Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
Contract 61183
CSC No. 61183 THE CITY OF FORT WORTH, TEXAS Crime Lab Full Building Generator Replacement PMD2023-10 111 FORT WORTHa MATTIE PARKER DAVID COOKE MAYOR CITY MANAGER Marilyn Marvin Interim Director, Property Management Department Baird Hampton Brown Engineering and Surveying September 2023 OFFICIAL RECORD CITY SECRETARY FT. WORTH, TX Instruction to Offerors Page 1 of 33 Crime Lab Full Building Generator Replacement - Proj. #102986 Sept. 2023) City of Fort Worth, Texas Mayor and Council Communication DATE: Tuesday, January 23, 2024 REFERENCE NO.: **M&C 24-0053 LOG NAME: 21POLICE DEPARTMENT CRIME LAB GENERATOR SUBJECT: (CD 11) Authorize Execution of a General Contractor Contract with SDB, Inc., in the Amount of $150,000.00, Including an Owner's Construction Contingency Allowance, for the Procurement of a Police Department Crime Lab Generator RECOMMENDATION: It is recommended that the City Council authorize the execution of a general contractor contract with SDB, Inc., in the amount of $150,000.00, including an owner's construction contingency allowance, for the procurement of a Police Department Crime Lab Generator. DISCUSSION: The purpose of this Mayor and Council Communication (M&C) is to take actions associated with procuring a General Contractor for the procurement and installation of a generator for the Police Department's Crime Lab located at 3616 E. Lancaster Avenue. This project is to provide equipment, materials and labor for the installation of a backup generator for the facility. A Notice to Offerors was advertised in the Fort Worth Star -Telegram on July 27, 2023 and August 3, 2023 in the Bids and Proposal section for Best Value. Proposals were due August 9, 2023. The City received two proposals from bidders. These contractors were: • NorCom Integrated Systems, Inc. . SDB, Inc. Upon review only SDB, Inc. provided all requested Bid, Payment and Performance Bonds, General Liability and Statutory Workers Compensation Coverage and was thus awarded the contract for this project. In order to expedite the project, SDB, Inc. identified construction equipment which has long lead times. Early procurement of the equipment is needed in order to hold pricing and maintain a construction start date of Fall 2024. The overall project costs expected is described in the table below: Crime Lab Generator Totals Engineering Design $61,400.00 Early Equipment Procurement I $150,000.00 Construction �� $813,983.00 Project Administration $24,918.001 PROJECT TOTAL 1 $1,050,301.001 Funding - Funding is budgeted in the Property Management Department's General Capital Projects Fund for the purpose of funding the Crime Lab Generator project, as appropriated. Waiver of Building Permit Fees - In accordance with the City Code of Ordinances, Part II, Chapter 7-1 Fort Worth Building Administrative Code, Section 109.2.1, Exception 2; "Work by non -City personnel on property under the control of the City of Fort Worth shall be exempt from the permit fees only if the work is http://apps.cfwnet.org/ecouncil/printmc.asp?id=31761&print=true&DocType=Print 1/24/2024 for action under a contract will be or has been approved by City Council with notes in the contract packages stating the fee is waived." Diversity and Inclusion Business Equity Office (DVIN) - A waiver of the goal for Business Equity subcontracting requirements was requested, and approved by the DVIN, in accordance with the applicable Ordinance, because the purchase of goods or services is from sources where subcontracting or supplier opportunities are negligible. The Police Department Crime Lab is located in COUNCIL DISTRICT 11. FISCAL INFORMATION / CERTIFICATION: The Director of Finance certifies that funds are available in the current capital budget, as previously appropriated, in the General Capital Projects Fund to support the approval of the above recommendation and execution of the contract. Prior to any expenditure being incurred, the Property Management Department has the responsibility to validate the availability of funds. FUND IDENTIFIERS (FIDs): TO Fund Department ccoun Project Program ctivity I Budget Reference # moun 1 ID ID Year (Chartfield 2) FROM Fund Department ccoun 1 Project ctivity Budget Reference # moun ID ID JProgram r I Year (Chartfield 2) 1 CERTIFICATIONS: Submitted for Citv Manaqer's Office bv: Dana Burghdoff (8018) Ricardo Salazar (8379) Oriqinatinq Department Head: Brian Glass (8088) Additional Information Contact: Nikita Watts (2028) ATTACHMENTS 1. 102986 Waiver Crimel-abFull Build ingGeneratorReolace Al.odf (CFW Internal) 2. 21CRIME LAB GENERATOR FID TABLE.xlsx (CFW Internal) 3. 21POLICE DEPT CRIME LAB GENERATOR.docx (CFW Internal) 4. Construction map Crime Lab.odf (CFW Internal) 5. Form 1295 Certificate (City of Fort Worth Crime Lab).pdf (CFW Internal) 6. SAM SDB Contracting Services.odf (CFW Internal) http://apps.cfvmet.org/ecouncil/printmc.asp?id=31761&print=true&DocType=Print 1/24/2024 Project: Project #: PMD Project # Bid Date: Advertised: PROPERTY MANAGEMENT DEPARTMENT FACILITIES / ARCHITECTURAL SERVICES BID TABULATION CRIME LAB FULL BUILDING GENERATOR REPLACEMENT 3616 E LANCASTER AVE FORT WORTH TEXAS 102986 PMD2023-10 SEPTEMBER 14, 2023 JULY 27, 2023 & AUGUST 3, 2023 DESCRIPTION Base Proposal Owner's Contingency Allowance Base Proposal Plus Owner's Contingency Allowance Tabulated by: Eng. Estimate: Addendums: 1 NorCom Integrated Systems, Inc. Vicki McDonald $900,000.00 2 2 SDB, Inc. dba SDB Contracting Services 921 Ridge Ct, Ste 200 Keller, Texas 76248 817-271-8045 paul@HasTechSolutions.com DAYS $ 750,000.00 $ $ 56,250.00 $ $ 806,250.00 365 $ 8131 LBJ Freeway Ste 785 Dallas, Texas 75251 469-619-3753 angie.schmidt@sdb.com DAYS 896,727.88 67,254.59 963,982.47 400 ADDENDUM'S: 2 2 NOTICE TO OFFERORS Proposals for the Crime Lab Full Building Generator Replacement located at 3616 E. Lancaster Ave. Fort Worth, Texas 76103 will be received at the Purchasing Office, City of Fort Worth, 200 Texas Street, Fort Worth, 76102, until 1:30 P.M on Thursday, Aug. 24, 2023, and will be opened and publicly read aloud approximately thirty minutes later in the Council Chambers. After evaluating the Proposals submitted, the City shall select the Offeror that offers the Best Value to the City and enter into negotiations with that Offeror. The City may discuss with the selected Offeror options for a scope or time modification and any price change associated with such modification. The last day for questions from prospective Offerors is at 5:00 PM on Friday, August 11, 2023. A Pre -Proposal Conference will be held at 10:30 A.M., Wednesday, August 9, 2023 at Architectural Services Conference Room at 401 W. 13th St. Fort Worth, TX. 76102. A guided tour of the site will follow the Conference. The offers will be valid for ONE HUNDRED TWENTY (120) calendar days. Estimated construction cost is approximately $900.000.00. The Offeror will add a 7.5% Owner's Contingency Allowance on a separate line item on the Proposal form and only the Owner will approve the use of this allowance during construction. Any Allowance remaining at the end of construction will be retained by the City of Fort Worth. This Allowance is not to be included in the Base Proposal and will not be used in the Best Value selection process. Refer to the evaluation matrix for the selection of the Best Value Offeror in the Instructions to Offerors. Refer to the Request for Proposal documents for the Business Equity Provision Information. The Business Equity participation will be evaluated in awarding this Contract. The Business Equity goal requirement is WAIVED and set at 0%. Also, Refer to Section 2. BUSINESS EQUITY PROVISIONS FOR BEST VALUE PROPOSAL in the Instructions to Offerors. Offerors must submit a bid bond with their proposal. Offeror(s) to whom an award of contract(s) is made will be required to provide Payment and Performance Bonds and provide Contractors General Liability and Statutory Workers Compensation Coverage. If you intend to submit a Proposal, request you inform the Project Manager or Architect/Engineer who can then inform the interested subcontractors. General Contractors and Suppliers may make copies of the Instructions to Offerors, General Conditions, Drawings, and Specifications through their printer. The construction documents are not available at the City but may be viewed and printed on-line by cutting and pasting the following LINK into your browser: httr)s://docs.b360.autodesk.com/shares/d93ac667-24c7-4f44-aa3l -1 567dObb2590 Contact the Project Manager, Don Isaacs, at (817) 392-8498 or email Donald. Isaacs(a),fortworthtexas.�4ov for assistance. For additional information contact the Project Engineer, Paul Morris, at (682) 348-0792 or email nmorris(&,hbinc.com Advertisement: July 27, 2023, August 3, 2023 Instruction to Offerors Page 2 of 33 Crime Lab Full Building Generator Replacement - Proj. #102986 Sept. 2023) TABLE OF CONTENTS • PROJECT COVER PAGE • NOTICE TO OFFERORS • TABLE OF CONTENTS • INSTRUCTIONS TO OFFERORS • PROPOSALFORM • CONFLICT OF INTEREST AFFIDAVIT • CONFLICT OF INTEREST QUESTIONAIRE (CIQ) • CONFLICT DISCLOSURE STATEMENT (CIS) • TEXAS SALES AND USE TAX EXEMPTION CERTIFICATE • 2013 PREVAILING WAGE RATES • WEATHER TABLE • GENERAL CONDITIONS OF THE CONTRACT FOR CONSTRUCTION (Separate Attachment) • CONSTRUCTION CONTRACT • PAYMENT BOND • PERFORMANCE BOND • CERTIFICATE OF INSURANCE • CONTRACTOR COMPLIANCE WITH WORKERS' COMPENSATION LAW • PROJECT SIGN Instruction to Offerors Page 3 of 33 Crime Lab Full Building Generator Replacement - Proj. #102986 Sept. 2023) INSTRUCTIONS TO OFFERORS PROPOSAL REQUIREMENTS: The following requirements shall be used in the preparation of the response to this Request for Sealed Proposals: • Use the Proposal Form provided below. • Entries on the Proposal Form may be handwritten or typed. • Write in contract duration if not specified. • Acknowledge all addenda on the Proposal Form. • Have a Principal sign the Proposal. If the Offeror is a corporation, the president or a vice- president must sign the Proposal. If the Offeror is a partnership, then the person/entity who is the managing/general partner must sign the proposal. • Complete and submit the Conflict of Interest Affidavit form. (Also submit associated Form CIQ and Form CIS if required.) • Include cashier's check or an acceptable bidder's bond written by a corporate surety payable to the City of Fort Worth, in an amount of not less than five (5%) per cent of the total of the bid submitted. • In order for a surety to be acceptable to the City, the surety must (1) hold a certificate of authority from the United States Secretary of the Treasury to qualify as a surety on obligations permitted or required under federal law; or (2) have obtained reinsurance for any liability in excess of $100,000 from a reinsurer that is authorized and admitted as a reinsurer in the state of Texas and is the holder of a certificate of authority from the United States Secretary of the Treasury to qualify as a surety on obligations permitted or required under federal law. Satisfactory proof of any such reinsurance shall be provided to the City upon request. The City, in its sole discretion, will determine the adequacy of the proof required herein. 1A. SELECTION OF CONTRACTOR: The City shall select the Offeror that offers the best value based upon the following criteria and on its ranking evaluation. In determining the Best Value Offeror, the City will consider: 1. Proposed Price (60 points) — The lowest priced responsive Proposal will receive 60 points for this rating criterion. Higher priced proposals will receive proportionally lower scores. When compared to the lowest price, the higher priced proposal will have its score reduced by one percent of the available points for every percent it is higher than the lowest price. The score will be rounded to the nearest whole number. 2. References/Experience (20 points) - References and experience of the Offeror as demonstrated by listing past and current projects including references with names and current telephone numbers; and, list of subcontractors if applicable. Instruction to Offerors Page 4 of 33 Crime Lab Full Building Generator Replacement - Proj. #102986 Sept. 2023) Proposed project schedule (10 points) — Proposals should include a general schedule showing the amount of time necessary to complete the project, critical path, major phases of the work, and major impacts on the project. This is to demonstrate an understanding of the project and the most efficient justifiable time. The best schedule demonstrating the most complete understanding of the project will receive 10 points. All others will be graded accordingly. 4 Past Work in the City of Fort Worth (10 points) — Points shall be awarded for experience working on similar projects within the city limits of the City of Fort Worth. Contractors with no experience in the City of Fort Worth will receive 5 points. Contractors demonstrating strong experience will receive more than 5 points. Contractors with poor examples may receive less than 5 points. If the score for any individual rating criteria is rated as zero, this will result in the overall score being zero regardless of how many points could have been earned in the other categories. 6 Compliance with the Business Equity (M/WBE) participation and ordinance is Responsive or Non - Responsive. The Business Equity participation will not be evaluated in awarding this Contract. The Business Equity goal REQUIREMENT is WAIVED, and set at 0%. 7 After ranking the responses to the Request for Proposal (RFP), the City shall first attempt to negotiate a contract with the selected Offeror. The City and its architect may discuss with the selected Offeror options for a scope or time modification and any price change associated with the modification. If the City is unable to negotiate a contract with the selected Offeror, the City shall, formally and in writing, end negotiations with that Offeror and proceed to the next Offeror in the order of the selection ranking until a contract is reached or all proposals are rejected. 2. BUSINESS EQUITY PROVISIONS FOR BEST VALUE PROPOSAL BUSINESS EQUITY ORDINANCE PROVISIONS Business Equity Provisions Business Equity Goal: 0% A. All proposers shall note that the Business Equity Ordinance No. 25165-10-2021 (codified in Chapter 20, Article X of the Fort Worth Code of Ordinances, as amended), and any relevant policy or guidance documents, was adopted to ensure the full and equitable participation of certified Minority — and Women -owned business enterprises (M/WBEs), (collectively, "Business Equity Firms") in City contracts for the procurement of goods and services where a contract's total dollar value is greater than $100,000, as detailed below. As a primary contracting division of the City, the Property Management Department aspires to lead in the City's efforts to promote diversity and inclusion in design, engineering, and construction project work. No M/W BE goals have been set on this project. B. Respondents shall note that goals are established as a MINIMUM standard and that efforts, commitments, and successful results which demonstrate and maintain the Department's leadership status for diversity and inclusion in contracting shall be considered to contribute to the best interest and overall value of the City. The procedures outlined below will apply when a selection is made, that specific work is scoped, and the Business Equity Division establishes a goal. Instruction to Offerors Page 5 of 33 Crime Lab Full Building Generator Replacement - Proj. #102986 Sept. 2023) C. Please note that the certified M/WBE firm(s) must meet one or more of the following three options: (1) have its principal place of business located inside the Marketplace; or (2) show proof it has its principal place of business located outside the Marketplace and verified to be in existence for a minimum of 24 months and from which at least 20% of the business's workforce is based in the Marketplace; or (3) a firm which can show proof it has cumulative business receipts greater than $1,000,000 for work done in the Marketplace since January 1, 2013. The City's geographic Marketplace includes six (6) counties: Tarrant, Dallas, Denton, Johnson, Parker, and Wise. The City of Fort Worth accepts certifications from the North Central Texas Regional Certification Agency (NCTRCA), Dallas/ Fort Worth Minority Supplier Development Council (D/FW MSDC), and the Women's Business Council Southwest (WBCS). D. Offerors must also comply with all local, state, and federal laws and regulations related to certified M/WBEs. The City reserves the right to verify compliance by examination of records, documents, or other information as may be required by the City. The Business Equity Firm must be certified before the recommendation of an award for participation to be counted towards the established goal. If an Offeror is certified as an MBE or WBE firm, please be aware that the City's Ordinance #25165-10- 2021 does allow a Business Equity Firm to count itself towards the established goal. 3. PROPOSAL SECURITY: Cashier's check or an acceptable Offeror's bond payable to the City of Fort Worth, in an amount of five (5) per cent of the Proposal submitted (See paragraph 1 above). The Proposal Security must accompany the Proposal and is subject to forfeit in the event the successful Offeror fails to execute the contract documents within ten (10) days after the contract has been awarded. The Proposal Security shall be included in the envelope containing the Proposal. Failure to submit the Proposal Security will result in the Proposal not being considered for this project. Offeror's bond will be returned if the City fails to award the contract within 90 calendar days of receipt of proposals, unless the Offeror agrees to an extension. The surety must be licensed to do business in the state of Texas. 4. PAYMENT BOND AND PERFORMANCE BOND: For projects in excess of $25,000, the successful Offeror entering into a contract for the work will be required to give the City surety in a sum equal to the amount of the contract awarded. The form of the bond shall be as herein provided and the surety shall be acceptable to the City. All bonds furnished hereunder shall meet the requirements of Texas Government Code Section 2253, as amended. In order for a surety to be acceptable to the City, the surety must (1) hold a certificate of authority from the United States Secretary of the Treasury to qualify as a surety on obligations permitted or required under federal law; or (2) have obtained reinsurance for any liability in excess of $100,000 from a reinsurer that is authorized and admitted as a reinsurer in the State of Texas and is the holder of a certificate of authority from the United States Secretary of the Treasury to qualify as a surety on obligations permitted or required under federal law. Satisfactory proof of any such reinsurance shall be provided to the City upon request. The City, in its sole discretion, will determine the adequacy of the proof required herein. No sureties will be accepted by the City that are at the time in default or delinquent on any bonds or which are interested in any litigation against the City. Should any surety on the contract be determined unsatisfactory at any time by the City, notice will be given to the contractor to that effect and the contractor shall immediately provide a new surety satisfactory to the City. If the total contract price is $25,000 or less, payment to the contractor shall be made in one lump sum. Payment shall not be made for a period of 45 calendar days from the date the work has been completed and accepted by the City. Instruction to Offerors Page 6 of 33 Crime Lab Full Building Generator Replacement - Proj. #102986 Sept. 2023) If the contract is in excess of $25,000, a Payment Bond shall be executed, in the amount of the contract, solely for the protection of all claimants supplying labor and materials in the prosecution of the work. If the contract amount is in excess of $100,000, a Performance Bond shall also be provided, in the amount of the contract, conditioned on the faithful performance of the work in accordance with the plans, specification, and contract documents. Said bond shall be solely for the protection of the City of Fort Worth. 5. PRE -PROPOSAL SITE INVESTIGATION: Prior to filing a response, the Offeror shall examine the site(s) of the work and the details of the requirements set out in these specifications to satisfy itself as to the conditions which will be encountered relating to the character, quality, and quantity of the work to be performed and materials and equipment required. The filing of a response by the Offeror shall be considered evidence that it has complied with these requirements. 6. AMBIGUITY: In case of ambiguity or lack of clearness in stating prices in the proposal, the City reserves the right to adopt the most advantageous construction thereof to the City or to reject the proposal. 7. WAGE RATES: Not less than the prevailing wage rates set forth in the Contract Documents must be paid on this project. 8. POST PROPOSAL - PREAWARD SUBMITTALS: Offerors are required to submit seven (7) hard copies and one (1) electronic copy of the following information to the Architectural Services Office, 401 West 13th Street, Fort Worth, Texas 76102 (phone number 817-392-2586), within three business days subsequent to bid opening (normally by 5:00 PM the next Thursday following a Thursday bid opening) in order to assist City staff in determining the Contractor's capability of performing the work and in meeting City contract requirements: • Contractors Qualification Statement (AIA Form A305), including client references • List of current projects & past projects built within the last 10 years, including owners' and architects' names with contact information for both current & past projects. • Proposed Subcontractors and Suppliers • Project Schedule • Schedule of Values (Breakout by CSI Divisions) • Proof of insurability for Statutory Workers Compensation Insurance Note: Business Equity Documentation is not required 9. PROPOSED SUBCONTRACTORS: Acceptance of the Proposal in no way requires the City to accept the qualifications of the subcontractors. The Subcontractor lists are for use by the City in preparing recommendations for award of the contract. The Contractor must provide and use subcontractors listed unless the City agrees to allow a substitute. 10. DISCREPANCIES AND ADDENDA: Should an Offeror find any discrepancies in the drawings and specifications, or should it be in doubt as to their meaning, it shall notify the City at once. If required, the City will then prepare a written addendum that will be available to all Offerors at the place designated for distribution of the Request for Proposal Documents by the Notice to Offerors. The Contractor is responsible for determining if addenda are available and for securing copies prior to submitting a response to this request for sealed proposals. Oral instructions or decisions unless confirmed by written addenda will not be considered valid, legal or binding. No extras will be authorized because of failure of the contractor to include work called for in the addenda. Instruction to Offerors Page 7 of 33 Crime Lab Full Building Generator Replacement - Proj. #102986 Sept. 2023) Offeror must acknowledge addenda in the Proposal. Failure to acknowledge addenda may cause the Proposal to be ruled non -responsive. It is the Contractor's responsibility to obtain Addenda and include its information in the Proposal. 11. WORKERS COMPENSATION INSURANCE: Offerors will be required to demonstrate that coverage is in effect at time of Award of Contract. Sample Certificate of Insurance, or other proof that Workers Compensation Insurance will be obtained, must be submitted within five working days of bid opening. 12. TAXES: Equipment and materials not consumed by or incorporated into the work are subject to State sales taxes under House Bill 11, enacted August 15, 1991. 13. PERMITS: Contractor shall apply for all City of Fort Worth Permits and for any other permits required by this project. City of Fort Worth Building and Trade Permit fees are waived. Separate permits may be required for each work location. 14. UTILITIES AND IMPACT FEES: The City will pay water and sewer utilities tap fees and impact fees. Unless shown otherwise, the City will coordinate and pay for water and sewer taps and meters to the property line. The Contractor will include all remaining fees from the electrical and gas companies in the Base Proposal. The Contractor will be responsible for coordinating with City and utility companies for installation of utilities. The Contractor will be responsible for all fees for electrical, gas, and other utilities within the property line of the project. Unless indicated otherwise on the plans, the contractor will be responsible for costs and installations from the building side of the water meter and sewer tap. 15. BID DOCUMENTS: Hard copies of bidding documents may be downloaded and printed by the Offeror. 16. MANUFACTURER'S REFERENCE: Catalog, brand names, and manufacturer's references are descriptive, not restrictive. Use of brands of like nature and quality will be considered. Upon request of the architect or contractor, the contractor will submit a full sized sample and/or detailed information as required to allow the architect to determine the acceptability of proposed substitutions. Where equipment has been listed as "no substitute accepted", the City will accept no alternates to the specified equipment. Also, refer to specification's product requirements. 17. TESTING SERVICES: The City shall provide for, independently of the contractor, the inspection services, the testing of construction materials engineering, and the verification testing services necessary for the acceptance of the construction work. 18. PROJECT SCHEDULE: The Project Schedule to be submitted with the Qualification Statement will, at the minimum, include the following: quality control submittals and approvals, mobilization, site preparation, under slab utilities, foundation work, structural erection, interior finish, commissioning, and closeout. The Schedule may be submitted as a table or PERT diagram. 19. STATE FORM 1295 "CERTIFICATE OF INTERESTED PARTIES": Texas Ethics Commission regulations require that the business entity must fill out the Form 1295 on an electronic filing application on the Texas Ethics Commission website (www.ethics.state.tx.us). The business entity that wishes to enter into the contract must supply the completed, signed and notarized Form 1295 to the City. 20. Any oral communications are considered unofficial and non -binding with regard to this proposal. Instruction to Offerors Page 8 of 33 Crime Lab Full Building Generator Replacement - Proj. #102986 Sept. 2023) Isaacs, Don M From: Watts, Nikita N Sent: Friday, November 17, 2023 12:26 PM To: Miles Wilson; Isaacs, Don M Cc: Jones, Jackson M; Madison Ashcroft Subject: RE: General Scope proposal with procurement and schedule updates --City of Ft. Worth Crime Lab Thank you Miles! I will get this moving From: Miles Wilson <Miles.Wilson@sdb.com> Sent: Friday, November 17, 2023 11:36 AM To: Isaacs, Don M <Donald.Isaacs@fortworthtexas.gov> Cc: Jones, Jackson M <Jackson.Jones@fortworthtexas.gov>; Watts, Nikita N <Nikita.Watts@fortworthtexas.gov>; Madison Ashcroft <Madison.Ashcroft@sdb.com> Subject: General Scope proposal with procurement and schedule updates --City of Ft. Worth Crime Lab Importance: High CAUTION: This email originated from outside of the City of Fort Worth ernail system. Do not click any links or open attachments unless you recognize the sender and know the content is safe, Don, Per you request, I have attached a general proposal update that addresses the lead items required during the procurement process for the City Crime Lab on Lancaster Avenue. Also, this attachment addresses the phasing of the project upon receipt to the long lead procured items. We have reviewed all work to be completed within this scope with our subcontractors. We have not included an owner controlled contingency" in our base proposal price. The deposit percentage was based on our base proposal and not inclusive of the owner project contingency. Do not hesitate getting back to me with any questions or clarifications. Respectfully submitted, Miles Wilson SENIOR PROJECT MANAGER OFFICE: (469) 619-3753 1 CELL: (214) 669-9379 8131 LBJ Freeway, Suite 785, Dallas, TX 75251 Miles.Wilson@sdb.com I www.sdb.com 1 CONTRACTING 1 SDBSERVICES certified The content of this email Is confidential for the use of the reclpient(s) only. Nothing herein may be construed to create, amend, or WBENCchange any contractual relationship between SDB, Inc. and any party. +cwa�►�,w�x�+•rwv AZ ROC 070507, ROC 175022 1 CA 1033051 1 OR 195469 1 WA SDBINID861NE rd1 CONTRACTING SDB SERVICES ZU Fort Worth Crime Lab Generator Replacement SDB Representative: Miles Wilson Senior Project Manager SDB, Inc. miles.wilson(@sdb.com M: 214.669.9379 November 17, 2023 Jackson Jones Construction Superintendent Property Management Department City Hall —Tunnel —Room T105 200 Texas Street Foil Worth, Texas 76102 Cell: 817-269-6578 ,IACKSON.JONES[P ORTMFOR'flFFFIXAS.GOV Don [saacs Registered Architect Property Management Department City Ifall—Tunnel—Room T105 200 'Texas Street For Worth, Texas 76102 1' 917.392.8498 M 817.992.0306 Dona Id. I saacs(cD,fortworthtcxas. aov Project Location: City of Fort Worth Crime Lab 3616 E Lancaster Avenue Fort Worth, Texas 76103 1 14951 Airport Parkway, Suite 800 Addison, TX 75001 469-619-3753 www.sdb.com Subiect: Crime Lab Generator Reolacement Gentlemen, SDB Contracting Services, Inc, respectfully submits our lump sum proposal. All work will be performed in accordance with regulations as directed by OSHA, Federal, State, and Local codes. Work will be performed in a manner that is acceptable by industry standards, and as mandated by the final AIA contract agreements between SDB Contracting Services, Inc. and the Property Management Department (City of Fort Worth) SCOPE OF WORK: Provide all plant, labor, equipment and materials and perform all operation necessary to perform the below scope of work. Work shall include the following: I. General Conditions: a. I'lans and specifications by Baird Ilampton Brown---Lnginecring and Surveying. b. Inclusive of the following sheets dated April 10, 2023: Cover sheet, S 1.0, E0.01, ES 1,01, l'DI.01, P1.01 c. All specifications for this project are inclusive in the set of plans on pages referenced in this heading. Sealed 4/12/2023 by Paul Morris d. Project will be completed during normal business hours. e. All weekend and off' work will be coordinated through the Property Management Dept. f. Daily and final clean up included. g. Start time and construction activities to be coordinated with City of Ft. Worth Project ;Manager. h, Provide and install dust protection and protection of adjacent finishes, while work is in progress i. Contractor to provide dumpster, as needed. Location to be coordinated with fire department. J. City of l-orl Worth will provide a "hazardous material investigative report' prior to commencement of any construction activity on -site_ 2. Mobilization and Selective Demolition: a. Furnish dumpster, temporary restroom facility, and temporary fencing around equipment, as needed- b. Ad,jacent finishes will be protected for demolition and construction. c. Demo existing concrete pad and related conduits and feeds to existing Gen -Set Unit, 3. Emuiiiment: a. New 1200 amp circuit breaker. b. New 1200 amp A`1;5 switch. c, New panel EMS3 d. New docking station and NSGD on outside wall per print. e. Relocate existing circuits for battery charger, jacket heater and annunciator panel. f. Provide wire for new Gen -Set and temporary Gen -Set. 21 4951 Airport Parkway, Suite 800 Addison, TX 75Q01 469-619-3753 www sdb corn 4. Concrete a, form, place, and finish concrete at new and temporary Gen -Set locations. S. Plumbing a. Extend gas connections to both permanent and temporary Gen -Set units, b. Gas disconnections as required. G. I2eceivine and Relocation: a. Receive new Gen -Set unit and place on new concrete pad b. Relocate lemporary unit C. Transport existing unit to new location with a lifteen (15) mile radius (crating exclude(l). 7. Clarifications: a. Contractor shall have full access to area to complete the pro.jecl. b. Proposal includes regular business liours for working. c. Anticipated duration of actual site construction —ten (10) weeks frotn lime of silt mobilization, not including material lead times d. Current lead time of materials after submittal approvals 6-8 weeks e. All unforeseen items or conditions that need to be removed or modified will require the written approval of the designated City of Fort Worth representative prior to commencement of work. f. All flabricated items to be reviewed and approved prior to release for fabrication. g. Coordination meeting will be required prior to any electrical and plumbing shutdowns. h. No wet pipe fire sprinkler system modifications included in this scope of work. 8. Exclusions: a. Excludes any allowances not specifically proposed here. b. Permit cost c. Fnginccring ofany type d. Excludes third party consultant or air monitoring Ibr dust controls. e. Excludes any abatement or remediation and testing. C Owner will address concealed contaminated material within walls, ceilings, chases, etc. g. Excludes new or relocation of existing wet pipe fire sprinkler. h. Excludes low voltage cabling and equipment not specified on drawings. i. No work in existing facility areas not specifically addressed on referenced drawings. J. Plaster ceilings, lath, support framing and related items concealed above the suspended grid ceiling. k, Removal of multiple layers of wall, ceiling, or flooring materials. Pricing is for single layers only. 1. Removal or relocation of any owner furnishings, personal items, or monitors. m. New security cameras it. Additional fire alarm devices o. Painting of ductwork (materials not specified on drawings) p. Work on I IVAC is limited to items shown on drawings. No additional work included. q. Gas or condensate lines not specifically related to Gen -Set units. r. Any controls, energy management requirements, fire alarm tie-ins, or upgrades. s. Repairs or painting of banjoist, ceiling deck, existing doors and franics. t. Replacement of existing cameras u. removal or relocation of any items not addressed in the project drawings or specifications. v. Coordination study 3 14951 Airport Parkway, Suite 800 Addison, TX 75001 469-619-3753 www.sdb com 9. Project milestones: Procurement Phase January 2024 - January 2025 Notice to Proceed Submittals/Shop Drawings Release of Fabricated Equipment Construction Phase September 2024 - March 2025 Site fencing Temp. Gen -Set Pad Coordinating Meeting with Crime Lab and Property Management Relocate existing Gen -Set to new pad location Demo old Gen -Set pad Form, Rough -in, Pour new Gen -Set pad Extend Gas and Power lines for new Gen -Set Set docking station, breakers, ATS Coordination meeting prior to final switch over Switch Over* Surat-up/Commissioning Disconnect/'Transport old Gen -Set unit Punch Demobilize 10. Pre-consh•action Procurement Items: a. (1) NG-500 500kW Natural Gas Driven LJ Power Generator b. (1) Steel, 150MPI-I Rated, Sound Attenuated Enclosure W/ Stainless Steel Lockable Hardware, Standard bevel 2 Enclosure, 73dba « 2311 c. (1) SBDS 800 Amp Single Breaker, Dual Purpose Docking Station d, ( I )ATS 1200 Amp, Bypass Isolation ATS in Nema 311 Enclosure Matching Specifications C. Wiring 11. PROPOSAL SUMMARY PRICING: Base Bid Cost for Project: $896,727.88 Allowance— Owner Construction Contingency: $ 67,254.59 Total Base Bid Cost for Project: $963,982.47 12. PROCUREMENT COST OF ITEMS LISTED IN SECTION 49 (Above) Deposit for long lead item procurement: (12.5%. Deposit) 5112,091.00 Sincerely, Senior Project Manager SDB, Inc, 4 14951 Airport Parkway, Suite 800 Addison, TX 75001 469.619-3753 www.sdb.com 8131 LBJ Fwy #785 Dallas, TX 75251 FORT WORTH., CONTRACTING SDuISERVICES www.sdb.com PROPOSAL TO: MR. DAVID COOKE CITY MANAGER ATTN: PURCHASING OFFICE 200 TEXAS STREET CITY OF FORT WORTH, TEXAS FOR: Crime Lab Full Building Generator Replacement 3616 E. Lancaster Ave. Fort Worth, Texas 76103 Project PMD2023-10 City Project # 102986 Pursuant to the foregoing "Instructions to Offerors," the undersigned has thoroughly examined the plans specifications and the site, understands the amount of work to be done, and hereby proposes to do all the work and furnish all labor, equipment and materials necessary to fully complete all the work as provided in the plans and specifications, and subject to the inspection and approval of the Director of Transportation and Public Works of the City of Fort Worth Upon acceptance of this Proposal by the City Council, the bidder is bound to execute a contract and, if the contract amount exceeds $25,000.00, furnish acceptable Performance andlor Payment Bonds approved by the City of Fort Worth for performing and completing the Work within the time stated and for the following sum, to wit: DESCRIPTION OF ITEMS $ 896,727.88 Base Proposal 400 Calendar Days $ 67.2S4.59 Owner's Contingency Allowance (7.5%) added to Base Proposal (This Allowance amount is not included in the Base Proposal but is added to the Base Proposal. Only the Owner will approve the use of this Allowance during construction, Any Allowance remaining at the end of construction will be retained by the City of Fort Worth). $ 963,982.47 Base Proposal Plus Owner's Contingency Allowance ALTERNATES — NOT USED UNIT PRICES — NOT USED The undersigned agrees to complete the Work within the calendar days specified above after the date of Notice to Proceed. A Project Schedule will be submitted as required in the Instructions to Offeror, The Clty reserves the right to accept or reject any and all bids or any combination thereof proposed for the above work. The undersigned assures that its employees and applicants for employment and those of any labor organization, subcontractors or employment agency in either furnishing or referring employee applicants to the undersigned are not discriminated against as prohibited by the terms of City Ordinance 7278 as amended by City Ordinance 7400 (Fort Worth City Code Section 13A-21 through 13A-29). Residency of Offerors: The 1985 Session of the Texas Legislature passed house Bill 620 relative to the award of contracts to non-resident bidders. The law provides that, in order to be awarded a contract as low bidder, non-resident bidders (out of state contractors whose corporate offices or principal place of business are outside of the State of Texas) that bid projects for construction, improvements, supplies or services in Texas at an amount lower than the lowest Texas resident bidder by the same amount that Texas resident bidder would be required to underbid a non-resident bidder in order to obtain a comparable contract in the Instruction to Offerors Page 9 of 32 Crime Lab Full Building Generator Replacement (July2023) state in which the non-resident's principal place of business is located. The appropriate blanks in Section A must be filled out by all non-resident bidders in order for your bid to meet specifications, The failure of out of state or non-resident bidders to complete the forms may disqualify that bidder. Resident bidders must check the box in Section B. A. 1_1 Non-resident vendors in (give state), our principal place of business, are required to be percent lower than resident bidders by state law. Ixl Non-resident vendors in Arizona (give state), are not required to underbid resident bidders. B 1_1 Our principal place of business or corporate offices are in the State of Texas. Within ten (10) days of receipt of notice of acceptance of this bid, the successful bidder will execute the formal contract and will deliver approved Performance and Payment Bonds for the faithful performance of this contact. The attached deposit check in the sum of N/A Dollars ($ N/A ) is to become the property of the City of Fort Worth, Texas, or the attached Bidder's Bond is to be forfeited in the event the contract and bonds are not executed within the time set forth, as liquidated damages for delay and additional work caused thereby. BUSINESS EQUITY PROVISION for proposals in excess of $100,000.00: Business Equity Provisions are not required Respectfully submitted, SDB, Inc. dba SDB Contracting Services Company Name By: Signature Angeline Schmidt Printed Name of Principal Address: 8131 L8J Freewav, Suite 785 Street Dallas, TX City Phone: (469) 619-3753 Fax: _1/A Email: angie.schmidt@sdb.com sdb.com Receipt is acknowledged of the following addenda: Chief Executive Officer Title Addendum No. 1: 8/21/2023 Addendum No. 2: 8/25/2023 Addendum No C Addendum No. D: 75251 Zip Instruction to Offerors Page 10 of 32 Crime Lab Full Building Generator Replacement (July2023) CONFLICT OF INTEREST AFFIDAVIT Each bidder, offeror, or respondent (hereinafter also referred to as "you") to a City of Fort Worth (also referred to as "City") procurement are required to complete Conflict of Interest Questionnaire (the attached CIQ Form) and Local Government Officer Conflicts Disclosure Statement ((he attached CIS Form) below pursuant to state law. This affidavit will certify that the Bidder has on file with the City Secretary the required documentation and is eligible to bid on City Work, The referenced forms may be downloaded from the website links provided below. htto://\YWw.ethics.Stitte.IX.us/f'Orms/CIO•vdf httnAN"k,w.etIli cs.state IX.uS/forms/CIS.ndf XD CIQ Form is on file with City Secretary 0 CIQ Form is being provided to the City Secretary XD CIS Form is on File with City Secretary a CIS Form is being provided to the City Secretary BIDDER: SDB, Inc. dba SDB Contracting Services Company 8131 LBJ Freeway, Suite 785 Address Dallas, TX 75251 City/State/Zip By; Angeline Schmidt (Please Print) Title: Chief Executive Officer (Please Print) Instruction to Offerors Page 12 of 33 WRMC Amon Carter Exhibit Hall Door Replacement (January 2023) CONFLICT OF INTEREST QUESTIONNAIRE FORM CIQ For vendor doing business with local governmental entity This questionnaire reflects changes made to the law by H.B. 23, 84th Leg., Regular Session. OFFICEUSEONLY This questionnaire Is being filed In accordance with Chapter 176, Local Government Code, by a vendor who Date Received has a business relationship as defined by Section 176.001(1-a) with a local governmental entity and the vendor meets requirements under Section 176.006(a). By law this questionnaire must be filed with the records administrator of the local governmental entity not later than the 7th business day after the date the vendor becomes aware of facts that require the statement to be filed. See Section 176.006(a 1), Local Government Code. A vendor commits an offense if the offense under this section Is a Misr J Name of vendor who has a N/A ?J Check this box if you thatyou file an updated completed questlonna after the date on which you became aware th. J Name of local government oiiiceraoouiwnom ine inrormailon is oeing alsciosea. Name of Officer J Describe each employment or other business relationship with the local government officer, or a family member of the officer, as described by Section 176.003(a)(2)(A). Also describe any family relationship with the local government officer. Complete subparts A and B for each employment or business relationship described. Attach additional pages to this Form CIQ as necessary. A. Is the local government officer or a family member of the officer receiving or likely to receive taxable income, other than investment income, from the vendor? a Yes F7 No B. Is the vendor receiving or likely to receive taxable income, other than investment income, from or at the direction of the local government officer or a family member of the officer AND the taxable income Is not received from the local governmental entity? F7 Yes a No J Describe each employment or business relationship thatthe vendor named in Section 1 maintains with a corporation or other business entity with respect to which the local government officer serves as an officer or director, or holds an ownership interest of one percent ormore. 11 ❑Check this box If the vendor has given the local government officer or a family member of the officer one or more gifts as described in Section 176.003(a)(2)(B), excluding gifts described in Section 176.003(a-1). 71 Signature of vendor doing business with the governmental entity Rate In15ttimtkawi)#Ad@ fftpftxas Ethics Commission www.ethics,stale.lx.us Page 13 of 33Revised 1113012015 WRMC Amon Carter Exhibit Hall Door Replacement (,January 2023) CONFLICT OF INTEREST QUESTIONNAIRE For vendor doing business with local governmental entity Acomplete copy of Chapter 176 of the Local Government Code may be found at http //www,statutes.legis.state.tx us/ Docs/LG/htm/LG,176.htm. For easy reference, below are some of the sections cited on this form. Local Government Code 6176.0010-al: "Business relationship" means a connection between two or more parties based on commercial activity of one of the parties. The term does not include a connection based on: (A) a transaction that is subject to rate or fee regulation by a federal, state, or local governmental entity or an agency of a federal, state, or local governmental entity; (B) a transaction conducted at a price and subject to terms available to the public; or (C) a purchase or lease of goods or services from a person that is chartered by a state or federal agency and that is subject to regular examination by, and reporting to, that agency, 1,1 LOCAL GOVERNMENT CODES 176.003(A)(2)(Al AND (B): (a) A local government officer shall file a conflicts disclosure statement with respect to a vendor if: 1.4 (2) the vendor: (A) has an employment or other business relationship with the local government officer or a family member of the officer that results in the officer or family member receiving taxable income, other than investment income, that exceeds $2,500 during the 12-month period preceding the date that the officer becomes aware that (i) a contract between the local governmental entity and vendor has been executed or (ii) the local governmental entity is considering entering into a contract with the vendor, (B) has given to the local government officer or a family member of the officer one or more gifts that have an aggregate value ofmorethan $100 in the 12-month period preceding the date the officer becomes aware that: (i) a contract between the local governmental entity and vendor has been executed; or (ii) the local governmental entity Is considering entering into a contract with the vendor. 1,2 LOCAL GOVERNMENT CODE 6176.006(A) AND (A-1) (a) A vendor shall file a completed conflict of interest questionnaire if the vendor has a business relationship with a local governmental entity and: (1) has an employment or other business relationship with a local government officer of that local governmental entity, or a family member of the officer, described by Section 176.003(a)(2)(A); (2) has given a local government officer of that local governmental entity, or a family member of the officer, one or more giftswith the aggregate value specified by Section 176.003(a)(2)(B), excluding any gift described by Section 176.003(a-1); or (3) has a family relationship with a local government officer of that local governmental entity. (a-1) The completed con 11ictofintereslquestionnaire mustlie Iiled wit[it lie appropriate recordsadministralornot later IhEui the seventh husiness day after the later of- (1) the date that the vendor: (A) begins discussions or negotiations to enter into a contract with the local governmental entity; or (B) submits to the local governmental entity an application, response to a request for proposals or bids, correspondence, or another writing related to a potential contract with the local governmental entity; or (2) the date the vendor becomes aware: (A) of an employment or other business relationship with a local government officer, or a family member of the officer, described by Subsection (a); (B) that the vendor has given one or more gifts described by Subsection (a); or (C) of a family relationship with a local government officer. Instruction to offerors Page 14 of 33 WRMC Amon Carter Exhibit Wall Door Replacement (January 2023) LOCAL GOVERNMENT OFFICER FORM CIS CONFLICTS DISCLOSURE STATEMENT (Instructions forcompleting and filing this form are provided on the next page.) This questionnaire reflects changes made to the law by H.B. 23, 84th Leg., Regular Session. OFFICE USEONLY This is the notice to the appropriate local governmental entity that the following local government officer has become aware of facts that require the officer to file this statement Date Received in accordance with Chapter 176, Local Government Code. ] Name of Local Government Officer J Office Held J Name of vendor describer N/A JDescription of the nature and extent of each employment or other business relationship and each family relationship with vendor named In item 3. JList gifts accepted by the local government officer and any family member, if aggregate value of the gifts accepted from vendor named in item 3 exceeds $100 during the 12-month period described by Section 176.003(a)(2)(B). Date Gift Accepted Description of Gift Date Gift Accepted Description of Gift Date Gift Accepted Description of Gift (attach additional forms as necessary) J AFFIDAVIT I swear under penalty of perjury that the above statement Is true and correct. I acknowledge that the disclosure applies to each family member (as defined by Section 176.001(2), Local Government Code) of this local government officer I also acknowledge that this statement covers the 12-month period described by Section 176.003(a)(2)(B), Local Government Code. Signature of Local Government Officer AFFIX NOTARY STAMP / SEAL ABOVE Sworn to and subscribed before me, by the said of , 20 , to certify which, witness my hand and seal of office. Signature of officer administering oath Printed name of officer administering oath Instruction to Offerors VV 9R J AMbNt'+AvrTLexmibfi4iflPd'cRffIf IP.'bment (January 2023) www.ethics.slate.lx.us this the day Title of officer administering oath Page 15 of 33 Revised 11130/2015 i nr'Al GOVERNMENI OFFICER CON11=1 trrc r-11QC.1 QSI IRP SIAXEM017 Section 176.003 of the Local Government Code requires certain local government officers to file this form. A "local government officer" is defined as a member of the governing body of a local governmental entity; a director, superintendent, administrator, president, or other person designated as the executive officer of a local governmental entity; or an agent of a local governmental entitywho exercises discretion in the planning, recommending, selecting, or contracting of a vendor. This form is required to be filed with the records administrator of the local governmental entity not later than 5 p.m. on the seventh business day afterthedate on which the officer becomes aware of the facts thatrequire the filing of this statement. A local government officer commits an offense if the officerknowi ngly violates Section 176.003, Local Government Code. An offense under this section is a misdemeanor. Refer to chapter 176 of the Local Government Code for detailed information regarding the requirement to file this form. PART 2 - INSTRUCTIONS FOR COMPLETING THIS FORM The following numbers correspond to the numbered boxes on the other side. 1. Name of Local Government Officer. Enter the name of the local government officer filing this statement. 2. Office Held. Enter the name of the office held by the local government officerfiling this statement. 3. Name of vendor described by Sections 176.001(7) and 176.003(a), Local Government Code. Enter the name of the vendor described by Section 176,001(7), Local Government Code, If the vendor: a) has an employment or other business relationship with the local government officer or a family member of the officer as described by Section 176.003(a)(2)(A), Local Government Code; b) has given to the local government officer or a family member of the officer one or more gifts as described by Section 176.003(a)(2)(B), Local Government Code; or c) has a family relationship with the local government officer as defined by Section 176.001(2-a), Local Government Code. 4. Description of the nature and extent of each employment or other business relationship and each family relationship with vendor named in item 3. Describe the nature and extent of the employment or other business relationship the vendor has with the local government officer or a family member of the officer as described by Section 176.003(a)(2)(A), Local Government Code, and each family relationship the vendor has with the local government officer as defined by Section 176,001(2-a), Local Government Code. 5. List gifts accepted, if the aggregate value of the gifts accepted from vendor named in item 3 exceeds $100. List gifts accepted during the 12-month period (described by Section 176.003(a)(2)(B), Local Government Code) by the local government officer or family member of the officerfrom the vendor named in item 3 that in the aggregate exceed $100 In value, 6. Affidavit. Signature of local governmentofficer. Local Government Code & 176.001(2-al: "Family relationship" means a relationship between a person and another person within the third degree by consanguinity or the second degree by affinity, as those terms are defined by Subchapter B, Chapter 573, Government Code, PART 3 - LOCAL GCUvtKiVwiti4 t wut 4110 b.UW(A)(2)(Al: (a) A local government officer shall file a conflicts disclosure statement with respect to a vendor if: (2) the vendor: (A) has an employment or other business relationship with the local government officer or a family member of the officer that results in the officer or family member receiving taxable income, other than investment income, that exceeds $2,500 during the 12-month period preceding the date that the officer becomes aware that: (i) a contract between the local governmental entity and vendor has been executed; or (ii) the local governmental entity is considering entering into a contract with the vendor. Instruction to Offerors WRMC Amon Carter Exhibit Hall Door Replacement (January 2023) Page 16 of 33 Texas Sales and Use Tax Exemption Certification This certificate does not require a number to be valid. Name of purchaser, firm or agency City of Fort Worth, Texas Address (Street & number, P.O. Box or Route number) Phone (Area code and number) 200 Texas Street 817-392-8360 City, State, ZIP code Fort Worth, Texas 76102 I, the purchaser named above, claim an exemption from payment of sales and use taxes (for the purchase of taxable items described below or on the attached order or invoice) from: Seller: All Vendors Street address: City, State, ZIP cor<a- Description of items to be purchased or on the attached order or invoice: All items. Purchaser acknowledoes that this Certificate cannot be used for the Durchase, lease or rental of a motor vehicle - Purchaser claims this exemption for the following reason: Municipality, Governmental Entity I understand that I will be liable for payment of all state and local sales or use taxes which may become due for failure to comply with the provisions of the Tax Code andlor all applicable law. I understand thatitisa criminal offense togive an exemption certificate to the sellerfortaxable items thatl know, at the time ofpurchase, will beused in amanner otherthan thatexpressedin this certificate, and depending on the amountoftax evaded, the offense mayrange from a Class C misdemeanor to a felony of the second degree. Purchaser Title Date Sign �� �/ Finance DirectorlCFO TWVM j ;16j X18 NOTE: This certificate cannot be issued for the purchase, lease, or rental of a motor vehicle. THIS CERTIFICATE DOES NOT REQUIRE A NUMBER TO BE VALID. Sales and Use Tax "Exemption Numbers" or'Tax Exempt" Numbers do not exist. This certificate should be furnished to the supplier. Do not send the completed certificate to the Comptroller of Public Accounts. Instruction to Offerors Page 16 of 32 Crime Lab Full Building Generator Replacement (July2023) 2013 PREVAILING WAGE RATES Commercial Construction Projects $ AC Mechanic Helper 13.67 $ Acoustical Ceiling Installer 16.83 Acoustical Ceiling Installer Helper 12$70 $ Bricklayer/Stone Mason 19.45 Bricklayer/Stone Mason Trainee 13$31 $ Bricklayer/Stone Mason Helper 10.91 $ Carpenter 17.75 $ Carpenter Helper 14.32 Concrete Cutter/Sawer 17.00 Concrete Cutter/Sawer Helper 11.00 $ Concrete Finisher 15.77 $ Concrete Finisher Helper 11.00 $ Concrete Form Builder 15.27 Concrete Form Builder Helper 11.00 $ Drywall Mechanic 15.36 $ Drywall Helper 12.54 $ Drywall Taper 15.00 $ Drywall Taper Helper 11.50 $ Electrician (Journeyman) 19.63 $ Electrician Apprentice (Helper) 15.64 $ Electronic Technician 20.00 $ Floor Layer 18.00 $ Floor Layer Helper 10.00 Instruction to Offerors Page 17 of 33 Crime Lab Full Building Generator Replacement - Proj. #102986 Sept. 2023) $ Glazier 21.03 $ Glazier Helper 12.81 $ Insulator 16.59 $ Insulator Helper 11.21 $ Laborer Common 10.89 $ Laborer Skilled 14.15 $ Lather 12.99 $ Metal Building Assembler 16.00 $ Metal Building Assembler Helper 12.00 Metal Installer (Miscellaneous) 13.00 $ Metal Installer Helper (Miscellaneous) 11.00 $ Metal Stud Framer 16.12 $ Metal Stud Framer Helper 12.54 $ Painter 16.44 $ Painter Helper 9.98 $ Pipefitter 21.22 $ Pipefitter Helper 15.39 $ Plasterer 16.17 $ Plasterer Helper 12.85 $ Plumber 21.98 $ Plumber Helper 15.85 $ Reinforcing Steel Setter 12.87 Reinforcing Steel Setter Helper 11.08 $ Roofer 16.90 $ Roofer Helper 11.15 $ Sheet Metal Worker 16.35 $ Sheet Metal Worker Helper 13.11 Instruction to Offerors Page 18 of 33 Crime Lab Full Building Generator Replacement - Proj. #102986 Sept. 2023) $ Sprinkler System Installer 19.17 $ Sprinkler System Installer Helper 14.15 $ Steel Worker Structural 17.00 Steel Worker Structural Helper 13$74 $ Waterproofer 15.00 Equipment Operators Concrete Pump 18$50 Crane, Clamshell, Backhoe, Derrick, D'Line Shovel 19$31 $ Forklift 16.45 Foundation Drill Operator 22$50 $ Front End Loader 16.97 $ Truck Driver 16.77 $ Welder 19.96 $ Welder Helper 13.00 The prevailing wage rates shown for Commercial construction projects were based on a salary survey conducted and published by the North Texas Construction Industry (Fall 2012) Independently compiled by the Lane Gorman Trubitt, PLLC Construction Group. The descriptions for the classifications listed are provided on the TEXO's (The Construction Association) website. www.texoassociation.org/Chapter/wagerates.asp Instruction to Offerors Page 19 of 33 Crime Lab Full Building Generator Replacement - Proj. #102986 Sept. 2023) CITY OF FORT WORTH WEATHER TABLE Average Days Month of Inches of Rainfall RainfSnowlice January 6 2.51 February 7 2.23 March 9 3.49 April 7 2.97 May 14 4.55 June 8 3.31 July 4 1_83 August 5 1.89 September 5 2.34 October 7 3.65 Novenlber 7 2.73 December 6 2.34 Annually 81 33.81 (1) Mean number of days precipitation of 0.01 " or more or 10 snow{ce (2) Average normal precipitation, in inches This table is based on information reported from Dallas -Fart Worth Intemational Airport, Texas. La4tude 32 deg 54 min north, longitude 97 deg 02 min west, elevation (ground) 551 ft. Average number of days of rain, snow, and ice days are based on records covering 21 yea . PrecipbUon is based on recorded information from 1996through 2016 period. This table is to be used as a baisis for calculation of excess rain or weather days for projects with d uraUon in calendar days. If the site records Mali cate that the Contractor was unable to carry out operations due to weather. it is counted as a weather day. If the norm ber of weather days exceeds the number of average rain days plus the snowfce days for the contact duration; the contract wHl be adjusted by Change Order_ Fort Worth Weatheriab:e 24 April 2U17 Instruction to Offerors Page 20 of 33 Crime Lab Full Building Generator Replacement - Proj. #102986 Sept. 2023) City of Fort Worth, Texas Property Management Department Facilities Management Group/Architectural Services Division GENERAL CONDITIONS OF THE CONTRACT FOR CONSTRUCTION LUMP SUM CONTRACT SECTION A DEFINITIONS, PROCEDURES AND INTERPRETATIONS A-1 CONTRACT DOCUMENTS: By the term Contract Documents is meant all of the written and drawn documents setting forth or affecting the rights of the parties, including but not necessarily limited to, the Contract, Notice to Bidders, Proposal, General Conditions, Special Conditions, Specifications, Plans, Bonds and all Addenda, Amendments signed by all parties, Change Orders, written Interpretations and any written Field Order for a minor change in the Work. A-2 ENTIRE AGREEMENT: The Contract Documents represent the entire agreement between the Parties, and no prior or contemporaneous, oral or written agreements, instruments or negotiations shall be construed as altering the terms and effects of the Contract Documents. After being executed, the Contract Documents can be changed only by a written Amendment signed by the Contractor and the Owner, or Change Order, or by a written Field Order for a minor change. A-3 WORK: By the term Work is meant all labor, supervision, materials and equipment necessary to be used or incorporated in order to produce the construction required by Contract Documents. A-4 EXECUTION OF THE CONTRACT DOCUMENTS: The Contract Documents shall be executed in four originals, with all required attachments, including required bonds and insurance certificates, by the Contractor and the Owner in such form as may be prescribed by law and returned to the Owner within ten business days of notification to Contractor. Failure to execute contracts and provide required enclosures will be grounds for revocation of award and taking of Bid Bond. A-5 FAMILIARITY WITH PROPOSED WORK: Before filing a Proposal, the Contractor shall examine carefully the, plans, specifications, special provisions, and the form of contract to be entered into for the work contemplated. He shall examine the site of work and satisfy himself as to the conditions that will be encountered relating to the character, quality and quantity of work to be performed and materials to be furnished. The filing of a bid by the bidder shall be considered evidence that he has complied with these requirements and has accepted the site as suitable for the work. Claims for additional compensation due to variations between conditions actually encountered in construction and as indicated by the plans will not be allowed. A-6 ONE UNIFIED CONTRACT: Insofar as possible, the Contract Documents will be bound together and executed as a single unified Contract. The intention of the Contract Documents being to provide for all labor, supervision, materials, equipment and other items necessary for the proper execution and completion of the Work. Words that have well -recognized technical or trade meanings are used herein in accordance with such recognized meanings. A-7 DIVISION OF WORK: The arrangement of Drawings and/or Specifications into Divisions, Sections, Articles, or other Subdivisions shall not be binding upon the Contractor in dividing the work among Subcontractors or Trades. A-8 INTERPRETATIONS: In the event of inconsistency in the contract documents, the following sequence for interpretation shall be used in order of precedence: Change Orders and/or Field Orders (by date of issuance); Addenda (by date of issuance); Drawings; Notes and dimensions on Drawings; Technical Specifications; Special Provisions; Supplementary General Conditions; General Conditions; and Construction Contract. The Architect will furnish such Interpretations of the Plans and Specifications as may be necessary for the proper execution or progress of the work. Such Interpretations shall be furnished at the instance of the Architect or at the request of the Contractor, or Owner, and will be issued with reasonable promptness and at such times and in accordance with such schedule as may be agreed upon. Such Interpretations shall be consistent with the purposes and intent of the Plans and Specifications and may be effected by Field Order. In the event of any dispute between any of the parties to the Contract and the Architect or each other involving the interpretation of the Contract Documents, the evaluation of work or materials performed or furnished by the Architect Contractor, or any subcontractor or materialsman, or involving any question of fault or liability of any party, the decision of the Owner shall be final and binding. A-9 CORRELATION AND INTENT: In general, the drawings indicate dimension, locations, positions, quantities, and kinds of construction; the specifications indicate the quality and construction procedures required. Work indicated on the drawings and not specified of vice -versa, shall be furnished as though set forth in both. Work not detailed, marked or specified shall be the same as similar parts that are detailed, marked or specified. If the drawings are in conflict or conflict with the specifications the better quality or greater quantity or work or materials shall be estimated and shall be furnished or included. Dimensions on drawings shall take precedence over small-scale drawings. Drawings showing locations of equipment, piping, ductwork, electrical apparatus, etc., are diagrammatic and job conditions may not allow installation in the exact location shown. Relocation shall not occur without the Architects approval. OFFICIAL RECORD General Conditions of the Contract for Construction Lump Sum Contract CITY SECRETARY page 1 of 28 CFW PMD — Crime Lab Full Building Generator Replacement — Project #102986 FT. WORTH, TX August 2023 A-10 COPIES OF WORKING DRAWINGS AND SPECIFICATIONS: The Architect will furnish to Contractor electronic working Drawings and Specifications. Contractor shall pay the cost of reproduction for all other copies of Drawings and Specifications furnished to him. All Drawings, Specifications and copies thereof furnished by the Owner or the Architect are and shall remain the property of the Owner. They are not to be used on any other project and, with the exception of one Contract set for each Party to the Contract, are to be returned to the Owner on request at the completion of the work. A-11 MINORITY BUSINESS ENTERPRISE (MBE) POLICY: As of June 1, 2012, The City of Fort Worth has implemented Business Diversity Ordinance (BDO) to reflect the City's availability and disparity study findings and recommendations. During this transition period, interested Offerors must obtain an MBE listing from the M/WBE Office at 817-212-2674. This will ensure that the MBE listings reflect only those currently certified by the North Central Texas Regional Certification Agency (NCTRCA) located in the six (6)-county geographic marketplace that have been accepted by the City. The City's geographic marketplace includes the counties of: Tarrant, Dallas, Denton, Johnson, Parker and Wise. Offerors are stronoly encouraaed to confirm that each MBE that it intends to use is located in the geographic marketplace that will be counted towards the established goal. The City of Fort Worth has goals for the participation of Minority Business Enterprises (MBE) in City contracts. Compliance with the policies designed to meet these goals is mandatory in order to be considered a responsive bidder. The City policy and procedures to be followed in submitting proposals are included. The City of Fort Worth MBE Program will take precedence over other subcontractor utilization programs on Block Grant and other federally funded Projects. A-12 AGE: In accordance with the policy ("Policy") of the Executive Branch of the federal government, Contractor covenants that neither it nor any of its officers, members, agents, employees, program participants or subcontractors, while engaged in performing this contract, shall, in connection with the employment, advancement or discharge of employees or in connection with the terms, conditions or privileges of their employment, discriminate against persons because of their age except on the basis of a bona fide occupational qualification, retirement plan or statutory requirement. Contractor further covenants that neither it nor its officers, members, agents, employees, subcontractors, program participants, or persons acting on their behalf, shall specify, in solicitations or advertisements for employees to work on this contract, a maximum age limit for such employment unless the specified maximum age limit is based upon a bona fide occupational qualification, retirement plan or statutory equipment. Contractor warrants it will fully comply with the Policy and will defend, indemnify and hold City harmless against any claims or allegations asserted by third parties or subcontractor against City arising out of Contractor's and/or its subcontractors' alleged failure to comply with the above referenced Policy concerning age discrimination in the performance of this agreement. A-13 DISABILITY: In accordance with the provisions of the Americans With Disabilities Act of 1990 ("ADA"), Contractor warrants that it and any and all of its subcontractors will not unlawfully discriminate on the basis of disability in the provision of services to the general public, nor in the availability, terms and/or conditions of employment for applicants for employment with, or employees of Contractor or any of its subcontractors. Contractor warrants it will fully comply with ADA provisions and any other applicable federal, state and local laws concerning disability and will defend, indemnify and hold City harmless against any claims or allegations asserted by third parties or subcontractors against City arising out of Contractor's and/or its subcontractors' alleged failure to comply with the above -referenced laws concerning disability discrimination in the performance of this agreement. A-14 IMMIGRATION NATIONALITY ACT: City actively supports the Immigration & Nationality Act (INA) which includes provisions addressing employment eligibility, employment verification, and nondiscrimination. Vendor shall verify the identity and employment eligibility of all employees who perform work under this Agreement. Vendor shall complete the Employment Eligibility Verification Form (1-9), maintain photocopies of all supporting employment eligibility and identity documentation for all employees, and upon request, provide City with copies of all 1-9 forms and supporting eligibility documentation for each employee who performs work under this Agreement. Vendor shall establish appropriate procedures and controls so that no services will be performed by any employee who is not legally eligible to perform such services. Vendor shall provide City with a certification letter that it has complied with the verification requirements required by this Agreement. Vendor shall indemnify City from any penalties or liabilities due to violations of this provision. City shall have the right to immediately terminate this Agreement for violations of this provision by Vendor. A-15 HOUSE BILL 89: Contractor acknowledges that in accordance with Chapter 2270 of the Texas Government Code, the City is prohibited from entering into a contract with a company for goods or services unless the contract contains a written verification from the company that it: (1) does not boycott Israel; and (2) will not boycott Israel during the term of the contract. The terms "boycott Israel" and "company" shall have the meanings ascribed to those terms in Section 808.001 of the Texas Government Code. By signing this contract, Contractor certifies that Contractor's signature provides written verification to the City that Contractor: (1) does not boycott Israel; and (2) will not boycott Israel during the term of the contract. General Conditions of the Contract for Construction Lump Sum Contract Page 2 of 28 CFW PMD — Crime Lab Full Building Generator Replacement — Project #102986 August 2023 SECTION B IDENTITY OF ARCHITECT B-1 CONTRACT ADMINISTRATION: The Architect is the person or person lawfully licensed to practice architecture identified as such in the Agreement. The Architect is retained by the Owner to prepare the construction documents and represent the Owner during the construction phase as directed by the Owner. B-2 DUTIES OF THE ARCHITECT: As used herein, the term Architect means the Architect or his authorized representative. Nothing contained in these Contract Documents shall create any privity of Contract between the Architect and the Contractor. B-3 ARCHITECT AS REPRESENTATIVE OF THE OWNER: The Architect will provide general administration of the Contract on behalf of the Owner and will have authority to act as the representative of the Owner to the extent provided in the Contract Documents unless changed in writing by the Owner. The Architect will be available for conferences and consultations with the Owner or the Contractor at all reasonable times. B-4 ACCESS TO JOB SITES: The Architect shall at all times have access to the Work whenever it is in preparation and progress. The Contractor shall provide facilities for such access so the Architect may perform its assigned functions under the Contract Documents. The Architect will make periodic visits to the Site to familiarize himself with the progress and quality of the work and to determine if the work is proceeding in accordance with the Contract documents. On the basis of on -site observations, the Architect will keep the Owner informed of the progress of the Work and will endeavor to guard the Owner against defects and deficiencies in the Work of the Contractor. Based upon such observations and the Contractor's applications for payments, the Architect will make determinations and recommendations concerning the amounts owing to the Contractor and will issue certificates for payment amounts. B-5 INTERPRETATIONS: The Architect will be, in the first instance, the interpreter of the requirements of the Plans and Specifications and the judge of the performance thereunder by the Contractor, subject to the final decision of the Owner. The Architect's decisions in matters relating to artistic effect will be final if consistent with the intent of the Contract Documents. B-6 AUTHORITY TO STOP WORK: The Architect will have authority to reject work that does not conform to the Plans and Specifications. In addition, whenever, in its reasonable opinion, the Architect considers it necessary or advisable in order to insure the proper realization of the intent of the Plans and Specifications, the Architect will have authority to require the Contractor to stop the Work or any portion thereof, or to require special inspection or testing of the Work whether or not such Work be then fabricated, installed or completed. B-7 MISCELLANEOUS Shop Drawings. Submittals and Samples: The Architect will review Shop Drawings, Submittals and Samples. Two copies of each approved Shop Drawing and submittal will be provided to the Owner by the Architect. Three copies will be returned to the Contractor. Change Orders: Change Orders, Owners Contingence Allowance forms, and Field Orders for Minor Changes in the work will be issued by the Owner through the Architect. Guarantees: The Architect will receive all written guarantees and related documents required of the Contractor. Upon completion of the project the Contractor shall provide the Owner three copies of each guarantee. Inspections: The Architect will conduct inspections for the purpose of determining and making his recommendations concerning the dates of substantial completion and final completion. The Architect will conduct the final acceptance inspection and issue the Certificate of Substantial Completion. Operation and Maintenance Manuals: The Architect will receive on behalf of the Owner one hard copy and two digital copies of all applicable equipment installation, operation, and maintenance brochures and manuals required of the Contractor. B-8 TERMINATION OF THE ARCHITECT: In case of the termination of the employment of the Architect by the Owner, the Owner shall either assume the duties of the Architect through the Director of the Property Management Department, or shall appoint a successor Architect against whom the Contractor makes no reasonable objection. SECTION C OWNER C-1 IDENTIFICATION: By the term Owner is meant the City of Fort Worth acting herein by its duly authorized representatives in the manner provided by law. Authorized representatives include the City Manager, Assistant City Manager, and Director of the Property Management Department and members of the Facilities Management Division. A designated representative will be identified from within the Facilities Management Division to act as a point of contact for day-to-day contract administration. General Conditions of the Contract for Construction Lump Sum Contract Page 3 of 28 CFW PMD — Crime Lab Full Building Generator Replacement — Project #102986 August 2023 C-2 DUTIES OF THE OWNER: The Owner shall furnish surveys describing the physical characteristics, legal limits and utility locations for the site of the Work; provided, however, that the Contractor hereby covenants that he has inspected the premises and familiarized himself therewith and that the locations of utilities and other obstacles to the prosecution of the Work as shown on the Owner's survey are for information only, are not binding upon the Owner, and the Owner shall not incur any liability for loss or damage by virtue of any inaccuracies or deficiencies in such surveys. The Owner shall secure and pay for title to the site and all necessary permanent or construction easements. The Owner will cooperate with the Contractor in the prosecution of the Work in such manner and to such extent as may be reasonable and shall furnish information under its control with reasonable promptness at the request of the Contractor. C-3 INSTRUCTIONS: The Owner shall issue all instructions to the Contractor through the Architect. C-4 ACCESS TO JOB SITE: The Owner shall at all times have access to the Work whenever it is in preparation and progress. The Contractor shall provide facilities for such access so the Owner may perform its assigned functions under the Contract Documents. C-5 PROGRESS INSPECTIONS: The Owner and Architect will make visits to the Site to familiarize themselves with the progress and quality of the Work and to determine if the work is proceeding in accordance with the Contract Documents. On the basis of on -site observations and reports concerning the progress and quality of the work, the Owner and Architect will approve and authorize the Contractor's applications for payments. C-6 AUTHORITY TO STOP WORK: The City will have authority to reject work that does not conform to the Plans and Specifications. Whenever, in its reasonable opinion, the City considers it necessary or advisable in order to insure the proper realization of the intent of the Plans and Specifications, the City will have authority to require the Contractor to stop the work or any portion thereof, or to require special inspection or testing of the Work whether or not such Work be then fabricated, installed or completed. The Contractor shall be responsible for the cost of special inspections and testing for work that is found not to comply with the plans and specifications. C-7 SUBSTANTIAL COMPLETION INSPECTION: Upon agreement of the Contractor and Architect that the Work is substantially complete, the Owner will schedule a Substantial Completion Inspection to be conducted by the Architect and attended by representatives of the Architect, Owner and Contractor. Items identified during this inspection as being incomplete, defective or deficient shall be incorporated into a punch list and attached to the AIA document G704, which is to be prepared by the Architect and signed by the Contractor, and accepted, approved and signed by the Owner. C-8 RIGHT TO AUDIT: Contractor agrees that the City shall, until the expiration of three years after final payment under this contract, have access to and the right to examine any directly pertinent books, documents, papers and records of the Contractor involving transactions relating to this contract. Contractor further agrees to include in all his subcontracts hereunder a provision to the effect that the subcontractor agrees that the City shall, until the expiration of three years after final payment under the subcontract, have access to and the right to examine any directly pertinent books, documents, papers and records of such subcontractor, involving transactions to the subcontract. The term "subcontract" as used herein includes purchase orders. Contractor agrees to photocopy such documents as may be requested by the city. The city agrees to reimburse Contractor for the costs of copies at the rate published in the Texas Administrative Code. C-9 TERMINATION AND SUSPENSION OF WORK: The Owner has the right to terminate the Project for any reason. If the project is terminated, the Contractor shall: a) Stop work under the Contract on the date and to the extent specified on the notice of termination. b) Place no further orders or subcontracts except as may be necessary for the completion of the work not terminated. c) Terminate all orders and subcontracts to the extent that they relate to the performance of the work terminated by the notice of termination. After termination as above, the City will pay the Contractor a proportionate part of the contract price based on the work completed; provided, however, that the amount of payment on termination shall not exceed the total contract price as reduced by the portion thereof allocable to the work not completed and further reduced by the amount of payments, if, any otherwise made. Contractor shall submit its claim for amounts due after termination as provided in this paragraph within 30 days after receipt of such claim. In the event of any dispute or controversy as to the propriety or allowability of all or any portion of such claim under this paragraph, such dispute or controversy shall be resolved and be decided by the City Council of the City of Fort Worth, and the decision by the City Council of the City of Fort Worth shall be final and binding upon all parties to this contract. SECTION D CONTRACTOR D-1 IDENTIFICATION: The Contractor is the person or organization identified as such in the Contract. The term Contractor means the Contractor or his authorized representative. General Conditions of the Contract for Construction Lump Sum Contract Page 4 of 28 CFW PMD — Crime Lab Full Building Generator Replacement — Project #102986 August 2023 D-2 INDEPENDENT CONTRACTOR: Contractor shall perform all work and services hereunder as an independent contractor, not as agent, or employee of the City. Contractor shall have exclusive control of and the exclusive right to control the details of the Work and services performed hereunder, and all persons performing same, and Contractor shall be solely responsible for the acts of its officers, agents, and employees. Nothing herein shall be construed as creating a partnership or joint enterprise between City and the Contractor, its officers, agents and employees, and the doctrine of respondent superior shall not apply. D-3 REVIEW OF CONTRACT DOCUMENTS: The Contractor shall carefully study and compare the Agreement, Conditions of the Contract, Drawings, Specifications, Addenda and modifications and shall at once report to the Owner and to the Architect any error, inconsistency or omission he may discover. The Contractor shall do no work without approved Submittals, Drawings, Specifications and Interpretations. D-4 SUPERVISION: The Contractor shall supervise and direct the Work, using reasonable skill and attention. He shall be solely responsible for all construction means, methods, safety, techniques, sequences and procedures and for coordinating all portions of the Work under the Contract Documents. D-5 LABOR AND MATERIALS: Unless otherwise specifically noted, the Contractor shall provide and pay for all labor, materials, equipment, tools, construction equipment and machinery, water, heat, utilities, transportation and other facilities and services necessary for the proper execution and completion of the Work. The Contractor will use its reasonable best efforts to hire local laborers, workmen and materialmen. The general condition is not to be constructed as limiting the right of the Contractor to employee laborers, workmen or materialmen from outside local area. The Contractor shall at all times enforce strict discipline and good order among his employees, and shall not employ on the Work any unfit person or anyone not skilled in the task assigned to him. D-6 COMPLIANCE WITH AND ENFORCEMENT OF PREVAILING WAGE RATE Dutv to Dav Prevailina Waoe Rates. The Contractor shall comply with all requirements of Chapter 2258, Texas Government Code (Chapter 2258), including the payment of not less than the rates determined by the City Council of the City of Fort Worth to be the prevailing wage rates in accordance with Chapter 2258. Such prevailing wage rates are included in these contract documents. Penaltv for Violation. A contractor or any subcontractor who does not pay the prevailing wage shall, upon demand made by the City, pay to the City $60 for each worker employed for each calendar day or part of the day that the worker is paid less than the prevailing wage rates stipulated in these contract documents. This penalty shall be retained by the City to offset its administrative costs, pursuant to Texas Government Code 2258.023. Complaints of Violations and Citv Determination of Good Cause. On receipt of information, including a complaint by a worker, concerning an alleged violation of 2258.023, Texas Government Code, by a contractor or subcontractor, the City shall make an initial determination, before the 31s` day after the date the City receives the information, as to whether good cause exists to believe that the violation occurred. The City shall notify in writing the contractor or subcontractor and any affected worker of its initial determination. Upon the City's determination that there is good cause to believe the contractor or subcontractor has violated Chapter 2258, the City shall retain the full amounts claimed by the claimant or claimants as the difference between wages paid and wages due under the prevailing wage rates, such amounts being subtracted from successive progress payments pending a final determination of the violation. Arbitration Required if Violation Not Resolved. An issue relating to an alleged violation of Section 2258.023, Texas Government Code, including a penalty owed to the City or an affected worker, shall be submitted to binding arbitration in accordance with the Texas General Arbitration Act (Article 224 et seq., Revised Statutes) if the contractor or subcontractor and any affected worker do not resolve the issue by agreement before the 15th day after the date the City makes its initial determination pursuant to paragraph (c) above. If the persons required to arbitrate under this section do not agree on an arbitrator before the 11th day after the date that arbitration is required, a district court shall appoint an arbitrator on the petition of any of the persons. The City is not a party in the arbitration. The decision and award of the arbitrator is final and binding on all parties and may be enforced in any court of competent jurisdiction. Records to be Maintained. The Contractor and each subcontractor shall, for a period of three (3) years following the date of acceptance of the Work, maintain records that show (i) the name and occupation of each worker employed by the Contractor in the construction of the Work provided for in this contract; and (ii) the actual per diem wages paid to each worker. The records shall be open at all reasonable hours for inspection by the City. The provisions of the Audit section of these contract documents shall pertain to this inspection. Pav Estimates. With each partial payment estimate or payroll period, whichever is less, the Contractor shall submit an affidavit stating that the Contractor has complied with the requirements of Chapter 2258, Texas Government Code. Postino of Waoe Rates. The Contractor shall post the prevailing wage rates in a conspicuous place at the site of the project at all times. Subcontractor Compliance. The Contractor shall include in its subcontracts and/or shall otherwise require all of its subcontractors to comply with paragraphs (a) through (g) above. On projects where special wage rates apply (e.g. Davis -Bacon) the Contractor agrees to meet all requirements of such programs. General Conditions of the Contract for Construction Lump Sum Contract Page 5 of 28 CFW PMD — Crime Lab Full Building Generator Replacement — Project #102986 August 2023 D-7 WARRANTY: The Contractor warrants to the Owner and the Architect that all materials and equipment furnished under this Contract will be new unless otherwise specified, and that all work will be of good quality, free from faults and defects, and in conformance with the Contract Documents. All work not so conforming to these standards may be considered defective. If required by the Architect or the Owner, the Contractor shall furnish satisfactory evidence as to the kind and quality of materials and equipment. Prior to occupancy of the Project by the Owner, the Contractor warranties and obligations to correct defective Work exclude remedy for damage or defect caused by (i) abuse by the Owner's separate contractors, or (ii) modifications made by the Owner or the Owner's separate contractors. After occupancy of the Project by the Owner, the Contractor warranties and obligations to correct defective Work exclude remedy for damage or defect caused by (i) abuse, (ii) modifications not executed by the Contractor, (iii) improper or insufficient maintenance, (iv) improper operation, (v) normal wear and tear, or (vi) normal usage. The warranty provided in this Section shall be in addition to and not in limitation of any other warranty or remedy provided by law or the Contract Documents. D-8 TAXES: The Contractor is exempt from State Sales Tax on material incorporated into the finished construction, Excise and Use Tax. Equipment and materials not consumed by or incorporated into the work are subject to State sales taxes under House Bill 11, enacted August 15, 1991. D-9 LICENSES. NOTICES AND FEES: The Contractor shall obtain all Permits, Licenses, Certificates, and Inspections, whether permanent or temporary, required by law or these Contract Documents. The City of Fort Worth Building and Trade Permit fees are waived. Separate permits may be required for each work location. If the Contractor allows any permit to expire, he shall be responsible for all renewals including any associated fees. The Contractor shall give all Notices and comply with all Laws, Ordinances, Rules, Regulations and Orders of any public authority bearing on the performance of the Work. If the Contractor observes or becomes aware that any of the Contract Documents are at variance therewith in any respect, he shall promptly notify the Architect and Owner in writing and any necessary changes will be made. If the Contractor performs any Work knowing that it is in violation of, or contrary to, any of such Laws, Statutes, Charter, Ordinances, Orders or Directives, or Regulations without furnishing Notice to the Architect and Owner, the Contractor will assume full responsibility therefore and bear all costs attributable thereto. D-10 CASH ALLOWANCES: The Contractor shall include in the Contract Sum all allowances stated in the Contract Documents. These allowances shall cover the net cost of the materials and equipment delivered and unloaded at the site, and all applicable taxes. The Contractor's handling costs on the site, labor, installation costs, overhead, profit and other expenses contemplated for the original allowance shall be included in the Contractor Sum and not in the allowance. The Contractor shall cause the Work covered by these allowances to be performed for such amounts and by such persons as the Owner may direct, but he will not be required to employ persons against whom he makes a reasonable objection. If the cost, when determined, is more than or less than the allowance, the Contract Sum shall be adjusted accordingly by Change Order which will include additional handling costs on the site, labor, installation costs, field overhead, profit and other direct expenses resulting to the Contractor from any increase over the original allowance. D-11 SUPERINTENDENT: The Contractor shall employ a competent superintendent and necessary assistants who shall be in attendance at the Project site during the progress of the Work. The superintendent shall be satisfactory to the Owner. The superintendent shall represent the Contractor and all communications given to the superintendent shall be binding as if given to the Contractor. Important communications will be confirmed in writing. Other communications will be so confirmed on written request in each case. D-12 RESPONSIBILITIES FOR EMPLOYEES AND SUB -CONTRACTORS: The Contractor shall be responsible to the Owner for the acts and omissions of all his employees and all Sub -contractors, their agents and employees, and all other persons performing any of the Work under a contract with the Contractor. D-13 FAILURE TO COMMENCE WORK: Should the Contractor fail to begin the Work herein provided for within the time herein fixed or to carry on and complete the same according to the true meaning of the intent and terms of said Plans, Specifications and Contract Documents, then the Owner shall have the right to either demand the surety to take over the Work and complete same in accordance with the Contract Documents or to take charge of and complete the Work in such a manner as it may deem proper, and if, in the completion thereof, the cost to the said City shall exceed the contract price or prices set forth in the said plans and specifications made a part hereof, the Contractor and/or its Surety shall pay said City on demand in writing, setting forth and specifying an itemized statement of the total cost thereof, said excess cost. D-14 PROGRESS SCHEDULE: The Contractor, immediately after being awarded the contract, shall prepare and submit for the Architect's and Owner's approval, an estimated progress schedule for the Work. The progress schedule shall be related to the entire Project and indicate critical path. This schedule shall indicate the dates for the starting and completion of the various states of construction and shall be revised as required by the conditions of the Work, subject to the Architect's approval. It shall also indicate the dates for submission and approval of shop drawings and submittals as well as the delivery schedule for major pieces of equipment and/or materials. The Contractor shall submit an updated progress schedule to the Architect and Owner at least monthly for approval along with the Contractor's monthly progress payment requests. General Conditions of the Contract for Construction Lump Sum Contract Page 6 of 28 CFW PMD — Crime Lab Full Building Generator Replacement — Project #102986 August 2023 D-15 DRAWINGS AND SPECIFICATIONS AT THE SITE: The Contractor shall maintain at the site for the Owner one copy of all Drawings, Specifications, Addenda, approved Shop Drawings, Change Orders, and other Changes and Amendments in good order and marked to record all changes made during construction. These shall also be available to the Architect. The Drawings, clearly marked to record all changes made during construction, shall be delivered to the Architect upon completion of the Work. The Architect will prepare, and provide to the Owner, one complete set of reproducible record drawings of the Work. D-16 SHOP DRAWINGS AND SAMPLES: Shop Drawings are drawings, diagrams, illustrations, schedules, performance charts, brochures and other data which are prepared by the Contractor or any Subcontractor, manufacturer, supplier or distributor, and which illustrate some portion of the Work. These may be provided in an electronic format acceptable to the Architect. Samples are physical examples furnished by the Contractor to illustrate materials, equipment or workmanship, and to establish standards by which the Work will be judged. Three copies of all physical examples shall be provided. The Contractor shall review, approve, and submit, with reasonable promptness and in orderly sequence so as to cause no delay in the Work or in the work of any other contractor, normally within the first 90 days of the work, three copies of all shop Drawings and Samples required by the Contract Documents or subsequently by the Architect as covered by changes or amendments. Shop Drawings and Samples shall be properly identified as specified, or as the Architect may require. At the time of submission the Contractor shall inform the Architect in writing of any deviation in the Shop Drawings or Samples from the requirements of the Contract Documents. By approving and submitting Shop Drawings and Samples, the Contractor thereby represents that he has determined and verified all field measurements, field construction criteria, materials, catalog numbers and similar data, and that he has checked and coordinated each shop drawing given in the Contract Documents. The Architect's approval of a separate item shall not indicate approval of an assembly in which the item functions. The Architect will review and approve Shop Drawings and Samples with reasonable promptness so as to cause no delay, but only for conformance with the design concept of the Project and with the information given in the Contract Documents. The Architect's approval of a separate item shall not indicate approval of an assembly in which the item functions. The Contractor shall make any corrections required by the Architect and shall resubmit the required number of corrected copies of Shop Drawings or new Samples until approved. The Contractor shall direct specific attention in writing or on resubmitted Shop Drawings to revisions other than the corrections requested by the Architect on previous submissions. The Architect's approval of Shop Drawings or Samples shall not relieve the Contractor of responsibility for any deviation from the requirements of the Contract Documents unless the Contractor has informed the Architect in writing of such deviation at the time of submission and the Architect has given written approval to the specific deviation. Architect's approval shall not relieve the Contractor from responsibility for errors or omissions in the Shop Drawings or Samples. No portion of the Work requiring a Shop Drawing or Sample submission shall be commenced until the Architect has approved the submittal. All such portions of the Work shall be in accordance with approved Shop Drawings and Samples. Payment for Shop Drawings will not be made until they are approved by the Architect or City. D-17 SITE USE: The Contractor shall confine operations at the site to areas permitted by law, ordinances, permits and the Contract Documents and shall not unreasonably encumber the site with any materials or equipment. Until acceptance of the Work by the City, the entire site of the Work shall be under the exclusive control, care and responsibility of the Contractor. Contractor shall take every precaution against injury or damage to persons or property by the action of the elements or from any other cause whatsoever. The Contractor shall rebuild, repair, restore and make good at his own expenses all injuries or damages to any portions of the Work occasioned by any of the above, caused before acceptance. D-18 CUTTING AND PATCHING OF WORK: The Contractor shall do all cutting, fitting or patching of his Work that may require making its several parts fit together properly, and shall not endanger any Work by cutting, excavating or otherwise altering the Work or any part of it. D-19 CLEAN UP: The Contractor at all times shall keep the premises free from accumulation of waste materials or rubbish. At the completion of the Work he shall remove all his waste materials and rubbish from and about the Project as well as all his tools, construction equipment, machinery and surplus materials, and shall clean all glass surfaces and leave the Work "Broom -clean" or its equivalent, except at otherwise specified. In addition to removal of rubbish and leaving the buildings "broom -clean", Contractor shall clean all glass, replace any broken glass, remove stains, spots, marks and dirt from decorated work, clean hardware, remove paint spots and smears from all surfaces, clean fixtures and wash all concrete, tile and terrazzo floors. If the Contractor fails to clean up, the Owner may do so, and the cost thereof shall be charged to the Contractor D-20 COMMUNICATIONS: The Contractor shall forward all communications to the Owner through the Architect D-21 CONTRACTOR REQUIREMENTS ON FEDERALLY FUNDED PROJECTS: Contractor shall observe and comply with the requirements of the City of Fort Worth Fiscal Department, Intergovernmental Affairs and Grants Management as outlined in the Supplemental Conditions contained in the Project Manual. General Conditions of the Contract for Construction Lump Sum Contract Page 7 of 28 CFW PMD — Crime Lab Full Building Generator Replacement — Project #102986 August 2023 SECTION E SUBCONTRACTORS E-1 DEFINITION: A Subcontractor is a person or organization that has a direct contract with the Contractor to perform any of the Work at the site. The term Subcontractor is referred to throughout the Contract Documents as if singular in number and masculine in gender and means a Subcontractor or his authorized representative. Nothing contained in the Contract, Documents shall create any contractual relation between the Owner and the Architect and any subcontractor or any of his sub -subcontractors or materialmen. E-2 AWARD OF SUBCONTRACTS: The Contractor shall furnish a list of the names of the subcontractors or other persons or organizations (including those who are to furnish materials or equipment fabricated to a special design) proposed for such portions of the Work as may be designated in the bidding requirements, or if none is so designated in the bidding requirements, the names of the Subcontractors proposed for the principal portions of the Work. Prior to the award of the Contract, the Architect shall notify the successful bidder in writing if either the Owner or Architect, after due investigation, has reasonable objection to any person or organization on such list. Failure of the Owner and Architect to make an objection to any person or organization on the list prior to the award of this Contract shall not constitute acceptance of such person or organization. If, prior to the award of the Contract, the Owner or Architect has an objective to any person or organization on such list, and refuses to accept such person or organization, the apparent low bidder may, prior to the award, withdraw his bid without forfeiture of bid security. If such bidder submits an acceptable substitute, the Owner may, at its discretion, accept the bid or he may disqualify the bid. If, after the award, the Owner or Architect objects in writing to any person or organization on such list, the Contractor shall provide an acceptable substitute. The Contractor shall not make any substitution for any Subcontractor or person or organization that has been accepted by the Owner and the Architect, unless the substitution is also acceptable to the Owner and the Architect. E-3 TERMS OF SUBCONTRACTS: All work performed for the Contractor by a Subcontractor shall be pursuant to an appropriate agreement between the Contractor and the Subcontractor (and where appropriate between Subcontractors and Sub - subcontractors) which shall contain provisions that: 1. Preserve and protect the rights of the Owner and the Architect under the Contract with respect to the Work to be performed under the subcontract so that the subcontracting thereof will not prejudice such rights; 2. Require that such Work be performed in accordance with the requirements of the Contract Documents; 3. Require submission to the Contractor of applications for payment under each subcontract to which the Contractor is a party, in reasonable time to enable the Contractor to apply for payment; 4. Require that all claims for additional costs, extensions of time, damages for delays or otherwise with respect to subcontracted portions of the Work shall be submitted to the Contractor (via any Subcontractor or Sub -subcontractor where appropriate) in the manner provided in the Contract Documents for like claims by the Contractor upon the Owner; 5. Waive all rights the contracting parties may have against one another for damages caused by fire or other perils covered by the property insurance, except such rights, if any, as they may have to proceeds of such insurance held by the Owner, and, 6. Obligate each Subcontractor specifically to consent to the provisions of this Section All of the provisions set out in this section shall be deemed to have been included in every subcontract, and every subcontract shall be so construed and applied as to the Owner and the Architect, whether or not such provisions are physically included in the sub- contract. E-4 MINORITY BUSINESS ENTERPRISE (MBE): Should the base proposal be $50,000 or less, the requirements of this section do not apply. As of June 1, 2012, The City of Fort Worth is implemented a new Business Diversity Ordinance (BDO) to reflect the City's availability and disparity study findings and recommendations. During this transition period, interested Offerors must obtain a MBE listing from the M/WBE Office. This will ensure that MBE listings reflect only those currently certified by the North Central Texas Regional Certification Agency (NCTRCA) located in the six (6)-county geographic marketplace that have been accepted by the City. The City's geographic marketplace includes the counties of: Tarrant, Dallas, Denton, Johnson, Parker and Wise. Offerors are stronalv encouraaed to confirm that each MBE that it intends to use is located in the geographic marketplace that will be counted towards the established goal. In accordance with City of Fort Worth Diversity Business Ordinance (BDO) No 20020-12-2011 (the "Ordinance"), the City of Fort Worth sets goals for the participation of Minority Business Enterprises (MBE) in City contracts. Ordinance No 20020-12-2011 is incorporated in these General Conditions by reference. A copy of the Ordinance may be obtained from the Office of the City Secretary. Failure to comply with the Ordinance shall be a material breach of contract. Prior to Award: The MBE documentation required by the procurement solicitation must be submitted within five city business days after the proposals are opened. Failure to comply with the City's Business Diversity Ordinance, or to demonstrate a "good faith effort", shall result in a bid being considered non -responsive. General Conditions of the Contract for Construction Lump Sum Contract Page 8 of 28 CFW PMD — Crime Lab Full Building Generator Replacement — Project #102986 August 2023 During Construction: Contractor shall provide copies of subcontracts or cosigned letters of intent with approved MBE subcontractors and or suppliers prior to issuance of the Notice to Proceed. Contractor shall also provide monthly reports on utilization of the subcontractors to the M/WBE Office and the designated representative identified from within the Facilities Management Division. Contractor must provide the City with complete and accurate information regarding actual work performed by an MBE on the contract and proof of payment thereof. Contractor further agrees to permit an audit and/or examination of any books, records or files in its possession that will substantiate the actual work performed by an MBE. The misrepresentation of facts and/or the commission of fraud by the Contractor will be grounds for termination of the contract and/or initiating action under appropriate federal, state, or local laws or ordinances relating to false statement. An Offeror who intentionally and/or knowingly misrepresents material facts shall be determined to be an irresponsible Offeror and barred from participating in City work for a period of time of not less than three (3) years. The failure of an Offeror to comply with this ordinance where such non-compliance constitutes a material breach of contract as stated herein, may result in the Offeror being determined to be an irresponsible Offeror and barred from participating in City work for a period of time of not less than one (1) year. The Contractor may count toward the goal any tier of MBE subcontractors and/or suppliers. The Contractor may count toward its goal a portion of the total dollar amount of the contract with a joint venture equal to the percentage of the MBE participation in the joint venture for a clearly defined portion of the work to be performed. All subcontractors used in meeting the goals must be certified prior to the award of the Contract. Change Orders: Whenever a change order affects the work of an MBE subcontractor or supplier, the MBE shall be given an opportunity to perform the work. Whenever a change order is $50,000 or more, the M/WBE Office Coordinator shall determine the goals applicable to the work to be performed under the change order. During the term of the contract the Contractor shall: 1. Make no unjustified changes or deletions in its MBE participation commitments submitted with the bid/proposal or during negotiation, without prior submission of the proper documentation for review and approval by the M/WBE Office. 2. If substantial subcontracting and/or supplier opportunities arise during the term of any contract when the Contractor represented in its bid/proposal to the City that it alone would perform the subcontracting/supplier opportunity work, the Contractor shall notify the City before subcontracts for work and/or supplies are awarded and shall be required to comply with subsections of the Ordinance, exclusive of the time requirements stated in such subsections. 3. The Contractor shall submit to the M/WBE Office for approval an MBE REQUEST FOR APPROVAL OF CHANGE FORM, if, during the term of any contract, the Contractor wishes to change or delete one or more MBE subcontractors or suppliers. Justification for change of subcontractors may be granted for the following: 1. An MBE's failure to provide Workers' Compensation Insurance evidence as required by state law; or 2. An MBE's -failure to provide evidence of general liability or other insurance under the same or similar terms as contained in the Contract Documents with limits of coverage no greater than the lower of 1) the limits required of the Contractor by the City; or 2) the limits contained in the Contractor's standard subcontract or supply agreements used on other projects of similar size and scope and within the Contractor's normal business practice with non -MBE subcontractors/sub consultant's or suppliers; or 3. An MBE's failure to execute the Contractor's standard subcontract form, if entering a subcontract is required by the Contractor in its normal course of business, unless such failure is due to: a) A change in the amount of the previously agreed to bid or scope of work; or b) The contract presented provides for payment once a month or longer and the Contractor is receiving payment from the City twice a month; or c) Any limitation being placed on the ability of the MBE to report violations of the Ordinance or any other ordinance or violations of any state or federal law or other improprieties to the City or to provide notice of any claim to the Contractor's surety company or insurance company. d) Mediation shall be a consideration before the request for change is approved. 4. An MBE defaults in the performance of the executed subcontract. In this event, the Contractor shall: a) Request bids from all MBE subcontractors previously submitting bids for the work, b) If reasonably practicable, request bids from previously non -bidding MBEs, and c) Provide to the M/WBE Office documentation of compliance with (a) and (b) above. 5. Any reason found to be acceptable by the M/WBE Office in its sole discretion. Within ten days after final payment from the City the Contractor shall provide the M/WBE Office with documentation to reflect final participation of each subcontractor and supplier, including non -MBEs, used on the project. General Conditions of the Contract for Construction Lump Sum Contract Page 9 of 28 CFW PMD — Crime Lab Full Building Generator Replacement — Project #102986 August 2023 E-5 PAYMENTS TO SUBCONTRACTORS: The Contractor shall pay each Subcontractor, upon receipt of payment from the Owner, an amount equal to the percentage of completion allowed to the Contractor on account of such Subcontractor's Work. The Contractor shall also require each Subcontractor to make similar payments to his subcontractors. If the Owner refuses to issue a Certificate for Payment for any cause which is the fault of the Contractor and not the fault of a particular subcontractor, the Contractor shall pay that Subcontractor on demand, made at any time after the Certificate for Payment would otherwise have been issued, for his Work to the extent completed, less the retained percentage. The Contractor shall pay each Subcontractor a just share of any insurance monies received by the Contractor, and he shall require each Subcontractor to make similar payments to his Subcontractors. The Owner may, on request and at its discretion, furnish to any Subcontractor, if practicable, information regarding percentages of completion certified to the Contractor on account of Work done by such Subcontractors. Neither the Owner nor the Architect shall have any obligation to pay or to see to the payment of any monies to any Subcontractor. E-6 SUBCONTRACTOR REQUIREMENTS FOR ECONOMIC DEVELOPMENT ADMINSTRATION (EDA) FUNDED PROJECTS: The Contractor will cause appropriate provisions to be inserted in all subcontracts to bind subcontractors to FDA contract requirements as contained herein and to 15 CFR 24 or OMB Circular A-110, as appropriate. Each subcontractor must agree to comply with all applicable Federal, State, and local requirements in addition to those set forth in this section. No subcontractor will be employed on this Project, except as specifically approved by the City, who is contained in the listing of contractors debarred, ineligible, suspended or indebted to the United States from contractual dealings with Federal government departments. The work performed by any such contractor or subcontractor will be ineligible for reimbursement wholly or partially from EDA grant fluids. All subcontracts in excess of $10,000 shall include, or incorporate by reference, the equal opportunity clause of Executive Order 11246. All subcontracts must contain a nondiscrimination clause. Each subcontract must contain a requirement for compliance with the Davis -Bacon and related acts. Each subcontractor must submit weekly each weekly payroll record and a weekly statement of compliance. These documents will be submitted to the prime contractor who will compile them and submit to the City. The subcontractor can satisfy this requirement by submitting a properly executed Department of Labor Form WH-347. Each subcontract with every subcontractor must contain a clause committing the subcontractor to employment of local labor to the maximum extent possible. All subcontractors who employ more than 50 employees, and is a prime or first tier subcontractor, and has a subcontract or purchase order of $50,000 or more must submit a completed Standard Form 100 (Compliance Report) by March 30 of each year. Subcontractors performing work in areas covered by published goals for minorities will be required to report monthly on Form CC- 257. SECTION F SEPARATE CONTRACTS F-1 OWNER'S RIGHT: The Owner reserves the right to award separate contracts in connection with other portions of the Work. When separate contracts are awarded for other portions of the Work, "the Contractor" in the Contract Documents in each case shall be the contractor who signs each separate contract. F-2 MUTUAL RESPONSIBILITY OF CONTRACTORS: The Contractor shall afford other contractors reasonable opportunity for the introduction and storage of their materials and equipment and the execution of their work, and shall properly connect and coordinate his work with theirs. If any part of the Contractor's Work depends for proper execution or results upon the work of any other separate contractor, the Contractor shall inspect and promptly report to the Owner any apparent discrepancies or defects in such work that render it unsuitable for such proper execution and results. Failure of the Contractor to inspect and report shall constitute an acceptance of the other contractor's work as fit and proper to receive his Work, except as to defects which may develop in the other separate contractor's work after the execution of the Contractor's Work. Should the Contractor cause damage to the work or property of any separate contractor on the site, the Contractor shall, upon due notice, settle with such other contractor by agreement, if he will so settle. If such separate contractor sues the Owner on account of any damage alleged to have been so sustained, the Owner shall notify the Contractor who shall defend against such suit at the Contractor's expense, and if any judgment against the Owner arises therefrom, the Contractor shall pay or satisfy such judgment General Conditions of the Contract for Construction Lump Sum Contract Page 10 of 28 CFW PMD — Crime Lab Full Building Generator Replacement — Project #102986 August 2023 and shall reimburse the Owner for all attorney's fees, court costs and expenses which the Owner has incurred in connection with such suit. F-3 CUTTING AND PATCHING UNDER SEPARATE CONTRACTS: The Contractor shall do all cutting, fitting or patching of his Work that may be required to fit it to receive or be received by the work of other contractors shown in the Contract Documents. The Contractor shall not endanger any work or any other contractors by cutting, excavating or otherwise altering any work and shall not cut or alter the work of any other contractor except with the written consent of the Architect. Any costs caused by defective or ill-timed work shall be borne by the party responsible therefor. F-4 OWNER'S RIGHT TO CLEAN UP: If a dispute arises between the separate contractors as to their responsibility for cleaning up, the Owner may clean up and charge the cost thereof to the several contractors as the Director of the Project Management Department shall determine to be just. SECTION G MISCELLANEOUS PROVISIONS G-1 CONFLICT OF LAWS: The law of the place where the site is located shall govern the Contract. The Contractor must familiarize himself and strictly comply with all Federal, State, and County and City Laws, Statutes, Charter, Ordinances, Regulations, or Directives controlling the action or operation of those engaged upon the work affecting the materials used. He shall indemnify and save harmless the City and all of its officers and agents against any claim or liability arising from or based on the violation of any such Laws, Statutes, Charter, Ordinances, Regulations, or Directives, whether by himself, his employees, agents or subcontractors. G-2 GOVERNING LAWS: It is mutually agreed and understood that this agreement is made and entered into by the parties hereto with reference to the existing Charter and Ordinances of the City of Fort Worth and the laws of the State of Texas with reference to and governing all matters affecting this Contract, and the Contractor agrees to fully comply with all the provisions of the same. G-3 PERSONAL LIABILITY OF PUBLIC OFFICIALS: In performing their duties under the Statutes of the State of Texas and the Charter and Ordinances of the City of Fort Worth in connection with this Contract, or in exercising any of the powers granted the Owner herein, the officers, agents and employees of the City of Fort Worth are engaged in the performance of a governmental function and shall not incur any personal liability by virtue of such performance hereunder, except for gross negligence or willful wrong. G-4 COMPLIANCE WITH LAWS: Contractor agrees to comply with all laws, Federal, state and local, including all ordinances, rules and regulations of the City of Fort Worth, Texas. Materials incorporated into the finished Project are not subject to State Sales Tax. The Owner is responsible for obtaining the Building Permit. The Contractor and the appropriate subcontractor are responsible for obtaining all other construction permits from the governing agencies. Contractor shall schedule all code inspections with the Code Inspection Division in accordance with the permit requirements. Building, plumbing, electrical and mechanical building permits are issued without charge. Water and sewer tap, impact & access fees will be paid by the City. Any other permit fees are the responsibility of the Contractor. G-5 INDEMNIFICATION: Contractor covenants and agrees to indemnify City's engineer and architect, and their personnel at the project site for Contractor's sole negligence. In addition, Contractor covenants and agrees to indemnify, hold harmless and defend, at its own expense, the Owner, its officers, servants and employees, from and against any and all claims or suits for property loss, property damage, personal injury, including death, arising out of, or alleged to arise out of, the work and services to be performed hereunder by Contractor, its officers, agents, employees, subcontractors, licensees or invitees, whether or not anv such iniurv. damage or death is caused, in whole or in part, by the nealiaence or alleaed nealiaence of Owner. its officers. servants. or emplovees. Contractor likewise covenants and agrees to indemnify and hold harmless the Owner from and against any and all injuries to Owner's officers, servants and employees and any damage, loss or destruction to property of the Owner arising from the performance of any of the terms and conditions of this Contract, whether or not anv such iniury or damage is caused in whole or in Dart by the nealiaence or alleged nealiaence of Owner. its officers, servants or emplovees. In the event Owner receives a written claim for damages against the Contractor or its subcontractors prior to final payment, final payment shall not be made until Contractor either (a) submits to Owner satisfactory evidence that the claim has been settled and/or a release from the claimant involved, or (b) provides Owner with a letter from Contractor's liability insurance carrier that the claim has been referred to the insurance carrier. The Director may, if he deems it appropriate, refuse to whom a claim for damages is outstanding as a result of work performed under a City Contract. G-6 SUCCESSORS AND ASSIGNS: Except as provided in Paragraph E-2, this contract shall be binding upon and insure to the benefit of the parties hereto, their Successors or Assigns. Contractor shall not assign or sublet all or any part of this Contract or his rights or duties hereunder without the prior written consent of the Owner. Any such purported assignment or subletting without the prior written consent of Owner shall be void. General Conditions of the Contract for Construction Lump Sum Contract Page 11 of 28 CFW PMD — Crime Lab Full Building Generator Replacement — Project #102986 August 2023 G-7 WRITTEN NOTICE: Written Notice shall be deemed to have been duly served if delivered in person to the individual or member of the firm or to an officer of the corporation for whom it was intended, or if delivered at or sent by registered or certified mail to the last business address known to him who gives the notice. G-8 SURETY BONDS: Surety Bonds are required on all City contracts in excess of $25,000. The Contractor agrees, on the submittal of his Proposal to make, execute and deliver to said City of Fort Worth good and sufficient surety bonds for the faithful performance of the terms and stipulations of the Contract and for the payment to all claimants for labor and/or materials furnished in the prosecution of the Work, such bonds being as provided and required in Article 5160 of the Revised Civil Statutes of Texas, as amended, in the form included in the Contract Documents, and such bonds shall be 100 percent of the total contract price, and the said surety shall be a surety company duly and legally authorized to do business in the State of Texas, and acceptable to the City Council of the City of Fort Worth. Bonds shall be made on the forms furnished by or otherwise acceptable to the City. Each bond shall be properly executed by both the Contractor and the Surety Company. Bonds required by the City shall be in compliance with all relevant local, state and federal statutes. To be an acceptable surety on the bond the name of the surety should be included on the current U. S. Treasury List of Acceptable Securities [Circular 570], and must be authorized to do business in Texas. Sureties not listed in Circular 570 may write performance and payment bonds on a project without reinsurance to the limit of 10 percent of its capital and surplus. Such a surety must reinsure any obligation over 10 percent. The amount in excess of 10 percent must be reinsured by reinsurers who are duly authorized, accredited, or trusteed to do business in the State of Texas. Should any surety for the contracted project be determined unsatisfactory at any time during same, the Contractor shall immediately provide a new surety bond satisfactory to the City. If the contract amount is $25,000 or less, payment to the Contractor shall be made in one lump sum. Payment shall not be made for a period of 45 calendar days from the date the work has been completed and accepted by the City. G-9 OWNER'S RIGHT TO CARRY OUT THE WORK: If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents or fails to perform any provision of the Contract, the Owner may, without prejudice to any other remedy he may have, enter the site and make good such deficiencies. In such case an appropriate Change Order shall be issued deducting from the payments then or thereafter due the Contractor the cost of correcting such deficiencies, including the cost of the Architect's additional services made necessary by such default, neglect or failure. If the payments then or thereafter due the Contractor are not sufficient to cover such amount, the Contract shall pay the difference to the Owner. G-10 ROYALTIES AND PATENTS: The Contractor shall pay all royalties and license fees. He shall defend all suits or claims for infringement of any patent rights and shall save the Owner harmless from loss on account thereof and shall be responsible for all such loss when a particular design, process or the product of a particular manufacturer or manufacturers is specified; however, if the Contractor has reason to believe that the design, process or product specified is an infringement of a patent, he shall be responsible for such loss unless he promptly gives such information to Owner. G-11 TESTS: If the Contract Documents, Laws, Ordinances, Rules, Regulations or Orders of any public authority having jurisdiction require any Work to be inspected, tested or approved, the Contractor shall give the Owner timely notice of its readiness and the date arranged so the Architect may observe such inspection, testing or approval. The Owner shall bear all costs of such inspection, tests and approvals unless otherwise provided. If after the commencement of the Work, the Owner determines that any work requires special inspection, testing or approval not included above, the Architect, upon written authorization from the Owner, will instruct the Contractor to order such special inspection, testing or approval, and the Contractor shall give notice as required in the preceding paragraph. If such special inspection or testing reveals a failure of the Work to comply (1) with the requirements of the Contract Documents or (2) with respect to the performance of the Work, with Laws, Statutes, Charter, Ordinances, Regulations or Orders of any public authority having jurisdiction, the Contractor shall bear all costs thereof, including the Architect's additional services made necessary by such costs; otherwise the Owner shall bear such costs, and an appropriate Change Order shall be issued. The Contractor shall secure certificate of inspection, testing or approval, and three copies will be promptly delivered by him to the Architect. The Architect will review the certificates and forward one copy of each with his recommendation(s) to the Owner. If the Owner wishes to observe the inspections, tests or approvals required by this Section, they will do so promptly and, where practicable, at the source of supply. Neither the observations of the Architect or the Owner in their administration of the Construction Contract, nor inspections, tests or approvals by persons other than the Contractor shall relieve the Contractor from his obligations to perform the Work in accordance with the Contract Documents. G-12 INTERRUPTION OF EXISTING UTILITIES SERVICES: The Contractor shall perform the Work under this Contract with a minimum of outage time for all utilities. Interruption shall be by approved sections of the utility. In some cases, the Contractor may be required to perform the Work while the existing utility is in service. The existing utility service may be interrupted only when approved by the Owner. When it is necessary to interrupt the existing utilities, the Contractor shall notify the Owner in writing at least ten days in advance of the time that he desires the existing service to be interrupted. The interruption time shall be kept to a minimum. Depending upon the activities at an existing facility that requires continuous service from the existing utility, an interruption General Conditions of the Contract for Construction Lump Sum Contract Page 12 of 28 CFW PMD — Crime Lab Full Building Generator Replacement — Project #102986 August 2023 may not be subject to schedule at the time desired by the Contractor. In such cases, the interruption may have to be scheduled at a time of minimum requirements of demand for the utility. The amount of time requested by the Contractor of existing utility services shall be as approved by the Owner. G-13 LAYING OUT WORK: The Contractor shall verify dimensions and elevations indicated in layout of existing work. Discrepancies between Drawings, Specifications, and existing conditions shall be referred to the Architect for adjustment before work affected is performed. Failure to make such notification shall place responsibility upon Contractor to carry out work in satisfactory workmanlike manner at the Contractor's sole expense. The Contractor shall be held responsible for the location and elevation of all the construction contemplated by the Construction Documents. Prior to commencing work, the Contractor shall carefully compare and check all Architectural, Structural, Mechanical an Electrical drawings; each with the other that in any affects the locations or elevation of the work to be executed by him, and should any discrepancy be found, he shall immediately report the same to the Architect for verification and adjustment. Any duplication of work made necessary by failure or neglect on his part to comply with this function shall be done at the Contractor's sole expense. G-14 MEASUREMENTS: Before ordering any material or doing any work, the Contractor shall verify all measurements at the site or at the building and shall be wholly responsible for the correctness of same. No extra charge or compensation will be allowed on account of any difference between actual dimensions and dimensions indicated on the drawings. Any difference that may be found shall be submitted to the Architect for consideration and adjustment before proceeding with the project. G-15 EXISTING OVERHEAD OR UNDERGROUND WORK: The Contractor shall carefully check the site where the project is to be erected and observe any existing overhead wires and equipment. Any such work shall be moved, replaced or protected, as required, whether or not shown or specified at the Contractor's sole expense. Attention is directed to the possible existence of pipe and other underground improvements that may or may not be shown on the Drawings. All reasonable precautions shall be taken to preserve and protect any such improvements whether or not shown on the Drawings. Location of existing underground lines, shown the Drawings are based on the best available sources, but are to be regarded as approximate only. Exercise extreme care in locating and identifying these lines before excavation in adjacent areas. G-16 ALIGNMENT OF JOINTS IN FINISH MATERIALS: It shall be the responsibility of the Contractor to make certain in the installation of jointed floor, wall and ceiling materials that: 1. Preserve and protect the rights of the Owner and the Architect under the Contract with respect to the Work to be performed under the subcontract so that the subcontracting thereof will not prejudice such rights; 2. Place joints to relate to all opening and breaks in the structure and be symmetrically placed wherever possible. This includes heating registers, light fixtures, equipment, etc. If because of the non -related sizes of the various materials and locations of openings, etc., it is not possible to accomplish the above, the Contractor shall request the Architect to determine the most satisfactory arrangement. The Contractor shall establish centerlines for all trades. G-17 INTEGRATING EXISTING WORK: The Contractor shall protect all existing street and other improvements from damages. Contractor's operations shall be confined to the immediate vicinity of the new work and shall not in any interfere with or obstruct the ingress or egress to and from existing adjacent facilities. Where new site work is to be connected to existing work, special care shall be exercised by the Contractor not to disturb or damage the existing work more than necessary. All damaged work shall be replaced, repaired and restored to its original condition at no cost to the Owner. G-18 HAZARDOUS MATERIAL CERTIFICATION: It is the intent of the contract documents, whether expressly stated or not, that nothing containing hazardous materials, such as asbestos, shall be incorporated in to the project. The Contractor shall exercise every reasonable precaution to ensure that asbestos -containing materials are not incorporated into any portion of the project, including advising all materials suppliers and subcontractors of this requirement. The Contractor shall verify that components containing lead do not contact the potable water supply. G-19 LOCATION OF EQUIPMENT AND PIPING: Drawing showing location of equipment, piping, ductwork, etc. are diagrammatic and job conditions may not always permit their installation in the location shown. When this situation occurs, it shall be brought to the Architect's attention immediately and the relocation determined in a joint conference. The Contractor will be held responsible for the relocating of any items without first obtaining the Architect's approval. He shall remove and relocate such items at his own expense if so directed by the Architect. Where possible; uniform margins shall be maintained between parallel lines and/or adjacent wall, floor or ceiling surfaces. General Conditions of the Contract for Construction Lump Sum Contract Page 13 of 28 CFW PMD — Crime Lab Full Building Generator Replacement — Project #102986 August 2023 G-20 OVERLOADING: The Contractor shall be responsible for loading of any part or parts of structures beyond their safe carrying capacities by placing of materials, equipment, tools, machinery or any other item thereon. No loads shall be placed on floors or roofs before they have attained their permanent and safe strength. G-21 MANUFACTURER'S INSTRUCTIONS: Where it is required in the Specifications that materials, products, processes, equipment, or the like be installed or applied in accordance with manufacturer's instructions, direction or specifications, or words to this effect, it shall be construed to mean that said application or installation shall be in strict accordance with printed instructions furnished by the manufacturer of the material concerned for use under conditions similar or those at the job site. Six copies of such instructions shall be furnished to the Architect and his approval thereof obtained before work is begun. G-22 CLEANING UP: The Contractor shall keep the premises free from accumulation of waste material or rubbish caused by employees or as a result of the Work. At completion of work, the General Contractor shall, immediately prior to final inspection of complete building, execute the following final cleaning work with trained janitorial personnel and with material methods recommended by the manufactures of installed materials. 1. Sweep and buff resilient floors and base, and vacuum carpeting. 2. Dust all metal and wood trim and similar finished materials. 3. Clean all cabinets and casework. 4. Dust all ceilings and walls. 5. Dust, and if necessary wash, all plumbing and electrical fixtures. 6. Wash all glass and similar non -resilient materials. 7. All hardware and other unpainted metals shall be cleaned and polished and all equipment and paint or decorated work shall be cleaned and touched -up if necessary, and all temporary labels, tags, and paper coverings removed throughout the buildings. Surfaces that are waxed shall be polished. 8. The exterior of the building, the grounds, approaches, equipment, sidewalks, streets, etc. shall be cleaned similar to interior of buildings and left in good order at the time of final acceptance. All paint surfaces shall be clean and unbroken, hardware shall be clean and polished, all required repair work shall be completed and dirt areas shall be scraped and cleared of weed growth. 9. Clean all glass surfaces and mirrors of putty, paint materials, etc., without scratching or injuring the glass and leave the work bright, clean and polished. Cost of this cleaning work shall be borne by Contractor. 10. Cleaning, polishing, scaling, waxing and all other finish operations indicated on the Drawings or required in the Specifications shall be taken to indicate the required condition at the time of acceptance of all work under the Contract. 11. Burning: Burning of rubbish on the premises will not be permitted. G-23 DUST CONTROL: Precaution shall be exercised at all times to control dust created as a result of any operations during the construction period. If serious problems or complaints arise due to air -borne dust, or when directed by the Architect, operations causing such problems shall be temporarily discontinued and necessary steps taken to control the dust. G-24 FIRE PROTECTION: The Contractor shall at all times maintain good housekeeping practices to reduce the risk of fire damage or injury to workmen. All scrap materials, rubbish and trash shall be removed daily from in and about the building and shall not be permitted to be scattered on adjacent property. Suitable storage space shall be provided outside the immediate building area for storing flammable materials and paints; no storage will be permitted in the building. Excess flammable liquids being used inside the building shall be kept in closed metal container and removed from the building during unused periods. A fire extinguisher shall be available at each location where cutting or welding is being performed. Where electric or gas welding or cutting work is done, interposed shields of incombustible material shall be used to protect against fire damage due to sparks and hot metal. When temporary heating devices are used, a watchman shall be present to cover periods when other workmen are not on the premises. The Contractor shall provide fire extinguishers in accordance with the recommendations and NFPA Bulletins Nos. 10 and 241. However, in all cases a minimum of two fire extinguishers shall be available for each floor of construction. G-25 CUTTING AND PATCHING: Wherever cutting and removal of portions of the existing work is indicated, such work shall be neatly sawed or cut by Contractor in a manner that will produce a neat straight line, parallel to adjacent surfaces or plumb for vertical surfaces. Care should be exercised not to damage any work that is to remain. At no time shall any structural members be cut without written consent from the Architect. General Conditions of the Contract for Construction Lump Sum Contract Page 14 of 28 CFW PMD — Crime Lab Full Building Generator Replacement — Project #102986 August 2023 G-26 PROJECT CLOSEOUT Final Inspection, Record Drawings: Attention is called to General Conditions Section entitled, "Substantial Completion and Final Payment". Maintenance Manual: Sheets shall be 8'/2" x 11 ", except pull out sheets may be neatly folded to 8'/2 "x 11 ". Manuals shall be bound in plastic covered, 3 ring, loose leaf binder with title of project lettered on front and shall contain: 1) Name, address and trade of all sub -contractors. 2) Complete maintenance instructions; name, address, and telephone number of installing Contractor, manufacturer's local representative, for each piece of operative equipment. 3) Catalog data on plumbing fixtures, valves, water heaters, heating and cooling equipment, temperature control, fan, electrical panels, service entrance equipment and light fixtures. 4) Manufacturer's name, type, color designation for resilient floors, windows, doors, concrete block, paint, roofing, and other materials. Submit two digital electronic copies and one hard copy of Maintenance Manuals, prior to request for final payment. Operational Inspection and Maintenance Instruction: The Contractor shall provide at his expense, competent manufacturer's representatives to completely check out all mechanical and electrical systems and items covered by the Drawings and Specifications. This requirement shall be scheduled just prior to and during the initial start-up. After all systems are functioning properly the representatives shall instruct maintenance personnel of the Owner in the proper operation and maintenance of each item. G-27 GUARANTEE AND EXTENDED GUARANTEE: Upon completion of the Project, prior to final payment, guarantees required by technical divisions of Specifications shall be properly executed in quadruplicate by subcontractors and submitted through the Contractor to Architect. Delivery of guarantees shall not relieve Contractor from any obligation assumed under Contract. The Contractor shall guarantee the entire Project for one year. In addition, where separate guarantees, for certain portions of work, are for longer periods, General Contractor's guarantee shall be extended to cover such longer periods. Manufacturer's extended warrantees shall be included in this contract. Guarantees shall become valid and operative and commence upon issuance of Certificate of Inspection and Acceptance by Owner. Guarantees shall not apply to work where damage is result of abuse, neglect by Owner or his successor(s) in interest. The Contractor agrees to warrant his work and materials provided in accordance with this contract and the terms of the Technical Specifications contained herein. Unless supplemented by the Technical Specifications or the manufacturer's normal extended warrantees, the Contractor shall warrant all work materials, and equipment against defects for a period of one year from the date of final acceptance. The Contractor further agrees to bear all costs of making good all work that is found to be defective or not provided in accordance with the Contract Documents. Additionally if the facility or contents are damaged due to defective materials or workmanship of the Contractor, the Contractor further agrees to bear all cost of repairing and/or replacing damaged items and components to bring such items back to at least their original condition. G-28 RECORD DRAWINGS: Upon completion of the Work and prior to application for final payment, one print of each of the drawings accompanying this specification shall be neatly and clearly marked in red by the Contractor to show variations between the construction actually provided and that indicated or specified in the Contract Documents. The annotated documents shall be delivered to Architect. Where a choice of materials and/or methods is permitted herein and where variations in the scope or character of the work from the entire work indicated or specified are permitted either by award of bidding items specified for that purpose, or by subsequent change to the drawings, the record drawings shall define the construction actually provided. The representation of such variations shall conform to standard drafting practice and shall include supplementary notes, legends and details which may be necessary for legibility and clear portrayal of the actual construction. The record drawings shall indicate, in addition, the actual location of all sub -surface utility lines, average depth below the surface and other appurtenances. G-29 CONSTRUCTION FENCE: The Contractor shall provide a substantial chain -link construction fence around all or a part of the site. The fences and gates must be maintained throughout the construction period. Remove the fences and gates upon completion of the Project and restore the site to the required original or contract condition. G-30 PRODUCT DELIVERY. STORAGE. HANDLING: The Contractor shall handle, store and protect materials and products, including fabricated components, by methods and means which will prevent damage, deterioration and loss, including theft (and resulting delays), thereby ensuring highest quality results as the work progresses. Control delivery schedules so as to minimize unnecessary long-term storage at project site prior to installation. G-31 REMOVAL OF SALVAGED MATERIAL: The Contractor shall remove salvaged material and equipment from the Project site and dispose of it in accordance with the law. Equipment or material identified in the Specifications or Plans for Owner salvage shall be carefully removed and delivered to the Owner at any location in within the City limits as directed by the City. General Conditions of the Contract for Construction Lump Sum Contract Page 15 of 28 CFW PMD — Crime Lab Full Building Generator Replacement — Project #102986 August 2023 G-32 MANUFACTURER'S REFERENCE: Catalog, brand names, and manufacturer's references are descriptive, not restrictive. Bids on brands of like nature and quality will be considered. Contractor shall inform the City of any substitutions intended for the project within 5 business days of bid opening. Failure to inform the City of substitute projects will obligate the Contractor to provide the specified material if awarded the contract. Within 14 days after bid opening and upon request of the Contractor, the Contractor will submit a full sized sample and/or detailed information as required to allow the architect to determine the acceptability of proposed substitutions. Where equipment has been listed as "no substitute accepted"; the City will accept no alternates to the specified equipment. SECTION H CONTRACT TIME H-1 DEFINITIONS The Contract Time is the period of time allotted in the Contract Documents for completion of the Work and is the number of calendar days elapsing between the date of commencement and the date of Substantial Completion plus additional days assessed for failure to complete punch list items from the Final Inspection in a timely manner and additional weather days beyond what is allotted in the contract. The Date of Commencement of the Work is the date established in the Notice to Proceed. See attachment "A" for a sample Notice to Proceed. The Date of Substantial Completion of the Work or designated portion thereof is the Date certified by the Architect with the approval of the Owner that construction is sufficiently complete, in accordance with the Contract Documents, so the Owner may occupy the Work or designated portion thereof for the use for which it is intended. Final acceptance of the completed work or any portion thereof can be made only by the Owner, and no other form of acceptance will be binding upon the Owner. A Calendar Dav constitutes 24 hours of time and is any one of the seven days of a week, including Sunday, regardless of whether a "Working Day" or not, and regardless of weather conditions or any situation which might delay construction. An extension of contract time shall be in accordance with this Section. Extensions of time will be as recommended by the Architect with final approval by City of Fort Worth. A Working Dav is defined as a calendar day, not including Saturdays, Sundays, and legal holidays, in which weather or other conditions not under the control of the Contractor permit the performance of work for a continuous period of not less than seven hours between 7:00 a.m. and 6:00 p.m. However, nothing in these Contract Documents shall be construed as prohibiting the Contractor from working on Saturdays if he so desires. Legal holidays for the City of Fort Worth are defined as being New Year's Day, Independence Day, Labor Day, Thanksgiving Day, and the day after Thanksgiving, Christmas Day, Memorial Day and Martin Luther King Jr. Day. H-2 PROGRESS AND COMPLETION: All the time limits stated in the Contract Documents are of essence to the Contract. The Contractor shall begin the Work on the date of commencement as defined in this Section. He shall carry the Work forward expeditiously with adequate forces and shall complete it within the Contract Time. H-3 CONSTRUCTION WORK: Noise created by construction work within three hundred (300) feet of an occupied residential structure involving the erection, excavation, demolition, alteration, or repair of any building, structure, or flatwork is prohibited as follows: Before 7:00 a.m. or after 8:00 p.m. Monday -Friday Before 9:00 a.m. or after 8:00 p.m. Saturday -Sunday H-4 DELAYS AND EXTENSIONS OF TIME: If the Contractor is delayed at any time in the progress of the Work by any act or neglect of the Owner or the Architect, or by any employee of the Owner, or by any separate contractor employed by the Owner, or by changes ordered in the Work, or by labor disputes, fire, unusual delay in transportation, unavoidable casualties or any causes beyond the Contractor's control, or by any cause which the Architect determines may justify the delay, then the contract time may be extended by Change Order for such reasonable time as recommended by the Architect and approved by the Owner. When the Contractor is delayed due to abnormal weather conditions, the weather table provided as WT-1 in these Contract Documents shall be used as the basis for providing a fair and equitable adjustment of the contract time. All claims for extension of time shall be made in writing to the Architect no more than fifteen days after the occurrence of the delay; otherwise they shall be waived. If no schedule or agreement is made stating the dates upon which written interpretations shall be furnished, then no claim for delay shall be allowed on account of failure to furnish such interpretation until fifteen days after demand is made for them, and not then unless such a claim is reasonable. H-5 NO DAMAGE FOR DELAY: No payment, compensation or adjustment or any kind (other than the extensions of time provided for) shall be made to the Contractor for damages because of hindrances or delays from an cause in the progress of the work, whether such hindrances or delays be avoidable or unavoidable, and the Contractor agrees that he will make no claim for compensation, damages or mitigation of liquidated damages for any such delays, and will accept in full satisfaction for such delays said extension of time. General Conditions of the Contract for Construction Lump Sum Contract Page 16 of 28 CFW PMD — Crime Lab Full Building Generator Replacement — Project #102986 August 2023 SECTION I PAYMENTS AND COMPLETION 1-1 CONTRACT SUM: The Contract Sum is stated in the contract and is the total amount payable by the Owner to the Contractor for the performance of the Work under the Contract Documents. 1-2 SCHEDULE OF VALUES: Before the first Applicable for Payment, the Contractor shall submit to the Architect a Schedule of Values of the various portions of the Work, including quantities if required by the Architect, aggregating the total Contract Sum, divided so as to facilitate payments to Sub -contractors, prepared in such form as specified or as the Architect and the Contractor may agree upon, and supported by such data to substantiate its correctness as the Architect may require. Each item in the Schedule of Values shall include its proper share of overhead and profit. This Schedule, when approved by the Architect and the Owner, shall be used as a basis for the Contractor's Applications for Payment. 1-3 PROGRESS PAYMENTS: On the first day of each month after the first month's work has been completed, the Contractor will make current estimates in writing for review by the Architect and Owner of materials in place complete and the amount of work performed during the preceding month or period and the value thereof at the prices contracted for as shown on the approved Schedule of Values and Progress Schedule. If payments are to be made on account of materials or equipment not incorporated in the Work but delivered and suitably stored at the site such payments shall be conditioned upon submission by the Contractor of bills of sale or such other procedures satisfactory to the Owner to establish the Owner's title to such materials or equipment or otherwise protect the Owner's interest including applicable insurance and transportation to the site. The Contractor warrants and guarantees that title to all Work, materials and equipment covered by an Application for Payment, whether incorporated in the Project or not, will pass to the Owner upon the receipt of such payment by the Contractor, free and clear of all liens, claims, security interests or encumbrances hereinafter referred to as "liens"; and that no Work, materials or equipment covered by an Application for Payment will have been acquired by the Contractor, or by any other persons performing the Work at the site or furnishing materials and equipment for the Work, subject to an agreement under which an interest therein or an encumbrance thereon is retained by the seller or otherwise imposed by the Contractor or such other person. The Contractor shall prepare each application for payment on AIA Document G702, "Application and Certificate for Payment", and attached thereto AIA Document G703, "Continuation Sheet", to indicate the progress made to date and the period or month for which payment is requested for each Item listed in the Schedule of Values. A copy of the revised monthly work progress schedule must be attached before the pay request can be accepted. 1-4 CERTIFICATES FOR PAYMENT: If the Contractor has made Application for Payment as above, the Architect will, with reasonable promptness but not more than seven days after the receipt of the Application, prepare a Certificate of Payment, with a copy to the Contractor, for such amount determined to be properly due, or state in writing reasons for withholding a Certificate. The issuance of a Certificate for Payment will constitute a representation by the Owner, based on the Architect's observations at the site and the data comprising the Application for Payment, that the Work has progressed to the point indicated; that the quality of the Work is in accordance with the Contract Documents (subject to an evaluation of the Work as a functioning whole upon Substantial Completion, to the results of any subsequent tests required by the Contract Documents, to minor deviations from the Contract Documents correctable prior to completion, and to any specific qualifications stated in the Certificate); and recommendations to the Owner that the Contractor be paid in the amount certified. In addition, the Architect's approval of final payment assures the Owner that the conditions precedent to the Contractor's being entitled to final payment as set forth in this Section have been fulfilled. After the Architect has issued a Certificate for Payment, the Owner shall approve or disapprove same within ten days after it has been delivered to the Owner. For contracts less than $400,000, Owner shall pay 90% of the approved estimate to the Contractor within seven days after its approval, and the remaining 10% of each such estimate will be retained by the Owner until Substantial Completion. For contracts in excess of $400,000, the Owner will retain only 5% of each estimate until Substantial Completion. No Certificate for a progress payment, nor any progress payment, nor any partial or entire use or occupancy of the Project by the Owner, shall constitute an acceptance of any Work not in accordance with the Contract Documents, or relieve the Contractor of liability in respect to any warranties or responsibility for faulty materials or workmanship. The Contractor shall promptly remedy any defects in the Work and pay for any damage to other work resulting therefrom that shall appear within a period of one year from the date of final acceptance of the Work unless a longer period is specified. 1-5 PAYMENTS WITHHELD: The Architect may decline to approve an Application for Payment and may withhold his Certificate in whole or in part if in his opinion he is unable to make the representations to the Owner as provided in this Section. The Architect may also decline to approve any Applications for Payment or, because of subsequently discovered evidence or subsequent inspections, may nullify the whole or any part of any Certificate for Payment previously issued to such extent as may be necessary in his opinion to protect the Owner from loss because of: 1) Defective work not remedied; 2) Claims filed or reasonable evidence indicating probable filing of claims; 3) Failure of the Contractor to make payments properly to Subcontractors, or for labor, materials or equipment; 4) Reasonable doubt that the Work can be completed for the unpaid balance of the Contract Sum; General Conditions of the Contract for Construction Lump Sum Contract Page 17 of 28 CFW PMD — Crime Lab Full Building Generator Replacement — Project #102986 August 2023 5) Damage to another contractor; 6) Reasonable indication that the Work will not be completed within the Contract Time; or 7) Unsatisfactory prosecution of the Work by the Contractor. When such grounds for the refusal of payment are removed, payment shall be made for amounts withheld because of them. The Owner reserves the right to withhold the payment of any monthly estimate, without payment of interest, if the Contractor fails to perform the Work in accordance with the specifications. 1-6 LIQUIDATED DAMAGES: The parties agree and acknowledge that actual damages are uncertain and difficult to ascertain because the Project relates to construction for a municipality. Normal damages of lost rent or profit are not applicable in this circumstance because the City is a municipality and the Project will not receive rent and the City will not have lost profits. Therefore, the parties agree that because City's actual damages are too difficult to ascertain that the liquidated damages stated below are reasonable and a correct representation of actual damages to the City. The parties also agree that the liquidated damages called for in this contract are not a penalty but an agreed upon damages calculation by two sophisticated parties. The deduction for liquidated damages shall be as follows: Amount of Contract Liquidated Damages per Day $15,000 or less $45 $15,001 to $25,000 $63 $25,001 to $50,000 $105 $50,001to $100,000 $154 $100,000to $500,000 $210 $500,001to $1,000,000 $315 $1,000,001 to $2,000,000 $420 $2,000,001 to $5,000,000 $630 $5,000,001 to $10,000,000 $840 Over$10,000,000 $980 1-7 FAILURE OF PAYMENT: If, without fault on the part of the Contractor, the Architect should fail to issue any Certificate for Payment within seven days after receipt of the Contractor's Application for Payment, if the Contractor's Application for Payment, or if, without fault on the part of the Contractor, the Owner should fail to approve such estimate or to pay to the Contractor 90% or 95% (as applicable) of the amount thereof within the period of time specified, then the Contractor may, upon seven (7) days additional written notice to the Owner and to the Architect, stop the Work until payment of the amount owing has been received. 1-8 SUBSTANTIAL COMPLETION AND FINAL PAYMENT: Prior to the request for final payment, the Contractor must meet all provisions for Project Closeout. When the Contractor determines that the Work is substantially complete, the City shall inspect the project with the Contractor and the contractor will prepare a "Preliminary Punch List". When the Architect, on the basis of a subsequent inspection, determines that the Work is substantially complete, he then will prepare a Certificate of Substantial Completion (G704) which, when approved by the Owner, shall allow the Contractor to request a Certificate of Occupancy which will establish the Date of Substantial Completion. The Certificate of Substantial Completion shall state the responsibilities of the Owner and the Contractor for maintenance, heat, utilities, and insurance, shall set forth the remaining work as a "final punch list". The Contractor shall complete the remaining work listed therein within 30 calendar days. When the Certificate of Occupancy has been issued, the retainage may be reduced to 4%. Upon completion of the work listed on the final punch list to the satisfaction of the City of Fort Worth, the retainage may be reduced to 2.5%. Should the Contractor fail to complete all contractual requirements of the contract, including submittals and final pay request within the fixed time, the contract time will again commence. Should the Contractor fail to complete the work within the contract duration, liquidated damages will be assessed Upon receipt of written notice that the Work is ready for final inspection, the City will conduct a joint inspection and certify completion of the final punch list by cosigning it with the Contractor. The Contractor shall submit the following items to the City prior to requesting final payment: 1) Contractor's Affidavit of Payment of Debts and Claims (G706) stating that all payrolls, bills for materials and equipment, and other indebtedness connected with the Work for which the Owner or his property might in any way be responsible, have been paid or otherwise satisfied, 2) Consent of Surety to Final Payment (G707), if any, to final payment, 3) Contractor's Affidavit of Release of Liens (G706A), and, 4) Other data establishing payment or satisfaction of all such obligations, such as receipts, releases, and waivers of liens arising out of the Contract, to the extent and in such form as may be designated by the Owner. 5) Contractor's Warranty 6) Statement that all outstanding work has been completed General Conditions of the Contract for Construction Lump Sum Contract Page 18 of 28 CFW PMD — Crime Lab Full Building Generator Replacement — Project #102986 August 2023 7) Issuance of the Final Certificate of Substantial Completion 8) Final acceptance by the City of Fort Worth. If any Subcontractor, materialman or laborer refuses to furnish a Contractor's Affidavit of Release of Liens, the Contractor may, at the election of the Owner, furnish a bond satisfactory to the Owner to indemnify him against any right, claim or lien which might be asserted by such Subcontractor, materialman or laborer. If any such right, claim or lien remains unsatisfied after all payments are made. The Contractor shall refund to the Owner all monies that the latter may be compelled to pay to discharging such right, claim or lien, including all costs and reasonable attorney's fees. The Contractor may then request final payment. The acceptance of final payment shall constitute a waiver of all claims by the Contractor except those previously made in writing and still unsettled. The Contractors one-year warranty will commence upon Substantial Completion of the Project. Prior to the expiration of the one year warranty there will be a walk through attended by the Owner, Architect, and Contractor to identify any items that need to be addressed. These items will be agreed upon by all parties and the contractor will complete the work within 30 days. The designated representative of the City of Fort Worth will make final acceptance and no other form of acceptance will be binding upon the Owner. 1-9 FINAL PAYMENT FOR UN -BONDED PROJECTS: Final payment will not be made for a period of 30 calendar days and until all requirements have been met, with the exception of Consent of Surety for Final Payment. SECTION J PROTECTION OF PERSONS AND PROPERTY J-1 SAFETY PRECAUTIONS AND PROGRAMS: The Contractor shall be responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the Work. The Contractor shall designate a responsible member of his organization at the site whose duty shall be the prevention of accidents. This person shall be the Contractor's superintendent unless otherwise designated in writing by the Contractor to the Architect. J-2 SAFETY OF PERSONS AND PROPERTY: The Contractor shall take all reasonable precautions for the safety of, and shall provide all reasonable protection to prevent damage, injury or loss to: (1) All employees on the Work and all other persons who may be affected thereby; (2) All the Work and all materials and equipment to be incorporated therein, whether in storage on or -off the site, under the care, custody or control of the Contractor or any of his Subcontractors or Sub -contractors; and (3) Other property at the site or adjacent thereto, including trees, shrubs, lawns, walks, pavements, roadways, structures and utilities not designated for removal, relocation or replacement in the course of construction. Until acceptance of the Work, it shall be under the charge and care of the Contractor, and he shall take every precaution against injury or damage to the Work by the action of the elements or from any other cause whatsoever, whether arising from the execution or from the non -execution of the Work. The Contractor shall rebuild, repair, restore and make good, at his own expense, all injuries or damages to any portion of the Work occasioned by any of the above, caused before its completion and acceptance. The Contractor shall comply with all applicable Laws, Ordinances, Rules, Regulations and Orders of any public authority having jurisdiction for the safety of persons or property or to protect them from damage, injury or loss. He shall erect and maintain, as required by existing conditions and progress of the Work, all reasonable safeguards for safety and protection, including posting danger signs and other warnings against hazards, promulgating safety regulations and notifying owners and users of adjacent utilities. When the use or storage of explosives or other hazardous materials or equipment is necessary for the execution of the Work, the Contractor shall exercise the utmost care and shall carry on such activities under the supervision of properly qualified personnel. All damage or loss to any property referred to in the preceding paragraphs caused in whole or in part by the Contractor, any Subcontractor, or anyone directly or indirectly employed by any of them, or by anyone for whose acts any of them may be liable, shall be remedied by the Contractor, including damage or loss attributable to faulty Drawings or Specifications and acts or omissions of the Architect or anyone employed by him or for whose acts he may be liable, and not attributable to the fault or negligence of the Contractor or anyone claiming through the Contractor for such damage or loss. The Contractor shall not load or permit any part of the Work to be loaded so as to endanger its safety. J-3 HARD HATS: Hard Hats will be required at all construction sites included in this Contract from start to completion of work. Each Contractor, employee and visitor at any construction site included in the Contract will be required to wear a hard hat. The Contractor shall enforce the wearing of hard hats by Contractor, employees and visitors. Contractor shall provide hard hats for use by the consulting Architects and Engineers and visitors. General Conditions of the Contract for Construction Lump Sum Contract Page 19 of 28 CFW PMD — Crime Lab Full Building Generator Replacement — Project #102986 August 2023 J-4 EMERGENCIES: In any emergency affecting the safety of persons or property, the Contractor shall act at his discretion to prevent threatened damage, injury or loss. Any additional compensation or extension of time claimed by the Contractor on account of emergency work shall be determined as provided in Changes in the Work. J-5 SAFE WORK PRACTICES: The Contractor shall employ safe practices in handling materials and equipment used in performing required work so as to insure the safety of his workmen, City employees and the public. The Contractor shall keep the premise free at all times from accumulation of waste materials or rubbish. At the completion of the work, the Contractor shall remove all his wastes and rubbish from and about the work area, as well as his tools, equipment and surplus materials and shall leave the area as clean and free of spot, stains, etc., as before the work was undertaken. J-6 TRENCH SAFETY: The Contractor shall be responsible for all design and implementation of trench shoring and stabilization to meet regulatory requirements. If the Proposal requires, the Contractor shall include a per -unit cost for trench safety measures in his bid. If not included in the Proposal, the Contractor shall include a cost for trench safety measures for all trenches over 5 feet in depth in his Schedule of Values. SECTION K - INSURANCE K-1 INSURANCE REQUIRED: The Contractor shall not commence work under this Contract until he has obtained all insurance required under this Section and such insurance has been approved by the City of Fort Worth, nor shall the Contractor allow any Subcontractor to commence work to be performed under this Contract until all similar insurance of the Subcontractor has been so obtained and approved. The City of Fort Worth will be listed as an "additional insured" on all policies except Worker's Compensation. K-2 WORKERS' COMPENSATION INSURANCE 1) General: a) Contractor's Worker's Compensation Insurance. Contractor agrees to provide to the Owner (City) a certificate showing that it has obtained a policy of workers compensation insurance covering each of its employees employed on the project in compliance with state law. No Notice to Proceed will be issued until the Contractor has complied with this section. b) Subcontractor's Worker's Compensation Insurance. Contractor agrees to require each and every subcontractor who will perform work on the project to provide to it a certificate from such subcontractor stating that the subcontractor has a policy of workers compensation insurance covering each employee employed on the project. Contractor will not permit any subcontractor to perform work on the project until such certificate has been acquired. Contractor shall provide a copy of all such certificates to the Owner (City). c) By signing this Contract or providing or causing to be provided a certificate of coverage, the Contractor is representing to the City that all employees of the Contractor who will provide services on the project will be covered by worker's compensation coverage for the duration of the project, that the coverage will be based on proper reporting of classification codes and payroll amounts, and that all coverage agreements will be filed with the appropriate insurance carrier or, in the case of a self -insured, with the Texas Worker's Compensation Commission's Division of Self -Insurance Regulation. Providing false or misleading information may subject the Contractor to administrative penalties, criminal penalties, civil penalties or other civil actions. d) The Contractor's failure to comply with any of these provisions is a breach of contract by the Contractor which entitles the City to declare the contract void if the Contractor does not remedy the breach within ten days after receipt of notice of breach from the City. 2) Definitions: a) Certificate of Coverage ("certificate"). A copy of a certificate of insurance, a certificate of authority to self -insure issued by the Texas Workers' Compensation Commission, or a coverage agreement (TWCC-81, TWCC-82, TWCC-83, or TWCC- 84), showing statutory workers' compensation insurance coverage for the person's or entity's employees providing services on a project, for the duration of the project. b) Duration of the Project. Includes the time from the beginning of the work on the project until the Contractor's/person's work on the project has been completed and accepted by the City. c) Persons providing services on the project ("subcontractor" in section 406.096)-includes all persons or entities performing all or part of the services the Contractor has undertaken to perform on the project, regardless of whether that person contracted directly with the Contractor and regardless of whether that person has employees. This includes, without limitation, independent contractors, subcontractors, leasing companies, motor carriers, owner -operators, employees of any such entity, or employees of any entity which furnishes persons to provide services on the project. "Services" include, without limitation, providing, hauling, or delivering equipment or materials, or providing labor, transportation, or other services related to a project. "Services" does not include activities unrelated to the project, such as food/beverage vendors, office supply deliveries, and delivery of portable toilets. 3) Requirements: a) The Contractor shall provide coverage, based on proper reporting of classification codes and payroll amounts and filing of any coverage agreements, which meets the statutory requirements of Texas Labor Code, Section 401.011(44) for all employees of the Contractor providing services of the project, for the duration of the project. General Conditions of the Contract for Construction Lump Sum Contract Page 20 of 28 CFW PMD — Crime Lab Full Building Generator Replacement — Project #102986 August 2023 b) The Contractor must provide a certificate of coverage to the governmental entity prior to being awarded the contract. c) If the coverage period shown on the Contractor's current certificate of coverage ends during the duration of the project, the Contractor must, prior to the end of the coverage period, file a new certificate of coverage with the City showing that coverage has been extended. d) The Contractor shall obtain from each person providing services on a project, and provide to the City: i) a certificate of coverage, prior to that person beginning work on the project, so the governmental entity will have on file certificates of coverage showing coverage for all persons providing services on the project; and ii) no later than seven days after receipt by the Contractor, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the project. e) The Contractor shall retain all required certificates of coverage for the duration of the project and for one year thereafter. f) The Contractor shall notify the City in writing by certified mail or personal delivery, within ten (10) days after the Contractor knew or should have known, of any change that materially affects the provision of coverage of any person providing services on the project. g) The Contractor shall post on each project site a notice, in the text, form and manner prescribed by the Texas Worker's Compensation Commission, informing all persons providing services on the project that they are required to be covered, and stating how a person may verify coverage and report lack of coverage. h) The Contractor shall contractually require each person with whom it contracts to provide services on a project, to: i) provide coverage, based on proper reporting on the classification codes and payroll amounts and filing of any coverage agreements, which meets the statutory requirements of Texas labor Code, Section 401.011(44) for all of its employees providing services on the project, for the duration of the project; ii) provide to the Contractor, prior to that person beginning work on the project, a certificate of coverage showing that coverage is being provided for all employees of the person providing services on the project, for the duration of the project; iii) provide the Contractor, prior to the end of the coverage period, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the project; iv) obtain from each other person with whom it contracts, and provide to the Contractor: (1) a certificate of coverage, prior to the other person beginning work on the project; and (2) a new certificate of coverage showing extension of coverage, prior to the end of the coverage period, if the coverage period shown on the current certificate of coverage ends during the duration of the project; v) retain all required certificates of coverage on file for the duration of the project and for one year thereafter. vi) notify the City in writing by certified mail or personal delivery, within ten (10) days after the person knew or should have known, of any change that materially affects the provision of coverage of any person providing services on the project; and vii) contractually require each person with whom it contracts, to perform as required by paragraphs h-i) - vii), with the certificates of coverage to be provided to the person for whom they are providing services. 4) Posting of Required Worker's Compensation Coverage: a) The Contractor shall post a notice on each project site informing all persons providing services on the project that they are required to be covered, and stating how a person may verify current coverage and report failure to provide coverage. This notice does not satisfy other posting requirements imposed by the Texas Worker's Compensation Act or other Texas Worker's Compensation Commission rules. This notice must be printed with a title in at least 30 point bold type and text in at least 19-point normal type, and shall be in both English and Spanish and any other language common to the worker population. The text for the notices shall be the following text, without any additional words or changes: "REQUIRED WORKER'S COMPENSATION COVERAGE The law requires that each person working on this site or providing services related to this construction project must be covered by worker's compensation insurance. This includes persons providing, hauling, or delivering equipment or materials, or providing labor or transportation or other service related to the project, regardless of the identity of their employer or status as an employee". Call the Texas Worker's Compensation Commission at 512-440-3789 to receive information on the legal requirement for coverage, to verify whether your employer has provided the required coverage, or to report an employer's failure to provide coverage." K-3 LIABILITY INSURANCE: The Contractor shall procure and maintain during the term of this Contract such Liability Insurance as shall protect him, the City of Fort Worth and any Subcontractor performing work covered by this Contract, from claims of damage which may arise from operations under this Contract, including blasting, when blasting is done on, or in connection with General Conditions of the Contract for Construction Lump Sum Contract Page 21 of 28 CFW PMD — Crime Lab Full Building Generator Replacement — Project #102986 August 2023 the Work of the Project, whether such operations be by himself or by any Subcontractor or by anyone directly or indirectly employed by either of them and the limits of such insurance shall be not less than the following: 1) Automobile Liability: $1,000,000 each accident or reasonably equivalent split limits for bodily injury and property damage. Coverage shall be on "any auto" including leased, hired, owned, non -owned and borrowed vehicles used in connection with this Contract. 2) Commercial General Liability: $1,000,000 each occurrence. Coverage under the policy shall be as comprehensive as that provided in a current Insurance Services Office (ISO) policy form approved for use in Texas and the policy shall have no exclusions by endorsement unless such are approved by the City. 3) Asbestos Abatement Liability Insurance: When the Project specifically requires the removal of Asbestos Containing Materials, the Contractor, or subcontractor performing the removal, shall be required to maintain Asbestos Abatement Liability Insurance as follows: $1,000,000 per occurrence; $2,000,000 aggregate limit. The coverage shall include any pollution exposure, including environmental impairment liability, associated with the services and operations performed under this contract in addition to sudden and accidental contamination or pollution liability for gradual emissions and clean-up costs. K-4 BUILDER'S RISK INSURANCE: Unless stated otherwise in the Proposal or Invitation, the Contractor shall procure, pay for and maintain at all times during the term of this Contract, Builder's Risk Insurance against the perils of fire, lightning, windstorm, hurricane, hail, riot, explosion, civic commotion, smoke, aircraft, land vehicles, vandalism, and malicious mischief, at a limit equal to 100% of the Contract Sum. The policy shall include coverage for materials and supplies while in transit and while being stored on or off site. If specifically required in the Instructions to Bidders, the policy shall include coverage for flood and earthquake. Different sub -limits for these coverages must be approved by the City. Consequential damage due to faulty workmanship and/or design performed by the Contractor or his agents shall be covered. Upon completion of the Work, the Contractor shall notify the City of Fort Worth in writing before terminating this insurance. K-5 PROOF OF CARRIAGE OF INSURANCE: The Contractor shall provide a certificate of insurance documenting the Property Management Department, City of Fort Worth as a "Certificate Holder", and noting the specific project(s) covered by the Contractor's insurance as documented on the certificate of insurance. More than one certificate may be required of the Contractor depending upon the agents and/or insurers for the Contractor's insurance coverages specified for the project(s). K-6 OTHER INSURANCE RELATED REQUIREMENTS 1) The City of Fort Worth shall be an additional insured, by endorsement, on all applicable insurance policies. 2) Applicable insurance policies shall each be endorsed with a waiver of subrogation in favor of the City of Fort Worth. 3) Insurers of policies maintained by Contractor and its subcontractor(s), if applicable, shall be authorized to do business in the State of Texas, or otherwise approved by the City of Fort Worth, and such shall be acceptable to the City of Fort Worth insofar as their financial strength and solvency are concerned. Any company through which the insurance is placed must have a rating of at least A:VII, as stated in current edition of A. M. Best's Key Rating Guide. At the City's sole discretion, a less favorable rate may be accepted by the City. 4) Deductible limits on insurance policies and/or self -insured retentions exceeding $10,000 require approval of the City of Fort Worth as respects this Contract. 5) The City of Fort Worth shall be notified in writing a minimum of thirty days prior to an insurer's action in the event of cancellation or non -renewal in coverage regarding any policy providing insurance coverage required in this Contract. 6) Full limits of insurance shall be available for claims arising out of this Contract with the City of Fort Worth. 7) The Contractor shall provide certificates of insurance to the City prior to commencement of operations pursuant to this Contract. Any failure on part of the City of Fort Worth to request such documentation shall not be construed as a waiver of insurance requirements specified herein. 8) The City of Fort Worth shall be entitled, upon request and without incurring expense, to review the insurance policies including endorsements thereto and, at its discretion, to require proof of payment for policy premiums. 9) The City of Fort Worth shall not be responsible for paying the cost of insurance coverages required herein. 10) Notice of any actual or potential claim and/or litigation that would affect insurance coverages required herein shall be provided to the City in a timely manner. 11) "Other insurance" as referenced in any policy of insurance providing coverages required herein shall not apply to any insurance policy or program maintained by the City of Fort Worth. 12) Contractor shall agree to either require its subcontractors to maintain the same insurance coverages and limits thereof as specified herein or the Contractor shall provide such coverage on the Contractor's subcontractors. General Conditions of the Contract for Construction Lump Sum Contract Page 22 of 28 CFW PMD — Crime Lab Full Building Generator Replacement — Project #102986 August 2023 SECTION L CHANGES IN THE WORK L-1 CHANGE ORDER: The Owner, without invalidating the Contract, may order Changes in the Work within the general scope of the Contract consisting of additions, deletions or other revisions, the Contract Sum and the Contract Time being adjusted accordingly. All Such Changes in the Work shall be authorized by Change Order, and shall be executed under the applicable conditions of the Contract Documents. A Change Order is a written order to the Contractor signed by the Contractor, Owner and the Architect, issued after the execution of the Contract, authorizing a Change in the Work or adjustment in the Contract Sum or the Contract Time. The Contract Sum and the Contract Time may be changed only by Change Order. Any changes in work required due to changed or unforeseen conditions, or by request of either the Contractor or the City, shall be coordinated with the Director, Property Management Department. A change order must be written and duly negotiated and executed prior to performing changed work. The cost or credit to the Owner resulting from a Change in the work shall be determined in one or more of the following ways: 1) by mutual acceptance of a lump sum property itemized, including the allowance to Contractor for overhead and profit stipulated in the original contract proposal; 2) by unit prices stated in the Contract Documents or subsequently agreed upon; or 3) by cost and a mutually acceptable fixed or percentage fee. If none of the methods set forth herein above is agreed upon, the Contractor, provided he receives a Change Order, shall promptly proceed with the Work involved. The cost of such work shall then be determined on the basis of the Contractor's reasonable expenditures and savings, including a reasonable allowance for overhead and profit as indicted in the original contract proposal. In such cases, the Contractor shall keep and present, in such form as the Architect shall prescribe, an itemized accounting together with appropriate supporting data. Pending final determination of cost to the Owner, payments on account shall be made on the Architect's Certificate of Payment as approved by the Owner. If after the Contract has been executed, the Architect, requests a price proposal from the Contractor for a proposed change in scope of the work, Contractor shall process such proposal within seven days of receipt and return the price quote to the Architect in writing. The Architect shall review the price quotation and if approval is recommended, forward the proposed change order request and price proposal to the Owner for approval. If approval is not recommended, the Architect will attempt to negotiate with Contractor to revise the proposal to a figure which is fair and reasonable and forward it on to the Owner for approval. If the negotiations do not result in an equitable solution, the Architect shall prepare a cost-plus type Change Order with a price -not -to -exceed figure for approval by the City and require specific documentation to be provided by Contractor in accordance with the paragraph above. Contractor is advised that according to City of Fort Worth Charter, that, the City Council must approve all Change Orders and Work Orders which results in an increase in cost of the contract amount by over $100,000. Normal processing time for the City Staff to obtain City Council approval, once the recommended change order has been received at the City, is approximately thirty days. Owner and Contractor shall endeavor to identify Change Order items as early in the Construction process as possible to minimize their impact on the construction schedule. If unit prices are stated in the Contract Documents or subsequently agreed upon, and if the quantities originally contemplated are so changed in a proposed Change Order that application of the agreed unit prices to the quantities of Work proposed will create a hardship on the Owner or the Contractor, the applicable unit prices shall be equitably adjusted to prevent such hardship. If the Contractor claims that additional cost or time is involved because of (1) any written interpretation issued pursuant to Section A, (2) any order by the Architect or Owner to stop the Work pursuant to Section B, where the Contract was not at fault, or (3) any written order for a minor change in the Work, the Contractor shall make such claim. L-2 CLAIMS FOR ADDITIONAL COST OR TIME: If the Contractor wishes to make a claim for an increase in the Contract Sum or an extension in the Contract Time, he shall give the Architect written notice thereof within a reasonable time after the occurrence of the event that gave rise to such claim. This notice shall be given by the Contractor before proceeding to execute the Work, except in an emergency endangering life or property in which case the Contractor shall proceed in accordance with Section J. No such claim shall be valid unless so made. Any change in the Contract Sum or Contract Time resulting from such claim, if approved by the Owner, shall be authorized by Change Order. L-3 OVERHEAD ALLOWANCES FOR CHANGES: Should any change in the work or extra work be ordered, the following applicable percentage shall be added to Material and Labor costs to cover overhead and profit: 1. Allowance to the Contractor for overhead and profit for extra work performed by the Contractor's own forces shall not exceed fifteen percent 15% . 2. Allowance to the Contractor for overhead and profit for extra work performed by a Subcontractor and supervised by the Contractor shall not exceed ten percent 1( 0%l. L-4 MINOR CHANGES IN THE WORK: The Architect shall have authority to order minor changes in the Work not involving an adjustment in the Contract Sum or an extension of the Contract Time and not inconsistent with the intent of the Contract General Conditions of the Contract for Construction Lump Sum Contract Page 23 of 28 CFW PMD — Crime Lab Full Building Generator Replacement — Project #102986 August 2023 Documents. Such changes may be effected by Field Order or by other written order. Such changes shall be confirmed in writing by the Architect and shall be binding on the Owner and the Contractor. L-5 FIELD ORDERS: The Architect may issue written Field Orders which interpret the Contract Documents, or which order minor changes in the Work without change in Contract Sum or Contract Time. The Contractor shall carry out such Field Orders promptly. SECTION M UNCOVERING AND CORRECTION OF WORK M-1 UNCOVERING OF WORK: If any Work should be covered contrary to the request of the Owner, it must be uncovered for observation and replaced, at the Contractor's expense. If any other work has been covered which the Owner has not specifically requested to observe prior to being covered, the Architect or the Owner may request to see such work and it shall be uncovered by the Contractor. If such Work be found in accordance with the Plans and Specifications, the cost of uncovering and replacement shall, by appropriate Change Order, be charged to the Owner. If such work be found not in accordance with the Plans and Specifications, the Contractor shall pay such costs unless it is found that this condition was caused by a separate contractor employed by the Owner. M-2 CORRECTION OF WORK: The Contractor shall promptly correct all work rejected by the Architect or Owner as defective or as failing to conform to the Plans and Specifications whether observed before or after Substantial Completion and whether or not fabricated, installed or completed. The Contractor shall bear all costs of correcting such rejected Work, including the cost of the Architect's additional service thereby made necessary. If, within one year after the Date of Substantial Completion or within such longer period of time as may be prescribed by law or by the terms of any applicable special guarantee required by the Contract Documents, any of the work is found to be defective or not in accordance with the Contract Documents, the Contractor shall correct it promptly after receipt of a written notice from the Owner to do so, unless the Owner has previously given the Contractor a written acceptance of such condition, describing same specifically and not generally. The Owner shall give such notice promptly after discovery of the condition. All such defective or non -conforming work under the preceding paragraphs shall be removed from the site where necessary and the work shall be corrected to comply with the Contract Documents without cost to the Owner. Defective or non -conforming work shall be completed in a timely manner. The Contractor shall respond and/or repair any work that is deemed an emergency by the City within 24 hours. The Contractor shall respond and/or repair any other defective or non- conforming work within three working days. The Contractor shall bear the cost of making good all work of separate contractors destroyed or damaged by such removal or correction. If the Contractor does not remove such defective or non -conforming work within a reasonable time fixed by written notice from the Owner, the Owner may remove it and may store the materials or equipment at the expense of the Contractor. If the Contractor does not pay the cost of such removal and storage within ten days thereafter, the Owner may upon ten additional days' written notice sell such work at auction or at private sale and shall account for the net proceeds thereof, after deducting all the costs that should have been borne by the Contractor including compensation for additional architectural services. If such proceeds of sale do not cover all costs that the Contractor should have borne, the difference shall be charged to the Contractor and an appropriate Change Order shall be issued. If the payments then or thereafter due the Contractor are not sufficient to cover such amount, the Contractor shall pay the difference to the Owner. If the Contractor fails to correct such defective or non -conforming work, the Owner may correct it in accordance with Section G. The obligation of the Contractor under this Section shall be in addition to and not in limitation of any obligations imposed upon him by special guarantees required by the Contract Documents or otherwise prescribed by law. M-3 ACCEPTANCE OF DEFECTIVE OR NON -CONFORMING WORK: If the Owner prefers to accept defective or non- conforming work, he may do so instead of requiring its removal and correction, in which case a Change Order will be issued to reflect an appropriate reduction in the Contract Sum, or, if the amount is determined after final payment, it shall be paid by the Contractor. SECTION N TERMINATION OF THE CONTRACT N-1 TERMINATION BY THE CONTRACTOR: If the work is stopped for a period of 30 days under an order or any court or other public authority having jurisdiction, through no act or fault of the Contractor or a Subcontractor or their agents or employees or any other persons performing any of the work under a contract with the Contractor, or if the work should be stopped for a period of 30 days by the Contractor for the Owner's failure to make payment thereon as provided in Section I, then the Contractor may after the end of such period of 30 days and upon seven additional days' written notice to the Owner, terminate the Contract. N-2 TERMINATION BY THE OWNER: If the Contractor is adjudged as bankrupt, or if he makes a general assignment for the benefit of his creditors, or if a receiver is appointed on account of his insolvency, or if the Contractor refuses, except in cases for which extension of time is provided, to supply enough properly skilled workmen or proper materials, or if he fails to make prompt General Conditions of the Contract for Construction Lump Sum Contract Page 24 of 28 CFW PMD — Crime Lab Full Building Generator Replacement — Project #102986 August 2023 payment to Subcontractors or for materials or labor, or fails to comply with all Laws, Statutes, Charter, Ordinances, Regulations or Orders of any public authority having jurisdiction, or otherwise is guilty of a substantial violation of a provision of the Contract Documents, then the Owner, on its own initiative that sufficient cause exists to justify such action, may, without prejudice to any rights or remedy and after giving the Contractor and his surety, if any, seven (7) days' written notice, terminate the employment of the Contractor and take possession of the site and of all materials, equipment, tools, construction equipment and machinery thereon owned by the Contractor and may finish the work by whatever method he may deem expedient. In such case the Contractor shall not be entitled to receive any further payment until the Work is finished. If the costs of finishing the Work, including compensation for the Architect's additional services exceed the unpaid balance of the Contract, the Contractor shall pay the difference to the Owner. The City of Fort Worth may terminate this contract in whole, or from time to time, in part, whenever such termination is in the best interest of the City. Termination will be effected by delivering to the Contractor a notice of termination specifying to what extent performance of the work of the contract is being terminated and the effective date of termination. After receipt of termination the Contractor shall: a) Stop work under the Contract on the date and to the extent specified on the notice of termination. b) Place no further orders or subcontracts except as may be necessary for the completion of the work not terminated. c) Terminate all orders and subcontracts to the extent that they relate to the performance of the work terminated by the notice of termination. After termination as above, the City will pay the Contractor a proportionate part of the contract price based on the work completed; provided, however, that the amount of payment on termination shall not exceed the total contract price as reduced by the portion thereof allocable to the work not completed and further reduced by the amount of payments, if, any otherwise made. Contractor shall submit its claim for amounts due after termination as provided in this paragraph within 30 days after receipt of such claim. In the event of any dispute or controversy as to the propriety or allowability of all or any portion of such claim under this paragraph, such dispute or controversy shall be resolved and be decided by the City Council of the City of Fort Worth, and the decision by the City Council of the City of Fort Worth shall be final and binding upon all parties to this contract. SECTION O SIGNS The Contractor shall construct and install the project designation sign as required in the Contract Documents and in strict accordance with the Specifications for "Project Designation Signs." This sign shall be a part of this Contract and shall be included in the Contractor's Base Bid for the Project. The Contractor may install their company sign and shall allow the Architect to install their company sign. No other signs will be allowed. SECTION P TEMPORARY FACILITIES P-1 SCOPE: The Contractor shall furnish, erect, and maintain facilities and perform temporary work required in the performance of this Contract, including those shown and specified. P-2 USE OF TEMPORARY FACILITIES: All temporary facilities shall be made available for use by all workmen and subcontractors employed on the project, subject to reasonable directions by the Contractor as to their proper and most efficient utilization. P-3 MAINTENANCE AND REMOVAL: The Contractor shall maintain temporary facilities in a proper, safe operating and sanitary condition for the duration of the Contract. Upon completion of the Contract, all such temporary work and facilities shall be removed from the premises and disposed of unless otherwise directed or specified hereunder. P-4 FIELD OFFICES AND SHED: The Contractor is not required to provide a temporary field office or telephone for projects under $1,000,000. Contractor shall equip the Project Superintendent with a pager and provide 24-hour contacts to the City. The Contractor shall provide a temporary field office building for himself, his subcontractors and use by the Architect and Owner. For construction contracts with a bid price in excess of $1,000,000.00, the Contractor shall provide a separate field office for the City's field representative (but the separate office may be in the same structure). The buildings shall afford protection against the weather, and each office shall have a lockable door, at least one window, adequate electrical outlets and lighting, and a shelf large enough to accommodate perusal of the project drawings. Openings shall have suitable locks. Field offices shall be maintained for the full time during the operation of the work of the Contract. During cold weather months, the field offices shall be suitably insulated and equipped with a heating device to maintain 70 degree Fahrenheit temperature during the workday. During warm weather the offices shall be equipped with an air conditioning device to maintain temperature below 75 degrees F. Upon completion of the work of the Contract, the Contractor shall remove the building from the premises. In addition to the drawing shelf, provide for the City field representatives office: one desk, four chairs, plan rack and a four drawer filing cabinet (with lock). Each office shall contain not less than 120 square feet of floor space. General Conditions of the Contract for Construction Lump Sum Contract Page 25 of 28 CFW PMD — Crime Lab Full Building Generator Replacement — Project #102986 August 2023 The Contractor shall provide and maintain storage sheds and other temporary buildings or trailers on the project site as required for his use. Location of sheds and trailers shall be as approved by the Owner. Remove sheds when work is completed, or as directed. P-5 WIRELESS CONNECTION: The Contractor shall provide and pay for wireless internet connection (WIFI) for the City and Architect. P-6 TOILET FACILITIES: The Contractor shall provide proper, sanitary and adequate toilet facilities for the use of all workmen and subcontractors employed on the project. P-7 UTILITIES: Contractor shall make all necessary arrangements and provide for temporary water and electricity required during the construction. Contractor shall provide and install temporary utility meters during the contract construction period. These meters will be read and the Contractor will be billed on this actual use. The Contractor shall provide all labor and materials required to tap into the utilities. The Contractor shall make the connections and extend the service lines to the construction area for use of all trades. Upon completion of the work all utility lines shall be removed and repairs made to the existing lines. Only utilities at existing voltages, pressures, frequencies, etc. will be available to the Contractor. Water. Provide an ample supply of potable water for all purposes of construction at a point convenient to the project or as shown on the Drawings. Pipe water from the source of supply to all points where water will be required. Provide sufficient hose to carry water to every required part of the construction and allow the use of water facilities to subcontractors engaged on the work. Provide pumps, tanks and compressors as may be required to produce required pressures. Electric Service. Provide adequate electric service for power and lighting to all points where required. Temporary, electric service shall be of sufficient capacity and characteristics to supply proper current for various types of construction tools, motors, welding machines, lights, heating plant, air conditioning system, pumps, and other work required. Provide sufficient number of electric outlets so that 50 foot long extension cords will reach all work requiring light or power. Lighting. Supply and maintain temporary lighting so that work of all trades may be properly and safely performed, in such areas and at such time that day -lighting is inadequate. Provide at least 0.75 watts of incandescent lighting per squgr4e foot and maintain a socket voltage of at least 110 volts. Use at least 100-watt lamps. In any event, the lighting intensity shall not be less than 5 foot candles in the vicinity of work and traffic areas. P-8 HEATING: Heating devices required under this paragraph shall not be electric. The Contractor shall provide heat, ventilation, fuel and services as required to protect all work and materials and to keep the humidity down to the extent required to prevent corrosion of any metal and to prevent dampness or mildew which is potentially damaging to materials and finishes. All such heating, ventilation and services shall be provided and maintained until final acceptance of all work. In addition, the Contractor shall provide heat ventilation prior and during the following work operations as follows: a) At all times during the placing, setting and curing of concrete provide sufficient heat to insure the heating of the spaces involved to not less than 40 F. b) From the beginning of the application of drywall and during the setting and curing period, provide sufficient heat to produce a temperature in the spaces involved of not less than 55 F. c) For a period of seven (7) days previous to the placing of interior finish materials and throughout the placing of finish painting, decorating and laying of resilient flooring materials, provide sufficient heat to produce a temperature of not less than 60 F. P-9 TEMPORARY CONSTRUCTION. EQUIPMENT AND PROTECTION: The Contractor shall provide, maintain, and remove upon completion of the work all temporary rigging, scaffolding, hoisting equipment, rubbish chutes, ladders to roof, barricades around openings, and all other temporary work as required to complete all work of the Contract. Contractor shall coordinate the use and furnishing of scaffolds with his sub -contractors. The Contractor shall provide, maintain, and remove upon completion of the work, or sooner, if authorized by the Owner, all fences, barricades, lights, shoring, pedestrian walkways, temporary fire escapes, and other protective structures or devices necessary for the safety of workmen, City employees, equipment, the public and property. All temporary construction and equipment shall conform to all regulations, ordinances, laws and other requirements of the authorities having jurisdiction, including insurance companies, with regards to safety precautions, operation and fire hazard. The Contractor shall provide and maintain pumping facilities, including power, for keeping the site, all times, whether from underground seepage, rainfall, drainage of broken lines. The Contractor shall maintain provision for closing and locking the building at such time as possible to do so. If this is not feasible, maintain a night The Contractor shall provide and maintain all barricades or enclosures, required to protect the work in progress from outside elements, dusts, and other disturbances as a result of work under this Contract. Such protection shall be positive, shall meet the approval of the Owner and shall be maintained for the duration of the construction period or as required to provide for the protection as specified. P-10 PROJECT BULLETIN BOARD: The Contractor shall furnish, install and maintain during the life of the project a weather - tight bulletin board approximately 3 feet high by 5 feet wide having not less than two hinged or sliding glass doors with provisions for General Conditions of the Contract for Construction Lump Sum Contract Page 26 of 28 CFW PMD — Crime Lab Full Building Generator Replacement — Project #102986 August 2023 locking. The bulletin board shall be mounted where and as approved by the Owner, in a prominent place accessible to employees of the Contractor and sub -contractors, and to applicants for employment. The bulletin board shall remain the property of the Contractor and shall be removed by him upon completion of the Contract work. The following information which will be furnished by the City to the Contractor shall be posted on the bulletin board and shall be maintained by the Contractor in easily readable condition at all times for the duration of the Contract. a. The Equal Opportunity Poster and Notice Nondiscrimination of Employment (Standard Form 38). b. Wage Rate Information Poster (Form SOL 155), with the Contract Schedule of minimum wage rates as required by the Davis -Bacon Act. C. Safety Posters. SECTION Q VENUE Should any action arise out of the terms and conditions of this contract, venue for said action shall lie in Tarrant County, Texas. General Conditions of the Contract for Construction Lump Sum Contract Page 27 of 28 CFW PMD — Crime Lab Full Building Generator Replacement — Project #102986 August 2023 FORTWORTH Attachment "A" Date: NOTICE TO PROCEED Contractor Address Phone: (xxx) xxx-xxxx Project Name: Gentlemen: Pursuant to the provisions of City Secretary Contract Number xxxxx this is your authority to proceed on the referenced project on date. Prior to commencing work, it will be necessary for you to contact James Diestel, Construction Superintendent, who will be in charge of subject project, and make arrangements with him to inspect project construction. He may be contacted at (817) 392-8072. Sincerely, James Diestel Construction Superintendent Cc: MAV13E Office File PROPERTY MANAGEMENT DEPARTMENT FACILITIES DIVISION THE CITY OF FORT WORTH * 401 WEST 13TH STREET * FORT WORTH, TEXAS 76102 (817) 392-2586 * FAx (817) 392-8488 General Conditions of the Contract for Construction Lump Sum Contract Page 28 of 28 CFW PMD — Crime Lab Full Building Generator Replacement — Project #102986 August 2023 CITY OF FORT WORTH, TEXAS CONSTRUCTION CONTRACT (LUMP SUM) THE STATE OF TEXAS § § KNOW ALL BY THESE PRESENTS: COUNTY OF TARRANT § This Agreement is made effective as of the date signed by the Assistant City Manager below between the CITY OF FORT WORTH, a municipal corporation of Tarrant County, Texas, organized and existing under and by virtue of a special charter adopted by the qualified voters within said City on the 11th day of December, A.D. 1924, under the authority (vested in said voters by the "Home Rule" provision) of the Constitution of Texas, and in accordance with a resolution duly passed at a regular, meeting of the City Council of said City, hereinafter called OWNER, and SDB.Inc. dba SDB Contracting Services of the City of Dallas County of Dallas , State of Texas, hereinafter called CONTRACTOR. WITNESSETH: That for and in consideration of the payments and agreements hereinafter mentioned to be made and performed by the Owner, and under the conditions expressed in the bond bearing even date herewith, the said Contractor hereby agrees with the said Owner to commence and complete the construction of certain improvements described as follows: City of Fort Worth Crime Lab Full Building Generator Replacement 3616 E. Lancaster Ave. Fort Worth, Texas 76103 PMD2023-10 That the work herein contemplated shall consist of furnishing as an independent contractor all labor, tools, appliances and materials necessary for the construction and completion of said project in accordance with the Plans and Specifications and Contract Documents adopted by the City Council of the City of Fort Worth, which Plans and Specifications and Contract Documents are hereto attached and made a part of this contract the same as if written herein. The Contractor hereby agrees and binds himself to commence the construction of said work within ten (10) days after being notified in writing to do so by the Owner. City agrees and binds itself to pay, and the said Contractor agrees to receive, for all of the aforesaid work, and for stated additions thereto or deductions there from, the price shown on the Proposal submitted by the successful bidder hereto attached and made a part hereof. Payment will be made in monthly installments upon actual work completed by contractor and accepted by the Owner and receipt of invoice from the Contractor. The agreed upon total contract amount shall be $150.000.00 Early Procurement Cost. Insurance Requirements: The Contractor shall not commence work under this contract until it has obtained all insurance required under the Contract Documents, and the Owner has approved such insurance. The Contractor shall be responsible for delivering to the Owner the sub -contractors' certificates of insurance for approval. The Contractor shall indicate on its certificate of insurance included in the documents for execution whether or not its insurance covers subcontractors. It is the intention of the Owner that the insurance coverage required herein shall include the coverage of all subcontractors. a. WORKER'S COMPENSATION INSURANCE: OFFICIAL RECORD • Statutory limits. CITY SECRETARY • Employer's liability: FT. WORTH, Tx Instruction to Offerors Page 21 of 32 Crime Lab Full Building Generator Replacement - Proj. #102986 Sept. 2023) • $100,000 disease each employee. • $500,000 disease policy limit. • $100,000 each accident. COMMERCIAL GENERAL LIABILITY INSURANCE: The Contractor shall procure and shall maintain during the life of this contract public liability insurance coverage in the form of a Commercial General Liability insurance policy to cover bodily injury, including death, and property damage at the following limits: $1,000,000 each occurrence and $2,000,000 aggregate limit. The insurance shall be provided on a project specific basis and shall be endorsed accordingly. • The insurance shall include, but not be limited to, contingent liability for independent contractors, XCU coverage, and contractual liability. C. BUSINESS AUTOMOBILE LIABILITY: • $1,000,000 each accident. • The policy shall cover any auto used in the course of the project. BUILDER'S RISK OR INSTALLATION FLOATER: This insurance shall be applicable according to the property risks associated with the project and commensurate with the contractual obligations specified in the contract documents. EXCESS LIABILITY UMBRELLA: $1,000,000 each occurrence; $2,000,000 aggregate limit. This insurance shall provide excess coverage over each line of liability insurance required herein. The policy shall follow the form(s) of the underlying policies. SCOPE OF INSURANCE AND SPECIAL HAZARD: The insurance required under the above paragraphs shall provide adequate protection for the Contractor and its subcontractors, respectively, against damage claims which may arise from operations under this contract, whether such operations be by the insured or by anyone directly or indirectly employed by it, against any insurable hazards which may be encountered in the performance of the Contract. PROOF OF CARRIAGE OF INSURANCE: The Contractor shall furnish the owner with satisfactory proof of coverage by insurance required in these Contract Documents in the amounts and by insurance carriers satisfactory to the Owner. The form to be used shall be the current Accord certificate of insurance form or such other form as the Owner may in its sole discretion deem acceptable. All insurance requirements made upon the Contractor shall apply to the sub -contractors, should the Contractor's insurance not cover the subcontractor's work operations performed in the course of this contracted project. ADDITIONAL INSURANCE REQUIREMENTS: The Owner, its officers, employees and servants shall be endorsed as an additional insured on Contractor's insurance policies excepting employer's liability insurance coverage under Contractor's workers' compensation insurance policy. Instruction to Offerors Page 22 of 33 Crime Lab Full Building Generator Replacement - Proj. #102986 Sept. 2023) Certificates of insurance shall be delivered to the City of Fort Worth, contract administrator in the respective department as specified in the bid documents, 200 Texas Street, Fort Worth, TX 76102, prior to commencement of work on the contracted project. Any failure on part of the Owner to request required insurance documentation shall not constitute a waiver of the insurance requirements specified herein. Each insurance policy shall be endorsed to provide the Owner a minimum thirty days' notice of cancellation, non -renewal, and/or material change in policy terms or coverage. A ten days' notice shall be acceptable in the event of non-payment of premium. Insurers must be authorized to do business in the State of Texas and have a current A.M. Best rating of A:VII or equivalent measure of financial strength and solvency. Deductible limits, or self -funded retention limits, on each policy must not exceed $10,000.00 per occurrence unless otherwise approved by the Owner. In lieu of traditional insurance, Owner may consider alternative coverage or risk treatment measures through insurance pools or risk retention groups. The Owner must approve in writing any alternative coverage. Workers' compensation insurance policy(s) covering employees employed on the project shall be endorsed with a waiver of subrogation providing rights of recovery in favor of the Owner. Owner shall not be responsible for the direct payment of insurance premium costs for contractor's insurance. j. Contractor's insurance policies shall each be endorsed to provide that such insurance is primary protection and any self -funded or commercial coverage maintained by Owner shall not be called upon to contribute to loss recovery. In the course of the project, Contractor shall report, in a timely manner, to Owner's officially designated contract administrator any known loss occurrence which could give rise to a liability claim or lawsuit or which could result in a property loss. Contractor's liability shall not be limited to the specified amounts of insurance required herein. M. Upon the request of Owner, Contractor shall provide complete copies of all insurance policies required by these contract documents. If this Contract is in excess of $25,000, the Contractor shall provide a Payment Bond in the full amount of the contract. If the contract is in excess of $100,000 Contractor shall provide both Payment and Performance Bonds for the full amount of the contract. Construction shall not start without a "Notice to Proceed". The Notice to Proceed shall not be issued without bonds in place. Contractor shall apply for all City of Fort Worth Permits and for any other permits required by this project. City of Fort Worth Permit fees are waived. Separate permits will be required for each facility. If the Contractor should fail to complete the work as set forth in the Plans and Specifications and Contract Documents within the time so stipulated, plus any additional time allowed as provided in the General Condi- tions, there shall be deducted from any monies due or which may thereafter become due him, the liquidated damages outlined in the General Conditions, not as a penalty but as liquidated damages, the Contractor and their Surety shall be liable to the Owner for such deficiency. Instruction to Offerors Page 23 of 33 Crime Lab Full Building Generator Replacement - Proj. #102986 Sept. 2023) IMMIGRATION NATIONALITY ACT: City actively supports the Immigration & Nationality Act (INA) which includes provisions addressing employment eligibility, employment verification, and nondiscrimination. Vendor shall verify the identity and employment eligibility of all employees who perform work under this Agreement. Vendor shall complete the Employment Eligibility Verification Form (1-9), maintain photocopies of all supporting employment eligibility and identity documentation for all employees, and upon request, provide City with copies of all 1-9 forms and supporting eligibility documentation for each employee who performs work under this Agreement. Vendor shall establish appropriate procedures and controls so that no services will be performed by any employee who is not legally eligible to perform such services. Vendor shall provide City with a certification letter that it has complied with the verification requirements required by this Agreement. Vendor shall indemnify City from any penalties or liabilities due to violations of this provision. City shall have the right to immediately terminate this Agreement for violations of this provision by Vendor. No Bovcott of Israel. If Contractor has fewer than 10 employees or the Agreement is for less than $100,000, this section does not apply. Contractor acknowledges that in accordance with Chapter 2270 of the Texas Government Code, City is prohibited from entering into a contract with a company for goods or services unless the contract contains a written verification from the company that it: (1) does not boycott Israel; and (2) will not boycott Israel during the term of the contract. The terms "boycott Israel" and "company" shall have the meanings ascribed to those terms in Section 808.001 of the Texas Government Code. By signing this Agreement, Contractor certifies that Contractor's signature provides written verification to City that Contractor: (1) does not boycott Israel; and (2) will not boycott Israel during the term of the Agreement. Prohibition on Bovcottinq Enerqv Companies. Vendor acknowledges that in accordance with Chapter 2274 of the Texas Government Code (as added by Acts 2021, 87th Leg., R.S., S.B. 13, § 2), the City is prohibited from entering into a contract for goods or services that has a value of $100,000 or more, which will be paid wholly or partly from public funds of the City, with a company (with 10 or more full-time employees) unless the contract contains a written verification from the company that it: (1) does not boycott energy companies; and (2) will not boycott energy companies during the term of the contract. The terms "boycott energy company" and "company" have the meaning ascribed to those terms by Chapter 2274 of the Texas Government Code (as added by Acts 2021, 87th Leg., R.S., S.B. 13, § 2). To the extent that Chapter 2274 of the Government Code is applicable to this Agreement, by signing this Agreement, Vendor certifies that Vendor's signature provides written verification to the City that Vendor: (1) does not boycott energy companies; and (2) will not boycott energy companies during the term of this Agreement. Prohibition on Discrimination Against Firearm and Ammunition Industries. Vendor acknowledges that except as otherwise provided by Chapter 2274 of the Texas Government Code (as added by Acts 2021, 87th Leg., R.S., S.B. 19, § 1), the City is prohibited from entering into a contract for goods or services that has a value of $100,000 or more which will be paid wholly or partly from public funds of the City, with a company (with 10 or more full-time employees) unless the contract contains a written verification from the company that it: (1) does not have a practice, policy, guidance, or directive that discriminates against a firearm entity or firearm trade association; and (2) will not discriminate during the term of the contract against a firearm entity or firearm trade association. The terms "discriminate," "firearm entity" and "firearm trade association" have the meaning ascribed to those terms by Chapter 2274 of the Texas Government Code (as added by Acts 2021, 87th Leg., R.S., S.B. 19, § 1). To the extent that Chapter 2274 of the Government Code is applicable to this Agreement, by signing this Agreement, Vendor certifies that Vendor's signature provides written verification to the City that Vendor: (1) does not have a practice, policy, guidance, or directive that discriminates against a firearm entity or firearm trade association; and (2) will not discriminate against a firearm entity or firearm trade association during the term of this Agreement. Instruction to Offerors Page 24 of 33 Crime Lab Full Building Generator Replacement - Proj. #102986 Sept. 2023) This Agreement is made effective as of the date signed by the Assistant City Manager below. FORT WORTH: City of Fort Worth Contract Compliance Manager: By signing I acknowledge that I am the person responsible for the monitoring and Oana GIOlcf administration of this contract, including By: Dana Burghdoff(Mar2,202412:44CDT) ensuring all performance and reporting Name: Dana Burghdoff, AICP requirements. Title: Assistant City Manager Date: Mar 26, 2024 By: Approval Recommended: Name: Nikita N. Watts Title: Sr. Capital Projects Officer 7- Approved as to Form and Legality: By: Name: Marilyn Marvin Title: Interim Director, Wo Property Management Dept. By: D Black (Mar 26,202411:41 CDT) Name: Doug Black Attest: 4� nib ° F F9Tu'9�d Title: Assistant City Attorney p�� oo P o-1d �a Contract Authorization: BpnnEXP?op MSC: 24-0053 By: Name: Jannette Goodall Title: City Secretary CONTRACTOR: Angeli Schmidt(Mar 12,202407:48 PDT) By: Name: Title Date: Mat' 12, 2024 OFFICIAL RECORD CITY SECRETARY FT. WORTH, TX Instruction to Offerors Page 25 of 33 Crime Lab Full Building Generator Replacement - Proj. #102986 Sept. 2023) Bond # 609206760 PAYMENT BOND "REVISED ORIGINAL' THE STATE OF TEXAS § § KNOW ALL BY THESE PRESENTS: COUNTY OF TARRANT § That we, SDB, Inc. dba S D B Contracting Services known as "Principal" herein, and •.�• U -� - ' r.� •n... a corporate surety (sureties), duly authorized to do business in the State of Texas, known as "Surety" herein (whether one or more), are held and firmly bound unto the City of Fort Worth, a municipal corporation created pursuant to the laws of the State of Texas, known as "City" herein, in the penal sum of, ONE HUNDRED FIFTY THOUSAND DOLLARS AND ZERO CENTS ($150.000.001 lawful money of the United States, to be paid in Fort Worth, Tarrant County, Texas, for the payment of which sum well and truly be made, we bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents: WHEREAS, Principal has entered into a certain written Contract with City, awarded the 12th day of February . 2024, which Contract is hereby referred to and made a part hereof for all purposes as if fully set forth herein, to furnish all materials, equipment, labor and other accessories as defined by law, in the prosecution of the Work as provided for in said Contract and designated as Crime Lab Full Building Generator Replacement, 3616 E. Lancaster Ave., Fort Worth, Texas 76103 (PMD2023-10). NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION is such that if Principal shall pay all monies owing to any (and all) payment bond beneficiary (as defined in Chapter 2253 of the Texas Goverment Code, as amended) in the prosecution of the Work under the Contract, then this obligation shall be and become null and void; otherwise to remain in full force and effect. This bond is made and executed in compliance with the provisions of Chapter 2253 of the Texas Government Code, as amended, and all liabilities on this bond shall be determined in accordance with the provisions of said statute. IN WITNESS WHEREOF, the Principal and Surety have each SIGNED and SEALED this instrument by duly authorized agents and officers on this the 12th day of February , 2024. PRINCIPAL: SDB, Inc. dba S D B Contracting Services ATTEST: BY: Signature ° Cool*•,_ (Principal) Secretary � ` Name and Title Address: 1001 S. Edward Drive — Tempe, AZ 85281-5223 Witness as to Prin ip I Lie Y��. �,� C ,r+-l�,�e1/i��. SURETY: P� 1NSU& Liberty Mutual Insurance Company �o �oR110 �? FO 1912 0 co 0 d' 9SSACHUS��da ATTEST: BY: c �eal No. 5631 Signature Stephanie L. Bucholz. Attornev-in-Fact (Surety) Secretary Name and Title Address: 175 Berkeley Street Boston. MA 02116 iftness as to Surety Debra K. Williams Telephone Number: (856) 628-6844 - James Sousa *Note: If signed by an officer of the Surety, there must be on file a certified extract from the bylaws showing that this person has authority to sign such obligation. If Surety's physical address is different from its mailing address, both must be provided. The date of the bond shall not be prior to the date the Contract is awarded. Bond # 609206760 PERFORMANCE BOND **REVISED ORIGINAL** THE STATE OF TEXAS § § KNOW ALL BY THESE PRESENTS: COUNTY OF TARRANT § That we, SDB, Inc. dba S D B Contracting Services , known as "Principal" herein and Libertv Mutual Insurance Comaanv , a corporate surety (sureties, if more than one) duly authorized to do business in the State of Texas, known as "Surety" herein (whether one or more), are held and firmly bound unto the City of Fort Worth, a municipal corporation created pursuant to the laws of Texas, known as "City" herein, in the penal sum of, ONE HUNDRED FIFTY THOUSAND DOLLARS AND ZERO CENTS (SI50.000.00t lawful money of the United States, to be paid in Fort Worth, Tarrant County, Texas for the payment of which sum well and truly to be made, we bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, the Principal has entered into a certain written contract with the City awarded the 12th day of February 2024, which Contract is hereby referred to and made a part hereof for all purposes as if fully set forth herein, to furnish all materials, equipment labor and other accessories defined by law, in the prosecution of the Work, including any Change Orders, as provided for in said Contract designated as Crime Lab Full Building Generator Replacement, 3616 E. Lancaster Ave., Fort Worth. Texas 76103 (PMD2023-10). NOW, THEREFORE, the condition of this obligation is such that if the said Principal shall faithfully perform it obligations under the Contract and shall in all respects duly and faithfully perform the Work, including Change Orders, under the Contract, according to the plans, specifications, and contract documents therein referred to, and as well during any period of extension of the Contract that may be granted on the part of the City, then this obligation shall be and become null and void, otherwise to remain in full force and effect. PROVIDED FURTHER, that if any legal action be filed on this Bond, venue shall lie in Tarrant County, Texas or the United States District Court for the Northern District of Texas, Fort Worth Division. This bond is made and executed in compliance with the provisions of Chapter 2253 of the Texas Goverment Code, as amended, and all liabilities on this bond shall be determined in accordance with the provisions of said statue. instruction to Offerors Page 28 of 32 Crime Lab Full Building Generator Replacement - Prol. #102988 Sept. 2023) IN WITNESS WHEREOF, the Principal and the Surety have SIGNED and SEALED this instrument by duly authorized agents and officers on this the 12th day of February , 2024. ATTEST: (Principal) tecretary COaa ,k V Witness as to Icipal � z21, //,/ 111,A, Witness as to Surety Debra K. Williams PRINCIPAL: SDB, Inc. dba S D B Contracting Services Signature w - 2; C-c-, -0 1(- FZ) Name and Title Address: 1001 S. Edward Drive Tempe, AL 85281-5223 SURETY: tNS p_ Liberty Mutual Insurance Company �JPoo4po�yo 1912 0 d� SsgCHUs��.aa Signature t6al No. 5831 Stephanie L. Bucholz, Attorney -in -Fact Name and Title Address: 175 Berkeley Street Boston, MA 02116 Telephone Number: (856) 628-6844 - James Sousa *Note: If signed by an officer of the Surety Company, there must be on file a certified extract from the by-laws showing that this person has authority to sign such obligation. If Surety's physical address is different from its mailing address, both must be provided. The date of the bond shall not be prior to the date the Contract is awarded Instruction to Offerors Page 29 of 32 Crime Lab Full Building Generator Replacement - Proj. #102986 Sept. 2023) This Power of Attorney limits the acts of those named herein, and they have no authority to bind the Company except in the manner and to the extent herein stated. Libert_yLiberty Mutual Insurance Company Mutual. The Ohio Casualty Insurance Company Certificate No: 8200472-975281 SURETY West American Insurance Company POWER OF ATTORNEY KNOWN ALL PERSONS BY THESE PRESENTS: That The Ohio Casualty Insurance Company is a corporation duly organized under the laws of the State of New Hampshire, that Liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts, and West American Insurance Company is a corporation duly organized under tfte laws of the State of Indiana (herein collectively called the 'Companies"), pursuant to and by authority herein set forth, does hereby name, constitute and appoint, Stephanie L. Bucholz, Andrew A. Farr, Barn R. Farr, Gregory P, Griffith, Debra K. Williams all of the city of Mesa state of Arizona each individually if there be more than one named, its true and lawful attomey4n-fact to make, execute, seal, acknowledge and deliver, for and on its behalf as surety and as its act and deed, any and all undertakings, bonds, recognlzances and other surety obligations, in pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies in their own proper persons. IN WITNESS WHEREOF, this Power of Attomey has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 7th day of February 2019 Liberty Mutual Insurance Company PV INSl1POSY INS& a %Nsu,pThe Ohio Casualty Insurance Company aJ aoaPORIrFy0 5J aoaPORQr�y `4QC; q Rlr�yC� West American Insurance Company a J 3 0 v o tr o to 19120 Lu ° 1919 „ 2 1991 /� n �°' 4 a) d� ss,��s% aD D NAW& a �' rNMAO By: $77 1� 3yd + t s3�Lf ��a (n Davin M Carey Assistant Secretary cu State of PENNSYLVANIA > � County of MONTGOMERY ss M L cm 0 a)On this 7th day of Febnrary 2019 before me personally appeared David M. Carey, who acknowledged himself to be the Assistant Secretary of Liberty Mutual Insurance o o t Company, The Ohio Casualty Company, and West American Insurance Company, and that he, as such, being authorized so to do, execute the foregoing instrument for the purposes > therein contained by signing on behalf of the corporations by himself as a duly authorized officer. v w m >` E IN WITNESS WHEREOF, I have hereunto subscribed my name and affixed my notarial seal at King of Prussia, Pennsylvania, on the day and year first above written. cCD a M O m oNy ;_ FOMMONWEALTH OF PENNSYLVANIA Q N o �¢-4cc)�d F�r� { Notarial5e1. /r\ O C r v �, Or Teresa Pas[ella, Notary Public _ p � Upper MerionTwp., Montgomery County By: l� [a C fC '� ;QCommission Expires j My Cission March 28.202t - - \vryyy��p�Teresa Pastella, Notary Public o .1- Member, PennsyNania Association of Nolarles a tad Q q� f N O C o This Power of Attorney is made and executed pursuant to and by autt&ty of the following By-laws and Authorizations of The Ohio Casualty Insurance Company, Liberty Mutual w °' o Insurance Company, and West American Insurance Company which resolutions are now in full force and effect reading as follows: o aa) ARTICLE IV— OFFICERS: Section 12. Power of Attorney.4'2 o ca Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President, and subject to such limitation as the Chairman or the 9 ;g > President may prescribe, shall appoint such attomeys-in-fact, as may be necessary to act in behalf of the Corporation to make, execute, seal, acknowledge and deliver as surety > o m o any and all undeltekings, bonds, recognizances and other surety obligations. Such attomeys-in-fact, subject to the limitations set forth in their respective powers of attorney, shall t N > have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation. When so executed, such "O° Z � instruments shall be as binding as if signed by the President and attested to by the Secretary. Any power or authority granted to any representative or attorney -in -fact under the M provisions of this article may be revoked at any time by the Board, the Chairman, the President or by the officer or officers granting such power orauthonty. o CO ARTICLE Xlll — Execution of Contracts: Section 5. Surety Bonds and Undertakings. L) Any officer of the Company authorized for that purpose in writing by the chairman or the president, and subject to such limitations as the chairman or the president may prescribe, H shall appoint such attomeys-in-fact, as may be necessary to act in behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attomeys-in-fact subject to the limitations set forth in their respective powers of attorney, shall have full power to bind the Company by their signature and execution of any such instrumenlc and to attach thereto the seal of the Company. When so executed such instruments shall be as binding as if signed by the president and attested by the secretary. Certificate of Designation —The President of the Company, acting pursuant to the Bylaws of the Company, authorizes David M. Carey, Assistant Secretary to appoint such attomeys-in- fact as may be necessary to act on behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Authorization — By unanimous consent of the Company's Board of Directors, the Company consents that facsimile or mechanically reproduced signature of any assistant secretary of the Company, wherever appearing upon a certified copy of any power of attorney issued by the Company In connection with surety bonds, shall be valid and binding upon the Company with the same force and effect as though manually affixed. I, Renee C. Llewellyn, the undersigned, Assistant Secretary, The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company do hereby certify that the original power of attorney of which the foregoing is a full, true and correct copy of the Power of Attorney executed by said Companies, is in full force and effect and has not been revoked. IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed the seals of said Companies this 12th day of Ft:brumy _2024 P\ 1NSU,�9 P\,,( INS& a 14suy J oaeo�r y J oaeorzq Pq VP oaaor� y � a [� 5 c r y . c r� 3 Fo to 11 r Fo m 3 ra 19 0 °_ Z 1919 o Q 1991 o 5�7_ad4t_ d" ssAe.1`'�da3 S° �NArnP'�� a� rs, �NorANP �a3 BY: �7) �RenAssisaSecrets ry LMS-12873 LMIC OCIC WAIC Muhl Co 062018 Policy No: MWZY30718123 COMMERCIAL GENERAL LIABILITY CG 2010 07 04 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS -SCHEDULED PERSON OR ORGANIZATION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name Of Additional Insured Person(s) Location(s) Of Covered Operations Or Organ ization(s): All persons or organizations as required by written contract or agreement The locations as specified in the written contracts or agreements Information required to complete this Schedule, if not shown above, will be shown in the Declarations. A. Section II — Who Is An Insured is amended to include as an additional insured the person(s) or organization(s) shown in the Schedule, but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by: 1. Your acts or omissions; or 2. The acts or omissions of those acting on your behalf; in the performance of your ongoing operations for the additional insured(s) at the location(s) desig- nated above. B. With respect to the insurance afforded to these additional insureds, the following additional exclu- sions apply: This insurance does not apply to "bodily injury" or "property damage" occurring after: 1. All work, including materials, parts or equip- ment furnished in connection with such work, on the project (other than service, maintenance or repairs) to be performed by or on behalf of the additional insured(s) at the location of the covered operations has been completed; or 2. That portion of "your work" out of which the injury or damage arises has been put to its in- tended use by any person or organization other than another contractor or subcontractor en- gaged in performing operations for a principal as a part of the same project. CG 2010 07 04 0 ISO Properties, Inc., 2004 Page 1 of 1 Po)icyNo: MWZY30718123 COMMERCIAL GENERAL LIABILITY CG 20 37 07 04 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - COMPLETED OPERATIONS This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART Name Of Additional Insured Person(s) Or Organization(s): All persons or organizations as required by written contract or agreement SCHEDULE Location And Description Of Completed Operations The locations as specified in the written contracts or agreements Information required to complete this Schedule, if not shown above, will be shown in the Declarations. Section II — Who Is An Insured is amended to include as an additional insured the person(s) or organization(s) shown in the Schedule, but only with respect to liability for "bodily injury" or 'property damage" caused, in whole or in part, by "your work" at the location designated and described in the schedule of this endorsement performed for that additional insured and included in the "products - completed operations hazard" CG 20 37 07 04 0 ISO Properties, Inc., 2004 Page 1 of 1 Policy No: MWTB30718223 IL 10 (12/06) OLD REPUBLIC INSURANCE COMPANY THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED AND PRIMARY AND NON-CONTRIBUTORY ENDORSEMENT This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE FORM MOTOR CARRIER COVERAGE FORM SCHEDULE Designated Person(s) or Organization(s): All persons or organizations where required by written contract A. SECTION II — COVERED AUTOS LIABILITY COVERAGE, paragraph 1. Who Is An Insured is amended to include the person(s) or organization(s) shown in the above Schedule as an additional "insured", but only with respect to "accidents" arising out of your work while being performed for such person(s) or organization(s). B. The following is added to the Other Insurance Condition in the Business Auto Coverage Form and the Other Insurance — Primary And Excess Insurance Provisions in the Motor Carrier Coverage Form and supersedes any provision to the contrary: This policy's Covered Autos Liability Coverage is primary to and will not seek contribution from any other insurance available to the "insured" person(s) or organization(s) shown in the above Schedule provided that: 1. Such "insured" is a Named Insured under such other insurance; and 2. You have agreed in writing in a contract or agreement that this insurance would be primary and would not seek contribution from any other insurance available to such "insured". PCA 048 09 19 Includes copyrighted material of Insurance Services Office, Inc., with its permission. Page 1 of 1 Policy No: MWZY30718123 COMMERCIAL GENERAL LIABILITY CG 20 01 12 19 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. PRIMARY AND NONCONTRIBUTORY - OTHER INSURANCE CONDITION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART LIQUOR LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART The following is added to the Other Insurance Condition and supersedes any provision to the contrary: Primary And Noncontributory Insurance This insurance is primary to and will not seek contribution from any other insurance available to an additional insured under your policy provided that: (1) The additional insured is a Named Insured under such other insurance; and (2) You have agreed in writing in a contract or agreement that this insurance would be primary and would not seek contribution from any other insurance available to the additional insured. CG 20 01 12 19 © Insurance Services Office, Inc., 2018 Page 1 of 1 Policy No: MWZY30718123 COMMERCIAL GENERAL LIABILITY CG24531219 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US (WAIVER OF SUBROGATION) - AUTOMATIC This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART ELECTRONIC DATA LIABILITY COVERAGE PART LIQUOR LIABILITY COVERAGE PART POLLUTION LIABILITY COVERAGE PART DESIGNATED SITES POLLUTION LIABILITY LIMITED COVERAGE PART DESIGNATED SITES PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART RAILROAD PROTECTIVE LIABILITY COVERAGE PART UNDERGROUND STORAGE TANK POLICY DESIGNATED TANKS The following is added to Paragraph 8. Transfer Of Rights Of Recovery Against Others To Us of Section IV — Conditions: We waive any right of recovery against any person or organization, because of any payment we make under this Coverage Part, to whom the insured has waived its right of recovery in a written contract or agreement. Such waiver by us applies only to the extent that the insured has waived its right of recovery against such person or organization prior to loss. CG 24 53 12 19 © Insurance Services Office, Inc., 2018 Page 1 of 1 Policy No: MWTB30718223 COMMERCIAL AUTO CA 04 43 11 20 IN: 1634011ITQ**14M14► III Its]:/_1kiM*11110:1=1aQICWA»=F_F9=1:7=F_1III 1110a_1041111114A'11111 WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US (WAIVER OF SUBROGATION) - AUTOMATIC WHEN REQUIRED BY WRITTEN CONTRACT OR AGREEMENT This endorsement modifies insurance provided under the following: AUTO DEALERS COVERAGE FORM BUSINESS AUTO COVERAGE FORM MOTOR CARRIER COVERAGE FORM With respect to coverage provided by this endorsement, the provisions of the Coverage Form apply unless modified by the endorsement. The Transfer Of Rights Of Recovery Against Others To Us Condition does not apply to any person(s) or organization(s) for whom you are required to waive subrogation with respect to the coverage provided under this Coverage Form, but only to the extent that subrogation is waived: A. Under a written contact or agreement with such person(s) or organization (s); and B. Prior to the "accident" or the "loss." CA 04 43 11 20 © Insurance Services Office, Inc., 2019 Page 1 of 1 WORKERS COMPENSATION AND EMPLOYERS LIABILITY INSURANCE POLICY WC 00 0313 POLICY NUMBER: MWC 30718023 WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule. (This agreement applies only to the extent that you perform work under a written contract that requires you to obtain this agreement from us.) This agreement shall not operate directly or indirectly to benefit anyone not named in the Schedule. Schedule WHERE REQUIRED BY WRITTEN CONTRACT OR AGREEMENT DATE OF ISSUE: �0 1983 National Council on Compensation Insurance. INSURED COPY POLICY NUMBER: MWZY30718123 COMMERCIAL GENERAL LIABILITY CG 25 03 05 09 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. DESIGNATED CONSTRUCTION PROJECT(S) GENERAL AGGREGATE LIMIT This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Designated Construction Project(s): The projects as specified in the written contracts or agreements Information required to complete this Schedule, if not shown above, will be shown in the Declarations. A. For all sums which the insured becomes legally obligated to pay as damages caused by "occur- rences" under Section I — Coverage A, and for all medical expenses caused by accidents under Section I — Coverage C, which can be attributed only to ongoing operations at a single designated construction project shown in the Schedule above: 1. A separate Designated Construction Project General Aggregate Limit applies to each des- ignated construction project, and that limit is equal to the amount of the General Aggregate Limit shown in the Declarations. 2. The Designated Construction Project General Aggregate Limit is the most we will pay for the sum of all damages under Coverage A, ex- cept damages because of "bodily injury" or "property damage" included in the "products - completed operations hazard", and for medi- cal expenses under Coverage C regardless of the number of: a. Insureds; b. Claims made or "suits" brought; or c. Persons or organizations making claims or bringing "suits" 3. Any payments made under Coverage A for damages or under Coverage C for medical expenses shall reduce the Designated Con- struction Project General Aggregate Limit for that designated construction project. Such payments shall not reduce the General Ag- gregate Limit shown in the Declarations nor shall they reduce any other Designated Con- struction Project General Aggregate Limit for any other designated construction project shown in the Schedule above. 4. The limits shown in the Declarations for Each Occurrence, Damage To Premises Rented To You and Medical Expense continue to apply. However, instead of being subject to the General Aggregate Limit shown in the Decla- rations, such limits will be subject to the appli- cable Designated Construction Project Gen- eral Aggregate Limit. CG 25 03 05 09 0 Insurance Services Office, Inc., 2008 Page 1 of 2 B. For all sums which the insured becomes legally C. obligated to pay as damages caused by 'occur- rences" under Section I — Coverage A, and for all medical expenses caused by accidents under Section I — Coverage C, which cannot be attrib- uted only to ongoing operations at a single des- ignated construction project shown in the Sched- ule above: 1. Any payments made under Coverage A for damages or under Coverage C for medical D. expenses shall reduce the amount available under the General Aggregate Limit or the Products -completed Operations Aggregate Limit, whichever is applicable; and 2. Such payments shall not reduce any Desig- nated Construction Project General Aggre- gate Limit. E. When coverage for liability arising out of the "products-oompleted operations hazard" is pro- vided, any payments for damages because of "bodily injury" or "property damage" included in the "products -completed operations hazard" will reduce the Products -completed Operations Ag- gregate Limit, and not reduce the General Ag- gregate Limit nor the Designated Construction Project General Aggregate Limit. If the applicable designated construction project has been abandoned, delayed, or abandoned and then restarted, or if the authorized contract- ing parties deviate from plans, blueprints, de- signs, specifications or timetables, the project will still be deemed to be the same construction pro- ject. The provisions of Section III -- Limits Of Insur- ance not otherwise modified by this endorsement shall continue to apply as stipulated. Page 2 of 2 0 Insurance Services Office, Inc., 2008 CG 25 03 05 09 CNA D. Coverage D - Key Employee Exclusions CNA Paramount Excess and Umbrella Liability With respect to Coverage D — Key Employee, this insurance does not apply to any actual or alleged: 1. Death or Disability death or permanent disability of a key employee relating to, or arising out of: a. nuclear reaction or radiation or radioactive contamination, however caused; b. sickness or disease, including mental illness or mental injury; c. pregnancy, childbirth, miscarriage or abortion; d. suicide, attempted suicide or self inflicted bodily injury, while sane or insane; e. the key employee's intoxication, impairment or otherwise being under the influence of alcohol or controlled substances; f. war, including undeclared or civil war; g. warlike action by a military force, including action in hindering or defending against an actual or expected attack, by any government, sovereign or other authority using military personnel or other agents; or h. insurrection, rebellion, revolution, usurped power, or action taken by governmental authority in hindering or defending against any of these. 2. Other Expenses a. expenses the Named Insured incurs which the Named Insured would not have incurred if the Named Insured had used all reasonable means to: L find a permanent replacement for the key employee; and ii. reduce or discontinue the key employee replacement expense; as soon as possible after the Named Insured's permanent loss of the services of the key employee caused by a covered accident. b. additional expenses incurred due to the Named Insured's loss of the services of a permanent replacement appointed or hired to replace a key employee, however caused. However, this exclusion does not apply if the replacement employee is included in the definition as a key employee and the Named Insured's loss of the services of the replacement employee is caused by a covered accident. IV. WHO IS AN INSURED The following persons or organizations are Insureds. A. With respect to Coverage A - Excess Follow Form Liability, the Named Insured and any persons or organizations included as an insured under the provisions of underlying insurance are Insureds, and then only for the same coverage, except for limits of insurance, afforded under such underlying insurance. B. With respect to the Coverage B - Umbrella Liability: 1. If the Named Insured is designated in the Declarations of this Policy as: a. an individual, the Named Insured and the Named Insured's spouse are Insureds, but only with respect to the conduct of a business of which the Named Insured is the sole owner. b. a partnership or joint venture, the Named Insured is an Insured. The Named Insured's members, the Named Insured's partners, and their spouses are also Insureds, but only with respect to the conduct of the Named Insured's business. Form No: CNA75504XX (03-2015) Policy No: CUE 7018652404 Policy Page: Policy Effective Date: 04/01 /2023 Underwriting Company: The Continental Insurance Company, 151 N Franklin St, Chicago, IL 60606 Policy Page: ° Copyright CNA All Rights Reserved. CNA Paramount Excess and Umbrella Liability Policy c. a limited liability company, the Named Insured is an Insured. The Named Insured's members are also Insureds, but only with respect to the conduct of the Named Insured's business. The Named Insured's managers are Insureds, but only with respect to their duties as the Named Insured's managers. d. an organization other than a partnership, joint venture or limited liability company, the Named Insured is an Insured. The Named Insured's executive officers and directors are Insureds, but only with respect to their duties as the Named Insured's officers or directors. The Named Insured's stockholders are also Insureds, but only with respect to their liability as stockholders. a trust, the Named Insured is an Insured. The Named Insured's trustees are also Insureds, but only with respect to their duties as trustees. 2. Each of the following are also Insureds: a. The Named Insured's volunteer workers but only while performing duties related to the conduct of the Named Insured's business. b. The Named Insured's employees, other than either the Named Insured's executive officers (if the Named Insured is an organization other than a partnership, joint venture or limited liability company) or the Named Insured's managers (if the Named Insured is a limited liability company), but only for acts within the scope of their employment by the Named Insured or while performing duties related to the conduct of the Named Insured's business. However, none of these employees or volunteer workers are Insureds for: i. bodily injury or personal and advertising injury: (a) to the Named Insured, to the Named Insured's partners or members (if the Named Insured is a partnership or joint venture), to the Named Insured's members (if the Named Insured is a limited liability company), to a co -employee while in the course of his or her employment or performing duties related to the conduct of the Named Insured's business, or to the Named Insured's other volunteer workers while performing duties related to the conduct of the Named Insured's business; (b) to the spouse, child, parent, brother or sister of that co -employee or volunteer worker as a consequence of paragraph (i)(a) above; (c) for which there is any obligation to share damages with or repay someone else who must pay damages because of the injury described in paragraph i. (a) or (b) above; or (d) arising out of his or her providing or failing to provide professional health care services. ii. property damage to property: (a) owned, occupied or used by; (b) rented to, in the care, custody or control of, or over which physical control is being exercised for any purpose by; the Named Insured, any of the Named Insured's employees, volunteer workers, any partner or member (if the Named Insured is a partnership or joint venture), or any member (if the Named Insured is a limited liability company). C. With respect to the Coverage C - Crisis Event Management and the Coverage D - Key Employee, the Named Insured is the Insured. V. LIMITS OF INSURANCE A. Multiple Insureds, claims, claimants The limits of insurance shown in the Declarations of this Policy and the rules below fix the most the Form No: CNA75504XX (03-2015) Policy No: CUE 7018652404 Policy Page: Policy Effective Date: 04/01 /2023 Underwriting Company: The Continental Insurance Company, 151 N Franklin St, Chicago, IL 60606 Policy Page: ° Copyright CNA All Rights Reserved. CNACNA Paramount Excess and Umbrella Liability or organization which may be liable to the Insured because of injury or damage to which this insurance may also apply; and vi. will not voluntarily make a payment, except at its own cost, assume any obligation, or incur any expense, other than for first aid, without the Insurer's prior consent. 3. Cooperation With respect to both Coverage A - Excess Follow Form Liability and Coverage B - Umbrella Liability, the Named Insured will cooperate with the Insurer in addressing all claims required to be reported to the Insurer in accordance with this paragraph O. Notice of Claims/Crisis Management Event/Covered Accident, and refuse, except solely at its own cost, to voluntarily, without the Insurer's approval, make any payment, admit liability, assume any obligation or incur any expense related thereto. P. Notices Any notices required to be given by an Insured shall be submitted in writing to the Insurer at the address set forth in the Declarations of this Policy. Q. Other Insurance If the Insured is entitled to be indemnified or otherwise insured in whole or in part for any damages or defense costs by any valid and collectible other insurance for which the Insured otherwise would have been indemnified or otherwise insured in whole or in part by this Policy, the limits of insurance specified in the Declarations of this Policy shall apply in excess of, and shall not contribute to a claim, incident or such event covered by such other insurance. With respect to Coverage A - Excess Follow Form Liability only, if: —> a. the Named Insured has agreed in writing in a contract or agreement with a person or entity that this insurance would be primary and would not seek contribution from any other insurance available; b. Underlying Insurance includes that person or entity as an additional insured; and c. Underlying Insurance provides coverage on a primary and noncontributory basis as respects that person or entity; then this insurance is primary to and will not seek contribution from any insurance policy where that person or entity is a named insured. R. Premium All premium charges under this Policy will be computed according to the Insurer's rules and rating plans that apply at the inception of the current policy period. Premium charges may be paid to the Insurer or its authorized representative. S. In Rem Actions A quasi in rem action against any vessel owned or operated by or for a Named Insured, or chartered by or for a Named Insured, will be treated in the same manner as though the action were in personam against the Named Insured. T. Separation of Insureds Except with respect to the limits of insurance, and any rights or duties specifically assigned in this Policy to the First Named Insured, this insurance applies: 1. as if each Named Insured were the only Named Insured; and 2. separately to each Insured against whom a claim is made. U. Transfervof Interest Form No: CNA75504XX (03-2015) Policy No: CUE 7018652404 Policy Page: Policy Effective Date: 04/01 /2023 Underwriting Company: The Continental Insurance Company, 151 N Franklin St, Chicago, IL 60606 Policy Page: ° Copyright CNA All Rights Reserved. CNA CNA Paramount Excess and Umbrella Liability Assignment of interest under this policy shall not bind the Insurer unless its consent is endorsed hereon. V. Unintentional Omission Based on Insurer's reliance on the Named Insured's representations as to existing hazards, if the Named Insured should unintentionally fail to disclose all such hazards at the effective date of this Policy, the Insurer will not deny coverage under this Policy because of such failure. > W. Waiver of Rights of Recovery The Insurer waives any right of recovery it may have against any person or organization because of payments the Insurer makes under this Policy if the Named Insured has agreed in writing to waive such rights of recovery in a contract or agreement, and only if the contract or agreement: 1. is in effect or becomes effective during the policy period; and 2. was executed prior to loss. VII. DEFINITIONS For purposes of this Policy, words in bold face type, whether expressed in the singular or the plural, have the meaning set forth below. Advertisement means a notice that is broadcast or published to the general public or specific market segments about the Named Insured's goods, products or services for the purpose of attracting customers or supporters. For the purposes of this definition: A. notices that are published include material placed on the Internet or on similar electronic means of communication; and B. regarding web -sites, only that part of a web -site that is about the Named Insured's goods, products or services for the purposes of attracting customers or supporters is considered an advertisement. Aircraft means any machine or device that is capable of atmospheric flight. Arbitration proceeding means a formal alternative dispute resolution proceeding or administrative hearing to which an Insured is required to submit by statute or court rule or to which an Insured has submitted with the Insurer's consent. Asbestos means the mineral in any form whether or not the asbestos was at any time airborne as a fiber, particle or dust, contained in or formed a part of a product, structure or other real or personal property, carried on clothing, inhaled or ingested, or transmitted by any other means. Authorized Insured means any executive officer, member of the Named Insured's risk management or in-house general counsel's office, or any employee authorized by the Named Insured to give or receive notice of a claim. Auto means: A. a land motor vehicle, trailer or semitrailer designed for travel on public roads, including any attached machinery or equipment; or B. any other land vehicle that is subject to a compulsory or financial responsibility law or other motor vehicle insurance law where it is licensed or principally garaged. However, auto does not include mobile equipment. Bodily injury means bodily injury, sickness or disease sustained by a person, including death, humiliation, shock, mental anguish or mental injury sustained by that person at any time which results as a consequence of the bodily injury, sickness or disease. Claim means a: A. suit; or Form No: CNA75504XX (03-2015) Policy No: CUE 7018652404 Policy Page: Policy Effective Date: 04/01 /2023 Underwriting Company: The Continental Insurance Company, 151 N Franklin St, Chicago, IL 60606 Policy Page: ° Copyright CNA All Rights Reserved. POLICY NUMBER: QT6604H598083TIA23 COMMERCIAL INLAND MARINE C. LIMITS OF INSURANCE The most we will pay for loss or damage in any one occurrence is the applicable Limit of Insur- ance shown in the Declarations, Schedule(s), Coverage Form(s) or Endorsement(s). But in the event coverage for loss or damage is provided under the Coverage Extensions or Additional Coverages, the Limits of Insurance for such Cov- erage Extension or Additional Coverage will apply as additional amounts of insurance, unless oth- erwise stated within the Coverage Extension or Additional Coverage. D. DEDUCTIBLE We will not pay for loss or damage in any one oc- currence until the amount of the adjusted loss or damage exceeds the applicable Deductible shown in the Declarations, Schedule(s), Cover- age Form(s) or Endorsement(s). We will then pay the amount of the adjusted loss or damage in ex- cess of the Deductible, up to the applicable Limit of Insurance. The applicable Deductible shown in the Declara- tions applies to the Coverage Extensions and Ad- ditional Coverages unless otherwise stated in the Coverage Extension or Additional Coverage. Unless otherwise stated, if more than one De- ductible amount applies to loss or damage in any one occurrence, the total of the deductible amounts applied in that occurrence will not ex- ceed the amount of the largest applicable De- ductible. E. ADDITIONAL CONDITIONS The following conditions apply in addition to the COMMERCIAL INLAND MARINE CONDITIONS and the COMMON POLICY CONDITIONS. > 1. Additional Named Insured The following persons or organizations are included as Additional Named Insureds when you have agreed in a written contract or writ- ten agreement, executed prior to loss, to name such persons or organizations as an Additional Named Insured, but only to the ex- tent of their financial interest in the Covered Property: 2. Coinsurance If a Coinsurance Percentage is shown in the Declarations for the applicable project, the fol- lowing condition applies: a. We will not pay the full amount of any loss if the applicable "total project value" at the time of loss multiplied by the stated Coinsurance Percentage is greater than the applicable Covered Property Limit of Insurance. Instead, we will determine the most we will pay using the following steps: Step (1) Multiply the "total project value" at the time of loss by the Coinsur- ance Percentage. Step (2) Divide the Covered Property Limit of Insurance by the figure deter- mined in Step (1). Step (3) Multiply the total amount of the covered loss, before the application of any deductible, by the figure determined in Step (2). Step (4) Subtract the deductible from the figure determined in Step (3). We will pay the amount determined in Step (4) or the Limit of Insurance, which- ever is less. For the remainder, you will either have to rely on other insurance or absorb the loss yourself. b. Coinsurance does not apply to: (1) Additional Coverages; or (2) Coverage Extensions. 3. Duties in the Event of Loss The following duties are added to the Duties In The Event of Loss LOSS CONDITION in the COMMERCIAL INLAND MARINE CON- DITIONS: You must see that the following are done in the event of loss: a. You must make every effort to meet the applicable "planned completion date". This includes: a. Owners of Covered Property; (1) Resuming, as soon as possible, all or b. Mortgagees or loss payee s; any part of the construction or repair; or c. Contractors, sub contractors and sub -sub (2) Using temporary or substitute: contractors; and d. Lessors or lessees. (a) Facilities, services, suppliers or customers; or Page 12 of 19 © 2013 The Travelers Indemnity Company. All rights reserved. CM T2 21 04 13 Includes copyrighted material of Insurance Services Office, Inc. with its permission. POLICY NUMBER: QT6604H598083TIA23 COMMERCIAL INLAND MARINE their financial interest in the Covered Prop- erty. 4. We may elect to defend you against suits arising from claims of owners of property. We will do this at our expense. 5. We will pay for covered loss or damage within 30 days after we receive the sworn proof of loss if you have complied with all the terms of this Coverage Part and: a. We have reached agreement with you on the amount of the loss; or b. An appraisal award has been made. 6. We will not be liable for any part of a loss that has been paid or made good by others. J F. Other Insurance H. Recovered Property If either you or we recover any property after loss settlement, that party must give the other prompt notice. At your option, the property will be re- turned to you. You must then return to us the amount we paid to you for the property. We will pay recovery expenses and the expenses to re- pair the recovered property, subject to the Limit of Insurance. I. Reinstatement Of Limit After Loss 1. You may have other insurance subject to the same plan, terms, conditions and provisions as the insurance under this Coverage Part. If you do, we will pay our share of the covered loss or damage. Our share is the proportion that the applicable Limit of Insurance under this Coverage Part bears to the Limits of In- surance of all insurance covering on the same basis. 2. If there is other insurance covering the same loss or damage, other than that described in 1. above, we will pay only for the amount of covered loss or damage in excess of the amount due from that other insurance, whether you can collect on it or not. But we will not pay more than the applicable Limit of Insurance. G. Pair, Sets Or Parts 1. Pair Or Set In case of loss or damage to any part of a pair or set we may: a. Repair or replace any part to restore the pair or set to its value before the loss or damage; or b. Pay the difference between the value of the pair or set before and after the loss or damage. 2. Parts In case of loss or damage to any part of Cov- ered Property consisting of several parts when complete, we will only pay for the value of the lost or damaged part. The Limit of Insurance will not be reduced by the payment of any claim, except for total loss or damage of a scheduled item, in which event we will refund the unearned premium on that item. Transfer Of Rights Of Recovery Against Others To Us If any person or organization to or for whom we make payment under this Coverage Part has rights to recover damages from another, those rights are transferred to us to the extent of our payment. That person or organization must do everything necessary to secure our rights and must do nothing after loss to impair them. But you may waive your rights against another party in writing: 1. Prior to a loss to your Covered Property. 2. After a loss to your Covered Property only if, at time of loss, that party is one of the follow- ing: a. Someone insured by this insurance; or b. A business firm: (1) Owned or controlled by you; or (2) That owns or controls you. This will not restrict your insurance. GENERAL CONDITIONS A. Concealment, Misrepresentation Or Fraud This Coverage Part is void in any case of fraud, intentional concealment or misrepresentation of a material fact, by you or any other insured, at any time, concerning: 1. This Coverage Part; 2. The Covered Property; 3. Your interest in the Covered Property; or 4. A claim under this Coverage Part. Page 2 of 3 CM 00 01 09 04 POLICY NUMBER: QT6604H598083TIA23 COMMERCIAL INLAND MARINE COMMERCIAL INLAND MARINE CONDITIONS The following conditions apply in addition to the set the damaged property aside and in the Common Policy Conditions and applicable Additional best possible order for examinat ion. Conditions in Commercial Inland Marine Coverage 5. You will not, except at your own cost, volun- Forms: tarily make a payment, assume any obliga- LOSS CONDITIONS tion, or incur any expense without our con - A. Abandonment sent. There can be no abandonment of any property to us. B. Appraisal If we and you disagree on the value of the prop- erty or the amount of loss, either may make writ- ten demand for an appraisal of the loss. In this event, each party will select a competent and impartial appraiser. The two appraisers will select an umpire. If they cannot agree, either may re- quest that selection be made by a judge of a court having jurisdiction. The appraisers will state separately the value of the property and amount of loss. If they fail to agree, they will submit their differences to the umpire. A decision agreed to by any two will be binding. Each party will: 1. Pay its chosen appraiser; and 2. Bear the other expenses of the appraisal and umpire equally. If there is an appraisal, we will still retain our right to deny the claim. C. Duties In The Event Of Loss You must see that the following are done in the event of loss or damage to Covered Property: 1. Notify the police if a law may have been bro- ken. 2. Give us prompt notice of the loss or damage. Include a description of the property involved. 3. As soon as possible, give us a description of how, when and where the loss or damage oc- curred. 4. Take all reasonable steps to protect the Cov- ered Property from further damage, and keep a record of your expenses necessary to pro- tect the Covered Property, for consideration in the settlement of the claim. This will not in- crease the Limit of Insurance. However, we will not pay for any subsequent loss or dam- age resulting from a cause of loss that is not a Covered Cause of Loss. Also, if feasible, 6. As often as may be reasonably required, permit us to inspect the property proving the loss or damage and examine your books and records. Also permit us to take samples of damaged and undamaged property for inspection, test- ing and analysis, and permit us to make cop- ies from your books and records. 7. We may examine any insured under oath, while not in the presence of any other insured and at such times as may be reasonably re- quired, about any matter relating to this in- surance or the claim, including an insured's books and records. In the event of an exami- nation, an insured's answers must be signed. 8. Send us a signed, sworn proof of loss con- taining the information we request to settle the claim. You must do this within 60 days af- ter our request. We will supply you with the necessary forms. 9. Immediately send us copies of any demands, notices, summonses or legal papers received in connection with the claim or suit. 10. Cooperate with us in the investigation or set- tlement of the claim. D. Insurance Under Two Or More Coverages If two or more of this policy's coverages apply to the same loss or damage, we will not pay more than the actual amount of the loss or damage. E. Loss Payment 1. We will give notice of our intentions within 30 days after we receive the sworn proof of loss. 2. We will not pay you more than your financial interest in the Covered Property. 3. We may adjust losses with the owners of lost or damaged property if other than you. If we pay the owners, such payments will satisfy your claim against us for the owners' prop- erty. We will not pay the owners more than CM 00 01 09 04 Page 1 of 3 COMMERCIAL INLAND MARINE their financial interest in the Covered Prop- erty. 4. We may elect to defend you against suits arising from claims of owners of property. We will do this at our expense. 5. We will pay for covered loss or damage within 30 days after we receive the sworn proof of loss if you have complied with all the terms of this Coverage Part and: a. We have reached agreement with you on the amount of the loss; or b. An appraisal award has been made. 6. We will not be liable for any part of a loss that has been paid or made good by others. F. Other Insurance 1. You may have other insurance subject to the same plan, terms, conditions and provisions as the insurance under this Coverage Part. If you do, we will pay our share of the covered loss or damage. Our share is the proportion that the applicable Limit of Insurance under this Coverage Part bears to the Limits of In- surance of all insurance covering on the same basis. 2. If there is other insurance covering the same loss or damage, other than that described in 1. above, we will pay only for the amount of covered loss or damage in excess of the amount due from that other insurance, whether you can collect on it or not. But we will not pay more than the applicable Limit of Insurance. G. Pair, Sets Or Parts 1. Pair Or Set In case of loss or damage to any part of a pair or set we may: a. Repair or replace any part to restore the pair or set to its value before the loss or damage, or b. Pay the difference between the value of the pair or set before and after the loss or damage. 2. Parts In case of loss or damage to any part of Cov- ered Property consisting of several parts when complete, we will only pay for the value of the lost or damaged part. H. Recovered Property If either you or we recover any property after loss settlement, that party must give the other prompt notice. At your option, the property will be re- turned to you. You must then return to us the amount we paid to you for the property. We will pay recovery expenses and the expenses to re- pair the recovered property, subject to the Limit of Insurance. I. Reinstatement Of Limit After Loss The Limit of Insurance will not be reduced by the payment of any claim, except for total loss or damage of a scheduled item, in which event we will refund the unearned premium on that item. J. Transfer Of Rights Of Recovery Against Others To Us If any person or organization to or for whom we make payment under this Coverage Part has rights to recover damages from another, those rights are transferred to us to the extent of our payment. That person or organization must do everything necessary to secure our rights and must do nothing after loss to impair them. But you may waive your rights against another party in writing: 1. Prior to a loss to your Covered Property. 2. After a loss to your Covered Property only if, at time of loss, that party is one of the follow- ing: a. Someone insured by this insurance; or b. A business firm: (1) Owned or controlled by you; or (2) That owns or controls you. This will not restrict your insurance. GENERAL CONDITIONS A. Concealment, Misrepresentation Or Fraud This Coverage Part is void in any case of fraud, intentional concealment or misrepresentation of a material fact, by you or any other insured, at any time, concerning: 1. This Coverage Part; 2. The Covered Property; 3. Your interest in the Covered Property; or 4. A claim under this Coverage Part. Page 2 of 3 CM 00 01 09 04 Policy No: CPPLS00023131 CPPL 03 01 (Ed. 09 17) Q. SEPARATION OF INSUREDS - Except with regard to the Limits of Liability, Self -Insured Retention, exclusions or limitations that refer to "any" INSURED, and any rights and duties assigned to the FIRST NAMED INSURED, this Policy applies as if each INSURED were the only INSURED, and separately to each INSURED against whom a CLAIM is made. Except as otherwise provided herein, misrepresentation, concealment, breach of a term or condition, or violation of any duty under this Policy by one INSURED shall not, by itself, affect coverage for another INSURED under this Policy. Provided, however, that this Condition shall not apply to any entity who is a parent, subsidiary, affiliate, director, officer, partner, member or employee of the INSURED that misrepresented, concealed or breached a term or condition, or violated a duty under this Policy. R. SUBROGATION - If the INSURED has rights to recover, from an entity other than an INSURED, any payment the Company makes under this Policy, those rights are transferred to the Company. The INSURED shall do whatever is necessary to secure such rights and shall do nothing to prejudice such rights. Any monies recovered as a result of subrogation proceedings shall accrue first to the INSURED to the extent of any payments it made in excess of the Limits of Liability, then to the Company to the extent of its payment under the Policy, and then to the INSURED to the extent of its payment of the Self -Insured Retention. Subrogation expenses incurred in such proceedings shall be apportioned amongst the INSURED and Company in the proportion that each party's share in the recovery bears to the total recovery. Notwithstanding the foregoing, the Company hereby expressly waives such rights of subrogation against an entity where such right has been waived, in writing, by the INSURED prior to the applicable CLAIM, POLLUTION CONDITION, INDOOR CONTAMINANT CONDITION or PROFESSIONAL LOSS. SECTION VIII. DEFINITIONS A. ADDITIONAL INSURED means: 1. any person or entity identified as an ADDITIONAL INSURED in an endorsement attached to this Policy; and > 2. solely with regard to Coverage A., when required by a written contract that is signed by the FIRST NAMED INSURED or an ADDITIONAL NAMED INSURED prior to the date the applicable POLLUTION CONDITION or INDOOR CONTAMINANT CONDITION first commences, ADDITIONAL INSURED also includes: a. the client entity for whom the INSURED performs CONTRACTING SERVICES pursuant to such written contract; and b. any other entity, unrelated to the FIRST NAMED INSURED or any ADDITIONAL NAMED INSURED pursuant to such written contract; The scope and limits of coverage of such entity under this Policy shall not exceed what is required by the written contract. Coverage is provided solely for its liability arising out of the FIRST NAMED INSURED's or any ADDITIONAL NAMED INSURED's ownership, maintenance, use, or operation of a COVERED LOCATION or vicarious liability for CONTRACTING SERVICES. Coverage shall only be afforded for such entity if it is named in a lawsuit, petition or regulatory action as a co-defendant with the FIRST NAMED INSURED or any ADDITIONAL NAMED INSURED alleging that it is liable as a result of either the FIRST NAMED INSURED's or any ADDITIONAL NAMED INSURED's ownership, maintenance, use, or operation of a COVERED LOCATION or such entity's vicarious liability for 34 CPPL 03 01 (Ed. 09 17) CONTRACTING SERVICES. No coverage will be provided under this Policy for an ADDITIONAL INSURED's own negligence or strict liability. B. ADDITIONAL NAMED INSURED means any entity identified as such in an endorsement attached to this Policy. C. APPLICABLE LAWS means: 1. any federal, state, commonwealth, local, or provincial laws, including but not limited to statutes, rules, ordinances, guidance documents, regulations and all amendments thereto, including risk based corrective action guidance, governing the liability or responsibilities of the INSURED; or in the absence of any of the items in 1. above, the recommendations of an ENVIRONMENTAL PROFESSIONAL. D. AUTOMOBILE means a land motor vehicle, trailer, semi -trailer, mobile equipment, or off -road motor vehicle, including any machinery or apparatus attached thereto. E. BODILY INJURY means: 1. physical injury, disease, sickness, or building -related illness sustained by any person, including death resulting therefrom and any medical or environmental monitoring costs that are intended to confirm any such physical injury, disease, sickness or illness; 2. court -ordered medical monitoring; or 3. mental anguish, emotional distress, or shock. F. BUSINESS INTERRUPTION LOSS means: the net profit or loss, before taxes, that the INSURED would have earned or incurred during the INTERRUPTION but for the INTERRUPTION, considering the financial performance of the business before the INTERRUPTION and the financial performance that most likely would have been realized thereafter had no INTERRUPTION occurred; the continuing normal operating expenses, at such JOB SITE or COVERED LOCATION as applicable, incurred by the INSURED during the INTERRUPTION, including the payroll expense for employees of the INSURED except for officers, directors, executives, department managers and contract employees; and 3. EXTRA EXPENSE incurred by the INSURED during the INTERRUPTION. G. CARGO means goods, products, or waste transported for delivery by a CARRIER. H. CARRIER means an entity, including an INSURED, engaged by or on behalf of the INSURED to transport material by AUTOMOBILE, aircraft, watercraft, or rolling stock, but only if such entity or INSURED, is properly licensed to transport such material and is in the business of transporting such material. CARRIER shall not include pipelines. CERTIFIED INDUSTRIAL HYGIENIST means a licensed professional as established by the American Board of Industrial Hygiene. The Company shall consult with the FIRST NAMED INSURED in the selection of the CERTIFIED INDUSTRIAL HYGIENIST. The Company may require that such professional meet certain minimum qualifications, including experience with similar MOLD MATTER or methamphetamine remediation, and that they maintain adequate errors and omissions insurance in light of the potential remediation. 35 CPPL 03 0108 08b Ed. (03 19) Endorsement No. 5 This endorsement, effective 4/1/2023, forms a part of Policy No: CPPL-S0002313-1 issued to SDB, Inc. by SiriusPoint Specialty Insurance Corporation (The Company) THIS ENDORSEMENT MODIFIES THE INSURANCE PROVIDED UNDER THIS POLICY. PLEASE READ IT CAREFULLY. AMENDMENTS TO THE DEFINITION OF ADDITIONAL INSURED AND TO THE OTHER INSURANCE CONDITION FOR THIRD PARTIES — SELECTED COVERAGES PRIMARY AND NON-CONTRIBUTORY WHEN REQUIRED BY CONTRACT In consideration of the following adjustment of premium: $0 The INSURED and the Company agree to the following change(s): Solely with regard to those Coverage Sections listed below and when required by written contract: I. SECTION VIII. DEFINTIONS, A. ADDITIONAL INSURED is deleted in its entirety and replaced with the following: A. ADDITIONAL INSURED means: solely with regard to the coverage sections listed below and when required by a written contract that is signed by the FIRST NAMED INSURED or an ADDITIONAL NAMED INSURED prior to the date the applicable POLLUTION CONDITION or INDOOR CONTAMINANT CONDITION first commences, ADDITIONAL INSURED includes: a. the client entity for whom the INSURED performs CONTRACTING SERVICES pursuant to such written contract; and b. any other entity, unrelated to the FIRST NAMED INSURED or any ADDITIONAL NAMED INSURED pursuant to such written contract. The scope and limits of coverage of such entity under this Policy shall not exceed what is required by the written contract. Coverage is provided solely for its vicarious liability for CONTRACTING SERVICES or a POLLUTION CONDITION as applicable. Coverage shall only be afforded for such entity if it is named in a lawsuit, petition or regulatory action as a co-defendant with the FIRST NAMED INSURED or any ADDITIONAL NAMED INSURED alleging such entity's vicarious liability for CONTRACTING SERVICES or a POLLUTION CONDITION as applicable. No coverage will be provided under this Policy for an ADDITIONAL INSURED's own negligence or strict liability. II. Solely with regard to an ADDITIONAL INSURED in Paragraph I above, SECTION VII. CONDITIONS, Item N. OTHER INSURANCE is deleted in its entirety and replaced with the following: N. OTHER INSURANCE - This insurance shall apply: 1. in excess of any applicable Self -Insured Retention or Deductible Period; 2. primary to, and non-contributory with, any other insurance available to the ADDITIONAL INSURED. 52 CPPL 03 0108 08b Ed. (03 19) The scope and limits of coverage under this Policy shall not exceed what is required by the written contract. Upon request of the Company, the INSURED shall promptly provide the Company with copies of all such other insurance policies. Coverage Section(s): COVERAGE A - CONTRACTOR'S OCCURENCE JOB SITE POLLUTION COVERAGE COVERAGE H — CONTRACTOR'S OCCURENCE NON -OWNED DISPOSAL SITE COVERAGE COVERAGE I — CONTRACTOR'S OCCURENCE TRANSPORTATION COVERAGE All other terms and conditions remain the same. 53 CONTRACTOR COMPLIANCE WITH WORKER'S COMPENSATION LAW Pursuant to Texas Labor Code Section 406.096(a), as amended, Contractor certifies that it provides worker's compensation insurance coverage for all of its employees employed on City Project, C IIime Lab Full Buildine Generator Replacement. 3616 E. Lancaster Ave.. Fort Worth, Texas 76103 (Pl1►iD2023- 10). Contractor fitrther certifies that, pursuant to Texas Labor Code, Section 406.096(b), as amended, it will provide to City its subcontractor's certificates of compliance with worker's compensation coverage. CONTRACTOR: SDB, Inc Company 1001 S. Edward Drive Address Tempe, AZ 85281 City/State/Zip 11v: John Fillion (Plea nt)/7 Signature: hilc: VP of Advanced Technoloqv (Please Print) THE STATE OF ARIZONA § KNOW ALL BY THESE PRESENTS: COUNTY OF MARICOPA § BEFORE ME, the undersigned authority. on this day personally appeared John Fillion known to me to ht the person whose name is subscribed to the foregoing instrument, and acknowledged to the t at he/she executed the same as the act and deed of SDB, Inc for the purposes and consideration therein expressed mid in the capacity therein stated. GIVEN UNDER MY HAND AND SEAL OF OFFICE this 6 day of February , 2024. +Nendy cuthbertson • Notary Public R Maricopa County, Arizona ' My Comm. Expires 09-24,24 commission No. 5s7152 Notary Public v for the Statc of Texas Instruction to Offerors Crime Lab Full Building Generator Replacement - Proj. #102986 Sept. 2023) Page 32 of 33 4'—C„ Z —O" 1 21-0" 00 CENTERLINE OF + SIGN, LOGO & TEXT INFORMATION FORT 01TH@) Project Title F r Architect: Architect's Name Contractor: PitContractor's Name FUNDED 9Y (List Bond Fund, etc.) SCHEDULED COMPLETION DATE YEAR SIGN COLOR & FONT: BACKGROUND - WHITE BORDER - 5116"WIDE, 3"RADIUS CORNERS, PMS 288 (BLUE) TEXT - HELVETICA or ARIAL, PMS 288 (BLUE) FORT WORTH LOGO COLORS & FONT: FORT WORTH - PMS 288 (BLUE), CHELTENHAM BOLD LONGHORN LOGO - PMS 725 (BROWN) PROJECT DESIGNATION SIGN Instruction to Offerors Page 33 of 33 Crime Lab Full Building Generator Replacement - Proj. #102986 Sept. 2023)