LA FRONTERA. - PHASE 3 28 and ►�.]' 30 3l 32 33 34 WHEREAS, Principal binds itself to use such materials and to so construct the Work in accordance with the plans, specifications and Contract Documents that the Work is and will remain free from defects in materials or workmanship for and during the period of two (2) years after the date of Final Acceptance of the Work by the City ("Maintenance Period"}; and CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised January 31, 2012 LA FRONTCRA — PHASE 3 CITY PROJECT NO.: 102811 00 62 19 - 2 MAINTF.NANCE BOND Page 2 of 3 1 WHEREAS, Principal binds itself to repair or reconstruct the Work in whole or in part 2 upon receiving notice from the Developer and/or City of the need thereof at any time within the 3 Maintena.nce Period. 4 5 NOW THEREFORE, the condition of this obligation is such that if Principal shall 6 remedy any defective Work, for which timely notice was provided by Developer or City, to a 7 completion satisfactory to the City, then this obligation shall become null and void; otherwise to 8 remain in full force and effect. 9 10 PROVIDED, HOWEVER, if Principal shall fail so to repair or reconstruct any timely 11 noticed defective Work, it is agreed that the Developer or City may cause any and all such 12 defective Work to be repaired andlor reconstructed with all associated costs thereof being borne 13 by the Principal and the Surety under this Maintenance Bond; and 14 15 PROV�ED FURTHER., that if any legal action be �led on this Bond, venue shall lie in 16 Tarrant County, Texas or the United States District Court for the Northern District of Texas, Fort 17 Worth Division; and 18 19 PROVIDED FURTHER, that this obligation sha.11 be continuous in nature and 20 successive recoveries may be had hereon for successive breaches. 21 22 23 C1TY OF FORT WORTH LA FRONTERA— PHASE 3 5TANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS CITY PROJECT NO.: 102811 Revised January 31, 2012 006219-3 MAiNTENANCE BOT�TD Page3 of3 1 IN WITNESS WHEREOF, the Principal and the Surety have each SIGNED and SEALED this 2 instrument by duly authorized agents and officers on this the ��'� day of 3 _-r_��.�_ . zo�_ � . 4 5 6 % g 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 40 41 42 Y � /Vv.�'`.�'v'�/'�,,. , p�� `� �Iyssa i�ofiman V^`�� h ��1y ;':ornmission Exqres OS%� t�2023 9�.��+P IDNo �32U�72a6 ATTEST: (Pru�cipal) Secr tary � Witness as to ' cipal ATTEST: N/A (Surety) Secretary .� y / Wlhl 3S t0 L1YCi}� PRINCIPAL: A'Lure Get�eral Contractors, LLC BY: Signature �;,; �-=� ` �— Name and "I itle Address: P.O. Box 14351 Haltom Cit� TX 76117 SURETY: FCCI Insurance Company BY: � S gtzatur Kaylee Parise, ttorney-in-Fact Name and Title Address: 6300 University Parkway arasota, 3 24 Telephone Number: R�p-��F-3�2� *Note: If signed by an officer of the Surety Company, there must be on file a certified extra.et from the by-laws showing that this person has authority to sign such obligatio:�. i.f. Surety's physical address is different from its mailing address, both must be provided. The date of the bond shall not be prior to the date the Contract is awarded. CITY OF FORT WORTT3 LA FRONTERA - PHASE 3 STt1NDARD CITY CONDITIONS - DE VELOPER AWARDED PROJECTS CITY PROJECT NO.: 102811 Revised January 31, 2012 „r��°�.s�a� . � i;�St'A.4";('1. G�t)L�P _. . �,', � •, ,; � : � � Know aH men by these presents: That the FGC! Insurance Company, a Corporation organized and exisfiing under the iaws of the State of Florida (the "Corporation”) does make, constitute and appoint: Ailen Ba1e; Frank Cruz; John R Wilson; Juanita Austira; Rainy Heady; Greg A Wilkerson; John R Wilson; Nikki Adams; Cr�/stal Carlson; Bonni Stafford; Eunice Duong; Tadd Durst; Tadia D'Abramo; Johnny Nf Grabner; Kaylee Pa�ise Each, its true and iawful Attorney-In-Fact, t� make, execute, seal and deliver, for and on its behalf as surefiy, and as its act and deed in all bonds and undertakings provided ihat no bond or undertaking or contract of suretyship executed under this authority shall exceed the sum of (not to exceed $10,000,000.00): $10,000,000.00 This Powrer of Attorney is made and executed by authority of a Resolution adopted by the Board of Directors. That resolution also authorized any further action by the office��rs of the Company necessary to effecfi such transaction. The signatures below and the seal of the Corporation may be affixed by facsimile, and any such facsimile signatures or facsimile seal shall be binding upon the Corporation when so aff'rxed and In the future with regard to any bond, undertaking or contract ofi surety to which it is attached. In witness whereof, the FCCI Insurance Company has caused these presents to be signed by its duly authorized officers and its corporate Seal to be hereunto affixed, this 23rd day of Juty , 2020 . A4tG'St: �'''�. � l..��+��____-' :'�''n¢Yoa,�T°�r-o`: � 'U��[� F'.v : Christina D. Welch, President :�=: 5�� . {_ Christopher Shoucair, FCCI Insurance Company ,,�;, . EVP, CFO, Treasurer, Secretary . . �'roFsa?.; :- FCCI Insurance Company State of Florida ��•��• County of Sarasota Before me this day personally appeared Christina D. Welch, who is personally known to me and who executed ihe foregoing document for the purposes expressed therein. My commission expires: 2/27/2023 � � ��s,�«�,� P�B9Y Snow , �, �a �.�� E��,�, �� i�Otary PubliC State of Florida County c�f Sarasota Before me this day personally appeared Christopher Shoucair, who is personally known to me and who executed the foregoing document for the purposes expressed therein. My commission expir�s: 2/27/2023 ;�'''�� `" ��"`�� -�$��`6'�-� a�R. � �;"w � �rao2�s � •�"� Notary Pubfic CEit'TIFICATE I, the undersigned Secretary of FCCI Insurance Company, a Florida Corporation, DO HEREBY CERiIFY tha� xhe foregoing Power of Attorney remains in full force and has not been revoked; and furthermore that th� Februar�a 27, 2020 Resalution of the Board of Directors, referenced in said Power of Attorney, is now in force. Dated #his day of __ _, _ C ��''�- Christopher Shoucair, EVP, CFO, Treasurer, Secretary FCCI Insurance Cornpany 1-IONA-3592-NA-04, 7/2020 , � ;� . • To obtain information or make a comptaint: You may call FCCI Inse�rance Group's {FCCI)* toll-free telephone number for information or to make a cornplaint at 1-800-226-3224. You may also write to FCCI Insurance Group Compliance Departmeni e-mail at StateComplaintsCc�ifcci-group.com. For Claims, you may write to FCCI Insurance Group Claim Departmenf e-mail at newclaimCa�fcci-qroup.cam. You may contact the Taxas department of Insurance to obtain information on campanies, coverages, rights or complaints at 1-800-252-3439. You may write the Texas Department of Insurance: PO Box 149104 Austin TX 78714-9104 Fax: 1-512-490-1007 Web: http://www.tai.texas.gov E-mail: Consumer�'rotections c(D,tdi.texas.c7ov PREMIUM OR CLAIM DISPUTES Should you have a dispute concerning your premium or about a claim you should contact FCCI first. If the dispute is not resolved, you may contact the Texas Department of Insurance. AT7'ACF; THIS NOTiCE Tt? YOt1R BOPdD This natice is for information only and does not become a part or condition of the attached documents. *The FCCI Insurance Group includes the following insurance carriers: BrierFeld Insurance Company, FCCI Advantage Insurance Company, FCCI Commercial lnsurance Company, FCCI Insurance Company, Monroe Guaran#y Insurance Company, and National Trust Insurance Company. 1-BD-TX-21690-NTP-07 95 Page 1 of 1 Copyright 2015 FCCt fnsurance Group. STREET LIGHTS CONTRACT FORMS C& S UTILITY CONTRACTORS, INC. 00 41 00 DAP BID FORM FOR PUBLICLY BID PROJECTS ONLY Page 1 of 3 SECTION 00 4140 DAF BID FORl�1 FOR PUBLICLY BID PROJECTS ONLY TO: LAFItONTERA I)EVELOPMENT, LLC. 100Q TEI�AS �.`RAIL, SUITE 200 G�EVYNE, 'TEXAS 76051 � � . . ,� . ,. � .. � �;•. � . . . . � , . i �,�:� � Ciiy Project 102811 No.: Units/Sections: S�'REET LIG�IT IMPROVEMENTS 1. Enter Into Agreement The undersigned Bidder proposes and agrees, if this Bid is accepted, to enter into an Agreement with Develaper in the form included in the Bidding Documents to perform and furnish all Work as specified or indicated in the Contract Documents for the Bid Price and within the Contract Time indicated in this Bid and in accordance with the other terms and conditions of the Contract Documents. 2. BIDDER Acknowledgements an� Certifcation 2.1. In submitting this Bid, Bidder accepts alI of the terms and conditions of the INVITATION TO BIDDERS and INSTRUCTIONS TO BIDDERS, including without limitation those deaPing with the disposition of Bid Bond. 2.2. Bidder is aware of all costs to provide the required insurance, will do so pending contract award, and will provide a val�d insurance certificate meeting all requirements in the construction contract. 2.3. Bidder certifes that this Bid is genuine and not made in the interest of or on behalf of any undisclosed individual or entity and is not submitted in conformity with any collusive agreement or rules of any group, association, organization, or corporation. 2.4. Bidder has not directly or indirectly induced or solicited any other Bidder to submit a false or sham Bid. 2.5. Bidder has not solicited or induced any individual or entity to refrain from bidding. 2.6. Bidder has not engaged in corz-upt, fraudulent, collusxve, or �oerciv� practices in coznpetang for the Conixact. For the purposes of this Paragraph: a. "corrupt practice" means the offering, giving, receiving, or soliciting of anything of value likely to influence the action of a public official in the bidding process. b. °'fraudulent practice" means an intentional misrepresentation of facts made (a) to influence the bidding process to the detriment of Developer (b) to establish Bid prices at CITY OF FORT WORTH STANDARD CONSTRUCTION 6�0 FORM— OEVELOPER AWARDED PROJECfS 004100 Bid Form — DAP.docx Form Revised Apri12, 2014 00 41 00 DAP BID FORM FOR PUBLICLY BID PROIECTS ONLY Page 2 of 3 artificial non-competitive levels, or (c) to deprive Developer of the benefits of free and open competition. c. "collusive practice" means a scheme or a.rrangement between two or more Bidders, with or without the knowledge of Developer, a purpose of which is to establish Bid prices at artificial, non-competitive levels. d. "coercive practice" means harming or threatening to harm, directly or indirectly, persons or their properiy to influence their participation in the bidding process or affect the execution of the Contract. 3. Prequalifacation The Bidder acknowledges that the following work types must be performed only by prequalified contractors and subcontractors: e. ST1tEET LIGHTS 4. Time of Completion 4. i. The Work will be complete for Final Acceptance within 30 working days after the date when the Con9.i-act Time commences to run as provided in the General Conditions. 4.2. Bidder accepts the provisions of the Agreement to liquidated damages, if applicable, in the event of failure to complete the Work {and/or achievernent of Milestones} within the times specified in the Agreement. 5. Attached to this Bid The following documents are attached to and made a part of this Bid: a. This Bid Porm, Section 00 41 00 b. Bid Bond (if required), Section 00 43 13 issued by a surety meeting the requirements af the General Conditions. c. Proposal Form, Section 00 42 43 d. MBE Forms (if required) e. Prequalification Statement, Section 00 45 12 f. Any additional documents that may be required by Section 12 of the Instructions to Bidders g. Bidder pre-qualification application (optional) 6. Total Bid A�nount 5.1. Bidder will complete the Work in accordance with the Contract Dacuments for the following bid amount. In the space provided below, please enter the total bid amount for this project. Qnly this figure will be read publicly by the City at the bid opening. 6.2. It is understood and agreed by the Bidder in signing this proposal that the total bid amount entered below is subject to verification and/or modification by multiplying the unit bid prices for each pay item by the respective estimated quantities shown in this proposal and then totaling all of the extended amounts. 63. Evaluation of Alternate Bid Items <use this if applicable, otherwise delete> CITY OF FORT WORTH STANDARD CONSTRUCf10N BID FORM — DEVELOPER AWARDED PROJECiS 004100 Bid Form— DAP.docx Form Revised April 2, 2014 D(Y il OU DAP AID FORhf FOR PUBLlCLY Hi� PROIECTS ONi:Y P�c3of3 6.3. Evaluation of Aiternate Bid Items <use this if applicable, atherwise delete> Total Base Bid �75,3�5.�fl Altetnate Bid Deductive Alternate t�ddative A(tem�te TO'1'AL BiD $75,345.�0 7. �iai Submitfi�i This Bid is submitted on p�/{381202'i ]Eiespectfully submirted, �y: �,,r_..-.� ---.- (Signature) Chaies tNesiey Saylors {Printed rtame) Title: President �I'itie or O�ce> Company: C&S Utility ContP�ctors, Inc. <Company Name� l�,ddress: �705 FiWY 287 <Address > <Address iFappiicable, otherwise delete> A�littgton, TX 7SQ01 <City, Sta#e, Zap Code> g�p� q�' Texas Incor�aration: Email: wesley a�csutifity.cam Phone: ��7-829-9623 i i t �I by the entity named below� Receipi is ackn�wiedged of �itial the following Addenria: Addendunn No. 1 Addendum Ido. 2 Addendum tVo. 3 Addendum No. 4 QTY Of FORT WORTH STMD'.RD CON57RUCTION &0 FORM — D EVELOPER qWpADED PROJEC7S 00 Al OD Btd Form — DAP.docx Form Rtvhad Api112, 2014 i�- - : � �� . �. 00 42 43 DAP- BID PROPOSAL Page 1 of 1 SECTION 00 42 43 Devebper Awarded Projects - PROPOSAL FORM LA FRON'fERA - PHASE 3 IPRC21-0004 CPN: 102811 7/7/21 UNIT PRICE BID Contrador agm�s to complete WORK for F7NAL ACCEPTANCE within CONI'RACI' commmces to mn as provided in the General Condi6ous. END OF SECI'ION CITY OFFORT WORTH STANDARD CONSfRUC170N SPEC7flCATtON DONMENTS - DEVELOPER A WARDED PROIECTS Form Version April 2, 2014 Bidder's Application Total Construction Bid 30 working days after the dafe whm ihe Bid Units CS Streetlights.�s s;a s��me.y UNIT I: WATER IMPROVEMENTS UNIT II: SANITARY SEWER IMPROVEMENTS ---- ---___._____...__.—___ UNIT III: DRAINAGE IMPROVEMENTS ----- -_------------- UNIT IV: PAVING IMPROVEMENTS - - -_ __ - --- ----- _-------- --- _..__ _. _ _._ _ _..�._.__.. .. _._._.. _ UNIT V: STREEf LIGHTING IMPROVEMENTS $75,345.40 06 45 12 DAP PRFQUALIFJCATION STATE1.fEN7 Pqgc 1 of i �� Q �� m DAP — PRE(�UI�LIFICATION S'I'A'iEiV[ENT Each Bidder is required to complete the infarmatian below by ider�tifying the prequa3if ed contractors and/or subcon#ractors whom they intend to utilize for t�e majar work type(s) listed. In the "11�Iajor Work T�e" box pre�virle the complete majar work ty_pe and actual descri�tion as nrovided bv the Water D�e ari�a�ent fflr water and sewer arnd TFW ior pavin� Major Work Type �ontractor/Subcon#raetor Company PJa�ne Prequalification Ex iration Date Str�ei Lightirag G�S C1�i3aty �sar�tracfors, inc. Q3J031�t}22 The undersigned hereby certifies that the cantrac#ars and/or subcontractors described in the table above are currently prequalified %r the work types Iisted. i;€ ;I :t: ; ' C&� Utility Contractors. Inc. 67os yw�r zs� Artinqtan, TX 76001 $v: cna��ES wes�ey Saylq�s �� (Signature) TITLE: President I3A'�'E: 071Q8l202'1 ;e � �i cirr oF Foer worrrH SfANDANDCONSTRULTIONPREQUAUFICqTIONSTATE�YtENT—OEVELOPERAWARDEDPAOJECCS OOA512_PrcqualiflcationStatement20u DAP.docx Fo�m Version September 1, 2015 00 45 26 -1 CONTRACTOR COMPLIANCE W[TH WORRER'S COMPENSATSON LAW Page 1 of i z 3 4 5 6 7 8 9 10 a1 ]2 13 1 �# 15 l� 37 is i9 20 21 22 23 24 25 26 27 28 29 30 3i 32 33 34 35 36 37 38 34 40 SEC�Oi�i UO 45 26 COIVTRACTOR C+DMPLIANCE VdITH WORKER'S CQMP�NSATION LA W Pursuant #o Texas Labor Code �ection 406.(�96(a), as amended, �ontractor certifies that it provides wagker's compensation instarance �overaoe for ail of its eanployees smployed on City Project No.102�11. Contractor further crrtifies tha#, pursuant to T�xas Labar Code, Section 4i}6.09{(b}, as amended, it will proVide to Crty its subcontractor's certificates of compiiance with worker's compensation coverage. CK17�•It ; � � : C&S Utiliiy Contract�rs, in�. Company 6705 H1/V1' 287 Address Artir��ton, �"X 76a{}1 ��ty/State/�i� 'THE SiATE O� TEXAS COUNTY QP TARRANT gy; Chartes Wes4ey Sayiors (P ase Print) 9ignature: Title: President (Ptease Prir�t} § § SE�QR� ME, the i�ndersigted auY3ioziiy, on this day p�rsonaily appeared Charies Wesley Sayiors �ay�;a �� g� �� p��n whose name is subscribed to the foregoing instrument, and aeknowledged to me that helshe executed the same as the act and deed of �s uti�rty coraractors, inc. for the purposes and consideration therein expressed and in the capacity therein stated. GIVEN UNDER MY HANI7 AND SEAL OF OPFdCE this �th day of Juty , 20 21. ._------ 3�Totary Pubiic i °�lae State af TeYas +! 1' t` CJ7'Y UF FORT WC?RTH STANDARD CdNSTRUC'flON SPECIFICATION DQCUMENTS Revised April 2, 2014 � , r euxE a�r,avace kotary i0 �7 3 0999 6 78 My tommts�fon Exptres Februmry 2, 2025 4A �RONTERA - PHASE 3 CITY PROJECT No � 102$i ] 00 52 43 - I Developer Awarded Project Agreemeni Page } 0£4 sECTiox ao sz a3 AG�tEEMENT 3 Z'I3dS A��2EEMENT, authorized on o��oslzoz9 is znade by and between the Developer, 4 I.AFi2{�1V'I'E�i DE'6�Ei.,OP1VIE1o1T, I.�L�., authorized to do business in Texas ("Develoger"), 5 and A'Lure General Contractors, LLC_ C8s uciitcv contraaars tr�c. ,, 6 auti�orized to do business iia Te�s, acting by and t�rough i�s du3y suthorized representative, 7 ("Contractor"}. 8 Y3evsloper and Contractor, in consideration of the mutual covenants hersinafter set forth, agree as 9 follows: i0 Artie9e 1. W�FtK 11 Contractar shaPl complete all �ork as specified or indi�a#ed in ti�e Coniract 13ocuments for the 12 Project identified herein. 13 Ac-gic9e 2. �'RO TEC'�' 14 The project for which the Work under the Contract Documenis may be the whole or only a part is 15 generally described as foliows: 16 L� F�20N'I'�+ RA — PI�SE 3 17 CI7f'Y PROJECT NO.: 102811 1a 19 Article 3. CCeN7'It�iC'i "�"INd� 20 3. I Tims is of the essence. 21 All time limiis for Milestones, if any, and Finai Rcceptance as stated in the Contract 22 �7ocuments are of the essenee to this Contract. 23 3.2 Final Accepiance. � 24 The Work will be complete for Final Acceptance within 34 working days after the date 25 when the Contract Time commences to run as provided in Paragraph 12.04 oiFthe Standard 26 City Conditions of the Constnzction Contract for D�veloper Awarded Projects. 27 3.3 Liquidated damages 28 Contractor recognizes that tirne is of the essence of this Agreement and that Developer 29 will suffer fnansia! toss if the Y+Iork is not completed within the times specified in 30 Paragraph 3.2 above, plus any exte�sion thereof allowed in accorciance with Article 10 of 37 the Standard Ci1y Cond3tions of the Construction �ontract for Deve3oper Awarded 32 Projecrs. The Contractor aiso recognizes the dslays, expense and diffcul#ies involved in 33 proving in a legal proceeding the a,ctual lass suffe�ed by ihe Developer if the Work is not 34 completed on time. Accordingly, instead of requi��ing any such proof, Contracto� agreas 35 thai as liquidated damages for deiay (but not as a penalty), Con#ractor shall pay 3b Developer 43NE TNm[TSANII DOLLARS, ($fl,OQO� for each day that expires after the 37 time spe�ified in Paragraph 3.2 for F�nal Acceptancs until t�e City issues the Final Letter 38 of Acceptance, CI'1'Y OF' FORT W(}RTH LA FApNTERA—PHASE 3 STANDARD CONSTRLJCTION SPECIFICATION DOCUME3VTS — DESrELOPER AWARDBD PROJECTS C1TY PROJECT NO.: 10281 l Revised iune 16, 2016 005243-2 Developer Awarded Project Agreement Page 2 of 4 39 Article 4. CO1�T'!'RACT P�tiCE 40 Developer agrees to pay Contractor for perfarmance pf the Work in accordance with the �ontract 41 DoCuments an dmoUnt tn CUT['ellt furids of: Seventy-Bve lhousand three hundred forty-five and four fenths , 42 (S 75,345.40 � 43 Article 5. �ONT'Itr�C'T DOCiT1VIEN�`S 44 5.1 CON'�'ENTS: 45 46 47 48 49 50 Sl 52 53 54 55 56 57 5$ 59 60 51 62 63 64 65 66 67 68 6R 70 71 72 73 74 75 ?6 A. �'he Contract Documents which campri�e tl�e ent�re �greement between Deveioper and Contractor conc�rning the �Iork consist of the following: 1. This Agreemene. 2. At#achments to this Agreem��t: a. Bid Form (As provided by Deve9oper) 2) Praposai Form (DAP Versionj 2) Prequali�cation Statement 3) Sta2e and .�ederal documents {project specific) b. Inswance ACORI7 Form(s) c. Payment Bond (DAP Version) d. Performance Bond (I?AP Versi�n) e. Maintenance Bond (DAP Version) f. Power of Attorney for the Bonds g. Worker's Compensation Affidavit h. MBIE and/or SBIE Commitment Form (If required� 3. Standard City General CondiTions of the Consttuetion Contract for Developer Awarded Projects. 4. Supplementary Conditions. 5. Speeifieations specifically made a part of the Contract Documents by attachment or, if not at#ached, as in�o��rated by reference and described in the Table of Contents of fhe Project's Contract I?�curnents. 5. Drawings. 7, Adtlenda. S. Docurnentation submittsd by Contractor prior to Notice of Award. 9. 'Tha following which may be delivered or issuerl aFter the Effective Dat� af the Agreemen� and, if issued, become an incorporaaed part of the Contract Documents: a. Notice to d'roceed. b. Field Orders. c. Change Orders. d. Letter �f Fina1 Acceptance. CtTY OF FORT WORTIi LA FROA'TERA— PHASE; 3 STANDARD CONSTRUCTION SPECIFICAT[ON DOCUMENTS — DEVELOPER AWARDED PitO,IEC'CS C1TY PROJECT NO,: 10281 I Revised June 16,20I6 005243-3 Developer Awarded Project Agreement Pege 3 of 4 fi7 Article b. IlVDEMI�iI�ICATI01`T 78 79 80 8] 82 83 84 85 8b 87 88 89 90 91 92 93 94 95 96 6.1 �ontrac�or cmv�nants and agr�es to �n2demnify, �old ia�rm4�ss aad def��d, ai its own expense, the city, its oiiicers, servaa�ts and �anployces, i'roa�e and agaimst any �nd ali il�ie�s a�asit�g oui mf, or aiHeged to arese out of, tb� work a�ed serv�ces ta be perfor�eed by the cme�tractor, i�.s o�cers, agents, ea�ployees, saabc��atractors, li+eemses or �aavit�es ��der �his cmnErac�. 'This inri��nifi�acion provisiom i� s�secafec�liv inYeneled io oaerate amd tse effcet�v� ev�n if i# is afl�ed o� g�roven that aHi ar soa�a� of the dama�es bein� so�s�l�f �ere ca�ssed. in whal� or in nart, bv anv �et. o�nis�a�� or �e�li�ence of the �itv. This Hffi4ICffiIIli� �39'OVL41p]1 is intended to in�iude, zvithou# 9inn�t�tiv�, flndc�mniiy for costs, e�pe�ses and tegal fe�s i�acae�red by the �ity im tiefes�ding ag$gnst sucb ci�i�s an�i caa�s�s of a�tions. 6.2 �omtr�ctor covenants ��d agrees to indemniffy and hold harmaess, at ifs own eapense, dbe city9 I�CS O11dCS',CSy SLI�V$I�tS ADY P.QA�PIOyCiS� from and �gaiaest $ny amd �tl loss, dama�e mr destraction ofl property of the city, arising out of, or �lleg�d ta arise out �f, the wurk and services ta i�e performed by the son�r�cior, ats ��cer�, agents, empioyees, sasbcontr�ctors, licensees or invitees uatder this sontracf. Tl�is indemnification Arovision is sneciiacallv intended to opea�ate and be effectiv� eve�e flf i� H5 BIIC�C[I OP mroven t7�ai all or some of tbe damases bein� sou�bt were causeci in w6oDe or in pa�t� �'y 8I@0' 2C� Offi1ISS1011 til' II&LIA�B�Ce O�$�!e Clty. 9i 98 Arti�le 7. MI�C'ELi�f�NEC9y.TS 99 7.l 7"erms. 100 Terms used in this Agreement are defined in Article l of the Standard City Conditions of (01 the Construction ion#ract for Developer Awazded I'rojects. 102 7.2 Assignment of Contract. ]{�3 This Agreemen�, including all of the Confract Docaanents may not be assigned by the 104 Contractor without the advanced express written consent of the I7eveloper. 105 7.3 Successors and Assigns. 1Q6 Developer and Contractor each bands itself, its partners, successors, assigns and l�ga! 107 represen4atives to the o2her party hereto, in respect io ali covenants, agreements and lOS obligations contained in the �9ntract I)acumenis. !09 7.4 Severability. t10 Any provision or part of the Contract Documents held to be unconstitutional, void or 1. 7] unen.fQrceab]e by a conrt of co�npetent jurisdiction shall be deerned stricken, and alI i l2 aemaining provisions shall c�ntinue to be vadid and binding upon DEVELOPER and 113 CONiRACTOR. I 14 7.5 {iove�ning Law and Venue. 1.15 T�ais Agreement, including all flf #h� Contra�t Documents is performable in the State of t 1G Texas. Venue shall be Tarrant County, Texas, or #he United States District Court for the ? 17 Northem Districf of Texas, Fart Worth Diaisian. CITY OF FORT WpRTH LA fRON7'�ItA — f'tfASL•' 3 STANDARD Ct1NSTRUCTION 5PECIFTCATION DC?CUMENI'S — DEVELOPBR Fi�i'ARDED PRdJECTS CITY PROJECT NO.: 102811 Ravised June 16, 2016 005243-� Devefoper Awarded Projeci Agreement Pagc G of-0 iH$ i I9 7.b Auiho�ity Yo Sigra. I20 i21 122 323 i24 i25 126 127 �c>naractor sha91 a�t�ch �viaence of aiithorit�� tm Sig71 Agf'£ETi1�3'1�, if cat�er ah,�r, d�y author�z�d sigraafaa�+ o� ttae Cc�a�i�actor. II�; i�VITNESS WI�EI2Et)F; De�eioper a�id Cantractor have ex�cutsd this A�reemsnt im multiple counterparts. '�'his Agreemeni �s effectave as of the last date signsd by #he Parties ("�f�'e.^.tive I3ate"}. �an�e'actor: C�S U51ity �anfractors, inc. Developer: Y4��H��1`7 Y�1'i'l�[['9. R�� V�8s1!%1TY9:.L\ Jl y 9.lB.'i.+. !� �Y� ��. � : i'{ . �SA�L18tUie� c^illgTE$fZ7J'C> cr�es �iEy �y�� ____ /� -G Z� � Ts'�1 {Pr�nted A�araae) �Printed Name) Tet9e: Pr�esident Tit(e: � .C,�. � CompaYzy Name: C&S t111iGfy Coa�tractars, fic. yCompany name: �.,�I�'g8��'g'�� ➢J�Y 9:+d.aYfS 1:AS.Jly .@ y �.C-�6.. �,,ddress: s7a5 H4NY 287 Address: 1flli0 7['E�� 'I"�II., S�T'� �fl0 City/Sta�e%�ep: Arli�igYon, rx asao� 0��8/2�2' i3ate 12$ City/Siat�I2ip: G � �,'�'E��S'7b0�� 7/r.��.� �a�e CITY O� FORT WOR17� LA FFiUN1'£RA--PIiAS� 3 STAI3DARA CONSTRU�TION SPECIFICATION DOCiJMEMS — DEVELOPER AWAitDED PROYECTS CITY PROJECT ND.: 102811 Rerised Iuae 16,2016 00 61 25 - 1 CERTIFICATE OF INSURANCE Page 1 of 1 1 SECTION 00 61 25 2 CERTIFICATE OF INSURANCE 3 4 INSERT CERTIFICATE OF INSURANCE DOCUMENTS 5 6 7 8 9 10 I1 12 13 14 15 l6 17 18 1.9 20 21 22 23 24 END OF SECTION CITY OF FORT WORTH LA FRONTERA - PHASE 3 S"1'ANDARD CONSTRUCCION SPECIFICATION DOCUMLNTS CITY PROJECT NO: 102811 Revised July 1, 201 I tx� sa �3 . a PEIEf�092MANCE BOND Page i of 3 Z 3 � S s � 'g'�E sT�`� i�F T�X�s � +: .,�. Sl�C1'�Ol�t 00 62 I� 4449I20 PE9ZF`C)1't1�AdCE �OND § § �ro� ar��, B� ��s� px�S��vi'5: � s � 10 I1 Th�t we, C8S U61fty Contractors, Inc. ,�o� �°rp�ncipal" herein and SureTec insurance �cmpany .$�orparat� surety�'saareties, if more ihan �ne) siuly ae�thori�ed tn do businsss in t�ae S#ate of Texas, k�aovwn as "Sa�rety�' tser�in (whether mne or �ore), are fl�e3d aesd firmly bou�sd �anto the I�eve3o�rer, �l�d) RA D��I.��14�E1liT, i,Y.C., !2 authorized to do businass in Texas ("I�eveloper") �nd #he City of �'ort �orth, a Texas municipal 13 corporatian ("City"), in the pensl sum of Seventy P�ve �'bmas��t� "�"Is�°ee �ue►da�ed F'orty �v� 14 �� lI�O (575,34s.40), lawful money a�f the United States, to be paid in Fort Worth, Tarrant 15 16 17 1� 19 20 Coutaiy, T�xas for the p�ayment of which stun well and tazt6y to be m�de jointly unto the LDeveloper and the City as dua3 obligees, we bind ourselves, our heirs, executors, �daniaystrators, successc>rs �nd assiSns, jointly aaad seveeally, fumly by ttzese presents. EYdIE'.�5, Dcvelopes and City have en#ered 'aito an .Agreem�nt for the construa6on of community �acitities in the Ciiy of Fort Worth by and throaagh a Cammunity Facilities Agreement, CFA Numher 102811 and 21 E ,�e Principal has entered iaato a cea�tasn writden �oaiitact with the Deueloper $waeded 22 the Sth day of .9uly , 20 2t , which ContracY is hcreby referred to and made a 23 part heeeof for alI purposes as if fully se� %rth her�in, to %►snish all pnaterials, equipmea�t labor 24 and other accessories defined by 9aw, i�a the prcrsecution of ehe Work, includ'ang any Change 2S C9rders, as provided for in said Contract designaied as ��ONi' — PH��; �, 2� ��, '��1�, the �onsii#iaxi o#°this obligstaon is �uch that if � said Principal 27 shali faitt�a�lly perform it nbligations und�r the ContracY and shall in a13 aespec�s duly and 28 fait�iiully perfarm the �lork, including Change �rdeas, a�nder t�e Contract, according tn the plans, 29 specificatio�as, and contract docuYxae�ts ih�rein refe�d to, and as we13 during any �seriud af 30 eartension of t6e Contract that may be grata#�d on the part of �.tze Develo�r and/ar City, then this 37 obligafion si�ail be and Uecome null and void, otherwise to rernain ia� full fcsrce and e�Cp. CdTl/ aF FQRT WQRTH LA FROATT'FRA — PHASE 3 STAidDAftD CITY COND17iON9 - DEVEI.9PEA �i�ARDEp pRO,TEC�'S CiTY PROJECT NO. 9028 ] l Rsrised Janunry 31, 2012 OQ5213-2 PERFORMhA10E HOidD Page 2 of3 I i'ii�V�Eii �'�BT�iE�E, t;�at if any legal a�tion be filed an this �ond, venue shall lie ia� 2 Tarrant �ounty, Texas or iha llnifed 6tates District �ourt for th� Northem District oi Texas, Fort 3 Vdorth Divisimra. 4 7'his bond as rnade a�ad executed in cornpliance writh the provisians oi �daapter 22$3 of i3ae 5 Texas Govemm�ni �de, as arr��nded, and all 1ia691'sties an this bond shali be determined in 6 accordarece with the provisir�ns of said sta�ue. 7 d�I 9� 5 E�OF, ghe Principa� arad the Sur�:ty ha�e SIGNED and SF.I�.,ED S t&�is ins�trumerat by duly aathorized agents anc� officers an this the ��,�'"` day of 4 ---------� 20�� . PO �l �z 13 i4 15 I6 1� is 49 20 2i 22 23 24 as zs �� a 24 30 31 32 33 34 3i 36 37 38 39 40 41 42 43 44 �5 4b �7 A�sT: {�renc6pa�) Sect�etary �arn � � � ��i PRINCIPl�L: cas u�tg r.rnecracf�s. �na B5': �/� '�-- Si�arature cnarPes saptovs, Presttlent Y�Tar�e an� Titie ' � Asida�s: e7ostirv�aa� nrnnfla:a,, nc �eooy :� , . .� - � �,: �r�� f,�� ; �� ; .� Itebecca id�reit, Attflrney-in-Fact Name and iitl.� �,d�: 1�3i0 4Vatsc�n Drive : � IC�ma,'I'X 75i43 , � � � • ------- - ___ --- -�._ .--- - 'f�aaess as to rcty 'F'e3��rahone hfumber: 214-382-076� �Note: Lf signed by � t�f6cer of the �a�rety �aznpa�►►y, ��se must be on �!� a certified �xtr�t fPom the by-�aws shQweng th�Y thss person D�as a�a2thority to sign s�h c�bligation. If Surety's physical addres� is differe�t ia�azn ii� s�a�l9ng �dress, bcrth r�►aast be provided. C3TY tDF FOR7' iVOR'iY�i LA FRON7'ERA - PHASE 3 STANID�ARD CTTY CONDIi'[OAIS - D�l�II,O�ER Abi�ARDED PROJF�C7S �PTY P120JE�T NO. 1fl281 ] RevSsed Jan�ry 31, 20Y2 li0 62 I3 - 3 PERFORMANCE BOND Page 3 of 3 The date of the bond shall noi I� priur do ihe date The Contract is awarded. Ci'TY OP FORT WOR'itI LA �AONTERA — PHASE 3 STAi3DARD CI7Y CONDITIpNS — DEVELOPER AWARDED PROJECTS CTfY nRO.Tf�Ci' id0, iD28i 1 Revised 7anuary 37, aoia 00 62 14 - i PAYMENT BOND Pagc 1 of 3 l 2 3 4 5 b 7 8 9 l {! �1 I2 t3 14 15 Ib . ; . .� . � �.: � :. ,��,_ ��4'I'If>l�d OU 62 i4 4449120 PAYh�ENT BOND � § �PT�W Ad.I. B�''I'�E�E PIt�S�AiTS: � '1'�,at we, C&S Utitity Cssntractors, �nc. , kno� as "Principal°' herein arxl SureTec Irasu�ance Coenpa�y , a coaparate saareiy ( or sureiies ii more than ane}, d�ly authorized to do business in tit� Siaie oi �'exas, known as "Surety" herein (whether ome ar more), �re held and frmly boa��d unto td�e Deeetoper, �I�1'�F� i9EVEY.,��2V"I", Zi.�., aut�ori�r! to do busin�ess in Texas "(Developes"), and the City �f Fort W�rth, a Texas anunicipal cospora#ifln ("Citg�"), in th� penal sa�rn of �saenty F'rve �,ou�And �°hree ��ndr�d Fariy P'ive and d41100 ($75,345.40�, lawful money of the United States, to be paid in Fort Worfh, Tarrant County, Texas, iFor the payment of svhicia sum well and Uruly be made joieatly utato the Developer and the City as dual obligee.s, we bind ourselves, our heir�, executors, administrators, successoas a8ad assigns> jointly and severally, %mniy try ihese pre.sertts: 17 , Beveloper and City hae�e entered into an Agreemeaat for the canstruction of 1� commucaity facili2ies in the Ciiy of Fort 'l�lorth, by and ii�rough a Community Facilities 19 A,gretment, ��A NuallbCi i02811 ;aHld 20 � , Princigal has enier�d into a ees4sin written Con�ract with I�eveloper, 21 �warded the �tlt day a�' Juiy , 20 21 , which Contract is her�eby 22 referred to and made a�aart her�of for all pur�oses as if fi�Yly set forth herein, to fumisii all 23 �saierials, equipment, labor and other �ccessories as defined by law, in the prosecutAon of the 24 Wark as providetl far in said Contract and designated as LaFro�tera %Deo�elop�nen� �,i,C. 25 26 PIt�W, T�E�I�'O�, THE CONDITION O�' THIS �BLIGATIQN is such that iP 27 �rincip�i s�sall pay all manies ��ving to arsy {and a!l) p�yment lsand benefaciary (as defined in 28 Chaptet 2253 of the 'Texas .C'.3avernmeM Co�e, as amernl�d) in th� prosecc�tavn 4f the LYork usader 29 ihe Contra�t, ihen this obiigation shail be and �,ecome null arad void; otherwise to �amain in fuil 30 f4rce and effect. CiTY OF F63RT WORTH LA FRON'i'ERA — PT3,4SE 3 STANDARD C1TY COAlD1T30A1S — DEVELQPfiR AbdARDED Pi(OlECTS CI3'Y YROJECT NO.: 10281 I Revixd Janu�ry 33, 2412 0062 ta-z YAYMENTBOND Page 2 of 3 1 This bond is rnade and executed in compliance with irhe provisi�ns of Cha�ter 2253 of ihe 2 Texas Goverrcment ��de, as arr,ende�, and ail I�abilaties on tl�s boa�d sh�l� be deteaat�ined in 3 acccsrdance rviB� the provisions af saa�i stat�tte. 4 ��'II'�.�5� ��9E+', the Psi�sc9pal and Surety �ave each sICYNED, �ad SE,4LED 5 t�is irestrument b dufl autharia.ed `��_J Y y agenis and officers �n this th�e�_ day of 6 __, 2b�'� E'R.INCIPAL: c�s ttb�tcy cor�fsa�t�s, dnc. 8 4 10 1] 12 A1['�ES'I': {Pripxipalj Ses�t�ry Wtn as to incipal A"I'I'ES'I': (Surety) �e�retary � �� y � �� r �� _�.o v�� ' t� ss as �sa S�arsty �Y: �.�'�—�---'� Si�naturs CCi�a� saytors. Nr�stder� Narrse �nnd T�eie A��: eaas t�n asr �con. zx 7aoa� SURE�''': Surei'ec Insurance Compang� � BY: � ` 5�`� / � � Sigra . •- �te�ecca Rockett, Accorney-in-Fac� N�r�ae �d Ti��e Address: 15374 �IVatsmaa Drive Keanp, °�'X 75i43 �'e8ep�2ane Na�ab�rr: 214-382-4761 Note: If signeci by an officer vf tlze 5ur�ty, there �nust be �sn �le a certi�ed e�str�ci from ihe bylaws showi�g tiia# this p�rson }sa� authorit� to sign suc� oblig�.7�or�, if Sureiy's p}�ysicab address is differe�►t �rorsa aTs mail3ng address, both naust be provided. c�Tv aF Foxa woazr� Si.1NDARD CYTY COND3T1CiNS —DEVEL.OYER AWA92DED PRpJECTS kterised Jaoxmry 31, 2012 LA F3tONTERA — PHAS�: 3 G7i'YPR03EeTN0.; i02873 Wb234-3 PAYla4EN? BOND Page 3 of 3 I ihe da€e of the bond sha1D not be prior to the date the ��ntract is �warded. f�l►N i ` ' !: �I Ci'4'Y UP �ORT SVORTdi LA FRONTERA — PHASE 3 STANL3AdtD CPTY �ONDITIOPIS — DEVELOPER AWARI)�D FRO3EC'[B C77Y P3iOdECT NO.: ]02$9 i RevisedJenuery 3i, 2012 oo6a �9- f MAINTF_NAYdCE BOND Page i of 3 1 2 3 4 5 6 7 � ' �� I�J� ,r ' � '"�� :t t 4449124 8 9 IO ii 12 13 14 IS i6 17 78 'i <I: " _ c : s: aYi1 § � �T0�119a.i. ��' �3��+ PR�SEN7'$: � 'd'hat we C&S lJti6ty Conirac#ors, fnc. . known as "Pr�ncipal" herein and SursTec Bnsur�nc� Company , a coaporate sursty (st�e�ties, if tnore ti�an onej duly sutharized to do buslness in �e St�#e af 1'e�s, kxiowaa �s `<Surety" her+�in (�vhether one or more), ara h�ld arad firmiy bpund eanto 89a� I�ev��aper, �1°�"A'EidA �EW�I.�P1dIE�t7', Y��'., authoria.ed to do busiraess in Texas ("I�evelaper"} and the City of Fori'dYorth, $ Texas mtaa�ieipal corporatimn ("�iiy„), in the sum of �evemig ��vve �"hoe��ad �'Beree �mndr�d FvrBg� �ivc and 401�OQ (�75,345.�) lawfu! money ofthe United States, to be paid in Fa�rt Warth, Tarrani Cousrty, 'fexas, for payanent of which sum vvell and 2ruiy be made jointly unto the Develaper and ttre Cily as draal obligecs and their successors, we bind o�.ruselves, our heirs, exectrtors, adminish�atoas, snccessors and assigns, j+�i�tly atid severally, firmLy by these presents. 19 �'�EfliEA�, LBeveloper and Citgr have enteseci iaato an Ag�e�ment for the constraction of 20 eoanma�nity facilaties in 2he �iiy of Fo�t �or�'� bv � throug�a a�oanmunit� Fsciiiiies 2t Agreement, CFA Number 1028'i 1 ;and 22 �E�EAS, the Principal has entered into a ceatain writfen coutract with the Devel�per 23 awarded the 8fh day of Ju6y , 20 29 , vvhich Contr,�ct is 24 hereby referreci to and � made part I�eeaeof for all pur�c�ses as if full y set fort� hereia, tv fvrnish ati 25 materia�s, equiprga�nd lab;+r ar�ci oi%er accessories as defi��l by Law, in the prosecattian csf #he 2b Work, including �ssy Wflrk sesultang frosn a d�Iy aaathorazed �hange i7rder (coilect�veiy her�in, 2fi the "Work"} as gsav�id�d fc�r in said �ontra�i and designated as I.�i FR�3V1'EleA - P�A�E 3 28 and 29 30 �AS, Principal binds itselit�o aase such materials and to so ccrnstruct the Worl� in 31 accordance wi� the plans, sp�cificadivns �d Con4ract I�cuments thai the Work is arad will 3� re�saain free from defects in materials or workmanship for and daaring the pe.rioti of two (Z) yeaa�s 33 afteP the date of Final Acc�paaaice of tt�e Work by the City ("Maintenaaace Pe�i�)"); atad 34 Ci7'Y OF F03tT WORTH LA FRONTIIiA— P}l,�}$E 3 STANDARD CI'fY COPfD1iTflNS — DEVELOPER AWARDED PRQTECTS CITY PROJECT NO.: 1p26] 1 Revised 3aramry 31, 2p12 OOfi2 i9-2 AiAtNTF,t�tANCE BONID Paga 2 of 3 ➢ 2 3 4 5 6 7 8 9 t0 ll 12 13 14 15 16 17 18 I9 ao ai za 23 '1�iiEREA�, Principai bir,ds itself to repair or reconstruct the Work in wh�ie ar an part upon receiving notice frmrn thc Developer and/or City of the need ther�eof at any time within the �aintenance Pet�ad. NCD1� �'�E�F()it�, the cond�tion oithis obligaiion is such that if I'rincipal shall remedy arry defec�ve 'bNork, for wtvch timely natiee was providad by Devetoper or �ity, to a completion satisfaatory to thc City, thsn this obiigation shall becoras� nu11 and vaid; othe�wise io remain an full force and sffect. �'i�dA��1EdB, S��VEIi, if Principal sha31 fasi so to re�air oa� recvnstsu�# any timely re�ticed defectiv� 4R/t�rk, it is agreed that the Developer or �9ty may causa any and all such defective Woek to be repaired and/or reconstructed widh a11 associated costs thereof being borne by ihe Prencipal and #he Sure2y under this Maintenance B�nd; and I'�� D � R, ihat if any lega! action be fiied on this Bond, venuc shali lie in Tarrant Cowaty, Texas or ti�e United States Dis#r�ct Court for tfie Northern District of Texas, FoYc 1�oeth D'uvision; and Y'BtO�E�.t �EIB, that this obliga2ion sha81 be continuoa.�.�ss in ns�iure and successive recoveries ffiay be had hereon f�r successive breaches. CITY OF FflRT WOR'33�3 �.A }�RON'lERA - pHIASE 3 SPANUARD CI1Y CON�ITIf3NS - DfiVELQPER AWARDED PRJJEG?S ClTY PRO)ECT NO.: 102$] 1 Rtvi�d January 31, 2if 12 !JU b2 19 • 3 MAtNTENANL'� BCDPID Page 3 of 3 1 ffi� �� 'Fi� ��', ci�� 1'rs�scipal asnd gh� Surery h�ve each iSd�''ihiED and SL-'�,LED this 2 instrumen# by du3y auti�tssaz�d a�ents �rsd ofiicers on �iais the ��..� day of _�-='� �� 3 , 20 � 5 6 % � 9 30 �$ i2 13 1� i5 i6 ]7 L$ t9 2fl 23 22 23 24 25 26 27 28 29 30 31 32 33 34 33 36 37 38 39 �t0 41 A2 ATI�ST: {�rincipai) Secretary �'' �ss as t rsnci�sa� A3i�,ST: (, ure9.3'� 3eereda�"� `��'`'�'..�� '�-�-' ' � � � 'i ;�.. �'�1'�'..-�.� � 'ii3r�ss �s tv SWr� t �1tiI�7CIPr�.i,: G&S UtBity Contrar.�rs, ksc. � B,5': � ._.---'� �igeaaeur� char�s Sayiors, Pr�idant N�e arpd Tat3e T Address: a�os rtuw as� Arl�gFon. TX 7s009 SiT�i]E'I'Y: SttxeT�t/l�ssurance �om an �a _ __� C�BY: �d d+ Si hare - Rebecca Ror.tcett Attorney-in-Fac* Name and Titic � e�,ddtiess: i5390 Wat�o�e I3riye �� TX 75I43 7Ce8ephoe�eNumbe�: _ 2i4-382-0�61 *Note: [isigned by ata of�i�r of tfae �urety Company, there must �Se on file a ceatified ea�-act irmra� ihe by-laws s�eowisag Yhat this person has ac�titority to sign such obdigation. �f Sorety's physic�l address is dafferent fmm iYs maiiing address, bot►x r�apst !ae provided. The c4ate o�'ihe b�ns! sh�ID n�t �e przor #o �e date the Con9sact is awaa�ded. CITY OF FOAT WORTH L.A TROIVTERA — PHA^sE 3 STANDARD CITY CONUSTSOWS — DEVELQPER AVYARDiED PROJF,C.'TS qTY �Rfl9ECT' pIO.: i02811 R evised January 31, 2012 r � r � . :. , . .� .- � .. f . . To ob�in informatior� or make a oomplaint: Yau may c�il Td�e Suret�'s io!! free ietephone number for 'aiformatior� or to maice a complalnt or P�e a da�ra at; 9-866-732-0099. You may aiso wtite Yo �iae Sur�ety a� Sursiec lnsur�nce Cvmpas�y 9?87 Great Hills Tr�i1, Suite 320 ,4us�, TX 78759 Yes� rr�ay s:ontaci ttse 3exas �par�m�rat o� lnsuran+c� ��bfi�in ir�farmatfon on compa�ies, coverage, rdghts ear c�orn�taints at 1-8Q0-252- 3439. Y�u may wrike the Fexms Depaattnent of �nsurance at: PO �ox 149904 Austin, TX 78i'9499fl4 Fax#: 512-49Q-7007 W�: hitq:/lvvvvw.tdi.texas.gov Eraaaii: Cor,s�emerFrotectiora dLlidi.texas.gov PREMIUAA fJl2 GLAdRAS DBSPIDTES: Should yrou have a dispufe concemirag yoa�r premiunn or about a claim, you shoufd contact fhe Surety flrsT. If the dis�ute is �aot resotved, you may confact the Texas Ll�epartment of Insurance. T�e�s Rider 8/2019 �o�,�: aa2�r9s . . ,, �- � �� . � �„ .� i. . • .� :: � � FCraow All A9ear by ?7rese Pres.ents, Thaz SU6�ET�C iNSURANCE COMPANY (#hc "Cumpa»�'}, a corporation dnly cmganized and existing c�ax0er the laws +nf the Stste of iexas, and having cts principal officE in Houston, Harris Cuunty, �"exas, do�; by these presents make, eonsteiut� and �ppoint Christiara Merritt, Rebeaca Rodc�tt lts true �nd lawfud Pittomey-in-face, with full power and authority 9atreby conferred in its name, place and siead, to execute, acla►owiedge and 8etiver any and a�3 boncls, recognizances, tandestaEcfngs �r oitier irsfirutnents os �ontraats u�'suretyship to inc3ude waivers ca the candiYians of cor�ra�is and ccsnsents of sucety for, }sroviding rhe i>ond Qenaity daes isoi ex�e�al One Nliliior� and OD/10a �ollars ($1,p(DU,000.00} arad to birtd the �om�any theaaby as faalty �d to tl�e same axtent as if such �nd were signed by the i'rzssden?, sealeri owpi�s ti�� corporate seal of the Comp�ny and du�y attestea� by its Secretary, hersby ratifying amd r.c�nfirming a114hat ihe said Attos�ey-in-Fact may do ira the �r$meses. SairJ appoin�nt 9s ar►ade asc�dsr aad by acsd�ori2y af ihe follo�ving aesolations oi tha �oard of 1?iaec&ors of ihe SuceTsc insurance �ompany: Be it Rcsalved, that ihs Pa�sidee�t, �ny Vace-Paesident, any Ass3starat VicaPresidrni, aa�y �ecretary or �ny AssisYatec Secraary s6aii Ix and as bea+tby vest�d wi#h fufl powee and aathar�ty to appoiut any ona or rrtore sa�tabk �+ersons as Attorncy(s}-in-Fact 4o reprascnt snd act for and on behalPof ihe Canpany s.�bject to the fo4dowing peovisiows: .�4rtarr�e�-is-Face may be given fuli power and autta�ity foa arxi in the name of and of ix�atf of ihe �ompaay, to execute, acknowkdgc mn�i deiiver, any end all bonds, t�eognizancss, coastracxs, agTednrnts ar indemnity and other eanditioaal or abiigatory underiakings snd any ead atl notices and documetats canoe{ing ur terminating ch� Conyasrt;l'S liability t}�e�under, and any Such irisRumrnts sp exe�trte� !yy any such AtEamey-in-Fact sheil ix bierling upon thc Co�rapaoy as if signcd by the Presi�tent and sealed and effxi�d by t�e Cnrporatc Secaetary. Be ii Resdved that Hte sigtaature af arey authorized offioa� snd seal of ihe Comgany hd-etoforc or }tcreafter a#i'ixcd to any power ot'�twmey or any cettlficate relaring rkereto by Eacsimile, and any power af attomey ar certificate bee�rrimg facs➢mile signaca►re or facsimile seai shal9 be valid and binding upon ehe Company with r�spax to nny bond or undateking av vrh9ch it is attaclded. (Adapted ca a meetin,g held on 2ti'� of ripril, /A99.) dn ii��imess 13'hereaj, SiiRETEC dNSiJRANCE �OA�'Al+�Y has causad these pr�sents ta be s'rgned by its Presidenc, and its corpoYat� seal to be hereta afliixed this sn� day ai s�,.� A.D. zoza . SiBbC OFTC7C�.S SS: C-ouuiy o.fHazris ,�5��ry� S�„IR�'d'EC il�dS[TRA1K�� OMI'Afdit �, r r'�'� � Q t�� $Y' s� y ri�� id�€C�tC� C. Ke[at[g, P't�eSi(ittlE � �°r '+.,�...�'� Y ✓ * i3n tfais am sisy af �,,�c� A.D. � tsefae me personally came Niictaul C. i�siauig, to me t�own, ,vho, being by cna du9y sworn, 8id deposa and say„ ti�9e he c�sade3 in $iouSUon, Texas, ihai he is Pa�tsidtttt of SURETEC iAdSUBAYy'CE CandPAAIY, ths campany dessn'6ed in and vvhich cxecutes� t�e above instrcmeut; ai�st 6c lmows ti�c seal of ssid f�mpany; Y� the seal afi5xod 4o said ir�tevmcrtt is sush corgaate seat; that is w�s so aiiixed by order of the Board of Directors of said �ompsny, and shat he signed his nema Yhare�c3 6y 1i?cs oriier. p�i�e� A 5�lE�t� : � s�.� � �� ,� �dra@6�g Oi3 9�4�.i1 � � ` ..-` T�uya S'�eeed, No�Pabiic —� P,+Iy c.oanmission exp s March 3a, 2+@23 1, M. Btsnt Beaty, Assistaret Scrratary of 5URETEC fiiSIiRA?d�E CflMPANY, d�o hercby sertify that the. abave and for�gaing is a hve and correcx copy of n Power of �ttomey, executed by said Company, whieh is st'sl! in fuli force and sffecY; and furehera�ora, ihe iesoDueians of the Boerd of iDira�vrs, set aut in ihc Power of Attacrny are in futl force a�d cffect, �C'iiven weder rny hand aaod the seal mf said Compae�y at H�ustmn, Texas this d�y of G��''� , A.D. s ' �_ . ` �' � !l�i. �cent �eaty, e�asistan et`{�etaay aa,y �r�anmse� dssu,�d tn excess oi 21,e penaity statsd akove 1s eotsaly dold acoa �ettaoue any uatsa�y. °cor +�ec[4leadoro oi the auatFwrity � tfils pmroer you easap eall (798j 812-080f9 arcy 3ausie4ess daq beteveen 8:30 mrst ae�d 6:00 pm CS7. STANDARD CITY CONDITIONS OF THE CONSTRUCTION CONTRACT FOR DEVELOPER AWARDED PRUJECTS CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 20] 3 STANDARD CIT'Y CONDITIONS OF THE CONSTRUCTION CONTRACT FOR DEVELOPER AWARDED PROJECTS TABLE OF CONTENTS Page Article 1— Definitions and Terminology .......................................................................................................... l 1.01 Defined Terms ............................................................................................................................... l 1.02 Terminology ..................................................................................................................................5 Article2 — Preliminary Matters .........................................................................................................................6 2.01 Before Starting Construction ........................................................................................................ 6 2.02 Preconstruction Conference ..........................................................................................................6 2.03 Public Meeting .............................................................................................................................. 6 Article 3— Contract Documents and Amending ............................................................................................... 6 3.01 Reference Standards .....................................................................................................................6 3.02 Amending and Supplementing Contract Documents .................................................................. 6 Article4— Bonds and Insurance ....................................................................................................................... 7 4.01 Licensed Sureties and Insurers ..................................................................................................... 7 4.02 Performance, Payment, and Maintenance Bonds ........................................................................ 7 4.03 Certificates of Insurance ............................................................................................................... 7 4.04 Contractor's Insurance ..................................................................................................................9 4.05 Acceptance of Bonds and Insurance; Option to Replace ...........................................................12 Article 5 — Contractor's Responsibilities ........................................................................................................12 5.01 Supervision and Superintendent .................................................................................................12 5.02 Labor; Working Hours ................................................................................................................13 5.03 Services, Materials, and Equipment ....................................................................................... 13 , 5.04 Pro�ect Schedule ..........................................................................................................................14 5.05 Substitutes and "Or-Equals" .......................................................................................................14 5.06 Pre-Qualification of Bidders (Prime Contractors and Subcontractors) .....................................16 5.07 Concerning Subcontractors, Suppliers, and Others ...................................................................16 5.08 Wage Rates ..................................................................................................................................18 5.09 Patent Fees and Royalties ...........................................................................................................19 5.10 Laws and Regulations .................................................................................................................19 5.11 Use of Site and Other Areas .......................................................................................................19 5.12 Record Documents ......................................................................................................................20 5.13 Safety and Protection ..................................................................................................................21 5.14 Safety Representative .................................................................................................................21 5.15 Hazard Communication Programs .............................................................................................22 5.16 Submittals ....................................................................................................................................22 5.17 Contractor's General Warranty and Guarantee ..........................................................................23 CITY OF FORT WORTH STANDARD CITY CONDIT[ONS — DEVELOPER AWARDED PROJECTS Revised:lanuary 10, 2013 5.18 Indemnifcation ...........................................................................................................................24 5.19 Delegation of Professional Design Services ..............................................................................24 5.20 Right to Audit : ............................................................................................................................25 5.21 Nondiscrimination .......................................................................................................................25 Article6- Other Work at the Site ...................................................................................................................26 6.01 Related Work at Site ...................................................................................................................26 Article7 - City's Responsibilities ...................................................................................................................26 7.01 Inspections, Tests, and Approvals ..............................................................................................26 7.02 Limitations on City's Responsibilities .......................................................................................26 7.03 Compliance with Safety Program ...............................................................................................27 Article 8- City's Observation Status During Construction ...........................................................................27 8.01 City's Project Representative .....................................................................................................27 8.02 Authorized Variations in Work ..................................................................................................27 8.03 Rejecting Defective Work ..........................................................................................................27 8.04 Deternninations for Work Performed ..........................................................................................28 Article9- Changes in the Work .....................................................................................................................28 9.01 Authorized Changes in the Work ...............................................................................................28 9.02 Notification to Surety ..................................................................................................................28 Article 10 - Change of Contract Price; Change of Contract Time ................................................................ 28 10.01 Change of Contract Price ............................................................................................................28 10.02 Change of Contract Time ............................................................................................................28 ]0.03 Delays ..........................................................................................................................................28 Article 11 - Tests and Inspections; Correction, Removal or Acceptance of Defective Work ......................29 11.01 Notice of Defects ........................................................................................................................29 11.02 Access to Work ...........................................................................................................................29 11.03 Tests and Inspections ..................................................................................................................29 11.04 Uncovering Work .......................................................................................................................30 11.05 City May Stop the Work .............................................................................................................30 11.06 Correction or Removal of Defective Work ................................................................................30 11.07 Correction Period ........................................................................................................................ 30 11.08 City May Correct Defective Work .............................................................................................31 Article12 - Completion .................................................................................................................................. 32 12.01 Contractor's Warranty of Title ................................................................................................... 32 12.02 Partial Utilization ........................................................................................................................32 12.03 Final Inspection ...........................................................................................................................32 12.04 Final Acceptance .........................................................................................................................33 Article13 - Suspension of Work .................................................................................................................... 33 13.01 City May Suspend Work ............................................................................................................33 Article14 - Miscellaneous ..............................................................................................................................34 14.O1 Giving Notice ..............................................................................................................................34 CITY OF FORT WORTH STANDARD CITY CONDITIONS - DEVELOP�R AWARDED PROJECTS Revised: January ] 0, 20 ] 3 14.02 Computation of Times ........................................................................... 14.03 Cumulative Remedies ............................................................................ 14.04 Survival of Obligations .......................................................................... 14.05 Headings ................................................................................................. ................................. 34 ................................. 34 ................................. 3 5 ................................. 35 CITY OF FORT WORTH STANDARD CITY CONDIT[ONS — DEVELOPER AWARDED PROJECTS Revised:lanuary 10, 2013 00 73 l0- 1 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Yage I of 35 ARTICLE 1— DEFINITIONS A1�D TERMINOLOGY 1.01 Defined Terms A. Wherever used in these General Cond'ations or in other Contract Documents, the terms listed below have the meanings indicated which are applicable to both the singular and plural thereof, and words denoting gender shall include the masculine, feminine and neuter. Said terms are generally capitalized or written in italics, but not always. When used in a context consistent with the definition of a listed-defined term, the term shall have a meaning as defined below whether capitalized or italicized or otherwise. In addition to rerms specifically defined, tenns with initial capital letters in the Contract Documents include references to identified articles and paragraphs, and the titles of other documents or forms. 1. Agr�eement - The written instrument which is evidence of the agreement between Developer and Contractor covering the Work 2. Asbestos—Any material that contains more than one percent asbestos and is friable or is releasing asbestos fibers into the air above current action levels established by the United States Occupational Safety and Health Administration. 3. Business Day — A business day is defined as a day that the City conducts normal business, generally Monday through Friday, except for federal or state holidays observed by the City. 4. Buzzsaw — City's on-line, electronic document management and collaboration system. 5. CalendaN Day — A day consisting of 24 hours measured from inidnight to the next midnight. 6. City— The City of Fort Worth, Texas, a Texas home-rule �nunicipal corporation, acting by, its gove�ning body through its City Manager, his designee, or agents authorized pursuant to its duly authoNzzed charter on his behalf. 7. Community Facilities Ag�eement (CFA) A Contract between the Developer and the City for the Construction of one or moNe following public facilities within the City public right-of- way or easement: WateY, Sanitary Sewer, St�^eet, Sto�^m Drain, St�eet Light, and Street Signs. A CFA may include pNivate facilities within the right-of-way dedicated as p�ivate right-of- way or easement on a recorded plat. 8. Contract—The entire and integr�ated written documerat incorporating the Contract Documents between the Developer, Contractor, and/oY City concerning the WoNk. The Contract super.redes prio�^ negotiations, representations, or agr�eements, whetheN written or oral. 9. Contract Documents—Those items that make up the contract and which must include the Ag�eement, and it's attachments such as standard construction specifications, standard City Conditions, other geneYal corrditions of the Developer, including: An Agreement CITY OF FORT WORTH STANDARD CITY CONDITIONS - DEVELOP�R AWARDED PROJECTS Revised: January 10, 2013 00 73 10- 2 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 2 of 35 � c. d. e. f. g• h. J• k. 1. m. n. Attachments to the Agreement i. Bid Form ii. Vendor Compliance with State Law Non-Resident Bidder iii. Prequalification Statement Current Prevailing Wage Rates Table (if required by City) Insurance Accord Form Payment Bond Performance Bond Maintenance Bond Power of Attorney for Bonds Workers Compensation Affidavit MWBE Commitment Form( If required by City) General Conditions Supplementary Conditions The Standard City Conditions Specifications specifically made part of the Contract Documents by attachment, if not attached, as incorporated by reference and described in the Table of Contents of the Project's Contract Documents o. Drawings p. Documentation submitted by contractor prior to Notice of Award. q. The following which may be delivered or issued after the effective date if the Agreement and, if issued become an incorporated part of the Contract Documents i. Notice to Proceed ii. Field Orders iii. Change Orders iv. Letters of Final Acceptance r. Approved Submittals, other Contractor submittals, and the reports and drawings of subsurface and physical conditions are not Contract Documents. 10. Cont�actor—The individual or entity with whom Developer has ente�ed into the Agreement. 11. Day or day — A day, unless otheNwise defined, shall mean a Calendar Day. 12. Developer — An individual or entity that desires to rrzake ceYtain improvements within the City of Fort Worth 13. DNawings—That part of the Contract Documents prepared or approved by Engineer which graphically shows the scope, extent, and cha�acter of the Work to be pe�formed by Cont�^actor. Submittals are not Drawings as so defined. 14. Engineer—The licensed professional engineeY o� engineering firn� registered in the State of Texas perfo�mrng professional services for the Developer. 15. Final Acceptance — The written notice given by the City to the Developer and/or Conh�actor that the Work specified in the Contract Documents has been completed to the satisfaction of the City. CITY OF FORT WORTH STANDARD CITY CONDITiONS — DEVELOP�R AWARDED PROJECTS Revised:lanuary 10, 2013 00 73 10- 3 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 3 of 35 16. Final Inspection — Inspection carried out by the City to ver� that the Contractor has completed the Work, and each and every part or appurtenance thereof, fully, entirely, and in conformance with the Contract Docunzents. 17. General Requirements A part of the ContNact Docurrzents between the Develope� and a Cont�actor. 18. Laws and Regulations Any and all applicable laws, rules, regulations, oNdinances, codes, and orders of any and all govern�nental bodies, agencies, authorities, and courts having jurisdiction. 19. Liens—Charges, security interests, or encumbrances upon Project funds, real property, or personal prope�^ry. 20. Milestone A principal event specified in the Cont�act Docu�nents relating to an inteNmediate Contract 3'ime prior to Final Acceptance of the WoYk. 2 L Non-Participating Change Order A document, which is prepared for and reviewed by the City, whrch is signed by Contractor, and Developer, and authorizes an addition, deletion, or revision in the Work or an adjustment i� the Contract P��ice or the Contract Time, issued on or after the Effective Date of the Agreement. 22. Participating Change Order A document, which is prepared for and approved by the City, which is signed by Contractor, DevelopeN, and Ciry and authorizes an addition, deletion, or �evision in the Work or an adjustment in the Contract Price or the Contract Time, issued on or after the Effective Date of the Ag�-eement. 23. Plans — See definition of Drawings. 24. Project Schedule A schedule, prepa�ed and maintained by Contractor, in accoNdance with the General Requirements, descNibing the sequence and duration of the activities comprising the ContractoN's plan to accofnplish the WoNk within the Conts^act Time. 25. Project—The Work to be performed unde� the �'ontract Documents. 26. Project Representative—The authorized representative of the City who will be assigned to the Szte. 27. Public Meeting — An announced meeting conducted by the Developer to facilitate public pa�ticipation and to assist the public in gazning an informed view of the Project. 28. Regula�• Working Hours — HouNs heginning at 7:00 a.m. and ending at 6:00 p.m., Monday thru FNiday (excluding legal holidays). 29. Samples—Physical examples of materials, equipment, or workmanship that are representative of some portion of the Work and which establish the standards by whzch such po�tion of the WoNk will be, judged. CITY OF PORT WORTH STANDARD CITY CONDITIONS — DLVGLOP�R AWARDED PR07ECTS Revised: Ja�ivary 10, 2013 00 73 10- 4 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 4 of 35 30. Schedule of Submittals A schedule, prepar^ed and maintained by Contractor, of required submittals and the time requirements to support scheduled performance of related construction activities. 31. Site—Lands or areas indicated in the Contract Documents as being furnished by City or Developer upon which the WoYk is to be perfornzed, including rights-of-way, permits, and easements fo� access thereto, and such other lands furnished by City or Develope�^ which are designated for the use of Contractof�. 32. Specifications—That part of the Contract Documents consisting of written requirenzents for materials, equipment, systems, standards and workmanship as applied to the Work, and certain administr�ative requirements and procedural matters applicable thereto. Specifications may be specifically made a part of the Cont�act Documents by attachment or, if not attached, may be incoNporated by reference as indicated in the Table of Contents (Division 00 DO 00) of each Project. 33. Standard City Conditions — That part of the Contract Documents setting forth �^equirements of the City. 34. Subco�tractoY An individual or entity having a diNect cont�act with Contractor or with any other Subcontractor fot� the performance of a pat^t of the Work at the Site. 35. Submittals All d�awings, diagrams, illustrations, schedules, and other data oN info�mation which are specifically prepa��ed or asse�nbled by o� for Contractor and submitted by Contractor to illustrate some portion of the Work. 36. Superintendent — The representative of the Contr^actor who is available at all times and able to receive instructions fi°om the City and/or Develope� and to act for the Contractor. 37. Supplementary Conditions—That part of the Contract Documents which amends or supplements the GeneNal Conditions. 38. SupplieN A manufacturer, fabricatoN, supplier, distributo�, n�aterzalman, or vendor having a direct contract with Cont�actof� or with any Subcont�actor to furnish materials oN equipment to be incoYporated in the Work by Contracto� or Subcontractor. 39. Underground Facilities All underground pipelines, conduits, ducts, cables, wil�es, manholes, vaults, tanks, tunnels, or other such facilities or attachrnents, and any encasements containing such faczlities, including but not limited to, those that convey electricity, gases, steam, liquid petroleum products, telephone or other communicatio�s, cable television, wateY, wastewater, storm water, otheN liquids oY chemicals, or tra�c or othe�^ control systems. 40. Weekend Working Hours — Hours beginning at 9: 00 a.m. and ending at 5: 00 p.m., Saturday, Sunday oN legal holiday, as app�oved in advance by the City. CITY OF PORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARD�D PROJECTS Revised: January 10, 2013 00 73 10- 5 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 5 of 35 41. Work—The entire const�^uction or the various separately zdentifiable parts thereof required to be provided under the Cont�act Documents. Work includes and is the result of perfo�^ming or providing all labor, services, and documentation necessary to produce such construction including any Participatzng Change OrdeN, Non-Participating Change Ordel^, or Field OrdeN, and furnishing, installing, and incorporating all materials and equipment into such const�uction, all as required by the Contr�act Documents. 42. Wo�king Day — A working day is defined as a day, not including Saturdays, Sundays, of° legal holidays authorized by the City for contract purposes, in which weather oN otheY conditions not under the control of the Contractor will permit the performance of the principal unit of work unde�way for a continuous period of rrot less than 7 hours between 7 a. m. and 6 p. m. 1.02 Tef�minology A. The words and terms discussed in Paragraph 1.02.B through D are not defined but, when used in the Bidding Requirements or Contract Documents, have the indicated meaning. B. Defective: 1. The word "defective," when modifying the word "Work," refers to Work that is unsatisfactory, faulty, or deficient in that it: a. does not conform to the Contract Documents; or b. does not meet the requirements of any applicable inspection, reference standard, test, or approval referred to in the Contract Documents; or c. has been damaged prior to City's written acceptance. C. Furnzsh, Install, PerfoYm, Provide: The word "Furnish" or the word "Install" or the word "Perform" or the word "Provide" or the word "Supply," or any combination or similar directive or usage thereof, shall mean furnishing and incorporating in the Work including all necessary labor, materials, equipment, and everything necessary to perform the Work indicated, unless specifically limited in the context used. D. Unless stated otherwise in the Contract Documents, words or phrases that have a well-known technical or construction industry or trade meaning are used in the Contract Documents in accordance with such recognized meaning. CITY OF FORT WORTH STANDARD CITY CONDITIONS — D�VELOPER A W ARDED PROJEC7'S Revised:January 10,2013 00 73 10- 6 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 6 oP35 ARTICLE 2 — PRELIMINARY MATTERS 2.01 Before Starting Construction Baseline Schedules: Submit to City in accordance with the Contract Documents, and prior to starting the Work. New schedules will be submitted to City when Participating Change Orders or Non- Participating Change Orders occur. 2.02 P��econstr�uction Conference Before any Work at the Site is started, the Contractor shall attend a Preconstruction Conference as specified in the Contract Documents. 2.03 Public Meeting Contractor may not mobilize any equipment, materials or resources to the Site prior to Contractor attending the Public Meeting as scheduled by the City. ARTICLE 3— CONTRACT DOCUMENTS AND AMENDING 3.01 Reference Standards A. Standards, Specifications, Codes, Laws, and Regulations Reference to standards, specifications, manuals, or codes of any technical society, organization, or association, or to Laws or Regulations, whether such reference be specific or by implication, shall mean the standard, specification, manual, code, or Laws or Regulations in effect at the time of opening of Bids (or on the Effective Date of the Agreement if there were no Bids), except as may be otherwise specifically stated in the Contract Documents. 2. No provision or instruction shall be effective to assign to City, or any of its officers, directors, members, partners, employees, agents, consultants, or subcontractors, any duty or autharity to supervise or direct the performance of the Work or any duty or authority to undertake responsibility inconsistent with the provisions of the Contract Documents. 3.02 Amending and Supplementing Contract Documents A. The Contract Documents may be amended to provide for additions, deletions, and revisions in the Worlc or to modify the terms and conditions thereof by a Participating Change Order or a Non-Participating Change Order. B. The requirements of the Contract Documents may be suppleinented, and minor variations and deviations in the Work not involving a change in Contract Price or Contract Time, may be authorized, by one or rnore of the following ways: l. A Field Order; CITY OP FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January ]0,2013 00 73 10- 7 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 7 of 35 1. City's or Engineer's review of a Submittal (subject to the provisions of Paragraph 5.16.C); or 2. City's written interpretation or clarification. ARTICLE 4— BONDS AND INSURANCE 4.01 Licensed Sureties and Insurers All bonds and insurance required by the Contract Documents to be purchased and maintained by Contractor shall be obtained from surety or insurance companies that are duly licensed or authorized in the State of Texas to issue bonds or insurance policies for the limits and coverage so required. Such surety and insurance companies shall also meet such additional requirements and qualifications as may be provided Section 4.04. 4.02 Performance, Payment, and Maintenance Bonds A. Contractor shall furnish performance and payment bonds in the name of Developer and City, in accordance with Texas Govemment Code Chapter 2253 or successor statute, each in an amount equal to the Contract Price as security for the faithful performance and payment of all of Contractor's obligations under the Contract Documents. B. Contractor shall furnish maintenance bonds in the name of Developer and City in an ainount equal to the Contract Price as security to protect the City against any defects in any portion of the Work described in the Contract Documents. Maintenance bonds shall remain in effect for two (2) years after the date of Final Acceptance by the City. C. A(1 bonds shall be in the form prescribed by the Contract Documents except as provided otherwise by Laws or Regulations, and shall be executed by such sureties as are named in the list of "Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsuring Companies" as published in Circular 570 (amended) by the Financial Management Service, Surety Bond Branch, U.S. Department of the Treasury. All bonds signed by an agent or attorney-in-fact must be accompanied by a sealed and dated power of attorney which shall show that it is effective on the date the agent or attorney-in-fact signed eacli bond. D. If the surety on any bond furnished by Contractor is declared bankrupt or becomes insolvent or its right to do business is terminated in the State of Texas or it ceases to meet the requirements of Paragraph 4.02.C, Contractor shall promptly notify City and shall, within 30 days after the event giving rise to such notifcation, provide another bond and surety, both of which shall comply with the requirements of Paragraphs 4.01 and 4.02.C. 4.03 Certificates o, f Insurance Contractor shall deliver to Developer and City, with copies to each additional insured and loss payee identified in these Standard City Conditions certificates of insurance (and other evidence of insurance requested by City or any other additional insured) which Contractor is required to purchase and maintain. CITY OF FORT WORTH STANDARD C1TY CONDITIONS - DEVELOPER AWARDED PROJECTS Revised: January ]0, 2013 00 73 10- 8 Standard City Conditions Of 7he Construction Contract For Developer Awarded Projects Page 8 of 35 1. The certificate of insurance shall document the City, an as "Additional Insured" on all liability policies. 2. The Contractor's general liability insurance shall include a, "per project" or "per location", endorsement, which shall be identified in the certificate of insurance provided to the City. 3. The certificate shall be signed by an agent authorized to bind coverage on behalf of the insured, be complete in its entirety, and show complete insurance carrier names as listed in the current A.M. Best Property & Casualty Guide 4. The insurers for all policies must be licensed and/or approved to do business in the State of Texas. Except for workers' compensation, all insurers rnust have a minimum rating of A-: VII in the current A. M. Best Key Rating Guide or have reasonably equivalent financial strength and solvency to the satisfaction of Risk Management. If the rating is below that required, written approval of City is required. 5. All applicable policies shall include a Waiver of Subrogation (Rights of Recovery) in favor of the City. In addition, the Contractor agrees to waive all rights of subrogation against the Engineer (if applicable), and each additional insured identified in these Standard City Conditions. Failure of the City to demand such certificates or other evidence of full compliance with the insurance requirements or failure of the City to identify a deficiency from evidence that is provided shall not be construed as a waiver of Contractor's obligation to maintain such lines of insurance coverage. 6. If insurance policies are not written for specified coverage limits, an Umbrella or Excess Liability insurance for any differences is required. Excess Liability shall follow form of the primary coverage. 7. Unless otherwise stated, all required insurance shall be written on the "occurrence basis". If coverage is underwritten on a claims-made basis, the retroactive date shall be coincident with or prior to the date of the effective date of the agreement and the certificate of insurance shall state that the coverage is claims-made and the retroactive date. The insurance coverage shall be maintained for the duration of the Contract and for three (3) years following Final Acceptance provided under the Contract Documents or for the warranty period, whichever is longer. An annual certificate of insurance submitted to the City shall evidence such insurance coverage. 8. Policies shall have no exclusions by endorsements, which, neither nullify or amend, the required lines of coverage, nor decrease the limits of said coverage unless such endorsements are approved in writing by the City. In the event a Contract has been bid or executed and the exclusions are determined to be unacceptable or the City desires additional insurance coverage, and the City desires the contractor/engineer to obtain such coverage, the contract price shall be adjusted by the cost of the premium for such additional coverage plus 10%. Any self-insured retention (SIR), in excess of $25,000.00, affecting required insurance coverage shall be approved by the City in regards to asset value and stockholders' equity. In CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised:January 1Q 2013 00 73 ] 0- 9 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 9 of 35 lieu of traditional insurance, alternative coverage maintained through insurance pools or risk retention groups, must also be approved by City. 10. Any deductible in excess of $5,000.00, for any policy that does not provide coverage on a first-dollar basis, must be acceptable to and approved by the City. 11. City, at its sole discretion, reserves the right to review the insurance requirements and to make reasonable adjustments to insurance coverage's and their limits when deemed necessary and prudent by the City based upon changes in statutory law, court decision or the claims history of the industry as well as of the contracting party to the City. The City shall be required to provide prior notice of 90 days, and the insurance adjustments shall be incorporated into the Work by Change Order. 12. City shall be entitled, upon written request and without expense, to receive copies of policies and endorsements thereto and may inake any reasonable requests for deletion or revision or modifications of particular policy terms, conditions, limitations, or exclusions necessary to conform the policy and endorsements to the requirements of the Contract. Deletions, revisions, or modifications shall not be required where policy provisions are established by law or regulations binding upon either party or the underwriter on any such policies. 13. City shall not be responsible for the direct payment of insurance premium costs for Contractor's insurance. 4.04 ContractoN's InsuNance A. WoNkers Compensation and Esnployers' Liability. Contractor shall purchase and maintain such insurance coverage with limits consistent with statutory benefits outlined in the Texas Workers' Compensation Act (Texas Labor Code, Ch. 406, as amended), and minimum limits for Employers' Liability as is appropriate for the Work being performed and as will provide protection from claims set forth below which may arise out of or result from Contractor's performance of the Work and Contractor's other obligations under the Contract Documents, whether it is to be perfonned by Contractor, any Subcontractor or Supplier, or by anyone directly or indirectly employed by any of them to perform any of the Work, or by anyone for whose acts any of them may be liable: l. claims under workers' compensation, disability benefits, and other similar employee benefit acts; 2. claims for damages because of bodily injury, occupational sickness or disease, or death of Contractor's employees. 3. The limits of liability for the insurance shall provide the following coverages for not less than the following amounts or greater where required by Laws and Regulations a. Statutory limits b. Employer's liability CITY OF FORT WORTH STANDARD C1TY CONDITIONS — D�VELOPER AWA2DF,D PRO]ECTS Revised: January 10, 2013 00 73 10-10 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page ] 0 of 35 1) $100,000 each accidentloccurrence 2) $100,000 Disease - each employee 3) $500,000 Disease - policy limit B. Commercial General Liability. Coverage shall include but not be limited to covering liability (bodily injury or properiy damage} arising from: premises/operations, independent contractors, products/completed operations, personal injury, and liability under an insured contract. Insurance shall be provided on an occurrence basis, and as comprehensive as the current Insurance Services Office (ISO) policy. This insurance shall apply as primary insurance with respect to any other insurance or self-insurance programs afforded to the City. The Commercial General Liability policy, shall have no exclusions by endorsements that would alter of nullify premises/operations, products/completed operations, contractual, personal injury, or advertising injury, which are normally contained with the policy, unless the City approves such exclusions in writing. 1. For construction projects that present a substantial completed operation exposure, the City may require the contractor to maintain completed operations coverage for a minimum of no less than three (3) years following the completion of the project 2. Contractor's Liability Insurance under this Section which shall be on a per project basis covering the Contractor with minimum limits o£ a. $1,000,000 each occurrence b. $2,000,000 aggregate limit The policy must have an endorsement (Amendment — Aggregate Limits of Insurance) mal<ing the General Aggregate Limits apply separately to each job site. 4. The Commercial General Liability Insurance policies shall provide "X", "C", and "U" coverage's. Verification of such coverage must be shown in the Remarks Article of the Certificate of Insurance. C. Automobile Liability. A commercial business auto policy shall provide coverage on "any auto", defined as autos owned, hired and non-owned and provide indemnity for claims for damages because bodily injury or death of any person and or property damage arising out of the work, maintenance or use of any motor vehicle by the Contractor, any Subcontractor or Supplier, or by anyone directly or indirectly emp(oyed by any of them to perform any of the Work, or by anyone for whose acts any of them may be liable. Automobile Liability, Contractor's Liability Insurance under this Section, which shall be in an amount not less than the following amounts: a. Automobile I,iability - a commercial business policy shall provide coverage on "Any Auto", defined as autos owned, hired and non-owned. CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOP�R AWARDED PROJECTS Revised: January 1Q 2013 00 73 10- 11 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page ] 1 of 35 1) $1,000,000 each accident on a combined single limit basis. Split limits are acceptable if limits are at least: 2) $250,000 3) $500,000 4) $100,000 Bodily Injury per person Bodily Injury per accident / Property Damage D. Railroad Protective Liability. If any of the work or any warranty work is within the limits of railroad right-of-way, the Contractor shall comply with the following requirements: The Contractor's construction activities will require its employees, agents, subcontractors, equipment, and material deliveries to cross railroad properties and tracks owned and operated by: none 4��rite the nume oCthc iaiilrwid cum��anc (II none. thcn �crite noncl 2. The Contractor shall conduct its operations on railroad properties in such a manner as not to interfere with, hinder, or obstruct the railroad company in any manner whatsoever in the use or operation of its/their trains or other property. Such operations on railroad properties may require that Contractor to execute a"Right of Entry Agreement" with the particular railroad company or companies involved, and to this end the Contractor should satisfy itself as to the requirements of each railroad company and be prepared to execute the right-of-entry (if any) required by a railroad company. The requirements specified herein likewise relate to the Contractor's use of private and/or construction access roads crossing said railroad company's properties. 3. The Contractual Liability coverage required by Paragraph 5.04D of the General Conditions shall provide coverage for not less than the following amounts, issued by companies satisfactory to the City and to the Railroad Company for a term that continues for so long as the Contractor's operations and work cross, occupy, or touch railroad property: a. General Aggregate: b. Each Occurrence: : none lintcr limits ��ii�� iilcd h�� IZuihoud C'i�m�am (Ifnonc �vitr n�,nr� none I�ntci limitti �uo� idcd h�� R,�iliuu�l ('onipem (Ifnunc. �critc nunrl 4. With respect to the above outlined insurance requirements, the following shall govern: a. Where a single railroad company is involved, the Contractor shall provide one insurance policy in the name of the railroad company. However, if more than one grade separation or at-grade crossing is affected by the Project at entirely separate locations on the line or lines of the same railroad company, separate coverage may be required, each in the amount stated above. b. Where more than one railroad company is operating on the same right-of-way or where several railroad companies are involved and operated on their own separate rights-of- CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 00 73 10- 12 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 12 of 35 way, the Contractor may be required to provide separate insurance policies in the name of each railroad coinpany. c. If, in addition to a grade separation or an at-grade crossing, other work or activity is proposed on a railroad company's right-of-way at a location entirely separate from the grade separation or at-grade crossing, insurance coverage for this work must be included in the policy covering the grade separation. d. If no grade separation is involved but other work is proposed on a railroad company's right-of-way, all such other work may be covered in a single policy for that railroad, even though the work may be at two or more separate locations. No work or activities on a railroad company's property to be performed by the Contractor shall be commenced until the Contractor has furnished the City with an original policy or policies of the insurance for each railroad company named, as required above. All such insurance must be approved by the City and each affected Railroad Company prior to the Contractor's beginning work. 6. The insurance specified above must be carried until all Work to be performed on the railroad right-of-way has been completed and the grade crossing, if any, is no longer used by the Contractor. In addition, insurance must be carried during all maintenance and/or repair work performed in the railroad right-of-way. Such insurance must name the railroad coinpany as the insured, together with any tenant or lessee of the railroad company operating over tracks involved in the Project. E. Notifieation of Policy Cancellation: Contractor shall immediately notify City upon cancellation or other loss of insurance coverage. Contractor shall stop work until replacement insurance has been procured. There shall be no time credit for days not worked pursuant to this section. 4.05 Acceptance of Bonds and InsuNance; Option to Replace If City has any objection to the coverage afforded by or other provisions of the bonds or insurance required to be purchased and inaintained by the Contractor in accordance with Article 5 on the basis of non-conformance with the Contract Documents, the Developer and City shall so notify the Contractor in writing within 10 Business Days after receipt of the certificates (or other evidence requested). Contractor shall provide to the City such additional information in respect of insurance provided as the Developer or City inay reasonably request. If Contractor does not purchase or maintain all of the bonds and insurance required by the Contract Documents, the Developer or City shall notify the Contractor in writing of such failure prior to the start of the Work, or of such failure to maintain prior to any change in the required coverage. ARTICLE 5 — CONTRACTOR'S RESPONSIBILITIES S.O1 Supervision and Superintendent A. Contractor shall supervise, inspect, and direct the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perfonn the CITY OF FORT WORTti STANDARD CITY CONDITIONS — DEVELOPER AWARD�D PROJECTS Revised: Ja�luary 10, 2013 00 73 ] 0- 13 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page I 3 of 35 Work in accordance with the Contract Documents. Contractor shall be solely responsible for the means, methods, techniques, sequences, and procedures of construction. B. At all times during the progress of the Work, Contractor shall assign a competent, English- speaking, Superintendent who shall not be replaced without written notice to City. The Superintendent will be Contractor's representative at the Site and shall have authority to act on behalf of Contractor. All communication given to or received from the Superintendent shall be binding on Contractor. C. Contractor shall notify the City 24 hours prior to moving areas during the sequence of construction. 5.02 Labor; Working Hours A. Contractor shall provide competent, suitably qualified personnel to perform construction as required by the Contract Documents. Contractor shall at all times maintain good discipline and order at the Site. B. Except as otherwise required for the safety or protection of persons or the Work or property at the Site or adjacent thereto, and except as otherwise stated in the Contract Documents, all Work at the Site shall be performed during Regular Working Hours. Contractor will not permit the performance of Work beyond Regular Working Hours or for Weekend Working Hours without City's written consent (which will not be unreasonably withheld). Written request (by letter or electronic communication) to perform Worlc 1. for beyond Regular Working Hours request must be made by noon at least two (2) Business Days prior 2. for Weekend Working Hours request must be inade by noon of the preceding Thursday for legal holidays request must be made by noon two Business Days prior to the legal holiday. 5.03 Services, Materials, and Equipment A. Unless otherwise specified in the Contract Documents, Contractor shall provide and assume full responsibility for all services, materials, equipment, labor, transportation, construction equipment and machinery, tools, appliances, fuel, power, light, heat, telephone, water, sanitary facilities, temporary facilities, and all other facilities and incidentals necessary for the perforrnance, Contractor required testing, start-up, and completion of the Work. B. All materials and equipment incorporated into the Work shall be as specified or, if not specified, shall be of good quality and new, except as otherwise provided in the Contract Documents. All special warranties and guarantees required by the Specifications shall expressly run to the benefit of City. If required by City, Contractor shall furnish satisfactory evidence (including reports of required tests) as to the source, lcind, and quality of materials and equipment. CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEV�LOPER AWARDED PROJECTS Revised: January 10, 2013 00 73 ] 0- 14 Standard City Conditions Of The Consiruction Contract For Developer Awarded Projects Page ] 4 of 35 C. All nnaterials and equipment to be incorporated into the Work shall be stored, applied, installed, connected, erected, protected, used, cleaned, and conditioned in accordance with instructions of the applicable Supplier, except as otherwise may be provided in the Contract Documents. 5.04 Project Schedule A. Contractor shall adhere to the Project Schedule established in accordance with Paragraph 2.01 and the General Requirements as it may be adjusted from time to time as provided below. 1. Contractor shall submit to City for acceptance (to the extent indicated in Paragraph 2.01 and the General Requirements) proposed adjustments in the Project Schedule. Proposed adjustments in the Project Schedule that will change the Contract Time shall be submitted in accordance with the requirements of Article 9. Adjustments in Contract Time for projects with City participation shall be made by participating change orders. 5.05 Substitutes and "O�°-Equals " A. Whenever an item of material or equipment is specified or described in the Contract Documents by using the name of a proprietary itein or the name of a partieular Supplier, the specification or description is intended to establish the type, function, appearance, and quality required. Unless the specification or description contains or is followed by words reading that no like, equivalent, or "or-equal" itenn or no substitution is permitted, other items of material or equipment of other Suppliers may be submitted to City for review under the circumstances described below. 1. "Or-Equal " Items: If in City's sole discretion an item of material or equipment proposed by Contractor is functionally equal to that named and suf�ciently similar so that no change in related Work will be required, it may be considered by City as an "or-equal" item, in which case review and approval of the proposed item may, in City's sole discretion, be accomplished without compliance with some or all of the requirements for approval of proposed substitute items. For the purposes of this Paragraph S.OS.A.1, a proposed item of material or equipment will be considered functionally equal to an item so named if: a. City detennines that: 1) it is at least equal in materials of construction, quality, durability, appearance, strength, and design characteristics; 2) it will reliably perform at least equally well the function and achieve the results innposed by the design concept of the completed Project as a functioning whole; and 3) it has a proven record of perfonnance and availability of responsive service; and b. Contractor certifies that, if approved and incorporated into the Work: 1) there will be no increase in cost to the City or increase in Contract Time; and CITY OF FORT WORTH STANDARD CITY CONDITIONS - DCVELOPER AWARDED PKOJECTS Revised: January 1 Q 20] 3 00 73 10- 15 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 15 of 35 2) it will conform substantially to the detailed requirements of the item named in the Contract Documents. 2. Substitute Items.� a. If in City's sole discretion an item of material or equipment proposed by Contractor does not qualify as an "or-equal" item under Paragraph S.OS.A.1, it may be submitted as a proposed substitute item. b. Contractor shall submit sufficient information as provided below to allow City to determine if the item of material or equipment proposed is essentially equivalent to that named and an acceptable substitute therefor. Requests for review of proposed substitute items of material or equipment will not be accepted by City from anyone other than Contractor. c. Contractor shall make written application to City for review of a proposed substitute item of rnaterial or equipment that Contractor seeks to furnish or use. The application shall comply with Section O1 25 00 and: 1) shall certify that the proposed substitute item will: i. perform adequately the functions and achieve the results called for by the general design; ii. be similar in substance to that specified; iii. be suited to the same use as that specified; and 2) will state: i. the extent, if any, to which the use of the proposed substitute item will prejudice Contractor's achieveinent of final completion on time; ii. whether use of the proposed substitute item in the Work will require a change in any of the Contract Documents (or in the provisions of any other direct contract with City for other work on the Project) to adapt the design to the proposed substitute item; iii. whether incorporation or use of the proposed substitute item in connection with the Work is subject to payment of any license fee or royalty; and 3) will identify: i. all variations of the proposed substitute item from that specified; ii. available engineering, sales, maintenance, repair, and replacement servicas; and CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDGD PROJECTS Revised: Ja��uary 10, 2013 00 73 ] 0- 16 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 16 of 35 4) shall contain an itemized estimate of all costs or credits that will result directly or indirectly from use of such substitute item, including costs of redesign and Damage Claims of other contractors affected by any resulting change. B. Substitute Construction Methods or Procedures: If a specific means, method, technique, sequence, or procedure of construction is expressly required by the Contract Documents, Contractor may furnish or utilize a substitute means, method, technique, sequence, or procedure of construction approved by City. Contractor shall submit sufficient information to allow City, in City's sole discretion, to determine that the substitute proposed is equivalent to that expressly called for by the Contract Documents. Contractor shall make written application to City for review in the same manner as those provided in Paragraph S.OS.A.2. C. City's Evaluation: City will be allowed a reasonable time within which to evaluate each proposal or submittal made pursuant to Paragraphs S.OS.A and S.OS.B. City may require Contractor to furnish additional data about the proposed substitute. City will be the sole judge of acceptability. No "or-equal" or substitute will be ordered, installed or utilized until City's review is complete, which will be evidenced by a Change Order in the case of a substitute and an accepted Submittal for an "or-equal." City will advise Contractor in writing of its determination. D. Special Guarantee: City may require Contractor to furnish at Contractor's expense a special performance guarantee, warranty, or other surety with respect to any substitute. Contracto� shall indemn� and hold harmless City and anyone directly or indirectly employed by them fi�om and against any and all claims, datnages, losses and expenses (including attorneys fees) arising out of the use of substituted materials o� equipment. E. Ciry's Cost ReimburseJnent: City will record City's costs in evaluating a substitute proposed or submitted by Contractor pursuant to Paragraphs S.OS.A.2 and S.OS.B. Whether or not City approves a substitute so proposed or submitted by Contractor, Contractor may be required to reimburse City for evaluating each such proposed substitute. Contractor may also be required to reimburse City for the charges for making changes in the Contract Documents. F. Contractor's Expense: Contractor shall provide all data in support of any proposed substitute or "or-equal" at Contractoc's expense. G. Substitute Reimbursement: Costs (savings or charges) attributable to acceptance of a substitute shall be incorporated to the Contract by Participating Change Order. 5.06 Pre-Qualification of Bidders (PNime Contf-actors and Subcont�^actors) A. The Contractor and any subcontractors are required to be prequalified for the wark types requiring pre-qualification 5.07 Concerning Subcontractars, Supplzers, and OtheNs A. Minority and Women Owned Business EnterpYise Compliance: CiTY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 00 73 ] 0- 17 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 17 of 35 ❑ Required for this Contract. fC'hcck this hu� if Ihcrc is um ('iK Puruci�atiun) � Not Required for this Contract. It is City policy to ensure the full and equitable participation by Minority and Women Business Enterprises (MWBE) in the procurement of goods and services on a contractual basis. If the Contract Documents provide for a MWBE goal, Contractor is required to comply with the intent of the City's MWBE Ordinance (as amended) by the following: 1. Contractor shall, upon request by City, provide complete and accurate information regarding actual work performed by a MWBE on the Contract and payment therefor. 2. Contractor will not make additions, deletions, or substitutions of accepted MWBE without written consent of the City. Any unjustified change or deletion shall be a material breach of Contract and may result in debarment in accordance with the procedures outlined in the Ordinance. 3. Contractor shall, upon request by City, allow an audit and/or examination of any books, records, or files in the possession of the Contractor that will substantiate the actual work performed by an MWBE. Material misrepresentation of any nature will be grounds for termination of the Contract. Any such misrepresentation may be grounds for disqualification of Contractor to bid on future contracts with the City for a period of not less than three years. B. Contractor shall be fully responsible to City for all acts and omissions of the Subcontractors, Suppliers, and other individuals or entities performing or furnishing any of the Work just as Contractor is responsible for Contractor's own acts and omissions. Nothing in the Contract Documents: l. shall create for the benefit of any such Subcontractor, Supplier, or other individual or entity any contractual relationship between City and any such Subcontractor, Supplier or other individual or entity; nor 2. shall create any obligation on the part of City to pay or to see to the payment of any moneys due any such Subcontractor, Supplier, or other individual or entity except as may otherwise be required by Laws and Regulations. C. Contractor shall be solely responsible for scheduling and coordinating the Work of Subcontractors, Suppliers, and other individuals or entities performing or furnishing any of the Work under a direct or indirect contract with Contractor. D. All Subcontractors, Suppliers, and such other individuals or entities performing or furnishing any of the Work shall communicate with City through Contractor. E. All Work performed for Contractor by a Subcontractor or Supplier will be pursuant to an appropriate agreement between Contractor and the Subcontractor or Supplier which specifically binds the Subcontractor or Supplier to the applicable terms and conditions of these Contract CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPtiR AWARDED PROJECTS Revised: January 10, 2013 00 73 10- 18 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 18 of 35 Documents, Contractor shall provide City contract numbers and reference numbers to the Subcontractors and/or Suppliers. 5.08 Wage Rates Required for this Contract. ❑ Not Required for this Contract. A. Duty to pay Prevailing Wage Rates. The Contractor shall comply with all requirements of Chapter 2258, Texas Government Code (as amended), including the payment of not less than the rates determined by the City Council of the City of Fort Worth to be the prevailing wage rates in accordance with Chapter 2258. Such prevailing wage rates are included in these Contract Documents. B. Penalty for Violation. A Contractor or any Subcontractor who does not pay the prevailing wage shall, upon demand made by the City, pay to the City $60 for each worker employed for each calendar day or part of the day that the worker is paid less than the prevailing wage rates stipulated in these contract documents. This penalty shall be retained by the City to offset its administrative costs, pursuant to Texas Government Code 2258.023. C. Complaints of Violations and City Determinatiorr of Good Cause. On receipt of information, including a complaint by a worker, concerning an alleged violation of 2258.023, Texas Government Code, by a Contractor or Subcontractor, the City shall make an initial determination, before the 31st day after the date the City receives the infarmation, as to whether good cause exists to believe that the violation occurred. The City shall notify in writing the Contractor or Subcontractor and any affected worker of its initial determination. Upon the City's determination that there is good cause to believe the Contractor or Subcontractor has violated Chapter 2258, the City shall retain the full amounts claimed by the claimant or claimants as the difference between wages paid and wages due under the prevailing wage rates, such amounts being subtracted from successive progress payments pending a final determination of the violation. D. Arbitration Required if Violation Not Resolved. An issue relating to an alleged violation of Section 2258.023, Texas Government Code, including a penalty owed to the City or an affected worker, shall be submitted to binding arbitration in accordance with the Texas General Arbitration Act (Article 224 et seq., Revised Statutes) if the Contractor or Subcontractor and any affected worker does not resolve the issue by agreement before the 15th day after the date the City makes its initial determination pursuant to Paragraph C above. If the persons required to arbitrate under this section do not agree on an arbitrator before the 1 lth day after the date that arbitration is required, a disirict court shall appoint an arbitrator on the petition of any of the persons. The City is not a party in the arbitration. The decision and award of the arbitrator is final and binding on all parties and may be enforced in any court of competent jurisdiction. E. Records to be Maintarned. The Contractor and each Subcontractor shall, for a period of three (3) years following the date of acceptance of the work, maintain records that show (i) the name and CITY OP FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARD�D PROJECTS Revised: Jamiary 10, 2013 00 73 10- 19 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 19 of 35 occupation of each worker employed by the Contractor in the construction of the Work provided for in this Contract; and (ii) the actual per diem wages paid to each worker. The records shall be open at all reasonable hours for inspection by the City. The provisions of Paragraph 6.23, Right to Audit, shall pertain to this inspection. F. Progress Payments. With each progress payznent ar payroll period, whichever is less, the Contractor shall submit an affidavit stating that the Contractor has complied with the requirements of Chapter 2258, Texas Government Code. G. Posting of Wage Rates. The Contractor shall post prevailing wage rates in a conspicuous place at all times. H. Subcontractor Compliance. The Contractor shall include in its subcontracts and/or shall otherwise require all of its Subcontractors to comply with Paragraphs A through G above. 5.09 Patent Fees and Royalties A. To the fullest extent permitted by Laws and Regulations, Contractor shall indemn� and hold harnzless City, fi�ofn and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and otheN professionals and all court or arbitr�ation oN other dispute Yesolution costs) arising out of or relating to any infi�ingement of patent rights or copyrights incident to the use in the performance of the Work o� resulting from the incorporation in the Work of any invention, design, pJ�ocess, product, or device not specified in the Contract Documenls. 5.10 Laws and Regulations A. Contractor shall give all notices required by and shall comply with all Laws and Regulations applicable to the performance of the Work. Except where otherwise expressly required by applicable Laws and Regulations, the City shall not be responsible for monitoring Contractor's compliance with any Laws or Regulations. B. If Contractor performs any Work knowing or having reason to lcnow that it is contrary to Laws or Regulations, Contractor shall bear all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such Work. However, it shall not be Contractor's responsibility to make certain that the Specifications and Drawings are in accordance with Laws and Regulations, but this shall not relieve Contractor of Contractor's obligations under Paragraph 3.01. 5.11 Use of Site and Other Areas A. Limitation on �Tse of Site and Other AYeas.• Contractor shall confine construction equiprnent, the storage of materials and equipment, and the operations of workers to the Site and other areas permitted by Laws and Regulations, and shall not unreasonably encumber the Site and other areas with construction equipment or CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: Ja�mary ]0, 2013 00 73 ] 0- 20 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 20 of 35 other materials or equipment. Contractor shall assume full responsibility for any damage to any such land or area, or to the owner or occupant thereof, or of any adjacent land or areas resulting from the performance of the Work. 2. At any time when, in the judgment of the City, the Contractor has obstructed or closed or is carrying on operations in a portion of a street, right-of-way, or easement greater than is necessary for proper execution of the Work, the City may require the Contractor to finish the section on which operations are in progress before work is commenced on any additional area of the Site. 3. Should any Damage Claim be made by any such owner or occupant because of the performance of the Work, Contractor shall promptly attempt to resolve the Damage Claim. 4. Pursuant to Paragraph 5.1 S, Contractor shall indemn� and hold ha�mless City, fi�om and against all claisns, costs, losses, and danzages arising out of or relating to any claim o� actzon, legal or equitable, brought by any such owner or occupant against City. B. Removal of DebYis During Perfo�mance of the Work: During the progress of the Work Contractor shall keep the Site and other areas free from accumulations of waste materials, rubbish, and other debris. Removal and disposal of such waste materials, rubbish, and other debris shall conform to applicable Laws and Regulations. C. Site Maintenance Cleaning.• 24 hours after written notice is given to the Contractor that the clean-up on the job site is proceeding in a manner unsatisfactory to the City or Developer, if the Contractor fails to correct the unsatisfactory procedure, the City may take such direct action as the City deems appropriate to correct the clean-up deficiencies cited to the Contractor in the written notice (by letter ar electronic communication), and shall be entitled to recover its cost in doing so. The City may withhold Final Acceptance until clean-up is complete and cost are recovered. D. Final Site Cleaning.• Prior to Final Acceptance of the Work Contractor shall clean the Site and the Work and make it ready for utilization by City or adjacent property owner. At the completion of the Work Contractor shall remove from the Site all tools, appliances, construction equipment and machinery, and surplus materials and shall restore to original condition or better all property disturbed by the Work. E. Loading Structures: Contractor shall not load nor permit any part of any structure to be loaded in any manner that will endanger the structure, nor shall Contractor subject any part of the Work or adjacent properiy to stresses or pressures that will endanger it. 5.12 Record Doculnents A. Contractor shall maintain in a safe place at the Site or in a place designated by the Contractor and approved by the City, one (1) record copy of all Drawings, Specifications, Addenda, Change Orders, Field Orders, and written interpretations and clarifications in good order and annotated to show changes made during construction. These record documents together with all approved CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEV�LOPER AWARD�D PROJECCS Revised: January 10, 2013 00 73 10- 21 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 21 of 35 Samples and a counterpart of all accepted Submittals will be available to City for reference. Upon completion of the Work, these record documents, any operation and maintenance manuals, and Submittals will be delivered to City prior to Final Inspection. Contractor shall include accurate locations for buried and imbedded items. 5.13 Safety and PYotection A. Contractor shall be solely responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the Work. Such responsibility does not relieve Subcontractors of their responsibility for the safety of persons or property in the performance of their work, nor for compliance with applicable safety Laws and Regulations. Contractor shall take all necessary precautions for the safety of, and shall provide the necessary protection to prevent darnage, injury or loss to: all persons on the Site or who may be affected by the Work; 2. all the Work and materials and equipment to be incorporated therein, whether in storage on or off the Site; and 3. other property at the Site or adjacent thereto, including trees, shrubs, lawns, walks, pavements, roadways, structures, utilities, and Underground Facilities not designated for removal, relocation, or replacement in the course of construction. B. Contractor shall comply with all applicable Laws and Regulations relating to the safety of persons or property, or to the protection of persons or property from damage, injury, or loss; and shall erect and maintain all necessary safeguards for such safety and protection. Contractor shall notify owners of adjacent property and of Underground Facilities and other utility owners when prosecution of the Work may affect them, and shall cooperate with them in the protection, removal, relocation, and replacement of their property. C. Contractor shall comply with the applicable requirements of City's safety programs, if any. D. Contractor shall inform City of the specific requirements of Contractor's safety program, if any, with which City's employees and representatives must comply while at the Site. E. All damage, injury, or loss to any property referred to in Paragraph 5.13.A.2 or 5.13.A.3 caused, directly or indirectly, in whole or in part, by Contractor, any Subcontractor, Supplier, or any other individual or entity directly or indirectly employed by any of them to perform any of the Work, or anyone for whose acts any of them may be liable, shall be remedied by Contractor. F. Contractor's duties and responsibilities for safety and for protection of the Work shall continue until such time as all the Work is completed and City has accepted the Work. 5.14 Safety Representative Contractor shall inform City in writing of Contractor's designated safety representative at the Site. C1TY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: Ja�ivary 10, 2013 00 73 10- 22 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 22 of 35 5.15 Hazard Communication P�ografns Contractor shall be responsible for coordinating any exchange of material safety data sheets or other hazard communication information required to be made available to or exchanged between or among employers in accordance with Laws or Regulations. 5.16 Submittals A. Contractor shall submit required Submittals to City for review and acceptance. Each submittal will be identified as required by City. 1. Submit number of copies specified in the General Requirements. 2. Data shown on the Submittals will be complete with respect to quantities, dimensions, specified perforinance and design criteria, materials, and similar data to show City the services, materials, and equipment Contractor proposes to provide and to enable City to review the information for the limited purposes required by Paragraph 5.16.C. 3. Submittals submitted as herein provided by Contractor and reviewed by City for confonnance with the design concept shall be executed in conformity with the Contract Documents unless otherwise required by City. 4. When Submittals are subrnitted for the purpose of showing the installation in greater detail, their review shall not excuse Contractor from requirements shown on the Drawings and Specifications. 5. For-Information-Only submittals upon which the City is not expected to conduct review or take responsive action may be so identified in the Contract Documents. 6. Submit required number of Samples specified in the Specifications. 7. Clearly identify each Sample as to material, Supplier, pertinent data such as catalog numbers, the use for which intended and other data as City may require to enable City to review the submittal for the limited purposes required by Paragraph 5.16.C. B. Where a Submittal is required by the Contract Docutnents or the Schedule of Submittals, any related Work performed prior to City's review and acceptance of the pertinent submittal will be at the sole expense and responsibility of Contractor. C. City's Review: l. City will provide timely review of required Submittals in accordance with the Schedule of Submittals acceptable to City. City's review and acceptance will be only to detennine if the items covered by the submittals will, after installation or incorporation in the Work, conform to the information given in the Contract Documents and be compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Docurnents. CITY OF POi2T' WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised:January iQ 2013 00 73 10- 23 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 23 of 35 2. City's review and acceptance will not extend to means, methods, techniques, sequences, or procedures of construction (except where a particular means, method, technique, sequence, or procedure of construction is specifically and expressly called for by the Contract Documents) or to safety precautions or programs incident thereto. The review and acceptance of a separate item as such will not indicate approval of the assembly in which the item functions. 3. City's review and acceptance shall not relieve Contractor from responsibility for any variation from the requirements of the Contract Documents unless Contractor has complied with the requirements of Section O1 33 00 and City has given written acceptance of each such variation by specific written notation thereof incorporated in or accompanying the Submittal. City's review and acceptance shall not relieve Contractor from responsibility for complying with the requirements of the Contract Documents. 5.17 Contr^actor's General War�anty and Guarantee A. Contractor warrants and guarantees to City that all Work will be in accordance with the Contract Documents and will not be defective. City and its officers, directors, members, partners, employees, agents, consultants, and subcontractors shall be entitled to rely on representation of Contractor's warranty and guarantee. $. Contractor's warranty and guarantee hereunder excludes defects or damage caused by: abuse, modification, or improper maintenance or operation by persons other than Contractor, Subcontractors, Suppliers, or any other individual or entity for whom Contractor is responsible; or 2. nonnal wear and tear under normal usage. C. Contractor's obligation to perform and complete the Work in accordance with the Contract Documents shall be absolute. None of the following will constitute an acceptance of Work that is not in accordance with the Contract Documents or a release of Contractor's obligation to perform the Worlc in accordance with the Contract Documents: 1. observations by City; 2. recommendation or payment by City or Developer of any progress or final payment; the issuance of a certificate of Final Acceptance by City or any payment related thereto by City; 4. use or occupancy of the Work or any part tllereof by City; 5. any review and acceptance of a Submittal by City; 6. any inspection, test, or approval by others; or C1TY OF FORT WORTH STANDARD CITY CONDITIONS —DEVELOPER AWARDED PROJCCTS Revised: January 10, 2013 00 73 10- 24 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 24 of 35 7. any correction of defective Work by City. D. The Contractor shall remedy any defects or damages in the Work and pay for any damage to other work or property resulting therefrom which shall appear within a period of two (2) years from the date of Final Acceptance of the Work unless a longer period is specified and shall furnish a good and sufficient maintenance bond, complying with the requirements of Article 4.02.B. The City will give notice of observed defects with reasonable promptness. 5.18 Indemnification A. Contractor covenants and agrees to indemnify, hold harmless and defend, at its own expense, the City, its officers, servants and employees, from and against any and all claims arising out of, or alleged to arise out of, the work and services to be performed by the Contractor, its officers, agents, employees, subcontractors, licenses or invitees under this Contract. THIS INDEMNIFICATION PROVISION IS SPECIFICALLY INTENDED TO OPERATE AND BE EFFECTIVE EVEN IF IT IS ALLEGED OR PROVEN THAT ALL OR SOME OF THE DAMAGES BEING SOUGHT WERE CAUSED, IN WHOLE OR IN PART, BY ANY ACT, OMISSION OR NEGLIGENCE OF THE CITY. This indemnity provision is intended to include, without limitation, indemnity for costs, expenses and legal fees incurred by the City in defending against such claims and causes of actions. B. Contractor covenants and agrees to indemnify and hold harmless, at its own expense, the City, its officers, servants and employees, from and against any and all loss, damage or destruction of property of the City, arising out of, or alIeged to arise out of, the work and services to be performed by the Contractor, its officers, agents, employees, subcontractors, licensees or invitees under this Contract. THIS INDEMNIFICATION PROVISION IS SPECIFICALLY INTENDED TO OPERATE AND BE EFFECTIVE EVEN IF IT IS ALLEGED OR PROVEN THAT ALL OR SOME OF THE DAMAGES BEING SOUGHT WERE CAUSED, IN WHOLE OR IN PART, BY ANY ACT, OMISSION OR NEGLIGENCE OF THE CITY. 5.19 Delegation of PNofessional Design Services A. Contractor will not be required to provide professional design services unless such services are specifically required by the Contract Documents for a portion of the Work or unless such services are required to carry out Contractor's responsibilities for construction means, methods, techniques, sequences and procedures. B. If professional design services or certifications by a design professional related to systems, materials or equipment are specifically required of Contractor by the Contract Documents, City will specify all performance and design criteria that such services must satisfy. Contractor shall cause such services or certifications to be provided by a properly licensed professional, whose signature and seal shall appear on all drawings, calculations, specifications, certifications, and Submittals prepared by such professional. Submittals related to the Work designed or certified by such professional, if prepared by others, shall bear such professional's written approval when submitted to City. CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARD�D PROJECTS Revised: January ] 0, 2013 00 73 10- 25 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 25 of 35 C. City shall be entitled to rely upon the adequacy, accuracy and completeness of the services, certifications or approvals performed by such design professionals, provided City has specified to Contractor performance and design criteria that such services must satisfy. D. Pursuant to this Paragraph 5.19, City's review and acceptance of design calculations and design drawings wili be only for the limited purpose of checking for conformance with performance and design criteria given and the design concept expressed in the Contract Documents. City's review and acceptance of Submittals (except design calculations and design drawings) will be only for the purpose stated in Paragraph 5.16.C. 5.20 Right to Audit: A. The City reserves the right to audit all projects utilizing City funds B. The Contractor agrees that the City shall, until the expiration of three (3) years after final payment under this Contract, have access to and the right to examine and photocopy any directly pertinent books, documents, papers, and records of the Contractor involving transactions relating to this Contract. Contractor agrees that the City shall have access during Regular Working Hours to all necessary Contractor facilities and shall be provided adequate and appropriate work space in order to conduct audits in compliance with the provisions of this Paragraph. The City shall give Contractor reasonable advance notice of intended audits. C. Contractor further agrees to include in all its subcontracts hereunder a provision to the effect that the subcontractor agrees that the City shall, until the expiration of three (3) years after final payment under this Contract, have access to and the right to examine and photocopy any directly pertinent books, documents, papers, and records of such Subcontractor, involving transactions to the subcontract, and further, that City shall have access during Regular Working Hours to all Subcontractor facilities, and shall be provided adequate and appropriate work space in order to conduct audits in compliance with the provisions of this Paragraph. The City shall give Subcontractor reasonable advance notice of intended audits. D. Contractor and Subcontractor agree to photocopy such documents as may be requested by the City. The City agrees to reimburse Contractor for the cost of the copies as follows at the rate published in the Texas Administrative Code in effect as of the time copying is performed. 5.21 Nondiscrimination A. The City is responsible for operating Public Transportation Programs and implementing transit- related projects, which are funded in part with Federal financial assistance awarded by the U.S. Department of Transportation and the Federal Transit Administration (FTA), without discriminating against any person in the United States on the basis of race, color, or national origin. B. Title VI, Civil Rights Act of 1964 as amended: Contractor shall comply with the requirements of the Act and the Regulations as further defined in the Supplementary Conditions for any project receiving Federal assistance. CITY OP PORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDGD PROJECTS Revised: January ] 0, 2013 00 73 ] 0- 26 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 26 of 35 ARTICL]E 6— OTHER WORK AT THE SITE 6.01 Related Work at Site A. City may perform other work related to the Project at the Site with City's employees, or other City contractors, or through other direct contracts therefor, or have other work performed by utility owners. If such other work is not noted in the Contract Documents, then written notice thereof will be given to Contractor prior to starting any such other work; and S. Contractor shall afford each other contractor who is a party to such a direct contract, each utility owner, and City, if City is performing other work with City's employees or other City contractors, proper and safe access to the Site, provide a reasonable opportunity for the introduction and storage of materials and equipment and the execution of such other work, and properly coordinate the Work with theirs. Contractor shall do all cutting, fitting, and patching of the Work that may be required to properly connect or otherwise make its several parts come together and properly integrate with such other work. Contractor shall not endanger any work of others by cutting, excavating, or otherwise altering such work; provided, however, that Contractor may cut or alter others' work with the written consent of City and the others whose work will be affected. C. If the proper execution or results of any part of Contractor's Work depends upon work performed by others under this Article 7, Contractor shall inspect such other work and promptly repart to City in writing any delays, defects, or deficiencies in such other work that render it unavailable or unsuitable for the proper execution and results of Contractor's Work. Contractor's failure to so report will constitute an acceptance of such other work as fit and proper for integration with Contractor's Work except for latent defects in the worlc provided by others. ARTICLE 7 — CITY'S RESPONSIBILITIES 7.01 Inspections, TesCs, and Approvals City's responsibility with respect to certain inspections, tests, and approvals is set forth in Paragraph 11.03. 7.02 Limitations on City's Responsibilities A. The City shall not supervise, direct, or have control or authority over, nor be responsible for, Contractor's means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the performance of the Work. City will not be responsible for Contractor's failure to perform the Work in accordance with the Contract Documents. B. City wi11 notify the Contractor of applicable safety plans pursuant to Paragraph 5.13. CITY OF FORT WORTH STANDARD CITY CONDII'IONS — DEVELOPER AWARDED PRO.TECTS Revised: January 10, 2013 00 73 10- 27 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 27 of 35 7.03 Compliance with Safety Program While at the Site, City's employees and representatives shall comply with the specific applicable requirements of Contractor's safety programs of which City has been informed pursuant to Paragraph 5.13. ARTICLE 8— CITY'S OBSERVATION STATUS DURING CONSTRUCTION 8.01 City's Project Representative City will provide one or more Project Representative(s) during the construction period. The duties and responsibilities and the limitations of authority of City's representative during construction are set forth in the Contract Documents. A. City's Project Representative will make visits to the Site at intervals appropriate to the various stages of construction as City deems necessary in order to observe the progress that has been made and the quality of the various aspects of Contractor's executed Work. Based on infarmation obtained during such visits and observations, City's Project Representative will determine, in general, if the Work is proceeding in accordance with the Contract Documents. City's Project Representative will not be required to make exhaustive or continuous inspections on the Site to check the quality or quantity of the Work. City's Project Representative's efforts will be directed toward providing City a greater degree of confidence that the completed Work will conform generally to the Contract Documents. B. City's Project Representative's visits and observations are subject to all the limitations on authority and responsibility in the Contract Documents. 8.02 Authorized T�a�iations in Work City's Project Representative may authorize minor variations in the Work from the requirements of the Contract Documents which do not involve an adjustment in the Contract Price or the Contract Time and are compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. These may be accomplished by a Field Order and will be binding on City Developer, and also on Contractor, who shall perform the Work involved promptly. 8.03 Rejecting Defective Work City will have authority to reject Work which City's Project Representative believes to be defective, or will not produce a completed Project that conforms to the Contract Documents or that will prejudice the integrity of the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. City will have authority to conduct special inspection or testing of the Work as provided in Article 11, whether or not the Work is fabricated, installed, or completed. CITY OF FORT WORTH STANDARD CITY CONDITIONS — DCVELOPER AWARDED PROJECTS Revised: January ] 0, 2013 00 73 10- 28 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 28 of 35 8.04 Determinations for Work Pe�formed Contractor will determine the actual quantities and classifications of Work performed. City's Project Representative will review with Contractor the preliminary determinations on such matters before rendering a written recommendation. City's written decision will be final (except as modified to reflect changed factual conditions or more accurate data). ARTICLE 9— CHANGES IN THE WORK 9.01 Authorized Changes in the WoNk A. Without invalidating the Contract and without notice to any surety, City may, at any time or from time to time, order Extra Work. Upon notice of such Extra Work, Contractor shall promptly proceed with the Work involved which will be performed under the applicable conditions of the Contract Documents (except as otherwise specifically provided). Extra Work shall be memorialized by a Participating Change Order which may or may not precede an order of Extra work. B. For ininor changes of Work not requiring changes to Contract Time or Contract Price on a project with City participation, a Field Order may be issued by the City. 9.02 Notification to Surety If the provisions of any bond require notice to be given to a surety of any change affecting the general scope of the Work or the provisions of the Contract Documents (including, but not limited to, Contract Price or Contract Time), the giving of any such notice will be Contractor's responsibility. The amount of each applicable bond will be adjusted by the Contractor to reflect the effect of any such change. ARTICLE 10 — CHANGE OF CONTRACT PRICE; CHANGE OF CONTRACT TIME 10.01 Change of Contract Price A. The Contract Price may only be changed by a Participating Change Order for projects with City participatiion. 10.02 Change of Contract Time A. The Contract Time may only be changed by a Participating Change Order for projects with City participation. 10.03 Delays A. If Contractor is delayed, City shall not be liable to Contractor for any claims, costs, losses, or damages (including but not liinited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) sustained by Contractor on or in connection with any other project or anticipated project. CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: .�anuary ] 0, 2013 00 �3 � o- 29 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 29 of 35 �.RTICLE 11 — TESTS AND INSPECTIONS; CORRECTION, REMOVAL OR ACCEPTANCE OF DEFECTIVE WORK I 1.0 ] Notice of Defects Notice of all defective Work of which City has actual knowledge will be given to Contractor. Defective Work may be rejected, corrected, or accepted as provided in this Article 13. 11.02 Access to Work City, independent testing laboratories, and governmental agencies with jurisdictional interests will have access to the Site and the Work at reasonable times for their observation, inspection, and testing. Contractor shall provide them proper and safe conditions for such access and advise them of Contractor's safety procedures and programs so that they may comply therewith as applicable. 11.03 Tests and Inspections A. Contractor shall give City timely notice of readiness of the Work for all required inspections, tests, or approvals and shall cooperate with inspection and testing personnel to facilitate required inspections or tests. B. If Contract Documents, Laws or Regulations of any public body having jurisdiction require any of the Work (or part thereo� to be inspected, tested, or approved, Contractor shall assume full responsibility for arranging and obtaining such independent inspections, tests, retests or approvals, pay all costs in connection therewith, and furnish City the required certificates of inspection or approval; excepting, however, those fees specifically identified in the Supplementary Conditions or any Texas Department of Licensure and Regulation (TDLR) inspections, which shall be paid as described in the Supplementary Conditions. C. Contractor shall be responsible for arranging and obtaining and shall pay all costs in connection with any inspections, tests, re-tests, or approvals required for City's acceptance of materials or equipment to be incorporated in the Work; or acceptance of materials, mix designs, or equipment submitted for approval prior to Contractor's purchase thereof for incorporation in the Work. Such inspections, tests, re-tests, or approvals shall be performed by organizations approved by City. D. City may arrange for the services of an independent testing laboratory ("Testing Lab") to perform any inspections or tests ("Testing") for any part of the Work, as determined solely by City. 1. City will coordinate such Testing to the extent possible, with Contractor; 2. Should any Testing under this Section 11.03 D result in a"fail", "did not pass" or other similar negative result, the Contractor shall be responsible for paying for any and all retests. Contractor's cancellation without cause of City initiated Testing shall be deemed a negative result and require a retest. CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 00 73 10- 30 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 30 of 35 3. Any amounts owed for any retest under this Section 11.43 D shall be paid directly to the Testing Lab by Contractor. City will forward all invoices for retests to Developer/Contractor. 4. If Contractor fails to pay the Testing Lab, City will not issue a letter of Final Acceptance until the Testing Lab is Paid E. If any Work (or the work of others) that is to be inspected, tested, or approved is covered by Contractor without written concurrence of City, Contractor shall, if requested by City, uncover such Work for observation. 11.04 Uncovering Work A. If any Work is covered contrary to the Contract Documents or specific instructions by the City, it must, if requested by City, be uncovered for City's observation and replaced at Contractor's expense. 11.05 City May Stop the Work If the Work is defective, or Contractor fails to supply sufficient skilled workers or suitable materials or equipment, or fails to perform the Work in such a way that the completed Work will conform to the Contract Documents, City may order Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, this right of City to stop the Work shall not give rise to any duty on the part of City to exercise this right for the benefit of Contractor, any Subcontractor, any Supplier, any other individual or entity, or any surety for, or employee or agent of any of them. 11.06 Correction or Removal of Defective Work A. Promptly after receipt of written notice, Contractor shall correct all defective Work pursuant to an acceptable schedule, whether or not fabricated, installed, or completed, or, if the Work has been rejected by City, remove it from the Project and replace it with Work that is not defective. Contractor shall pay all claims, costs, additional testing, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such correction or removal (including but not limited to all costs of repair or replacement of work of others). Failure to require the removal of any defective Work shall not constitute acceptance of such Work. B. When correcting defective Work under the terms of this Paragraph 11.06 or Paragraph 11.07, Contractor shall take no action that would void or otherwise impair City's special warranty and guarantee, if any, on said Work. 11.07 Correction Period A. If within two (2) years after the date of Final Acceptance (or such longer period of time as may be prescribed by the terms of any applicable special guarantee required by the Contract CITY OF FORT WORTH STANDARD C1TY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January ]0, 2013 00 73 10- 31 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 31 of 35 Documents), any Work is found to be defective, or if the repair of any damages to the land or areas made available for Contractor's use by City or permitted by Laws and Regulations as contemplated in Paragraph S.lO.A is found to be defective, Contractor shall promptly, without cost to City and in accordance with City's written instructions: 1. repair such defective land or areas; or 2. correct such defective Work; or 3. if the defective Work has been rejected by City, remove it from the Project and replace it with Work that is not defective, and 4. satisfactorily correct or repair or remove and replace any damage to other Work, to the work of others or other land or areas resulting therefrom. B. If Contractor does not promptly comply with the terms of City's written instructions, or in an emergency where delay would cause serious risk of loss or damage, City may have the defective Work corrected or repaired or may have the rejected Work removed and replaced. All claims, costs, losses, and darnages (including but not lirnited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or other dispute resolution costs) arising out of or relating to such correction or repair or such removal and replacement (including but not limited to all costs of repair or replacement of work of others) will be paid by Contractor. C. Where defective Work (and damage to other Work resulting therefrom) has been corrected or removed and replaced under this Paragraph 11.07, the correction period hereunder with respect to such Work may be required to be extended for an additional period of one year after the end of the initial correction period. City shall provide 30 days written notice to Contractor and Developer should such additional warranty coverage be required. Contractor's obligations under this Paragraph 11.07 are in addition to any other obligation or warranty. The provisions of this Paragraph 11.07 shall not be construed as a substitute for, or a waiver of, the provisions of any applicable statute of limitation or repose. 11.08 City May CorJ�ect Defective Work A. If Contractor fails within a reasonable time after written notice from City to correct defective Work, or to remove and replace rejected Work as required by City in accordance with Paragraph 11.06.A, or if Contractor fails to perform the Work in accordance with the Contract Documents, or if Contractor fails to comply with any other provision of the Contract Documents, City may, after seven (7) days written notice to Contractor and the Developer, correct, or remedy any such deficiency. B. In exercising the rights and remedies under this Paragraph 11.09, City shall proceed expeditiously. In connection with such corrective or retnedial action, City may exclude Contractor from all or part of the Site, take possession of all or part of the Work and suspend Contractor's services related thereto, and incorporate in the Work all materials and equipment incorporated in the Work, stored at the Site or for which City has paid Contractor but which are CITY OF FORT WORTH STANDARD CITY CONDIT[ONS — D�VELOPER AWARDCD PR07ECTS Revised: January 10, 2013 00 73 10- 32 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 32 of 35 stored elsewhere. Contractor shall allow City, City's representatives, agents, consultants, employees, and City's other contractors, access to the Site to enable City to exercise the rights and remedies under this Paragraph. C. All claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or other dispute resolution costs) incurred or sustained by City in exercising the rights and remedies under this Paragraph 13.09 will be charged against Contractor, and a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Work; and City shall be entitled to an appropriate decrease in the Contract Price. D. Contractor shall not be allowed an extension of the Contract Time because of any delay in the performance of the Work attributable to the exercise of City's rights and remedies under this Paragraph 11.09. ARTICLE 12 — COMPLETION 12.01 Contr�actor's Wa�^v�anty of Title Contractor warrants and guarantees that title to all Work, materials, and equipment covered by any Application for Payment will pass to City no later than the time of Final Acceptance and shall be free and clear of all Liens. 12.02 Partial Utilization A. Prior to Final Acceptance of all the Work, City may use or occupy any substantially completed part of the Work which has specifically been identified in the Contract Documents, or which City, determines constitutes a separately functioning and usable part of the Work that can be used by City for its intended purpose without significant interference with Contractor's performance of the remainder of the Work. City at any time may notify Contractor in writing to permit City to use or occupy any such part of the Work which City determines to be ready for its intended use, subject to the following conditions: 1. Contractor at any time may notify City in writing that Contractor considers any such part of the Work ready for its intended use. 2. Within a reasonable time after notification as enumerated in Paragraph 14.OS.A.1, City and Contractor shall make an inspection of that part of the Work to determine its status of completion. If Ciiy does not consider that part of the Work to be substantially complete, City will notify Contractor in writing giving the reasons therefor. 3. Partial Utilization will not constitute Final Acceptance by City. 12.03 Finallnspection A. Upon written notice from Contractor that the entire Work is complete i�i accordance with the Contract Documents: CITY OF PORT WORTH STANDARD CITY CONDITIONS — DEVLLOPCR AWARDLD PROJECTS Revised: January 10, 2013 00 73 10- 33 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 33 of 35 1. within 10 days, City will schedule a Final Inspection with Contractor. 2. City will notify Contractor in writing of all particulars in which this inspection reveals that the Work is incomplete or defective. Contractor shall immediately take such measures as are necessary to complete such Work or remedy such deficiencies. 12.04 Final Acceptance A. Upon completion by Contractor to City's satisfaction, of any additional Work identified in the Final Inspection, City will issue to Contractor a letter of Final Acceptance upon the satisfaction of the following: 1. All documentation called for in the Contract Documents, including but not limited to the evidence of insurance required by Paragraph 5.03; 2. consent of the surety, if any, to Final Acceptance; a list of all pending or released Damage Claims against City that Contractor believes are unsettled; and 4. affidavits of payments and complete and legally effective releases or waivers (satisfactory to City) of all Lien rights arising out of or Liens filed in connection with the Work. 5. after all Damage Claims have been resolved: a. directly by the Contractor or; b. Contractor provides evidence that the Damage Claim has been reported to Contractor's insurance provider for resolution. 6. Issuing Final Acceptance by the City shall not relieve the Contractor of any guarantees or other requirements of the Contract Documents which specifically continue thereafter. ARTICL� 13 — SUSPENSION OF WORK 13.01 City May Suspend Wot�k A. At any time and without cause, City may suspend the Work or any portion thereof by written notice to Contractor and which may fix the date on which Work will be resumed. Contractor shall resume the Work on the date so fixed. During temporary suspension of the Work covered by these Contract Documents, for any reason, the City will stop contract time on City participation projects. B. Should the Contractor not be able to complete a portion of the Project due to causes beyond tl�e control of and without the fault or negligence of the Contractor, and should it be determined by mutual consent of the Contractor and City that a solution to allow construction to proceed is not CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJ�CTS Revised: January 10, 2013 00 73 10- 34 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 34 of 35 available within a reasonable period of time, Contractor may request an extension in Contract Time, directly attributable to any such suspension. C. If it should become necessary to suspend the Work for an indefinite period, the Contractor shall store all materials in such a manner that they will not obstruct or impede the public unnecessarily nor becoine damaged in any way, and he shall take every precaution to prevent damage or deterioration of the work performed; he shall provide suitable drainage about the work, and erect temporary structures where necessary. ARTICLE 14 — MISCELLANEOUS 14.01 Giving Notice A. Whenever any provision of the Contract Documents requires the giving of written notice, it will be deemed to have been validly given if: delivered in person to the individuai or to a member of the firm or to an officer of the corporation for whom it is intended; or delivered at or sent by registered or certified mail, postage prepaid, to the last business address known to the giver of the notice. B. Business address changes must be promptly made in writing to the other party. C. Whenever the Contract Documents specifies giving notice by electronic means such electronic notice shall be deemed sufficient upon confirmation of receipt by the receiving party. 14.02 Computation of Times When any period of time is referred to in the Contract Documents by days, it will be computed to exclude the first and include the last day of such period. If the last day of any such period falls on a Saturday or Sunday or on a day made a legal holiday the next Working Day shall become the last day of the period. 14.03 Cumulative Remedies The duties and obligations imposed by these General Conditions and the rights and remedies available hereunder to the parties hereto are in addition to, and are not to be construed in any way as a limitation of, any rights and rernedies available to any or all of them which are otherwise imposed or available by Laws or Regulations, by special warranty or guarantee, or by other provisions of the Contract Documents. The provisions of this Paragraph will be as effective as if repeated speci�cally in the Contract Documents in connection with each particular duty, obligation, right, and remedy to which they apply. CITY OF FORT WORTI-I STANDARD CITY CONDITIONS — DEVELOPER AWA.RD�D PROJECTS Revised: January ] 0, 20] 3 00 73 I 0- 35 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 35 of 35 14.04 SuYvival of Obligations All representations, indemnifications, warranties, and guarantees made in, required by, or given in accordance with the Contract Documents, as well as all continuing obligations indicated in the Contract Documents, will survive final payinent, completion, and acceptance of the Work or termination or completion of the Contract or termination of the services of Contractor. 14.05 Headings Article and paragraph headings are inserted for convenience only and do not constitute parts of these General Conditions. CITY OF FORT WORTH STANDARD CITY CONDITIONS —DEVELOPER AWARD�D PROJECTS Revised: January l0, 2013 011100-1 SUMMARY OP WORK Page 1 of 3 1 2 3 PART1- GENERAL 4 1.1 SUMMARY 5 6 7 8 9 10 11 12 SECTION O1 11 00 SUMMARY OF WORK A. Section Includes: 1. Summary of Work to be perfonned in accordance with the Contract Documents B. Deviations from this City of Fort Worth Standard Specification l. Modified 1.2.A.1 2. Added 1.2.A.2 3. Modified 1.4.B.1 4. Added 1.4.B.2 5. Added 1.4.0 & 1.4.F U C. Related Specification Sections include, but are not necessarily limited to: 14 1. Division 0- Bidding Requirements, Contract Forms, and Conditions of the Contract 15 2. Division 1- General Requirements 16 1.2 PRICE AND PAYMENT PROCEDURES 17 A. Measurement and Payment 18 1. Unit Priee - Work associated with this Item is considered subsidiary to the various 19 items bid. No separate payment wiIl be allowed for this Item. 20 2. Lump Sum Price - Work associated with this Item is included in the total lump 21 sum price. 22 1.3 REFERENCES [NOT USED] 23 1.4 ADMINISTRATIVE REQUIREMENTS 24 25 26 27 28 29 30 31 32 33 34 35 36 37 A. Work Covered by Contract Documents 1. Work is to include furnishing all labor, rnaterials, and equipment, and performing all Work necessary for this construction project as detailed in the Drawings and Specifications. B. Subsidiary Work 1. Unit Price Bid - Any and all Wark specifically governed by documentary requirements for the project, such as conditions imposed by the Drawings or Contract Documents in which no specific item for bid has been provided for in the Proposal and the item is not a typical unit bid itein included on the standard bid item list, then the item shall be considered as a subsidiary item of Work, the cost of which shall be included in the price bid in the Proposal for various bid items. 2. Lump Sum Price — Any and all Work suecificallv governed bv documentary repuirements for the project, such as conditions imposed by the Drawin�s or Contract Documents are included in the total lump sum nrice bid. CITY OF PORT WORTH STANDARD CONSTRUCTION LA FRONTERA — PHASE 3 SPECIFICATION DOCUMENTS — WATER FACILITY PRO]ECTS CITY PROJECT NO.: 102811 Revised December 2Q 2012 oi ii o0-2 SUMMARY OF WORK Page 2 of 3 1 C. Examination of the Site 2 1. Visit the site, to comAare drawin sg and specifications with anv work in nlace, 3 and observe all site conditions, includin� other work, if anv, is being 4 performed. Failure to visit the site shall not relieve the Contractor from the 5 necessity of furnishin� materials or performin� work required to complete 6 work in accordance with the Contract Documents. 7 D. Use of Premises 8 1. Coordinate uses of premises under direction of the City. 9 2. Assume full responsibility for protectioil and safekeeping of materials and 10 equipment stored on the Site. 11 3. Use and occupy only portions of the public streets and alleys, or other public places 12 or other rights-of-way as provided for in the ordinai�ces of the City, as shown in the 13 Contract Documents, or as may be specifically authorized in writing by the City. 14 a. A reasonable amount of tools, materials, and equipment for construction 15 purposes may be stored in such space, but no more than is necessary to avoid 16 delay in the construction operations. 17 b. Excavated and waste materials shall be stored in such a way as not to interfere 18 with the use of spaces that may be designated to be left free and unobstructed 19 and so as not to inconvenience occupants of adjacent property. 20 c. If the street is occupied by railroad tracks, the Work shall be carried on in such 21 manner as not to interfere with the operation of the railroad. 22 1) All Work shall be in accordance with railroad requirements set forth in 23 Division 0 as well as the railroad permit. 24 E. Work within Easemezlts 25 1. Do not enter upon private properiy for any purpose without having previously 26 obtained pennission from the owner of such property. 27 2. Do not store equipment or material on private property unless and until the 28 specified approval of the property owner has been secured in writing by the 29 Contractor and a copy furnished to the City. 30 3. Unless specifically provided otherwise, clear all rights-of-way or easements of 31 obstructions which must be removed to make possible proper prosecution of the 32 Work as a part of the project construction operations. 33 4. Preserve and use every precaution to prevent damage to, all trees, shrubbery, plants, 34 lawns, fences, culverts, curbing, and all other types of structures or improvements, 35 to all water, sewer, and gas lines, to all conduits, overhead pole lines, or 36 appurtenances thereof, including the construction of temporary fences and to all 37 other public or private property adjacent to the Work. 38 5. Notify the proper representatives of the owners or occupants of the public or private 39 lands of interest in lands whicl� �night be affected by the Work. 40 a. Such notice shall be made at least 48 hours in advance of the begimiing of the 41 Work. 42 b. Notices shall be applicable to both public and private utility companies and any 43 corporation, company, individual, or other, either as owners or occupants, 44 whose land or interest in land might be affected by the Work. CITY OF FORT WORTH STANDARD CONSTRUCTION LA FRONTERA— PHASE 3 SPECIFICATION DOCUMENTS — WATER FACILITY PROJECTS CITY PROJECT NO.: 10281 ] Revised December 20, 2012 O1 11 00-3 SUMMARY OF WORK Page 3 of 3 1 c. Be responsible for all damage or injury to property of any character resulting 2 from any act, omission, neglect, or misconduct in the manner or method or 3 execution of the Work, or at any time due to defective work, material, or 4 equipment. 5 6. Fence 6 a. Restore all fences encountered and removed during construction of the Project 7 to the original or a better than original condition. 8 b. Erect temporary fencing in place of the fencing removed whenever the Work is 9 not in progress and when the site is vacated overnight, and/or at all tiines to 10 provide site security. 11 c. The cost for all fence work within easements, including removal, temporary 12 closures and replacement, shall be subsidiary to the various items bid in the 13 project proposal, unless a bid item is specifically provided in the proposal. 14 F. Partial Owner Occupancv 15 1. The City reserves the ri�ht to take,possession and use anv completed or 16 partiallv comnleted portion of the Work regardless of the time of comuletion l7 of the Work, qrovidin� it does not interfere with the Contractor's work Such 18 possession or use of the Work shall not be construed as final acceptance of the 19 proiect or anv portion thereof. 20 1.5 SUBMITTALS [NOT USED] 21 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 22 1.7 CLOSEOUT SUBMITTALS [NOT USED] 23 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 24 1.9 QUALITY ASSURANCE [NOT USED] 25 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] 26 1.11 FIELD [SITE] CONDITIONS [NOT USED] 27 1.12 WARRANTY [NOT USED] 28 PART 2- PRODUCTS [NOT USED] 29 PART 3- EXECUTION [NOT USED] 30 END OF SECTION Revision Log DATE NAME SUMMARY OF CHANGE 31 CITY OF FORT WORTH STANDARD CONSTRUCTiON LA FRONT�RA — PHASE 3 SPECIFICATION DOCUMENTS — WATER FACILITY PROJECTS CITY PROJECT NO.: 102811 Revised December 20, 2012 ol2soo-� SUBSTITUTION PROCEDURES Page 1 of 4 1 2 3 PART1- GENERAL 4 1.1 SUMMARY SECTION 01 25 00 SUBSTITUTION PROCEDURES 5 A. Section Includes: 6 1. The procedure for requesting tl�e approval of substitution of a product that is not 7 equivalent to a product which is specified by descriptive or perfarmance criteria or 8 defined by reference to 1 or more of the following: 9 a. Name of manufacturer 10 � b. Name of vendor 11 c. Trade name 12 d. Catalog number 13 2. Substitutions are not "or-equals". 14 B. Deviations from this City of Fort Worth Standard Specification 15 1. None. 16 17 18 19 1.2 C. Related Specification Sections i�iclude, but are not necessarily limited to: 1. Division 0— Bidding Requirements, Contract Forrns and Conditions of the Contract 2. Division 1— General Requirements PRICE AND PAYMENT PROCEDURES 20 A. Measurement and Pay�nent 21 1. Work associated with this Item is considered subsidiary to the various iteins bid. 22 No separate payment will be allowed for this Item. 23 1.3 REFERENCES [NOT USED] 24 1.4 ADMINISTRATIVE REQUIREMENTS 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 40 A. Request for Substitution - General 1. Within 30 days after award of Contract (unless noted otherwise), the City will consider formal requests from Contractor for substitution of products in place of those specified. 2. Certain types of equipment and kinds of material are described in Specifications by means of references to names of manufacturers and vendors, trade names, or catalog numbers. a. When this method of specifying is used, it is nat intended to exclude from consideration other products bearing other manufacturer's or vendor's names, trade names, or catalog numbers, provided said products are "or-equals," as determined by City. 3. Other types of equipment and kinds of material may be acceptable substitutions under the following conditions: a. Or-equals are unavailable due to strike, discontinued production of products meeting specified requirements, or other factors beyond control of Contractor; or, CITY OF FORT WORTH LA FRONTERA — PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO.: 102811 Revised Ju(y 1, 2011 ot zs oo - a SUBSTI'['UTION PROCEDURES Page 2 of 4 b. Contractor proposes a cost and/or time reduction incentive to the City. 2 1.5 SUSMITTALS 3 A. See Request for Substitution Form (attached) 4 B. Procedure for Requesting Substitution 5 1. Substitution shall be considered only: 6 a. After award of Contract 7 b. Under the conditions stated herein 8 9 10 11 12 13 14 15 16 17 l8 19 20 21 22 23 24 25 26 27 28 29 30 3l 32 33 34 35 36 37 38 39 40 41 2. Submit 3 copies of each written request for substitution, including: a. Documentation 1) Complete data substantiating compliance of proposed substitution with Contract Documents 2) Data relating to changes in construction schedule, when a reduction is proposed 3) Data relating to changes in cost b. For products 1) Product identification a) Manufacturer's name b) Telephone number and representative contact name c) Specification Section or Drawing reference of originally specified product, including discrete tiame or tag number assigned to original product in the Contract Documents 2) Manufacturer's literature clearly marked to show compliance of proposed product with Contract Documents 3) Itemized comparison of original and proposed product addressing product characteristics including, but not necessarily li�nited to: a) Size b) Composition or materials of construction c) Weight d) Electrical or mecl�anical requirements 4) Product experience a} Location of past projects utilizing product b) Name and telephone number of persons associated with referenced projects knowledgeable concerning proposed product c) Available field data and reports associated with proposed product 5) Samples a) Provide at request of City. b) Samples become t11e properiy of the City. c. For construction methods: 1) Detailed description ofproposed method 2) Illustration drawings C. Approval or Rejection 42 l. Written approval or rejection of substitution given by the City 43 2. City reserves the right to require proposed product to comply with color and pattern 44 of specified product if necessary to secure design intent. 45 3. In the event the substitution is approved, the resulting cost and/or time reduction 46 will be documented by Change Order in accordance with the General Conditions. CITY OF FORT WORTH LA FRONTCRA — PHASE 3 STANDARD CONSTRUCTION SPCCIFICATION DOCUMENTS CITY PROJECT NO.: 102811 Revised .luly I, 20t 1 012500-3 SUBSTITUTION PROC�DURES Page 3 of 4 1 2 3 4 5 6 7 8 9 1.6 4. No additional contract time will be given for substitution. 5. Substitution will be rejected if: a. Submittal is not through the Contractor with his stamp of approval b. Request is not made in accordance with this Specification Section c. In the City's opinion, acceptance will require substantial revision of the original design d. In the City's opinion, substitution will not perform adequately the function consistent with the design intent ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 10 1.7 CLOSEOUT SUBMITTALS [NOT USED] 11 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 12 1.9 QUALITY ASSURANCE 13 14 15 16 17 18 19 20 21 22 23 24 25 26 A. In making request for substitution or in using an approved product, the Contractor represents that the Contractor: 1. Has investigated proposed product, and has determined that it is adequate or superior in all respects to that specified, and that it will perform fimction for which it is intended 2. Will provide same guarantee for substitute item as for product specified 3. Will coordinate installation of accepted substitution into Work, to include building modifications if necessary, making such changes as may be required for Work to be complete in all respects 4. Waives all claims for additional costs related to substitution which subsequently arise 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] 1.11 FIELD [SITE] CONDITIONS [NOT USED] 1.12 WARRANTY [NOT USED] 27 PART 2- PRODUCTS [NOT USED] 28 PART 3- EXECUTION [NOT USED] 29 30 END OF SECTION Revision Log DATE NAME SUMMARY OF CHANGE 31 CITY OF FOR7' WORTH LA FRONTERA — PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS C]TY PROJECT NO.: 102811 Revised July l, 2011 012500-4 SUBSTITUTION PROCEDURES Page 4 of 4 1 2 3 4 5 6 7 8 9 10 [� 12 13 14 15 16 17 18 19 20 2l 22 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 40 41 42 43 44 45 46 47 48 49 EXHIBIT A REQUEST FOR SUSSTITUTION FORM: TO: PROJECT: DATE: We hereby submit for your consideration the following product instead of the specified item for the above project: SECTION PARAGRAPH SPECIFIED ITEM Proposed Substitution: Reason for Substitution: Include complete information on changes to Drawings and/or Specifications which proposed substitution will require for its proper installation. Fill in Blanks Below: A. Will the undersigned contractor pay for changes to the building design, including engineering and detailing costs caused by the requested substitution? B. What effect does substitution have on other trades? C. Differences between proposed substitution and specified item? D. Differences in product cost or product delivery time? E. Manufacturer's guarantees of the proposed and specified items are: Equal Better (explain on attachrnent) The undersigned states that the function, appearance and quality are equivalent or superior to the specified item. Submitted By: For Use by City Signature as noted Finn Address Date Telephone For Use by City: Approved City _ Recommended _ Recommended Not recommended Received late By Date Remarks Date C1TY OF FORT WORTH STANDARD CONSTRUCTION SPECIFICA'I'ION DOCUMENTS Revised July 1, 2011 Rejected LA FRONTERA — PHASE 3 CITY PROJECT NO.: 102811 Oi3119-1 PRECONSTRUCTION MCETING Page 1 of 3 1 2 3 PART 1 - GENER.AL 4 1.1 SUMMARY SECTION 01 31 19 PRECONSTRUCTION MEETING 5 A. Section Includes: 6 1. Provisions for the preconstruction meeting to be held prior to the start of Work to 7 clarify construction contract administration procedures 8 B. Deviations from this City of Fort Worth Standard Specification 9 1. None. 10 C. Related Specification Sections include, but are not necessarily limited to: I 1 1. Division 0— Bidding Requirements, Contract Forms and Conditions of the Contract 12 2. Division 1— General Requirements 13 1.2 PRICE AND PAYMENT PROCEDURES 14 A. Measurement and Payment 15 1. Work associated with this Item is considered subsidiary to the various items bid. 16 No separate payment will be allowed for this Item. 17 1.3 REFERENCES [NOT USED] 18 1.4 ADMINISTRATIVE REQUIREMENTS 19 A. Coordination 20 1. Attend preconstructio�l ineeting. 21 2. Representatives of Contractor, subcontractors and suppliers attending meetings 22 shall be qualified and authorized to act on behalf of the entity each represents. 23 3. Meeting administered by City may be tape recorded. 24 a. If recorded, tapes will be used to prepare minutes and retained by City for 25 future reference. 26 27 28 29 �0 3l 32 33 34 35 36 37 38 B. Preconstruction Meeting 1. A preconstruction meeting will be held within l4 days after the execution of the Agreement and before Work is started. a. The meeting will be scheduled and administered by the City. 2. The Project Representative will preside at the meeting, prepare the notes of the meeting and distribute copies of same to all participants who so request by fully completing the attendance form to be circulated at the beginning of the meeting. 3. Attendance shall include: a. Project Representative b. Contractor's project manager c. Contractor's superintendent d. Any subcontractor or supplier representatives whom the Contractor may desire to invite or the City may request CITY OP FORT WOATH LA FRONTERA — PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUM�NTS CITY PROJECT NO.: 102811 Revised August 17, 2012 O1 31 19 - 2 PRECONSTRUCTION MEETING Page 2 of 3 1 2 3 4 5 6 7 8 9 10 11 12 13 l4 15 16 17 18 19 20 2l 22 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 40 41 42 43 44 45 � S. e. Other City representatives f. Others as appropriate Construction Schedule a. Prepare baseline construction schedule in accordance witl� Section O1 32 16 and provide at Preconstruction Meeting. b. City will notify Contractor of any schedule changes upon Notice of Preconsiruction Meeting. Preliminary Agenda may include: a. Introduction of Project Personnel b. General Description of Project c. Status of right-of-way, utility clearances, ease�nents or other pertinent pennits d. Contractor's work plan and schedule e. Contract Time f. Notice to Proceed g. Construction Staking h. Progress Payments i. Extra Work and Change Order Procedures j. Field Orders k. Disposal Site Letter for Waste Material l. Insurance Renewals m. Payroll Certification n. Material Certifications and Quality Control Testing o. Public Safety and Convenience p. Documentation of Pre-Construction Conditions q. Weekend Work Notification r. Legal Holidays s. Trench Safety Plans t. Confined Space Entry Standards u. Coordination with the City's representative for operations of existing water systems v. Stonn Water Pollution Prevention Plan w. Coordination with other Contractors x. Early Warning System y. Contractor Evaluation z. Special Conditions applicable to the project aa. Damages Claims bb. Submittal Procedures cc. Substitution Procedures dd. Correspondence Routing ee. Record Drawings ff. Temporary construction facilities gg. M/WBE ar MBE/SBE procedures hh. Final Acceptance ii. Final Payment jj. Questions or Comments CITY OF FORT WORTH STANDARD CONSTRUCTION SPECIFICATION DOCUM�NTS Revised August 17, 2012 LA FRONTERA— PHASE 3 CITY PROJGCT NO.: 102811 O1 31 19 -3 PRECONSTRUCTION MEETING Page 3 of 3 1 1.5 SUBMITTALS [NOT USED] 2 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS (NOT USED] 3 1.7 CLOSEOUT SUBMITTALS [NOT USED] 4 1.8 MAINTENANCE MATERIAL SUBMITTALS (NOT USED] 5 1.9 QUALITY ASSURANCE [NOT USED] 6 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] 7 l.l l FIELD [SITE] CONDITIONS [NOT USED] 8 1.12 WARRANTY [NOT USED] 9 PART 2- PRODUCTS [NOT USED] 10 PART 3- EXECUTION [NOT USED] 11 12 END OF SECTION Revision Log DATE NAME SUMMARY OF CHANGE 13 CITY OF PORT WORTH LA FRONTERA— PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO.: 102811 Revised August 17, 2�12 013216-1 CONSTRUCTION PROGRESS SCHEDULE Page 1 of 5 � 3 PART1- GENERAL SECTION 0132 16 CONSTRUCTION PROGRESS SCHEDULE 4 1.1 SUMMARY 5 A. Section Includes: 6 1. General requirements for the preparation, submittal, updating, status reporting and 7 management of the Construction Progress Schedule 8 2. Specific requirements are presented in the City of Fort Worth Schedule Guidance 9 Document l 0 B. Deviations from this City of Fort Worth Standard Specification 11 1. Modified 1.2A.1 12 2. Added 1.2A.2 ]3 14 IS 16 1.2 17 18 l9 20 21 22 1.3 C. Related Specification Sections include, but are not necessarily limited to: 1. Division 0— Bidding Requireinents, Contract Forms and Conditions of the Contract 2. Division 1— General Requirements PRICE AND PAYMENT PROCEDURES A. Measurement and Payment 1. Unit Price - Work associated with this Item is considered subsidiary to the various items bid. No separate payment will be allowed for this Item. 2. Lump Sum Price - Work associated with this Item is included in the total lump sum price. REFERENCES 23 A. Definitions 24 1. Schedule Tiers 25 a. Tier 1- No schedule submittal required by contract. Small, brief duration 26 projects 27 b. Tier 2- No schedule submittal required by contract, but will require some 28 milestone dates. Small, brief duration projects 29 c. Tier 3- Schedule submittal required by contract as described in the 30 Specification and herein. Majority of City projects, including all bond program 31 projects 32 d. Tier 4- Schedule submittal required by contract as described in the 33 Specification and herein. Large and/or complex projects with long durations 34 1) Exainples: large water pump station project and associated pipeline with 35 interconnection to another governmental entity 36 e. Tier 5- Schedule submittal required by contract as described in the 37 Specification and herein. Large and/or very complex projects with long 38 durations, high public visibility 39 1) Examples might include a water or wastewater treatment plant CITY OF FORT WORTH STANDARD CONSTRUCTION LA FRONTERA — PHASE 3 SPECIFICATION DOCUMENTS — WATER FACILI'CY PROJECTS CITY PROJECT NO.: 102811 Revised July 1, 2011 013216-2 CONSTRUCTION PROGRESS SCHEDULE Page 2 of 5 1 2 3 4 5 6 7 2. Baseline Schedule - Initial schedule submitted before work begins that will serve as the baseline for measuring progress and departures from the schedule. 3. Progress Schedule - Monthly submittal of a progress schedule documenting progress on the project and any changes anticipated. 4. Schedule Narrative - Concise narrative of the scl�edule including schedule changes, expected delays, key schedule issues, critical path items, etc B. Reference Standards 8 1. City of Fort Worth Schedule Guidance Document 9 1.4 ADMINISTRATIVE REQUIREMENTS 10 11 12 13 14 15 16 17 18 19 A. Baseline Schedule 1. General a. Prepare a cost-loaded baseline Schedule using approved software and the Critical Path Method (CPM) as required in the City of Fort Worth Schedule Guidance Document. b. Review the draft cost-loaded baseline Schedule with the City to demonstrate understanding of the work to be performed and known issues and constraints related to the schedule. c. Designate an authorized representative (Project Scheduler) responsible for developing and updating the schedule and preparing reports. 20 B. Progress Schedule 21 1. Update the progress Sclledule monthly as required in the City of Fort Worth 22 Scl�edule Guidance Document. 23 2. Prepare the Schedule Narrative to accompany the monthly progress Schedule. 24 3. Change Orders 25 a. Incorporate approved change orders, resulting in a change of contract time, in 26 the baseline Schedule in accordance with City of Fort Worth Schedule 27 Guidance Document. 28 C. Responsibility for Schedule Compliance 29 1. Whenever it becomes apparent from the current progress Schedule and CPM Status 30 Report that delays to the critical path have resulted and the Contract completion 31 date will not be met, or when so directed by the City, make some or all of the 32 following actions at no additional cost to the City 33 a. Submit a Recovery Plan to the City for approval revised baseline Schedule 34 outlining: 35 1) A written statement of the steps intended to take to remove or arrest the 36 delay to the critical path in the approved schedule 37 2) Increase construction manpower in such quantities and crafts as will 38 substantially eliminate the backlog of work and return curreiit Schedule to 39 meet projected baseline completion dates 40 3) Increase the number of working hours per shift, shifts per day, working 41 days per week, the amount of construction equipment, or any combination 42 of the foregoing, sufficiently to substantially eliminate the backlog of work 43 4) Reschedule activities to achieve maximum practical concurrency of 44 accomplishment of activities, and comply with the revised schedule CITY OF FORT WORTH STANDARD CONSTRUCTION LA FRONTERA — PHASE 3 SPECIFICATION DOCUMENTS — WATER FACILITY PROJECTS CITY PROJECT NO.: 102811 Revised July 1, 20] 1 013216-3 CONSTRUCTION PROGRESS SCHEDULE Page 3 of 5 1 2. If no written statei�lent of the steps intended to take is submitted wl�en so req�iested 2 by the City, the City may direct the Contractor to increase the level of effort in 3 manpower (trades), equipment and work schedule (overtime, weekend and holiday 4 work, etc.) to be einployed by the Contractor in order to remove or arrest the delay 5 to the critical path in the approved schedule. 6 a. No additional cost for such work will be considered. 7 D. The Contract completion time will be adjusted only for causes specified in this 8 Contract. 9 a. Requests for an extension of any Contract completion date must be 10 supplemented with the following: 11 1) Furnish justification and supporting evidence as the City may deem 12 necessary to detenni�le whether the requested extension of time is entitled 13 under the provisions of this Contract. 14 a) The City will, after receipt of such justification and supporting 15 evidence, inake findings of fact and will advise the Contractor, in 16 writing thereof. 17 2) If the City finds that the requested extension of time is entitled, the City's 18 determination as to the total number of days allowed for the extensions 19 shall be based upon the approved total baseline schedule and on all data 20 relevant to the extension. 21 a) Such data s11a11 be included in the next updating of the Progi•ess 22 schedule. 23 b) Actual delays in activities which, according to the Baseline schedule, 24 do not affect any Contract completion date shown by the critical pat11 in 25 the network will not be the basis for a change therein. 26 2. Submit each request for change in Contract completion date to the City within 30 27 days after the beginning of the delay for which a time extension is requested but 28 before the date of final payment under this Contract. 29 a. No time extension will be granted for requests which are not submitted within 30 the foregoing time limit. 31 32 33 34 35 36 37 38 39 40 4l 42 43 44 45 46 47 48 b. From time to time, it may be necessary for the Contract schedule or completion time to be adjusted by the City to reflect the effects of job conditions, weather, technical difficulties, strikes, unavoidable delays on the part of the City or its representatives, and other unforeseeable conditions which may indicate schedule adjustments or completion time extensions. 1) Under such canditions, the City will direct the Contractor to reschedule the work or Contract completion time to reflect the changed conditions and the Contractor shall revise his schedule accordingly. a) No additional compensation will be made to the Contractor for such schedule changes except for unavoidable overall contract time extensions beyond the actual completion of unaffected work, in which case the Contractor shall take all possible action to minimize any time extension and any additional cost to the City. b) Available float time in the Baseline schedule may be used by the City as well as by the Contractor. 3. Float or slack time is defined as the annount of time between the earliest start date and the latest start date or between the earliest finish date and the latest finish date of a chain of activities on the Baseline Schedule. C1TY OF FORT WORTH STANDARD CONSTRUCTION LA FRONTERA — PHAS� 3 SPECIFICATION DOCUMENTS — WATGR FACILITY PROJECTS CITY PROJECT NO.: 102811 Revised .1uly t, 2011 013216-4 CONSTRUCTION PROGRESS SCHEDULE Page 4 of 5 1 2 3 4 5 6 7 8 9 10 ll 12 13 14 15 16 t7 18 19 20 21 a. Float or slack time is not for the exclusive use or benefit of either the Contractor or the City. b. Proceed with work according to early start dates, and the City shall have the right to reserve and apportion float time according to the needs of the project. c. Acknowledge and agree that actual delays, affecting paths of activities containing float time, will not have any effect upon contract completion times, providing that the actual delay does not exceed the float time associated with those activities. E. Coordinating Schedule with Other Contract Schedules 1. Where work is to be performed under this Contract concurrently with or contingent upon work performed on the same facilities or area under other contracts, the Baseline Schedule shall be coordinated with the schedules of the other contracts. a. Obtain the schedules of the other appropriate contracts from the City for the preparation and updating of Baseline schedule and make the required changes in his schedule when indicated by changes in corresponding schedules. 2. In case of interference between the operations of different contractors, the City will determine the work priority of each contractor and the sequence of work necessary to expedite the completion of the entire Project. a. In such cases, the decision of the City shall be accepted as final. b. The temporary delay of any work due to such circumstances shall not be considered as justification for claims for additional compensation. 22 1.5 SUBMITTALS 23 A. Baseline Schedule 24 25 26 27 28 29 1. Submit Schedule in native file format and pdf fonnat as required in the City of Fort Worth Schedule Guidance Document. a. Native file format includes: 1) Primavera (P6 or Primavera Contractor) 2. Submit draft baseline Schedule to City prior to the pre-construction meeting and bring in hard copy to the meeting for review and discussion. 30 B. Progress Schedule 31 1. Submit progress Schedule in native file fonnat and pdf fonnat as required in the 32 City of Fort Worth Schedule Guidance Document. 33 2. Submit progress Schedule monthly no later than the last day of the month. 34 35 36 37 38 C. Schedule Narrative 1. Submit the schedule narrative in pdf fonnat as required in the City of Fort Worth Schedule Guidance Document. 2. Submit schedule narrative monthly no later than the last day of the month. D. Submittal Process 39 1. The City administers and manages schedules through Buzzsaw. 40 2. Contractor shall submit documents as required in the City of Fort Worth Schedule 41 Guidance Document. 42 3. Once the project has been completed and Final Acceptance has been issued by the 43 City, no further progress schedules are required. CITY OF FORT WORTH STANDARD CONSTRUCTION LA PRONTERA — PHASE 3 SPECIFICATION DOCUMENTS — WATER FACILITY PROJ�CTS CITY PROJECT NO.: 10281 ] Revised July l, 2011 013216-5 CONSTRUCTION PROGRESS SCHEDULE Page 5 of 5 1 1.6 ACTION SUgMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 2 1.7 CLOSEOUT SUBMITTALS [NOT USED] 3 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 4 1.9 QUALITY ASSURANCE 5 A. The person preparing and revising the construction Progress Schedule shall be 6 experienced in the preparation of schedules of similar complexity. 7 B. Schedule and supporting documents addressed in this Specification shall be prepared, 8 updated and revised to accurately reflect the performance of the construction. 9 C. Contractor is responsible for the quality of all submittals in this section meeting the 10 standard of care for the construction industry for similar projects. l 1 1.10 DELIVERY, S'i'ORAGE, AND HANDLING [NOT USED] 12 1.11 FIELD [SITE] CONDITIONS [NOT USED] 13 1.12 WARRANTY [NOT USED] 14 PART 2- PRODUCTS [NOT USED] 15 PART 3- EXECUTION [NOT USED] 16 l7 END OF SECTION Revision Log DATE NAME SUMMARY OF CHANGE 18 CITY OF FORT WORTH STANDARD CONSTRUCTION LA FRONTERA— PHASE 3 SPECIPICATION DOCUMENTS — WATER FACILITY PROJECTS CITY PROJECT NO.: 102811 Revised July I, 2011 013233-1 PRECONSTRUCTION VIDEO Page 1 of 2 � 3 PARTl- GENERAL 4 1.1 SUMMARY SECTIOIV Ol 32 33 PRECONSTRUCTION VIDEO 5 A. Section Includes: b 1. Administrative and procedural requirements for: 7 a. Preconstruction Videos 8 B. Deviations from this City of Fort Worth Standard Specification 9 1. None. 10 C. Related Specification Sections include, but are not necessarily limited to: l 1 1. Division 0— Bidding Requirements, Contract Forms and Conditions of the Contract 12 2. Division 1— General Requirements 13 1.2 PRICE AND PAYMENT PROCEDURES 14 A. Measurement and Payment I S 1. Work associated with this Item is considered subsidiary to the various items bid. 16 No separate payment will be allowed for this Item. 17 1.3 REFERENCES [NOT USED] 18 1.4 ADMINISTRATIVE REQUIREMENTS 19 A. Preconstruction Video 20 1. Produce a preconstruction video of the site/alignment, including all areas in the 2l vicinity of and to be affected by construction. 22 a. Provide digital copy of video upon request by the City. 23 2. Retain a copy of the preconstruction video until the end of the maintenance surety 24 period. 25 1.5 SUBMITTAI,S [NOT USED] 26 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 27 1.7 CLOSEOUT SUBMITTALS [NOT USED] 28 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 29 1.9 QUALITY ASSURANCE [NOT USED] 30 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] 31 1.11 FIELD [SITE] CONDITIONS [N�T USED] 32 1.12 WARRANTY [NOT USED] 33 PART 2- PROI)UCTS [NOT USED] CITY OF FORT WORTH LA PRON'I'ERA — PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO.: 102811 Revised July 1, 201 I O13233-2 PRECONSTRUCTION VIDEO Page 2 of 2 PART 3 - EXECUTION [NOT USED] END OF SECTION Revision Log DATE NAME SUMMARY OF CHANGE CITY OF FORT WORTH LA FRONTERA — PHASE 3 STANDARD CONSTRUCTION SP�CIPICATION DOCUMENTS CITY PROJECT NO.: 102811 Revised July i, 2011 013300-i SUBMITTALS Page I of 8 1 2 3 PART1- GENERAL 4 l.l SUMMARY 5 6 7 8 9 10 11 12 13 14 15 16 17 1.2 18 19 20 21 1.3 SECTI�N O1 33 00 SUBMITTALS A. Section Includes: 1. General methods and requirements of submissions applicable to the following Work-related submittals: a. Shop Drawings b. Product Data (including Standard Product List submittals) c. Samples d. Mock Ups B. Deviations from this City of Fort Worth Standard Specification l. None. C. Related Specification Sections include, but are not necessarily limited to: 1. Division 0— Bidding Requirements, Contract Fonns ai�d Conditions of the Contract 2. Division 1— General Requirements PRICE AND PAYMENT PROCEDURES A. Measurement and Payment 1. Work associated with this Itenn is considered subsidiary to the various items bid. No separate payment will be allowed for this Item. REFERENCES [NOT USEDj 22 1.4 ADMINISTRA.TIVE REQUIREMENTS 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 40 A. Coordination 1. Notify the City izz writing, at the time of submittal, of any deviations in the submittals from the requirements of the Contract Documents. 2. Coordination of Submittal Times a. Prepare, prioritize and transmit each submittal suffciently in advance of performing the related Work or other applicable activities, or within the time specified in the individual Work Sections, of the Specifications. b. Contractor is responsible such that the installation will not be delayed by processing times including, but �Zot limited to: a) Disapproval and resubmittal (if required) b} Coordination with other subinittals c) Testing d) Purchasing e) Fabrication � Delivery g) Similar sequenced activities c. No extension of time will be authorized because of the Contractor's failure to transmit submittals sufficiently in advance of the Work. CITY OF FORT WORTH LA FRONTERA — PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO.: 102811 Revised December 20, 2012 O1 33 00 - 2 SUBMITTALS Page 2 of 8 1 ? 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 d. Make submittals promptly in accordance with approved schedule, and in such sequence as to cause no delay in the Work or in the work of any other contractor. B. Submittal Numbering 1. When submitting shop drawings or samples, utilize a 9-character submittal cross- reference identification numbering system in the following manner: a. Use the first 6 digits of the applicable Specification Section Number. b. For the next 2 digits number use numbers 01-99 to sequentially number each initial separate item or drawing submitted under each specific Section number. c. Last use a letter, A-Z, indicating the resubmission of the same drawing (i.e. A=2nd submission, B=3rd submission, C=4th submission, etc.). A typical submittal number would be as follows: [I�#IIZIZ131�:�:? 1} 03 30 00 is the Specification Section for Concrete 2) 08 is the eighth initial submittal under this Specification Section 3) B is the third submission (second resubmission) of that particular shop drawing C. Contractor Certification 21 1. Review shop drawings, product data and samples, including those by 22 subcontractors, prior to submission to determine and verify the following: 23 a. Field measurements 24 b. Field construction criteria 25 c. Catalog numbers and similar data 26 d. Conformance with the Contract Documents 27 2. Provide each shop drawing, sample and product data submitted by the Contractor 28 with a Certification Statement affixed including: 29 a. The Contractor's Company name 30 b. Signature of submittal i•eviewer 31 c. Certification Statement 32 1) "By this submittal, I hereby represe�it that I have detennined and verified 33 field measure�nents, field construction criteria, materials, dimensions, 34 catalog numbers and similar data and I have checked and coordinated each 35 item with other applicable approved shop drawings." 36 37 38 39 40 41 42 43 44 45 46 D. Submittal Format 1. Fold shop drawings larger than 8'/2 inches x 11 inches to 8'/z inches x 11 inches. 2. Bind shop drawings and product data sheets together. 3. Order a. Cover Sheet 1) Description of Packet 2) Contractor Certification b. List of items / Table of Contents c. Product Data /Shop Drawings/Samples /Calculations E. Submittal Content 1. The date of submission and the dates of any previous submissions CITY OF FORT WORTH STANDARD CONSTRUCT[ON SP�CIFICt1TION DOCUMENTS Revised December 20, 2012 LA PRONT�RA — PHASE 3 CITY PRO.iECT NO.: ] 02811 013300-3 SUBMITTALS Page 3 of 8 2 3 4 5 6 7 8 � 2. The Project title and number 3. Contractor identification 4. The names o£ a. Contractor b. Supplier c. Manufacturer 5. Identification of the product, with the Specification Section nunnber, page and paragraph(s) 6. Field dimensions, clearly identified as such 10 7. Relation to adjacent or critical features of the Work or materials 11 8. Applicable standards, such as ASTM or Federal Specification numbers 12 9. Identification by highlighting of deviations from Contract Documents 13 10. Identification by highlighting of revisions on resubmittals 14 l 1. An 8-inch x 3-inch blank space for Contractor and City stamps IS 16 17 18 19 20 2l 22 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 40 41 42 43 44 45 46 F. Shop Drawings l. As specified in individual Work Sections includes, but is not necessarily limited to: a. Custom-prepared data such as fabrication and erection/installation (working) drawings b. Scheduled inforrnation c. Setting diagrams d. Actual shopwork manufacturing instructions e. Custom templates f. Special wiring diagrams g. Coordination drawings h. Individual system or equipment inspection and test reports including: 1) Performance curves and certifications i. As applicable to the Work 2. Details a. Relation of the various parts to the main members and lines of the structure b. Where correct fabrication of the Work depends upon field ineasurements 1) Provide such measurements and note on the drawings prior to submitting for approval. G. Product Data 1. For submittals of product data for products included on the City's Standard Product List, clearly identify each item selected for use on the Project. 2. For submittals of product data for products not included on the City's Standard Product List, submittal data may include, but is not necessarily limited to: a. Standard prepared data for manufactured products (sometimes referred to as catalog data) 1) Such as the manufacturer's product specification and installation instructions 2) Availability of colors and patterns 3) Manufacturer's printed statements of compliances and applicability 4) Roughing-in diagrams and templates 5) Catalog cuts 6) Product photographs CITY OF FORT WORTH LA FRONTERA — PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO.: ] 0281 I Revised December 20, 2012 Oi3300-4 SUBMITTALS Page 4 of 8 1 7) Standard wiring diagrams ? 8) Printed performance curves and operational-range diagrams 3 9) Production ar quality control inspection and test reports and certifications 4 10) Mill reports 5 1 l} Product operat�ng and maintenance instructions and recommended 6 spare-parts listing and printed product warranties 7 12) As applicable to the Work 8 H. Samples 9 1. As specified in individual Sections, include, but are not necessarily limited to: 10 a. Physical examples of the Work such as: 11 1) Sections of manufactured or fabricated Work 12 2) Small cuts or containers of materials 13 3) Complete units of repetitively used products color/texture/pattern swatches 14 and range sets 15 4) Specimens for coordination of visual effect 16 5) Graphic symbols and units of Work to be used by the City for independent 17 inspection and testing, as applicable to the Work 18 I. Do not start Work requiring a shop drawing, sample or product data nor any material to 19 be fabricated or installed prior to the approval or quatified approval of such item. 20 1. Fabrication performed, materials purchased or on-site construction accomplished 21 which does not conform to approved shop drawings and data is at the Contractor's 22 risk. 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 40 41 42 43 44 45 46 47 2. The City will not be liable for any expense or delay due to corrections or remedies rec�uired to accomplish conformity. 3. Complete project Work, inaterials, fabrication, and installations in conformance with approved shop drawings, applicable samples, and product data. J. Submittal Distribution l. Electronic Distribution a. Confirm development of Project directory for electronic submittals to be uploaded to City's Buzzsaw site, or another external FTP site approved by the City. b. Shop Drawings 1) Upload submittal to designated project directory and notify appropriate City representatives via email of submittal posting. 2) Hard Copies a) 3 copies for all submittals b) If Contractor requires i�nore than 1 hard copy of Shop Drawings returned, Contractor shall submit more than the number of copies listed above. c. Product Data 1) Upload submittal to designated project directory and notify appropriate City representatives via email of submittal posting. Z) Hard Copies a) 3 copies for all submittals d. Samples 1) Distributed to the Project Representative 2. Hard Copy Distribution (if required in lieu of electronic distribution) CITY OF FORT WORTH LA FRONTERA— PHAS� 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO.: 102811 Revised December 20, 2012 013300-5 SUBMITTALS Page 5 of 8 1 2 3 4 5 6 7 8 9 1Q 11 12 13 ]4 15 16 17 18 19 20 a. Shop Drawings 1) Distributed to the City 2) Copies a) 8 copies for mechanical submittals b) 7 copies for all other submittals c) If Contractor requires more than 3 copies of Shop Drawings returned, Contractor shall submit more than the number of copies listed above. b. Product Data 1) Distributed to the City 2) Copies a) 4 copies c. Samples 1} Distributed to the Project Representative 2) Copies a) Subinit the number stated in the respective Specification Sections. 3. Distribute reproductions of approved shop drawings and copies of approved product data and sainples, where required, to the job site file and elsewhere as directed by the City. a. Provide number of copies as directed by the City but not exceeding the number previously specified. 21 K. Submittal Review 22 1. The review of shop drawings, data and samples will be for general conformance 23 with the design concept and Contract Documents. This is not to be construed as: 24 a. Permitting any departure from the Contract requirements 25 b. Relieving the Contractor of respansibility for any errors, including details, 26 dimensions, and materials 27 c. Approving departures from details furnished by the City, except as otherwise 28 provided herein 29 2. The review and approval of shop drawings, samples or product data by the City 30 does not relieve the Contractor from his/her respo»sibility with regard to the 31 fulfillment of the terms of the Contract. 32 a. All risks of error and omission are assumed by the Contractor, and the City will 33 have no responsibility therefore. 34 3. The Contractor remains responsible for details and accuracy, for coordinating the 35 Work with all other associated work and trades, for selecting fabrication processes, 36 for techniques of assembly and for performing Work in a safe manner. 37 4. If the shop drawings, data or samples as submitted describe variations and show a 38 departure from the Contract requirements which City finds to be in the interest of 39 the City and to be so minor as not to involve a change in Contract Price or time for 40 performance, the City may return the reviewed drawings without noting an 41 exception. 42 43 44 45 46 47 48 5. Submittals will be returned to the Contractor under 1 of the following codes: a. Code 1 1) "NO EXCEPTIONS TAKEN" is assigned when there are no notations or comments on tlle submittal. a) When returtied under this code the Contractor may release the equipment and/or material for inanufacture. b. Code 2 CITY OF FORT WORTH LA FRONTERA — PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO.: 102811 Revised December 20, 2012 013300-6 SUBMITTALS Page 6 of S 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 40 41 42 43 44 45 46 47 48 49 7 8. 1) "EXCEPTIONS NOTED". This code is assigned when a confirnlation of the notations and comments IS NOT required by the Contractor. a) The Contractor may release the equipment or material for manufacture; however, all notations and cominents must be incorporated into the final product. c. Code 3 1) 'BXCEPTIONS NOTED/RESUBMIT". This combination of codes is assigned when notations and comments are extensive enough to require a resubmittal of the package. a) The Contractor may release the equipment or material for manufacture; however, all notations and comments must be incorporated into the final product. b) This resubmittal is to address all comments, omissions and non-confonning items that were noted. c) Resubmittal is to be received by the City within 15 Calendar Days of the date of the City's transmittal requiriilg the resubmittal. d. Code 4 1) "NOT APPROVED" is assigiled when the submittal does not meet the intent of the Contract Documents. a) The Contractor must resubmit the entire package revised to bring the submittal into confonnance. b) It inay be necessary to resubmit using a different manufacturer/vendor to meet the Contract Documents. 6. Resubmittals a. Handled in the same manner as first submittals l) Corrections other than requested by the City 2) Marked with revision triangle or other similar method a) At Contractor's risk if not marked b. Submittals for each item will be reviewed no more than twice at the City's expense. 1) All subsequent reviews will be performed at times convenient to the City and at the Contractor's expense, based on the City's or City Representative's then prevailing rates. 2) Provide Contractor reimbursement to the City within 30 Calendar Days for all such fees invoiced by the City. c. The need for more than 1 resubmission or any other delay in obtaining City's review of submittals, will not entitle the Contractor to an extension of Contract Time. Partial Submittals a. City reserves the right to not review submittals deeined partial, at the City's discretion. b. Sub�nittals deemed by the City to be not complete will be returned to the Contractor, and will be considered "Not Approved" until resubmitted. c. The City may at its option provide a list or mark the submittal directing the Contractor to the areas that are incomplete. If the Contractor considers auy correction indicated on the shop drawings to constitute a change to the Contract Documents, then written notice must be provided thereof to the City at least 7 Calendar Days prior to release for manufacture. CITY OF FORT WORTH STANDARD CONSTRUCTION SPECIPICATION DOCUMENTS Revised December 20, 2012 LA FRONTCRA — PHASE 3 CITY PROJECT NO.: 102811 013300-7 SU$MITTALS Page 7 of 8 1 2 3 4 5 0 � When the shop drawings have been completed to the satisfaction of the City, the Contractor may carry out the construction in accordance therewith and no further changes therein except upon written instructions from the City. Each submittal, appropriately coded, will be returned within 30 Calendar Days following receipt of submittal by the City. 6 L. Mock ups 7 1. Mock Up units as specified in individual Sections, include, but are not necessarily 8 liinited to, complete units of the standard of acceptance for that type of Work to be 9 used on the Project. Remove at the completion of the Work or when directed. 10 il 12 13 14 IS 16 17 18 19 20 M. Qualifications 1. If specifically required in other Sections of these Specifications, submit a P.E. Certification for each item required. N. Request for Information (RFI) 1. Contractor Request for additional information a. Clarification or interpretation of the contract documents b. When the Contractor believes there is a conflict between Contract Documents c. When the Contractor believes there is a conflict between the Drawings and Specifications 1) Identify the conflict and request clarifcation 2. Use the Request for Infonnation (RFI) form provided by the City. 21 3. Numbering of RFI 22 a. Prefix with "RFI" followed by series number, "-xxx", beginning with "O1" and 23 increasing seque�ltially with each additional transmittal. 24 4. Sufficient infonnation shall be attached to permit a written response without further 25 information. 26 5. The City will log each request and will review the request. 27 a. If review of the project information request indicates that a change to the 28 Contract Documents is required, the City will issue a Field Order or Change 29 Order, as appropriate. 30 1.5 SUBMITTALS [NOT USED] 31 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 32 1.7 CLOSEOUT SUBMITTALS [NOT USED] 33 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 34 1.9 QUALITY ASSURANCE [NOT USED] 35 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] 36 1.11 FIELD [SITE] CONDITIONS [NOT USED] 37 1.12 WARRANTY [NOT USED] CITY OF FORT WORTH LA FRONTERA — PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO.: 1028ll Revised December 2Q 2012 013300-8 SUBMITTALS Page 8 of 8 1 PART 2- IPRODUCTS [NOT USEDj 2 PART 3- EXECUTION (NOT USED] 3 END OF SECTION Revision Log DATE NAME SUMMARY OF CHANGE 12/20/2012 D. Johnson 1.4.K.8. Working Days modified to Calendar Days CITY OF PORT WORTH LA FRONTERA — PHASE 3 STANDARD CONSTRUCTION SPECIPICATION DOCUMENTS CITY PRO.�ECT NO.: ]028ll Revised December 2Q 2012 013513-1 DAP SPECIAL PROJECI' PROCEDUR�S Page 1 of 7 1 2 3 PART1- GENERAL 4 1.1 SUMMARY 5 6 7 8 9 10 11 l2 13 14 15 16 l7 18 1 21 22 23 24 25 SECTION O1 35 13 SPECIAL PROJECT PROCEDURES A. Section Iiicludes: l. The procedures for special project circumstances that includes, but is not limited to: a. Coordination with the Texas Department of Transportation b. Work near High Voltage Lines c. Confined Space Entry Program d. Air Pollution Watch Days e. Use of Explosives, Drop Weight, Etc. £ Water Department Notification g. Public Notification Prior to Beginning Construction h. Coordination with United States Anny Corps of Engineers i. Coordination within Railroad permits areas j. Dust Control k. Employee Parking B. Deviations from this City of Fort Worth Standard Specification l. None. C. Related Specification Sections include, but are not necessarily limited to: 1. Division 0— Bidding Requirements, Contract Forms and Conditions of the Contract 2. Division 1— General Requirements 3. Section 33 12 25 — Connection to Existing Water Mains 26 1.2 REFERENCES 27 28 29 30 31 32 33 34 35 1.3 A. Reference Standards 1. Reference standards cited in this Specification refer to the current reference standard published at the time of the latest revision date logged at the end of this Specification, unless a date is specifically cited. 2. Health and Safety Code, Title 9. Safety, Subtitle A. Public Safety, Chapter 752. High Voltage Overhead Lines. 3. North Central Texas Council of Governments (NCTCOG} — Clean Construction Specification ADMINISTRATIVE REQUIREMENTS 36 A. Coordination with the Texas Department of Transportation 37 l. When work in the right-of-way which is under the jurisdiction of the Texas 38 Deparhnent of Transportation (TxDOT): 39 a. Notify the Texas Department of Transportation prior to commencing any work 40 therein in accordance with the provisions of the pennit CITY OP FORT WORTH LA FRONTERA — PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEV�LOPER AI��ARDED PROJECTS CITY PROJECT NO.: 102811 Revised August, 30, 2013 013513-2 DAP SPECIAL PROJBCT PROCEDURES Page 2 of 7 1 2 3 4 5 6 7 8 9 10 ll 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 3$ 39 40 41 42 43 44 45 b. All work performed in the TxDOT right-of-way shall be performed in compliance with and subject to approval from the Texas Department of Transportation B. Work near High Voltage Lines �� 3 L� Regulatory Requireanents a. All Work near High Voltage Lines (more thar1600 volts measured between conductors or between a conductor and the ground) shall be in accordance with Health and Safety Code, Title 9, Subtitle A, Chapter 752. Warning sign a. Provide sign of sufficient size meeting all OSHA requirements. Equipment operating within 10 feet of high voltage lines will require the following safety features a. Insulating cage-type of guard about the boom or ann b. Insulator links on the lift hook connections for back hoes or dippers c. Equipment must meet the safety requirements as set forth by OSHA and the safety requirements of the owner of the high voltage lines Work within 6 feet of high voltage electric lines a. Notification shall be given to: 1) The power company (example: ONCOR) a) Maintain an accurate log of all such calls to power company and record action taken in each case. b. Coordination with power company 1) After notification coordinate with the power company to: a) Erect temporary mechanical barriers, de-energize the lines, or raise or lower the lines c. No personnel may work within 6 feet of a high voltage line before the above requirements have been met. C. Confined Space Entry Program 1. Provide and follow approved Confined Space Entry Program in accordance with OSHA requirements. 2. Confined Spaces include: a. Manholes b. All other confined spaces in accordance with OSHA's Permit Required for Confined Spaces D. Use of Explosives, Drop Weight, Etc. 1. When Contract Documents permit on the project the following will apply: a. Public Notification 1) Subinit notice to City and proof of adequate insurance coverage, 24 hours prior to commencing. 2) Minimum 24-hour public notification in accordance with Section O1 31 13 E. Water Department Coordination 1. During the construction of this project, it will be necessary to deactivate, for a period of time, existing lines. The Contractor shall be required to coordinate with the Water Department to determine the best times for deactivating and activating those lines. CITY OF FORT WORTH LA FRONTERA — PHASE 3 STANDARD CONSTRUCTION SPECIFICAI'TON DOCUMENTS — DEVELOPER AWARDED PROJECTS C[TY PROJECT NO.: 102811 Revised August, 30, 2013 01 35 13 - 3 DAP SPECIAL PROJECT PROC�DURES Page 3 of 7 1 2. Coordinate aily event that will require connecting to or the operation of an existing 2 City water line system with the City's representative. 3 a. Coordination shall be in accordance with Section 33 12 25. 4 b. If needed, obtain a hydrant water meter from the Water Department for use 5 during the life of named project. 6 c. In the event that a water valve on an existing live system be turned off and on 7 to accommodate the construction of the project is required, coordinate this 8 activity through the appropriate City representative, 9 1) Do not operate water line valves of existing water system. 10 a) Failure to comply will render the Contractor in violation of Texas Penal ll Code Title 7, Chapter 28.03 (Criminal Mischie fl and the Contractor 12 will be prosecuted to the full extent of the law. 13 b) In addition, the Contractor will assume all liabilities and 14 responsibilities as a result of these actions. 15 F. Public Notification Prior to Beginning Construction 16 1. Prior to beginning construction on any block in the project, on a block by block 17 basis, prepare and deliver a notice or flyer of the pending construction to the front 18 door of each residence or business that will be impacted by construction. The notice 19 shall be prepared as follows: 20 a. Post notice or flyer 7 days prior to beginning any construction activity on each 21 block in the project area. 22 1) Prepare flyer on the Contractor's letterhead and include the following 23 information: 24 a} Name of Project 25 b) City Project No (CPN) 26 c) Scope of Project (i.e. type of construction activity) 27 d) Actual construction duration within the block 28 e) Name of the contractor's foreman and phone number 29 � Name of the City's inspector and phone number 30 g) City's after-hours phone number 31 2) A sample of the `pre-construction notification' flyer is attached as Exhibit 32 A. 33 3) Submit schedule showing the construction start and fiilish time for each 34 block of the project to the inspector. 35 4) Deliver flyer to the City Inspector for review prior to distribution. 36 b. No construction will be allowed to begin on any block until the flyer is 37 delivered to all residents of the block. 38 G. Public Notification of Temporary Water Service Interruption during Construction 39 1. In the event it becomes necessary to temporarily shut down water service to 40 residents or businesses during construction, prepare and deliver a notice or flyer of 41 the pending interruption to the front door of each affected resident. 42 2. Prepared notice as follows: 43 a. The notification or flyer shall be posted 24 hours prior to the temporary 44 interruption. 45 b. Prepare flyer on the contractor's letterhead and include the following 46 infonnation: 47 1) Name ofthe project 48 2) City Project Number CITY OF PORT WORTH LA FRONTERA — PHASE 3 STANDARD CONSTRUCTION SPECIPICATION DOCUM�NTS — DEV�LOPER AWARD�D PROJECTS CITY PROJECT NO.: 102811 Revised August, 30, 2013 013513-4 DAP SPEC[AL PROJECT PROCEDURES Page 4 of 7 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 3l 32 33 34 35 36 37 c. d. e. f. 3) Date of the interruption of service 4) Period the interruption will take place 5) Name of the contractor's foreman and phone number 6) Name of the City's ins}�ector and phone number A sample of the temporary water service interruption notification is attached as Exhibit B. Deliver a copy of the temporary interruption notification to the City inspector for review prior to being distributed. No interruption of water service can occur until the flyer has been delivered to all affected residents and businesses. Electronic versions of the sample flyers can be obtained from the Project Construction Inspector. H. Coordination with United States Army Corps of Engineers (USACE) 1. At locations in the Project where construction activities occur in areas where USACE permits are required, meet all requirements set forth in each designated perm it. I. Coordination within Railroad Permit Areas At locations in the project where construction activities occur in areas where railroad permits are required, meet all requirements set forth in each designated railroad permit. This includes, but is not limited to, provisions for: a. Flagmen b. Inspectors c. Safety training d. Additional insurance e. Insurance certificates f. Other employees required to protect the right-of-way and property of the Railroad Company from damage arising out of and/or from the construction of the project. Proper utility c(earance procedures shall be used in accordance with the permit guidelines. 2. Obtain any supplemental infonnation needed to comply with the railroad's requirements. J. Dust Control 1. Use acceptable measures to control dust at the Site. a. If water is used to control dust, capture and properly dispose of waste water. b. If wet saw cutting is performed, capture and properly dispose of slurry. K. Employee Parking l. Provide parking for employees at locations approved by the City. CITY OF FORT WORTH LA PRONTERA — PHASE 3 STANDARD CONSTRUCTION SP�CIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS CITY PROJECT NO.: 102811 Revised August, 30, 2013 013513-5 DAP SPECIAL PROJECT PROCCDURES Page 5 of 7 1 1.4 SYTBMITTALS [NOT USED] 2 1.5 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 3 1.6 CLOSEOUT SUBMITTALS [NOT USED] 4 1.7 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 5 1.8 QUALITY ASSiTRANCE [NOT USEDJ 6 1.9 DELIVERY, STORAGE, AND HANDLING [NOT USED] 7 1.10 FIELD [SITE] CONDITIONS [NOT USED] 8 1.11 WARRANTY [NOT USED] 9 PART 2- PRODUCTS [NOT USED] 10 PART 3- EXECUTION (NOT USED] 11 � END OF SECTION Revision Log DATE NAME SUMMARY OF CHANGE 13.B — Added requirement of compliance with Health and Safety Code, Title 9. 8/3l/2012 D. Johnson Safety, Subtitle A. Public Safety, Chapter 752. High Voltage Overhead Lines. 13 CITY OF FORT WORTH LA FRONTERA — PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOP�R AWARDED PRO.IECTS CITY PROJ�CT NO.: 10281 I Revised August, 30, 2013 013513-6 DAP SPECIAL PRO.tECT PROCEDURES Page 6 of 7 1 2 3 4 5 6 7 s 9 10 11 12 13 14 IS 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 Date: CPN Na.: Project Name: Mapsco Location: Limits of Construction: EXHIBIT A (To be printed on Contractor's Letterhead) ' THIS IS TO INFORM YOU THAT UNDER A CONTRACT WITH THE CITY OF FORT WORTH, OUR COMPANY WILL WORK ON UTILITY LINES ON OR AROUND YOUR PROPERTY. CONSTRUCTION WILL BEGIN APPROXIMATELY SEVEN DAYS FROM THE DATE OF THIS NOTICE. IF YOU HAVE QUESTIONS ABOUT ACCESS, SECURITY, SAFETY OR ANY OTHER ISSUE, PLEASE CALL: Mr. <CONTRACTOR°S SUPERINTENDENT> AT <TELEPHONE NO.> OR Mr. <CITY INSPECTOR> AT < TELEPHONE NO.> AFTER 4:30 PM OR ON WEEKENDS, PLEASE CALL (817) 392 8306 PLEASE KEEP THIS FLYER HANDY WHEN YOU CALL CITY OF FORT WORTH LA FRONTERA — PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS CITY PROJECT NO.: 102811 Revised August, 30, 2013 O1 35 13 - 7 DAP SPECIAL PROJECT PROCEDURES Page 7 of 7 1 2 EXHIBIT B Fo�T WoRTH � DOE I�Q. XXXX Project I�ame: I�1CfTICE C1F TEMPORARY WA?ER SERVICE II�ITERRi�PTIOI�i DUE TO UTILITY IMPR��TENfENT3 IN YOUR NEIGHSORHOOD, YOUR WATER SERYICE WILL BE INTERRUPTED ON BETWEEN TFtE HOURS OF AND IFYOU I3AVE QI7E5TIONS ABOUT THIS SHUT-OUT, PLEASE CALL: MR, AT (CQNTRACTORS SUPERINTENDEN'i) (TELEPHONE Ni3MBER) OR MR AT (CiTY INSPECTUR) (TELEPHONE NUMSER) THIS IIYCONVENIENCE WILL BE A3 SHOitT AS POSSIBLE. THANK YOiJ, ,CONTRACTOR 3 4 CITY OF FORT WORTH LA FRONT�RA — PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARD�D PRO.IGCTS CITY PROJECT NO.: ] 02811 Revised August, 30, 2013 014523-1 TESTING AND INSPECTTON SERVICES Page 1 of 2 ] 2 3 PART1- GENERAL SECTION O1 45 23 TESTiNG AND INSPECTION SERVICES 4 l.l SUMMARY 5 A. Section Includes: 6 1. Testing and inspection services procedures and coordination 7 B. Deviations from this City of Fort Worth Standard Specification 8 1. None. 9 10 11 12 1.2 ]3 14 15 l6 17 18 19 20 21 22 23 24 25 1.3 C. Related Specification Sections include, but are not necessarily limited to: 1. Division 0— Bidding Requirements, Contract Forms and Conditions of the Contract 2. Division 1— General Requirements PRICE AND PAYMENT PROCEDURES A. Measurement and Payment 1. Work associated with this Item is considered subsidiary to the various ltems bid. No separate payment will be allowed for this Item. a. Contractor is responsible for perfonning, coordinating, and payment of all Quality Control testing. b. City is responsible for performing and payment for first set of Quality Assurance testing. 1) If the first Quality Assurance test performed by the City fails, the Contractor is responsible for payment of subsequent Quality Assurance testing until a passing test occurs. a) Final acceptance will not be issued by City until all required payments for testing by Contractor have been paid in full. REFERENCES [NOT USED] 26 1.4 ADMINISTRATIVE REQUIREMENTS 27 28 29 30 31 32 33 34 35 36 37 38 A. Testing 1. Complete testing in accordance with the Contract Documents. 2. Coordination a. When testing is required to be performed by the City, notify City, sufficiently in advance, when testing is needed. b. When testing is required to be completed by the Contractor, notify City, sufficiently in advance, that testing will be performed. 3. Distribution of Testing Reports a. Electronic Distribution 1} Confirm development of Project directory for electronic submittals to be uploaded to City's Buzzsaw site, or another external FTP site approved by the City. CITY OP PORT WORTH LA FRONTERA — PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO.: 10281 I Revised July l, 2011 014523-2 TESTING AND INSPECTION SERVICES Page 2 of 2 1 2 3 4 S 6 7 8 9 10 i1 ia 13 14 2) Upload test reports to designated project directory and notify appropriate City representatives via email of submittal posting. 3) Hard Copies a) 1 copy for all subrnittals submitted to the Project Representative b. Hard Copy Distribution (if required in lieu of electronic distribution) 1) Tests performed by City a) Distribute 1 hard copy to the Contractor 2) Tests performed by the Contractor a) Distribute 3 hard copies to City's Project Representative 4. Provide City's Project Representative with trip tickets for each delivered load of Concrete or Liine material including the following information: a. Name of pit b. Date of delivery c. Material delivered 15 B. Inspection 16 1. Inspection or lack of inspection does not relieve the Contractor from obligation to 17 perform work in accordance with the Contract Documents. 18 1.5 SUBMITTALS [NOT USED] 19 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 20 1.7 CLOSEOUT SUBMITTALS [NOT USEDJ 21 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 22 1.9 QUALITY ASSURANCE [NOT USED] 23 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] 24 25 1.11 FIELD [SITE] CONDITIONS [NOT USED] 1.12 WARRANTY [NOT USED] 26 PART 2- PRODUCTS [NOT USED] 27 28 29 PART 3 - EXECUTION [NOT USED] END OF SECTION Revision Log DATE NAME SUMMARY OF CHANGE 30 CITY OF FORT WORTH LA FRONTERA — PHASC 3 STANDARD CONSTRUCTION SPECIPICATION DOCUMI:NTS CITY PROJGCT NO.: 1028] 1 Revised July 1, 201 I 01 50 00 - 1 TEMPORARY FACILITIGS AND CONTROLS Page 1 of 4 1 2 SECTION O1 50 00 TEMPORARY FACILITIES AND CONTROLS 3 PART1- GENERAL 4 1.1 SUMMARY 5 6 7 8 9 10 ll 12 13 14 15 16 Section Includes: 1. Provide temporary facilities and controls needed for the Work including, but not necessarily limited to: a. Temporary utilities b. Sanitary facilities c. Storage Sheds and Buildings d. Dust control e. Temporary fencing of the construction site Deviations from this City of Fort Worth Standard Specification 1. Modified 1.2.A.1 2. Added 1.2.A.2 3. Added 1.4.C.7 /:1 C 17 C. Related Specification Sections include, but are not necessarily limited to: 18 1. Division 0— Bidding Requirements, Contract Forms and Conditions of the Contract l9 2. Division 1— General Requirements 20 1.2 PRICE AND PAYMENT PROCEDURES 21 22 23 24 25 26 1.3 A. Measurement and Payment 1. Unit Price - Work associated with this Item is considered subsidiary to the various items bid. No separate payment will be allowed for this Item. 2. Lump Sum Price - Work associated with this Item is included in the total lump sum price. REFERENCES [NOT USED] 27 1.4 ADMINISTRATIVE REQUIREMENTS 28 29 30 31 32 33 34 35 36 37 A. Temporary Utilities 1. Obtaining Temporary Service a. Make arrangements with utility service companies for temporary services. b. Abide by rules and regulations of utility service companies or authorities having jurisdiction. c. Be responsible for utility service costs until Work is approved for Final Acceptance. 1) Included are fuel, power, light, heat and other utility services necessary for execution, completion, testing and initial operation of Work. 2. Water CITY OF FORT WORTH S1'ANDARD CONSTRUCTiON LA FRONTERA — PHASE 3 SPECIFICATION DOCUMENTS — WATER FACILITY PROJECTS CITY PROJECT NO.: 102811 Revised July ], 2011 015000-2 TEMPORARY FACILITIES AND CONTROLS Page 2 of 4 1 2 3 4 5 6 7 8 9 10 I1 l2 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 40 41 42 43 44 45 3 Q 5 a. Contractor to provide water required for and in connection with Work to be perfonned and for specified tests of piping, equipment, devices or other use as required for the completion of the Work. b. Provide and maintain adequate supply of potable water for domestic consumption by Contractor personnel and City's Project Representatives. c. Coordination 1) Contact City 1 week before water for co�lstruction is desired d. Contractor Payment for Construction Water 1) Obtain construction water meter from City for payment as billed by City's established rates. Electricity and Lighting a. Provide and pay for electric powered service as required for Work, including testing of Work. 1) Provide power for lighting, operation of equipment, or other use. b. Electric power service includes teinporary power service or generator to maintain operations during scheduled shutdown. Telephone a. Provide emergency telephone service at Site for use by Contractor personnel and others performing work or furnishing services at Site. Temporary Heat and Ventilation a. Provide temporary heat as necessary for protection or completion of Work. b. Provide teinporary heat and ventilation to assure safe working conditions. B. Sanitary Facilities � 3. Provide and maintain sanitary facilities for persons on Site. a. Comply with regulations of State and local depariments of health. Enforce use of sanitary facilities by construction persom�el at job site. a. Enclose and anchor sanitary facilities. b. No discharge will be allowed from these facilities. c. Collect and store sewage and waste so as not to cause nuisance or health problem. d. Haul sewage and waste off-site at no less than weekly intervals and properly dispose in accordance with applicable regulation. Locate facilities near Work Site and keep clean and maintained throughout Project. 4. Remove facilities at completion of Project C. Storage Sheds and Buildings 1. Pravide adequately ventilated, watertight, weatherproof storage facilities with floor above ground level for materials and equipinent susceptible to weather damage. 2. Storage of materials not susceptible to weather damage may be on blocks off ground. 3. Store materials in a neat and orderly manner. a. Place materials and equipment to permit easy access for identification, inspection and inventory. 4. Equip building with lockable doors and lighting, and provide electrical service for equipment space heaters and heating or ventilation as necessary to provide storage environments acceptable to specified manufacturers. CITY OF FORT WORTT-I STANDARD CONSTRUCTION SPECIFICATION DOCUM�NTS — WATER FACILITY PR0.IECTS Revised July 1, 2011 LA FRONT�RA — PHASE 3 CITY PROJECT NO.: 102811 015400-3 TEMPORARY FACILITICS AND CONTROLS Page 3 of 4 1 2 3 4 5 6 7 8 9 10 I1 12 l3 14 IS 16 17 18 19 5. Fill and grade site for temporary structures to provide drainage away from temporary and existing buildings. 6. Remove building from site prior to Final Acceptance. 7. A field offce is repuired for this project. D. Temporary Fencing 1. Provide and maintain for the duration or construction when required in contract documents E. Dust Control 1. Contractor is responsible for maintaining dust control through the duration of the project. a. Contractor remains on-call at all times b. Must respond in a timely manner F. Temporary Protection of Construction 1. Contractor or subcontractors are responsible for protecting Work from damage due to weather. 1.5 SUSMITTALS [NOT USED] 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] l.� CLOSEOUT SUBMITTALS [NOT USED) 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 20 1.9 QUALITY ASSURANCE [NOT USED] 21 1.10 DELIVERY, STORAGE, AND I3ANDLING [NOT USED] 22 1.11 FIELD [SITE] CONDITIONS [NOT USED] 23 1.12 WARRANTY [NOT USED] 24 PART 2- PRODUCTS [NOT USED] 25 PART 3- EXECUTION [NOT USED) 26 3.1 INSTALLERS [NOT USED] 27 3.2 EXAMINATION [NOT USED] 28 3.3 PREPARATION [NOT USED] 29 3.4 INSTALLATION 30 A. Temparary Facilities 31 1. Maintain all temporary facilities for duration of construction activities as needed. CITY OF FORT WORTH STANDARD CONSTRUCTION LA FRONTERA — PHASE 3 SPECIFICATION DOCUMENTS — WATER FACILITY PROJECTS CITY PROJECT NO.: 102811 Revised July 1, 20l I O15000-4 TEMPORARY FACILITIES AND CONTROLS Page 4 of 4 1 3.5 [REPAIR] / [REST�R..A.TION) 2 3.6 RE-INSTALLATION 3 3.7 FIELD [oR] SITE QUALITY CONTROL [NOT USED] 4 3.8 SYSTEM STARTUP [NOT USED] 5 3.9 ADJUSTING [NOT USED] 6 3.10 CLEANING [NOT USED] 7 3.11 CLOSEOUT ACTIVITIES 8 A. Temporary Facilities 9 1. Remove all temporary facilities and restore area after completion of the Work, to a 10 condition equal to or better than prior to start of Work. 11 3.12 PROTECTION [NOT USED) 12 3.13 MAINTENANCE [NOT USED] 13 3.14 A�'TACHMENTS [NOT USED] l4 15 EIiTD OF SECTION Revision Log DATE NAME SUMMARY OF CHANGE 16 CITY OF FORT WORTH STANDARD CONSTRUCTION LA FRONTERA — PI-IASE 3 SPECIFICATION DOCUMENTS — WATER PACILITY PROJECTS CITY PROJECT NO.: 102811 Revised July l, 2011 O15526-I STRECT USE PERMIT AND MODIPICATIONS TO TRAFFIC CONTROL Page I of 3 1 SECTION O1 55 26 2 STREET USE PERMIT AND MODIFICATIONS TO TRAFFIC CONTROL 3 PARTl- GENERAL 4 1.1 SUMMARY 5 A 6 7 8 9 10 B. 11 Section Includes: l. Administrative procedures for: a. Street Use Permit b. Modification of approved traffic control c. Reinoval of Street Signs Deviations from this City of Fort Worth Standard Specification 1. None. 12 C. Related Specification Sections include, but are not necessarily limited to: 13 1. Division 0— Bidding Requirements, Contract Forms and Conditions of the Contract 14 2. Division 1— General Requirements 15 3. Section 34 71 13 — Traffic Control l6 1.2 PRICE AND PAYMENT PROCEDURES 17 A. Measurement and Payment 18 l. Work associated with this Item is considered subsidiary to the various Items bid. 19 No separate payment will be allowed for this Item. 20 1.3 REFERENCES 21 A. Reference Standards 22 1. Reference standards cited in this specification refer to the current reference standard 23 published at the time of the latest revision date logged at the end of this 24 specification, unless a date is specifically cited. 25 2. Texas Manual on Uniform Traffic Control Devices (TMUTCD). 26 1.4 ADMINISTRATIVE REQUIREMENTS 27 28 29 3� 31 32 33 34 A. Traffic Control 1. General a. When traffic control plans are included in the Drawings, provide Traffic Control in accordance with Drawings and Section 34 71 13. b. When traffic control plans are not included in the Drawings, prepare traffic control plans in accordance with Section 34 71 13 and submit to City for review. 1) Allow minimum 10 working days for review of proposed Traffic Control. 35 B. Street Use Perrnit 36 1. Prior to installation of Traffic Control, a City Street Use Permit is required. 37 a. To obtain Street Use Permit, submit Traffic Control Plans to City 38 Transportation and Public Works Department. CITY OP PORT WORTH LA FRONTERA — PHASE 3 STANDARD CONSTRUCTION SPECIPICATION DOCUMENTS CITY PROJECT NO.: 10281 I Revised Jtiily i, 2011 015526-2 STREET USE PERMIT AND MODIFICATIONS TO TRAFPIC CONTROL Page 2 of 3 l 2 3 1) Allow a minimuin of 5 working days for pei-�nit review. 2) Contractor's responsibility to coordinate review of Traffc Control plans for Street Use Permit, such that construction is not delayed. 4 C. Modification to Approved Traf�c Control 5 1. Prior to installation traffic coi�trol: 6 a. Submit revised traffc control plans to City Department Transportation and 7 Public Works Department. 8 1) Revise Traffic Control plans in accordance with Section 34 71 13. 9 2) Allow minimum 5 working days for review of revised Traffic Control. 10 3) It is the Contractor's responsibility to coordinate review of Traffic Control 11 plans for Street Use Pennit, such that construction is not delayed. 12 D. Removal of Street Sign 13 1. If it is determined that a street sign must be removed for construction, then contact 14 City Transportation and Public Works Deparhnent, Signs and Markings Division to 15 remove the sign. 16 17 18 19 20 21 22 23 24 25 E. Temporaxy Signage 1. In the case of regulatory signs, replace pennanent sign with temporary sign ineeting requirements of the latest edition of the Texas Manual on Uniform Traffic Control Devices (MUTCD). 2. Install tetnparary sign before the removal of permanent sign. 3. When construction is complete, to the extent that the permanent sign can be reinstalied, contact the City Transportation and Public Works Department, Signs and Markings Division, to reinstall the pennanent sign. F. Traffic Control Standards 1. Traffc Control Standards can be found on the City's Buzzsaw website. 26 1.5 SUBMITTALS [NOT USED] 27 1.6 ACTION SUSMITTALS/INFORMATIONAL SUBMITTALS [NOT US�D] 28 1.7 CLOSEOUT SUBMITTALS [NOT USED] 29 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 30 1.9 QUALITY ASSiTI2ANCE [NOT USED] 31 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] 32 33 1.11 FIELD [SITE] CONDITIONS [NOT USED] 1.12 WARRANTY [NOT USED] 34 PART 2- PRODUCTS [NOT USED] 35 PAR'I' 3- EXECUTION [NOT USED] 36 END OF SECTION CITY OF FORT WORTH LA FRONTERA — PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO.: 102811 Revised July 1, 2011 015526-3 STREET USE PERMIT AND MODIPICATIONS TO TRAFFIC CONTROL Page 3 of 3 Revision Log DATE NAME SUMMARY OF CHANGE CITY OF FOR"1' WORTH LA FRONTERA — PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJGCT NO.: 102811 Revised July 1, 2011 015713-1 STORM WATER POLLUTION PR�VENTION Page 1 of 3 l 2 SECTION Ol 57 13 STORM WATER POLLUTION PREVENTION 3 PAR.T 1 - GENERAL 4 l.l SUMMAR�' �. 7 8 A. Section Includes: 1. Procedures for Stonn Water Pollution Prevention Plans B. Deviations from this City of Fort Worth Standard Specification 1. None. 9 C. Related Specification Sections include, but are not necessarily limited to: 10 1. Division 0— Bidding Requirements, Contract Forms and Conditions of the Contract l 1 2. Division 1— General Requirements 12 3. Section 31 25 00 — Erosion and Sediment Control 13 1.2 PRICE AND PAYMENT PROCEDURES 14 15 16 17 18 19 A. Measurement and Payment 1. Construction Activities resulting in less than 1 acre of disturbance a. Work associated with this Item is considered subsidiary to the various Ttems bid. No separate payinent will be allowed for this Item. 2. Construction Activities resulting in greater than 1 acre of disturbance a. Measurement and Payment shall be in accordance with Section 31 25 00. 20 1.3 REFERENCES 21 A. Abbreviations and Acronyms 22 1. Notice of Intent: NOI 23 2. Notice of Termination: NOT 24 3. Storm Water Pollution Prevention Plan: SWPPP 25 4. Texas Commission on Enviromnental Quality: TCEQ 26 5. Notice of Chailge: NOC 27 A. Reference Standards 28 1. Reference standards cited in this Specification refer to the current reference 29 standard published at the time of the latest revision date logged at the end of this 30 Specification, unless a date is specifically cited. 31 2. Integrated Storm Management (iSWM) Technical Manual for Construction 32 Controls 33 1.4 AD1VdINISTRAT'IVE REQUIREMENTS 34 A. General 35 1. Contractor is responsible for resolution and payment of any fines issued associated 36 with compliance to Stormwater Pollution Prevention Plan. CITY OF FORT WORTH LA FRONT�RA — PHASE 3 STANDARD CONSTRUCTION SPECIFIC�TION DOCUMCNTS CITY PROJECT NO.: I0281 I Revised July I, 201 I 015'713-2 STORM WATER POLLUTION PREVENTION Page 2 of 3 1 2 3 4 5 6 7 8 9 10 I1 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 B. Construction Activities resulting in: 1. Less than 1 acre of disturbance a. Provide erosion and sediinent control in accordance with Section 31 25 00 and Drawings. 2. 1 to less than 5 acres of disturbance a. Texas Pollutant Discharge Elimination System (TPDES) General Construction Pennit is reqtiired b. Complete SWPPP in accordance with TCEQ requirements 1) TCEQ Small Construction Site Notice Required under general permit TXR150000 a) Sign and post at job site b) Prior to Preconstruction Meeting, send 1 copy to City Department of Transportation and Public Works, Environmental Division, (817) 392- 6088. 2) Provide erosion and sediment control in accordance with: a) Section 31 25 00 b) The Drawings c) TXR150000 General Pennit d) SWPPP e) TCEQ requirements 3. 5 acres or more of Disturbance a. Texas Pollutant Discharge Elimination System (TPDES) General Construction Permit is required b. Complete SWPPP in accordance with TCEQ requirements 1) Prepare a TCEQ NOI form and submit to TCEQ along with required fee a) Sign and post at job site b) Send copy to City Department of Transportation and Public Works, Environmental Division, (817) 392-6088. 2) TCEQ Notice of Change required if making changes ar updates to NOI 3) Provide erosioii and sediment control in accordance with: a) Section 31 25 00 b) The Drawings c) TXR150000 General Permit d) SWPPP e) TCEQ requirements 4) Once the project has been completed and all the closeout requirements of TCEQ have been met a TCEQ Notice of Termination can be submitted. a) Send copy to City Department of Transportation and Public Works, Environmental Division, (817) 392-6088. 40 1.5 SUBMITTALS 41 42 43 44 45 46 47 A. SWPPP 1. Submit in accordance with Section O1 33 00, except as stated herein. a. Prior to the Preconstruction Meeting, submit a draft copy of SWPPP to the City as follows: 1) 1 copy to the City Project Manager a) City Project Manager will forward to the City Department of Transportation and Public Works, Environmental Division for review C1TY OF FORT WORTH LA FRONTERA — PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS C1TY PROJECT NO.: 102811 Revised July 1, 2011 01 57 13 - 3 STORM WATER POLLUTTON PREVENTION Page 3 of 3 i B. Modified SWPPP 2 1. If the SWPPP is revised during construction, resubmit modified SWPPP to the City 3 in accordance with Section O1 33 00. 4 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 5 1.7 CLOSEOUT SUBMITTALS [NOT USED] 6 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 7 1.9 QUALITY ASSURANCE [NOT USED) 8 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] 9 1.11 FIELD [SITE] CONDITIONS [NOT USED] 10 1.12 WARRANTY [NOT USED] 11 PART 2- PRODUCTS [NOT USED] 12 PART 3- EXECUTION [NOT USED] 13 l4 END OF SECTION Revision Log DATE NAME SUMMARY OF CHANGE 15 CITY OF FORT WORTH LA FRONTERA — PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO.: 102811 Revised July 1, 20ll 0t6000-1 PRODUCT REQUIR�MENTS Page 1 of 2 1 2 3 PART1- GENERAL SECTION O1 60 00 PRODUCT REQUIREMENTS 4 1.1 SUMMARY 5 A. Section Includes: 6 l. References for Product Requirements and City Standard Products List 7 B. Deviations from this City of Fort Worth Standard Specification 8 1. None. 9 C. Related Specification Sections include, but are not necessarily limited to: ] 0 1. Division 0— Bidding Requirements, Contract Fonns and Conditions of the Contract 11 2. Division 1— General Requirements 12 1.2 PRICE AND PAYMENT PROCEDURES [NOT USED] 13 1.3 REFERENCES [NOT USED] 14 1.4 ADMINISTRA.TIVE REQUIREMENTS 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 1.5 A. A list of City approved products for use is located on Buzzsaw as follows: 1. Resources\02 - Construction Documents\Standard Products List B. Only products specifically included on City's Standard Product List in these Contract Documents shall be allowed for use on the Project. 1. Any subsequently approved products will only be allowed for use upon specific approval by the City. C. Any specific product requirements in the Contract Documents supersede similar products included on the City's Standard Product List. 1. The City reserves the right to not allow products to be used for certain projects even though the product is listed on the Ciiy's Standard Product List. D. Although a specific product is included on City's Standard Product List, not all products from that manufacturer are approved for use, including but not limited to, that manufacturer's standard product. E. See Section Ol 33 00 for submittal requirements of Product Data included on City's Standard Product List. SUBMITTALS [NOT USED] 31 1.6 ACTION SUBMITTALS/INFORMATIONAI. SUBMITTALS [NOT USED] 32 1.7 CLOSEOUT SUBMITTALS [NOT USED] 33 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 34 1.9 QUALITY ASSURANCE [NOT USED] CITY OP FORT WORTH LA FRONTERA - PHASE 3 STANDARD CONSTRUCT]ON SPGCIFICATION DOCUM�NTS CITY PROJECT NO. 102811 Revised December 20, 2012 oi �o 00 - 2 PRODUCT REQIJIREMENTS Page 2 of 2 1 110 DELiVERY, STORAGE, AND HANDLING [NOT USED] 2 1.11 FIELD [SITE) CONDITIONS [NOT USED] 3 1.12 WAR.RANTY [NOT USED] 4 PART 2- PRODUCTS [NOT USED] 5 PART 3- EXECUTION [NOT USED] 6 END OF SECTION Revision Log DATE NAME SUMMARY OF CHANGE 10/12/12 D. Johnson Modified Location of City's Standard Product List CITY OF FORT WORTH LA FRONTERA - PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO. 10281 I Revised December 20, 2012 016600-I PRODUCT STORAGE AND HANDLING REQUIREMENTS Page 1 of4 1 2 SECTION O1 66 00 PRODUCT STORAGE AND HANDLING REQUIREMENTS 3 PARTl- GENERAL 4 1.1 SUMMARY 5 6 7 8 9 10 11 12 13 14 15 16 A. Section Includes: 1. Scheduling of product delivery 2. Packaging of products for delivery 3. Protection of products against damage from: a. Handling b. Exposure to elements or harsh environments B. Deviations from this City of Fort Worth Stai7dard Specification 1. None. C. Related Specification Sections include, but are not necessarily liinited to: 1. Division 0— Bidding Require�nents, Contract Fonns and Conditions of the Contract 2. Division 1— General Requirements 1.2 PRICE AND PAYMENT PROCEDURES 17 A. Measurement and Payment 18 1. Work associated with this Item is considered subsidiary to the various Items bid. 19 No separate payment will be allowed for this Item. 20 1.3 REFERENCES (NOT USED] 21 1.4 ADMINISTRATIVE REQUIREMENTS [NOT USED] 22 1.5 SUBMITTALS [NOT USED] 23 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 24 25 26 27 28 29 30 31 32 33 1.7 CLOSEOUT SUBMITTALS [NOT USED] 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 1.9 QUALITY ASSURANCE [NOT USED] 1.10 DELIVERY AND HANDLING A. Delivery Requirements 1. Schedule delivery of products or equiprnent as required to allow timely installation and to avoid prolonged storage. 2. Provide appropriate personnel and equipment to receive deliveries. 3. Delivery trucks will not be pennitted to wait extended periods of time on the Site for personnel or equipment to receive the delivery. CITY OP FORT WORTH • LA FRONTERA— PHASE 3 STANDARD CONSTRUCTION SP�CIFICATION DOCUMENTS CITY PROJECT NO.: 102811 Revised July 1, 2011 or6600-z PRODUCT STORAGE AND HANDLING REQUIRGMENTS Page 2 of 4 1 4. Deliver products or equipment in manufacturer's original unbroken cartons or other 2 containers designed and constructed to protect the contents from physical or 3 environmental damage. 4 5. Clearly and fully mark and identify as to manufacturer, item and installation 5 location. 6 6. Provide manufacturer's instructions for storage and handling. 7 B. Handling Requirements 8 1. Handle products or equipment in accordance with these Contract Documents and 9 manufacturer's recommendations and instructions. 10 11 12 13 14 15 16 l7 C. Storage Requirements 1. Store materials in accordance with manufacturer's recommendations and requirements of these Specifications. 2. Make necessary provisions for safe storage of materials and equipment. a. Place loose soil materials and materials to be incorporated into Work to prevent damage to any part of Work or existing facilities and to maintain free access at all times to all parts of Work and to utility service company installations in vicinity of Work. 18 3. 19 20 21 22 4. 23 24 5. 25 26 27 28 29 30 31 32 33 34 35 35 37 38 7 8 9. 10 Keep materials and equipment neatly and compactly stored in locations that will cause aninimum inconvenience to other contractors, public travel, adjoining owners, tenants and occupants. a. Arrange storage to provide easy access for inspection. Restrict storage to areas available on construction site for storage of material and equipment as shown on Drawings, or approved by City's Project Representative. Provide off-site storage and protection when on-site storage is not adequate. a. Provide addresses of and access to off-site storage locations for inspection by City's Project Representative. 6. Do not use lawns, grass plots or other private properiy for storage purposes without written permission of owner or other person in possession or control of premises. Store in manufacturers' unopened containers. Neatly, safely and compactly stack materials delivered and stored along line of Work to avoid inconvenience and damage to property owners and general public a�ld maintain at least 3 feet from fire hydrant. Keep public and private driveways and street crossings open. Repair or replace damaged lawns, sidewalks, streets or other improvements to satisfaction of City's Project Representative. a. Total length which materials may be distributed along route of construction at one time is 1,000 linear feet, unless otherwise approved in writing by City's Project Representative. CITY OF FORT WORTH LA FRONTGRA — PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PRO.iECT NO.: 102811 Revised July I, 201 I 016600-3 PRODUCT STORAGE AND HANDLING REQUIREMENTS Page 3 of 4 1 l.l l FIELD [SITE] CONDITIONS [NOT USED] 2 1.12 WARRANTY [N�T USED] 3 PART 2- PRODUCTS [NOT USED] 4 PART 3 - EXECUTION 5 3.1 INSTALLERS [NOT USED] 6 3.2 EXAMINATION [NOT USED] 7 3.3 PREPARATION [NOT USED] 8 3.4 ERECTION [NOT USED] 9 3.5 REPAIR / RESTORA.TION [NOT USED] l0 3.6 RE-INSTALLATION [NOT USED] 11 3.7 FIELD [ox] SITE QUALITY CONTROL 12 A. Tests and Inspections 13 1. Inspect all products or equipmeilt delivered to the site prior to unloading. 14 B. Non-Conforming Work 15 1. Reject all products or equipment that are damaged, used or in any other way 16 unsatisfactory for use on the project. 17 3.8 SYSTEM STARTUP [NOT USED] 18 3.9 ADJLTSTING [NOT USED] 19 3.10 CLEANING [NOT USED] 20 3.11 CLOSEOUT ACTIVITIES [NOT USED] 21 22 23 24 25 26 27 28 29 30 3.12 PROTECTION A. Protect all products or equipment in accordance with manufacturer's written directions. B. Store products or equipment in location to avoid physical damage to items while in storage. C. Protect equipment from exposure to elements and keep thoroughly dry if required by the manufacturer. 3.13 MAINTENANCE [NOT USED] 3.14 ATTACHMENTS [NOT USED] END OF SECTION CITY OF PORT WORTH LA FRONTERA — PHASE 3 STANDARD CONSTRUCTION SPECIPICATION DOCUMENTS CITY PRO.iECT NO.: ] 02811 Revised July 1, 2011 016600-4 PRODUCT STORAGE AND HANDLING REQUIREMENTS Page 4 of 4 Revision Log DATE NAME SUMMARY OF CHANGE CITY OP FORT WORTH LA FRONTERA — PHASE 3 STANDARD CONSTRUCTION SPECI];ICATION DOCUMENTS CITY PROJECT NO.: 10281 I Revised Ju(y 1, 2011 017123-1 CONSTRUCTION STAKING AND SURVEY Page 1 of4 1 2 3 4 PART 1 - GENERA.L 5 1.1 SUMMARY 6 7 8 9 10 11 12 13 1.2 14 IS 16 17 18 19 20 21 22 23 24 25 1.3 SECTION O1 71 23 CONSTRUCTION STAKING AND SURVEY RET�ISIONS IN BOLD AND ITALdC A. Section Includes: 1. Requirements for construction staking and construction survey B. Deviations from this City of Fort Worth Standard Specification 1. Staking is provided by and paid for by tlae Developer. C. Related Specification Sections include, but are not necessarily limited to: 1. Division 0— Bidding Requirements, Contract Forms and Conditions of the Contract 2. Division 1— General Requirements PRICE AND PAYMENT PROCEDURES A. Measurement and Payment 1. Construction Staking a. Measurement 1) Staking is provided by and paid for by t/ze Developen b. Payinent 1) Staking is provided by and paic� for by the Developer. 2. Construction Survey a. Measurement 1) Staking is provided by and paid for by the Developer. b. Payment 1) Staking is provided by and paid for by the Developer. REFERENCES [NOT USED] 26 1.4 ADMINTSTRATIVE REQUIREMENTS [NOT USED] 27 1.5 SUBMITTALS 28 A. Submittals, if required, shall be in accordance with Section O1 33 00. 29 B. All submittals shall be approved by the City prior to delivery. 30 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS 31 A. Certificates 32 1. Provide certificate certifying that elevations and locations of improvements are in 33 conformance or non-confonnance with requirements of the Contract Documents. 34 a. Certificate must be sealed by a registered professional land surveyor in the 35 State of Texas. 36 B. Field Quality Control Submittals 37 1. Documentatio» verifying accuracy of field engineering work. CI7'Y OF FORT WORTH LA FRONTERA - PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS PROJECT NO.: 10281 I Revised December 20, 2012 01 71 23 - 2 CONSTRUCTION STAKING AND SURVEY Page 2 of 4 1.7 CLOSEOUT SUBMITTALS [NOT USED] 2 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 3 1.9 QUALITY ASSURANCE 4 5 G 7 8 9 10 11 12 13 14 15 16 l7 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 40 41 42 43 44 45 A. Construction Staking I. Staking is provided by and paid for by t/ze Developer. 2. Coordination a. Contact Developer's Project Representative at least 2 weeks in advance for scheduling of Construction Staking. b. It is the Contractor's responsibility to coordinate staking such that construction activities are not delayed or negatively impacted. 3. General a. Contractor is responsible for preserving and maintaining stakes furnished by Developer's Surveyor. b. If in the opinion of the City or Developer, a sufficient number of stakes or markings have been lost, destroyed or disturbed, by Contractor's neglect, such that the contracted Work cannot take place, then the Contractor will be required to pay the Developer's Surveyor for new staking with a 25 percent markup. The cost for staking will be deducted from the payment due to the Contractor for the Project. B. Construction Survey Construction Survey will be performed by the Developer's Surveyor. 2. Coordination a. Contractor to verify that control data established in the design survey remains intact. b. Coordinate with the City/Developer prior to field investigation to determine which horizontal and vertical control data will be required for construction survey. c. It is the Contractor's responsibility to coordinate Construction Survey such that construction activities are not delayed or negatively impacted. d. Notify City/Developer if any control data needs to be restored or replaced due to damage caused during construction operations. 1) Developer's Surveyor shall perform replacements and/or restorations. 3. General a. Construction survey will be perfonned in order to maintain complete and accurate logs of control and survey work as it progresses for Project Records. b. The Contractor will need to ensure coordination is maintained with the City/Developer's Surveyor to perfonn construction survey to obtain construction features, including but not limited to the following: 1) All Utility Lines a) Rim and flowline elevations and coordinates for each manhole or junction structure 2) Water Lines a} Top of pipe elevations and coordinates for waterlii�es at the following locations: (1) Every 250 linear feet CITY OF FORT WORTH LA FRONTERA - PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENI'S PROJECT NO.: 102811 Revised December 20, 2012 017123-3 CONSTRUCTION STAKING AND SURVEY Page 3 of 4 r 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 40 41 42 4� 44 45 46 47 48 c. .�`l. (2) Horizontal and vertical points of inflection, curvature, etc. (All Fittings) (3) Cathodic protection test stations (4) Sampling stations (5) Meter boxes/vaults (All sizes) (6) Fire lines (7) Fire hydrants (8) Gate valves (9) Plugs, stubouts, dead-end lines (10) Air Release valves (Manhole rim and vent pipe) (11) Blow offvalves (Manhole rim and valve lid) (12) Pressure plane valves (13) Cleaning wyes (14) Casing pipe (each end) b) Storm Sewer ( l) Top of pipe elevations and coordinates at the following locations: (a) Every 250 linear feet (b) Horizontal and vertical points of inflection, curvature, etc. c) Sanitary Sewer (1) Top of pipe elevations and coordinates for sanitary sewer lines at the following locations: (a) Every 250 linear feet (b) Horizontal and vertical points of inflection, curvature, etc. (c) Cleanouts Construction suivey will be performed in order to maintain complete and accurate logs of control and survey work associated with meeting or exceeding the line and grade required by these Specifications. The Contractor will need to ensure coordination is inaintained with the City/Developers Surveyor to perform construction survey and to verify control data, including but not limited to the following: 1) Established benchmarks and control points provided for the Contractor's use are accurate 2) Benchmarks were used to furnish and inaintain all reference lines and grades for tunneling 3) Lines and grades were used to establish the location of the pipe 4) Submit to the City copies of field notes used to establish all lines and grades and allow the City to check guidance system setup prior to beginning each tunneling drive. 5) Provide access for the City to verify the guidance system and the line and grade of the carrier pipe on a daily basis. 6) The Contractor remains fully respousible for the accuracy of the work and the correction of it, as required. 7) Monitor line and grade continuously during construction. 8) Record deviation with respect to design liile and grade once at each pipe joint and submit daily records to City. 9) If the installation does not meet the specified tolerances, immediately notify the City and correct the installation in accordaiice with the Contract Documents. 49 110 DELIVERY, STORAGE, AND HANDLING [N�T USED] CITY OF FORT WORTH STANDARD CONSTRUCTION SPECIPICATION DOCUMENTS Revised December 20, 2012 LA C'RON7'ERA - PHASE 3 PROJECT NO.: 102811 01 71 23 - 4 CONSTRUCT[ON STAKING AND SURVEY Page 4 of 4 1 1.11 FIELD [SITE] CONDITIONS [NOT USED] 2 1.12 WARRANTY (NOT USED] 3 PART 2- PRODUCTS �NOT iTSED] 4 PART 3 - EXECUTION 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 3.1 INSTALLERS [11oTTOT USED] 3.2 EXAMINATION [NOT USED] 3.3 PREPARATION [NOT USED] 3.4 APPLICATION 3.5 REPAIR / RESTORATION [NOT USED] 3.6 RE-INSTALLATION [NOT USED] 3.7 FIELD (oR] SITE QUALITY CONTROL A. It is the Contractor's responsibility to maintain all stakes and control data placed by the City in accordance vvith this Specification. B. Do not change or relocate stakes or control data without approval from the City. 3.8 SYSTEM STARTUP [NOT USED] 3.9 ADJUSTING [NOT USED] 3.10 CLEANING [NOT USED] 3.11 CLOSEOUT ACTIVITIES [NOT USED] 3.12 PROTECTION [NOT USED] 3.13 MAINTENANCE [NOT USED] 3.14 ATTACHMENTS [NOT USED] END OF SECTION Revision Log DATE NAME SUMMARY OF CHANGE 8/31/2012 D. Johnson 24 CITY OF FORT WORTH LA FRONTERA - PHASE 3 STANDARD CONSTRUCTION SPECIPICATION DOCUMENTS PRO7ECT NO.: 102811 Revised December 20, 2012 017423-1 CLEANiNG Page ] of 4 1 2 3 PART1- GENERAL 4 1.1 SUMMARY 5 6 7 8 9 10 ll 12 ]3 l4 SECTION O1 74 23 CLEANING A. Section Includes: 1. Intermediate and final cleaning for Work not including special cleaning of closed systeins specified elsewhere B. Deviations from this City of Fort Worth Standard Specification 1. None. C. Related Specification Sections include, but are not necessarily limited to: 1. Division 0— Bidding Requirements, Contract Fonns and Conditions of the Contract 2. Division 1— General Requirements 3. Section 32 92 13 — Hydro-Mulching, Seeding and Sodding 1.2 PRICE AND PAYMENT PROCEDURES 15 A. Measurement and Payment 16 1. Work associated with this Item is considered subsidiary to the various Items bid. 17 No separate payment will be allowed for this Item. 18 1.3 REFERENCES [NOT USED] l9 1.4 ADMINISTRA.TIVE REQUIREMENTS 20 A. Scheduling 21 l. Schedule cleaniiig operations so that dust and other contaminants disturbed by 22 cleaning process will not fall on newly painted surfaces. 23 2. Schedule final cleaning upon completion of Work and immediately prior to final 24 inspection. 25 1.5 SUBMITTALS [NOT USED] 26 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 27 28 29 30 31 32 33 1.7 CLOSEOUT SUBMITTALS [NOT USED] 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 1.9 QUALITY ASSURANCE [NOT USED] 1.10 STORAGE, AND HANDLING A. Storage and Handling Requirements 1. Store cleaning products and cleaning wastes in containers specifically designed for those materials. CITY OF FORT WORTH LA FRONTERA — PHASE 3 STANDARD CONSTRUCTION SP�CIFICATION DOCUMENTS C1TY PROJECT NO.: 102811 Revised July 1, 2011 01 74 23 - 2 CLEANING Page 2 of 4 l 1.11 FIELD [SITE] CONDITIONS [NOT USEDJ 2 1.12 WARRANTY [NOT USED] 3 PART2- PRODUCTS 4 2.1 OWNER-FURNISHED [oR] OWNER-SUPPLIEDPRODUCTS [NOT USED] 5 2.2 MATERIALS 6 7 8 9 10 11 12 A. Cleaning Agents 1. Compatible with surface being cleaned 2. New and uncontaminated 3. For manufactured surfaces a. Material recommended by manufacturer 2.3 ACCESSORIES [NOT USED] 2.4 SOURCE QUALITY CONTROL [NOT USED] 13 PART 3 - EXECUTION 14 3.1 INSTALLERS [NOT USED] 15 3.2 EXAMINATION [NOT USED] 16 3.3 PREPARATION [NOT USED] l7 3.4 APPLICATION (NOT USED] 18 3.5 REPAIR / RESTORATION (NOT USED] 19 3.b RE-INSTALLATION [NOT USED] 20 3.7 FIELD [oR] SITE QUALITY CONTROL [NOT USED] 21 3.8 SYSTEM STARTUP [NOT USED] 22 3.9 ADJUSTING [NOT USED] 23 24 25 26 27 28 29 30 31 32 3.10 CLEANING A. General 1. Prevent accumulation of wastes that create hazardous conditions. 2. Conduct cleaning and disposal operations to comply with laws and safety orders of governing authorities. 3. Do not dispose of volatile wastes such as mineral spirits, oil or paint thinner in storm or sanitary drains or sewers. 4. Dispose of degradable debris at an approved solid waste disposal site. 5. Dispose of nondegradable debris at an approved solid waste disposal site or in an alternate manner approved by City and regulatory agencies. CITY OP FORT WORTH LA FRONTERA — PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO.: ]028ll Revised July 1, 2011 O l 74 23 - 3 CLEANING Page 3 of 4 1 6. Handle materials in a controlled manner with as few handlings as possible. 2 7. Thoroughly clean, sweep, wash and polish all Work and equipment associated with 3 this project. 4 8. Remove all signs of temporary construction and activities incidental to construction 5 of requir•ed pennanent Work. 6 9. If project is not cleaned to the satisfaction of the City, the City reserves the right to 7 have the cleaning completed at the expense of the Contractor. 8 10. Do not burn on-site. 9 10 I1 12 13 14 rs 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 40 41 42 B. Intermediate Cleaning during Construction 1. Keep Work areas clean so as not to hinder health, safety or convenience of personnel in existing facility operations. 2. At maximum weekly intervals, dispose of waste materials, debris and rubbish. 3. Confine construction debris daily in strategically located container(s): a. Cover to prevent blowing by wind b. Store debris away from construction or operational activities c. Haul from site at a minimum of once per week 4. Vacuum clean interior areas when ready to receive finish painting. a. Continue vacuum cleaning on an as-needed basis, until Final Acceptance. 5. Prior to storm events, thoroughly clean site of all loose or unsecured items, which may becoine airborne or transported by flowing water during the storm. C. Interior Final Cleaning 1. Remove grease, mastic, adl�esives, dust, dirt, stains, fingerprints, labels and other foreign materials from sight-exposed surfaces. 2. Wipe all lighting fixture reflectors, lenses, lamps and trims clean. 3. Wash and shine glazing and mirrors. 4. Polish glossy surfaces to a clear shine. 5. Ventilating systems a. Clean permanent flters and replace disposable filters if units were operated during construction. b. Clean ducts, blowers and coils if units were operated without filters during construction. 6. Replace all burned out lamps. 7. Broom clean process area floors. 8. Mop office and control room floors. D. Exterior (Site or Right of Way) Final Cleaning 1. Remove trash and debris containers from site. a. Re-seed areas disturbed by location of trash and debris containers in accordance with Section 32 92 13. 2. Sweep roadway to remove all rocks, pieces of asphalt, concrete or any other object that may hinder or disrupt the flow of traffic along the roadway. 3. Clean any interior areas including, but not limited to, vaults, manholes, structures, junction boxes and inlets. CITY OF PORT WORTH LA FRONTERA— PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO.: 102811 Revised Juty 1, 2011 O1 7423 -4 CLEANING Page 4 of 4 1 4. If no longer required for maintenance of erosion facilities, and upon approval by 2 City, remove erosion control from site. 3 5. Clean signs, lights, signals, etc. 4 3.11 CLOSEOUT AC'I'NITIES [NOT USED] 5 3.12 PROTECTION [NOT USED] 6 3.13 MAINTENANCE [NOT USED] 7 3.14 ATTACHMENTS (NOT USED] 8 9 END OF SECTION Revision Log DATE NAME SUMMARY OF CHANGE 10 CITY OF FORT WORTH LA FRONTERA— PHASE 3 STANDARD CONSTRUCTION SPECIPICATION DOCUMENTS CITY PRdJGCT NO.: 102811 Revised Juty 1, 2011 017719-I CLOSEOUT REQUTREMENTS Page 1 of 3 1 2 3 PART1- GENERAL 4 1.1 SUMMARY SECTION O1 77 19 CLOSEOUT REQUIREMENTS 5 A. Section Includes: 6 1. The procedure for closing out a contract 7 B. Deviations from this City of Fort Worth Standard Specification 8 1. None. 9 C. Related Specification Sections include, but are not necessarily limited to: 10 1. Division 0— Bidding Requirements, Contract Fonns and Conditions of the Covtract 11 2. Division 1— General Requirements l2 1.2 PRICE AND PAYMENT PROCEDURES 13 A. Measurernent and Payment 14 1. Work associated with this Item is considered subsidiary to the various Items bid. 15 No separate payment will be allowed for this Item. 16 1.3 RE�'ERENCES [NOT USED] 17 1.4 ADMINISTRATIVE REQUIREMENTS 18 A. Guarantees, Bonds and Affidavits 19 1. No application for final payment will be accepted until all guarantees, bonds, 20 certificates, licenses and affidavits required for Work or equipment as specified are 21 satisfactorily filed with the City. 22 B. Release of Liens or Claims 23 1. No application for final payment will be accepted until satisfactory evidence of 24 release of liens has been submitted to the City. 25 1.5 SUBMITTALS 26 A. Submit all required documentation to City's Project Representative. CITY OP FORT WORTH LA FRONTERA — PHASE 3 STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS CITY PROJECT NO.: ] 02811 Revised July 1, 2011 01 77 19 - 2 CLOSEOUT REQUtREMENTS Page 2 of 3 1 1.6 INFORMATIONAL SUBMITTALS [NOT USED] 2 1.7 CLOSEOUT SUBMITTALS [NOT USED] 3 PART 2- PRODUCTS [NOT USED] 4 PAl�T 3 - EXECUTION 5 3.1 INSTALLERS [NOT USED] 6 3.2 EXAMINATION [NOT USED] 7 8 3.3 PREPARATION [NOT USED] 3.4 CLOSEOUT PROCEDURE 9 A. Prior to requesting Final Inspection, submit: 10 1. Project Record Documents in accordance with Section O1 78 39 11 2. Operation and Maintenance Data, if required, in accordance with Section O 1 78 23 12 13 14 IS 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 B. Prior to requesting Fit�al Inspection, perfonn final cleaning in accordance with Section O1 74 23. C. FinalInspection 1. After final cleaning, provide notice to the City Project Representative that the Work is completed. a. The City will make an initial Final Inspection with the Contractor present. b. Upon completion of this inspection, the City will notify the Contractor, in writing within 10 business days, of any particulars in which this inspection reveals that the Work is defective or incomplete. 2. Upon receiving written notice from the City, immediately undertake the Work required to remedy deficiencies and complete the Work to the satisfaction of the City. 3. Upon completion of Work associated with the items listed in the City's written notice, infonn the City, that the required Work has been completed. Upon i•eceipt of this notice, the City, in the presence of the Contractor, will make a subsequent Final Inspection of the project. 4. Provide all special accessories required to place each item of equipment i�l full operation. These special accessory items include, but are not limited to: a. Speci�ed spare parts b. Adequate oil and grease as required for the first lubrication of the equipment c. Initial fill up of all chemical tanks and fuel tanks d. Light bulbs e. Fuses f. Vault keys g. Handwheels h. Other expei�dable items as required for initial start-up and operation of all equipment D. Notice of Project Completion CITY OF FORT WORTH LA FRONTERA — PHASE 3 STANDARD CONSTRUCTION SPECIPICATION DOCUMENTS CITY PROJECT NO.: 102811 Revised July l, 2011 01 77 19 - 3 CLOSEOUT REQUIREMENTS Page 3 of 3 1 2 3 4 5 6 7 8 9 10 11 12 13 14 IS 16 17 18 l9 20 21 22 23 24 25 26 27 28 1. Once the City Project Representative finds the Work subsequent to Final Inspection to be satisfactory, the City will issue a Notice of Project Completion (Green Sheet). E. Supporting Documentation 1. Coordinate with the City Project Representative to complete the following additional forins: a. Final Payment Request b. Statement of Contract Time c. Affidavit of Payment and Release of Liens d. Consent of Surety to Final Payment e. Pipe Report (if required) £ Contractor's Evaluation of City g. Performance Evaluation of Contractor F. Letter of Final Acceptance I. Upon review and acceptance of Notice of Project Completion and Supporting Documentation, in accordance with General Conditions, City will issue Letter of Final Acceptance and release the Final Payment Request for payment. 3.5 REPAIR / RESTORATION [NOT USED] 3.6 RE-INSTALLATION [NOT USED] 3.7 FIELD (ox] SITE QUALITY CONTROL [NOT USED] 3.8 SYSTEM STARTUP [NOT USED] 3.9 ADJUSTING [NOT USED] 3.10 CLEANING [NOT USED] 3.11 CLOSEOUT ACTIVITIES [NOT USED] 3.12 PROTECTION [NOT USED] 3.13 MAINTENANCE [NO�' USED] 3.14 ATTACHMENTS [NOT USED] END OF SECTION Revision Log DATE NAME SUMMARY OF CHANGE 29 CITY OF FORT WORTH STANDARD CONSTRUC'I']ON SPECIFICATION DOCUMENTS Revised July I, 2011 LA FRONTERA — PHASE 3 CITY PR0IECT NO.: ] 028] 1 017823-I OPERA7'ION AND MAINTENANCE DATA Page 1 of 5 1 2 3 PART1- GENERAL 4 1.1 SUMMARY 5 6 7 8 9 10 I1 12 13 14 15 16 17 18 1.2 19 20 21 22 23 24 1.3 SECTION O1 78 23 OPERATION AND MAINTENANCE DATA A. Section Includes: 1. Product data and related information appropriate for City's maintenance and operation of products furnished under Contract 2. Such products may include, but are not limited to: a. Traffic Controllers b. Irrigation Controllers (to be operated by the City) c. Butterfly Valves B. Deviations from this City of Fort Worth Standard Specification 1. Modifed 1.2.A.1 2. Added 1.2.A.2 C. Related Specification Sections include, but are not necessarily limited to: 1. Division 0— Bidding Requirements, Contract Forms and Conditions of the Contract 2. Division 1— General Requirements PRICE AND PAYMENT PROCEDURES A. Measurement and Payment 1. Unit Price - Work associated with this Item is considered subsidiary to the various Items bid. No separate payment will be allowed for this Item. 2. Lump Sum Price - Work associated with this Item is included in the total lum.p sum price. REFERENCES [NOT USED] 25 1.4 ADMINISTRATIVE REQUIREMENTS 26 A. Schedule 27 1. Submit manuals in final form to the City within 30 calendar days of product 28 shipment to the project site. 29 1.5 SUBMITTALS 3o A. Submittals shall be in accordance with Section O1 33 00 . All submittals shall be 31 approved by the City prior to delivery. 32 1.6 INFORMATIONAL SUBMITTALS 33 A. Submittal Form 34 1. Prepare data in fonn of an instructional manual for use by City personnel. 35 2. Forma� 36 a. Size: 8'/z inches x 11 inches CITY OF PORT WORTH STANDARD CONSTRUCTION LA FRONTERA — PHASE 3 SPECIFICATION DOCUMENTS — WATER FACILITY PROJECTS CITY PROJECT NO.: 102811 Revised DecemUer 20, 2012 01 78 23 - 2 OPERATION AND MAINTENANC� DATA Page 2 of 5 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 b. Paper 1) 40 pound minimum, white, for typed pages 2) Holes reinforced with plastic, cloth or metal c. Text: Manufacturer's printed data, or neatly typewritten d. Drawixigs 1) Provide reinforced punched binder tab, bind in with text 2) Reduce larger drawings and fold to size of text pages. e. Provide fly-leaf for each separate product, or each piece of operating equipment. 1) Provide typed description of product, and major component parts of equipment. 2) Provide indexed tabs. £ Cover 1) Identify each volume with typed or printed title "OPERATING AND MAINTENANCE INSTRUCTIONS". 2) List: a) Title of Project b) Identity of separate structLire as applicable c) Identity of general subject matter covered in the manual 20 3. Binders 21 a. Commercial quality 3-ring binders with durable and cleanable plastic covers 22 b. When multiple binders are used, correlate the data into related consistent 23 groupings. 24 4. If available, provide an electronic form of the O&M Manual. 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 40 41 42 43 44 45 46 47 48 B. Manual Content 1. Neatly typewritten table of contents for each volume, arranged in systematic order a. Contractor, name of responsible principal, address and telephone number b. A list of each product required to be included, indexed to content of the volume c. List, with each product: 1) The name, address and telephone number of the subcontractor or installer 2) A list of each product required to be included, indexed to content of the volume 3) Identify area of responsibility of each 4) Local source of supply for parts and replacement d. Identify each product by product name and other identifying symbols as set forth in Contract Documents. 2. Product Data a. Include only those sheets which are pertinent to the specific product. b. Annotate each sheet to: 1) Clearly identify specific product or part installed 2) Clearly ideutify data applicable to installation 3) Delete references to inapplicable information 3. Drawings a. Supplement product data with drawings as necessary to clearly illustrate: 1) Relations of component parts of equipment and systems 2) Control and flow diagrams b. Coordinate drawings with information in Project Record Documents to assure correct illusti•ation of completed installation. CITY OF PORT WORTH STANDARD CONSTRUCTION LA PRONTERA — PHASE 3 SPECIFICATION DOCUMENTS — WATER PACILITY PROJECTS CITY PROJECT NO.: 102811 Revised December 20, 2012 01 78 23 - 3 OPERATION AND MAINT�NANCE DATA Page 3 of 5 1 c. Do not use Project Record Drawings as maintenance drawings. 2 4. Written text, as required to supplement product data for the particular installatian: 3 a. Organize in consistent format under separate headings for different procedures. 4 b. Provide logical sequence of instructions of each procedure. 5 6 7 8 9 10 ll 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 40 41 42 43 44 45 46 47 5. Copy of each warranty, bond and service contract issued a. Provide information sheet for City personnel giving: 1) Proper procedures in event of failure 2) Instances which inight affect validity of warranties or bonds C. Manual for Materials and Finishes 1. Submit 5 copies of complete manual in final form. 2. Content, for architectural products, applied materials and finishes: a. Manufacturer's data, giving full information on products 1) Catalog number, size, composition 2) Color and texture designations 3) Information required for reordering special manufactured products b. Instructions for care and maintenance 1) Manufacturer's recommendation for iypes of cleaning agents and methods 2) Cautions against cleaning agents and methods which are detrimental to product 3) Recommended schedule for cleaning and maintenance 3. Content, for moisture protection and weather exposure products: a. Manufacturer's data, giving full information on products 1) Applicable standards 2) Chemical composition 3) Details of installation b. Instructions for inspection, maintenance and repair D. Manual for Equipment and Systems 1. Submit 5 copies of complete manual in final form. 2. Content, for each unit of equipment and system, as appropriate: a. Description of unit and component parts 1) Function, normal operating characteristics and limiting conditions 2) Performance curves, engineering data and tests 3) Complete nomenclature and commercial number of replaceable parts b. Operating procedures 1) Start-up, break-ii1, routine and nonnal operating instructions 2) Regulation, control, stopping, shut-down and emergency instructions 3) Summer and winter operating instructions 4) Special operating instructions c. Maintenance procedures 1) Routine operations 2) Guide to "trouble shooting" 3) Disassembly, repair and reassembly 4) Alignment, adjusting and checking d. Servicing and lubrication schedule 1) List of lubricants required e. Manufacturer's printed operating and maintenance instructions f. Description of sequence of operation by control manufacturer CITY OF FOR7' WORTH STANDARD CONSTRUCTION LA FRONTERA — PHASE 3 SPECIFICATION DOCUMENTS — WATER FACILITY PROJECTS CITY PROJ�CT NO.: I028ll Revised December 20, 2012 017823-4 OPERATION AND MAINTENANCE DATA Page 4 of 5 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 l6 17 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 34 1} Predicted life of parts subject to wear 2) Items recommended to be stocked as spare parts g. As installed control diagrams by controls manufacturer h. Each contractor's coordination drawings 1) As installed color coded piping diagrams i. Charts of valve tag numbers, with location and function of each valve j. List of original manufacturer's spare parts, manufacturer's current prices, and recommended quantities to be maintained in storage k. Other data as required under pertiilent Sections of Specifications 3. Content, for each electric and electronic system, as appropriate: a. Description of system and component parts 1) Function, nonnal operating characteristics, and limiting conditions 2) Performance curves, engineering data and tests 3) Complete nomenclature and commercial number of replaceable parts b. Circuit directories of panelboards 1) Electrical service 2) Controls 3) Communications c. As installed color coded wiring diagrams d. Operating procedures 1) Routine and normal operating instructions 2) Sequences required 3) Special operating instructions e. Maintenance procedures 1) Routine operations 2) Guide to "trouble shooting" 3) Disassembly, repair and reassembly 4) Adjustment and checking £ Manufacturer's printed operating and maintenance instructions g. List of original manufacturer's spare parts, manufacturer's current prices, and recommended quantities to be maintained in storage h. Other data as required under pertinent Sections of Specifications 4. Prepare and include additional data when the need for such data becomes apparent during instruction of City's personnel. 35 1.7 CLOSEOUT SUBMITTALS [NOT USED] 36 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 37 1.9 QUALITY ASSURANCE 38 A. Provide operation and inaintenance data by personnel with the following criteria: 39 1. Trained and experienced in maintenance and operation of described products 40 2. Skilled as technical writer to the extent required to communicate essential data 41 3. Skilled as draftsman competent to prepare required drawings CITY OF FORT WORTH STANDARD CONSTRUCTION LA FRONTERA - PI-IASE 3 SPECIFICATION DOCUMENTS - WATER FACILITY PROJECI'S CITY PROJECT NO.: 102811 Revised December 20, 2012 01 78 23 - 5 OPERATION AND MA[NTENANCE DATA Page 5 of 5 1 1.10 DELIVER�', STORAGE, AND HANDLING [NOT USED] 2 1.11 FIELD [SITE] CONDITIONS [NOT USED] 3 1.12 WARRANTY [NOT USED] 4 PART 2- PRODUCTS (NOT USED] 5 PART 3- EXECUTION [NOT USED) 6 END OF SECTION Revision Log DATE NAME SUMMARY OF CHANGE 8/31/2012 D. Johnson 1.S.A.1 —title of section removed CITY OP FORT WORTH STANDARD CONSTRUCTION LA PRONTERA - PHASG 3 SPECIFICATION DOCUM�NTS - WATER FACILITY PROJECTS C[TY PROJECI' NO.: 102811 Revised December 20, 2012 01 78 39 - i PROJECT RECORD DOCUMENTS Page 1 of 4 1 2 3 PART1- GENERAL n 5 6 7 8 9 10 I1 12 13 14 IS 16 17 f��Y11►��%I��i'� SECTION O1 78 39 PROJECT RECORD DOCUMENTS A. Section Includes: 1. Work associated with the documenting the project and recording changes to project documents, including: a. Record Drawings b. Water Meter Service Reports c. Sanitary Sewer Service Reports d. Large Water Meter Reports B. Deviations from this City of Fort Worth Standard Specification 1. None. C. Related Specification Sections include, but axe not necessarily limited to: 1. Division 0— Bidding Requirements, Contract Forms and Conditions of the Contract 2. Division 1— General Requirernents 1.2 PRICE AND PAYMENT PROCEDURES 18 A. Measurement and Payment 19 1. Work associated with this Item is considered subsidiary to the various Items bid. 20 No separate payment will be allowed for this Item. 21 1.3 REFERENCES [NOT USED] 22 23 1.4 ADMINISTRATNE REQUIREMENTS [NOT USED] 1.5 SUBMITTALS 24 A. Prior to submitting a request for Final Inspection, deliver Project Record Documents to 25 City's Project Representative. 26 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 27 28 � 30 31 32 33 34 35 36 1.7 CLOSEOUT SUBMITTALS [NOT USED] 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 1.9 QUALITY ASSURANCE A. Accuracy of Records 1. Thoroughly coordinate changes within the Record Docuinents, making adequate and proper entries on each page of Specifications a��d each sheet of Drawings and other pocuments where such entry is required to show the change properly. 2. Accuracy of records shall be such that future search for items shown in the Contract Documents may rely reasonably on infonnation obtained from the approved Project Record Documents. CITY OF FORT WORTH LA PRONTERA — PHASE 3 STANDARD CONSTRtJCTION SPECIFICATION DOCUMENTS CITY PRO.iGCT NO.: 102811 Revised July 1, 20ll 01 78 39 - 2 PROJEC7' RECORD DOCUMENTS Page 2 of 4 1 2 3 4 5 � 7 8 9 10 I1 12 13 14 15 � 3. To facilitate accuracy of records, make entries within 24 hours after receipt of information that the change has occurred. 4. Provide factual information regarding all aspects of the Work, both concealed and visible, to enable future modification of the Work to proceed without lengthy and expensive site measurement, investigation and examination. 1.10 STORAGE AND HANDLING A. Storage and Handling Requirements 1. Maintain the job set of Record Documents completely protected from deterioi•ation aild from loss and damage until completion of the Work and transfer of all recorded data to the final Project Record Documents. 2. In the event of loss of recorded data, use means necessary to again secure the data to the City's approval. a. In such case, provide replacements to the standards originally required by the Contract Documents. 1.11 FIELD [SITE] CONDITIONS [NOT USED] 1.12 WARRANTY [NOT USED] 17 PART 2 - PRODUCTS 18 19 20 21 22 23 24 25 26 27 2.1 OWNER-FURNISHED [oR] OWNER-SUPPLIED PRODUCTS [NOT USED] 2.2 RECORD DOCUMENTS A. Job set 1. Promptly following receipt of the Notice to Proceed, secure from the City, at no charge to the Contractor, 1 complete set of all Documents comprising the Contract. B. Final Record Documents 1. At a time nearing the completion of the Work and prior to Final Inspection, provide the City 1 complete set of all Final Record Drawings in the Contract. 2.3 ACCESSORIES [NOT USED] 2.4 SOURCE QUALITY CONTROL [NOT USED] 28 PART 3 - EXECUTION 29 3.1 INSTALLERS [NOT USED] 30 31 32 33 34 35 3.2 EXAlVIINATION [NOT USED] 3.3 PR.EPARATION [NOT USED] 3.4 MAINTENANCE DOCUMENTS A. Maintenance of Job Set 1. Immediately upon receipt of the job set, identify each of the Documents with the title, "RECORD DOCUMENTS - JOB SET". CITY OP PORT WORTH LA FRONTERA— PHASE 3 S7'ANDARD CONSTRUCTION SPECIPICATION DOCUMCNTS CITY PROJECT NO.: 102811 Revised July 1, 2011 017839-3 PROJECT RECORD DOCUMENTS Page 3 of 4 1 2. Preservation 2 a. Considering the Contract completion time, the probable number of occasions 3 upon which the job set must be taken out for new entries and for examination, 4 and the conditions under which these activities will be perfonned, devise a 5 suitable method for protecting the job set. 6 b. Do not use the job set for any purpose except entry of new data and for review 7 by the City, until start of transfer of data to final Project Record Documents. 8 c. Maintain the job set at the site of work. 9 3. Coordination with Construction Survey 10 a. At a minimum, in accordance with the intervals set forth in Section O1 71 23, 11 clearly mark any deviations from Contract Documents associated with 12 installation of the infrastructure. 13 14 15 16 17 18 19 20 4. Making entries on Drawings a. Record any deviations from Contract Documents. b. Use an erasable colored pencil (not ink or indelible pencil), clearly describe the change by graphic line and note as required. c. Date all entries. d. Call attention to the entry by a"cloud" drawn around the area or areas affected. e. In the event of overlapping changes, use different colors for the overlappiilg changes. 21 5. Conversion of schematic layouts 22 a. In some cases on the Drawings, arrangements of conduits, circuits, piping, 23 ducts, and similar items, are shown schematically and are not intended to 24 portray precise physical layout. 25 I) Final physical arrangement is determined by the Contractor, subject to the 26 City's approval. 27 2) However, design of future modifications of the facility may require 28 accurate infonnation as to the final physical layout of items which are 29 shown only schematically on the Drawings. 30 b. Show on the job set of Record Drawings, by dimension accurate to within 1 31 inch, the centerline of each run of items. 32 1) Final physical arrangement is determined by the Contractor, subject to the 33 City's approval. 34 2) Show, by symbol or note, the vertical location of the Item ("under slab", "in 35 ceiling plenum", "exposed", and the like). 36 3) Make all identification sufficiently descriptive that it rnay be related 3� reliably to the Specifications. 38 c. The City may waive the requirements for conversion of schematic layouts 39 where, in the City's judgment, conversion serves no useful purpose. However, 40 do not rely upon waivers being issued except as specifically issued in writing 41 by the City. 42 B. Final Project Record Documents 43 1. Transfer of data to Drawings 44 a. Carefully transfer change data shown on the job set of Recoz-d Drawings to the 45 corresponding final docurnents, coordinating the changes as required. 46 b. Clearly indicate at each affected detail and other Drawing a full description of 47 changes made during construction, and the actual location of items. CITY OF FORT WORTH LA FRONT�IZA — PHASG 3 STANDARD CONSTRUCTION SPECIPICATION DOCUMENTS CITY PROJCCT NO.: 102811 Revised July l, 201 I 01 78 39 - 4 PROJECT RECORD DOCUMENTS Page 4 of 4 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 l9 20 2l 22 23 24 25 c. Call attention to each entry by drawing a"cloud" around the area or areas affected. d. Make changes neatly, consistently and with the proper media to assure longevity and clear reproduction. 2. Transfer of data to other pocuments a. If the Documents, other than Drawings, Ilave been kept clean during progress of the Work, and if entries thereon have been orderly to the approval of the City, the job set of those Documents, other than Drawings, will be accepted as final Record Documents. b. If any such Document is not so approved by the City, secure a new copy of that Document from the City at the City's usual charge for reproduction and handling, and carefully transfer the change data to the new copy to the approval of the City. 3.5 REPAIR / RESTORATION [NOT USED] 3.6 RE-INSTALLATION (NOT USED] 3.7 FIELD [oR] SITE QUALITY CONTROL [NOT USED] 3.8 SYSTEM STARTUP [NC)T USED] 3.9 ADJUSTING [NOT USED] 3.10 CLEANING [NOT USED] 3.11 CLOSEOUT ACTIVITIES [NOT USED] 3.12 PROTECTION [NOT USED] 3.13 MAINTENANCE [NOT USED] 3.14 ATTACHMENTS [NOT USED] END OF SECTION Revision Log DATE NAME SUMMARY OF CHANGE 26 CITY OF FORT WORTH STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS Revised July I, 2011 LA PRONTERA — PHASE 3 CITY PROJECT NO.: 102811 F RT W RT 0 � H� CITY OF FORT WORTH WATER DEPARTMENT STANDARD PRODUCT LIST Updated: December 6, 2018 The Fort Worth Water Department's Standaxd Products List has been developed to minimize the submittal review of products which meet the Fort Worth Water Deparhnent's Standard Specificatians during utility construction projects. When Technical Specificaiions for specific products, are included as part of the Construction Contract Documents, the requirements of the Technical Specification will override the Fort Worth Waier Department's Standard Specificatians and the Fort Worth Water Department's Standard Products List and approval of the specific products will be based on the requiremenis of the Technical Specification whether or not the specific product meets ihe Fort Worth Water Department's Standard Specifications or is on the Fort Worth Water Department's Standard Products List. Tabie vf Content (Click on items to go directly to the page) Items Page A. Water & Sewer l. Manholes & Bases/Components ........................................................... 1 2. Manholes & Bases/Fiberglass ...............................................................2 3. Manholes & Bases/Frames & Covers/Rectangular ............................... 3 4. Manhoies & Bases/Frames & CoverslRound ....................................... 4 5. Manholes & Bases/Frames & Covers/Water Tight & P��essure Tight .. 5 6. Manholes & Bases/Precast Concrete .................................................... 6 7. Manholes & Bases/Rehab Systems/Cementitious ................................ 7 8. Manholes & Bases/Rehab Systems/NonCementitious ......................... 8 9. Manl�ole Insert (Field Operations Use Only) ........................................ 9 l0. Pipe Casing Spacer ...................... 11. Pipes/Ductile Iron ........................ 12. Utility Line Marker ...................... ............................................... 10 ................................................ I 1 ................................................ 12 B. Sewer 13. Coatings/Epoxy ..................................................................................... 13 l4. Coatings/Polyurethane .......................................................................... 14 I5. Combination Air Valves ....................................................................... 15 16. Pi�es/Concrete ...................................................................................... 16 17. Pipe Enlargement Syste�n (Method) ..................................................... 17 18. Pipes/Piberglass Reinforced Pipe ......................................................... 18 19. Pipes/HDPC .......................................................................................... 19 20. Pipes/PVC (Pressure Sewer} ................................................................. 24 21. Pipes/PVC* ........................................................................................... 2t 22. Pipes/Rehab/CIPP .................................................................................22 23. Pipes/Rehab/Pold & Form .................................................................... 23 24. Pipes/Open Profile Large Diameter ...................................................... 24 G Water 25. Appurtenances ....................................................................................... 25 26. Bolts, Nuts, and Gaskets ....................................................................... 26 27. Combination Air Release Valve ........................................................... 27 28. Dry Barrel Fire Hydrants ...................................................................... 28 29. Meters ................................................................................................... 29 30. Pipes/PVC (Pressure Water) ................................................................. 30 31. Pipes/Valves & Fittings/Ductile Iron Fittings ....................................... 31 32. Pipes/Valves & Fittings/Resilient Seated Gate Valve .......................... 32 33. Pipes/Valves & Fittings/Rubber Seated Sutterfly Valve ...................... 33 34. Polyethylene Encasement ..................................................................... 34 35. SampIing Stations ................................................................................. 35 � ., 0 N b O N 'O d R � G. � H w � a a w A W �"� � x a 0 3 a 0 w � 0 � U l� � � � H � 0 a a � A � F� � V x H x � H x w M i a� a• _ 0 � 0 � .� � d s 0 � � 3 N K ° Y u J � � 0 a .� � � � � � m 0 0 : V d � 'b a � H z w � a a W A W d � x H x 0 3 a O w G4 O � �I V H � � a H � 0 a a � z F � r �l'i W ��/ 1�1 � ��/ li� 1�1 c m � � 0 a � � d � Y ° E � a � 0 Y V J � 0 a` � `m v c � � 'eo O E 0 � . '+� d � 'O t4 r�7 F z � a d W A W F � x Ey a 3 E� a � w O � V �"� � � r� v A O�/ w a � A d F-� � a x F�/ liy � � � F�1 r C N C v° 0 � � � a � M 0 � � d � � Y u u � � 0 a v � v c � m c .m O E 0 � d � b a 5 F z w � a � a w A W � � x H a 3 H x 0 w 0 E-� � V E"� � � a H U A 0 a a � A � F� � � x H a � F a c� � d � 0 V w 0 a .� � d L 0 _ � 3 N � � 0 a -� � � _ � � � .� 0 � LY M � d � b � � F z w � a a W A W F � x H a 3 a �r'� 1� w 0 � � V F � � a H � 0 � Qi � Q A � Fy � , � E� � � ��/ W 1�1 � r c u° 0 � .� � d s r M � 3 � 0 v � 0 a` a `m a c � m 'ao O E 0 . TJ d � 'ti LL .'7 H z w � � QI W A W F� 3 x H a � � O w w O � � V � � � a F r`� 0�/ W a � � A � F � !i x H x � F C�G L� C N _ s w 0 m .Q F� N t M 0 � 3 d � « Y u J � 0 d � � � � � � m 0 LL . b d � � a � N z w � a � a w a W F� 3 x H x 0 3 H � 0 w � � H �I V E� � � a H U a O a a � d A � F�+ � x` lN ' ^ � � � ^ � d _ � a d .� � d s 0 � 3 W � 0 M Y u V J O 1 � N V C � N m �C C 0 LL � � � � a � H z w � a a w A W � � x H x O 3 a 0 w w O � U E� � a Ey U � 0 x a � A � F � c� x H a � F a Gi.� c � � 0 u w 0 � .� � � t 0 _ i 3 � 0 Y V � .� a` -o `m v c � � o` E lL A � � 0 N b O N � W R � a � F W � a a w A W � 3 x � � 3 a O w c�, O F � V E"� � � a F"� � 0 a d, � A d Ey � , x E� a � H x w � _ � � c U O O1 � � � � 0 .. � � 3 d � O M Y u � � 0 a � � � � � � � .m 0 � �° . � .. 0 N � O N � 9 d � b GY .7 H z w � � a w A W H 3 x F a 3 a 0I-� I� � 0 � H I� U � � � a H � 0 a a � � A � � 0 x H x � � � 1� C N � u° 0 � .� � a s 0 Y _ 3 a � « Y v � 0 � � a c � � m O 0 . �o � R � � � Ey Hza O W U 3 � A Fi � � W f�r A p O W Q � � A U � � � a x � a � H x w .. � d � u° 0 �, .� � a, r .. � c � � � 0 Y u 'b d � R7 GL � H z w � � a w A W F � 3 x F x 3 a 0 �I � �'+ F � U �r^ vI a H � 0 x a � A d H � � � � � � � � 1� Y C � i u° 0 � � � � � r 0 � 3 � 0 Y Y V J U J 'O O 1 V N 9 C m m c .m O E : . � 0 N � O N � N R � a � F � a W F �aA � w a�", A � wa O W F�z V � F � � x H�/ lil � LN ' /� 1� Y � d � 0 v 0 � � � d t Y � E 3 N � 0 Y V � � 0 a 0 m` V c m � C .� � E 0 � � d R b a � F z W � a � a w A W F� 3 x H � 3 E� � 0 w O H 1�1 U H � � a H U A O a a � A � � n x H a � H x c� c « c u° 0 d � � � d s 0 � « �, � 0 .. Y v J � 0 � � � � � m 0 0 R � � 0 N b O N 9 W � 'fl 0. a H z w � a a w A W d � x H x 0 3 a O w w O F� 1�1 U Fy � � a H � 0 � a � A � F� � ,, x H a � H a w c � _ 0 � 0 � � � �, s .. ° � � � � 0 Y Y v � � 0 d � � � � � � m 0 0 lL k �o d � � � � F W � � d a W A F d � x � 0 3 F-+ a O �I O F 1�1 V F � � a F� U A O a w d A � F� � l`ti x � � � C�"/'' W 1� .. � d M � u° 0 a, � � a � 0 � 3 d � 0 � Y U J � 3 O a � m v c A m c .m O E LL « � 0 N b O N � 'O u R 'ti G � H z w � a a w A F d� 3 x H x 3 a 0 w w O E� � U � � � a H � 0 a a � A z H � � � E-� � � L��/ ii� 1� C N _ s w 0 a .� � a t 0 � 5 � � 0 Y � � 0 a` a �o � c � m c 'eo O E LL . � d R � C ."� H w � a a w A W H � x a O 3 F � w w O F� 1�1 U � � a E-� � � a � A d H � � x E-+ � � l��/ Fil 1�1 C N � u° w 0 d a � a, _ 0 � 3 d � ° Y v � a a` �o �o v c � m c .� O LL ■ � d � � a a H W � � �r w A W F � x � 3 � 0 w � O � � U H � � a Ey � 0 a a a d A � E� � � x F a � l� ^1 � .. c m « _ u° 0 � a H ai s 0 .. � 3 � 0 � Y v � � 0 a � � a c m A �e0 � O f � d � � a 0 H z W � a � a w A W F � � x H � 3 F� � 0 w O � F � U F � � a H U A O a a � d A d H � r�+ E-� � � � �1 ^ _ v _ 0 U O a .� � d s 0 � 3 d � � � 0 a` -o m v c � m �00 0 LL 'CJ d ++ R 'a c. a H z w � � �4 W A WL l "' 3 � H a � � O w O H 1�1 U H � � a F � 0 a i�[ � A � F� � � x H a � L��/ W F� c m c v° w 0 a .n F v L a+ 0 � � 3 �+ W � � Y u � 0 d � a m � m c .m O E 0 s � d � � a � F w � a a W A W � 3 x a O 3 a O w w � H � V E� � � � E-� � 0 a a � A � � e� x F x �r� ` a F�1 � d � u° w 0 d � � �, _ 0 � 3 N � u v J � � 0 d -� � � C N N C .� o` E 0 . � .. 0 N b O N N b � K 'b a � H z w � z a W A W F-� 3 x H x 3 H O w w O � H � V H � � a h � 0 a a d z E � � H i� � � a w .. c � � 0 v w 0 d .� � �, s 0 � � v � r Y u � ti a v n v c � C .m 0 0 � 0 N b O N � 'd W K 'd a � F z w � a a w A W F � x H x 3 H O w w O � U H � a H � 0 a � A Q E� � ,� x � a � � a w c m c � 0 � � � d s 0 � � d � 0 v u 7 O a` v `m v c � m m 0 E 0 LL f � v � b a � H z � a d a W A H d� 3 x H 0 3 � x O w O F � V H � � a U A 0 a a � A d E� � a � H i� � Mil 1� � c � _ s 0 d � � d t 0 � � � � � 0 « v u � a a` v v c � m m O E 0 � . �o d � b � a H w � a a W A W � 3 x a 3 Ey Or'� ^ � O E� � V � � � h� H U A � p, � A d E� � , x E�-/y Fil � ��/ W �1 M C G1 a.� _ V 0 a .� � v _ 0 Y � 3 d � M Y v � � � 0 a v `m � c m m c .m O E 0 � 0 N b O N � 7 d R � G � H z w � F d� a w A H � x H x 3 a w w O � U F � a E-� � � x a � A � Fy � J x � o� � F x w � c � � 0 u w 0 d .o � � s 0 � � a � 0 Y v � .� a � � � � � � .m 0 E W M � d � � � � H w � a a w A W F � x a O 3 z 0 w w O � U E� � � a E� � 0 x a � A d H � , � E-� 04 � ��/ W 1� .. � � _ u° w 0 � � � � s 0 _ � a � ° u � � � a` v m v c � c .m O 0 LL � d � � a � x H � 3 a O w O � F � U H z W � F � a w A W F d� � F � � a Ey � O a a � � A d F� � x E-+ 04 � �_['�I ^ � � �, _ u° 0 d � � �, r a � � 3 N � 0 Y v � � 0 a` v m v C N � m 0 LL � d R 9 G � H w � � a W a W F � x a 3 a 0 w 0 F � U F � � a H � O a � � A d E� � � F�/ li� � � � � v � � s N i d Y � � fC '� � U G Lr1 N G � <V N N i4 N r 1 N V V � a � K �.". � � U c .c ¢ v o 0 0 0 3 00 0 0 0 0 � :: .= �c 3^ V V V V P�� I � v� � r I Q� < Q Q < =�l � `�^�e g� 3 3 3 3��,s¢��;s Qa < a ¢ ¢��.�:�F�. : 3 3 ¢ a c _ a oo v_ = •+ "2 � �2 Q Q� c� a m a m Q � C 3 q � N m m C �= u, w [i1 .i1 o ; s s �� 9 � � E o o r. a a v v v ;�;,�� ; = �= ° � � �� c4 `L ` a a ' C °' ' � ? � > 'c. °� � � � .� � 'o" 'o � � : � : : � a � " n c. 'c. ii. 'a a a n. c- u w �± � 7 > > > 3 � � v u � a a a a` a` a c`. U U V U U > > > > > :� i a o. n. a w a c. N N N N N ^I r! � — ': � � � n' .. . . � �n i� A � w o0 00 0o z Oo N N N N rl C � P P N N � � � M M N Vl - ^ Y � d _ 0 � 0 d a H �, t 0 C � � � 0 Y � � � � 0 a � m v c � A m � L # �o � � b a 5 H z w � a � a W A W � 3 x � a 0 3 H x O �I O � U H � � a H U A 0 a a � A � F � �� x H a � H a w a, � � � r 0 _ 3 N � v J � 0 � � � � � � m 0 ° 7 d � 9 G � H z W � a � a. w A W F � x H � 3 Fy � O w � � U � � � a E� U A O a a � A � H � x E-y � � C�""/ li� 1�1 G N _ u° 0 d � � � d r 0 � � 0 w � « Y u � 0 c`. v m v c � m m O E 0 tl � � 0 N � O N 'O d R � G r7 H z w � � � W A W F� 3 x H x 3 � � W O F H V � � � a F � 0 � a � A � E� � L � �/�/ 1i1 �r - • � � C N _ s 0 d a 1� d s r E � a � 0 Y U J V 7 O a` a m � C N N m 0 � IL ! � d R � o. � H z W � a a W A W F� � � x H x O 3 a � � w O � F � U H � � a F � 0 a � � d A d F � � x H a � L�^/ I�1 1�1 e w � 0 U w 0 �, � � d L �+ O C � d � 0 � u � 0 6 'O `m v c � A c .m � E 0 « H w � a d a W A W F � x H � � H � O w O H hN V Ey � � a E� U A O � Q, � A � � , � E� a � L^ � F� c ai _ u° 0 a � � d � 0 _ � � 0 U � � a v ry v c � m c .m o` 0 LL 4