HomeMy WebLinkAboutContract 30702 CITY SECRETARY OTT,
CONTRACT NO.
CITY OF FORT WORTH, TEXAS
STANDARD AGREEMENT FOR ENGINEERING SERVICES
This AGREEMENT is between the City of Fort Worth (the "CITY"), and
Transystems Corporation, (the "ENGINEER"), for a PROJECT generally described as:
CONSTRUCTION INSPECTION FOR STREET MANAGEMENT.
Article I
Scope of Services
A. The Scope of Services is set forth in Attachment A.
Article 11
Compensation
A. The ENGINEER's compensation is set forth in Attachment B.
Article III
Terms of Payment
Payments to the ENGINEER will be made as follows:
A. Invoice and Payment
(1) The Engineer shall provide the City sufficient documentation to reasonably
substantiate the invoices.
(2) The ENGINEER will issue monthly invoices for all work performed under
this AGREEMENT. Invoices are due and payable within 30 days of receipt.
(3) Upon completion of services enumerated in Article 1, the final payment of
any balance will be due within 30 days of receipt of the final invoice.
(4) In the event of a disputed or contested billing, only that portion so contested
will be withheld from payment, and the undisputed portion will be paid. The
CITY will exercise reasonableness in contesting any bill or portion thereof.
No interest will accrue on any contested portion of the billing until mutually
resolved.
(5) If the CITY fails to make payment in full to ENGINEER for billings contested
in good faith within 60 days of the amount due, the ENGINEER may, after
giving 7 days' written notice to CITY, suspend services under this
AGREEMENT until paid in full, including interest. In he--eyent-�.
suspension of services, the ENGINEER shall have no liabilil y!'WIM1,14
delays or damages caused the CITY because of such -q us
services.
Article IV
Obligations of the Engineer
Amendments to Article IV, if any, are included in Attachment C.
A. General
The ENGINEER will serve as the CITY's professional engineering representative
under this Agreement, providing professional engineering consultation and advice
and furnishing customary services incidental thereto.
B. Standard of Care
The standard of care applicable to the ENGINEER's services will be the degree of
skill and diligence normally employed in the State of Texas by professional
engineers or consultants performing the same or similar services at the time such
services are performed.
C. Subsurface Investigations
(1) The ENGINEER shall advise the CITY with regard to the necessity for
subcontract work such as special surveys, tests, test borings, or other
subsurface investigations in connection with design and engineering work to
be performed hereunder. The ENGINEER shall also advise the CITY
concerning the results of same. Such surveys, tests, and investigations
shall be furnished by the CITY, unless otherwise specified in Attachment A.
(2) In soils, foundation, groundwater, and other subsurface investigations, the
actual characteristics may vary significantly between successive test points
and sample intervals and at locations other than where observations,
exploration, and investigations have been made. Because of the inherent
uncertainties in subsurface evaluations, changed or unanticipated
underground conditions may occur that could affect the total PROJECT cost
and/or execution. These conditions and cost/execution effects are not the
responsibility of the ENGINEER.
D. Preparation of Engineering Drawings
The ENGINEER will provide to the CITY the original drawings of all plans in ink on
reproducible plastic film sheets, or as otherwise approved by CITY, which shall
become the property of the CITY. CITY may use such drawings in any manner it
desires; provided, however, that the ENGINEER shall not be liable for the use of
such drawings for any project other than the PROJECT described herein.
E. Engineer's Personnel at Construction Site
(1) The presence or duties of the ENGINEER's personnel at a construction
site, whether as on-site representatives or otherwise, do not make the
ENGINEER or its personnel in any way responsible for those duties that
belong to the CITY and/or the CITY's construction contractors or other
entities, and do not relieve the construction contractors or any other entity of
their obligations, duties, and responsibilities, including, but not limited to, all
construction methods, means, techniques, sequences, and procedures
necessary for coordinating and completing all portions of the construction
work in accordance with the Contract Documents and any health or safety
precautions required by such construction work. The ENGINEER and its
personnel have no authority to exercise any control over any construction
contractor or other entity or their employees in connection with their work or
any health or safety precautions.
(2) Except to the extent of specific site visits expressly detailed and set forth in
Attachment A, the ENGINEER or its personnel shall have no obligation or
responsibility to visit the construction site to become familiar with the
progress or quality of the completed work on the PROJECT or to determine,
in general, if the work on the PROJECT is being performed in a manner
indicating that the PROJECT, when completed, will be in accordance with
the Contract Documents, nor shall anything in the Contract Documents or
the agreement between CITY and ENGINEER be construed as requiring
ENGINEER to make exhaustive or continuous on-site inspections to
discover latent defects in the work or otherwise check the quality or quantity
of the work on the PROJECT. If, for any reason, the ENGINEER should
make an on-site observation(s), on the basis of such on-site observations, if
any, the ENGINEER shall endeavor to keep the CITY informed of any
deviation from the Contract Documents coming to the actual notice of
ENGINEER regarding the PROJECT.
(3) When professional certification of performance or characteristics of
materials, systems or equipment is reasonably required to perform the
services set forth in the Scope of Services, the ENGINEER shall be entitled
to rely upon such certification to establish materials, systems or equipment
and performance criteria to be required in the Contract Documents.
F. Opinions of Probable Cost,, Financial Considerations, and Schedules
(1) The ENGINEER shall provide opinions of probable costs based on the
current available information at the time of preparation, in accordance with
Attachment A.
(2) In providing opinions of cost, financial analyses, economic feasibility
projections, and schedules for the PROJECT, the ENGINEER has no
control over cost or price of labor and materials; unknown or latent
conditions of existing equipment or structures that may affect operation or
maintenance costs; competitive bidding procedures and mark M
FYI
time or quality of performance by third parties; quality, type, management,
or direction of operating personnel; and other economic and operational
factors that may materially affect the ultimate PROJECT cost or schedule.
Therefore, the ENGINEER makes no warranty that the CITY's actual
PROJECT costs, financial aspects, economic feasibility, or schedules will
not vary from the ENGINEER's opinions, analyses, projections, or
estimates.
G. Construction Progress Payments
Recommendations by the ENGINEER to the CITY for periodic construction
progress payments to the construction contractor will be based on the
ENGINEER's knowledge, information, and belief from selective sampling and
observation that the work has progressed to the point indicated. Such
recommendations do not represent that continuous or detailed examinations have
been made by the ENGINEER to ascertain that the construction contractor has
completed the work in exact accordance with the Contract Documents; that the
final work will be acceptable in all respects; that the ENGINEER has made an
examination to ascertain how or for what purpose the construction contractor has
used the moneys paid; that title to any of the work, materials, or equipment has
passed to the CITY free and clear of liens, claims, security interests, or
encumbrances; or that there are not other matters at issue between the CITY and
the construction contractor that affect the amount that should be paid.
H. Record Drawings
Record drawings, if required, will be prepared, in part, on the basis of information
compiled and furnished by others,and may not always represent the exact
location, type of various components, or exact manner in which the PROJECT was
finally constructed. The ENGINEER is not responsible for any errors or omissions
in the information from others that is incorporated into the record drawings.
1. Minority and Woman Business Enterprise (MNVBE)
participation
In accord with City of Fort Worth Ordinance No. 11923, the City has goals for the
participation of minority business enterprises and woman business enterprises in
City contracts. Engineer acknowledges the M/WBE goal established for this
contract and its commitment to meet that goal. Any misrepresentation of facts
(other than a negligent misrepresentation) and/or the commission of fraud by the
Engineer may result in the termination of this agreement and debarment from
participating in City contracts for a period of time of not less than three (3) years.
J. Right to Audit
(1) ENGINEER agrees that the CITY shall, until the expiration of three (3) years
after final payment under this contract, have access to and the right to
examine and photocopy any directly pertinent books, docum. r,.%,-,papprq-,-,
DD
and records of the ENGINEER involving transactions relating to this
contract. ENGINEER agrees that the CITY shall have access during
normal working hours to all necessary ENGINEER facilities and shall be
provided adequate and appropriate work space in order to conduct audits in
compliance with the provisions of this section. The CITY shall give
ENGINEER reasonable advance notice of intended audits.
(2) ENGINEER further agrees to include in all its subconsultant agreements
hereunder a provision to the effect that the subconsultant agrees that the
CITY shall, until the expiration of three (3) years after final payment under
the subcontract, have access to and the right to examine and photocopy
any directly pertinent books, documents, papers and records of such
subconsultant, involving transactions to the subcontract, and further, that
the CITY shall have access during normal working hours to all
subconsultant facilities, and shall be provided adequate and appropriate
work space, in order to conduct audits in compliance with the provisions of
this article together with subsection (3)hereof. CITY shall give subcon-
sultant reasonable advance notice of intended audits.
(3) ENGINEER and subconsultant agree to photocopy such documents as may
be requested by the CITY. The CITY agrees to reimburse ENGINEER for
the cost of copies at the rate published in the Texas Administrative Code in
effect as of the time copying is performed.
K. ENGINEER's Insurance
(1) Insurance coverage and limits:
ENGINEER shall provide to the City certificate(s) of insurance documenting
policies of the following coverage at minimum limits that are to be in effect prior to
commencement of work on the PROJECT:
Commercial General Liability
$1,000,000 each occurrence
$1,000,000 aggregate
Automobile Liability
$1,000,000 each accident (or reasonably equivalent limits of coverage
if written on a split limits basis). Coverage shall be on any vehicle used
in the course of the PROJECT.
'I I-Dil
L
H V l 4K
Worker's Compensation
Coverage A: statutory limits
Coverage B: $100,000 each accident
$500,000 disease - policy limit
$100,000 disease - each employee
Professional Liability
$1,000,000 each claim/annual aggregate
(2) Certificates of insurance evidencing that the ENGINEER has obtained all
required insurance shall be delivered to the CITY prior to ENGINEER
proceeding with the PROJECT.
(a) Applicable policies shall be endorsed to name the CITY an
Additional Insured thereon, as its interests may appear. The term
CITY shall include its employees, officers, officials, agents, and
volunteers as respects the contracted services.
(b) Certificate(s) of insurance shall document that insurance coverage
specified according to items section K.(1) and K.(2) of this
agreement are provided under applicable policies documented
thereon.
(c) Any failure on part of the CITY to request required insurance
documentation shall not constitute a waiver of the insurance
requirements.
(d) A minimum of thirty (30) days notice of cancellation or material
change in coverage shall be provided to the CITY. A ten (10) days
notice shall be acceptable in the event of non-payment of premium.
Such terms shall be endorsed onto ENGINEER's insurance policies.
Notice shall be sent to the respective Department Director (by
name), City of Fort Worth, 1000 Throckmorton, Fort Worth, Texas
76102.
(e) Insurers for all policies must be authorized to do business in the
state of Texas or be otherwise approved by the CITY; and, such
insurers shall be acceptable to the CITY in terms of their financial
strength and solvency.
(f) Deductible limits, or self-insured retentions, affecting insurance
required herein shall be acceptable to the CITY in its sole discretion;
and, in lieu of traditional insurance, any alternative coverage
maintained through insurance pools or risk retention groups must be
also approved. Dedicated financial resources or letters of credit may
also be acceptable to the City.
V, i0l
(g) Applicable policies shall each be endorsed with a waiver of
subrogation in favor of the CITY as respects the PROJECT.
(h) The City shall be entitled, upon its request and without incurring
expense, to review the ENGINEER's insurance policies including
endorsements thereto and, at the CITY's discretion, the ENGINEER
may be required to provide proof of insurance premium payments.
(i) The Commercial General Liability insurance policy shall have no
exclusions by endorsements unless the CITY approves such
exclusions.
The Professional Liability insurance policy, if written on a claims
made basis shall be maintained by the ENGINEER for a minimum
two (2) year period subsequent to the term of the respective
PROJECT contract with the CITY unless such coverage is provided
the ENGINEER on an occurrence basis.
(k) The CITY shall not be responsible for the direct payment of any
insurance premiums required by this agreement. It is understood
that insurance cost is an allowable component of ENGINEER's
overhead.
(1) All insurance required in section K, except for the Professional
Liability insurance policy, shall be written on an occurrence basis in
order to be approved by the CITY.
(m) Subconsultants to the ENGINEER shall be required by the
ENGINEER to maintain the same or reasonably equivalent
insurance coverage as required for the ENGINEER. When
subconsultants maintain insurance coverage, ENGINEER shall
provide CITY with documentation thereof on a certificate of
insurance. Notwithstanding anything to the contrary contained
herein, in the event a subconsultant's insurance coverage is
canceled or terminated, such cancellation or termination shall not
constitute a breach by ENGINEER of the Agreement.
L. Independent Consultant
The ENGINEER agrees to perform all services as an independent consultant and
not as a subcontractor, agent, or employee of the CITY.
M. Disclosure
The ENGINEER acknowledges to the CITY that it has made full disclosure in
writing of any existing conflicts of interest or potential conflicts of interest, including
personal financial interest, direct or indirect, in property abutting the proposed
PROJECT and business relationships with abutting property r_
lid
Ir I�flcl---J 01i DD,
It "KN
11Iff �1*1 �-, M!"UMV
H. VEIL
ENGINEER further acknowledges that it will make disclosure in writing of any
conflicts of interest that develop subsequent to the signing of this contract and prior
to final payment under the contract.
N. Asbestos or Hazardous Substances
(1) If asbestos or hazardous substances in any form are encountered or
suspected, the ENGINEER will stop its own work in the affected portions of
the PROJECT to permit testing and evaluation.
(2) If asbestos or other hazardous substances are suspected, the ENGINEER
will, if requested, assist the CITY in obtaining the services of a qualified
subcontractor to manage the remediation activities of the PROJECT.
O. Permitting Authorities - Design Changes
If permitting authorities require design changes so as to comply with published
design criteria and/or current engineering practice standards which the ENGINEER
should have been aware of at the time this Agreement was executed, the
ENGINEER shall revise plans and specifications, as required, at its own cost and
expense. However, if design changes are required due to the changes in the
permitting authorities' published design criteria and/or practice standards criteria
which are published after the date of this Agreement which the ENGINEER could
not have been reasonably aware of, the ENGINEER shall notify the CITY of such
changes and an adjustment in compensation will be made through an amendment
to this AGREEMENT.
Article V
Obligations of the City
Amendments to Article V, if any, are included in Attachment C.
A. City-Furnished Data
The CITY will make available to the ENGINEER all technical data in the CITY's
possession relating to the ENGINEER's services on the PROJECT. The
ENGINEER may rely upon the accuracy, timeliness, and completeness of the
information provided by the CITY.
B. Access to Facilities and Property
The CITY will make its facilities accessible to the ENGINEER as required for the
ENGINEER's performance of its services and will provide labor and safety
equipment as required by the ENGINEER for such access. The CITY will perform,
at no cost to the ENGINEER, such tests of equipment, machinery, pipelines, and
other components of the CITY's facilities as may be required in connection with the
ENGINEER's services. The CITY will be responsible for all acts o the CITY's
T DD
nn q
personnel.
C. Advertisements, Permits, and Access
Unless otherwise agreed to in the Scope of Services, the CITY will obtain, arrange,
and pay for all advertisements for bids; permits and licenses required by local,
state, or federal authorities; and land, easements, rights-of-way, and access
necessary for the ENGINEER's services or PROJECT construction.
D. Timely Review
The CITY will examine the ENGINEER's studies, reports, sketches, drawings,
specifications, proposals, and other documents; obtain advice of an attorney,
insurance counselor, accountant, auditor, bond and financial advisors, and other
consultants as the CITY deems appropriate; and render in writing decisions
required by the CITY in a timely manner in accordance with the project schedule in
Attachment A.
E. Prompt Notice
The CITY will give prompt written notice to the ENGINEER whenever CITY
observes or becomes aware of any development that affects the scope or timing of
the ENGINEER's services or of any defect in the work of the ENGINEER or
construction contractors.
F. Asbestos or Hazardous Substances Release.
(1) CITY acknowledges ENGINEER will perform part of the work at CITY's
facilities that may contain hazardous materials, including asbestos
containing materials, or conditions, and that ENGINEER had no prior role
in the generation, treatment, storage, or disposition of such materials. In
consideration of the associated risks that may give rise to claims by third
parties or employees of City, City hereby releases ENGINEER from any
damage or liability related to the presence of such materials.
(2) The release required above shall not apply in the event the discharge,
release or escape of hazardous substances, contaminants, or asbestos is a
result of ENGINEER's negligence or if ENGINEER brings such hazardous
substance, contaminant or asbestos onto the project.
10 50
I
G. Contractor Indemnification and Claims
The CITY agrees to include in all construction contracts the provisions of Article
IV.E. regarding the ENGINEER's Personnel at Construction Site, and provisions
providing contractor indemnification of the CITY and the ENGINEER for
contractor's negligence.
H. Contractor Claims and Third-Party Beneficiaries
(1) The CITY agrees to include the following clause in all contracts with
construction contractors and equipment or materials suppliers:
"Contractors, subcontractors and equipment and materials
suppliers on the PROJECT, or their sureties, shall maintain
no direct action against the ENGINEER, its officers,
employees, and subcontractors, for any claim arising out
of, in connection with, or resulting from the engineering
services performed. Only the CITY will be the beneficiary
of any undertaking by the ENGINEER."
(2) This AGREEMENT gives no rights or benefits to anyone other than the
CITY and the ENGINEER and there are no third-party beneficiaries.
(3) The CITY will include in.each agreement it enters into with any other entity
or person regarding the PROJECT a provision that such entity or person
shall have no third-party beneficiary rights under this Agreement.
(4) Nothing contained in this section V.H. shall be construed as a waiver of any
right the CITY has to bring a claim against ENGINEER.
1. CITYs Insurance
(1) The CITY may maintain property insurance on certain pre-existing
structures associated with the PROJECT.
(2) The CITY will ensure that Builders Risk/installation insurance is maintained
at the replacement cost value of the PROJECT. The CITY may provide
ENGINEER a copy of the policy or documentation of such on a certificate of
insurance.
(3) The CITY will specify that the Builders Risk/Installation insurance shall be
comprehensive in coverage appropriate to the PROJECT risks.
J. Litigation Assistance
The Scope of Services does not include costs of the ENGINEER for required or
requested assistance to support, prepare, document, bring, defend, or assist in
litigation undertaken or defended by the CITY. In the event CITY re uests such
l�DD
`�*.it"DID R H VEX
services of the ENGINEER, this AGREEMENT shall be amended or a separate
agreement will be negotiated between the parties.
K. Changes
The CITY may make or approve changes within the general Scope of Services in
this AGREEMENT. If such changes affect the ENGINEER's cost of or time
required for performance of the services, an equitable adjustment will be made
through an amendment to this AGREEMENT with appropriate CITY approval.
Article VI
General Legal Provisions
Amendments to Article VI, if any, are included in Attachment C.
A. Authorization to Proceed
ENGINEER shall be authorized to proceed with this AGREEMENT upon receipt of
a written Notice to Proceed from the CITY.
B. Reuse of Project Documents
All designs, drawings, specifications, documents, and other work products of the
ENGINEER, whether in hard copy or in electronic form, are instruments of service
for this PROJECT, whether the PROJECT is completed or not. Reuse, change, or
alteration by the CITY or by others acting through or on behalf of the CITY of any
such instruments of service without the written permission of the ENGINEER will
be at the CITY's sole risk. The final designs, drawings, specifications and
documents shall be owned by the CITY.
C. Force Majeure
The ENGINEER is not responsible for damages or delay in performance caused
by acts of God, strikes, lockouts, accidents, or other events beyond the control of
the ENGINEER.
D. Termination
(1) This AGREEMENT may be terminated only by the City for convenience on
30 days' written notice. This AGREEMENT may be terminated by either the
CITY or the ENGINEER for cause if either party fails substantially to
perform through no fault of the other and does not commence correction of
such nonperformance with 5 days of written notice and diligently complete
the correction thereafter.
(2) If this AGREEMENT is terminated for the convenience of the City, the
ENGINEER will be paid for termination expenses as follows:
"�-I i�11-11- �E
111vlff R11 MARY
in. w �-C?Vflj Va.
a.) Cost of reproduction of partial or complete studies, plans,
specifications or other forms of ENGINEER'S work product;
b.) Out-of-pocket expenses for purchasing storage containers,
microfilm, electronic data files, and other data storage supplies or services;
c.) The time requirements for the ENGINEER'S personnel to document
the work underway at the time the CITY'S termination for convenience so
that the work effort is suitable for long time storage.
(3) Prior to proceeding with termination services, the ENGINEER will submit to
the CITY an itemized statement of all termination expenses. The CITY'S approval
will be obtained in writing prior to proceeding with termination services.
E. Suspension, Delay, or Interruption to Work
The CITY may suspend, delay, or interrupt the services of the ENGINEER for the
convenience of the CITY. In the event of such suspension, delay, or interruption,
an equitable adjustment in the PROJECT's schedule, commitment and cost of the
ENGINEER's personnel and subcontractors, and ENGINEER's compensation will
be made.
F. Indemnification
(1) The ENGINEER agrees to indemnify and defend the CITY from any loss,
cost, or expense claimed by third parties for property damage and bodily
injury, including death, caused solely by the negligence or willful misconduct
of the ENGINEER, its employees, officers, and subcontractors in
connection with the PROJECT.
(2) If the negligence or willful misconduct of both the ENGINEER and the CITY
(or a person identified above for whom each is liable) is a cause of such
damage or injury, the loss, cost, or expense shall be shared between the
ENGINEER and the CITY in proportion to their relative degrees of
negligence or willful misconduct as determined pursuant to T.C.P. & R.
Code, section 33.011(4) (Vernon Supplement 1996).
G. Assignment
Neither party shall assign all or any part of this AGREEMENT without the prior
written consent of the other party.
J�1 RE 1f`1 P Y
H. �'�yS��V7 U`u U U 9 ROL
H. Interpretation
Limitations on liability and indemnities in this AGREEMENT are business
understandings between the parties and shall apply to all the different theories of
recovery, including breach of contract or warranty, tort including negligence, strict
or statutory liability, or any other cause of action, except for willful misconduct or
gross negligence for limitations of liability and sole negligence for indemnification.
Parties mean the CITY and the ENGINEER, and their officers, employees, agents,
and subcontractors.
1. Jurisdiction
The law of the State of Texas shall govern the validity of this AGREEMENT, its
interpretation and performance, and any other claims related to it. The venue for
any litigation related to this AGREEMENT shall be Tarrant County, Texas.
J. Alternate Dispute Resolution
(1) All claims, disputes, and other matters in question between the CITY and
ENGINEER arising out of, or in connection with this Agreement or the
PROJECT, or any breach of any obligation or duty of CITY or ENGINEER
hereunder, will be submitted to mediation. If mediation is unsuccessful, the
claim, dispute or other matter in question shall be submitted to arbitration if
both parties acting reasonably agree that the amount of the dispute is likely
to be less than $50,000, exclusive of attorney's fees, costs and expenses.
Arbitration shall be in accordance with the Construction Industry Arbitration
Rules of the American Arbitration Association or other applicable rules of
the Association then in effect. Any award rendered by the arbitrators less
than $50,000, exclusive of attorney's fees, costs and expenses, will be final,
judgment may be entered thereon in any court having jurisdiction, and will
not be subject to appeal or modification except to the extent permitted by
Sections 10 and 11 of the Federal Arbitration Act (9 U.S.C. Sections 10 and
11).
(2) Any award greater than $50,000, exclusive of attorney's fees, costs and
expenses, may be litigated by either party on a de novo basis. The award
shall become final ninety (90) days from the date same is issued. If litigation
is filed by either party within said ninety (90) day period, the award shall
become null and void and shall not be used by either party for any purpose
in the litigation.
K. Severability and Survival
If any of the provisions contained in this AGREEMENT are held for any reason to
be invalid, illegal, or unenforceable in any respect, such invalidity, illegality, or
unenforceability will not affect any other provision, and this AGREEMENT shall be
!� C 0)dip
, 9YY !�
construed as if such invalid, illegal, or unenforceable provision had never been
contained herein. Articles V.F., VI.B., VI.D., VI.H., VI.I., and VI.J. shall survive
termination of this AGREEMENT for any cause.
L. Observe and Comply
ENGINEER shall at all times observe and comply with all federal and State laws
and regulations and with all City ordinances and regulations which in any way
affect this AGREEMENT and the work hereunder, and shall observe and comply
with all orders, laws ordinances and regulations which may exist or may be
enacted later by governing bodies having jurisdiction or authority for such
enactment. No plea of misunderstanding or ignorance thereof shall be considered.
ENGINEER agrees to defend, indemnify and hold harmless CITY and all of its
officers, agents and employees from and against all claims or liability arising out of
the violation of any such order, law, ordinance, or regulation, whether it be by itself
or its employees.
Article VII
Attachments, Schedules, and Signatures
This AGREEMENT, including its attachments and schedules, constitutes the entire
AGREEMENT, supersedes all prior written or oral understandings, and may only be
changed by a written amendment executed by both parties. The following attachments
and schedules are hereby made a part of this AGREEMENT:
Attachment A- Scope of Services
Attachment B - Compensation
Executed this the day of 20_4
(REMAINDER OF PAGE INTENTIONALLY LEFT BLANK)
I 0V
lU y�''v�r',(�j�➢ U�G�o
ATTEST: CITY OFF RT WO
Marty Hendrix Assistant City Manage
City Secretary
APPROVED AS TO FORM
Contract Authoriaatioa.
AND LEGALITY
Date
Assistant City Attorney
ATTEST: ENGINEER
By.
Ra4 Pena I, P.E.
Principal
TranSystems Corporation Consultants
�o z` U���UU� �IS�Uo
ATTACHMENT A
SCOPE OF SERVICES
STREET MANAGEMENT CONSTRUCTION INSPECTION
Upon receipt of notice to proceed from the CITY, Transystems Corporation will perform
the following scope of services:
PART A-ADMINISTRATION
The ENGINEER shall monitor the contractor's progress, submit weekly progress reports
with attached daily reports,recommend changes to the CITY if the Contractor is not
meeting the proposed construction schedule, and track quantities for payment if
applicable.
PART B—COORDINATION
The ENGINEER shall coordinate with the CITY, TXDOT, and utilities for temporary
lane closures and utility disruptions. Field changes shall allow for any new facilities or
adjustment to existing facilities within the project limits. The ENGINEER will also
coordinate the delivery of any owner- supplied equipment or materials.
PART C-SITE INSPECTION AND TESTING
The ENGINEER will inspect the construction site on a daily basis to ensure that the
project is constructed in accordance with the plans and specifications approved by the
CITY. The ENGINEER shall be present during backfill and all concrete pours,patching
of pavement and any asphalt pavement placement.
The ENGINEER shall monitor the Contractor's safety and environmental programs to
ensure compliance with OSHA, EPA,and other local, state. and Federal guidelines. The
ENGINEER can stop work in cases of immediate danger or hazards. ENGINEER shall
contact CITY on all other safety issues.
a.) Drainage facilities shall be inspected for compliance with the CITY'S Standard
Specifications for Street and Storm Drain Construction and Storm Drainage criteria
and Design Manual,latest editions.
b.) Roadways shall be inspected for compliance the CITY'S Standard Specifications
for Street and Storm Drain Construction, Traffic Engineering Design Standards and
Policy Guidelines,Roadway Cross-sections and Pavement Design Standards, latest
editions.
A-1
'1k DD
'd
c.) Erosion Control shall be inspected for compliance with the Storm Water Pollution
Prevention Plan(SW3P). All Temporary erosion and pollution control devices shall
comply with the requirements of NCTCOG'S Storm Water Quality Best Management
Practices(RAM for Construction Activities, latest edition.
d.) Illumination shall be inspected for compliance with the CITY'S Illumination
Design Guidelines for streetlight foundations,poles, luminare arms, luminaires, electrical
conduit,wiring, electrical service, and ground boxes.
e.) Pavement marking and signs shall be inspected for compliance with the City's
standard details and the Texas Manual on Uniform Traffic Control Devices.
f.) Traffic control during construction shall be inspected for compliance with the
project's Traffic Control Plan approved by the CITY. Construction shall be staged and
developed as required to minimize impact on vehicles and pedestrians including all
intersecting side streets. The Traffic Control Plan will comply with the Texas Manual on
Uniform Traffic Control Devices.
PART D—NEWBE
The ENGINEER will comply with the City's goal of 10%M\WBE participation for this
project.
PART E-PROJECT CLOSE-OUT
The ENGINEER shall participate in all final inspections for acceptance by the City The
Contractor and CITY shall be notified immediately of any deficiencies. The ENGINEER
will recommend final payment only after all deficiencies have been corrected, if required.
The ENGINEER will maintain a separate set of marked-up drawings and will review the
CONTRACTOR'S as-built drawings to ensure they depict the utility installation
performed in the field
A-2
c� J��HGli4 r 0i�P2D
ATTACHMENT B
COMPENSATION
The ENGINEER shall be compensated with an hourly fee not to exceed$180,000 for the
project including mileage. Payment shall be considered fall compensation for all labor,
materials, supplies, and equipment necessary to complete the services described in
Attachment A.
The ENGINEER shall provide monthly invoices to the City of Fort Worth for
reimbursement of labor costs and mileage incurred in the work performed under this
agreement set forth in Article III Terms of Payment. The total fee will not be exceeded
without prior written approval from the City of Fort Worth.
The ENGINEER will be paid$54.00-$58.00 per hour and$0.36 per mile for travel while
performing the tasks identified in Attachment A.
When subconsultants are used, ENGINEER will be reimbursed the subconsultant's
invoice amount plus ten percent(10%).
B-1
TranSystems Corporation Consultants
Street Management Inspectors
09/10/2004
Gordon, I have attached a brief description about the inspectors that we can supply you with. I
have also attached resumes with more detailed experience and background. Please let me know if
any additional info. is needed.
Rod Newberry $55.00/Hr—you already know Rod. He really enjoys his job working with your
group. He is a full-time employee dedicated to construction inspection. We have dedicated him for
your use.
Fred Winstead- $54.00/Hr-35 years in both design and various types of construction. Sixteen
years with Texas Dept. of Transportation as inspector of contractor compliance. Fred has also
worked for the City of Fort Worth as an Inspector.
Floyd Thomas $58.00/Hr—Floyd has about 30 years of design and construction experience. He
is currently working on another inspection project but could be made available on a job by job basis
with some advance notice.
Fred Rodriguez $58.00/Hr - Fred has about 30 years of design,surveying and construction
experience. He is a great guy but wanting to reduce his hours to spend more time with
grandchildren. Fred will work about 40 hours per month. He might be good for a specific project or
can pinch hit if needed.
MMBE—we have teamed with GTFS, Inc to meet M/WBE goals. Do you know what the goals are
for this project?The following two people have been identified by GTFS as potential candidates for
your use:
Nathan Price—$55/Hr- 20 plus years of electrical,telecommunications and fiber construction.
Michael Smith-$57/Hr- 18 years of design and multidiscipline construction observation and
inspection experience.
Mileage at 0.36/mile
Thanks, Raul
-i� roam TEX,
City of Fort Wolrth., Texas
Mayor and Council Communication
COUNCIL ACTION: Approved on 10/512004
DATE: Tuesday, October 05, 2004
LOG NAME: 20TRANSYSTEMS REFERENCE NO.: **C-20316
SUBJECT:
Award of Contract to TranSystems Corporation Consultants for Utility Construction Inspections for
the Transportation and Public Works Street Management Section
RECOMMENDATION:
It is recommended that the City Council authorize the City Manager to execute a contract with TranSystems
Corporation Consultants for utility construction inspections for the Transportation and Public Works
Department, Street Management Division, for an aggregate fee not to exceed $180,000; and
DISCUSSION:
The FY2004-2005 budget includes $180,000 budgeted for supplemental utility inspectors. This contract
would allow City staff to use contract services to the extent that funds are available.
The use of a private firm to assist City staff in utility inspections would allow the Transportation and Public
Works Department to supplement existing City staff and provide a higher degree of service. These
additional inspectors would provide needed resources to inspect utility cuts and other street disruptions to
manage traffic flow and work in the field monitoring/coordinating with contractors and other entities to
ensure all street activities are safe and authorized. Also, residents and various organizations requesting
street closures for different social events would be served more effectively.
City staff solicited unpriced statements of qualifications and received responses from one firm. A selection
committee of City staff reviewed the proposal and based on qualifications, approved TranSystems
Corporation Consultants for the services to be performed.
City staff has negotiated unit prices for the contract and believes them to be fair and reasonable. City staff
recommends that TranSystems Corporation Consultants be awarded a contract for a term of one-year or an
aggregate fee not to exceed $180,000, whichever occurs first. This contract will begin October 1, 2004 and
expire September 30, 2005, with an option for two one-year renewals with renegotiated unit prices.
M/WBE - TranSystems Corporation Consultants is in compliance with the City's M/WBE Ordinance by
committing to 10% M/WBE participation. The City's goal on this project is 10%.
FISCAL INFORMATION/CERTIFICATION:
The Finance Director certifies that funds will be available in the current operating budget, as appropriated,
of the General Fund.
Logname: 20TRANSYSTEMS Page 1 of 2
TO Fund/Account/Centers FROM Fund/Account/Centers
0001 539120 0202502 $180.000.00
Submitted for City Manager's Office b Marc Ott (8476)
Originating Department Head: Robert Goode (7804)
Additional Information Contact: Cynthia Alexander (7894)
Logname: 20TRANSYSTEMS Page 2 of 2