The URL can be used to link to this page

Home My WebLink AboutOrdinance 26313-06-2023ORDINANCE NO. 26313-06-2023 AN ORDINANCE INCREASING ESTIMATED RECEIPTS AND APPROPRIATIONS IN THE GENERAL CAPITAL PROJECTS FUND, IN THE AMOUNT OF $4,000,000.00, FROM AVAILABLE FUNDS, FOR THE PURPOSE OF FUNDING THE FIRE STATION 43 PROJECT (CITY PROJECT NO. CO2501); PROVIDING FOR A SEVERABILITY CLAUSE; MAKING THIS ORDINANCE CUMULATIVE OF PRIOR ORDINANCES; REPEALING ALL ORDINANCES IN CONFLICT HEREWITH; AND PROVIDING AN EFFECTIVE DATE. BE IT ORDAINED BY THE CITY COUNCIL OF THE CITY OF FORT WORTH, TEXAS: SECTION 1. That in addition to those amounts allocated to the various City departments for Fiscal Year 2022-2023 in the Budget of the City Manager, there shall also be increased estimated receipts and appropriations in the General Capital Projects Fund in the amount of $4,000,000.00, from available funds, for the purpose of funding the Fire Station 43 project (City Project No. CO2501). SECTION 2. That should any portion, section or part of a section of this ordinance be declared invalid, inoperative or void for any reason by a court of competent jurisdiction, such decision, opinion or judgment shall in no way impair the remaining portions, sections, or parts of sections of this ordinance, which said remaining provisions shall be and remain in full force and effect. SECTION 3. That this ordinance shall be cumulative of Ordinance 25773-09-2022 and all other ordinances and appropriations amending the same except in those instances where the provisions of this ordinance are in direct conflict with such other ordinances and appropriations, in which instance said conflicting provisions of said prior ordinances and appropriations are hereby expressly repealed. SECTION 4. This ordinance shall take effect upon adoption. APPROVED AS TO FORM AND LEGALITY: CITY SECRETARY Assistant City Attorney ADOPTED AND EFFECTIVE: June 27, 2023 Jannette S. Goodall City Secretary A MAYOR AND COUNCIL COMMUNICATION MAP 21Fire Station 43 Construction Contract ,a aid W..Ih.il.rd Rd NORTH +.rr, 4'�+ Rd (Rd W.. Wf d Rd Old Rd 44UU VVdlbF] KdF➢Ul rKwy ,=s Fort Worth, TX 76008 i ■ -i eaddl. Rd leek' 0.6 mi % I -. pd�4iA kd+pi Council District 3 FORTWORTH.-� - t lit rt� ` +...c IT! ...�. t � Copyright 2023 City of Fort Worth. Unauthorized reproduction is a violation of applicable laws. This product is for informational purposes and may not have been prepared for or be suitable for legal, engineering, or surveying purposes. It does not represent an on -the -ground survey and represents only the approximate relative location of property boundaries. The City of Fort Worth takes no responsibility for the accuracy of said data. City of Fort Worth, Texas Mayor and Council Communication DATE: 06/27/23 M&C FILE NUMBER: M&C 23-0567 LOG NAME: 21 FIRE STATION 43 CONSTRUCTION CONTRACT SUBJECT (CD 3) Authorize Execution of a Construction Contract with RJM Contractors, Inc, in an Amount Not to Exceed $9,134,687.00, Including the Owner's Construction Allowance, for the Construction of a New Fire Station 43 for a Total Anticipated Project Cost of $10,817,345.00 (2014 Bond Program); and Adopt Appropriation Ordinances in the Amount of $4,000,000.00 for Additional Funding for the Fire Station 43 Project; and Amend the Fiscal Years 2023-2027 Capital Improvement Program RECOMMENDATION: It is recommended that the City Council: 1. Authorize the execution of a construction contract with RJM Contractors, Inc., in an amount not to exceed $9,134,687.00, including the owner's construction allowance, for the new Fire Station 43 for a total anticipated project cost of $10,817,345.00; 2. Adopt the attached appropriation ordinance increasing estimated receipts and appropriations in the General Fund in an amount not to exceed $4,000,000.00, from available fund balance, for the purpose of transferring to the General Capital Projects Fund for the Fire Station 43 project (City Project No. CO2501); and 3. Adopt the attached appropriation ordinance increasing estimated receipts and appropriations in the General Capital Projects Fund in an amount not to exceed $4,000,000.00, transferred from the General Fund, for the purpose of funding Fire Station 43 project (City Project No. CO2501). 4. Amend the Fiscal Year 2023 Adopted Budget and the Fiscal Years 2023-2027 Capital Improvement Program DISCUSSION: The purpose of this Mayor and Council Communication (M&C) is to authorize the execution of a construction contract with RJM Contractors, Inc in the amount not to exceed $9,134,687.00 including the owner's construction allowance, for the new Fire Station 43. The 2014 Bond Program allocated $4,700,000.00 for the design and construction of the new Fire Station 43. The start of this project was delayed allowing development of the area to progress. A site was selected and purchased (M&C L-16171), Dec 11, 2018, however unforeseen water utility issues made the initial site unusable for a fire station. A temporary fire station was established at Cook Children's Pediatrics Walsh Ranch, 13340 Highland Hills Drive (M&C 21-0759), Dec 11, 2018. The City's one-story, prototype design was adapted for a site on Walsh Ranch Parkway, north of Interstate Highway 30. As part of obtaining the land, certain improvements to Walsh Ranch Parkway were included in the project (M&C 22-0978), Nov 29, 2022. The design portion of the project was authorized with Mayor and Council Communication (M&C C-28651), April 3, 2018. Construction documents were completed and submitted for advertisement in the Fort Worth Star -Telegram on April 12, and April 20, 2023. The City of Fort Worth received four bids from general contractors on May 11, 2023. The four firms were: • Azteca Enterprises, LLC • Batson -Cook Company • RJM Contractors, Inc. • Modern Contractors, Inc. Three of the four firms provided the required "Post Proposal -Pre Award Submittals" to be further evaluated by the City and the Design Architect. A selection team composed of members of the Fire Department, Property Management Department, RPGA Design Group, and the Diversity & Inclusion Department, reviewed the proposals and evaluated them for the best value based on the criteria set forth in the Request for Proposal. Based on this evaluation, the selection team recommends award of the construction contract to RJM Contractors, Inc. SCORING MATRIX TABLE: RJM Azteca 'Contractor Contractors Modern I I Enterprises, Evaluation Inc. Contractors, Incl I LLC Proposed FeesJ JProposed Schedule 60 8 50 IL 9....__�J 40 References & ..................._ i Experience 17 17 1 10 Work in the � C lPast CityL j , jl L MWBE Office Review ---- Responsive _ _ [Responsive Responsive TOTALS �.. I 94 83 _ L 63 The overall project costs are expected to be as described in the table below: PROJECT BUDGET I TOTAL Land $376,782.00i Architectural & Engineering Contract $603,980.00 Construction Contract, including Owner's Construction Allowance $9 134,687.00 Project Administration Cost: Project Management, Bid Advertisement, IT, Security, Materials Testing, $701,896.00 I Contingency, FFE, etc. I i PROJECT TOTAL $10,817,345.00� Schedule - The design portion of this project will start in the summer of 2024 and construction is anticipated to be completed in the fall of 2024. Waiver of Building Permits - In accordance with the City Code of Ordinances, Part II, Chapter 7-1 Fort Worth Building Administrative Code, Section 109.2.1, Exception 2; "Work by non -City personnel on property under the control of the City of Fort Worth shall be exempt from the permit fees only if the work is for action under a contract that will be or has been approved by City Council with notes in the contract packages stating the fee is waived." Funding - Funding is available for appropriation in the fund balance of the General Fund for the purpose of funding the Fire Station 43 project within the General Capital Projects Fund. As a part of the Fiscal Year 2022 year-end process, funding for capital shortfalls was identified and available fund balance from the General Fund was assigned to close this funding gap. (M&C 23-0095) Diversity and Inclusion Business Equity Office - RJM Contractors, Inc. is in compliance with the City's Business Equity Ordinance by committing to 24% MWBE participation on this project. The City's MWBE goal on this project is 17%. The new Fire Station 43 is to be located in Council District 3. FISCAL INFORMATION / CERTIFICATION: The Director of Finance certifies that funds are available in the General Fund and upon approval of the above recommendations and adoption of the appropriation ordinances, funds will be available in the General Capital Projects Fund for the Fire Station 43 project to support the above recommendations and execution of the contract. Prior to any expenditures being incurred, the Fire Department has the responsibility to validate the availability of funds. Submitted for City Manager's Office by: Dana Burghdoff 8018 Originating Business Unit Head: Steve Cooke 5134 Additional Information Contact: Expedited