Loading...
HomeMy WebLinkAboutContract 51755-PM1i FORT WORTH PROJECT MANUAL FOR THE CONSTRUCTION OF City Secretary Contract No _ a� 1 'L M L WATER IMPROVEMENTS TO SERVE VICTORY SHOPS AT BAILEY BOSWELL City Project No. 101876 Water Project No. 56008-0600430-101876-001580 Betsy Price David Cooke Mayor City Manager Christopher P. Harder, P.E. Water Director David V. Magana, P.E. Director, Transportation and Public Works Department Prepared for The City of Fort Worth DECEMEBER 2018 PREPARED BY KIRKMAN ENGINEERING 4821 MERLOT AVENUE, SUITE 210 GRAPEVINE, TEXAS 76051 817-488-4960 J� OFFICIAL CITY SECRETARY FT WORTH, TX i/3/Zv1�7 WR Mok am PM Me i 4W 004 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 40 41 42 43 44 45 46 47 48 00 0010-1 TABLE OF CONTENTS FOR DEVELOPER AWARDED PROJECTS Page 1 of 4 SECTION 00 00 10 TABLE OF CONTENTS DEVELOPER AWARDED PROJECTS Division 00 - General Conditions 0044-4-3 Irr.-i4atic.-i tc Biddefs 002i i Tn 004"0 Bid Fefr 00 42 43 Proposal Form Unit Price 0043 13 Rid mid 00-4-541 B; ' 0045 12 Prequalification Statement 00-4 ` 12 B i 00 45 26 Contractor Compliance with Workers' Compensation Law 00-4-540 MineFity Business Enterprise Goal 00 52 43 Agreement 00 61 25 Certificate of Insurance 0062 13 Performance Bond 0062 14 Payment Bond 0062 19 Maintenance Bond 00 72 00 General Conditions 00 73-N 0073 10 Standard City Conditions of the Construction Contract for Developer Awarded Projects Division 01- General Requirements 01 1100 Summary of Work 04-2500 l; 01 31 19 Preconstrupcption Meeting 04-34-2-0 Dee J 0132 it ien Pr- 01 3233 Preconstruction Video 01 3300 Submittals 0? 3f 13 spedvaesedlrres 01 4523 Testing and Inspection Services 01 5000 Temporary Facilities and Controls 01 5526 Street Use Permit and Modifications to Traffic Control 01 57 13 Storm Water Pollution Prevention Plan 04-4521? T 01 60 00 Product Requirements 01 66 00 Product Storage and Handling Requirements 01 70 00 Mobilization and Remobilization 0�-- z 3 Constmstia. S`Akirg 01 7423 Cleaning 0177 19 Closeout Requirements 01 78 23 Operation and Maintenance Data 01 7839 Project Record Documents CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised September 1, 2015 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 40 41 42 43 44 45 46 47 48 49 50 00 00 10- 2 TABLE OF CONTENTS FOR DEVELOPER AWARDED PROJECTS Page 2 of 4 Technical Specifications listed below are included for this Project by reference and can be viewed/downloaded from the City's Buzzsaw site at: htvs:Ht)roiectDoint.buzzsaw.com/client/fortworthi ov/Resources/02%20- %20Construction%2ODocuments/SDeCification s Division 02 - Existing Conditions 0241 13 Selective Site Demolition 0241 14 Utility Removal/Abandonment 0241 15 Paving Removal Division 03 - Concrete 03-30-00 10 ft84 T., nlaee C;Ofl ffete 0_3?/1,3 03 344C 03 W-00 N Division 26 - Electrical 24-05 40 D 2-6-95 13 Division 31- Earthwork 314-0-00 l; 3123 16 UL-1 3 i 23-2 Bsrr-ew 3-� Embankments 31 25 00 Erosion and Sediment Control 34- 36 -W dens 3147-s0 Ripr� Division 32 - Exterior Improvements 3201 17 Permanent Asphalt Paving Repair 3241 19 Tsmpenm-y Asphalt Paving Repair- 324_ I Co :srete Paving Relt 321]99 Flexible 3 44-I%) ✓me -rfea4ea Base Gear-ses 32 1 i 21 Cement Tr-emed Base re,,. e� 32Wi6 Asphalt Paving 222 Asphalt It Paving Craek Se la is 324-3 13 Generete Paving 32-43-40 , C-Ane'r4#0 ne. 32 13 73 3314 46 ing joint sealants BrislUnit Paving 32 46 1? Generete Curb Gutters Valle), Guttem and and 32 17 2 Have. ew r,rafkings 32-3,1, 13 Chain Link Fence and r' ate-. 323126 VVir-e Fenees and Gates CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS —DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised September 1, 2015 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 40 41 42 43 44 45 46 47 48 49 50 0000 10-3 TABLE OF CONTENTS FOR DEVELOPER AWARDED PROJECTS Page 3 of 4 32-3-i 9 Weed Fences and Gates ;2-3Q 13 Cast in Dlaee Conefete Retaining Walls 3-291. !P To 32-92 13 Hydre Mulehing, Seeding, and Sodding 32-73-4f-? Trzas and'Shfubs Division 33 - Utilities 34-A4-M c» 33-0131 close 33 03 i o B`>vw' 33--04 -0 tad 33-N 11 Gerre 33 0430 T 33 04 40 Cleaning and Aeeeptanee Testing of Water- Mains 33 05 10 Utility Trench Excavation, Embedment, and Backfill 33-05 i Water- hine be 33 05-1-3 FffifflO, 33 05 i Adjusting r,r"., eles Met Valve Be*es, ..a Other mwtli 33 05 31 Tunnel 33 05 2 Steel Gasing Pipe 33 0533 I-'_wid Tufmeling 3305 1 L. b :r. T v- 3305 1 T.%:lty Mafker-A seaters 33 0530 Exploratory Excavation for Existing Utilities 33 11 10 Ductile Iron Pipe 33 11 11 Ductile Iron Fittings 33 11 12 Polyvinyl Chloride (PVC) Pressure Pipe 33 --)-1 13 , Steel Cylindep-T-fpe =1?11?1 Bur-ied Steel Pipe and Fittings 33 11 15 Pre stfessed Goner-ete Cylinder- Pipe 33 12 10 Water Services 1-inch to 2-inch 32 1.] 11 T 33 1220 Resilient Seated Gate Valve 33-4-3-21. 33 1225 Connection to Existing Water Mains fa ! ..,1.:.,"t: A:,- Valve Assemblies &f: Potable Al ter Systems 33 1240 Dry -Barrel Fire Hydrants 331i 59 944-2-60 WateF Sample Stations Blow off Valves 3331 12 Cured in Dlaee Pipe (CIPP) Fib , FAmta:,, Sewers 33 3 i i 3-r31 15 _1A)PF44Wo. ✓.ram er 33-34 o n,.l.,..;.tyl Chloride (PVC) GFav:t.vw J1ar _Sewed 34-34-421 34 34- 22 Eani", Sewer Slip Lining CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised September 1, 2015 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 34 35 36 00 00 10- 4 TABLE OF CONTENTS FOR DEVELOPER AWARDED PROJECTS Page 4 of 4 33-3430 ✓r. 1 33-3430 Air- Valve for- Sani+a f), Sewer- For- .e N 33 39 40 Cast in Place GOReFete Mmheles 3333920 Pr -,oast r,.ner-ete r,r.,.. eles 3349-39 Fi1 33-39-40 Wastewater- Aracess GhambeF (WAG) 33-39- 0 Epoxy 3341 19 P ' 3-2 1 ! 1 ? 19DPE Sotom. Ewe 33-4"9 ✓Jk baimge 39-46-0-1 ElettedStcew Drums 33-4" TreffA _Drum 33-4949 33-49--2U is 444940 Sott\e is DrarYc Division 34 - Transportation 34-4.119 34 41 1 nT7af�ls Removing 34-44 -49 Raziway illumination Assemblies 34-44-M Aluminum Signs 3471 13 Traffic Control Appendix G -4.01 GG-4.02 pia FAG-4.04 7UTrd 'es GG 48S GC-f.0,"' Wage Rates GC-649 Permit-- w. T Ts- 44kies GC-631 Nandisuifnifimien END OF SECTION CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised September 1, 2015 aW SECION 00 42 43 Developer Awarded Projects - PROPOSAL FORM UNIT PRICE BID Victory at Bailey Boswell 00 42 43 DAP - BID PROPOSAL Page I of I Bidder's Application Project Item Information Bidllst Item) Description I Specification I Unit of I Bid No. UNITI: WATER Section No. IMPROVEMENTS Measure Quantity 1 3311.0161 6" PVC Water Pipe 33 11 12 LF 81 2 3312.2203 2" Water Service 33 12 10 EA 1 3 3312.0001 Fire Hydrant 33 1240 EA 1 4 3312,4004 8" x 6" Tapping Sleeve & Valve 33 12 25 EA 2 5 3305.0109 Trench Safety 33 05 10 LF 81 6 0241.1100 Remove Asphalt Pvmt 02 41 15 SY 34 7 3201.0117 10' Wide Asphalt Pvmt Repair, Residential 32 01 17 LF 30 8 3471.0001 Traffic Control 34 71 13 TOTAL UNITI: WATER MO IMPROVEMENTS 1 Bid Summary UNIT I: WATER IMPROVEMENTS Total Construction Bid Bidders Proposal Unit Price I Bid Value $38.00 $3,078.00 $2,425.00 $2,425.00 $3,650,00 $3,650.00 $3,450.00 $6,900.00 $3.00 $243.00 $50.00 $1,700.00 $250.00 $7,500.00 $2.000.00 $2,000.00 $27,496.00 $27,496.00 527,496.00 Contractor agrees to complete WORK for FINAL ACCEPTANCE within 2) calendar days after the date when the CONTRACT commences to run as provided in the General Conditions. CITY OF FORT WORTH STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS -DEVELOPER AWARDED PROJECTS Form Verson Sepember 1.20l5 END OF SECTION 00 42 43 _Bid Proposal_DAPI IIIIIIII 004512 DAP PREQUALIFICATION STATEMENT Page I of I SECTION 00 45 12 DAP — PREQUALIFICATION STATEMENT Each Bidder is required to complete the information below by identifying the prequalified contractors and/or subcontractors whom they intend to utilize for the major work type(s) listed. In the "Maior Work Tvoe" box provide the complete maior work tvDe and actual description as provided by the Water Department for water and sewer and TPW for paving. Major Work Type Contractor/Subcontractor Company Name Prequalification Expiration Date Water and Wastewater New Development, Rehabilitation, and Tri Dal Utilities, LTD 4/30/2019 Redevelopment Open Cut (all sizes) The undersigned hereby certifies that the contractors and/or subcontractors described in the table above are currently prequalified for the work types listed. BIDDER: Tri Dal Utilities, LTD 540 Commerce St. Southlake, Texas 76092 BY: 'n (Signature) TITLE: Vice President o,�,,,��,, DATE: a011S END OF SECTION CITY OF FORT WORTH STANDARD CONSTRUCTION PREQUALIFICATION STATEMENT— DEVELOPER AWARDED PROJECTS 00 45 12 Prequallflcation Statement 2015 DAP.docx Form Version September 1, 2015 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 40 00 45 26 - I CONTRACTOR COMPLIANCE WITH WORKER'S COMPENSATION LAW Page I of I SECTION 00 45 26 CONTRACTOR COMPLIANCE WITH WORKER'S COMPENSATION LAW Pursuant to Texas Labor Code Section 406.096(a), as amended, Contractor certifies that it provides worker's compensation insurance coverage for all of its employees employed on City Project No. 10191ja . Contractor further certifies that, pursuant to Texas Labor Code, Section 406.096(b), as amended, it will provide to City its subcontractor's certificates of compliance with worker's compensation coverage. CONTRACTOR: Tri Dal Utilities, LTD Company 540 Commerce Address Southlake TX 76092 City/State/Zip THE STATE OF TEXAS § COUNTY OFTARRANT § By: Tim Mullikin (Please Pri ) 1V Signature: �.. Title: Vice President of Operations (Please Print) BEFORE ME, the undersigned authority, on this day personally appeared known to me to be the person whose name is subscribed to the foregoing i trument, and acknowledged to me that he/she executed the same as the act and deed of N\ `4 t- t>NebkA- - tc)�oaNfor the purposes and consideration therein expressed and in the capacity th rein stated. GIVEN UNDER MY HAND AND SEAL OF OFFICE this a'n'`. day of 20�� �%,,gp,WBF,4 00 Not Pu lic in and for the Stan f Texas o ••QY•P� .�F ft do 0 esdo ft 0 1.do z T � / b • do ••�28861..' ��i kp 08.28•Z��� �, END OF SECTION CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS City Project No. Revised April 2, 2014 00 52 43 - 1 Developer Awarded Project Agreement Page I of 4 1 SECTION 00 52 43 2 AGREEMENT 3 4 THIS AGREEMENT, authorized on 01/03/2019 ismade by and between the Developer, 5 Victory Shops @ Bailey Boswell, LLC authorized to do business in Texas ("Developer") , and 6 Tri Dal Utilities, LTD authorized to do business in Texas, acting by and 7 through its duly authorized representative, ("Contractor"). 8 Developer and Contractor, in consideration of the mutual covenants hereinafter set forth, agree as 9 follows: 10 Article 1. WORK 11 Contractor shall complete all Work as specified or indicated in the Contract Documents for the 12 Project identified herein. 13 Article 2. PROJECT 14 The project for which the Work under the Contract Documents may be the whole or only a part is 15 generally described as follows: 16 Victory Shops at Bailey Boswell 17 City Project No. 101876 18 Article 3. CONTRACT TIME 19 3.1 Time is of the essence. 20 All time limits for Milestones, if any, and Final Acceptance as stated in the Contract 21 Documents are of the essence to this Contract. .. 22 3.2 Final Acceptance. 23 The Work will be complete for Final Acceptance within {2L_j calendar days after the 24 date when the Contract Time commences to run as provided in Paragraph 12.04 of the 25 Standard City Conditions of the Construction Contract for Developer Awarded Projects. 26 3.3 Liquidated damages 27 Contractor recognizes that time is of the essence of this Agreement and that Developer 28 will suffer financial loss if the Work is not completed within the times specified in 29 Paragraph 3.2 above, plus any extension thereof allowed in accordance with Article 10 of 30 the Standard City Conditions of the Construction Contract for Developer Awarded 31 Projects. The Contractor also recognizes the delays, expense and difficulties involved in 32 proving in a legal proceeding the actual loss suffered by the Developer if the Work is not 33 completed on time. Accordingly, instead of requiring any such proof, Contractor agrees 34 that as liquidated damages for delay (but not as a penalty), Contractor shall pay 35 Developer Zero Dollars ($ 0.00 ) 36 for each day that expires after the time specified in Paragraph 3.2 for Final Acceptance 37 until the City issues the Final Letter of Acceptance. W CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. Revised June 16, 2016 W 005243-2 Dcvcloper Awardcd Projcct Agrecmcnt Pagc 2 of 4 38 Article 4. CONTRACT PRICE 39 Developer agrees to pay Contractor for performance of the Work in accordance with the Contract 40 Documents an amount in current funds of Twenty Seven Thousand Four Hundres Ninety Six Dollars 41 ($ 27,496.00 � 42 Article 5. CONTRACT DOCUMENTS 43 5.1 CONTENTS: 44 45 46 47 48 49 50 51 52 53 54 55 56 57 58 59 60 61 62 63 64 65 66 67 68 69 70 71 72 73 74 75 A. The Contract Documents which comprise the entire agreement between Developer and Contractor concerning the Work consist of the following: 1. This Agreement. 2. Attachments to this Agreement: a. Bid Form (As provided by Developer) 1) Proposal Form (DAP Version) 2) Prequalification Statement 3) State and Federal documents (project specific) b. Insurance ACORD Form(s) c. Payment Bond (DAP Version) d. Performance Bond (DAP Version) e. Maintenance Bond (DAP Version) f. Power of Attorney for the Bonds g. Worker's Compensation Affidavit h. MBE and/or SBE Commitment Form (If required) 3. Standard City General Conditions of the Construction Contract for Developer Awarded Projects. 4. Supplementary Conditions. 5. Specifications specifically made a part of the Contract Documents by attachment or, if not attached, as incorporated by reference and described in the Table of Contents of the Project's Contract Documents. 6. Drawings. 7. Addenda. 8. Documentation submitted by Contractor prior to Notice of Award. 9. The following which may be delivered or issued after the Effective Date of the Agreement and, if issued, become an incorporated part of the Contract Documents: a. Notice to Proceed. b. Field Orders. c. Change Orders. d. Letter of Final Acceptance. CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. Revised June 16, 2016 005243-3 Developer Awarded Project Agreement Page 3 of 4 76 Article 6. INDEMNIFICATION 77 6.1 Contractor covenants and agrees to indemnify, hold harmless and defend, at its own 78 expense, the city, its officers, servants and employees, from and against any and all 79 claims arising out of, or alleged to arise out of, the work and services to be performed 80 by the contractor, its officers, agents, employees, subcontractors, licenses or invitees 81 under this contract. This indemnification provision is specifically intended to operate 82 and be effective even if it is alleged or proven that all or some of the damages being 83 sought were caused, in whole or in part, by anv act, omission or negligence of the city. 84 This indemnity provision is intended to include, without limitation, indemnity for 85 costs, expenses and legal fees incurred by the city in defending against such claims and 86 causes of actions. 87 88 6.2 Contractor covenants and agrees to indemnify and hold harmless, at its own expense, 89 the city, its officers, servants and employees, from and against any and all loss, damage 90 or destruction of property of the city, arising out of, or alleged to arise out of, the work 91 and services to be performed by the contractor, its officers, agents, employees, 92 subcontractors, licensees or invitees under this contract. This indemnification 93 provision is specifically intended to operate and be effective even if it is alleged or 94 proven that all or some of the damages being sought were caused, in whole or in Dart, 95 by anv act, omission or negligence of the city. 96 97 Article 7. MISCELLANEOUS 98 7.1 Terms. 99 Terms used in this Agreement are defined in Article 1 of the Standard City Conditions of 100 the Construction Contract for Developer Awarded Projects. 101 7.2 Assignment of Contract. 102 This Agreement, including all of the Contract Documents may not be assigned by the 103 Contractor without the advanced express written consent of the Developer. 104 7.3 Successors and Assigns. 105 Developer and Contractor each binds itself, its partners, successors, assigns and legal 106 representatives to the other party hereto, in respect to all covenants, agreements and 107 obligations contained in the Contract Documents. 108 7.4 Severability. 109 Any provision or part of the Contract Documents held to be unconstitutional, void or 110 unenforceable by a court of competent jurisdiction shall be deemed stricken, and all 111 remaining provisions shall continue to be valid and binding upon DEVELOPER and 112 CONTRACTOR. 113 7.5 Governing Law and Venue. 114 This Agreement, including all of the Contract Documents is performable in the State of 115 Texas. Venue shall be Tarrant County, Texas, or the United States District Court for the 116 Northern District of Texas, Fort Worth Division. CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. Revised June 16, 2016 00 52 43 - 4 Developer Awarded Project Agreement Page 4 of 4 117 118 7.6 Authority to Sign. 119 Contractor shall attach evidence of authority to sign Agreement, if other than duly 120 authorized signatory of the Contractor. 121 122 IN WITNESS WHEREOF, Developer and Contractor have executed this Agreement in multiple 123 counterparts. 124 Mt 125 This Agreement is effective as of the last date signed by the Parties ("Effective Date"). 126 Contractor: Ieveloper: Tri Dal Utties, LTD \14, ry S hops Q Nil.t,,t 6o5W.u{L, I` By: ,.� (Signature) (Si ture) Tim Mullikin -T-r)nq Q 01JVKn k (Printed Name) (Pri&ed Name) Title: Vice President of Operations Title: W-:P-c� &,Y ' c1 U Company Name: Tri Dal Utilities, LTD Company name: I Address: 540 Commerce Address: A Z0 Pr-e- 6VI i& a A City/State/Zip:Southlake TX, 76092 City/State/Zip: akA (i s t 71t IS 2 25 12/28/18 _(�v 63— U I &-1 Date Date 127 MR MP M CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. Revised June 16, 2016 0062 13- 1 PERFORMANCE BOND Page 1 of 2 1 SECTION 00 62 13 2 PERFORMANCE BOND 3 4 THE STATE OF TEXAS § 5 § KNOW ALL BY THESE PRESENTS: 6 COUNTY OF TARRANT § 7 8 That we, Tri Dal Utilities, Ltd. , known as 9 "Principal" herein and Travelers Casualtv and Suretv Companv of America . a corporate 10 surety(sureties, if more than one) duly authorized to do business in the State of Texas, known as 11 "Surety" herein (whether one or more), are held and firmly bound unto the Developer, 12 Victory Shops @ Bailey Boswell, LLC), authorized to do business in Texas ("Developer") and the City of Fort 13 Worth, a Texas municipal corporation ("City"), in the penal sum of, 14 Twenty-seven Thousand Four Hundred Ninety-six and Noll 00 Dollars ($ 27.496.00 ), 15 lawful money of the United States, to be paid in Fort Worth, Tarrant County, Texas for the 16 payment of which sum well and truly to be made jointly unto the Developer and the City as dual 17 i obligees, we bind ourselves, our heirs, executors, administrators, successors and assigns, jointly 18 and severally, firmly by these presents. 19 WHEREAS, Developer and City have entered into an Agreement for the construction of 20 community facilities in the City of Fort Worth by and through a Community Facilities 21 Agreement, CFA Number 101876 and 22 WHEREAS, the Principal has entered into a certain written contract with the Developer awarded 23 the 03 day of January . 20 19 , which Contract is hereby referred to and made a 24 part hereof for all purposes as if fully set forth herein, to furnish all materials, equipment labor 25 and other accessories defined by law, in the prosecution of the Work, including any Change 26 Orders, as provided for in said Contract designated as Victory Shops at Bailey Boswell. ' 27 NOW, THEREFORE, the condition of this obligation is such that if the said Principal 28 shall faithfully perform it obligations under the Contract and shall in all respects duly and 29 faithfully perform the Work, including Change Orders, under the Contract, according to the plans, 30 specifications, and contract documents therein referred to, and as well during any period of 31 extension of the Contract that may be granted on the part of the Developer and/or City, then this 32 obligation shall be and become null and void, otherwise to remain in full force and effect. CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised January 31, 2012 Victory Shops at Bailey Boswell City Project No. M 006213-2 PERFORMANCE BOND Page 2 of 2 1 PROVIDED FURTHER, that if any legal action be filed on this Bond, venue shall lie in 2 Tarrant County, Texas or the United States District Court for the Northern District of Texas, Fort 3 Worth Division. 4 This bond is made and executed in compliance with the provisions of Chapter 2253 of the 5 Texas Government Code, as amended, and all liabilities on this bond shall be determined in 6 accordance with the provisions of said statue. 7 IN WITNESS WHEREOF, the Principal and the Surety have SIGNED and SEALED 8 this instrument by duly authorized agents and officers on this the Z day of 9 30L&V Vj , 20 to(. . 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 40 41 42 43 44 45 46 W ATTEST: (Principal) Secretary ne s as to Principal" �- PRINCIPAL: Tri Wiggnatturse" d. BY: Tim Mullikin, Vice President of Operations Name and Title Address: 540 Commerce St. Southlake. TX_76092 SURETY: Travelers Casualty and Surety Company of America BY: Signs re Felix Navejar' Attorney -in -Farr Name and Title Address: One Tower Sauare Hartford. CT 06183 ;<,/z Witness as to Surety Eric Lesch, Witness Telephone Number: 1-800-252-3439 *Note: If signed by an officer of the Surety Company, there must be on file a certifiedAV",t#,,i,,,, from the by-laws showing that this person has authority to sign such ob]Ai !p ETA Surety's physical address is different from its mailing address, both must bip�,byu"'••., eo The date of the bond shall not be prior to the date the Contract is awarded NARTF0R0. •i CITY OF FORT WORTH VicfpricJ�s at BaileY,Bo Ac�il:� STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS a,•77�/1 r•�'r���• Revised January 31, 2012 'brrrrrunrrrN�. 00 62 14 - 1 PAYMENTBOND Page 1 of 2 1 SECTION 00 62 14 2 PAYMENT BOND 3 — 4 THE STATE OF TEXAS § 5 § KNOW ALL BY THESE PRESENTS: 6 COUNTY OF TARRANT § 7 That we, Tri Dal Utilities, Ltd. known as 8 "Principal" herein, and Travelers Casualty and Surety Company of America a Y 9 corporate surety ( or sureties if more than one), duly authorized to do business in the State of 10 Texas, known as "Surety" herein (whether one or more), are held and firmly bound unto the — 11 Developer.Victory Shops @ Bailey Boswell, LLC , authorized to do business in Texas 12 "(Developer"), and the City of Fort Worth, a Texas municipal corporation ("City"), in the penal ,.. 13 sum of Twenty-seven Thousand Four Hundred Ninety-six and No/100 Dollars 14 ($ 27.496.00------------), lawful money of the United States, to be paid in Fort Worth, 15 Tarrant County, Texas, for the payment of which sum well and truly be made jointly unto the 16 Developer and the City as dual obligees, we bind ourselves, our heirs, executors, administrators, 17 successors and assigns, jointly and severally, firmly by these presents: 18 WHEREAS, Developer and City have entered into an Agreement for the construction of 19 community facilities in the City of Fort Worth, by and through a Community Facilities 20 Agreement, CFA Number 101876 and 21 WHEREAS, Principal has entered into a certain written Contract with Developer, 22 awarded the 03 day of January , 2019 , which Contract is hereby 23 referred to and made a part hereof for all purposes as if fully set forth herein, to furnish all 24 materials, equipment, labor and other accessories as defined by law, in the prosecution of the 25 Work as provided for in said Contract and designated as Victory Shops at Bailey Boswell. 26 NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION is such that if 27 Principal shall pay all monies owing to any (and all) payment bond beneficiary (as defined in 28 Chapter 2253 of the Texas Government Code, as amended) in the prosecution of the Work under 29 the Contract, then this obligation shall be and become null and void; otherwise to remain in full 30 force and effect. CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised January 31, 2012 Victory Shops at Bailey Boswell City Project No. 006214-2 PAYMENT BOND Page 2 of 2 1 This bond is made and executed in compliance with the provisions of Chapter 2253 of the 2 Texas Government Code, as amended, and all liabilities on this bond shall be determined in 3 accordance with the provisions of said statute. 4 IN WITNESS WHEREOF, the Principal and Surety have each SIGNED and SEALED 5 this instrument by duly authorized agents and officers on this the 0 day of 7 PRINCIPAL: Tri Dal Utilities, Ltd. a ATTEST: BY: Signature Tim Mullikin, Vice President of Operations (Principal) Secretary Name and Title _ Address: 540 Commerce St Southlake. TX 76092 Wi es as torincipa� SURETY: Travelers Suretv Comoanv of America .Cas�ualt-viand ATTEST: BY: Signature Felix Naveiar, Attorney -in -Fact Name and Title Address: One Tower Square Hartford, CT 06183 Witness as to Surety Eric Lesch, Witness Telephone Number: 1-800-252-3439 8 9 Note: If signed by an officer of the Surety, there must be on file a certified extract from the 10 bylaws showing that this person has authority to sign such obligation. If�ety's physical 11 address is different from its mailing address, both must be provided. `T 13 The date of the bond shall not be prior to the date the Contract is awarded..�`��`�'-��'�cp 14 END OF SECTION V c MAR1•MU, %. CONIL CITY OF FORT WORTH � 7 *dV,' ,9tY•SktlpLQt }Q'iley Boswell STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS i��i,, ` * ti •.City Project No. '0N������I,������•,••`' Revised January 31, 2012 006219-1 MAINTENANCE BOND Page l of 3 SECTION 00 62 19 2 MAINTENANCE BOND 3 4 THE STATE OF TEXAS § 5 § KNOW ALL BY THESE PRESENTS: 6 COUNTY OF TARRANT § 7 8 That we Tri Dal Utilities, Ltd. . known as 9 "Principal" herein and Travelers Casualty and Surety Company of America . a corporate surety 10 (sureties, if more than one) duly authorized to do business in the State of Texas, known as 11 "Surety" herein (whether one or more), are held and firmly bound unto the Developer, 12 Victory Shops A Bailey Boswell, LLC , authorized to do business in Texas ("Developer") and the 13 City of Fort Worth, a Texas municipal corporation ("City"), in the sum 14 of Twenty-seven Thousand Four Hundred Ninety-six and Nol100 Dollars ($ 27,496.00--------------), 15 lawful money of the United States, to be paid in Fort Worth, Tarrant County, Texas, for payment 16 of which sum well and truly be made jointly unto the Developer and the City as dual obligees and 17 their successors, we bind ourselves, our heirs, executors, administrators, successors and assigns, 18 jointly and severally, firmly by these presents. 19 20 WHEREAS, Developer and City have entered into an Agreement for the construction of 21 community facilities in the City of Fort Worth by and through a Community Facilities 22 Agreement, CFA Number 101876 and 23 WHEREAS, the Principal has entered into a certain written contract with the Developer 24 awarded the 03 day of January 2019 ) Which Contract is 25 hereby referred to and a made part hereof for all purposes as if fully set forth herein, to furnish all 26 materials, equipment labor and other accessories as defined by law, in the prosecution of the 27 Work, including any Work resulting from a duly authorized Change Order (collectively herein, 28 the "Work") as provided for in said Contract and designated as Victory Shops at Bailey Boswell; 29 and 30 31 WHEREAS, Principal binds itself to use such materials and to so construct the Work in 32 accordance with the plans, specifications and Contract Documents that the Work is and will 33 remain free from defects in materials or workmanship for and during the period of two (2) years 34 after the date of Final Acceptance of the Work by the City ("Maintenance Period"); and i CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised January 31, 2012 Victory Shops at Bailey Boswell City Project No. E* 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 006219-2 MAINTENANCE BOND Page 2 of 3 WHEREAS, Principal binds itself to repair or reconstruct the Work in whole or in part upon receiving notice from the Developer and/or City of the need thereof at any time within the Maintenance Period. NOW THEREFORE, the condition of this obligation is such that if Principal shall remedy any defective Work, for which timely notice was provided by Developer or City, to a completion satisfactory to the City, then this obligation shall become null and void; otherwise to remain in full force and effect. PROVIDED, HOWEVER, if Principal shall fail so to repair or reconstruct any timely noticed defective Work, it is agreed that the Developer or City may cause any and all such defective Work to be repaired and/or reconstructed with all associated costs thereof being borne by the Principal and the Surety under this Maintenance Bond; and PROVIDED FURTHER, that if any legal action be filed on this Bond, venue shall lie in Tarrant County, Texas or the United States District Court for the Northern District of Texas, Fort Worth Division; and PROVIDED FURTHER, that this obligation shall be continuous in nature and successive recoveries may be had hereon for successive breaches. CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised January 31, 2012 Victory Shops at Bailey Boswell City Project No. 006219-3 MAINTENANCE BOND Page 3 of 3 1 IN WITNESS WHEREOF, the Principal and the Surety have each SIGNED and SEALED this 2 instrument by duly authorized agents and officers on this the b 2, day of l CX^ V W V-) 3 , 201 6�& . 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 40 41 42 ATTEST: (Principal) Secretary � alWi es as to Principal ATTEST: 4—. Witness as to urety Eric Lesch, Witness PRINCIPAL: Tri Dal U(ilitieCre s, Ltd.r)BY: ,I/afo Tim Mullikin, Vice President of Operations Name and Title Address: 540 Commerce St. Southlake. TX 76092 SURETY: Travelers Casualty and Surety Company of America BY: • . Slg�tu O v Felix Naveiar, Attorney -in -Fact Name and Title Address: One Tower Square Hartford, CT 06183 Telephone Number: 1-800-252-3439 *Note: If signed by an officer of the Surety Company, there must be on file a certified extract from the by-laws showing that this person has authority to sign such obligation. If Surety's physical address is different from its mailing address, both must be provided. The date of the bond shall not be prior to the date the Contract is awarded. CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised January 31, 2012 ,04 Oil •` KARTF3RD. .. : CONM• S�/h••4.'•v1G)941SRoai $2i- Boswell ,, �` ,k 1% ity roject No. TEXAS - INFORMATION OR COMPLAINTS NOTICE To obtain information or make a complaint: You may call Travelers toll -free telephone number for information or to make a complaint at: 1-800-328-2189 You may contact the Texas Department of Insurance to obtain information on companies, coverages, rights, or complaints at: 1-800-252-3439 You may write the Texas Department of Insurance PO Box 149104 Austin, TX 78714-9104 Fax (512) 475-1771 Web: httD://www.tdi.texas.Rov E-mail: ConsumerProtectionCa-Dtdi.texas.eov PREMIUM OR CLAIM DISPUTES: Should you have a dispute concerning your premium or about a claim you should contact your Agent or Travelers first. If the dispute is not resolved, you may contact the Texas Department of Insurance. ATTACH THIS NOTICE TO YOUR POLICY: This notice is for information only and does not become a part or condition of the attached document. AVISO IMPORTANTE - INFORMACIO/ N O QUEJAS - TEXAS Usted puede Ilamar al numero de telefono gratis de Travelers para informacio/n o para someter una queja al: 1-800-328-2189 Puede comunicarse con el Departamento de Seguros de Texas para obtener informacio/n acerca de companias, coberturas, derechos o quejes al: 1-800-252-3439 Puede escribir al Departamento de Seguros de Texas PO Box 149104 Austin, TX 78714-9104 Fax (512) 475-1771 Web: httD://www.tdi.texas.eov E-mail: ConsumerProtectionC@tdi.texas.eov DISPUTAS SOBRE PRIMAS O RECLAMOS: Si tiene una disputa concerniente a su prima o a un reclamo, debe comunicarse con el Agente o Travelers primero. Si no se resuelve la disputa, puede entonces comunicarse con el departamento (TDI). UNA ESTE AVISO A SU POLIZA: Este aviso es solo para proposito de Informacio/n y no se convierte en parte o condicion del documento adjunto. NTC-19023 Ed. 05-13 Page 1 of 1 0 2013 The Travelers Indemnity Company. All rights reserved. Bond No. 106997576 TRAVELERS Travelers Casualty and Surety Company of America Travelers Casualty and Surety Company St. Paul Fire and Marine Insurance Company POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS: That Travelers Casualty and Surety Company of America, Travelers Casualty and Surety Company, and St. Paul Fire and Marine Insurance Company are corporations duly organized under the laws of the State of Connecticut (herein collectively called the "Companies"), and that the Companies do hereby make, constitute and appoint Felix Navejar, of Grapevine, Texas, their true and lawful Attorney -in - Fact to sign, execute, seal and acknowledge any and all bonds, recognizances, conditional undertakings and other writings obligatory in the nature thereof on behalf of the Companies in their business of guaranteeing the fidelity of persons, guaranteeing the performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law. IN WITNESS WHEREOF, the Companies have caused this instrument to be signed, and theircorporate seals to be hereto affixed, this 3rd day of February, 2017. testy �� Tr 7 CONK State of Connecticut City of Hartford ss. By:���� Robert L. Raney, Seer Vice President On this the 3rd day of February, 2017, before me personally appeared Robert L. Raney, who acknowledged himself to be the Senior Vice President of Travelers Casualty and Surety Company of America, Travelers Casualty and Surety Company, and St. Paul Fire and Marine Insurance Company, and that he, as such, being authorized so to do, executed the foregoing instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer. In Witness Whereof, I hereunto set my hand and official seal. G• My Commission expires the 30th day of June, 2021 TAA Mank C. C. Tetreault, Notary Public This Power of Attorney is granted under and by the authority of the following resolutions adopted by the Boards of Directors of Travelers Casualty and Surety Company of America, Travelers Casualty and Surety Company, and St. Paul Fire and Marine Insurance Company, which resolutions are now in full force and effect, reading as follows: RESOLVED, that the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President, any Vice President, any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary may appoint Attorneys -in -Fact and Agents to act for and on behalf of the Company and may give such appointee such authority as his or her certificate of authority may prescribe to sign with the Company's name and seal with the Company's seal bonds, recognizances, contracts of indemnity, and other writings obligatory in the nature of a bond, recognizance, or conditional undertaking, and any of said officers or the Board of Directors at any time may remove any such appointee and revoke the power given him or her: and it is FURTHER RESOLVED, that the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice President may delegate all or any part of the foregoing authority to one or more officers or employees of this Company, provided that each such delegation is in writing and a copy thereof is filed in the office of the Secretary; and it is FURTHER RESOLVED, that any bond, recognizance, contract of indemnity, or writing obligatory in the nature of a bond, recognizance, or conditional undertaking shall be valid and binding upon the Company when (a) signed by the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice President, any Second Vice President. the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary and duly attested and sealed with the Company's seal by a Secretary or Assistant Secretary; or (b) duly executed (under seal, if required) by one or more Attorneys -in -Fact and Agents pursuant to the power prescribed in his or her certificate or their certificates of authority or by one or more Company officers pursuant to a written delegation of authority; and it is FURTHER RESOLVED, that the signature of each of the following officers: President, any Executive Vice President, any Senior Vice President, any Vice President, any Assistant Vice President, any Secretary, any Assistant Secretary, and the seal of the Company may be affixed by facsimile to any Power of Attorney or to any certificate relating thereto appointing Resident Vice Presidents, Resident Assistant Secretaries or Attorneys -in -Fact for purposes only of executing and attesting bonds and undertakings and other writings obligatory in the nature thereof, and any such Power of Attorney or certificate bearing such facsimile signature or facsimile seal shall be valid and binding upon the Company and any such power so executed and certified by such facsimile signature and facsimile seal shall be valid and binding on the Company in the future with respect to any bond or understanding to which it is attached. I, Kevin E. Hughes, the undersigned, Assistant Secretary of Travelers Ctas0V1Wdtrd•Surety Company of America, Travelers Casualty and Surety Company, and St. Paul Fire and Marine Insurance Company, do hereby N%fg1h1Vt4j0ove and foregoing is a true and correct copy of the Power of Attorney executed by said Companies, which remains in full force and ,`e 1. Dated this day of 201L, Tc ^ s° fi caft a M , 6 S ', '••,;�'d f �� r Kevin E. COOK Hughes, As�cretary •%i Jryrra.. a N�"'•• To verify the authea fcity of this Power of Attorney, please callus at 1-800-4113880. Please refer to the above -named Attorney -in -Fact and the details of the bond to whicah the power is attached. P" f This document has important legal consequences; consultation with an attorney is encouraged with respect to its use or modification. This document should be adapted to the particular circumstances of the contemplated Project and the controlling Laws and Regulations. STANDARD GENERAL CONDITIONS OF THE CONSTRUCTION CONTRACT Prepared by ENGINEERS JOINT CONTRACT DOCUMENTS COMMITTEE and Issued and Published Jointly by 1 ACEC "w Coy m iJJGRiF im Comwn- ASCE American Society of Civil Engineers National Society of Professional Engineers Professional Engineer In Private Practice AMERICAN COUNCIL OF ENGINEERING COMPANIES ASSOCIATED GENERAL CONTRACTORS OF AMERICA AMERICAN SOCIETY OF CIVIL ENGINEERS PROFESSIONAL ENGINEERS IN PRIVATE PRACTICE A Practice Division of the NATIONAL SOCIETY OF PROFESSIONAL ENGINEERS Endorsed by w � ,., CONSTRUCTION SPECIFICATIONS INSTITUTE 00 EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. These General Conditions have been prepared for use with the Suggested Forms of Agreement Between Owner and Contractor (EJCDC C-520 or C-525, 2007 Editions). Their provisions are interrelated and a change in one may necessitate a change in the other. Comments concerning their usage are contained in the Narrative Guide to the EJCDC Construction Documents (EJCDC C-001, 2007 Edition). For guidance in the preparation of Supplementary Conditions, see Guide to the Preparation of Supplementary Conditions (EJCDC C-800, 2007 Edition). Copyright © 2007 National Society of Professional Engineers 1420 King Street, Alexandria, VA 22314-2794 .+ (703) 684-2882 www.nsi)e.or2 American Council of Engineering Companies 1015 15th Street N.W., Washington, DC 20005 (202) 347-7474 www.acec.om American Society of Civil Engineers 1801 Alexander Bell Drive, Reston, VA 20191-4400 (800) 548-2723 www.asce.ora Associated General Contractors of America _ 2300 Wilson Boulevard, Suite 400, Arlington, VA 22201-3308 (703) 548-3118 www.aP-c.ora The copyright for this EJCDC document is owned jointly by the four EJCDC sponsoring organizations and held in trust for their benefit by NSPE. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. M i STANDARD GENERAL CONDITIONS OF THE CONSTRUCTION CONTRACT TABLE OF CONTENTS Page Article 1 — Definitions and Terminology.......................................................................................................... I 1.01 Defined Terms...............................................................................................................................1 1.02 Terminology.................................................................................................................................. 5 Article2 — Preliminary Matters......................................................................................................................... 6 2.01 Delivery of Bonds and Evidence of Insurance............................................................................. 6 2.02 Copies of Documents....................................................................................................................6 2.03 Commencement of Contract Times; Notice to Proceed............................................................... 6 2.04 Starting the Work.......................................................................................................................... 7 2.05 Before Starting Construction........................................................................................................ 7 2.06 Preconstruction Conference; Designation of Authorized Representatives .................................. 7 2.07 Initial Acceptance of Schedules....................................................................................................7 MW Article 3 — Contract Documents: Intent, Amending, Reuse............................................................................ 8 3.01 Intent.............................................................................................................................................. 8 3.02 Reference Standards...................................................................................................................... 8 3.03 Reporting and Resolving Discrepancies.......................................................................................9 3.04 Amending and Supplementing Contract Documents...................................................................9 3.05 Reuse of Documents 10 ................................................................................................................... 3.06 Electronic Data............................................................................................................................10 Article 4 — Availability of Lands; Subsurface and Physical Conditions; Hazardous Environmental Conditions; Reference Points...........................................................................................................11 4.01 Availability of Lands................................................................................................................... I I '~ 4.02 Subsurface and Physical Conditions........................................................................... ......11 4.03 Differing Subsurface or Physical Conditions.............................................................................12 4.04 Underground Facilities................................................................................................................13 i 4.05 Reference Points ..........................................................................................................................14 4.06 Hazardous Environmental Condition at Site..............................................................................14 i Article 5 — Bonds and Insurance......................................................................................................................16 5.01 Performance, Payment, and Other Bonds...................................................................................16 5.02 Licensed Sureties and Insurers....................................................................................................16 i 5.03 Certificates of Insurance.............................................................................................................17 5.04 Contractor's Insurance................................................................................................................17 i 5.05 Owner's Liability Insurance........................................................................................................19 5.06 Property Insurance.......................................................................................................................19 5.07 Waiver of Rights......................................................................................................................... 20 5.08 Receipt and Application of Insurance Proceeds.........................................................................21 EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page MR 5.09 Acceptance of Bonds and Insurance; Option to Replace........................................................... 21 .. 5.10 Partial Utilization, Acknowledgment of Property Insurer..........................................................22 Article 6 - Contractor's Responsibilities........................................................................................................22 6.01 Supervision and Superintendence...............................................................................................22 6.02 Labor; Working Hours................................................................................................................22 6.03 Services, Materials, and Equipment........................................................................................... 22 6.04 Progress Schedule....................................................................................................................... 23 6.05 Substitutes and "Or-Equals"....................................................................................................... 23 6.06 Concerning Subcontractors, Suppliers, and Others....................................................................25 Mi. 6.07 Patent Fees and Royalties...........................................................................................................27 6.08 Permits.........................................................................................................................................27 6.09 Laws and Regulations 28 6.10 Taxes...........................................................................................................................................28 6.11 Use of Site and Other Areas ........................................................................................................28 6.12 Record Documents......................................................................................................................29 6.13 Safety and Protection.................................................................................................................. 29 6.14 Safety Representative..................................................................................................................30 6.15 Hazard Communication Programs..............................................................................................30 6.16 Emergencies................................................................................................................................ 30 6.17 Shop Drawings and Samples...................................................................................................... 31 i 6.18 Continuing the Work...................................................................................................................32 6.19 Contractor's General Warranty and Guarantee.......................................................................... 33 6.20 Indemnification........................................................................................................................... 33 PM 6.21 Delegation of Professional Design Services............................................................................... 34 Article 7 - Other Work at the Site...................................................................................................................35 7.01 Related Work at Site................................................................................................................... 35 7.02 Coordination................................................................................................................................35 7.03 Legal Relationships.....................................................................................................................36 i Article 8 - Owner's Responsibilities............................................................................................................... 36 8.01 Communications to Contractor................................................................................................... 36 8.02 Replacement of Engineer............................................................................................................36 8.03 Furnish Data................................................................................................................................36 8.04 Pay When Due.............................................................................................................................36 8.05 Lands and Easements; Reports and Tests...................................................................................36 8.06 Insurance...................................................................................................................................... 36 8.07 Change Orders.............................................................................................................................37 -� 8.08 Inspections, Tests, and Approvals..............................................................................................37 8.09 Limitations on Owner's Responsibilities...................................................................................37 8.10 Undisclosed Hazardous Environmental Condition....................................................................37 -` 8.11 Evidence of Financial Arrangements..........................................................................................37 8.12 Compliance with Safety Program...............................................................................................37 Article 9 - Engineer's Status During Construction......................................................................................... 37 9.01 Owner's Representative..............................................................................................................37 ., EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page ii 9.02 Visits to Site................................................................................................................................ 37 9.03 Project Representative.................................................................................................................38 9.04 Authorized Variations in Work..................................................................................................38 9.05 Rejecting Defective Work...........................................................................................................38 9.06 Shop Drawings, Change Orders and Payments..........................................................................39 9.07 Determinations for Unit Price Work..........................................................................................39 - 9.08 Decisions on Requirements of Contract Documents and Acceptability of Work ..................... 39 9.09 Limitations on Engineer's Authority and Responsibilities........................................................ 39 9.10 Compliance with Safety Program...............................................................................................40 Article 10 - Changes in the Work; Claims.....................................................................................................40 10.01 Authorized Changes in the Work............................................................................................... 40 10.02 Unauthorized Changes in the Work............................................................................................41 10.03 Execution of Change Orders.......................................................................................................41 10.04 Notification to Surety..................................................................................................................41 - 10.05 Claims..........................................................................................................................................41 Article 11 - Cost of the Work; Allowances; Unit Price Work....................................................................... 42 11.01 Cost of the Work......................................................................................................................... 42 11.02 Allowances.................................................................................................................................. 45 11.03 Unit Price Work.......................................................................................................................... 45 Article 12 - Change of Contract Price; Change of Contract Times...............................................................46 12.01 Change of Contract Price............................................................................................................ 46 12.02 Change of Contract Times 47 12.03 Delays.......................................................................................................................................... 47 Article 13 - Tests and Inspections; Correction, Removal or Acceptance of Defective Work.......................48 13.01 Notice of Defects.........................................................................................................................48 13.02 Access to Work........................................................................................................................... 48 13.03 Tests and Inspections.................................................................................................................. 49 13.04 Uncovering Work........................................................................................................................49 +„ 13.05 Owner May Stop the Work......................................................................................................... 50 13.06 Correction or Removal of Defective Work................................................................................ 50 13.07 Correction Period........................................................................................................................ 50 13.08 Acceptance of Defective Work...................................................................................................51 13.09 Owner May Correct Defective Work......................................................................................... 52 Article 14 - Payments to Contractor and Completion.................................................................................... 52 14.01 Schedule of Values...................................................................................................................... 52 14.02 Progress Payments...................................................................................................................... 52 .. 14.03 Contractor's Warranty of Title....................................................................................................55 14.04 Substantial Completion...............................................................................................................55 14.05 Partial Utilization........................................................................................................................ 56 Mkl 14.06 Final Inspection..................................................................................... ......................................57 14.07 Final Payment..............................................................................................................................57 14.08 Final Completion Delayed..........................................................................................................58 EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page Ill 14.09 Waiver of Claims........................................................................................................................ 58 Article 15 — Suspension of Work and Termination........................................................................................ 59 15.01 Owner May Suspend Work....................................................................................................... 59 15.02 Owner May Terminate for Cause............................................................................................... 59 15.03 Owner May Terminate For Convenience................................................................................... 60 15.04 Contractor May Stop Work or Terminate...................................................................................60 Article16 — Dispute Resolution...................................................................................................................... 61 16.01 Methods and Procedures.............................................................................................................61 Article17 — Miscellaneous.............................................................................................................................. 61 17.01 Giving Notice.............................................................................................................................. 61 17.02 Computation of Times................................................................................................................ 62 17.03 Cumulative Remedies................................................................................................................. 62 17.04 Survival of Obligations............................................................................................................... 62 17.05 Controlling Law.......................................................................................................................... 62 17.06 Headings......................................................................................................................................62 Fft !0. P% o. 4M EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page iv 12. Contract Documents —Those items so designated in the Agreement. Only printed or hard copies of the items listed in the Agreement are Contract Documents. Approved Shop Drawings, other Contractor submittals, and the reports and drawings of subsurface and physical conditions are not Contract Documents. 13. Contract Price —The moneys payable by Owner to Contractor for completion of the Work in accordance with the Contract Documents as stated in the Agreement (subject to the provisions of Paragraph 11.03 in the case of Unit Price Work). 14. Contract Times —The number of days or the dates stated in the Agreement to: (i) achieve _ Milestones, if any; (ii) achieve Substantial Completion; and (iii) complete the Work so that it is ready for final payment as evidenced by Engineer's written recommendation of final payment. ow 15. Contractor —The individual or entity with whom Owner has entered into the Agreement. 16. Cost of the Work —See Paragraph 11.01 for definition. 17. Drawings —That part of the Contract Documents prepared or approved by Engineer which Oft graphically shows the scope, extent, and character of the Work to be performed by Contractor. Shop Drawings and other Contractor submittals are not Drawings as so defined. 18. Effective Date of the Agreement —The date indicated in the Agreement on which it becomes effective, but if no such date is indicated, it means the date on which the Agreement is signed and delivered by the last of the two parties to sign and deliver. ,.. 19. Engineer —The individual or entity named as such in the Agreement. MW 20. Field Order —A written order issued by Engineer which requires minor changes in the Work but which does not involve a change in the Contract Price or the Contract Times. 21. General Requirements —Sections of Division 1 of the Specifications. 22. Hazardous Environmental Condition —The presence at the Site of Asbestos, PCBs, Petroleum, Hazardous Waste, or Radioactive Material in such quantities or circumstances that may present a substantial danger to persons or property exposed thereto. &. 23. Hazardous Waste —The term Hazardous Waste shall have the meaning provided in Section 1004 of the Solid Waste Disposal Act (42 USC Section 6903) as amended from time to time. 24. Laws and Regulations; Laws or Regulations —Any and all applicable laws, rules, regulations, ordinances, codes, and orders of any and all governmental bodies, agencies, authorities, and courts having jurisdiction. 25. Liens —Charges, security interests, or encumbrances upon Project funds, real property, or personal property. SM 26. Milestone —A principal event specified in the Contract Documents relating to an intermediate completion date or time prior to Substantial Completion of all the Work. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 2 of 62 d„ 27. Notice of Award —The written notice by Owner to the Successful Bidder stating that upon timely compliance by the Successful Bidder with the conditions precedent listed therein, Owner will sign and deliver the Agreement. 28. Notice to Proceed —A written notice given by Owner to Contractor fixing the date on which the Contract Times will commence to run and on which Contractor shall start to perform the ..� Work under the Contract Documents. 29. Owner —The individual or entity with whom Contractor has entered into the Agreement and ... for whom the Work is to be performed. 30. PCBs —Polychlorinated biphenyls. 31. Petroleum —Petroleum, including crude oil or any fraction thereof which is liquid at standard conditions of temperature and pressure (60 degrees Fahrenheit and 14.7 pounds per square .r inch absolute), such as oil, petroleum, fuel oil, oil sludge, oil refuse, gasoline, kerosene, and oil mixed with other non -Hazardous Waste and crude oils. aM 32. Progress Schedule —A schedule, prepared and maintained by Contractor, describing the sequence and duration of the activities comprising the Contractor's plan to accomplish the Work within the Contract Times. 33. Project —The total construction of which the Work to be performed under the Contract Documents may be the whole, or a part. 34. Project Manual —The bound documentary information prepared for bidding and constructing the Work. A listing of the contents of the Project Manual, which may be bound in one or more volumes, is contained in the table(s) of contents. 35. Radioactive Material —Source, special nuclear, or byproduct material as defined by the — Atomic Energy Act of 1954 (42 USC Section 2011 et seq.) as amended from time to time. 36. Resident Project Representative —The authorized representative of Engineer who may be assigned to the Site or any part thereof. 37. Samples —Physical examples of materials, equipment, or workmanship that are representative = of some portion of the Work and which establish the standards by which such portion of the Work will be judged. = 38. Schedule of Submittals —A schedule, prepared and maintained by Contractor, of required submittals and the time requirements to support scheduled performance of related construction activities. 39. Schedule of Values —A schedule, prepared and maintained by Contractor, allocating portions of the Contract Price to various portions of the Work and used as the basis for reviewing Contractor's Applications for Payment. dw EJCDC C-700 Standard General Conditions of the Construction Contract Copyright C 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 3 of 62 M 40. Shop Drawings —All drawings, diagrams, illustrations, schedules, and other data or information which are specifically prepared or assembled by or for Contractor and submitted by Contractor to illustrate some portion of the Work. 41. Site —Lands or areas indicated in the Contract Documents as being furnished by Owner upon which the Work is to be performed, including rights -of -way and easements for access thereto, and such other lands furnished by Owner which are designated for the use of Contractor. 42. Specifications —That part of the Contract Documents consisting of written requirements for materials, equipment, systems, standards and workmanship as applied to the Work, and T certain administrative requirements and procedural matters applicable thereto. 43. Subcontractor —An individual or entity having a direct contract with Contractor or with any other Subcontractor for the performance of a part of the Work at the Site. 44. Substantial Completion —The time at which the Work (or a specified part thereof) has r progressed to the point where, in the opinion of Engineer, the Work (or a specified part thereof) is sufficiently complete, in accordance with the Contract Documents, so that the Work (or a specified part thereof) can be utilized for the purposes for which it is intended. The terms "substantially complete" and "substantially completed" as applied to all or part of the Work refer to Substantial Completion thereof. 45. Successful Bidder —The Bidder submitting a responsive Bid to whom Owner makes an award. 46. Supplementary Conditions —That part of the Contract Documents which amends or supplements these General Conditions. 47. Supplier —A manufacturer, fabricator, supplier, distributor, materialman, or vendor having a direct contract with Contractor or with any Subcontractor to furnish materials or equipment to be incorporated in the Work by Contractor or Subcontractor. 48. Underground Facilities —All underground pipelines, conduits, ducts, cables, wires, manholes, vaults, tanks, tunnels, or other such facilities or attachments, and any encasements containing such facilities, including those that convey electricity, gases, steam, liquid petroleum products, telephone or other communications, cable television, water, wastewater, storm water, other liquids or chemicals, or traffic or other control systems. — 49. Unit Price Work —Work to be paid for on the basis of unit prices. 50. Work —The entire construction or the various separately identifiable parts thereof required to be provided under the Contract Documents. Work includes and is the result of performing or providing all labor, services, and documentation necessary to produce such construction, and — furnishing, installing, and incorporating all materials and equipment into such construction, all as required by the Contract Documents. 51. Work Change Directive —A written statement to Contractor issued on or after the Effective Date of the Agreement and signed by Owner and recommended by Engineer ordering an EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 4 of 62 M Mft addition, deletion, or revision in the Work, or responding to differing or unforeseen subsurface or physical conditions under which the Work is to be performed or to emergencies. A Work Change Directive will not change the Contract Price or the Contract Times but is evidence that the parties expect that the change ordered or documented by a Work Change Directive will be incorporated in a subsequently issued Change Order following negotiations by the parties as to its effect, if any, on the Contract Price or Contract Times. i 1.02 Terminology A. The words and terms discussed in Paragraph 1.02.13 through F are not defined but, when used in the Bidding Requirements or Contract Documents, have the indicated meaning. B. Intent of Certain Terms or Adjectives: i 1. The Contract Documents include the terms "as allowed," "as approved," "as ordered," "as directed" or terms of like effect or import to authorize an exercise of professional judgment by Engineer. In addition, the adjectives "reasonable," "suitable," "acceptable," "proper," "satisfactory," or adjectives of like effect or import are used to describe an action or determination of Engineer as to the Work. It is intended that such exercise of professional judgment, action, or determination will be solely to evaluate, in general, the Work for i compliance with the information in the Contract Documents and with the design concept of the Project as a functioning whole as shown or indicated in the Contract Documents (unless there is a specific statement indicating otherwise). The use of any such term or adjective is not intended to and shall not be effective to assign to Engineer any duty or authority to supervise or direct the performance of the Work, or any duty or authority to undertake _ responsibility contrary to the provisions of Paragraph 9.09 or any other provision of the Contract Documents. i Fft C. Day: 1. The word "day" means a calendar day of 24 hours measured from midnight to the next midnight. D. Defective: 1. The word "defective," when modifying the word "Work," refers to Work that is unsatisfactory, faulty, or deficient in that it: a. does not conform to the Contract Documents; or b. does not meet the requirements of any applicable inspection, reference standard, test, or approval referred to in the Contract Documents; or c. has been damaged prior to Engineer's recommendation of final payment (unless "" responsibility for the protection thereof has been assumed by Owner at Substantial Completion in accordance with Paragraph 14.04 or 14.05). ME EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 5 of 62 qM E. Furnish, Install, Perform, Provide: 1. The word "furnish," when used in connection with services, materials, or equipment, shall mean to supply and deliver said services, materials, or equipment to the Site (or some other specified location) ready for use or installation and in usable or operable condition. 2. The word "install," when used in connection with services, materials, or equipment, shall mean to put into use or place in final position said services, materials, or equipment complete and ready for intended use. 3. The words "perform" or "provide," when used in connection with services, materials, or equipment, shall mean to furnish and install said services, materials, or equipment complete and ready for intended use. 4. When "furnish," "install," "perform," or "provide" is not used in connection with services, materials, or equipment in a context clearly requiring an obligation of Contractor, "provide" is implied. F. Unless stated otherwise in the Contract Documents, words or phrases that have a well-known technical or construction industry or trade meaning are used in the Contract Documents in accordance with such recognized meaning. i ARTICLE 2 — PRELIMINARY MATTERS 2.01 Delivery of Bonds and Evidence of Insurance ,r A. When Contractor delivers the executed counterparts of the Agreement to Owner, Contractor shall also deliver to Owner such bonds as Contractor may be required to furnish. B. Evidence of Insurance: Before any Work at the Site is started, Contractor and Owner shall each deliver to the other, with copies to each additional insured identified in the Supplementary _ Conditions, certificates of insurance (and other evidence of insurance which either of them or any additional insured may reasonably request) which Contractor and Owner respectively are required to purchase and maintain in accordance with Article 5. 2.02 Copies of Documents A. Owner shall furnish to Contractor up to ten printed or hard copies of the Drawings and Project Manual. Additional copies will be furnished upon request at the cost of reproduction. 2.03 Commencement of Contract Times; Notice to Proceed A. The Contract Times will commence to run on the thirtieth day after the Effective Date of the _ Agreement or, if a Notice to Proceed is given, on the day indicated in the Notice to Proceed. A Notice to Proceed may be given at any time within 30 days after the Effective Date of the Agreement. In no event will the Contract Times commence to run later than the sixtieth day after _ the day of Bid opening or the thirtieth day after the Effective Date of the Agreement, whichever date is earlier. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 6 of 62 ,., 2.04 Starting the Work A. Contractor shall start to perform the Work on the date when the Contract Times commence to run. No Work shall be done at the Site prior to the date on which the Contract Times commence to run. 2.05 Before Starting Construction A. Preliminary Schedules: Within 10 days after the Effective Date of the Agreement (unless otherwise specified in the General Requirements), Contractor shall submit to Engineer for timely review: 1. a preliminary Progress Schedule indicating the times (numbers of days or dates) for starting and completing the various stages of the Work, including any Milestones specified in the Contract Documents; 2. a preliminary Schedule of Submittals; and 3. a preliminary Schedule of Values for all of the Work which includes quantities and prices of items which when added together equal the Contract Price and subdivides the Work into component parts in sufficient detail to serve as the basis for progress payments during performance of the Work. Such prices will include an appropriate amount of overhead and profit applicable to each item of Work. _ 2.06 Preconstruction Conference; Designation of Authorized Representatives A. Before any Work at the Site is started, a conference attended by Owner, Contractor, Engineer, and others as appropriate will be held to establish a working understanding among the parties as to the Work and to discuss the schedules referred to in Paragraph 2.05.A, procedures for handling Shop Drawings and other submittals, processing Applications for Payment, and maintaining required records. B. At this conference Owner and Contractor each shall designate, in writing, a specific individual to act as its authorized representative with respect to the services and responsibilities under the Contract. Such individuals shall have the authority to transmit instructions, receive information, render decisions relative to the Contract, and otherwise act on behalf of each respective party. 2.07 Initial Acceptance of Schedules A. At least 10 days before submission of the first Application for Payment a conference attended by Contractor, Engineer, and others as appropriate will be held to review for acceptability to Engineer as provided below the schedules submitted in accordance with Paragraph 2.05.A. �. Contractor shall have an additional 10 days to make corrections and adjustments and to complete and resubmit the schedules. No progress payment shall be made to Contractor until acceptable schedules are submitted to Engineer. 1. The Progress Schedule will be acceptable to Engineer if it provides an orderly progression of the Work to completion within the Contract Times. Such acceptance will not impose on FA EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 7 of 62 w Engineer responsibility for the Progress Schedule, for sequencing, scheduling, or progress of the Work, nor interfere with or relieve Contractor from Contractor's full responsibility therefor. 2. Contractor's Schedule of Submittals will be acceptable to Engineer if it provides a workable arrangement for reviewing and processing the required submittals. i 3. Contractor's Schedule of Values will be acceptable to Engineer as to form and substance if it provides a reasonable allocation of the Contract Price to component parts of the Work. i ARTICLE 3 — CONTRACT DOCUMENTS: INTENT, AMENDING, REUSE 3.01 Intent A. The Contract Documents are complementary; what is required by one is as binding as if required by all. B. It is the intent of the Contract Documents to describe a functionally complete project (or part thereof) to be constructed in accordance with the Contract Documents. Any labor, documentation, services, materials, or equipment that reasonably may be inferred from the Contract Documents or from prevailing custom or trade usage as being required to produce the indicated result will be provided whether or not specifically called for, at no additional cost to Owner. C. Clarifications and interpretations of the Contract Documents shall be issued by Engineer as provided in Article 9. 3.02 Reference Standards A. Standards, Specifications, Codes, Laws, and Regulations 1. Reference to standards, specifications, manuals, or codes of any technical society, organization, or association, or to Laws or Regulations, whether such reference be specific or by implication, shall mean the standard, specification, manual, code, or Laws or Regulations in effect at the time of opening of Bids (or on the Effective Date of the Agreement if there were no Bids), except as may be otherwise specifically stated in the Contract Documents. 2. No provision of any such standard, specification, manual, or code, or any instruction of a Supplier, shall be effective to change the duties or responsibilities of Owner, Contractor, or Engineer, or any of their subcontractors, consultants, agents, or employees, from those set forth in the Contract Documents. No such provision or instruction shall be effective to assign to Owner, Engineer, or any of their officers, directors, members, partners, employees, agents, consultants, or subcontractors, any duty or authority to supervise or direct the performance of the Work or any duty or authority to undertake responsibility inconsistent with the provisions of the Contract Documents. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright 3 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 8 of 62 M on 3.03 Reporting and Resolving Discrepancies A. Reporting Discrepancies: 1. Contractor's Review of Contract Documents Before Starting Work: Before undertaking each part of the Work, Contractor shall carefully study and compare the Contract Documents and check and verify pertinent figures therein and all applicable field measurements. Contractor shall promptly report in writing to Engineer any conflict, error, ambiguity, or discrepancy which Contractor discovers, or has actual knowledge of, and shall obtain a written interpretation or clarification from Engineer before proceeding with any Work affected thereby. 2. Contractor's Review of Contract Documents During Performance of Work: If, during the performance of the Work, Contractor discovers any conflict, error, ambiguity, or discrepancy within the Contract Documents, or between the Contract Documents and (a) any applicable Law or Regulation , (b) any standard, specification, manual, or code, or (c) any instruction of any Supplier, then Contractor shall promptly report it to Engineer in writing. Contractor shall not proceed with the Work affected thereby (except in an emergency as required by Paragraph 6.16.A) until an amendment or supplement to the Contract Documents has been issued by one of the methods indicated in Paragraph 3.04. 3. Contractor shall not be liable to Owner or Engineer for failure to report any conflict, error, ambiguity, or discrepancy in the Contract Documents unless Contractor had actual knowledge thereof. B. Resolving Discrepancies: 1. Except as may be otherwise specifically stated in the Contract Documents, the provisions of the Contract Documents shall take precedence in resolving any conflict, error, ambiguity, or discrepancy between the provisions of the Contract Documents and: a. the provisions of any standard, specification, manual, or code, or the instruction of any Supplier (whether or not specifically incorporated by reference in the Contract Ma Documents); or b. the provisions of any Laws or Regulations applicable to the performance of the Work (unless such an interpretation of the provisions of the Contract Documents would result in violation of such Law or Regulation). i 3.04 Amending and Supplementing Contract Documents A. The Contract Documents may be amended to provide for additions, deletions, and revisions in the Work or to modify the terms and conditions thereof by either a Change Order or a Work Change Directive. B. The requirements of the Contract Documents may be supplemented, and minor variations and deviations in the Work may be authorized, by one or more of the following ways: EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 9 of 62 1. A Field Order; 2. Engineer's approval of a Shop Drawing or Sample (subject to the provisions of Paragraph 6.17.D.3); or 3. Engineer's written interpretation or clarification. 3.05 Reuse of Documents A. Contractor and any Subcontractor or Supplier shall not: 1. have or acquire any title to or ownership rights in any of the Drawings, Specifications, or other documents (or copies of any thereof) prepared by or bearing the seal of Engineer or its consultants, including electronic media editions; or 2. reuse any such Drawings, Specifications, other documents, or copies thereof on extensions of the Project or any other project without written consent of Owner and Engineer and specific written verification or adaptation by Engineer. B. The prohibitions of this Paragraph 3.05 will survive final payment, or termination of the Contract. Nothing herein shall preclude Contractor from retaining copies of the Contract Documents for record purposes. 3.06 Electronic Data A. Unless otherwise stated in the Supplementary Conditions, the data furnished by Owner or Engineer to Contractor, or by Contractor to Owner or Engineer, that may be relied upon are limited to the printed copies (also known as hard copies). Files in electronic media format of text, data, graphics, or other types are furnished only for the convenience of the receiving party. Any conclusion or information obtained or derived from such electronic files will be at the user's sole risk. If there is a discrepancy between the electronic files and the hard copies, the hard copies govern. B. Because data stored in electronic media format can deteriorate or be modified inadvertently or _ otherwise without authorization of the data's creator, the party receiving electronic files agrees that it will perform acceptance tests or procedures within 60 days, after which the receiving party shall be deemed to have accepted the data thus transferred. Any errors detected within the 60-day .� acceptance period will be corrected by the transferring party. C. When transferring documents in electronic media format, the transferring party makes no representations as to long term compatibility, usability, or readability of documents resulting from the use of software application packages, operating systems, or computer hardware differing from those used by the data's creator. — EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 10 of 62 .� ARTICLE 4 — AVAILABILITY OF LANDS; SUBSURFACE AND PHYSICAL CONDITIONS; HAZARDOUS ENVIRONMENTAL CONDITIONS; REFERENCE POINTS 4.01 Availability of Lands A. Owner shall furnish the Site. Owner shall notify Contractor of any encumbrances or restrictions not of general application but specifically related to use of the Site with which Contractor must comply in performing the Work. Owner will obtain in a timely manner and pay for easements for permanent structures or permanent changes in existing facilities. If Contractor and Owner are unable to agree on entitlement to or on the amount or extent, if any, of any adjustment in the Contract Price or Contract Times, or both, as a result of any delay in Owner's furnishing the Site or a part thereof, Contractor may make a Claim therefor as provided in Paragraph 10.05. B. Upon reasonable written request, Owner shall furnish Contractor with a current statement of record legal title and legal description of the lands upon which the Work is to be performed and Owner's interest therein as necessary for giving notice of or filing a mechanic's or construction lien against such lands in accordance with applicable Laws and Regulations. C. Contractor shall provide for all additional lands and access thereto that may be required for temporary construction facilities or storage of materials and equipment. ma 4.02 Subsurface and Physical Conditions A. Reports and Drawings: The Supplementary Conditions identify: i 1. those reports known to Owner of explorations and tests of subsurface conditions at or contiguous to the Site; and 2. those drawings known to Owner of physical conditions relating to existing surface or subsurface structures at the Site (except Underground Facilities). B. Limited Reliance by Contractor on Technical Data Authorized: Contractor may rely upon the accuracy of the "technical data" contained in such reports and drawings, but such reports and •� drawings are not Contract Documents. Such "technical data" is identified in the Supplementary Conditions. Except for such reliance on such "technical data," Contractor may not rely upon or make any claim against Owner or Engineer, or any of their officers, directors, members, partners, employees, agents, consultants, or subcontractors with respect to: 1. the completeness of such reports and drawings for Contractor's purposes, including, but not limited to, any aspects of the means, methods, techniques, sequences, and procedures of construction to be employed by Contractor, and safety precautions and programs incident thereto; or 2. other data, interpretations, opinions, and information contained in such reports or shown or indicated in such drawings; or 3. any Contractor interpretation of or conclusion drawn from any "technical data" or any such other data, interpretations, opinions, or information. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 11 of 62 4.03 Differing Subsurface or Physical Conditions A. Notice: If Contractor believes that any subsurface or physical condition that is uncovered or revealed either: 1. is of such a nature as to establish that any "technical data" on which Contractor is entitled to rely as provided in Paragraph 4.02 is materially inaccurate; or 2. is of such a nature as to require a change in the Contract Documents; or 3. differs materially from that shown or indicated in the Contract Documents; or 4. is of an unusual nature, and differs materially from conditions ordinarily encountered and generally recognized as inherent in work of the character provided for in the Contract Documents; then Contractor shall, promptly after becoming aware thereof and before further disturbing the subsurface or physical conditions or performing any Work in connection therewith (except in an emergency as required by Paragraph 6.16.A), notify Owner and Engineer in writing about such condition. Contractor shall not further disturb such condition or perform any Work in connection therewith (except as aforesaid) until receipt of written order to do so. B. Engineer's Review: After receipt of written notice as required by Paragraph 4.03.A, Engineer will promptly review the pertinent condition, determine the necessity of Owner's obtaining additional exploration or tests with respect thereto, and advise Owner in writing (with a copy to Contractor) of Engineer's findings and conclusions. C. Possible Price and Times Adjustments: 1. The Contract Price or the Contract Times, or both, will be equitably adjusted to the extent that the existence of such differing subsurface or physical condition causes an increase or F decrease in Contractor's cost of, or time required for, performance of the Work; subject, however, to the following: a. such condition must meet any one or more of the categories described in Paragraph 4.03.A; and b. with respect to Work that is paid for on a unit price basis, any adjustment in Contract Price will be subject to the provisions of Paragraphs 9.07 and 11.03. 2. Contractor shall not be entitled to any adjustment in the Contract Price or Contract Times if a. Contractor knew of the existence of such conditions at the time Contractor made a final commitment to Owner with respect to Contract Price and Contract Times by the submission of a Bid or becoming bound under a negotiated contract; or b. the existence of such condition could reasonably have been discovered or revealed as a result of any examination, investigation, exploration, test, or study of the Site and EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 12 of 62 M i contiguous areas required by the Bidding Requirements or Contract Documents to be conducted by or for Contractor prior to Contractor's making such final commitment; or AM c. Contractor failed to give the written notice as required by Paragraph 4.03.A. 3. If Owner and Contractor are unable to agree on entitlement to or on the amount or extent, if r, any, of any adjustment in the Contract Price or Contract Times, or both, a Claim may be made therefor as provided in Paragraph 10.05. However, neither Owner or Engineer, or any of their officers, directors, members, partners, employees, agents, consultants, or subcontractors shall be liable to Contractor for any claims, costs, losses, or damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) sustained by Contractor on or in connection with any other project or anticipated project. 4.04 Underground Facilities A. Shown or Indicated: The information and data shown or indicated in the Contract Documents with respect to existing Underground Facilities at or contiguous to the Site is based on information and data furnished to Owner or Engineer by the owners of such Underground Facilities, including Owner, or by others. Unless it is otherwise expressly provided in the Supplementary Conditions: i 1. Owner and Engineer shall not be responsible for the accuracy or completeness of any such information or data provided by others; and _ 2. the cost of all of the following will be included in the Contract Price, and Contractor shall have full responsibility for: qM a. reviewing and checking all such information and data; an b. locating all Underground Facilities shown or indicated in the Contract Documents; c. coordination of the Work with the owners of such Underground Facilities, including #, Owner, during construction; and d. the safety and protection of all such Underground Facilities and repairing any damage y. thereto resulting from the Work. B. Not Shown or Indicated: 1. If an Underground Facility is uncovered or revealed at or contiguous to the Site which was not shown or indicated, or not shown or indicated with reasonable accuracy in the Contract Documents, Contractor shall, promptly after becoming aware thereof and before further disturbing conditions affected thereby or performing any Work in connection therewith (except in an emergency as required by Paragraph 6.16.A), identify the owner of such *� Underground Facility and give written notice to that owner and to Owner and Engineer. Engineer will promptly review the Underground Facility and determine the extent, if any, to which a change is required in the Contract Documents to reflect and document the R EJCDC C-700 Standard General Conditions of the Construction Contract -- Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 13 of 62 consequences of the existence or location of the Underground Facility. During such time, Contractor shall be responsible for the safety and protection of such Underground Facility. 2. If Engineer concludes that a change in the Contract Documents is required, a Work Change Directive or a Change Order will be issued to reflect and document such consequences. An equitable adjustment shall be made in the Contract Price or Contract Times, or both, to the extent that they are attributable to the existence or location of any Underground Facility that t was not shown or indicated or not shown or indicated with reasonable accuracy in the Contract Documents and that Contractor did not know of and could not reasonably have been expected to be aware of or to have anticipated. If Owner and Contractor are unable to agree on entitlement to or on the amount or extent, if any, of any such adjustment in Contract Price or Contract Times, Owner or Contractor may make a Claim therefor as provided in Paragraph 10.05. 4.05 Reference Points A. Owner shall provide engineering surveys to establish reference points for construction which in Engineer's judgment are necessary to enable Contractor to proceed with the Work. Contractor shall be responsible for laying out the Work, shall protect and preserve the established reference points and property monuments, and shall make no changes or relocations without the prior written approval of Owner. Contractor shall report to Engineer whenever any reference point or property monument is lost or destroyed or requires relocation because of necessary changes in grades or locations, and shall be responsible for the accurate replacement or relocation of such reference points or property monuments by professionally qualified personnel. 4.06 Hazardous Environmental Condition at Site A. Reports and Drawings: The Supplementary Conditions identify those reports and drawings known to Owner relating to Hazardous Environmental Conditions that have been identified at the Site. B. Limited Reliance by Contractor on Technical Data Authorized.• Contractor may rely upon the accuracy of the "technical data" contained in such reports and drawings, but such reports and drawings are not Contract Documents. Such "technical data" is identified in the Supplementary Conditions. Except for such reliance on such "technical data," Contractor may not rely upon or make any claim against Owner or Engineer, or any of their officers, directors, members, partners, employees, agents, consultants, or subcontractors with respect to: I. the completeness of such reports and drawings for Contractor's purposes, including, but not limited to, any aspects of the means, methods, techniques, sequences and procedures of construction to be employed by Contractor and safety precautions and programs incident thereto; or 2. other data, interpretations, opinions and information contained in such reports or shown or indicated in such drawings; or 3. any Contractor interpretation of or conclusion drawn from any "technical data" or any such other data, interpretations, opinions or information. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 14 of 62 C. Contractor shall not be responsible for any Hazardous Environmental Condition uncovered or revealed at the Site which was not shown or indicated in Drawings or Specifications or identified in the Contract Documents to be within the scope of the Work. Contractor shall be responsible for a Hazardous Environmental Condition created with any materials brought to the Site by Contractor, Subcontractors, Suppliers, or anyone else for whom Contractor is responsible. D. If Contractor encounters a Hazardous Environmental Condition or if Contractor or anyone for whom Contractor is responsible creates a Hazardous Environmental Condition, Contractor shall immediately: (i) secure or otherwise isolate such condition; (ii) stop all Work in connection with such condition and in any area affected thereby (except in an emergency as required by Paragraph 6.16.A); and (iii) notify Owner and Engineer (and promptly thereafter confirm such notice in writing). Owner shall promptly consult with Engineer concerning the necessity for Owner to retain a qualified expert to evaluate such condition or take corrective action, if any. Promptly after consulting with Engineer, Owner shall take such actions as are necessary to permit Owner to timely obtain required permits and provide Contractor the written notice required by Paragraph 4.06.E. E. Contractor shall not be required to resume Work in connection with such condition or in any ` affected area until after Owner has obtained any required permits related thereto and delivered written notice to Contractor: (i) specifying that such condition and any affected area is or has been rendered safe for the resumption of Work; or (ii) specifying any special conditions under which such Work may be resumed safely. If Owner and Contractor cannot agree as to entitlement to or on the amount or extent, if any, of any adjustment in Contract Price or Contract Times, or both, as a result of such Work stoppage or such special conditions under which Work is agreed to be resumed by Contractor, either party may make a Claim therefor as provided in Paragraph 10.05. F. If after receipt of such written notice Contractor does not agree to resume such Work based on a - reasonable belief it is unsafe, or does not agree to resume such Work under such special conditions, then Owner may order the portion of the Work that is in the area affected by such condition to be deleted from the Work. If Owner and Contractor cannot agree as to entitlement to or on the amount or extent, if any, of an adjustment in Contract Price or Contract Times as a result of deleting such portion of the Work, then either party may make a Claim therefor as provided in Paragraph 10.05. Owner may have such deleted portion of the Work performed by Owner's own forces or others in accordance with Article 7. G. To the fullest extent permitted by Laws and Regulations, Owner shall indemnify and hold harmless Contractor, Subcontractors, and Engineer, and the officers, directors, members, -� partners, employees, agents, consultants, and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other ` dispute resolution costs) arising out of or relating to a Hazardous Environmental Condition, provided that such Hazardous Environmental Condition: (i) was not shown or indicated in the Drawings or Specifications or identified in the Contract Documents to be included within the scope of the Work, and (ii) was not created by Contractor or by anyone for whom Contractor is responsible. Nothing in this Paragraph 4.06.G shall obligate Owner to indemnify any individual or entity from and against the consequences of that individual's or entity's own negligence. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 15 of 62 H. To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless Owner and Engineer, and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to a Hazardous Environmental Condition created by Contractor or by anyone for whom Contractor is responsible. Nothing in this Paragraph 4.06.1-1 shall obligate Contractor to indemnify any individual or entity from and against the consequences of that individual's or entity's own negligence. I. The provisions of Paragraphs 4.02, 4.03, and 4.04 do not apply to a Hazardous Environmental Condition uncovered or revealed at the Site. ARTICLE 5 — BONDS AND INSURANCE 5.01 Performance, Payment, and Other Bonds A. Contractor shall furnish performance and payment bonds, each in an amount at least equal to the Contract Price as security for the faithful performance and payment of all of Contractor's ., obligations under the Contract Documents. These bonds shall remain in effect until one year after the date when final payment becomes due or until completion of the correction period specified in Paragraph 13.07, whichever is later, except as provided otherwise by Laws or Regulations or by the Contract Documents. Contractor shall also furnish such other bonds as are required by the Contract Documents. B. All bonds shall be in the form prescribed by the Contract Documents except as provided otherwise by Laws or Regulations, and shall be executed by such sureties as are named in the list of "Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsuring Companies" as published in Circular 570 (amended) by the Financial Management Service, Surety Bond Branch, U.S. Department of the Treasury. All bonds signed by an agent or attorney -in -fact must be accompanied by a certified copy of that individual's — authority to bind the surety. The evidence of authority shall show that it is effective on the date the agent or attorney -in -fact signed each bond. C. If the surety on any bond furnished by Contractor is declared bankrupt or becomes insolvent or its right to do business is terminated in any state where any part of the Project is located or it ceases to meet the requirements of Paragraph 5.01.13, Contractor shall promptly notify Owner and Engineer and shall, within 20 days after the event giving rise to such notification, provide another bond and surety, both of which shall comply with the requirements of Paragraphs 5.01.13 and 5.02. 5.02 Licensed Sureties and Insurers A. All bonds and insurance required by the Contract Documents to be purchased and maintained by Owner or Contractor shall be obtained from surety or insurance companies that are duly licensed or authorized in the jurisdiction in which the Project is located to issue bonds or insurance policies for the limits and coverages so required. Such surety and insurance companies shall also EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 16 of 62 meet such additional requirements and qualifications as may be provided in the Supplementary Conditions. 5.03 Certificates of Insurance A. Contractor shall deliver to Owner, with copies to each additional insured and loss payee identified in the Supplementary Conditions, certificates of insurance (and other evidence of insurance requested by Owner or any other additional insured) which Contractor is required to purchase and maintain. B. Owner shall deliver to Contractor, with copies to each additional insured and loss payee identified in the Supplementary Conditions, certificates of insurance (and other evidence of �. insurance requested by Contractor or any other additional insured) which Owner is required to purchase and maintain. C. Failure of Owner to demand such certificates or other evidence of Contractor's full compliance with these insurance requirements or failure of Owner to identify a deficiency in compliance from the evidence provided shall not be construed as a waiver of Contractor's obligation to maintain such insurance. D. Owner does not represent that insurance coverage and limits established in this Contract necessarily will be adequate to protect Contractor. E. The insurance and insurance limits required herein shall not be deemed as a limitation on Contractor's liability under the indemnities granted to Owner in the Contract Documents. 5.04 Contractor's Insurance A. Contractor shall purchase and maintain such insurance as is appropriate for the Work being performed and as will provide protection from claims set forth below which may arise out of or result from Contractor's performance of the Work and Contractor's other obligations under the Contract Documents, whether it is to be performed by Contractor, any Subcontractor or Supplier, or by anyone directly or indirectly employed by any of them to perform any of the Work, or by anyone for whose acts any of them may be liable: 1. claims under workers' compensation, disability benefits, and other similar employee benefit acts; 2. claims for damages because of bodily injury, occupational sickness or disease, or death of -- Contractor's employees; 3. claims for damages because of bodily injury, sickness or disease, or death of any person other than Contractor's employees; 4. claims for damages insured by reasonably available personal injury liability coverage which are sustained: EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 17 of 62 PM a. by any person as a result of an offense directly or indirectly related to the employment of such person by Contractor, or b. by any other person for any other reason; M 5. claims for damages, other than to the Work itself, because of injury to or destruction of tangible property wherever located, including loss of use resulting therefrom; and AM 6. claims for damages because of bodily injury or death of any person or property damage arising out of the ownership, maintenance or use of any motor vehicle. B. The policies of insurance required by this Paragraph 5.04 shall: 1. with respect to insurance required by Paragraphs 5.04.A.3 through 5.04.A.6 inclusive, be +' written on an occurrence basis, include as additional insureds (subject to any customary exclusion regarding professional liability) Owner and Engineer, and any other individuals or entities identified in the Supplementary Conditions, all of whom shall be listed as additional insureds, and include coverage for the respective officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of all such additional insureds, and the insurance afforded to these additional insureds shall provide primary coverage for all claims covered thereby; 2. include at least the specific coverages and be written for not less than the limits of liability provided in the Supplementary Conditions or required by Laws or Regulations, whichever is greater; 3. include contractual liability insurance covering Contractor's indemnity obligations under Paragraphs 6.11 and 6.20; PM 4. contain a provision or endorsement that the coverage afforded will not be canceled, materially changed or renewal refused until at least 30 days prior written notice has been given to Owner and Contractor and to each other additional insured identified in the Supplementary Conditions to whom a certificate of insurance has been issued (and the certificates of insurance furnished by the Contractor pursuant to Paragraph 5.03 will so provide); 5. remain in effect at least until final payment and at all times thereafter when Contractor may be correcting, removing, or replacing defective Work in accordance with Paragraph 13.07; ... and 6. include completed operations coverage: a. Such insurance shall remain in effect for two years after final payment. b. Contractor shall furnish Owner and each other additional insured identified in the Supplementary Conditions, to whom a certificate of insurance has been issued, evidence satisfactory to Owner and any such additional insured of continuation of such insurance at oft final payment and one year thereafter. Mok EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 18 of 62 a" �. 5.05 Owner's Liability Insurance A. In addition to the insurance required to be provided by Contractor under Paragraph 5.04, Owner, at Owner's option, may purchase and maintain at Owner's expense Owner's own liability insurance as will protect Owner against claims which may arise from operations under the Contract Documents. 5.06 Property Insurance A. Unless otherwise provided in the Supplementary Conditions, Owner shall purchase and maintain property insurance upon the Work at the Site in the amount of the full replacement cost thereof (subject to such deductible amounts as may be provided in the Supplementary Conditions or required by Laws and Regulations). This insurance shall: 1. include the interests of Owner, Contractor, Subcontractors, and Engineer, and any other -- individuals or entities identified in the Supplementary Conditions, and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them, each of whom is deemed to have an insurable interest and shall be listed as a loss payee; 2. be written on a Builder's Risk "all-risk" policy form that shall at least include insurance for physical loss or damage to the Work, temporary buildings, falsework, and materials and equipment in transit, and shall insure against at least the following perils or causes of loss: fire, lightning, extended coverage, theft, vandalism and malicious mischief, earthquake, collapse, debris removal, demolition occasioned by enforcement of Laws and Regulations, water damage (other than that caused by flood), and such other perils or causes of loss as may be specifically required by the Supplementary Conditions. 3. include expenses incurred in the repair or replacement of any insured property (including but not limited to fees and charges of engineers and architects); 4. cover materials and equipment stored at the Site or at another location that was agreed to in writing by Owner prior to being incorporated in the Work, provided that such materials and equipment have been included in an Application for Payment recommended by Engineer; 5. allow for partial utilization of the Work by Owner; 6. include testing and startup; and 7. be maintained in effect until final payment is made unless otherwise agreed to in writing by Owner, Contractor, and Engineer with 30 days written notice to each other loss payee to whom a certificate of insurance has been issued. B. Owner shall purchase and maintain such equipment breakdown insurance or additional property insurance as may be required by the Supplementary Conditions or Laws and Regulations which will include the interests of Owner, Contractor, Subcontractors, and Engineer, and any other individuals or entities identified in the Supplementary Conditions, and the officers, directors, EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 19 of 62 members, partners, employees, agents, consultants and subcontractors of each and any of them, each of whom is deemed to have an insurable interest and shall be listed as a loss payee. C. All the policies of insurance (and the certificates or other evidence thereof) required to be purchased and maintained in accordance with this Paragraph 5.06 will contain a provision or endorsement that the coverage afforded will not be canceled or materially changed or renewal refused until at least 30 days prior written notice has been given to Owner and Contractor and to each other loss payee to whom a certificate of insurance has been issued and will contain waiver provisions in accordance with Paragraph 5.07. D. Owner shall not be responsible for purchasing and maintaining any property insurance specified in this Paragraph 5.06 to protect the interests of Contractor, Subcontractors, or others in the Work to the extent of any deductible amounts that are identified in the Supplementary Conditions. The risk of loss within such identified deductible amount will be borne by Contractor, Subcontractors, or others suffering any such loss, and if any of them wishes property insurance coverage within the limits of such amounts, each may purchase and maintain it at the purchaser's own expense. — E. If Contractor requests in writing that other special insurance be included in the property insurance policies provided under this Paragraph 5.06, Owner shall, if possible, include such insurance, and the cost thereof will be charged to Contractor by appropriate Change Order. Prior to commencement of the Work at the Site, Owner shall in writing advise Contractor whether or not such other insurance has been procured by Owner. 5.07 Waiver of Rights A. Owner and Contractor intend that all policies purchased in accordance with Paragraph 5.06 will protect Owner, Contractor, Subcontractors, and Engineer, and all other individuals or entities identified in the Supplementary Conditions as loss payees (and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them) in such policies and will provide primary coverage for all losses and damages caused by the perils or causes of loss covered thereby. All such policies shall contain provisions to the effect that in the event of payment of any loss or damage the insurers will have no rights of recovery against any of the insureds or loss payees thereunder. Owner and Contractor waive all rights against each other and their respective officers, directors, members, partners, employees, agents, consultants and i~ subcontractors of each and any of them for all losses and damages caused by, arising out of or resulting from any of the perils or causes of loss covered by such policies and any other property insurance applicable to the Work; and, in addition, waive all such rights against Subcontractors and Engineer, and all other individuals or entities identified in the Supplementary Conditions as loss payees (and the officers, directors, members, partners, employees, agents, consultants, and jm, subcontractors of each and any of them) under such policies for losses and damages so caused. None of the above waivers shall extend to the rights that any party making such waiver may have to the proceeds of insurance held by Owner as trustee or otherwise payable under any policy so �. issued. B. Owner waives all rights against Contractor, Subcontractors, and Engineer, and the officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them for: EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 20 of 62 1. loss due to business interruption, loss of use, or other consequential loss extending beyond direct physical loss or damage to Owner's property or the Work caused by, arising out of, or resulting from fire or other perils whether or not insured by Owner; and 2. loss or damage to the completed Project or part thereof caused by, arising out of, or resulting from fire or other insured peril or cause of loss covered by any property insurance maintained on the completed Project or part thereof by Owner during partial utilization pursuant to Paragraph 14.05, after Substantial Completion pursuant to Paragraph 14.04, or after final payment pursuant to Paragraph 14.07. C. Any insurance policy maintained by Owner covering any loss, damage or consequential loss referred to in Paragraph 5.07.13 shall contain provisions to the effect that in the event of payment of any such loss, damage, or consequential loss, the insurers will have no rights of recovery against Contractor, Subcontractors, or Engineer, and the officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them. 5.08 Receipt and Application of Insurance Proceeds A. Any insured loss under the policies of insurance required by Paragraph 5.06 will be adjusted with Owner and made payable to Owner as fiduciary for the loss payees, as their interests may appear, subject to the requirements of any applicable mortgage clause and of Paragraph 5.08.13. Owner shall deposit in a separate account any money so received and shall distribute it in accordance with such agreement as the parties in interest may reach. If no other special agreement is reached, the damaged Work shall be repaired or replaced, the moneys so received applied on account thereof, and the Work and the cost thereof covered by an appropriate Change Order. B. Owner as fiduciary shall have power to adjust and settle any loss with the insurers unless one of the parties in interest shall object in writing within 15 days after the occurrence of loss to Owner's exercise of this power. If such objection be made, Owner as fiduciary shall make settlement with the insurers in accordance with such agreement as the parties in interest may reach. If no such agreement among the parties in interest is reached, Owner as fiduciary shall adjust and settle the loss with the insurers and, if required in writing by any party in interest, Owner as fiduciary shall give bond for the proper performance of such duties. 5.09 Acceptance of Bonds and Insurance; Option to Replace '- A. If either Owner or Contractor has any objection to the coverage afforded by or other provisions of the bonds or insurance required to be purchased and maintained by the other party in accordance with Article 5 on the basis of non-conformance with the Contract Documents, the objecting party shall so notify the other party in writing within 10 days after receipt of the certificates (or other evidence requested) required by Paragraph 2.01.13. Owner and Contractor shall each provide to the other such additional information in respect of insurance provided as the other may reasonably request. If either party does not purchase or maintain all of the bonds and insurance required of such party by the Contract Documents, such party shall notify the other party in writing of such failure to purchase prior to the start of the Work, or of such failure to maintain prior to any change in the required coverage. Without prejudice to any other right or remedy, the other party may elect to obtain equivalent bonds or insurance to protect such other party's EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 21 of 62 PM interests at the expense of the party who was required to provide such coverage, and a Change Order shall be issued to adjust the Contract Price accordingly. 5.10 Partial Utilization, Acknowledgment of Property Insurer A. If Owner fords it necessary to occupy or use a portion or portions of the Work prior to Substantial Completion of all the Work as provided in Paragraph 14.05, no such use or occupancy shall , commence before the insurers providing the property insurance pursuant to Paragraph 5.06 have acknowledged notice thereof and in writing effected any changes in coverage necessitated thereby. The insurers providing the property insurance shall consent by endorsement on the policy or policies, but the property insurance shall not be canceled or permitted to lapse on account of any such partial use or occupancy. ARTICLE 6 — CONTRACTOR'S RESPONSIBILITIES 6.01 Supervision and Superintendence A. Contractor shall supervise, inspect, and direct the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with the Contract Documents. Contractor shall be solely responsible for the means, methods, techniques, sequences, and procedures of construction. Contractor shall not be responsible for the negligence of Owner or Engineer in the design or specification of a specific means, method, technique, sequence, or procedure of construction which is shown or indicated in and expressly required by the Contract Documents. B. At all times during the progress of the Work, Contractor shall assign a competent resident superintendent who shall not be replaced without written notice to Owner and Engineer except under extraordinary circumstances. 6.02 Labor; Working Hours A. Contractor shall provide competent, suitably qualified personnel to survey and lay out the Work and perform construction as required by the Contract Documents. Contractor shall at all times maintain good discipline and order at the Site. B. Except as otherwise required for the safety or protection of persons or the Work or property at the Site or adjacent thereto, and except as otherwise stated in the Contract Documents, all Work at •� the Site shall be performed during regular working hours. Contractor will not permit the performance of Work on a Saturday, Sunday, or any legal holiday without Owner's written consent (which will not be unreasonably withheld) given after prior written notice to Engineer. 6.03 Services, Materials, and Equipment A. Unless otherwise specified in the Contract Documents, Contractor shall provide and assume full responsibility for all services, materials, equipment, labor, transportation, construction equipment and machinery, tools, appliances, fuel, power, light, heat, telephone, water, sanitary facilities, temporary facilities, and all other facilities and incidentals necessary for the performance, testing, start-up, and completion of the Work. w EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 22 of 62 ai B. All materials and equipment incorporated into the Work shall be as specified or, if not specified, shall be of good quality and new, except as otherwise provided in the Contract Documents. All special warranties and guarantees required by the Specifications shall expressly run to the benefit of Owner. If required by Engineer, Contractor shall furnish satisfactory evidence (including reports of required tests) as to the source, kind, and quality of materials and equipment. C. All materials and equipment shall be stored, applied, installed, connected, erected, protected, used, cleaned, and conditioned in accordance with instructions of the applicable Supplier, except as otherwise may be provided in the Contract Documents. 6.04 Progress Schedule A. Contractor shall adhere to the Progress Schedule established in accordance with Paragraph 2.07 as it may be adjusted from time to time as provided below. 1. Contractor shall submit to Engineer for acceptance (to the extent indicated in Paragraph 2.07) proposed adjustments in the Progress Schedule that will not result in changing the Contract Times. Such adjustments will comply with any provisions of the General Requirements applicable thereto. 2. Proposed adjustments in the Progress Schedule that will change the Contract Times shall be submitted in accordance with the requirements of Article 12. Adjustments in Contract Times may only be made by a Change Order. -- 6.05 Substitutes and "Or -Equals " A. Whenever an item of material or equipment is specified or described in the Contract Documents by using the name of a proprietary item or the name of a particular Supplier, the specification or description is intended to establish the type, function, appearance, and quality required. Unless the specification or description contains or is followed by words reading that no like, equivalent, - or "or -equal" item or no substitution is permitted, other items of material or equipment or material or equipment of other Suppliers may be submitted to Engineer for review under the circumstances described below. 1. "Or -Equal" Items: If in Engineer's sole discretion an item of material or equipment proposed by Contractor is functionally equal to that named and sufficiently similar so that no change in related Work will be required, it may be considered by Engineer as an "or -equal" item, in which case review and approval of the proposed item may, in Engineer's sole discretion, be accomplished without compliance with some or all of the requirements for approval of proposed substitute items. For the purposes of this Paragraph 6.05.A.1, a proposed item of material or equipment will be considered functionally equal to an item so named if " a. in the exercise of reasonable judgment Engineer determines that: 1) it is at least equal in materials of construction, quality, durability, appearance, strength, and design characteristics; EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 23 of 62 2) it will reliably perform at least equally well the function and achieve the results imposed by the design concept of the completed Project as a functioning whole; and 3) it has a proven record of performance and availability of responsive service. b. Contractor certifies that, if approved and incorporated into the Work: 1) there will be no increase in cost to the Owner or increase in Contract Times; and 2) it will conform substantially to the detailed requirements of the item named in the Contract Documents. 2. Substitute Items: a. If in Engineer's sole discretion an item of material or equipment proposed by Contractor does not qualify as an "or -equal" item under Paragraph 6.05.A.1, it will be considered a proposed substitute item. b. Contractor shall submit sufficient information as provided below to allow Engineer to determine if the item of material or equipment proposed is essentially equivalent to that an named and an acceptable substitute therefor. Requests for review of proposed substitute items of material or equipment will not be accepted by Engineer from anyone other than On Contractor. c. The requirements for review by Engineer will be as set forth in Paragraph 6.05.A.2.d, as _ supplemented by the General Requirements, and as Engineer may decide is appropriate under the circumstances. d. Contractor shall make written application to Engineer for review of a proposed substitute item of material or equipment that Contractor seeks to furnish or use. The application: 1) shall certify that the proposed substitute item will: a) perform adequately the functions and achieve the results called for by the general design, b) be similar in substance to that specified, and c) be suited to the same use as that specified; 2) will state: a) the extent, if any, to which the use of the proposed substitute item will prejudice Contractor's achievement of Substantial Completion on time, b) whether use of the proposed substitute item in the Work will require a change in any of the Contract Documents (or in the provisions of any other direct contract with Owner for other work on the Project) to adapt the design to the proposed substitute item, and EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 24 of 62 c) whether incorporation or use of the proposed substitute item in connection with the Work is subject to payment of any license fee or royalty; �. 3) will identify: a) all variations of the proposed substitute item from that specified, and MP b) available engineering, sales, maintenance, repair, and replacement services; and _ 4) shall contain an itemized estimate of all costs or credits that will result directly or indirectly from use of such substitute item, including costs of redesign and claims of other contractors affected by any resulting change. MP B. Substitute Construction Methods or Procedures: If a specific means, method, technique, sequence, or procedure of construction is expressly required by the Contract Documents, .� Contractor may furnish or utilize a substitute means, method, technique, sequence, or procedure of construction approved by Engineer. Contractor shall submit sufficient information to allow Engineer, in Engineer's sole discretion, to determine that the substitute proposed is equivalent to that expressly called for by the Contract Documents. The requirements for review by Engineer will be similar to those provided in Paragraph 6.05.A.2. Mq C. Engineer's Evaluation: Engineer will be allowed a reasonable time within which to evaluate each proposal or submittal made pursuant to Paragraphs 6.05.A and 6.05.13. Engineer may require Contractor to furnish additional data about the proposed substitute item. Engineer will be the sole judge of acceptability. No "or equal" or substitute will be ordered, installed or utilized until _ Engineer's review is complete, which will be evidenced by a Change Order in the case of a substitute and an approved Shop Drawing for an "or equal." Engineer will advise Contractor in i writing of any negative determination. D. Special Guarantee: Owner may require Contractor to furnish at Contractor's expense a special performance guarantee or other surety with respect to any substitute. E. Engineer's Cost Reimbursement: Engineer will record Engineer's costs in evaluating a substitute proposed or submitted by Contractor pursuant to Paragraphs 6.05.A.2 and 6.05.13. Whether or not Engineer approves a substitute so proposed or submitted by Contractor, Contractor shall reimburse Owner for the reasonable charges of Engineer for evaluating each such proposed substitute. Contractor shall also reimburse Owner for the reasonable charges of Engineer for making changes in the Contract Documents (or in the provisions of any other direct contract with Owner) resulting from the acceptance of each proposed substitute. F. Contractor's Expense: Contractor shall provide all data in support of any proposed substitute or "or -equal" at Contractor's expense. 6.06 Concerning Subcontractors, Suppliers, and Others A. Contractor shall not employ any Subcontractor, Supplier, or other individual or entity (including those acceptable to Owner as indicated in Paragraph 6.06.13), whether initially or as a replacement, against whom Owner may have reasonable objection. Contractor shall not be EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 25 of 62 required to employ any Subcontractor, Supplier, or other individual or entity to furnish or perform any of the Work against whom Contractor has reasonable objection. B. If the Supplementary Conditions require the identity of certain Subcontractors, Suppliers, or other individuals or entities to be submitted to Owner in advance for acceptance by Owner by a specified date prior to the Effective Date of the Agreement, and if Contractor has submitted a list thereof in accordance with the Supplementary Conditions, Owner's acceptance (either in writing or by failing to make written objection thereto by the date indicated for acceptance or objection in the Bidding Documents or the Contract Documents) of any such Subcontractor, Supplier, or other individual or entity so identified may be revoked on the basis of reasonable objection after due — investigation. Contractor shall submit an acceptable replacement for the rejected Subcontractor, Supplier, or other individual or entity, and the Contract Price will be adjusted by the difference in the cost occasioned by such replacement, and an appropriate Change Order will be issued. No -- acceptance by Owner of any such Subcontractor, Supplier, or other individual or entity, whether initially or as a replacement, shall constitute a waiver of any right of Owner or Engineer to reject defective Work. C. Contractor shall be fully responsible to Owner and Engineer for all acts and omissions of the Subcontractors, Suppliers, and other individuals or entities performing or furnishing any of the Work just as Contractor is responsible for Contractor's own acts and omissions. Nothing in the Contract Documents: 1. shall create for the benefit of any such Subcontractor, Supplier, or other individual or entity any contractual relationship between Owner or Engineer and any such Subcontractor, Supplier or other individual or entity; nor 2. shall create any obligation on the part of Owner or Engineer to pay or to see to the payment of any moneys due any such Subcontractor, Supplier, or other individual or entity except as may = otherwise be required by Laws and Regulations. D. Contractor shall be solely responsible for scheduling and coordinating the Work of Subcontractors, Suppliers, and other individuals or entities performing or furnishing any of the Work under a direct or indirect contract with Contractor. E. Contractor shall require all Subcontractors, Suppliers, and such other individuals or entities performing or furnishing any of the Work to communicate with Engineer through Contractor. F. The divisions and sections of the Specifications and the identifications of any Drawings shall not control Contractor in dividing the Work among Subcontractors or Suppliers or delineating the Work to be performed by any specific trade. G. All Work performed for Contractor by a Subcontractor or Supplier will be pursuant to an appropriate agreement between Contractor and the Subcontractor or Supplier which specifically binds the Subcontractor or Supplier to the applicable terms and conditions of the Contract Documents for the benefit of Owner and Engineer. Whenever any such agreement is with a Subcontractor or Supplier who is listed as a loss payee on the property insurance provided in Paragraph 5.06, the agreement between the Contractor and the Subcontractor or Supplier will contain provisions whereby the Subcontractor or Supplier waives all rights against Owner, EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 26 of 62 FM Contractor, Engineer, and all other individuals or entities identified in the Supplementary Conditions to be listed as insureds or loss payees (and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them) for all losses and damages caused by, arising out of, relating to, or resulting from any of the perils or causes of loss covered by such policies and any other property insurance applicable to the Work. If the insurers on any such policies require separate waiver forms to be signed by any Subcontractor or Supplier, Contractor will obtain the same. 6.07 Patent Fees and Royalties A. Contractor shall pay all license fees and royalties and assume all costs incident to the use in the performance of the Work or the incorporation in the Work of any invention, design, process, product, or device which is the subject of patent rights or copyrights held by others. If a particular invention, design, process, product, or device is specified in the Contract Documents for use in the performance of the Work and if, to the actual knowledge of Owner or Engineer, its use is subject to patent rights or copyrights calling for the payment of any license fee or royalty to others, the existence of such rights shall be disclosed by Owner in the Contract Documents. B. To the fullest extent permitted by Laws and Regulations, Owner shall indemnify and hold harmless Contractor, and its officers, directors, members, partners, employees, agents, consultants, and subcontractors from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals, and all court or arbitration or other dispute resolution costs) arising out of or relating to any _ infringement of patent rights or copyrights incident to the use in the performance of the Work or resulting from the incorporation in the Work of any invention, design, process, product, or device specified in the Contract Documents, but not identified as being subject to payment of any license fee or royalty to others required by patent rights or copyrights. C. To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless Owner and Engineer, and the officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to any infringement of patent rights or copyrights incident to the use in the performance of the Work or resulting from the incorporation in the Work of any invention, design, process, product, or device not specified in the Contract Documents. 6.08 Permits A. Unless otherwise provided in the Supplementary Conditions, Contractor shall obtain and pay for all construction permits and licenses. Owner shall assist Contractor, when necessary, in obtaining such permits and licenses. Contractor shall pay all governmental charges and inspection fees necessary for the prosecution of the Work which are applicable at the time of opening of Bids, or, if there are no Bids, on the Effective Date of the Agreement. Owner shall pay all charges of utility owners for connections for providing permanent service to the Work. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright C 2007 National society orProressional Engineers for EJCDC. All rights reserved. Page 27 of 62 MR 6.09 Laws and Regulations A. Contractor shall give all notices required by and shall comply with all Laws and Regulations applicable to the performance of the Work. Except where otherwise expressly required by applicable Laws and Regulations, neither Owner nor Engineer shall be responsible for monitoring Contractor's compliance with any Laws or Regulations. B. If Contractor performs any Work knowing or having reason to know that it is contrary to Laws or Regulations, Contractor shall bear all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such Work. However, it shall not be Contractor's responsibility to make certain that the Specifications and Drawings are in accordance with Laws and Regulations, but this shall not relieve Contractor of Contractor's obligations under Paragraph 3.03. C. Changes in Laws or Regulations not known at the time of opening of Bids (or, on the Effective .f Date of the Agreement if there were no Bids) having an effect on the cost or time of performance of the Work shall be the subject of an adjustment in Contract Price or Contract Times. If Owner and Contractor are unable to agree on entitlement to or on the amount or extent, if any, of any such adjustment, a Claim may be made therefor as provided in Paragraph 10.05. 6.10 Taxes A. Contractor shall pay all sales, consumer, use, and other similar taxes required to be paid by Contractor in accordance with the Laws and Regulations of the place of the Project which are -- applicable during the performance of the Work. 6.11 Use of Site and Other Areas A. Limitation on Use of Site and Other Areas: 1. Contractor shall confine construction equipment, the storage of materials and equipment, and the operations of workers to the Site and other areas permitted by Laws and Regulations, and shall not unreasonably encumber the Site and other areas with construction equipment or other materials or equipment. Contractor shall assume full responsibility for any damage to any such land or area, or to the owner or occupant thereof, or of any adjacent land or areas resulting from the performance of the Work. 2. Should any claim be made by any such owner or occupant because of the performance of the Work, Contractor shall promptly settle with such other party by negotiation or otherwise resolve the claim by arbitration or other dispute resolution proceeding or at law. 3. To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless Owner and Engineer, and the officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to any claim or action, legal or equitable, brought EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 28 of 62 w by any such owner or occupant against Owner, Engineer, or any other party indemnified hereunder to the extent caused by or based upon Contractor's performance of the Work. .� B. Removal of Debris During Performance of the Work: During the progress of the Work Contractor shall keep the Site and other areas free from accumulations of waste materials, rubbish, and other debris. Removal and disposal of such waste materials, rubbish, and other debris shall conform to applicable Laws and Regulations. C. Cleaning: Prior to Substantial Completion of the Work Contractor shall clean the Site and the Work and make it ready for utilization by Owner. At the completion of the Work Contractor shall remove from the Site all tools, appliances, construction equipment and machinery, and surplus materials and shall restore to original condition all property not designated for alteration by the Contract Documents. D. Loading Structures: Contractor shall not load nor permit any part of any structure to be loaded in any manner that will endanger the structure, nor shall Contractor subject any part of the Work or adjacent property to stresses or pressures that will endanger it. 40 6.12 Record Documents A. Contractor shall maintain in a safe place at the Site one record copy of all Drawings, Specifications, Addenda, Change Orders, Work Change Directives, Field Orders, and written interpretations and clarifications in good order and annotated to show changes made during construction. These record documents together with all approved Samples and a counterpart of ;- all approved Shop Drawings will be available to Engineer for reference. Upon completion of the Work, these record documents, Samples, and Shop Drawings will be delivered to Engineer for Owner. 6.13 Safety and Protection ^� A. Contractor shall be solely responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the Work. Such responsibility does not relieve Subcontractors of their responsibility for the safety of persons or property in the performance of their work, nor for compliance with applicable safety Laws and Regulations. Contractor shall take all necessary precautions for the safety of, and shall provide the necessary protection to prevent damage, injury or loss to: 1. all persons on the Site or who may be affected by the Work; 2. all the Work and materials and equipment to be incorporated therein, whether in storage on or off the Site; and 3. other property at the Site or adjacent thereto, including trees, shrubs, lawns, walks, _ pavements, roadways, structures, utilities, and Underground Facilities not designated for removal, relocation, or replacement in the course of construction. B. Contractor shall comply with all applicable Laws and Regulations relating to the safety of persons or property, or to the protection of persons or property from damage, injury, or loss; and EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 29 of 62 shall erect and maintain all necessary safeguards for such safety and protection. Contractor shall notify owners of adjacent property and of Underground Facilities and other utility owners when prosecution of the Work may affect them, and shall cooperate with them in the protection, removal, relocation, and replacement of their property. C. Contractor shall comply with the applicable requirements of Owner's safety programs, if any. The Supplementary Conditions identify any Owner's safety programs that are applicable to the Work. D. Contractor shall inform Owner and Engineer of the specific requirements of Contractor's safety program with which Owner's and Engineer's employees and representatives must comply while at the Site. E. All damage, injury, or loss to any property referred to in Paragraph 6.13.A.2 or 6.13.A.3 caused, directly or indirectly, in whole or in part, by Contractor, any Subcontractor, Supplier, or any other individual or entity directly or indirectly employed by any of them to perform any of the Work, or anyone for whose acts any of them may be liable, shall be remedied by Contractor (except damage or loss attributable to the fault of Drawings or Specifications or to the acts or omissions of Owner or Engineer or anyone employed by any of them, or anyone for whose acts any of them may be liable, and not attributable, directly or indirectly, in whole or in part, to the fault or negligence of Contractor or any Subcontractor, Supplier, or other individual or entity directly or indirectly employed by any of them). F. Contractor's duties and responsibilities for safety and for protection of the Work shall continue until such time as all the Work is completed and Engineer has issued a notice to Owner and Contractor in accordance with Paragraph 14.07.13 that the Work is acceptable (except as otherwise expressly provided in connection with Substantial Completion). 6.14 Safety Representative A. Contractor shall designate a qualified and experienced safety representative at the Site whose duties and responsibilities shall be the prevention of accidents and the maintaining and supervising of safety precautions and programs. 6.15 Hazard Communication Programs A. Contractor shall be responsible for coordinating any exchange of material safety data sheets or other hazard communication information required to be made available to or exchanged between or among employers at the Site in accordance with Laws or Regulations. 6.16 Emergencies A. In emergencies affecting the safety or protection of persons or the Work or property at the Site or �- adjacent thereto, Contractor is obligated to act to prevent threatened damage, injury, or loss. Contractor shall give Engineer prompt written notice if Contractor believes that any significant changes in the Work or variations from the Contract Documents have been caused thereby or are required as a result thereof. If Engineer determines that a change in the Contract Documents is i EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 30 of 62 /4 i required because of the action taken by Contractor in response to such an emergency, a Work Change Directive or Change Order will be issued. M 6.17 Shop Drawings and Samples A. Contractor shall submit Shop Drawings and Samples to Engineer for review and approval in accordance with the accepted Schedule of Submittals (as required by Paragraph 2.07). Each submittal will be identified as Engineer may require. M 1. Shop Drawings: a. Submit number of copies specified in the General Requirements. .. b. Data shown on the Shop Drawings will be complete with respect to quantities, dimensions, specified performance and design criteria, materials, and similar data to show Engineer the services, materials, and equipment Contractor proposes to provide and to enable Engineer to review the information for the limited purposes required by Paragraph 6.17.D. M 2. Samples: OM a. Submit number of Samples specified in the Specifications. b. Clearly identify each Sample as to material, Supplier, pertinent data such as catalog numbers, the use for which intended and other data as Engineer may require to enable Engineer to review the submittal for the limited purposes required by Paragraph 6.17.D. B. Where a Shop Drawing or Sample is required by the Contract Documents or the Schedule of Submittals, any related Work performed prior to Engineer's review and approval of the pertinent submittal will be at the sole expense and responsibility of Contractor. i C. Submittal Procedures: 1. Before submitting each Shop Drawing or Sample, Contractor shall have: a. reviewed and coordinated each Shop Drawing or Sample with other Shop Drawings and Samples and with the requirements of the Work and the Contract Documents; b. determined and verified all field measurements, quantities, dimensions, specified Moo performance and design criteria, installation requirements, materials, catalog numbers, and similar information with respect thereto; MM c. determined and verified the suitability of all materials offered with respect to the indicated application, fabrication, shipping, handling, storage, assembly, and installation pertaining to the performance of the Work; and d d. determined and verified all information relative to Contractor's responsibilities for means, methods, techniques, sequences, and procedures of construction, and safety precautions and programs incident thereto. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 31 of 62 ^ 2. Each submittal shall bear a stamp or specific written certification that Contractor has satisfied Contractor's obligations under the Contract Documents with respect to Contractor's review and approval of that submittal. ^ 3. With each submittal, Contractor shall give Engineer specific written notice of any variations that the Shop Drawing or Sample may have from the requirements of the Contract Documents. This notice shall be both a written communication separate from the Shop Drawings or Sample submittal; and, in addition, by a specific notation made on each Shop Drawing or Sample submitted to Engineer for review and approval of each such variation. D. Engineer's Review: Engineer will provide timely review of Shop Drawings and Samples in accordance with the Schedule of Submittals acceptable to Engineer. Engineer's review and approval will be only to determine if the items covered by the submittals will, after installation or incorporation in the Work, conform to the information given in the Contract Documents and be compatible ,^ with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. ^ 2. Engineer's review and approval will not extend to means, methods, techniques, sequences, or procedures of construction (except where a particular means, method, technique, sequence, or procedure of construction is specifically and expressly called for by the Contract Documents) or to safety precautions or programs incident thereto. The review and approval of a separate item as such will not indicate approval of the assembly in which the item functions. 3. Engineer's review and approval shall not relieve Contractor from responsibility for any variation from the requirements of the Contract Documents unless Contractor has complied with the requirements of Paragraph 6.17.C.3 and Engineer has given written approval of each such variation by specific written notation thereof incorporated in or accompanying the Shop Drawing or Sample. Engineer's review and approval shall not relieve Contractor from responsibility for complying with the requirements of Paragraph 6.17.C.1. E. Resubmittal Procedures: Contractor shall make corrections required by Engineer and shall return the required number of corrected copies of Shop Drawings and submit, as required, new Samples for review and approval. Contractor shall direct specific attention in writing to revisions other than the corrections called for by Engineer on previous submittals. 6.18 Continuing the Work A. Contractor shall carry on the Work and adhere to the Progress Schedule during all disputes or disagreements with Owner. No Work shall be delayed or postponed pending resolution of any disputes or disagreements, except as permitted by Paragraph 15.04 or as Owner and Contractor may otherwise agree in writing. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 32 of 62 M MR 6.19 _ Contractor's General Warranty and Guarantee A. Contractor warrants and guarantees to Owner that all Work will be in accordance with the Contract Documents and will not be defective. Engineer and its officers, directors, members, partners, employees, agents, consultants, and subcontractors shall be entitled to rely on representation of Contractor's warranty and guarantee. B. Contractor's warranty and guarantee hereunder excludes defects or damage caused by: 1. abuse, modification, or improper maintenance or operation by persons other than Contractor, Subcontractors, Suppliers, or any other individual or entity for whom Contractor is responsible; or i 2. normal wear and tear under normal usage. 4M C. Contractor's obligation to perform and complete the Work in accordance with the Contract Documents shall be absolute. None of the following will constitute an acceptance of Work that is not in accordance with the Contract Documents or a release of Contractor's obligation to perform the Work in accordance with the Contract Documents: 1. observations by Engineer; 2. recommendation by Engineer or payment by Owner of any progress or final payment; 3. the issuance of a certificate of Substantial Completion by Engineer or any payment related thereto by Owner; M 4. use or occupancy of the Work or any part thereof by Owner; 5. any review and approval of a Shop Drawing or Sample submittal or the issuance of a notice MW of acceptability by Engineer; 6. any inspection, test, or approval by others; or 7. any correction of defective Work by Owner. 6.20 Indemnification A. To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless Owner and Engineer, and the officers, directors, members, partners, employees, agents, IM consultants and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, me and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to the performance of the Work, provided that any such claim, cost, loss, or damage is attributable to bodily injury, sickness, disease, or death, or to injury to or destruction of tangible 4M property (other than the Work itself), including the loss of use resulting therefrom but only to the extent caused by any negligent act or omission of Contractor, any Subcontractor, any Supplier, or any individual or entity directly or indirectly employed by any of them to perform any of the ..t Work or anyone for whose acts any of them may be liable. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright C 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 33 of 62 w B. In any and all claims against Owner or Engineer or any of their officers, directors, members, partners, employees, agents, consultants, or subcontractors by any employee (or the survivor or personal representative of such employee) of Contractor, any Subcontractor, any Supplier, or any individual or entity directly or indirectly employed by any of them to perform any of the Work, or anyone for whose acts any of them may be liable, the indemnification obligation under Paragraph 6.20.A shall not be limited in any way by any limitation on the amount or type of damages, compensation, or benefits payable by or for Contractor or any such Subcontractor, Supplier, or other individual or entity under workers' compensation acts, disability benefit acts, or other employee benefit acts. C. The indemnification obligations of Contractor under Paragraph 6.20.A shall not extend to the liability of Engineer and Engineer's officers, directors, members, partners, employees, agents, consultants and subcontractors arising out of: -- 1. the preparation or approval of, or the failure to prepare or approve maps, Drawings, opinions, reports, surveys, Change Orders, designs, or Specifications; or 2. giving directions or instructions, or failing to give them, if that is the primary cause of the injury or damage. 6.21 Delegation of Professional Design Services w A. Contractor will not be required to provide professional design services unless such services are specifically required by the Contract Documents for a portion of the Work or unless such services are required to carry out Contractor's responsibilities for construction means, methods, techniques, sequences and procedures. Contractor shall not be required to provide professional services in violation of applicable law. B. If professional design services or certifications by a design professional related to systems, materials or equipment are specifically required of Contractor by the Contract Documents, Owner and Engineer will specify all performance and design criteria that such services must satisfy. Contractor shall cause such services or certifications to be provided by a properly licensed professional, whose signature and seal shall appear on all drawings, calculations, specifications, certifications, Shop Drawings and other submittals prepared by such professional. Shop Drawings and other submittals related to the Work designed or certified by such professional, if prepared by others, shall bear such professional's written approval when submitted to Engineer. C. Owner and Engineer shall be entitled to rely upon the adequacy, accuracy and completeness of the services, certifications or approvals performed by such design professionals, provided Owner and Engineer have specified to Contractor all performance and design criteria that such services must satisfy. D. Pursuant to this Paragraph 6.21, Engineer's review and approval of design calculations and } design drawings will be only for the limited purpose of checking for conformance with performance and design criteria given and the design concept expressed in the Contract Documents. Engineer's review and approval of Shop Drawings and other submittals (except design calculations and design drawings) will be only for the purpose stated in Paragraph 6.17.D.1. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 34 of 62 i E. Contractor shall not be responsible for the adequacy of the performance or design criteria required by the Contract Documents. z ARTICLE 7 — OTHER WORK AT THE SITE 7.01 Related Work at Site A. Owner may perform other work related to the Project at the Site with Owner's employees, or through other direct contracts therefor, or have other work performed by utility owners. If such other work is not noted in the Contract Documents, then: 1. written notice thereof will be given to Contractor prior to starting any such other work; and i 2. if Owner and Contractor are unable to agree on entitlement to or on the amount or extent, if any, of any adjustment in the Contract Price or Contract Times that should be allowed as a result of such other work, a Claim may be made therefor as provided in Paragraph 10.05. B. Contractor shall afford each other contractor who is a party to such a direct contract, each utility owner, and Owner, if Owner is performing other work with Owner's employees, proper and safe access to the Site, provide a reasonable opportunity for the introduction and storage of materials and equipment and the execution of such other work, and properly coordinate the Work with theirs. Contractor shall do all cutting, fitting, and patching of the Work that may be required to properly connect or otherwise make its several parts come together and properly integrate with such other work. Contractor shall not endanger any work of others by cutting, excavating, or #+ otherwise altering such work; provided, however, that Contractor may cut or alter others' work with the written consent of Engineer and the others whose work will be affected. The duties and responsibilities of Contractor under this Paragraph are for the benefit of such utility owners and other contractors to the extent that there are comparable provisions for the benefit of Contractor in said direct contracts between Owner and such utility owners and other contractors. am C. If the proper execution or results of any part of Contractor's Work depends upon work performed by others under this Article 7, Contractor shall inspect such other work and promptly report to Engineer in writing any delays, defects, or deficiencies in such other work that render it unavailable or unsuitable for the proper execution and results of Contractor's Work. Contractor's failure to so report will constitute an acceptance of such other work as fit and proper for integration with Contractor's Work except for latent defects and deficiencies in such other work. 7.02 Coordination A. If Owner intends to contract with others for the performance of other work on the Project at the Site, the following will be set forth in Supplementary Conditions: on 1. the individual or entity who will have authority and responsibility for coordination of the activities among the various contractors will be identified; 2. the specific matters to be covered by such authority and responsibility will be itemized; and 3. the extent of such authority and responsibilities will be provided. w. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 35 of 62 MW B. Unless otherwise provided in the Supplementary Conditions, Owner shall have sole authority and responsibility for such coordination. 7.03 Legal Relationships A. Paragraphs 7.01.A and 7.02 are not applicable for utilities not under the control of Owner. B. Each other direct contract of Owner under Paragraph 7.01.A shall provide that the other contractor is liable to Owner and Contractor for the reasonable direct delay and disruption costs incurred by Contractor as a result of the other contractor's wrongful actions or inactions. C. Contractor shall be liable to Owner and any other contractor under direct contract to Owner for the reasonable direct delay and disruption costs incurred by such other contractor as a result of Contractor's wrongful action or inactions. ARTICLE 8 — OWNER'S RESPONSIBILITIES 8.01 Communications to Contractor A. Except as otherwise provided in these General Conditions, Owner shall issue all communications to Contractor through Engineer. 8.02 Replacement of Engineer A. In case of termination of the employment of Engineer, Owner shall appoint an engineer to whom Contractor makes no reasonable objection, whose status under the Contract Documents shall be that of the former Engineer. 8.03 Furnish Data A. Owner shall promptly famish the data required of Owner under the Contract Documents. 8.04 Pay When Due A. Owner shall make payments to Contractor when they are due as provided in Paragraphs 14.02.0 and 14.07.C. 8.05 Lands and Easements; Reports and Tests A. Owner's duties with respect to providing lands and easements and providing engineering surveys to establish reference points are set forth in Paragraphs 4.01 and 4.05. Paragraph 4.02 refers to Owner's identifying and making available to Contractor copies of reports of explorations and tests of subsurface conditions and drawings of physical conditions relating to existing surface or subsurface structures at the Site. 8.06 Insurance A. Owner's responsibilities, if any, with respect to purchasing and maintaining liability and property insurance are set forth in Article 5. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 36 of 62 MW i 8.07 Change Orders A. Owner is obligated to execute Change Orders as indicated in Paragraph 10.03. 8.08 Inspections, Tests, and Approvals Pot A. Owner's responsibility with respect to certain inspections, tests, and approvals is set forth in Paragraph 13.03.B. 8.09 Limitations on Owner's Responsibilities i A. The Owner shall not supervise, direct, or have control or authority over, nor be responsible for, Contractor's means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the performance of the Work. Owner will not be responsible for Contractor's failure to perform the Work in accordance with the Contract Documents. 4M 8.10 Undisclosed Hazardous Environmental Condition A. Owner's responsibility in respect to an undisclosed Hazardous Environmental Condition is set forth in Paragraph 4.06. 8.11 Evidence of Financial Arrangements A. Upon request of Contractor, Owner shall furnish Contractor reasonable evidence that financial arrangements have been made to satisfy Owner's obligations under the Contract Documents. 8.12 Compliance with Safety Program A. While at the Site, Owner's employees and representatives shall comply with the specific applicable requirements of Contractor's safety programs of which Owner has been informed pursuant to Paragraph 6.13.D. ARTICLE 9 — ENGINEER'S STATUS DURING CONSTRUCTION 9.01 Owner's Representative A. Engineer will be Owner's representative during the construction period. The duties and responsibilities and the limitations of authority of Engineer as Owner's representative during construction are set forth in the Contract Documents. i 9.02 Visits to Site A. Engineer will make visits to the Site at intervals appropriate to the various stages of construction as Engineer deems necessary in order to observe as an experienced and qualified design professional the progress that has been made and the quality of the various aspects of i Contractor's executed Work. Based on information obtained during such visits and observations, Engineer, for the benefit of Owner, will determine, in general, if the Work is proceeding in accordance with the Contract Documents. Engineer will not be required to make exhaustive or i EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 37 of 62 i continuous inspections on the Site to check the quality or quantity of the Work. Engineer's efforts will be directed toward providing for Owner a greater degree of confidence that the completed Work will conform generally to the Contract Documents. On the basis of such visits and observations, Engineer will keep Owner informed of the progress of the Work and will endeavor _ to guard Owner against defective Work. B. Engineer's visits and observations are subject to all the limitations on Engineer's authority and _ responsibility set forth in Paragraph 9.09. Particularly, but without limitation, during or as a result of Engineer's visits or observations of Contractor's Work, Engineer will not supervise, direct, control, or have authority over or be responsible for Contractor's means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the performance of the Work. 9.03 Project Representative A. If Owner and Engineer agree, Engineer will furnish a Resident Project Representative to assist Engineer in providing more extensive observation of the Work. The authority and responsibilities of any such Resident Project Representative and assistants will be as provided in the �- Supplementary Conditions, and limitations on the responsibilities thereof will be as provided in Paragraph 9.09. If Owner designates another representative or agent to represent Owner at the Site who is not Engineer's consultant, agent or employee, the responsibilities and authority and limitations thereon of such other individual or entity will be as provided in the Supplementary Conditions. 9.04 Authorized Variations in Work A. Engineer may authorize minor variations in the Work from the requirements of the Contract Documents which do not involve an adjustment in the Contract Price or the Contract Times and are compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. These may be accomplished by a Field Order and will be binding on Owner and also on Contractor, who shall perform the Work involved promptly. If Owner or Contractor believes that a Field Order justifies an adjustment in the Contract Price or Contract Times, or both, and the parties are unable to agree on entitlement to or on the amount or extent, if any, of any such adjustment, a Claim may be made therefor as provided in Paragraph 10.05. 9.05 Rejecting Defective Work A. Engineer will have authority to reject Work which Engineer believes to be defective, or that Engineer believes will not produce a completed Project that conforms to the Contract Documents or that will prejudice the integrity of the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. Engineer will also have authority to require special inspection or testing of the Work as provided in Paragraph 13.04, whether or not the Work is fabricated, installed, or completed. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 38 of 62 M ,t 9.06 Shop Drawings, Change Orders and Payments A. In connection with Engineer's authority, and limitations thereof, as to Shop Drawings and Samples, see Paragraph 6.17. B. In connection with Engineer's authority, and limitations thereof, as to design calculations and design drawings submitted in response to a delegation of professional design services, if any, see Paragraph 6.21. C. In connection with Engineer's authority as to Change Orders, see Articles 10, 11, and 12. D. In connection with Engineer's authority as to Applications for Payment, see Article 14. 9.07 Determinations for Unit Price Work A. Engineer will determine the actual quantities and classifications of Unit Price Work performed by Contractor. Engineer will review with Contractor the Engineer's preliminary determinations on such matters before rendering a written decision thereon (by recommendation of an Application for Payment or otherwise). Engineer's written decision thereon will be final and binding (except as modified by Engineer to reflect changed factual conditions or more accurate data) upon Owner and Contractor, subject to the provisions of Paragraph 10.05. 9.08 Decisions on Requirements of Contract Documents and Acceptability of Work i A. Engineer will be the initial interpreter of the requirements of the Contract Documents and judge of the acceptability of the Work thereunder. All matters in question and other matters between Owner and Contractor arising prior to the date final payment is due relating to the acceptability of r. the Work, and the interpretation of the requirements of the Contract Documents pertaining to the performance of the Work, will be referred initially to Engineer in writing within 30 days of the event giving rise to the question. B. Engineer will, with reasonable promptness, render a written decision on the issue referred. If Owner or Contractor believes that any such decision entitles them to an adjustment in the ... Contract Price or Contract Times or both, a Claim may be made under Paragraph 10.05. The date of Engineer's decision shall be the date of the event giving rise to the issues referenced for the purposes of Paragraph 10.05.13. C. Engineer's written decision on the issue referred will be final and binding on Owner and Contractor, subject to the provisions of Paragraph 10.05. D. When functioning as interpreter and judge under this Paragraph 9.08, Engineer will not show partiality to Owner or Contractor and will not be liable in connection with any interpretation or i decision rendered in good faith in such capacity. 9.09 Limitations on Engineer's Authority and Responsibilities Ak A. Neither Engineer's authority or responsibility under this Article 9 or under any other provision of the Contract Documents nor any decision made by Engineer in good faith either to exercise or not EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 39 of 62 MW exercise such authority or responsibility or the undertaking, exercise, or performance of any authority or responsibility by Engineer shall create, impose, or give rise to any duty in contract, tort, or otherwise owed by Engineer to Contractor, any Subcontractor, any Supplier, any other individual or entity, or to any surety for or employee or agent of any of them. B. Engineer will not supervise, direct, control, or have authority over or be responsible for Contractor's means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the performance of the Work. Engineer will not be responsible for Contractor's failure to perform the Work in accordance with the Contract Documents. .� C. Engineer will not be responsible for the acts or omissions of Contractor or of any Subcontractor, any Supplier, or of any other individual or entity performing any of the Work. D. Engineer's review of the final Application for Payment and accompanying documentation and all maintenance and operating instructions, schedules, guarantees, bonds, certificates of inspection, tests and approvals, and other documentation required to be delivered by Paragraph 14.07.A will only be to determine generally that their content complies with the requirements of, and in the case of certificates of inspections, tests, and approvals that the results certified indicate compliance with, the Contract Documents. E. The limitations upon authority and responsibility set forth in this Paragraph 9.09 shall also apply to the Resident Project Representative, if any, and assistants, if any. 9.10 Compliance with Safety Program A. While at the Site, Engineer's employees and representatives shall comply with the specific applicable requirements of Contractor's safety programs of which Engineer has been informed pursuant to Paragraph 6.13.D. ARTICLE 10 — CHANGES IN THE WORK; CLAIMS 10.01 Authorized Changes in the Work A. Without invalidating the Contract and without notice to any surety, Owner may, at any time or from time to time, order additions, deletions, or revisions in the Work by a Change Order, or a Work Change Directive. Upon receipt of any such document, Contractor shall promptly proceed with the Work involved which will be performed under the applicable conditions of the Contract Documents (except as otherwise specifically provided). B. If Owner and Contractor are unable to agree on entitlement to, or on the amount or extent, if any, of an adjustment in the Contract Price or Contract Times, or both, that should be allowed as a result of a Work Change Directive, a Claim may be made therefor as provided in Paragraph 10.05. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright C 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 40 of 62 MR 10.02 Unauthorized Changes in the Work A. Contractor shall not be entitled to an increase in the Contract Price or an extension of the Contract Times with respect to any work performed that is not required by the Contract Documents as amended, modified, or supplemented as provided in Paragraph 3.04, except in the case of an emergency as provided in Paragraph 6.16 or in the case of uncovering Work as provided in Paragraph 13.04.D. 10.03 Execution of Change Orders A. Owner and Contractor shall execute appropriate Change Orders recommended by Engineer covering: — 1. changes in the Work which are: (i) ordered by Owner pursuant to Paragraph 10.0l.A, (ii) required because of acceptance of defective Work under Paragraph 13.08.A or Owner's .� correction of defective Work under Paragraph 13.09, or (iii) agreed to by the parties; 2. changes in the Contract Price or Contract Times which are agreed to by the parties, including ,. any undisputed sum or amount of time for Work actually performed in accordance with a Work Change Directive; and 3. changes in the Contract Price or Contract Times which embody the substance of any written decision rendered by Engineer pursuant to Paragraph 10.05; provided that, in lieu of executing any such Change Order, an appeal may be taken from any such decision in accordance with the provisions of the Contract Documents and applicable Laws and Regulations, but during any such appeal, Contractor shall carry on the Work and adhere to the Progress Schedule as provided in Paragraph 6.18.A. 10.04 Notification to Surety MR A. If the provisions of any bond require notice to be given to a surety of any change affecting the general scope of the Work or the provisions of the Contract Documents (including, but not limited to, Contract Price or Contract Times), the giving of any such notice will be Contractor's On responsibility. The amount of each applicable bond will be adjusted to reflect the effect of any such change. 10.05 Claims A. Engineer's Decision Required. All Claims, except those waived pursuant to Paragraph 14.09, — shall be referred to the Engineer for decision. A decision by Engineer shall be required as a condition precedent to any exercise by Owner or Contractor of any rights or remedies either may otherwise have under the Contract Documents or by Laws and Regulations in respect of such Claims. B. Notice: Written notice stating the general nature of each Claim shall be delivered by the claimant to Engineer and the other party to the Contract promptly (but in no event later than 30 days) after the start of the event giving rise thereto. The responsibility to substantiate a Claim shall rest with the party making the Claim. Notice of the amount or extent of the Claim, with supporting data EJCDC C-700 Standard General Conditions of the Construction Contract Copyright O 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 41 of 62 i shall be delivered to the Engineer and the other party to the Contract within 60 days after the start of such event (unless Engineer allows additional time for claimant to submit additional or more accurate data in support of such Claim). A Claim for an adjustment in Contract Price shall be prepared in accordance with the provisions of Paragraph 12.01.B. A Claim for an adjustment in Contract Times shall be prepared in accordance with the provisions of Paragraph 12.02.13. Each Claim shall be accompanied by claimant's written statement that the adjustment claimed is the entire adjustment to which the claimant believes it is entitled as a result of said event. The — opposing party shall submit any response to Engineer and the claimant within 30 days after receipt of the claimant's last submittal (unless Engineer allows additional time). C. Engineer's Action: Engineer will review each Claim and, within 30 days after receipt of the last submittal of the claimant or the last submittal of the opposing party, if any, take one of the following actions in writing: 1. deny the Claim in whole or in part; 2. approve the Claim; or 3. notify the parties that the Engineer is unable to resolve the Claim if, in the Engineer's sole discretion, it would be inappropriate for the Engineer to do so. For purposes of further resolution of the Claim, such notice shall be deemed a denial. D. In the event that Engineer does not take action on a Claim within said 30 days, the Claim shall be deemed denied. E. Engineer's written action under Paragraph 10.05.0 or denial pursuant to Paragraphs 10.05.C.3 or 10.05.1) will be final and binding upon Owner and Contractor, unless Owner or Contractor invoke the dispute resolution procedure set forth in Article 16 within 30 days of such action or denial. F. No Claim for an adjustment in Contract Price or Contract Times will be valid if not submitted in accordance with this Paragraph 10.05. ARTICLE 11— COST OF THE WORK; ALLOWANCES; UNIT PRICE WORK .-. 11.01 Cost of the Work A. Costs Included: The term Cost of the Work means the sum of all costs, except those excluded in Paragraph 11.01.13, necessarily incurred and paid by Contractor in the proper performance of the Work. When the value of any Work covered by a Change Order or when a Claim for an adjustment in Contract Price is determined on the basis of Cost of the Work, the costs to be reimbursed to Contractor will be only those additional or incremental costs required because of the change in the Work or because of the event giving rise to the Claim. Except as otherwise may — be agreed to in writing by Owner, such costs shall be in amounts no higher than those prevailing in the locality of the Project, shall not include any of the costs itemized in Paragraph 11.01.13, and shall include only the following items: EJCDC C-700 Standard General Conditions of the Construction Contract Copyright C) 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 42 of 62 MER 1. Payroll costs for employees in the direct employ of Contractor in the performance of the Work under schedules of job classifications agreed upon by Owner and Contractor. Such employees shall include, without limitation, superintendents, foremen, and other personnel employed full time on the Work. Payroll costs for employees not employed full time on the Work shall be apportioned on the basis of their time spent on the Work. Payroll costs shall include, but not be limited to, salaries and wages plus the cost of fringe benefits, which shall include social security contributions, unemployment, excise, and payroll taxes, workers' compensation, health and retirement benefits, bonuses, sick leave, vacation and holiday pay applicable thereto. The expenses of performing Work outside of regular working hours, on MR Saturday, Sunday, or legal holidays, shall be included in the above to the extent authorized by Owner. 'i 2. Cost of all materials and equipment furnished and incorporated in the Work, including costs of transportation and storage thereof, and Suppliers' field services required in connection therewith. All cash discounts shall accrue to Contractor unless Owner deposits funds with Mft Contractor with which to make payments, in which case the cash discounts shall accrue to Owner. All trade discounts, rebates and refunds and returns from sale of surplus materials and equipment shall accrue to Owner, and Contractor shall make provisions so that they may be obtained. 3. Payments made by Contractor to Subcontractors for Work performed by Subcontractors. If required by Owner, Contractor shall obtain competitive bids from subcontractors acceptable to Owner and Contractor and shall deliver such bids to Owner, who will then determine, with the advice of Engineer, which bids, if any, will be acceptable. If any subcontract provides that the Subcontractor is to be paid on the basis of Cost of the Work plus a fee, the Subcontractor's Cost of the Work and fee shall be determined in the same manner as Contractor's Cost of the Work and fee as provided in this Paragraph 11.01. 4. Costs of special consultants (including but not limited to engineers, architects, testing laboratories, surveyors, attorneys, and accountants) employed for services specifically related to the Work. 5. Supplemental costs including the following: a. The proportion of necessary transportation, travel, and subsistence expenses of _ Contractor's employees incurred in discharge of duties connected with the Work. b. Cost, including transportation and maintenance, of all materials, supplies, equipment, machinery, appliances, office, and temporary facilities at the Site, and hand tools not owned by the workers, which are consumed in the performance of the Work, and cost, less market value, of such items used but not consumed which remain the property of Contractor. c. Rentals of all construction equipment and machinery, and the parts thereof whether rented from Contractor or others in accordance with rental agreements approved by Owner with the advice of Engineer, and the costs of transportation, loading, unloading, assembly, dismantling, and removal thereof. All such costs shall be in accordance with the terms of EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 43 of 62 w said rental agreements. The rental of any such equipment, machinery, or parts shall cease T when the use thereof is no longer necessary for the Work. d. Sales, consumer, use, and other similar taxes related to the Work, and for which Contractor is liable, as imposed by Laws and Regulations. e. Deposits lost for causes other than negligence of Contractor, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable, and royalty payments and fees for permits and licenses. f. Losses and damages (and related expenses) caused by damage to the Work, not compensated by insurance or otherwise, sustained by Contractor in connection with the performance of the Work (except losses and damages within the deductible amounts of property insurance established in accordance with Paragraph 5.06.1)), provided such losses and damages have resulted from causes other than the negligence of Contractor, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable. Such losses shall include settlements made with the written consent and approval of Owner. No such losses, damages, and expenses shall be included in the Cost of the Work for the purpose of determining Contractor's fee. g. The cost of utilities, fuel, and sanitary facilities at the Site. h. Minor expenses such as telegrams, long distance telephone calls, telephone service at the Site, express and courier services, and similar petty cash items in connection with the Work. -- i. The costs of premiums for all bonds and insurance Contractor is required by the Contract Documents to purchase and maintain. — B. Costs Excluded: The term Cost of the Work shall not include any of the following items: 1. Payroll costs and other compensation of Contractor's officers, executives, principals (of partnerships and sole proprietorships), general managers, safety managers, engineers, architects, estimators, attorneys, auditors, accountants, purchasing and contracting agents, expediters, timekeepers, clerks, and other personnel employed by Contractor, whether at the Site or in Contractor's principal or branch office for general administration of the Work and not specifically included in the agreed upon schedule of job classifications referred to in — Paragraph 11.0I.A.1 or specifically covered by Paragraph 11.0I.A.4, all of which are to be considered administrative costs covered by the Contractor's fee. 2. Expenses of Contractor's principal and branch offices other than Contractor's office at the Site. 3. Any part of Contractor's capital expenses, including interest on Contractor's capital employed for the Work and charges against Contractor for delinquent payments. 4. Costs due to the negligence of Contractor, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable, including but not EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 44 of 62 MN on limited to, the correction of defective Work, disposal of materials or equipment wrongly supplied, and making good any damage to property. 5. Other overhead or general expense costs of any kind and the costs of any item not specifically and expressly included in Paragraphs 11.0I I.A. C. Contractor's Fee: When all the Work is performed on the basis of cost-plus, Contractor's fee shall be determined as set forth in the Agreement. When the value of any Work covered by a Change Order or when a Claim for an adjustment in Contract Price is determined on the basis of Cost of the Work, Contractor's fee shall be determined as set forth in Paragraph 12.01.C. D. Documentation: Whenever the Cost of the Work for any purpose is to be determined pursuant to Paragraphs 11.01.A and 11.01.13, Contractor will establish and maintain records thereof in accordance with generally accepted accounting practices and submit in a form acceptable to Engineer an itemized cost breakdown together with supporting data. 11.02 Allowances A. It is understood that Contractor has included in the Contract Price all allowances so named in the Contract Documents and shall cause the Work so covered to be performed for such sums and by such persons or entities as may be acceptable to Owner and Engineer. B. Cash Allowances: 1. Contractor agrees that: a. the cash allowances include the cost to Contractor (less any applicable trade discounts) of materials and equipment required by the allowances to be delivered at the Site, and all applicable taxes; and i b. Contractor's costs for unloading and handling on the Site, labor, installation, overhead, profit, and other expenses contemplated for the cash allowances have been included in the Contract Price and not in the allowances, and no demand for additional payment on account of any of the foregoing will be valid. C. Contingency Allowance: 1. Contractor agrees that a contingency allowance, if any, is for the sole use of Owner to cover unanticipated costs. D. Prior to final payment, an appropriate Change Order will be issued as recommended by Engineer to reflect actual amounts due Contractor on account of Work covered by allowances, and the Contract Price shall be correspondingly adjusted. 11.03 Unit Price Work A. Where the Contract Documents provide that all or part of the Work is to be Unit Price Work, initially the Contract Price will be deemed to include for all Unit Price Work an amount equal to EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 45 of 62 the sum of the unit price for each separately identified item of Unit Price Work times the estimated quantity of each item as indicated in the Agreement. B. The estimated quantities of items of Unit Price Work are not guaranteed and are solely for the purpose of comparison of Bids and determining an initial Contract Price. Determinations of the actual quantities and classifications of Unit Price Work performed by Contractor will be made by Engineer subject to the provisions of Paragraph 9.07. C. Each unit price will be deemed to include an amount considered by Contractor to be adequate to cover Contractor's overhead and profit for each separately identified item. _ D. Owner or Contractor may make a Claim for an adjustment in the Contract Price in accordance with Paragraph 10.05 if: 1. the quantity of any item of Unit Price Work performed by Contractor differs materially and significantly from the estimated quantity of such item indicated in the Agreement; and .., 2. there is no corresponding adjustment with respect to any other item of Work; and 3. Contractor believes that Contractor is entitled to an increase in Contract Price as a result of having incurred additional expense or Owner believes that Owner is entitled to a decrease in Contract Price and the parties are unable to agree as to the amount of any such increase or decrease. ARTICLE 12 — CHANGE OF CONTRACT PRICE; CHANGE OF CONTRACT TIMES 12.01 Change of Contract Price A. The Contract Price may only be changed by a Change Order. Any Claim for an adjustment in the Contract Price shall be based on written notice submitted by the party making the Claim to the Engineer and the other party to the Contract in accordance with the provisions of Paragraph _ 10.05. B. The value of any Work covered by a Change Order or of any Claim for an adjustment in the Contract Price will be determined as follows: 1. where the Work involved is covered by unit prices contained in the Contract Documents, by ,+ application of such unit prices to the quantities of the items involved (subject to the provisions of Paragraph 11.03); or 2. where the Work involved is not covered by unit prices contained in the Contract Documents, by a mutually agreed lump sum (which may include an allowance for overhead and profit not necessarily in accordance with Paragraph 12.0l .C.2); or 3. where the Work involved is not covered by unit prices contained in the Contract Documents and agreement to a lump sum is not reached under Paragraph 12.013.2, on the basis of the Cost of the Work (determined as provided in Paragraph 11.01) plus a Contractor's fee for overhead and profit (determined as provided in Paragraph 12.01.C). EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 46 of 62 C. Contractor's Fee: The Contractor's fee for overhead and profit shall be determined as follows: 1. a mutually acceptable fixed fee; or MM 2. if a fixed fee is not agreed upon, then a fee based on the following percentages of the various portions of the Cost of the Work: MR a. for costs incurred under Paragraphs 11.0I.A.1 and 11.0I.A.2, the Contractor's fee shall be 15 percent; ,h b. for costs incurred under Paragraph 11.0l.A.3, the Contractor's fee shall be five percent; _ c. where one or more tiers of subcontracts are on the basis of Cost of the Work plus a fee and no fixed fee is agreed upon, the intent of Paragraphs 12.0l.C.2.a and 12.0l.C.2.b is that the Subcontractor who actually performs the Work, at whatever tier, will be paid a fee of 15 percent of the costs incurred by such Subcontractor under Paragraphs 11.0I.A. I and 11.01.A.2 and that any higher tier Subcontractor and Contractor will each be paid a fee of five percent of the amount paid to the next lower tier Subcontractor; d. no fee shall be payable on the basis of costs itemized under Paragraphs 11.0l.A.4, 11.0I.A.5, and 11.0I.B; e. the amount of credit to be allowed by Contractor to Owner for any change which results in a net decrease in cost will be the amount of the actual net decrease in cost plus a i deduction in Contractor's fee by an amount equal to five percent of such net decrease; and f. when both additions and credits are involved in any one change, the adjustment in Contractor's fee shall be computed on the basis of the net change in accordance with Paragraphs 12.0I.C.2.a through 12.0I .C.2.e, inclusive. i 12.02 Change of Contract Times A. The Contract Times may only be changed by a Change Order. Any Claim for an adjustment in the Contract Times shall be based on written notice submitted by the party making the Claim to the Engineer and the other party to the Contract in accordance with the provisions of Paragraph i 10.05. B. Any adjustment of the Contract Times covered by a Change Order or any Claim for an adjustment in the Contract Times will be determined in accordance with the provisions of this Article 12. -- 12.03 Delays A. Where Contractor is prevented from completing any part of the Work within the Contract Times �. due to delay beyond the control of Contractor, the Contract Times will be extended in an amount equal to the time lost due to such delay if a Claim is made therefor as provided in Paragraph 12.02.A. Delays beyond the control of Contractor shall include, but not be limited to, acts or EJCDC C-700 Standard General Conditions of the Construction Contract Copyright O 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 47 of 62 neglect by Owner, acts or neglect of utility owners or other contractors performing other work as contemplated by Article 7, fires, floods, epidemics, abnormal weather conditions, or acts of God. B. If Owner, Engineer, or other contractors or utility owners performing other work for Owner as contemplated by Article 7, or anyone for whom Owner is responsible, delays, disrupts, or interferes with the performance or progress of the Work, then Contractor shall be entitled to an equitable adjustment in the Contract Price or the Contract Times, or both. Contractor's entitlement to an adjustment of the Contract Times is conditioned on such adjustment being essential to Contractor's ability to complete the Work within the Contract Times. C. If Contractor is delayed in the performance or progress of the Work by fire, flood, epidemic, abnormal weather conditions, acts of God, acts or failures to act of utility owners not under the control of Owner, or other causes not the fault of and beyond control of Owner and Contractor, then Contractor shall be entitled to an equitable adjustment in Contract Times, if such adjustment is essential to Contractor's ability to complete the Work within the Contract Times. Such an adjustment shall be Contractor's sole and exclusive remedy for the delays described in this Paragraph 12.03.C. D. Owner, Engineer, and their officers, directors, members, partners, employees, agents, consultants, or subcontractors shall not be liable to Contractor for any claims, costs, losses, or damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) sustained by Contractor on or in connection with any other project or anticipated project. E. Contractor shall not be entitled to an adjustment in Contract Price or Contract Times for delays — within the control of Contractor. Delays attributable to and within the control of a Subcontractor or Supplier shall be deemed to be delays within the control of Contractor. ARTICLE 13 — TESTS AND INSPECTIONS; CORRECTION, REMOVAL OR ACCEPTANCE OF DEFECTIVE WORK 13.01 Notice of Defects A. Prompt notice of all defective Work of which Owner or Engineer has actual knowledge will be given to Contractor. Defective Work may be rejected, corrected, or accepted as provided in this Article 13. 13.02 Access to Work A. Owner, Engineer, their consultants and other representatives and personnel of Owner, -- independent testing laboratories, and governmental agencies with jurisdictional interests will have access to the Site and the Work at reasonable times for their observation, inspection, and testing. Contractor shall provide them proper and safe conditions for such access and advise them of Contractor's safety procedures and programs so that they may comply therewith as applicable. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. . Page 48 of 62 M 13.03 Tests and Inspections A. Contractor shall give Engineer timely notice of readiness of the Work for all required inspections, tests, or approvals and shall cooperate with inspection and testing personnel to facilitate required inspections or tests. i B. Owner shall employ and pay for the services of an independent testing laboratory to perform all inspections, tests, or approvals required by the Contract Documents except: 1. for inspections, tests, or approvals covered by Paragraphs 13.03.0 and 13.03.1) below; 2. that costs incurred in connection with tests or inspections conducted pursuant to Paragraph to, 13.043 shall be paid as provided in Paragraph 13.04.C; and 3. as otherwise specifically provided in the Contract Documents. C. If Laws or Regulations of any public body having jurisdiction require any Work (or part thereof) specifically to be inspected, tested, or approved by an employee or other representative of such public body, Contractor shall assume full responsibility for arranging and obtaining such inspections, tests, or approvals, pay all costs in connection therewith, and furnish Engineer the required certificates of inspection or approval. D. Contractor shall be responsible for arranging and obtaining and shall pay all costs in connection with any inspections, tests, or approvals required for Owner's and Engineer's acceptance of .� materials or equipment to be incorporated in the Work; or acceptance of materials, mix designs, or equipment submitted for approval prior to Contractor's purchase thereof for incorporation in the Work. Such inspections, tests, or approvals shall be performed by organizations acceptable to �- Owner and Engineer. E. If any Work (or the work of others) that is to be inspected, tested, or approved is covered by — Contractor without written concurrence of Engineer, Contractor shall, if requested by Engineer, uncover such Work for observation. = F. Uncovering Work as provided in Paragraph 13.03.E shall be at Contractor's expense unless Contractor has given Engineer timely notice of Contractor's intention to cover the same and Engineer has not acted with reasonable promptness in response to such notice. 13.04 Uncovering Work Aft A. If any Work is covered contrary to the written request of Engineer, it must, if requested by Engineer, be uncovered for Engineer's observation and replaced at Contractor's expense. B. If Engineer considers it necessary or advisable that covered Work be observed by Engineer or inspected or tested by others, Contractor, at Engineer's request, shall uncover, expose, or otherwise make available for observation, inspection, or testing as Engineer may require, that �+ portion of the Work in question, furnishing all necessary labor, material, and equipment. 0M EJCDC C-700 Standard General Conditions of the Construction Contract Copyright C 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 49 of 62 wa C. If it is found that the uncovered Work is defective, Contractor shall pay all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such uncovering, exposure, observation, inspection, and testing, and of satisfactory replacement or reconstruction (including but not limited to all costs of repair or replacement of work of others); and Owner shall be entitled to an appropriate decrease in the Contract Price. If the parties are unable to agree as to the amount thereof, Owner may make a Claim therefor as provided in Paragraph 10.05. D. If the uncovered Work is not found to be defective, Contractor shall be allowed an increase in the Contract Price or an extension of the Contract Times, or both, directly attributable to such uncovering, exposure, observation, inspection, testing, replacement, and reconstruction. If the parties are unable to agree as to the amount or extent thereof, Contractor may make a Claim therefor as provided in Paragraph 10.05. 13.05 Owner May Stop the Work FM A. If the Work is defective, or Contractor fails to supply sufficient skilled workers or suitable materials or equipment, or fails to perform the Work in such a way that the completed Work will -- conform to the Contract Documents, Owner may order Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, this right of Owner to stop the Work shall not give rise to any duty on the part of Owner to exercise this right for the benefit of Contractor, any Subcontractor, any Supplier, any other individual or entity, or any surety for, or employee or agent of any of them. 13.06 Correction or Removal of Defective Work A. Promptly after receipt of written notice, Contractor shall correct all defective Work, whether or not fabricated, installed, or completed, or, if the Work has been rejected by Engineer, remove it from the Project and replace it with Work that is not defective. Contractor shall pay all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such correction or removal (including but not limited to all costs of repair or replacement of work of others). B. When correcting defective Work under the terms of this Paragraph 13.06 or Paragraph 13.07, Contractor shall take no action that would void or otherwise impair Owner's special warranty and guarantee, if any, on said Work. 13.07 Correction Period A. If within one year after the date of Substantial Completion (or such longer period of time as may be prescribed by the terms of any applicable special guarantee required by the Contract Documents) or by any specific provision of the Contract Documents, any Work is found to be defective, or if the repair of any damages to the land or areas made available for Contractor's use by Owner or permitted by Laws and Regulations as contemplated in Paragraph 6.1 LA is found to be defective, Contractor shall promptly, without cost to Owner and in accordance with Owner's written instructions: EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 50 of 62 1. repair such defective land or areas; or 2. correct such defective Work; or 3. if the defective Work has been rejected by Owner, remove it from the Project and replace it with Work that is not defective, and 4. satisfactorily correct or repair or remove and replace any damage to other Work, to the work of others or other land or areas resulting therefrom. B. If Contractor does not promptly comply with the terms of Owner's written instructions, or in an emergency where delay would cause serious risk of loss or damage, Owner may have the defective Work corrected or repaired or may have the rejected Work removed and replaced. All claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such correction or repair or such removal and replacement (including but not limited to all costs of repair or replacement of work of others) will be paid by Contractor. C. In special circumstances where a particular item of equipment is placed in continuous service before Substantial Completion of all the Work, the correction period for that item may start to run *+ from an earlier date if so provided in the Specifications. D. Where defective Work (and damage to other Work resulting therefrom) has been corrected or �+ removed and replaced under this Paragraph 13.07, the correction period hereunder with respect to such Work will be extended for an additional period of one year after such correction or removal and replacement has been satisfactorily completed. i E. Contractor's obligations under this Paragraph 13.07 are in addition to any other obligation or warranty. The provisions of this Paragraph 13.07 shall not be construed as a substitute for, or a waiver of, the provisions of any applicable statute of limitation or repose. 13.08 Acceptance of Defective Work .r, A. If, instead of requiring correction or removal and replacement of defective Work, Owner (and, prior to Engineer's recommendation of final payment, Engineer) prefers to accept it, Owner may do so. Contractor shall pay all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) attributable to Owner's evaluation of and determination to accept such defective Work (such costs to be approved by Engineer as to reasonableness) and for the diminished value of the Work to the extent not otherwise paid by Contractor pursuant to this sentence. If any such acceptance occurs prior to Engineer's recommendation of final payment, a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Work, and Owner shall be entitled to an appropriate decrease in the Contract Price, reflecting the diminished value of Work so accepted. If the parties are unable to agree as to the amount thereof, Owner may make a Claim therefor as provided in Paragraph 10.05. If the acceptance occurs after such recommendation, an appropriate amount will be paid by Contractor to Owner. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 51 of 62 13.09 Owner May Correct Defective Work A. If Contractor fails within a reasonable time after written notice from Engineer to correct defective Work, or to remove and replace rejected Work as required by Engineer in accordance with Paragraph 13.06.A, or if Contractor fails to perform the Work in accordance with the Contract Documents, or if Contractor fails to comply with any other provision of the Contract Documents, Owner may, after seven days written notice to Contractor, correct, or remedy any such deficiency. .., B. In exercising the rights and remedies under this Paragraph 13.09, Owner shall proceed expeditiously. In connection with such corrective or remedial action, Owner may exclude Contractor from all or part of the Site, take possession of all or part of the Work and suspend Contractor's services related thereto, take possession of Contractor's tools, appliances, construction equipment and machinery at the Site, and incorporate in the Work all materials and .� equipment stored at the Site or for which Owner has paid Contractor but which are stored elsewhere. Contractor shall allow Owner, Owner's representatives, agents and employees, Owner's other contractors, and Engineer and Engineer's consultants access to the Site to enable Owner to exercise the rights and remedies under this Paragraph. C. All claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) incurred or sustained by Owner in exercising the rights and remedies under this Paragraph 13.09 will be charged against Contractor, and a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Work; and Owner shall be entitled to an appropriate decrease in the Contract Price. If the parties are unable to agree as to the amount of the adjustment, Owner may make a Claim therefor as provided in Paragraph 10.05. Such claims, costs, losses and damages will include but not be limited to all costs of repair, or replacement of work of others destroyed or damaged by correction, removal, or replacement of Contractor's defective Work. D. Contractor shall not be allowed an extension of the Contract Times because of any delay in the performance of the Work attributable to the exercise by Owner of Owner's rights and remedies under this Paragraph 13.09. ARTICLE 14 — PAYMENTS TO CONTRACTOR AND COMPLETION 14.01 Schedule of Values A. The Schedule of Values established as provided in Paragraph 2.07.A will serve as the basis for progress payments and will be incorporated into a form of Application for Payment acceptable to Engineer. Progress payments on account of Unit Price Work will be based on the number of units ` completed. 14.02 Progress Payments A. Applications for Payments: 1. At least 20 days before the date established in the Agreement for each progress payment (but not more often than once a month), Contractor shall submit to Engineer for review an EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 52 of 62 .N Application for Payment filled out and signed by Contractor covering the Work completed as of the date of the Application and accompanied by such supporting documentation as is required by the Contract Documents. If payment is requested on the basis of materials and equipment not incorporated in the Work but delivered and suitably stored at the Site or at another location agreed to in writing, the Application for Payment shall also be accompanied by a bill of sale, invoice, or other documentation warranting that Owner has received the materials and equipment free and clear of all Liens and evidence that the materials and equipment are covered by appropriate property insurance or other arrangements to protect Owner's interest therein, all of which must be satisfactory to Owner. 2. Beginning with the second Application for Payment, each Application shall include an affidavit of Contractor stating that all previous progress payments received on account of the Work have been applied on account to discharge Contractor's legitimate obligations associated with prior Applications for Payment. hm 3. The amount of retainage with respect to progress payments will be as stipulated in the Agreement. B. Review of Applications: 1. Engineer will, within 10 days after receipt of each Application for Payment, either indicate in *R writing a recommendation of payment and present the Application to Owner or return the Application to Contractor indicating in writing Engineer's reasons for refusing to recommend payment. In the latter case, Contractor may make the necessary corrections and resubmit the Application. 2. Engineer's recommendation of any payment requested in an Application for Payment will constitute a representation by Engineer to Owner, based on Engineer's observations of the executed Work as an experienced and qualified design professional, and on Engineer's review of the Application for Payment and the accompanying data and schedules, that to the PM best of Engineer's knowledge, information and belief: a. the Work has progressed to the point indicated; MM b. the quality of the Work is generally in accordance with the Contract Documents (subject to an evaluation of the Work as a functioning whole prior to or upon Substantial y' Completion, the results of any subsequent tests called for in the Contract Documents, a final determination of quantities and classifications for Unit Price Work under Paragraph 9.07, and any other qualifications stated in the recommendation); and c. the conditions precedent to Contractor's being entitled to such payment appear to have been fulfilled in so far as it is Engineer's responsibility to observe the Work. 3. By recommending any such payment Engineer will not thereby be deemed to have represented that: a. inspections made to check the quality or the quantity of the Work as it has been performed have been exhaustive, extended to every aspect of the Work in progress, or EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 53 of 62 WP involved detailed inspections of the Work beyond the responsibilities specifically assigned to Engineer in the Contract Documents; or b. there may not be other matters or issues between the parties that might entitle Contractor to be paid additionally by Owner or entitle Owner to withhold payment to Contractor. 4. Neither Engineer's review of Contractor's Work for the purposes of recommending payments nor Engineer's recommendation of any payment, including final payment, will impose responsibility on Engineer: i a. to supervise, direct, or control the Work, or b. for the means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or c. for Contractor's failure to comply with Laws and Regulations applicable to Contractor's performance of the Work, or d. to make any examination to ascertain how or for what purposes Contractor has used the moneys paid on account of the Contract Price, or e. to determine that title to any of the Work, materials, or equipment has passed to Owner _ free and clear of any Liens. 5. Engineer may refuse to recommend the whole or any part of any payment if, in Engineer's opinion, it would be incorrect to make the representations to Owner stated in Paragraph 14.02.13.2. Engineer may also refuse to recommend any such payment or, because of subsequently discovered evidence or the results of subsequent inspections or tests, revise or revoke any such payment recommendation previously made, to such extent as may be necessary in Engineer's opinion to protect Owner from loss because: a. the Work is defective, or completed Work has been damaged, requiring correction or replacement; b. the Contract Price has been reduced by Change Orders; c. Owner has been required to correct defective Work or complete Work in accordance with Paragraph 13.09; or d. Engineer has actual knowledge of the occurrence of any of the events enumerated in Paragraph 15.02.A. C. Payment Becomes Due: 1. Ten days after presentation of the Application for Payment to Owner with Engineer's recommendation, the amount recommended will (subject to the provisions of Paragraph 14.02.D) become due, and when due will be paid by Owner to Contractor. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright C 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 54 of 62 M M D. Reduction in Payment: 1. Owner may refuse to make payment of the full amount recommended by Engineer because: a. claims have been made against Owner on account of Contractor's performance or furnishing of the Work; b. Liens have been filed in connection with the Work, except where Contractor has delivered a specific bond satisfactory to Owner to secure the satisfaction and discharge of .. such Liens; c. there are other items entitling Owner to a set-off against the amount recommended; or Am d. Owner has actual knowledge of the occurrence of any of the events enumerated in Paragraphs 14.02.B.5.a through 14.02.B.5.c or Paragraph 15.02.A. 1W 2. If Owner refuses to make payment of the full amount recommended by Engineer, Owner will give Contractor immediate written notice (with a copy to Engineer) stating the reasons for such action and promptly pay Contractor any amount remaining after deduction of the amount so withheld. Owner shall promptly pay Contractor the amount so withheld, or any adjustment thereto agreed to by Owner and Contractor, when Contractor remedies the reasons for such action. 3. Upon a subsequent determination that Owner's refusal of payment was not justified, the amount wrongfully withheld shall be treated as an amount due as determined by Paragraph 14.02.C.1 and subject to interest as provided in the Agreement. 14.03 Contractor's Warranty of Title A. Contractor warrants and guarantees that title to all Work, materials, and equipment covered by �. any Application for Payment, whether incorporated in the Project or not, will pass to Owner no later than the time of payment free and clear of all Liens. 14.04 Substantial Completion A. When Contractor considers the entire Work ready for its intended use Contractor shall notify Owner and Engineer in writing that the entire Work is substantially complete (except for items specifically listed by Contractor as incomplete) and request that Engineer issue a certificate of Substantial Completion. i B. Promptly after Contractor's notification, Owner, Contractor, and Engineer shall make an inspection of the Work to determine the status of completion. If Engineer does not consider the Work substantially complete, Engineer will notify Contractor in writing giving the reasons therefor. C. If Engineer considers the Work substantially complete, Engineer will deliver to Owner a tentative certificate of Substantial Completion which shall fix the date of Substantial Completion. There shall be attached to the certificate a tentative list of items to be completed or corrected before EJCDC C-100 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 55 of 62 i 1. delivered in person to the individual or to a member of the firm or to an officer of the corporation for whom it is intended; or 2. delivered at or sent by registered or certified mail, postage prepaid, to the last business r, address known to the giver of the notice. 17.02 Computation of Times A. When any period of time is referred to in the Contract Documents by days, it will be computed to exclude the first and include the last day of such period. If the last day of any such period falls on on a Saturday or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction, such day will be omitted from the computation. 17.03 Cumulative Remedies A. The duties and obligations imposed by these General Conditions and the rights and remedies available hereunder to the parties hereto are in addition to, and are not to be construed in any way as a limitation of, any rights and remedies available to any or all of them which are otherwise imposed or available by Laws or Regulations, by special warranty or guarantee, or by other ,! provisions of the Contract Documents. The provisions of this Paragraph will be as effective as if repeated specifically in the Contract Documents in connection with each particular duty, obligation, right, and remedy to which they apply. 17.04 Survival of Obligations A. All representations, indemnifications, warranties, and guarantees made in, required by, or given in accordance with the Contract Documents, as well as all continuing obligations indicated in the Contract Documents, will survive final payment, completion, and acceptance of the Work or termination or completion of the Contract or termination of the services of Contractor. 17.05 Controlling Law A. This Contract is to be governed by the law of the state in which the Project is located. 17.06 Headings A. Article and paragraph headings are inserted for convenience only and do not constitute parts of these General Conditions. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 62 of 62 I STANDARD CITY CONDITIONS OF THE CONSTRUCTION CONTRACT FOR DEVELOPER AWARDED PROJECTS CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 STANDARD CITY CONDITIONS OF THE .� CONSTRUCTION CONTRACT FOR DEVELOPER AWARDED PROJECTS TABLE OF CONTENTS Page Article 1— Definitions and Terminology.......................................................................................................... I 1.01 Defined Terms...............................................................................................................................1 1.02 Terminology..................................................................................................................................5 Article2 — Preliminary Matters......................................................................................................................... 6 2.01 Before Starting Construction........................................................................................................6 2.02 Preconstruction Conference .......................................................................................................... 6 2.03 Public Meeting.............................................................................................................................. 6 Article 3 — Contract Documents and Amending............................................................................................... 6 3.01 Reference Standards..................................................................................................................... 6 3.02 Amending and Supplementing Contract Documents.................................................................. 6 Mw Article 4 — Bonds and Insurance....................................................................................................................... 7 4.01 Licensed Sureties and Insurers..................................................................................................... 7 4.02 Performance Payment, and Maintenance Bonds 7 on 4.03 Certificates of Insurance............................................................................................................... 7 4.04 Contractor's Insurance..................................................................................................................9 4.05 Acceptance of Bonds and Insurance; Option to Replace...........................................................12 Article 5 — Contractor's Responsibilities........................................................................................................12 5.01 Supervision and Superintendent.................................................................................................12 5.02 Labor; Working Hours................................................................................................................13 5.03 Services, Materials, and Equipment...........................................................................................13 5.04 Project Schedule..........................................................................................................................14 5.05 Substitutes and "Or-Equals".......................................................................................................14 5.06 Pre -Qualification of Bidders (Prime Contractors and Subcontractors).....................................16 5.07 Concerning Subcontractors, Suppliers, and Others...................................................................16 5.08 Wage Rates..................................................................................................................................18 5.09 Patent Fees and Royalties...........................................................................................................19 5.10 Laws and Regulations.................................................................................................................19 5.11 Use of Site and Other Areas .......................................................................................................19 5.12 Record Documents......................................................................................................................20 5.13 Safety and Protection.................................................................................................................. 21 5.14 Safety Representative................................................................................................................. 21 5.15 Hazard Communication Programs............................................................................................. 22 5.16 Submittals....................................................................................................................................22 5.17 Contractor's General Warranty and Guarantee..........................................................................23 CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 Aw w 5.18 Indemnification........................................................................................................................... 24 5.19 Delegation of Professional Design Services.............................................................................. 24 5.20 Right to Audit: :--* ... * .... ******"*'******"****'****"***"***'*"****"******'*'*********'**"** ... **""*"*****"*********"****** 25 �.I5.21 Nondiscrimination.......................................................................................................................25 Article 6 — Other Work at the Site................................................................................................................... 26 6.01 Related Work at Site................................................................................................................... 26 ,rt Article 7 — City's Responsibilities...................................................................................................................26 7.01 Inspections, Tests, and Approvals.............................................................................................. 26 0 7.02 Limitations on City's Responsibilities....................................................................................... 26 7.03 Compliance with Safety Program...............................................................................................27 Article 8 — City's Observation Status During Construction...........................................................................27 8.01 City's Project Representative.....................................................................................................27 8.02 Authorized Variations in Work..................................................................................................27 8.03 Rejecting Defective Work..........................................................................................................27 8.04 Determinations for Work Performed.......................................................................................... 28 Article9 Changes in the Work..................................................................................................................... 28 9.01 Authorized Changes in the Work...............................................................................................28 9.02 Notification to Surety.................................................................................................................. 28 Article 10 — Change of Contract Price; Change of Contract Time................................................................28 10.01 Change of Contract Price............................................................................................................28 10.02 Change of Contract Time............................................................................................................28 10.03 Delays..........................................................................................................................................28 Mi Article 11 — Tests and Inspections; Correction, Removal or Acceptance of Defective Work......................29 11.01 Notice of Defects........................................................................................................................29 11.02 Access to Work........................................................................................................................... 29 11.03 Tests and Inspections 11.04 Uncovering Work.......................................................................................................................30 nr 11.05 City May Stop the Work.............................................................................................................30 11.06 Correction or Removal of Defective Work................................................................................30 11.07 Correction Period........................................................................................................................ 30 - 11.08 City May Correct Defective Work............................................................................................. 31 Article12 — Completion.................................................................................................................................. 32 12.01 Contractor's Warranty of Title................................................................................................... 32 ' 12.02 Partial Utilization........................................................................................................................32 12.03 Final Inspection...........................................................................................................................32 12.04 Final Acceptance.........................................................................................................................33 Article13 — Suspension of Work.................................................................................................................... 33 13.01 City May Suspend Work............................................................................................................ 33 Article14 — Miscellaneous.............................................................................................................................. 34 14.01 Giving Notice..............................................................................................................................34 CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 M 0073 10-10 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 10 of 35 1) $100,000 each accident/occurrence 2) $100,000 Disease - each employee 3) $500,000 Disease - policy limit B. Commercial General Liability. Coverage shall include but not be limited to covering liability (bodily injury or property damage) arising from: premises/operations, independent contractors, products/completed operations, personal injury, and liability under an insured contract. Insurance shall be provided on an occurrence basis, and as comprehensive as the current Insurance Services Office (ISO) policy. This insurance shall apply as primary insurance with respect to any other insurance or self-insurance programs afforded to the City. The Commercial General Liability policy, shall have no exclusions by endorsements that would alter of nullify premises/operations, products/completed operations, contractual, personal injury, or advertising injury, which are normally contained with the policy, unless the City approves such exclusions in writing. 1. For construction projects that present a substantial completed operation exposure, the City may require the contractor to maintain completed operations coverage for a minimum of no less than three (3) years following the completion of the project 2. Contractor's Liability Insurance under this Section which shall be on a per project basis covering the Contractor with minimum limits of a. $1,000,000 each occurrence b. $2,000,000 aggregate limit 3. The policy must have an endorsement (Amendment — Aggregate Limits of Insurance) making the General Aggregate Limits apply separately to each job site. 4. The Commercial General Liability Insurance policies shall provide "X", "C", and "U" coverage's. Verification of such coverage must be shown in the Remarks Article of the Certificate of Insurance. C. Automobile Liability. A commercial business auto policy shall provide coverage on "any auto", defined as autos owned, hired and non -owned and provide indemnity for claims for damages because bodily injury or death of any person and or property damage arising out of the work, maintenance or use of any motor vehicle by the Contractor, any Subcontractor or Supplier, or by anyone directly or indirectly employed by any of them to perform any of the Work, or by anyone for whose acts any of them may be liable. 1. Automobile Liability, Contractor's Liability Insurance under this Section, which shall be in an amount not less than the following amounts: a. Automobile Liability - a commercial business policy shall provide coverage on "Any Auto", defined as autos owned, hired and non -owned. CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 f M ft am P" or. dor aw 0 M ft W .W N ri I 0073 10- I I Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page I I of 35 1) $1, 000, 000 each accident on a combined single limit basis. Split limits are acceptable if limits are at least: 2) $250,000 Bodily Injury per person 3) $500,000 Bodily Injury per accident / 4) $100,000 Property Damage D. Railroad Protective Liability. If any of the work or any warranty work is within the limits of railroad right-of-way, the Contractor shall comply with the following requirements: 1. The Contractor's construction activities will require its employees, agents, subcontractors, equipment, and material deliveries to cross railroad properties and tracks owned and operated by: None 2. The Contractor shall conduct its operations on railroad properties in such a manner as not to interfere with, hinder, or obstruct the railroad company in any manner whatsoever in the use or operation of its/their trains or other property. Such operations on railroad properties may require that Contractor to execute a "Right of Entry Agreement" with the particular railroad company or companies involved, and to this end the Contractor should satisfy itself as to the requirements of each railroad company and be prepared to execute the right -of -entry (if any) required by a railroad company. The requirements specified herein likewise relate to the Contractor's use of private and/or construction access roads crossing said railroad company's properties. 3. The Contractual Liability coverage required by Paragraph 5.04D of the General Conditions shall provide coverage for not less than the following amounts, issued by companies satisfactory to the City and to the Railroad Company for a term that continues for so long as the Contractor's operations and work cross, occupy, or touch railroad property: a. General Aggregate: None b. Each Occurrence:: None 4. With respect to the above outlined insurance requirements, the following shall govern: a. Where a single railroad company is involved, the Contractor shall provide one insurance policy in the name of the railroad company. However, if more than one grade separation or at -grade crossing is affected by the Project at entirely separate locations on the line or lines of the same railroad company, separate coverage may be required, each in the amount stated above. b. Where more than one railroad company is operating on the same right-of-way or where several railroad companies are involved and operated on their own separate rights -of - CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 0073 10- 12 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 12 of 35 way, the Contractor may be required to provide separate insurance policies in the name of each railroad company. c. If, in addition to a grade separation or an at -grade crossing, other work or activity is proposed on a railroad company's right-of-way at a location entirely separate from the t{ grade separation or at -grade crossing, insurance coverage for this work must be included in the policy covering the grade separation. d. If no grade separation is involved but other work is proposed on a railroad company's right-of-way, all such other work may be covered in a single policy for that railroad, even though the work may be at two or more separate locations. 5. No work or activities on a railroad company's property to be performed by the Contractor shall be commenced until the Contractor has furnished the City with an original policy or policies of the insurance for each railroad company named, as required above. All such insurance must be approved by the City and each affected Railroad Company prior to the Contractor's beginning work. 6. The insurance specified above must be carried until all Work to be performed on the railroad right-of-way has been completed and the grade crossing, if any, is no longer used by the Contractor. In addition, insurance must be carried during all maintenance and/or repair work performed in the railroad right-of-way. Such insurance must name the railroad company as the insured, together with any tenant or lessee of the railroad company operating over tracks involved in the Project. E. Notification of Policy Cancellation: Contractor shall immediately notify City upon cancellation or other loss of insurance coverage. Contractor shall stop work until replacement insurance has been procured. There shall be no time credit for days not worked pursuant to this section. 4.05 Acceptance of Bonds and Insurance; Option to Replace If City has any objection to the coverage afforded by or other provisions of the bonds or insurance required to be purchased and maintained by the Contractor in accordance with Article 5 on the basis of non-conformance with the Contract Documents, the Developer and City shall so notify the Contractor in writing within 10 Business Days after receipt of the certificates (or other evidence requested). Contractor shall provide to the City such additional information in respect of insurance provided as the Developer or City may reasonably request. If Contractor does not purchase or maintain all of the bonds and insurance required by the Contract Documents, the Developer or City shall notify the Contractor in writing of such failure prior to the start of the Work, or of such failure to maintain prior to any change in the required coverage. ARTICLE 5 — CONTRACTOR'S RESPONSIBILITIES 5.01 Supervision and Superintendent A. Contractor shall supervise, inspect, and direct the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 M 0073 10- 13 Standard City Conditions Of The Construction Contract For Developer Awarded Projects i Page 13 of35 Work in accordance with the Contract Documents. Contractor shall be solely responsible for the means, methods, techniques, sequences, and procedures of construction. B. At all times during the progress of the Work, Contractor shall assign a competent, English- speaking, Superintendent who shall not be replaced without written notice to City. The Superintendent will be Contractor's representative at the Site and shall have authority to act on behalf of Contractor. All communication given to or received from the Superintendent shall be i binding on Contractor. C. Contractor shall notify the City 24 hours prior to moving areas during the sequence of construction. 5.02 Labor; Working Hours MW A. Contractor shall provide competent, suitably qualified personnel to perform construction as required by the Contract Documents. Contractor shall at all times maintain good discipline and M, order at the Site. B. Except as otherwise required for the safety or protection of persons or the Work or property at the Site or adjacent thereto, and except as otherwise stated in the Contract Documents, all Work at the Site shall be performed during Regular Working Hours. Contractor will not permit the performance of Work beyond Regular Working Hours or for Weekend Working Hours without i City's written consent (which will not be unreasonably withheld). Written request (by letter or electronic communication) to perform Work: 1. for beyond Regular Working Hours request must be made by noon at least two (2) Business Days prior M 2. for Weekend Working Hours request must be made by noon of the preceding Thursday 3. for legal holidays request must be made by noon two Business Days prior to the legal MW holiday. 5.03 Services, Materials, and Equipment A. Unless otherwise specified in the Contract Documents, Contractor shall provide and assume full responsibility for all services, materials, equipment, labor, transportation, construction equipment and machinery, tools, appliances, fuel, power, light, heat, telephone, water, sanitary facilities, temporary facilities, and all other facilities and incidentals necessary for the performance, Contractor required testing, start-up, and completion of the Work. B. All materials and equipment incorporated into the Work shall be as specified or, if not specified, shall be of good quality and new, except as otherwise provided in the Contract Documents. All special warranties and guarantees required by the Specifications shall expressly run to the benefit i of City. If required by City, Contractor shall furnish satisfactory evidence (including reports of required tests) as to the source, kind, and quality of materials and equipment. i CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 0073 10- 14 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 14 of 35 .., C. All materials and equipment to be incorporated into the Work shall be stored, applied, installed, connected, erected, protected, used, cleaned, and conditioned in accordance with instructions of Mh the applicable Supplier, except as otherwise may be provided in the Contract Documents. 5.04 Project Schedule A. Contractor shall adhere to the Project Schedule established in accordance with Paragraph 2.01 and the General Requirements as it may be adjusted from time to time as provided below. 1. Contractor shall submit to City for acceptance (to the extent indicated in Paragraph 2.01 and the General Requirements) proposed adjustments in the Project Schedule. _ 2. Proposed adjustments in the Project Schedule that will change the Contract Time shall be submitted in accordance with the requirements of Article 9. Adjustments in Contract Time for projects with City participation shall be made by participating change orders. 5.05 Substitutes and "Or -Equals" A. Whenever an item of material or equipment is specified or described in the Contract Documents by using the name of a proprietary item or the name of a particular Supplier, the specification or description is intended to establish the type, function, appearance, and quality required. Unless the specification or description contains or is followed by words reading that no like, equivalent, or "or -equal" item or no substitution is permitted, other items of material or equipment of other Suppliers may be submitted to City for review under the circumstances described below. i 1. "Or -Equal" Items: If in City's sole discretion an item of material or equipment proposed by Contractor is functionally equal to that named and sufficiently similar so that no change in related Work will be required, it may be considered by City as an "or -equal" item, in which case review and approval of the proposed item may, in City's sole discretion, be accomplished without compliance with some or all of the requirements for approval of proposed substitute items. For the purposes of this Paragraph 5.05.A.1, a proposed item of material or equipment will be considered functionally equal to an item so named if. a. City determines that: 1) it is at least equal in materials of construction, quality, durability, appearance, ~` strength, and design characteristics; 2) it will reliably perform at least equally well the function and achieve the results imposed by the design concept of the completed Project as a functioning whole; and 3) it has a proven record of performance and availability of responsive service; and b. Contractor certifies that, if approved and incorporated into the Work: 1) there will be no increase in cost to the City or increase in Contract Time; and CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 0073 10- 15 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 15 of 35 2) it will conform substantially to the detailed requirements of the item named in the -� Contract Documents. 2. Substitute Items: a. If in City's sole discretion an item of material or equipment proposed by Contractor does not qualify as an "or -equal" item under Paragraph 5.05.A.1, it may be submitted as a proposed substitute item. b. Contractor shall submit sufficient information as provided below to allow City to determine if the item of material or equipment proposed is essentially equivalent to that named and an acceptable substitute therefor. Requests for review of proposed substitute items of material or equipment will not be accepted by City from anyone other than - Contractor. c. Contractor shall make written application to City for review of a proposed substitute item of material or equipment that Contractor seeks to furnish or use. The application shall comply with Section 0125 00 and: 1) shall certify that the proposed substitute item will: i. perform adequately the functions and achieve the results called for by the general design; ii. be similar in substance to that specified; iii. be suited to the same use as that specified; and 2) will state: i. the extent, if any, to which the use of the proposed substitute item will prejudice Contractor's achievement of final completion on time; ii. whether use of the proposed substitute item in the Work will require a change in any of the Contract Documents (or in the provisions of any other direct contract with City for other work on the Project) to adapt the design to the proposed substitute item; iii. whether incorporation or use of the proposed substitute item in connection with the Work is subject to payment of any license fee or royalty; and i 3) will identify: Oik M. i. all variations of the proposed substitute item from that specified; ii. available engineering, sales, maintenance, repair, and replacement services; and CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 0073 10- 16 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 16 of 35 4) shall contain an itemized estimate of all costs or credits that will result directly or indirectly from use of such substitute item, including costs of redesign and Damage .. Claims of other contractors affected by any resulting change. B. Substitute Construction Methods or Procedures: If a specific means, method, technique, sequence, or procedure of construction is expressly required by the Contract Documents, Contractor may furnish or utilize a substitute means, method, technique, sequence, or procedure of construction approved by City. Contractor shall submit sufficient information to allow City, in — City's sole discretion, to determine that the substitute proposed is equivalent to that expressly called for by the Contract Documents. Contractor shall make written application to City for review in the same manner as those provided in Paragraph 5.05.A.2. C. City's Evaluation: City will be allowed a reasonable time within which to evaluate each proposal or submittal made pursuant to Paragraphs 5.05.A and 5.05.13. City may require — Contractor to furnish additional data about the proposed substitute. City will be the sole judge of acceptability. No "or -equal" or substitute will be ordered, installed or utilized until City's review is complete, which will be evidenced by a Change Order in the case of a substitute and an accepted Submittal for an "or -equal." City will advise Contractor in writing of its determination. D. Special Guarantee: City may require Contractor to furnish at Contractor's expense a special performance guarantee, warranty, or other surety with respect to any substitute. Contractor shall indemnify and hold harmless City and anyone directly or indirectly employed by them from and against any and all claims, damages, losses and expenses (including attorneys fees) arising out — of the use of substituted materials or equipment. E. City's Cost Reimbursement: City will record City's costs in evaluating a substitute proposed or submitted by Contractor pursuant to Paragraphs 5.05.A.2 and 5.05.13. Whether or not City approves a substitute so proposed or submitted by Contractor, Contractor may be required to reimburse City for evaluating each such proposed substitute. Contractor may also be required to reimburse City for the charges for making changes in the Contract Documents. F. Contractor's Expense: Contractor shall provide all data in support of any proposed substitute or "or -equal" at Contractor's expense. G. Substitute Reimbursement: Costs (savings or charges) attributable to acceptance of a substitute t shall be incorporated to the Contract by Participating Change Order. 5.06 Pre -Qualification of Bidders (Prime Contractors and Subcontractors) A. The Contractor and any subcontractors are required to be prequalified for the work types requiring pre -qualification 5.07 Concerning Subcontractors, Suppliers, and Others A. Minority and Women Owned Business Enterprise Compliance: CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 M 0073 10- 17 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 17 of 35 ❑ Required for this Contract. ® Not Required for this Contract. It is City policy to ensure the full and equitable participation by Minority and Women Business Enterprises (MWBE) in the procurement of goods and services on a contractual basis. If the Contract Documents provide for a MWBE goal, Contractor is required to comply with the intent of the City's MWBE Ordinance (as amended) by the following: 1. Contractor shall, upon request by City, provide complete and accurate information regarding actual work performed by a MWBE on the Contract and payment therefor. 2. Contractor will not make additions, deletions, or substitutions of accepted MWBE without Mo written consent of the City. Any unjustified change or deletion shall be a material breach of Contract and may result in debarment in accordance with the procedures outlined in the Ordinance. 3. Contractor shall, upon request by City, allow an audit and/or examination of any books, records, or files in the possession of the Contractor that will substantiate the actual work performed by an MWBE. Material misrepresentation of any nature will be grounds for termination of the Contract. Any such misrepresentation may be grounds for disqualification of Contractor to bid on future contracts with the City for a period of not less than three years. B. Contractor shall be fully responsible to City for all acts and omissions of the Subcontractors, Suppliers, and other individuals or entities performing or furnishing any of the Work just as Contractor is responsible for Contractor's own acts and omissions. Nothing in the Contract Documents: 1. shall create for the benefit of any such Subcontractor, Supplier, or other individual or entity any contractual relationship between City and any such Subcontractor, Supplier or other individual or entity; nor i 2. shall create any obligation on the part of City to pay or to see to the payment of any moneys due any such Subcontractor, Supplier, or other individual or entity except as may otherwise ..� be required by Laws and Regulations. C. Contractor shall be solely responsible for scheduling and coordinating the Work of Subcontractors, Suppliers, and other individuals or entities performing or furnishing any of the Work under a direct or indirect contract with Contractor. D. All Subcontractors, Suppliers, and such other individuals or entities performing or furnishing any of the Work shall communicate with City through Contractor. E. All Work performed for Contractor by a Subcontractor or Supplier will be pursuant to an appropriate agreement between Contractor and the Subcontractor or Supplier which specifically binds the Subcontractor or Supplier to the applicable terms and conditions of these Contract CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 0073 10- 18 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 18 of35 Documents, Contractor shall provide City contract numbers and reference numbers to the Subcontractors and/or Suppliers. 5.08 Wage Rates ❑ Required for this Contract. ® Not Required for this Contract. A. Duty to pay Prevailing Wage Rates. The Contractor shall comply with all requirements of Chapter 2258, Texas Government Code (as amended), including the payment of not less than the rates determined by the City Council of the City of Fort Worth to be the prevailing wage rates in accordance with Chapter 2258. Such prevailing wage rates are included in these Contract Documents. B. Penalty for Violation. A Contractor or any Subcontractor who does not pay the prevailing wage shall, upon demand made by the City, pay to the City $60 for each worker employed for each s calendar day or part of the day that the worker is paid less than the prevailing wage rates stipulated in these contract documents. This penalty shall be retained by the City to offset its administrative costs, pursuant to Texas Government Code 2258.023. .� C. Complaints of Violations and City Determination of Good Cause. On receipt of information, including a complaint by a worker, concerning an alleged violation of 2258.023, Texas _ Government Code, by a Contractor or Subcontractor, the City shall make an initial determination, before the 31 st day after the date the City receives the information, as to whether good cause exists to believe that the violation occurred. The City shall notify in writing the _ Contractor or Subcontractor and any affected worker of its initial determination. Upon the City's determination that there is good cause to believe the Contractor or Subcontractor has violated Chapter 2258, the City shall retain the full amounts claimed by the claimant or claimants as the difference between wages paid and wages due under the prevailing wage rates, such amounts being subtracted from successive progress payments pending a final determination of the violation. — D. Arbitration Required if Violation Not Resolved. An issue relating to an alleged violation of Section 2258.023, Texas Government Code, including a penalty owed to the City or an affected worker, shall be submitted to binding arbitration in accordance with the Texas General Arbitration Act (Article 224 et seq., Revised Statutes) if the Contractor or Subcontractor and any affected worker does not resolve the issue by agreement before the 15th day after the date the City makes its initial determination pursuant to Paragraph C above. If the persons required to arbitrate under this section do not agree on an arbitrator before the 11 th day after the date that arbitration is required, a district court shall appoint an arbitrator on the petition of any of the T- persons. The City is not a party in the arbitration. The decision and award of the arbitrator is final and binding on all parties and may be enforced in any court of competent jurisdiction. E. Records to be Maintained. The Contractor and each Subcontractor shall, for a period of three (3) years following the date of acceptance of the work, maintain records that show (i) the name and CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 0073 10- 19 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 19 of 35 occupation of each worker employed by the Contractor in the construction of the Work provided for in this Contract; and (ii) the actual per diem wages paid to each worker. The records shall be open at all reasonable hours for inspection by the City. The provisions of Paragraph 6.23, Right to Audit, shall pertain to this inspection. F. Progress Payments. With each progress payment or payroll period, whichever is less, the Contractor shall submit an affidavit stating that the Contractor has complied with the requirements of Chapter 2258, Texas Government Code. G. Posting of Wage Rates. The Contractor shall post prevailing wage rates in a conspicuous place at all times. H. Subcontractor Compliance. The Contractor shall include in its subcontracts and/or shall otherwise require all of its Subcontractors to comply with Paragraphs A through G above. 5.09 Patent Fees and Royalties A. To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless City, from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to any infringement of patent rights or copyrights incident to the use in the performance of the Work or resulting from the incorporation in the Work of any invention, design, process, product, or device not specified in the Contract Documents. 5.10 Laws and Regulations A. Contractor shall give all notices required by and shall comply with all Laws and Regulations applicable to the performance of the Work. Except where otherwise expressly required by applicable Laws and Regulations, the City shall not be responsible for monitoring Contractor's compliance with any Laws or Regulations. B. If Contractor performs any Work knowing or having reason to know that it is contrary to Laws or Regulations, Contractor shall bear all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such Work. However, it shall not be Contractor's responsibility to make certain that the Specifications and Drawings are in accordance with Laws and Regulations, but this shall not relieve Contractor of Contractor's obligations under Paragraph 3.01. 5.11 Use of Site and Other Areas A. Limitation on Use of Site and Other Areas: 1. Contractor shall confine construction equipment, the storage of materials and equipment, and the operations of workers to the Site and other areas permitted by Laws and Regulations, and shall not unreasonably encumber the Site and other areas with construction equipment or CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 0073 10- 20 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 20 of 35 other materials or equipment. Contractor shall assume full responsibility for any damage to any such land or area, or to the owner or occupant thereof, or of any adjacent land or areas .� resulting from the performance of the Work. 2. At any time when, in the judgment of the City, the Contractor has obstructed or closed or is carrying on operations in a portion of a street, right-of-way, or easement greater than is necessary for proper execution of the Work, the City may require the Contractor to finish the section on which operations are in progress before work is commenced on any additional area of the Site. 3. Should any Damage Claim be made by any such owner or occupant because of the performance of the Work, Contractor shall promptly attempt to resolve the Damage Claim. 4. Pursuant to Paragraph 5.18, Contractor shall indemnify and hold harmless City, from and against all claims, costs, losses, and damages arising out of or relating to any claim or action, legal or equitable, brought by any such owner or occupant against City. B. Removal of Debris During Performance of the Work: During the progress of the Work Contractor shall keep the Site and other areas free from accumulations of waste materials, rubbish, and other debris. Removal and disposal of such waste materials, rubbish, and other _ debris shall conform to applicable Laws and Regulations. C. Site Maintenance Cleaning: 24 hours after written notice is given to the Contractor that the clean-up on the job site is proceeding in a manner unsatisfactory to the City or Developer, if the Contractor fails to correct the unsatisfactory procedure, the City may take such direct action as the City deems appropriate to correct the clean-up deficiencies cited to the Contractor in the written notice (by letter or electronic communication), and shall be entitled to recover its cost in doing so. The City may withhold Final Acceptance until clean-up is complete and cost are recovered. _ D. Final Site Cleaning: Prior to Final Acceptance of the Work Contractor shall clean the Site and the Work and make it ready for utilization by City or adjacent property owner. At the completion of the Work Contractor shall remove from the Site all tools, appliances, construction equipment and machinery, and surplus materials and shall restore to original condition or better all property disturbed by the Work. _ E. Loading Structures: Contractor shall not load nor permit any part of any structure to be loaded in any manner that will endanger the structure, nor shall Contractor subject any part of the Work or adjacent property to stresses or pressures that will endanger it. 5.12 Record Documents A. Contractor shall maintain in a safe place at the Site or in a place designated by the Contractor and approved by the City, one (1) record copy of all Drawings, Specifications, Addenda, Change Orders, Field Orders, and written interpretations and clarifications in good order and annotated to show changes made during construction. These record documents together with all approved CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 0073 10- 21 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 21 of 35 Samples and a counterpart of all accepted Submittals will be available to City for reference. �- Upon completion of the Work, these record documents, any operation and maintenance manuals, and Submittals will be delivered to City prior to Final Inspection. Contractor shall include accurate locations for buried and imbedded items. 5.13 Safety and Protection A. Contractor shall be solely responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the Work. Such responsibility does not relieve Subcontractors of their responsibility for the safety of persons or property in the performance of their work, nor for compliance with applicable safety Laws and Regulations. Contractor shall take all necessary precautions for the safety of, and shall provide the necessary protection to prevent damage, injury or loss to: 1. all persons on the Site or who may be affected by the Work; ,.. 2. all the Work and materials and equipment to be incorporated therein, whether in storage on or off the Site; and 3. other property at the Site or adjacent thereto, including trees, shrubs, lawns, walks, pavements, roadways, structures, utilities, and Underground Facilities not designated for removal, relocation, or replacement in the course of construction. B. Contractor shall comply with all applicable Laws and Regulations relating to the safety of persons or property, or to the protection of persons or property from damage, injury, or loss; and shall erect and maintain all necessary safeguards for such safety and protection. Contractor shall notify owners of adjacent property and of Underground Facilities and other utility owners when prosecution of the Work may affect them, and shall cooperate with them in the protection, .. removal, relocation, and replacement of their property. C. Contractor shall comply with the applicable requirements of City's safety programs, if any. D. Contractor shall inform City of the specific requirements of Contractor's safety program, if any, with which City's employees and representatives must comply while at the Site. E. All damage, injury, or loss to any property referred to in Paragraph 5.13.A.2 or 5.13.A.3 caused, directly or indirectly, in whole or in part, by Contractor, any Subcontractor, Supplier, or any other individual or entity directly or indirectly employed by any of them to perform any of the Work, or anyone for whose acts any of them may be liable, shall be remedied by Contractor. F. Contractor's duties and responsibilities for safety and for protection of the Work shall continue until such time as all the Work is completed and City has accepted the Work. 5.14 Safety Representative Contractor shall inform City in writing of Contractor's designated safety representative at the Site. CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 0073 10- 22 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 22 of 35 5.15 Hazard Communication Programs Contractor shall be responsible for coordinating any exchange of material safety data sheets or other hazard communication information required to be made available to or exchanged between or among employers in accordance with Laws or Regulations. 5.16 Submittals A. Contractor shall submit required Submittals to City for review and acceptance. Each submittal will be identified as required by City. 1. Submit number of copies specified in the General Requirements. 2. Data shown on the Submittals will be complete with respect to quantities, dimensions, specified performance and design criteria, materials, and similar data to show City the services, materials, and equipment Contractor proposes to provide and to enable City to review the information for the limited purposes required by Paragraph 5.16.C. 3. Submittals submitted as herein provided by Contractor and reviewed by City for conformance with the design concept shall be executed in conformity with the Contract Documents unless otherwise required by City. 4. When Submittals are submitted for the purpose of showing the installation in greater detail, their review shall not excuse Contractor from requirements shown on the Drawings and Specifications. 5. For -Information -Only submittals upon which the City is not expected to conduct review or take responsive action may be so identified in the Contract Documents. 6. Submit required number of Samples specified in the Specifications. 7. Clearly identify each Sample as to material, Supplier, pertinent data such as catalog numbers, the use for which intended and other data as City may require to enable City to review the submittal for the limited purposes required by Paragraph 5.16.C. B. Where a Submittal is required by the Contract Documents or the Schedule of Submittals, any — related Work performed prior to City's review and acceptance of the pertinent submittal will be at the sole expense and responsibility of Contractor. C. City's Review: 1. City will provide timely review of required Submittals in accordance with the Schedule of — Submittals acceptable to City. City's review and acceptance will be only to determine if the items covered by the submittals will, after installation or incorporation in the Work, conform to the information given in the Contract Documents and be compatible with the design - concept of the completed Project as a functioning whole as indicated by the Contract Documents. CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 0073 10- 23 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 23 of 35 2. City's review and acceptance will not extend to means, methods, techniques, sequences, or procedures of construction (except where a particular means, method, technique, sequence, or procedure of construction is specifically and expressly called for by the Contract Documents) or to safety precautions or programs incident thereto. The review and acceptance of a separate item as such will not indicate approval of the assembly in which the item functions. 3. City's review and acceptance shall not relieve Contractor from responsibility for any variation from the requirements of the Contract Documents unless Contractor has complied with the requirements of Section 01 33 00 and City has given written acceptance of each such variation by specific written notation thereof incorporated in or accompanying the Submittal. City's review and acceptance shall not relieve Contractor from responsibility for complying with the requirements of the Contract Documents. 5.17 Contractor's General Warranty and Guarantee -- A. Contractor warrants and guarantees to City that all Work will be in accordance with the Contract Documents and will not be defective. City and its officers, directors, members, partners, employees, agents, consultants, and subcontractors shall be entitled to rely on representation of Contractor's warranty and guarantee. B. Contractor's warranty and guarantee hereunder excludes defects or damage caused by: 1. abuse, modification, or improper maintenance or operation by persons other than Contractor, Subcontractors, Suppliers, or any other individual or entity for whom Contractor is responsible; or 2. normal wear and tear under normal usage. C. Contractor's obligation to perform and complete the Work in accordance with the Contract Documents shall be absolute. None of the following will constitute an acceptance of Work that is not in accordance with the Contract Documents or a release of Contractor's obligation to perform the Work in accordance with the Contract Documents: 1. observations by City; 2. recommendation or payment by City or Developer of any progress or final payment; 3. the issuance of a certificate of Final Acceptance by City or any payment related thereto by City; 4. use or occupancy of the Work or any part thereof by City; 5. any review and acceptance of a Submittal by City; 6. any inspection, test, or approval by others; or CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 0073 10- 24 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 24 of 35 7. any correction of defective Work by City. D. The Contractor shall remedy any defects or damages in the Work and pay for any damage to other work or property resulting therefrom which shall appear within a period of two (2) years from the date of Final Acceptance of the Work unless a longer period is specified and shall famish a good and sufficient maintenance bond, complying with the requirements of Article 4.02.13. The City will give notice of observed defects with reasonable promptness. 5.18 Indemnification A. Contractor covenants and agrees to indemnify, hold harmless and defend, at its own expense, the City, its officers, servants and employees, from and against any and all claims arising out of, or alleged to arise out of, the work and services to be performed by the Contractor, its officers, agents, employees, subcontractors, licenses or invitees under this Contract. THIS INDEMNIFICATION PROVISION IS SPECIFICALLY INTENDED TO OPERATE AND BE EFFECTIVE EVEN IF IT IS ALLEGED OR PROVEN THAT ALL OR SOME OF THE DAMAGES BEING SOUGHT WERE CAUSED. IN WHOLE OR IN PART. BY ANY ACT, OMISSION OR NEGLIGENCE OF THE CITY. This indemnity provision is intended to include, without limitation, indemnity for costs, expenses and legal fees incurred by the City in defending against such claims and causes of actions. _ B. Contractor covenants and agrees to indemnify and hold harmless, at its own expense, the City, its officers, servants and employees, from and against any and all loss, damage or destruction of property of the City, arising out of, or alleged to arise out of, the work and services to be performed by the Contractor, its officers, agents, employees, subcontractors, licensees or invitees under this Contract. THIS INDEMNIFICATION PROVISION IS SPECIFICALLY �. INTENDED TO OPERATE AND BE EFFECTIVE EVEN IF IT IS ALLEGED OR PROVEN THAT ALL OR SOME OF THE DAMAGES BEING SOUGHT WERE CAUSED, IN WHOLE OR IN PART, BY ANY ACT, OMISSION OR NEGLIGENCE OF THE CITY. 5.19 Delegation of Professional Design Services A. Contractor will not be required to provide professional design services unless such services are specifically required by the Contract Documents for a portion of the Work or unless such services are required to carry out Contractor's responsibilities for construction means, methods, techniques, sequences and procedures. B. If professional design services or certifications by a design professional related to systems, materials or equipment are specifically required of Contractor by the Contract Documents, City will specify all performance and design criteria that such services must satisfy. Contractor shall cause such services or certifications to be provided by a properly licensed professional, whose signature and seal shall appear on all drawings, calculations, specifications, certifications, and Submittals prepared by such professional. Submittals related to the Work designed or certified by such professional, if prepared by others, shall bear such professional's written approval when submitted to City. CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 i 0073 10- 25 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 25 of 35 C. City shall be entitled to rely upon the adequacy, accuracy and completeness of the services, certifications or approvals performed by such design professionals, provided City has specified to Contractor performance and design criteria that such services must satisfy. D. Pursuant to this Paragraph 5.19, City's review and acceptance of design calculations and design drawings will be only for the limited purpose of checking for conformance with performance and design criteria given and the design concept expressed in the Contract Documents. City's review and acceptance of Submittals (except design calculations and design drawings) will be only for the purpose stated in Paragraph 5.16.C. 5.20 Right to Audit: A. The City reserves the right to audit all projects utilizing City funds B. The Contractor agrees that the City shall, until the expiration of three (3) years after final payment under this Contract, have access to and the right to examine and photocopy any directly pertinent books, documents, papers, and records of the Contractor involving transactions relating to this Contract. Contractor agrees that the City shall have access during Regular Working Hours to all necessary Contractor facilities and shall be provided adequate and appropriate work space in order to conduct audits in compliance with the provisions of this Paragraph. The City shall give Contractor reasonable advance notice of intended audits. C. Contractor further agrees to include in all its subcontracts hereunder a provision to the effect that the subcontractor agrees that the City shall, until the expiration of three (3) years after final payment under this Contract, have access to and the right to examine and photocopy any directly pertinent books, documents, papers, and records of such Subcontractor, involving transactions to the subcontract, and further, that City shall have access during Regular Working Hours to all Subcontractor facilities, and shall be provided adequate and appropriate work space in order to conduct audits in compliance with the provisions of this Paragraph. The City shall give Subcontractor reasonable advance notice of intended audits. D. Contractor and Subcontractor agree to photocopy such documents as may be requested by the City. The City agrees to reimburse Contractor for the cost of the copies as follows at the rate published in the Texas Administrative Code in effect as of the time copying is performed. 5.21 Nondiscrimination A. The City is responsible for operating Public Transportation Programs and implementing transit - related projects, which are funded in part with Federal financial assistance awarded by the U.S. Department of Transportation and the Federal Transit Administration (FTA), without discriminating against any person in the United States on the basis of race, color, or national origin. ,o B. Title VI, Civil Rights Act of 1964 as amended: Contractor shall comply with the requirements of the Act and the Regulations as further defined in the Supplementary Conditions for any project receiving Federal assistance. CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 0073 10- 26 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 26 of 35 �. ARTICLE 6 — OTHER WORK AT THE SITE 6.01 Related Work at Site A. City may perform other work related to the Project at the Site with City's employees, or other _ City contractors, or through other direct contracts therefor, or have other work performed by utility owners. If such other work is not noted in the Contract Documents, then written notice thereof will be given to Contractor prior to starting any such other work; and B. Contractor shall afford each other contractor who is a party to such a direct contract, each utility owner, and City, if City is performing other work with City's employees or other City _ contractors, proper and safe access to the Site, provide a reasonable opportunity for the introduction and storage of materials and equipment and the execution of such other work, and properly coordinate the Work with theirs. Contractor shall do all cutting, fitting, and patching of _ the Work that may be required to properly connect or otherwise make its several parts come together and properly integrate with such other work. Contractor shall not endanger any work of others by cutting, excavating, or otherwise altering such work; provided, however, that _ Contractor may cut or alter others' work with the written consent of City and the others whose work will be affected. C. If the proper execution or results of any part of Contractor's Work depends upon work performed by others under this Article 7, Contractor shall inspect such other work and promptly report to City in writing any delays, defects, or deficiencies in such other work that render it unavailable or unsuitable for the proper execution and results of Contractor's Work. Contractor's failure to so report will constitute an acceptance of such other work as fit and proper for integration with Contractor's Work except for latent defects in the work provided by others. ARTICLE 7 — CITY'S RESPONSIBILITIES 7.01 Inspections, Tests, and Approvals City's responsibility with respect to certain inspections, tests, and approvals is set forth in Paragraph 11.03. 7.02 Limitations on City's Responsibilities A. The City shall not supervise, direct, or have control or authority over, nor be responsible for, Contractor's means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the performance of the Work. City will not be responsible for Contractor's failure to perform the Work in accordance with the Contract Documents. B. City will notify the Contractor of applicable safety plans pursuant to Paragraph 5.13. CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 0073 10- 27 Standard City Conditions Of The Construction Contract For Developer Awarded Projects �~ Page 27 of 35 7.03 Compliance with Safety Program While at the Site, City's employees and representatives shall comply with the specific applicable requirements of Contractor's safety programs of which City has been informed pursuant to Paragraph 5.13. ARTICLE 8 — CITY'S OBSERVATION STATUS DURING CONSTRUCTION 8.01 City's Project Representative City will provide one or more Project Representative(s) during the construction period. The duties and responsibilities and the limitations of authority of City's representative during construction are set forth in the Contract Documents. A. City's Project Representative will make visits to the Site at intervals appropriate to the various stages of construction as City deems necessary in order to observe the progress that has been made and the quality of the various aspects of Contractor's executed Work. Based on information obtained during such visits and observations, City's Project Representative will determine, in general, if the Work is proceeding in accordance with the Contract Documents. City's Project Representative will not be required to make exhaustive or continuous inspections on the Site to check the quality or quantity of the Work. City's Project Representative's efforts will be directed toward providing City a greater degree of confidence that the completed Work M will conform generally to the Contract Documents. B. City's Project Representative's visits and observations are subject to all the limitations on authority and responsibility in the Contract Documents. 8.02 Authorized Variations in Work City's Project Representative may authorize minor variations in the Work from the requirements of the Contract Documents which do not involve an adjustment in the Contract Price or the Contract Time and are compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. These may be accomplished by a Field Order and will be binding on City Developer, and also on Contractor, who shall perform the Work involved promptly. 8.03 Rejecting Defective Work City will have authority to reject Work which City's Project Representative believes to be defective, or will not produce a completed Project that conforms to the Contract Documents or that will prejudice the integrity of the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. City will have authority to conduct special inspection or testing of the Work as provided in Article 11, whether or not the Work is fabricated, installed, or completed. CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 00 73 10- 28 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 28 of 35 8.04 Determinations for Work Performed Contractor will determine the actual quantities and classifications of Work performed. City's Project Representative will review with Contractor the preliminary determinations on such matters before rendering a written recommendation. City's written decision will be final (except as modified to reflect changed factual conditions or more accurate data). ARTICLE 9 — CHANGES IN THE WORK 9.01 Authorized Changes in the Work A. Without invalidating the Contract and without notice to any surety, City may, at any time or from time to time, order Extra Work. Upon notice of such Extra Work, Contractor shall promptly proceed with the Work involved which will be performed under the applicable conditions of the Contract Documents (except as otherwise specifically provided). Extra Work shall be memorialized by a Participating Change Order which may or may not precede an order of Extra work. _ B. For minor changes of Work not requiring changes to Contract Time or Contract Price on a project with City participation, a Field Order may be issued by the City. OW 9.02 Notification to Surety If the provisions of any bond require notice to be given to a surety of any change affecting the general scope of the Work or the provisions of the Contract Documents (including, but not limited to, Contract Price or Contract Time), the giving of any such notice will be Contractor's responsibility. The amount of each applicable bond will be adjusted by the Contractor to reflect the effect of any such change. ARTICLE 10 — CHANGE OF CONTRACT PRICE; CHANGE OF CONTRACT TIME 10.01 Change of Contract Price A. The Contract Price may only be changed by a Participating Change Order for projects with City participation. 10.02 Change of Contract Time A. The Contract Time may only be changed by a Participating Change Order for projects with City op participation. 10.03 Delays A. If Contractor is delayed, City shall not be liable to Contractor for any claims, costs, losses, or damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) sustained by Contractor on or in connection with any other project or anticipated project. CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 i oft 0073 10- 29 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 29 of 35 ARTICLE 11— TESTS AND INSPECTIONS; CORRECTION, REMOVAL OR ACCEPTANCE OF DEFECTIVE WORK 11.01 Notice of Defects Notice of all defective Work of which City has actual knowledge will be given to Contractor. Defective Work may be rejected, corrected, or accepted as provided in this Article 13. 11.02 Access to Work City, independent testing laboratories, and governmental agencies with jurisdictional interests will have access to the Site and the Work at reasonable times for their observation, inspection, and testing. Contractor shall provide them proper and safe conditions for such access and advise them of Contractor's safety procedures and programs so that they may comply therewith as applicable. 11.03 Tests and Inspections A. Contractor shall give City timely notice of readiness of the Work for all required inspections, tests, or approvals and shall cooperate with inspection and testing personnel to facilitate required inspections or tests. B. If Contract Documents, Laws or Regulations of any public body having jurisdiction require any of the Work (or part thereof) to be inspected, tested, or approved, Contractor shall assume full responsibility for arranging and obtaining such independent inspections, tests, retests or approvals, pay all costs in connection therewith, and furnish City the required certificates of inspection or approval; excepting, however, those fees specifically identified in the i Supplementary Conditions or any Texas Department of Licensure and Regulation (TDLR) inspections, which shall be paid as described in the Supplementary Conditions. C. Contractor shall be responsible for arranging and obtaining and shall pay all costs in connection with any inspections, tests, re -tests, or approvals required for City's acceptance of materials or equipment to be incorporated in the Work; or acceptance of materials, mix designs, or equipment submitted for approval prior to Contractor's purchase thereof for incorporation in the Work. Such inspections, tests, re -tests, or approvals shall be performed by organizations approved by City. D. City may arrange for the services of an independent testing laboratory ("Testing Lab") to perform any inspections or tests ("Testing") for any part of the Work, as determined solely by City. 1. City will coordinate such Testing to the extent possible, with Contractor; i 2. Should any Testing under this Section 11.03 D result in a "fail", "did not pass" or other similar negative result, the Contractor shall be responsible for paying for any and all retests. Contractor's cancellation without cause of City initiated Testing shall be deemed a negative result and require a retest. Am CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 EM 0073 10- 30 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 30 of 35 PM 3. Any amounts owed for any retest under this Section 11.03 D shall be paid directly to the Testing Lab by Contractor. City will forward all invoices for retests to dM Developer/Contractor. 4. If Contractor fails to pay the Testing Lab, City will not issue a letter of Final Acceptance i until the Testing Lab is Paid E. If any Work (or the work of others) that is to be inspected, tested, or approved is covered by o, Contractor without written concurrence of City, Contractor shall, if requested by City, uncover such Work for observation. MM 11.04 Uncovering Work A. If any Work is covered contrary to the Contract Documents or specific instructions by the City, it w must, if requested by City, be uncovered for City's observation and replaced at Contractor's expense. 11.05 City May Stop the Work If the Work is defective, or Contractor fails to supply sufficient skilled workers or suitable materials or equipment, or fails to perform the Work in such a way that the completed Work will conform to the Contract Documents, City may order Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, this right of City to stop the Work shall not i give rise to any duty on the part of City to exercise this right for the benefit of Contractor, any Subcontractor, any Supplier, any other individual or entity, or any surety for, or employee or agent of any of them. i 11.06 Correction or Removal of Defective Work A. Promptly after receipt of written notice, Contractor shall correct all defective Work pursuant to an acceptable schedule, whether or not fabricated, installed, or completed, or, if the Work has been rejected by City, remove it from the Project and replace it with Work that is not defective. Contractor shall pay all claims, costs, additional testing, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such correction or removal (including but not limited to all costs of repair or replacement of work of others). Failure to require the removal of any defective Work shall not constitute acceptance of such Work. i B. When correcting defective Work under the terms of this Paragraph 11.06 or Paragraph 11.07, Contractor shall take no action that would void or otherwise impair City's special warranty and i guarantee, if any, on said Work. 11.07 Correction Period A. If within two (2) years after the date of Final Acceptance (or such longer period of time as may be prescribed by the terms of any applicable special guarantee required by the Contract CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 OM 0073 10- 31 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 31 of 35 Documents), any Work is found to be defective, or if the repair of any damages to the land or •- areas made available for Contractor's use by City or permitted by Laws and Regulations as contemplated in Paragraph 5.10.A is found to be defective, Contractor shall promptly, without cost to City and in accordance with City's written instructions: 1. repair such defective land or areas; or 2. correct such defective Work; or 3. if the defective Work has been rejected by City, remove it from the Project and replace it �. with Work that is not defective, and 4. satisfactorily correct or repair or remove and replace any damage to other Work, to the work of others or other land or areas resulting therefrom. B. If Contractor does not promptly comply with the terms of City's written instructions, or in an emergency where delay would cause serious risk of loss or damage, City may have the defective Work corrected or repaired or may have the rejected Work removed and replaced. All claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, ,M architects, attorneys, and other professionals and all court or other dispute resolution costs) arising out of or relating to such correction or repair or such removal and replacement (including but not limited to all costs of repair or replacement of work of others) will be paid by Contractor. i C. Where defective Work (and damage to other Work resulting therefrom) has been corrected or removed and replaced under this Paragraph 11.07, the correction period hereunder with respect MR to such Work may be required to be extended for an additional period of one year after the end of the initial correction period. City shall provide 30 days written notice to Contractor and Developer should such additional warranty coverage be required. Contractor's obligations under MR this Paragraph 11.07 are in addition to any other obligation or warranty. The provisions of this Paragraph 11.07 shall not be construed as a substitute for, or a waiver of, the provisions of any applicable statute of limitation or repose. w 11.08 City May Correct Defective Work A. If Contractor fails within a reasonable time after written notice from City to correct defective Work, or to remove and replace rejected Work as required by City in accordance with Paragraph 11.06.A, or if Contractor fails to perform the Work in accordance with the Contract Documents, or if Contractor fails to comply with any other provision of the Contract Documents, City may, after seven (7) days written notice to Contractor and the Developer, correct, or remedy any such deficiency. B. In exercising the rights and remedies under this Paragraph 11.09, City shall proceed expeditiously. In connection with such corrective or remedial action, City may exclude Contractor from all or part of the Site, take possession of all or part of the Work and suspend Contractor's services related thereto, and incorporate in the Work all materials and equipment incorporated in the Work, stored at the Site or for which City has paid Contractor but which are CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 0073 10- 32 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 32 of 35 stored elsewhere. Contractor shall allow City, City's representatives, agents, consultants, employees, and City's other contractors, access to the Site to enable City to exercise the rights and remedies under this Paragraph. C. All claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or other dispute resolution costs) incurred or sustained by City in exercising the rights and remedies under this Paragraph 13.09 will be charged against Contractor, and a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Work; and City shall be entitled to an appropriate decrease in the Contract Price. D. Contractor shall not be allowed an extension of the Contract Time because of any delay in the performance of the Work attributable to the exercise of City's rights and remedies under this Paragraph 11.09. ARTICLE 12 — COMPLETION 12.01 Contractor's Warranty of Title Contractor warrants and guarantees that title to all Work, materials, and equipment covered by any r Application for Payment will pass to City no later than the time of Final Acceptance and shall be free and clear of all Liens. 12.02 Partial Utilization A. Prior to Final Acceptance of all the Work, City may use or occupy any substantially completed part of the Work which has specifically been identified in the Contract Documents, or which +` City, determines constitutes a separately functioning and usable part of the Work that can be used by City for its intended purpose without significant interference with Contractor's performance of the remainder of the Work. City at any time may notify Contractor in writing to permit City to use or occupy any such part of the Work which City determines to be ready for its intended use, subject to the following conditions: 1. Contractor at any time may notify City in writing that Contractor considers any such part of the Work ready for its intended use. _ 2. Within a reasonable time after notification as enumerated in Paragraph 14.05.A.1, City and Contractor shall make an inspection of that part of the Work to determine its status of completion. If City does not consider that part of the Work to be substantially complete, City will notify Contractor in writing giving the reasons therefor. 3. Partial Utilization will not constitute Final Acceptance by City. 12.03 Final Inspection A. Upon written notice from Contractor that the entire Work is complete in accordance with the Contract Documents: CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 0073 10- 33 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 33 of 35 1. within 10 days, City will schedule a Final Inspection with Contractor. 2. City will notify Contractor in writing of all particulars in which this inspection reveals that the Work is incomplete or defective. Contractor shall immediately take such measures as are •• necessary to complete such Work or remedy such deficiencies. 12.04 Final Acceptance A. Upon completion by Contractor to City's satisfaction, of any additional Work identified in the Final Inspection, City will issue to Contractor a letter of Final Acceptance upon the satisfaction of the following: 1. All documentation called for in the Contract Documents, including but not limited to the .� evidence of insurance required by Paragraph 5.03; 2. consent of the surety, if any, to Final Acceptance; 3. a list of all pending or released Damage Claims against City that Contractor believes are unsettled; and 4. affidavits of payments and complete and legally effective releases or waivers (satisfactory to City) of all Lien rights arising out of or Liens filed in connection with the Work. 5. after all Damage Claims have been resolved: a. directly by the Contractor or; b. Contractor provides evidence that the Damage Claim has been reported to Contractor's insurance provider for resolution. 6. Issuing Final Acceptance by the City shall not relieve the Contractor of any guarantees or other requirements of the Contract Documents which specifically continue thereafter. ARTICLE 13 — SUSPENSION OF WORK 13.01 City May Suspend Work A. At any time and without cause, City may suspend the Work or any portion thereof by written notice to Contractor and which may fix the date on which Work will be resumed. Contractor shall resume the Work on the date so fixed. During temporary suspension of the Work covered by these Contract Documents, for any reason, the City will stop contract time on City participation projects. B. Should the Contractor not be able to complete a portion of the Project due to causes beyond the control of and without the fault or negligence of the Contractor, and should it be determined by mutual consent of the Contractor and City that a solution to allow construction to proceed is not CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 M 0073 10- 34 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 34 of 35 rr available within a reasonable period of time, Contractor may request an extension in Contract Time, directly attributable to any such suspension. IM C. If it should become necessary to suspend the Work for an indefinite period, the Contractor shall store all materials in such a manner that they will not obstruct or impede the public unnecessarily �. nor become damaged in any way, and he shall take every precaution to prevent damage or deterioration of the work performed; he shall provide suitable drainage about the work, and erect temporary structures where necessary. ARTICLE 14 — MISCELLANEOUS MM 14.01 Giving Notice A. Whenever any provision of the Contract Documents requires the giving of written notice, it will i be deemed to have been validly given if: 1. delivered in person to the individual or to a member of the firm or to an officer of the corporation for whom it is intended; or 2. delivered at or sent by registered or certified mail, postage prepaid, to the last business address known to the giver of the notice. B. Business address changes must be promptly made in writing to the other party. C. Whenever the Contract Documents specifies giving notice by electronic means such electronic notice shall be deemed sufficient upon confirmation of receipt by the receiving party. PM 14.02 Computation of Times When any period of time is referred to in the Contract Documents by days, it will be computed to .� exclude the first and include the last day of such period. If the last day of any such period falls on a Saturday or Sunday or on a day made a legal holiday the next Working Day shall become the last day of the period. '- 14.03 Cumulative Remedies i The duties and obligations imposed by these General Conditions and the rights and remedies available hereunder to the parties hereto are in addition to, and are not to be construed in any way as a limitation of, any rights and remedies available to any or all of them which are otherwise imposed or available by Laws or Regulations, by special warranty or guarantee, or by other provisions of the Contract Documents. The provisions of this Paragraph will be as effective as if repeated specifically in the Contract Documents in connection with each particular duty, obligation, right, and remedy to ^ which they apply. CITY OF FORT WORTH STANDARD CITY CONDITIONS —DEVELOPER AWARDED PROJECTS Revised: January 10, 2013 aw i 0073 10- 35 Standard City Conditions Of The Construction Contract For Developer Awarded Projects Page 35 of 35 14.04 Survival of Obligations All representations, indemnifications, warranties, and guarantees made in, required by, or given in accordance with the Contract Documents, as well as all continuing obligations indicated in the �- Contract Documents, will survive final payment, completion, and acceptance of the Work or termination or completion of the Contract or termination of the services of Contractor. 14.05 Headings Article and paragraph headings are inserted for convenience only and do not constitute parts of these .. General Conditions. MW MR P, i MM CITY OF FORT WORTH STANDARD CITY CONDITIONS — DEVELOPER AWARDED PROJECTS Revised: January I0, 20I3 i 1 2 SECTION 01 11 00 SUMMARY OF WORK 011100-1 DAP SUMMARY OF WORK Page 1 of 3 3 PART1- GENERAL 4 1.1 SUMMARY 5 A. Section Includes: 6 1. Summary of Work to be performed in accordance with the Contract Documents 7 B. Deviations from this City of Fort Worth Standard Specification 8 1. None. 9 C. Related Specification Sections include, but are not necessarily limited to: 10 1. Division 0 - Bidding Requirements, Contract Forms, and Conditions of the Contract 11 2. Division 1 - General Requirements 12 1.2 PRICE AND PAYMENT PROCEDURES 13 A. Measurement and Payment 14 1. Work associated with this Item is considered subsidiary to the various items bid. 15 No separate payment will be allowed for this Item. 16 1.3 REFERENCES [NOT USED] 17 1.4 ADMINISTRATIVE REQUIREMENTS 18 A. Work Covered by Contract Documents 19 1. Work is to include furnishing all labor, materials, and equipment, and performing 20 all Work necessary for this construction project as detailed in the Drawings and 21 Specifications. 22 B. Subsidiary Work 23 1. Any and all Work specifically governed by documentary requirements for the -- 24 project, such as conditions imposed by the Drawings or Contract Documents in 25 which no specific item for bid has been provided for in the Proposal and the item is 26 not a typical unit bid item included on the standard bid item list, then the item shall 27 be considered as a subsidiary item of Work, the cost of which shall be included in 28 the price bid in the Proposal for various bid items. 29 C. Use of Premises 30 1. Coordinate uses of premises under direction of the City. 31 2. Assume full responsibility for protection and safekeeping of materials and 32 equipment stored on the Site. 33 3. Use and occupy only portions of the public streets and alleys, or other public places 34 or other rights -of -way as provided for in the ordinances of the City, as shown in the 35 Contract Documents, or as may be specifically authorized in writing by the City. 36 a. A reasonable amount of tools, materials, and equipment for construction 37 purposes may be stored in such space, but no more than is necessary to avoid 38 delay in the construction operations. CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — Developer Awarded Projects City Project No. 101876 '� Revised December 20, 2012 01 11 00 - 2 DAP SUMMARY OF WORK Page 2 of 3 1 b. Excavated and waste materials shall be stored in such a way as not to interfere 2 with the use of spaces that may be designated to be left free and unobstructed 3 and so as not to inconvenience occupants of adjacent property. 4 c. If the street is occupied by railroad tracks, the Work shall be carried on in such 5 manner as not to interfere with the operation of the railroad. 6 1) All Work shall be in accordance with railroad requirements set forth in 7 Division 0 as well as the railroad permit. 8 D. Work within Easements 9 1. Do not enter upon private property for any purpose without having previously 10 obtained permission from the owner of such property. 11 2. 12 3. Do not store equipment or material on private property unless and until the 13 specified approval of the property owner has been secured in writing by the 14 Contractor and a copy furnished to the City. 15 4. Unless specifically provided otherwise, clear all rights -of -way or easements of 16 obstructions which must be removed to make possible proper prosecution of the 17 Work as a part of the project construction operations. 18 5. Preserve and use every precaution to prevent damage to, all trees, shrubbery, plants, 19 lawns, fences, culverts, curbing, and all other types of structures or improvements, 20 to all water, sewer, and gas lines, to all conduits, overhead pole lines, or 21 appurtenances thereof, including the construction of temporary fences and to all 22 other public or private property adjacent to the Work. 23 6. Notify the proper representatives of the owners or occupants of the public or private 24 lands of interest in lands which might be affected by the Work. 25 a. Such notice shall be made at least 48 hours in advance of the beginning of the 26 Work. 27 b. Notices shall be applicable to both public and private utility companies and any 28 corporation, company, individual, or other, either as owners or occupants, 29 whose land or interest in land might be affected by the Work. 30 c. Be responsible for all damage or injury to property of any character resulting 31 from any act, omission, neglect, or misconduct in the manner or method or 32 execution of the Work, or at any time due to defective work, material, or 33 equipment. 34 7. Fence 35 a. Restore all fences encountered and removed during construction of the Project 36 to the original or a better than original condition. 37 b. Erect temporary fencing in place of the fencing removed whenever the Work is 38 not in progress and when the site is vacated overnight, and/or at all times to 39 provide site security. 40 c. The cost for all fence work within easements, including removal, temporary 41 closures and replacement, shall be subsidiary to the various items bid in the 42 project proposal, unless a bid item is specifically provided in the proposal. CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — Developer Awarded Projects City Project No. 101876 'm Revised December 20, 2012 M 011100-3 DAP SUMMARY OF WORK Page 3 of 3 1 1.5 SUBMITTALS [NOT USED] 2 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 3 1.7 CLOSEOUT SUBMITTALS [NOT USED] 4 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 5 1.9 QUALITY ASSURANCE [NOT USED] 6 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] 7 1.11 FIELD [SITE] CONDITIONS [NOT USED] 8 1.12 WARRANTY [NOT USED] 9 PART 2 - PRODUCTS [NOT USED] 10 PART 3 - EXECUTION [NOT USED] 11 END OF SECTION 12 13 i i Revision Log DATE NAME SUMMARY OF CHANGE CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — Developer Awarded Projects City Project No. 101876 Revised December 20, 2012 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 40 0131 19 - 2 DAP PRECONSTRUCTION MEETING Page 2 of 3 e. Other City representatives f. Others as appropriate 4. Preliminary Agenda may include: a. Introduction of Project Personnel b. General Description of Project c. Status of right-of-way, utility clearances, easements or other pertinent permits d. Contractor's work plan and schedule e. Contract Time f. Notice to Proceed g. Construction Staking h. Progress Payments i. Extra Work and Change Order Procedures j. Field Orders k. Disposal Site Letter for Waste Material 1. Insurance Renewals m. Payroll Certification n. Material Certifications and Quality Control Testing o. Public Safety and Convenience p. Documentation of Pre -Construction Conditions q. Weekend Work Notification r. Legal Holidays s. Trench Safety Plans t. Confined Space Entry Standards u. Coordination with the City's representative for operations of existing water systems v. Storm Water Pollution Prevention Plan w. Coordination with other Contractors x. Early Warning System y. Contractor Evaluation z. Special Conditions applicable to the project aa. Damages Claims bb. Submittal Procedures cc. Substitution Procedures dd. Correspondence Routing ee. Record Drawings ff. Temporary construction facilities gg. MBE/SBE procedures hh. Final Acceptance ii. Final Payment J. Questions or Comments CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised August 30, 2013 ■ � 01 31 19 - 3 DAP PRECONSTRUCTION MEETING Page 3 of 3 1 1.5 SUBMITTALS [NOT USED] 2 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 3 1.7 CLOSEOUT SUBMITTALS [NOT USED] 4 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 5 1.9 QUALITY ASSURANCE [NOT USED] 6 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] 7 1.11 FIELD [SITE] CONDITIONS [NOT USED] 8 1.12 WARRANTY [NOT USED] 9 PART 2 - PRODUCTS [NOT USED] 10 PART 3 - EXECUTION [NOT USED] 11 END OF SECTION 12 Revision Log DATE NAME SUMMARY OF CHANGE 13 CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised August 30, 2013 1 2 3 PART1- GENERAL SECTION 0132 33 PRECONSTRUCTION VIDEO 01 32 33 - 1 DAP PRECONSTRUCTION VIDEO Page 1 of 2 4 1.1 SUMMARY 5 A. Section Includes: 6 1. Administrative and procedural requirements for: 7 a. Preconstruction Videos 8 B. Deviations from this City of Fort Worth Standard Specification 9 1. Though not mandatory, it is highly recommended on infill developer projects. 10 C. Related Specification Sections include, but are not necessarily limited to: 11 1. Division 0 — Bidding Requirements, Contract Forms and Conditions of the Contract 12 2. Division 1 — General Requirements 13 1.2 PRICE AND PAYMENT PROCEDURES 14 A. Measurement and Payment 15 1. Work associated with this Item is considered subsidiary to the various items bid. 16 No separate payment will be allowed for this Item. 17 1.3 REFERENCES [NOT USED] 18 1.4 ADMINISTRATIVE REQUIREMENTS 19 A. Preconstruction Video 20 1. Produce a preconstruction video of the site/alignment, including all areas in the 21 vicinity of and to be affected by construction. 22 a. Provide digital copy of video upon request by the City. 23 2. Retain a copy of the preconstruction video until the end of the maintenance surety 24 period. 25 1.5 SUBMITTALS [NOT USED] 26 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 27 1.7 CLOSEOUT SUBMITTALS [NOT USED] 28 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 29 1.9 QUALITY ASSURANCE [NOT USED] 30 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] 31 1.11 FIELD [SITE] CONDITIONS [NOT USED] 32 1.12 WARRANTY [NOT USED] 33 PART 2 - PRODUCTS [NOT USED] CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 �* Revised August 30, 2013 01 32 33 - 2 DAP PRECONSTRUCTION VIDEO Page 2 of 2 1 PART 3 - EXECUTION [NOT USED] 2 END OF SECTION 3 Revision Log DATE NAME SUMMARY OF CHANGE 4 CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 to Revised August 30, 2013 013300-1 DAP SUBMITTALS Page 1 of 12 1 SECTION 0133 00 2 DAP SUBMITTALS 3 PART1- GENERAL 4 1.1 SUMMARY 5 A. Section Includes: 6 1. General methods and requirements of submissions applicable to the following 7 Work -related submittals: 8 a. Shop Drawings 9 b. Product Data (including Standard Product List submittals) 10 c. Samples 11 d. Mock Ups - 12 B. Deviations from this City of Fort Worth Standard Specification 13 1. None. 14 C. Related Specification Sections include, but are not necessarily limited to: 15 1. Division 0 — Bidding Requirements, Contract Forms and Conditions of the Contract 16 2. Division 1— General Requirements 17 1.2 PRICE AND PAYMENT PROCEDURES 18 A. Measurement and Payment 19 1. Work associated with this Item is considered subsidiary to the various items bid. 20 No separate payment will be allowed for this Item. 21 1.3 REFERENCES [NOT USED) K 22 1.4 ADMINISTRATIVE REQUIREMENTS 23 A. Coordination CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS —DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised August 30, 2013 i Wft 013300 2 DAP SUBMITTALS Page 2 of 12 1 1. Notify the City in writing, at the time of submittal, of any deviations in the 2 submittals from the requirements of the Contract Documents. 3 2. Coordination of Submittal Times 4 a. Prepare, prioritize and transmit each submittal sufficiently in advance of 5 performing the related Work or other applicable activities, or within the time 6 specified in the individual Work Sections, of the Specifications. 7 b. Contractor is responsible such that the installation will not be delayed by 8 processing times including, but not limited to: 9 a) Disapproval and resubmittal (if required) 10 b) Coordination with other submittals 11 c) Testing 12 d) Purchasing 13 e) Fabrication 14 f) Delivery 15 g) Similar sequenced activities 16 c. No extension of time will be authorized because of the Contractor's failure to 17 transmit submittals sufficiently in advance of the Work. 18 d. Make submittals promptly in accordance with approved schedule, and in such 19 sequence as to cause no delay in the Work or in the work of any other 20 contractor. 21 B. Submittal Numbering 22 1. When submitting shop drawings or samples, utilize a 9-character submittal cross- 23 reference identification numbering system in the following manner: 24 a. Use the first 6 digits of the applicable Specification Section Number. 25 b. For the next 2 digits number use numbers 01-99 to sequentially number each 26 initial separate item or drawing submitted under each specific Section 27 number. CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised August 30, 2013 i i i 013300-3 DAP SUBMITTALS Page 3 of 12 1 c. Last use a letter, A-Z, indicating the resubmission of the same drawing (i.e. 2 A=2nd submission, B=3rd submission, C=4th submission, etc.). A typical 3 submittal number would be as follows: 4 5 03 30 00-08-B 6 7 1) 03 30 00 is the Specification Section for Concrete 8 2) 08 is the eighth initial submittal under this Specification Section 9 3) B is the third submission (second resubmission) of that particular shop 10 drawing 11 C. Contractor Certification 12 1. Review shop drawings, product data and samples, including those by 13 subcontractors, prior to submission to determine and verify the following: 14 a. Field measurements 15 b. Field construction criteria 16 c. Catalog numbers and similar data 17 d. Conformance with the Contract Documents 18 2. Provide each shop drawing, sample and product data submitted by the Contractor 19 with a Certification Statement affixed including: 20 a. The Contractor's Company name 21 b. Signature of submittal reviewer 22 c. Certification Statement 23 1) "By this submittal, I hereby represent that I have determined and verified 24 field measurements, field construction criteria, materials, dimensions, 25 catalog numbers and similar data and I have checked and coordinated 26 each item with other applicable approved shop drawings." 27 D. Submittal Format 28 1. Fold shop drawings larger than 8 %: inches x 11 inches to 8 %2 inches x 11inches. CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS— DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised August 30, 2013 013300-4 DAP SUBMITTALS Page 4 of 12 1 2. Bind shop drawings and product data sheets together. 2 3. Order 3 a. Cover Sheet 4 1) Description of Packet 5 2) Contractor Certification 6 b. List of items / Table of Contents 7 c. Product Data /Shop Drawings/Samples /Calculations 8 E. Submittal Content 9 1. The date of submission and the dates of any previous submissions 10 2. The Project title and number 11 3. Contractor identification 12 4. The names of: 13 a. Contractor 14 b. Supplier 15 c. Manufacturer 16 5. Identification of the product, with the Specification Section number, page and 17 paragraph(s) 18 6. Field dimensions, clearly identified as such 19 7. Relation to adjacent or critical features of the Work or materials 20 8. Applicable standards, such as ASTM or Federal Specification numbers 21 9. Identification by highlighting of deviations from Contract Documents 22 10. Identification by highlighting of revisions on resubmittals 23 11. An 8-inch x 3-inch blank space for Contractor and City stamps 24 F. Shop Drawings y CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS— DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised August 30, 2013 013300-5 DAP SUBMITTALS Page 5 of 12 1 1. As specified in individual Work Sections includes, but is not necessarily limited to: 2 a. Custom -prepared data such as fabrication and erection/installation (working) 3 drawings 4 b. Scheduled information 5 c. Setting diagrams 6 d. Actual shopwork manufacturing instructions 7 e. Custom templates 8 f. Special wiring diagrams 9 g. Coordination drawings 10 h. Individual system or equipment inspection and test reports including: 11 1) Performance curves and certifications 12 i. As applicable to the Work 13 2. Details 14 a. Relation of the various parts to the main members and lines of the structure 15 b. Where correct fabrication of the Work depends upon field measurements 16 1) Provide such measurements and note on the drawings prior to submitting 17 for approval. 18 G. Product Data 19 1. For submittals of product data for products included on the City's Standard 20 Product List, clearly identify each item selected for use on the Project. 21 2. For submittals of product data for products not included on the City's Standard 22 Product List, submittal data may include, but is not necessarily limited to: 23 a. Standard prepared data for manufactured products (sometimes referred to as 24 catalog data) 25 1) Such as the manufacturer's product specification and installation 26 instructions 27 2) Availability of colors and patterns CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised August 30, 2013 013300-6 DAP SUBMITTALS Page 6 of 12 1 3) Manufacturer's printed statements of compliances and applicability 2 4) Roughing -in diagrams and templates 3 5) Catalog cuts 4 6) Product photographs 5 7) Standard wiring diagrams 6 8) Printed performance curves and operational -range diagrams 7 9) Production or quality control inspection and test reports and certifications 8 10) Mill reports 9 11) Product operating and maintenance instructions and recommended 10 spare -parts listing and printed product warranties 11 12) As applicable to the Work 12 H. Samples 13 1. As specified in individual Sections, include, but are not necessarily limited to: 14 a. Physical examples of the Work such as: 15 1) Sections of manufactured or fabricated Work 16 2) Small cuts or containers of materials 17 3) Complete units of repetitively used products color/texture/pattern 18 swatches and range sets 19 4) Specimens for coordination of visual effect 20 5) Graphic symbols and units of Work to be used by the City for independent 21 inspection and testing, as applicable to the Work 22 I. Do not start Work requiring a shop drawing, sample or product data nor any material 23 to be fabricated or installed prior to the approval or qualified approval of such item. 24 1. Fabrication performed, materials purchased or on -site construction accomplished 25 which does not conform to approved shop drawings and data is at the Contractor's 26 risk. CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS— DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised August 30, 2013 013300-7 DAP SUBMITTALS Page 7 of 12 1 2. The City will not be liable for any expense or delay due to corrections or remedies 2 required to accomplish conformity. 3 3. Complete project Work, materials, fabrication, and installations in conformance 4 with approved shop drawings, applicable samples, and product data. 5 J. Submittal Distribution 6 1. Electronic Distribution 7 a. Confirm development of Project directory for electronic submittals to be 8 uploaded to City's Buzzsaw site, or another external FTP site approved by the 9 City. 10 b. Shop Drawings 11 1) Upload submittal to designated project directory and notify appropriate 12 City representatives via email of submittal posting. 13 2) Hard Copies 14 a) 3 copies for all submittals 15 b) If Contractor requires more than 1 hard copy of Shop Drawings 16 returned, Contractor shall submit more than the number of copies 17 listed above. 18 c. Product Data 19 1) Upload submittal to designated project directory and notify appropriate 20 City representatives via email of submittal posting. 21 2) Hard Copies 22 a) 3 copies for all submittals 23 d. Samples 24 1) Distributed to the Project Representative 25 2. Hard Copy Distribution (if required in lieu of electronic distribution) 26 a. Shop Drawings 27 1) Distributed to the City 28 2) Copies CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS— DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised August 30, 2013 0133 00 - 8 DAP SUBMITTALS Page 8 of 12 1 a) 8 copies for mechanical submittals 2 b) 7 copies for all other submittals 3 c) If Contractor requires more than 3 copies of Shop Drawings returned, 4 Contractor shall submit more than the number of copies listed above. 5 b. Product Data 6 1) Distributed to the City 7 2) Copies 8 a) 4 copies 9 c. Samples 10 1) Distributed to the Project Representative 11 2) Copies 12 a) Submit the number stated in the respective Specification Sections. 13 3. Distribute reproductions of approved shop drawings and copies of approved 14 product data and samples, where required, to the job site file and elsewhere as 15 directed by the City. 16 a. Provide number of copies as directed by the City but not exceeding the 17 number previously specified. 18 K. Submittal Review 19 1. The review of shop drawings, data and samples will be for general conformance 20 with the design concept and Contract Documents. This is not to be construed as: 21 a. Permitting any departure from the Contract requirements 22 b. Relieving the Contractor of responsibility for any errors, including details, 23 dimensions, and materials 24 c. Approving departures from details furnished by the City, except as otherwise 25 provided herein 26 2. The review and approval of shop drawings, samples or product data by the City 27 does not relieve the Contractor from his/her responsibility with regard to the 28 fulfillment of the terms of the Contract. CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised August 30, 2013 013300-9 DAP SUBMITTALS Page 9 of 12 1 a. All risks of error and omission are assumed by the Contractor, and the City will 2 have no responsibility therefore. 3 3. The Contractor remains responsible for details and accuracy, for coordinating the 4 Work with all other associated work and trades, for selecting fabrication 5 processes, for techniques of assembly and for performing Work in a safe manner. 6 4. If the shop drawings, data or samples as submitted describe variations and show a 7 departure from the Contract requirements which City finds to be in the interest of 8 the City and to be so minor as not to involve a change in Contract Price or time for 9 performance, the City may return the reviewed drawings without noting an 10 exception. 11 S. Submittals will be returned to the Contractor under 1 of the following codes: 12 a. Code 1 13 1) "NO EXCEPTIONS TAKEN" is assigned when there are no notations or 14 comments on the submittal. 15 a) When returned under this code the Contractor may release the 16 equipment and/or material for manufacture. 17 b. Code 2 18 1) "EXCEPTIONS NOTED". This code is assigned when a confirmation of the 19 notations and comments IS NOT required by the Contractor. 20 a) The Contractor may release the equipment or material for 21 manufacture; however, all notations and comments must be 22 incorporated into the final product. 23 c. Code 3 24 1) "EXCEPTIONS NOTED/RESUBMIT". This combination of codes is assigned 25 when notations and comments are extensive enough to require a 26 resubmittal of the package. 27 a) The Contractor may release the equipment or material for 28 manufacture; however, all notations and comments must be 29 incorporated into the final product. 30 b) This resubmittal is to address all comments, omissions and 31 non -conforming items that were noted. CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised August 30, 2013 i i 0133 00 - 30 DAP SUBMITTALS Page 30 of 12 1 c) Resubmittal is to be received by the City within 15 Calendar Days of 2 the date of the City's transmittal requiring the resubmittal. 3 d. Code 4 4 1) "NOT APPROVED" is assigned when the submittal does not meet the intent 5 of the Contract Documents. 6 a) The Contractor must resubmit the entire package revised to bring the 7 submittal into conformance. 8 b) It may be necessary to resubmit using a different 9 manufacturer/vendor to meet the Contract Documents. 10 6. Resubmittals 11 a. Handled in the same manner as first submittals 12 1) Corrections other than requested by the City 13 2) Marked with revision triangle or other similar method 14 a) At Contractor's risk if not marked 15 b. Submittals for each item will be reviewed no more than twice at the City's 16 expense. 17 1) All subsequent reviews will be performed at times convenient to the City 18 and at the Contractor's expense, based on the City's or City 19 Representative's then prevailing rates. 20 2) Provide Contractor reimbursement to the City within 30 Calendar Days for 21 all such fees invoiced by the City. 22 c. The need for more than 1 resubmission or any other delay in obtaining City's 23 review of submittals, will not entitle the Contractor to an extension of 24 Contract Time. 25 7. Partial Submittals 26 a. City reserves the right to not review submittals deemed partial, at the City's 27 discretion. 28 b. Submittals deemed by the City to be not complete will be returned to the 29 Contractor, and will be considered "Not Approved" until resubmitted. ' CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised August 30, 2013 013300-11 DAP SUBMITTALS Page 11 of 12 1 c. The City may at its option provide a list or mark the submittal directing the 2 Contractor to the areas that are incomplete. 3 8. If the Contractor considers any correction indicated on the shop drawings to 4 constitute a change to the Contract Documents, then written notice must be 5 provided thereof to the Developer at least 7 Calendar Days prior to release for 6 manufacture. 7 9. When the shop drawings have been completed to the satisfaction of the City, the 8 Contractor may carry out the construction in accordance therewith and no further 9 changes therein except upon written instructions from the City. 10 10. Each submittal, appropriately coded, will be returned within 30 Calendar Days 11 following receipt of submittal by the City. 12 L. Mock ups 13 1. Mock Up units as specified in individual Sections, include, but are not necessarily 14 limited to, complete units of the standard of acceptance for that type of Work to 15 be used on the Project. Remove at the completion of the Work or when directed. 16 M. Qualifications 17 1. If specifically required in other Sections of these Specifications, submit a P.E. 18 Certification for each item required. 19 N. Request for Information (RFI) 20 1. Contractor Request for additional information 21 a. Clarification or interpretation of the contract documents 22 b. When the Contractor believes there is a conflict between Contract Documents 23 c. When the Contractor believes there is a conflict between the Drawings and 24 Specifications 25 1) Identify the conflict and request clarification 26 2. Sufficient information shall be attached to permit a written response without 27 further information. 28 CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised August 30, 2013 1 2 3 4 1.5 SUBMITTALS [NOT USED] 5 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 6 1.7 CLOSEOUT SUBMITTALS [NOT USED] 7 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 8 1.9 QUALITY ASSURANCE [NOT USED] 9 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] 10 1.11 FIELD [SITE] CONDITIONS [NOT USED] 11 1.12 WARRANTY [NOT USED] 12 PART 2 - PRODUCTS [NOT USED] 13 PART 3 - EXECUTION [NOT USED] 14 END OF SECTION 15 Revision Log DATE NAME SUMMARY OF CHANGE 12/20/2012 D. Johnson 1.4.K.8. Working Days modified to Calendar Days 16 0133 00 -12 DAP SUBMITTALS Page 12 of 12 CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS— DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised August 30, 2013 014523-1 DAP TESTING AND INSPECTION SERVICES — Page 1 of 2 1 SECTION 0145 23 2 TESTING AND INSPECTION SERVICES 3 PART1- GENERAL 4 1.1 SUMMARY 5 A. Section Includes: 6 1. Testing and inspection services procedures and coordination 7 B. Deviations from this City of Fort Worth Standard Specification 8 1. None. 9 C. Related Specification Sections include, but are not necessarily limited to: 10 1. Division 0 — Bidding Requirements, Contract Forms and Conditions of the Contract 11 2. Division 1 — General Requirements 12 1.2 PRICE AND PAYMENT PROCEDURES 13 A. Measurement and Payment 14 1. Work associated with this Item is considered subsidiary to the various Items bid. 15 No separate payment will be allowed for this Item. 16 a. Contractor is responsible for performing, coordinating, and payment of all �. 17 Quality Control testing. 18 b. City is responsible for performing and payment for first set of Quality 19 Assurance testing. 20 1) If the first Quality Assurance test performed by the City fails, the 21 Contractor is responsible for payment of subsequent Quality Assurance 22 testing until a passing test occurs. 23 a) Final acceptance will not be issued by City until all required payments .� 24 for testing by Contractor have been paid in full. 25 1.3 REFERENCES [NOT USED] 26 1.4 ADMINISTRATIVE REQUIREMENTS 27 A. Testing 28 1. Complete testing in accordance with the Contract Documents. 29 2. Coordination 30 a. When testing is required to be performed by the City, notify City, sufficiently 31 in advance, when testing is needed. 32 b. When testing is required to be completed by the Contractor, notify City, 33 sufficiently in advance, that testing will be performed. 34 3. Distribution of Testing Reports 35 a. Electronic Distribution 36 1) Confirm development of Project directory for electronic submittals to be — 37 uploaded to City's Buzzsaw site, or another form of distribution approved 38 by the City. CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 *'� Revised August 30, 2013 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 01 45 23 - 2 DAP TESTING AND INSPECTION SERVICES Page 2 of 2 2) Upload test reports to designated project directory and notify appropriate City representatives via email of submittal posting. 3) Hard Copies a) 1 copy for all submittals submitted to the Project Representative b. Hard Copy Distribution (if required in lieu of electronic distribution) 1) Tests performed by City a) Distribute 1 hard copy to the Contractor 2) Tests performed by the Contractor a) Distribute 3 hard copies to City's Project Representative 4. Provide City's Project Representative with trip tickets for each delivered load of Concrete or Lime material including the following information: a. Name of pit b. Date of delivery c. Material delivered B. Inspection 1. Inspection or lack of inspection does not relieve the Contractor from obligation to perform work in accordance with the Contract Documents. 1.5 SUBMITTALS [NOT USED] 1.6 ACTION SUBMITTALSANFORMATIONAL SUBMITTALS [NOT USED] 1.7 CLOSEOUT SUBMITTALS [NOT USED] 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 1.9 QUALITY ASSURANCE [NOT USED] 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] 1.11 FIELD [SITE] CONDITIONS [NOT USED] 1.12 WARRANTY [NOT USED] PART 2 - PRODUCTS [NOT USED] 27 PART 3 - EXECUTION [NOT USED] 28 29 30 END OF SECTION Revision Log DATE NAME SUMMARY OF CHANGE CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised August 30, 2013 01 50 00 - 1 DAP TEMPORARY FACILITIES AND CONTROLS Page 1 of 4 I SECTION 0150 00 2 TEMPORARY FACILITIES AND CONTROLS 3 PART1- GENERAL 4 1.1 SUMMARY 5 A. Section Includes: 6 1. Provide temporary facilities and controls needed for the Work including, but not 7 necessarily limited to: 8 a. Temporary utilities 9 b. Sanitary facilities 10 c. Storage Sheds and Buildings '— 11 d. Dust control 12 e. Temporary fencing of the construction site 13 B. Deviations from this City of Fort Worth Standard Specification 14 1. None. 15 C. Related Specification Sections include, but are not necessarily limited to: 16 1. Division 0 — Bidding Requirements, Contract Forms and Conditions of the Contract 17 2. Division 1 — General Requirements 18 1.2 PRICE AND PAYMENT PROCEDURES 19 A. Measurement and Payment 20 1. Work associated with this Item is considered subsidiary to the various Items bid. 21 No separate payment will be allowed for this Item. 22 1.3 REFERENCES [NOT USED] 23 1.4 ADMINISTRATIVE REQUIItEMENTS 24 A. Temporary Utilities Y 25 1. Obtaining Temporary Service 26 a. Make arrangements with utility service companies for temporary services. 27 b. Abide by rules and regulations of utility service companies or authorities 28 having jurisdiction. 29 c. Be responsible for utility service costs until Work is approved for Final 30 Acceptance. — 31 1) Included are fuel, power, light, heat and other utility services necessary for 32 execution, completion, testing and initial operation of Work. 33 2. Water 34 a. Contractor to provide water required for and in connection with Work to be 35 performed and for specified tests of piping, equipment, devices or other use as 36 required for the completion of the Work. 37 b. Provide and maintain adequate supply of potable water for domestic 38 consumption by Contractor personnel and City's Project Representatives. 39 c. Coordination CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised JULY 1, 2011 ,m 01 50 00 - 2 DAP TEMPORARY FACILITIES AND CONTROLS Page 2 of 4 1 1) Contact City 1 week before water for construction is desired 2 d. Contractor Payment for Construction Water 3 1) Obtain construction water meter from City for payment as billed by City's 4 established rates. 5 3. Electricity and Lighting 6 a. Provide and pay for electric powered service as required for Work, including 7 testing of Work. 8 1) Provide power for lighting, operation of equipment, or other use. 9 b. Electric power service includes temporary power service or generator to 10 maintain operations during scheduled shutdown. 11 4. Telephone 12 a. Provide emergency telephone service at Site for use by Contractor personnel 13 and others performing work or furnishing services at Site. 14 5. Temporary Heat and Ventilation 15 a. Provide temporary heat as necessary for protection or completion of Work. 16 b. Provide temporary heat and ventilation to assure safe working conditions. 17 B. Sanitary Facilities 18 1. Provide and maintain sanitary facilities for persons on Site. 19 a. Comply with regulations of State and local departments of health. 20 2. Enforce use of sanitary facilities by construction personnel at job site. 21 a. Enclose and anchor sanitary facilities. 22 b. No discharge will be allowed from these facilities. 23 c. Collect and store sewage and waste so as not to cause nuisance or health 24 problem. 25 d. Haul sewage and waste off -site at no less than weekly intervals and properly 26 dispose in accordance with applicable regulation. 27 3. Locate facilities near Work Site and keep clean and maintained throughout Project. 28 4. Remove facilities at completion of Project 29 C. Storage Sheds and Buildings 30 1. Provide adequately ventilated, watertight, weatherproof storage facilities with floor 31 above ground level for materials and equipment susceptible to weather damage. 32 2. Storage of materials not susceptible to weather damage may be on blocks off 33 ground. 34 3. Store materials in a neat and orderly manner. 35 a. Place materials and equipment to permit easy access for identification, 36 inspection and inventory. 37 4. Equip building with lockable doors and lighting, and provide electrical service for 38 equipment space heaters and heating or ventilation as necessary to provide storage 39 environments acceptable to specified manufacturers. 40 5. Fill and grade site for temporary structures to provide drainage away from 41 temporary and existing buildings. 42 6. Remove building from site prior to Final Acceptance. 43 D. Temporary Fencing 44 1. Provide and maintain for the duration or construction when required in contract 45 documents CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised JULY 1, 2011 w w In Mo MM dER 01 50 00 - 3 DAP TEMPORARY FACILITIES AND CONTROLS Page 3 of 4 1 E. Dust Control 2 1. Contractor is responsible for maintaining dust control through the duration of the 3 project. 4 a. Contractor remains on -call at all times 5 b. Must respond in a timely manner 6 F. Temporary Protection of Construction 7 1. Contractor or subcontractors are responsible for protecting Work from damage due 8 to weather. 9 1.5 SUBMITTALS [NOT USED] 10 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 11 1.7 CLOSEOUT SUBMITTALS [NOT USED] 12 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 13 1.9 QUALITY ASSURANCE [NOT USED] 14 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] 15 1.11 FIELD [SITE] CONDITIONS [NOT USED] 16 1.12 WARRANTY [NOT USED] 17 PART 2 - PRODUCTS [NOT USED] 18 PART 3 - EXECUTION [NOT USED] 19 3.1 INSTALLERS [NOT USED] 20 3.2 EXAMINATION [NOT USED] 21 3.3 PREPARATION [NOT USED] 22 3.4 INSTALLATION 23 A. Temporary Facilities 24 1. Maintain all temporary facilities for duration of construction activities as needed. CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised JULY 1, 2011 01 50 00 - 4 DAP TEMPORARY FACILITIES AND CONTROLS Page 4 of 4 1 3.5 [REPAIR] / [RESTORATION] 2 3.6 RE -INSTALLATION 3 3.7 FIELD [OR] SITE QUALITY CONTROL [NOT USED] 4 3.8 SYSTEM STARTUP [NOT USED] 5 3.9 ADJUSTING [NOT USED] 6 3.10 CLEANING [NOT USED] 7 3.11 CLOSEOUT ACTIVITIES 8 A. Temporary Facilities 9 1. Remove all temporary facilities and restore area after completion of the Work, to a 10 condition equal to or better than prior to start of Work. 11 3.12 PROTECTION [NOT USED] 12 3.13 MAINTENANCE [NOT USED] 13 3.14 ATTACHMENTS [NOT USED] 14 END OF SECTION 15 16 Revision Log DATE NAME SUMMARY OF CHANGE CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised JULY 1, 2011 01 55 26 - 1 DAP STREET USE PERMIT AND MODIFICATIONS TO TRAFFIC CONTROL Page 1 of 3 1 SECTION 0155 26 NOR 2 STREET USE PERMIT AND MODIFICATIONS TO TRAFFIC CONTROL 3 PART1- GENERAL 4 1.1 SUMMARY 5 A. Section Includes: 6 1. Administrative procedures for: 7 a. Street Use Permit 8 b. Modification of approved traffic control 9 c. Removal of Street Signs d. 10 B. Deviations from this City of Fort Worth Standard Specification 11 1. None. _ 12 C. Related Specification Sections include, but are not necessarily limited to: 13 1. Division 0 — Bidding Requirements, Contract Forms and Conditions of the Contract 14 2. Division 1 — General Requirements 15 3. Section 34 71 13 — Traffic Control 16 1.2 PRICE AND PAYMENT PROCEDURES 17 A. Measurement and Payment 18 1. Work associated with this Item is considered subsidiary to the various Items bid. 19 No separate payment will be allowed for this Item. 20 1.3 REFERENCES 21 A. Reference Standards 22 1. Reference standards cited in this specification refer to the current reference standard 23 published at the time of the latest revision date logged at the end of this 24 specification, unless a date is specifically cited. 25 2. Texas Manual on Uniform Traffic Control Devices (TMUTCD). 26 1.4 ADMINISTRATIVE REQUIREMENTS 27 A. Traffic Control 28 1. General 29 a. When traffic control plans are included in the Drawings, provide Traffic 30 Control in accordance with Drawings and Section 34 71 13. 31 b. When traffic control plans are not included in the Drawings, prepare traffic 32 control plans in accordance with Section 34 71 13 and submit to City for 33 review. 34 1) Allow minimum 10 working days for review of proposed Traffic Control. 35 B. Street Use Permit 36 1. Prior to installation of Traffic Control, a City Street Use Permit is required. 37 a. To obtain Street Use Permit, submit Traffic Control Plans to City 38 Transportation and Public Works Department. MM CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 an Revised July 1, 2011 M MER i i i a i .t 01 55 26 - 2 DAP STREET USE PERMIT AND MODIFICATIONS TO TRAFFIC CONTROL Page 2 of 3 1 1) Allow a minimum of 5 working days for permit review. 2 2) Contractor's responsibility to coordinate review of Traffic Control plans for 3 Street Use Permit, such that construction is not delayed. 4 C. Modification to Approved Traffic Control 5 1. Prior to installation traffic control: 6 a. Submit revised traffic control plans to City Department Transportation and 7 Public Works Department. 8 1) Revise Traffic Control plans in accordance with Section 34 71 13. 9 2) Allow minimum 5 working days for review of revised Traffic Control. 10 3) It is the Contractor's responsibility to coordinate review of Traffic Control 11 plans for Street Use Permit, such that construction is not delayed. 12 D. Removal of Street Sign 13 1. If it is determined that a street sign must be removed for construction, then contact 14 City Transportation and Public Works Department, Signs and Markings Division to 15 remove the sign. 16 E. Temporary Signage 17 1. In the case of regulatory signs, replace permanent sign with temporary sign meeting 18 requirements of the latest edition of the Texas Manual on Uniform Traffic Control 19 Devices (MUTCD). 20 2. Install temporary sign before the removal of permanent sign. 21 3. When construction is complete, to the extent that the permanent sign can be 22 reinstalled, contact the City Transportation and Public Works Department, Signs 23 and Markings Division, to reinstall the permanent sign. 24 F. Traffic Control Standards 25 1. Traffic Control Standards can be found on the City's Buzzsaw website. 26 1.5 SUBMITTALS [NOT USED] 27 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 28 1.7 CLOSEOUT SUBMITTALS [NOT USED] 29 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 30 1.9 QUALITY ASSURANCE [NOT USED] 31 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] 32 1.11 FIELD [SITE] CONDITIONS [NOT USED] 33 1.12 WARRANTY [NOT USED] 34 PART 2 - PRODUCTS [NOT USED] 35 PART 3 - EXECUTION [NOT USED] 36 END OF SECTION CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised July 1, 2011 m ON I 01 55 26 - 3 DAP STREET USE PERMIT AND MODIFICATIONS TO TRAFFIC CONTROL Page 3 of 3 OR Revision Log DATE NAME SUMMARY OF CHANGE +4 ao 2 •w W m m UR 04 m go CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 MR Revised July 1, 2011 0157 13- 1 DAP STORM WATER POLLUTION PREVENTION Page 1 of 3 1 SECTION 0157 13 2 STORM WATER POLLUTION PREVENTION 3 PART1- GENERAL 4 1.1 SUMMARY 5 A. Section Includes: 6 1. Procedures for Storm Water Pollution Prevention Plans 7 B. Deviations from this City of Fort Worth Standard Specification 8 1. None. 9 C. Related Specification Sections include, but are not necessarily limited to: 10 1. Division 0 — Bidding Requirements, Contract Forms and Conditions of the 11 Contract 12 2. Division 1 — General Requirements 13 3. Section 31 25 00 — Erosion and Sediment Control 14 1.2 PRICE AND PAYMENT PROCEDURES 15 A. Measurement and Payment 16 1. Construction Activities resulting in less than 1 acre of disturbance 17 a. Work associated with this Item is considered subsidiary to the various Items 18 bid. No separate payment will be allowed for this Item. 19 2. Construction Activities resulting in greater than 1 acre of disturbance 20 a. Measurement and Payment shall be in accordance with Section 3125 00. 21 1.3 REFERENCES 22 A. Abbreviations and Acronyms 23 1. Notice of Intent: NOI 24 2. Notice of Termination: NOT 25 3. Storm Water Pollution Prevention Plan: SWPPP 26 4. Texas Commission on Environmental Quality: TCEQ 27 5. Notice of Change: NOC 28 A. Reference Standards 29 1. Reference standards cited in this Specification refer to the current reference 30 standard published at the time of the latest revision date logged at the end of this 31 Specification, unless a date is specifically cited. 32 2. Integrated Storm Management (iSWM) Technical Manual for Construction 33 Controls 34 1.4 ADMINISTRATIVE REQUIREMENTS 35 A. General 36 1. Contractor is responsible for resolution and payment of any fines issued associated 37 with compliance to Stormwater Pollution Prevention Plan. CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised July 1, 2011 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 01 57 13 - 2 DAP STORM WATER POLLUTION PREVENTION Page 2 of 3 B. Construction Activities resulting in: 1. Less than 1 acre of disturbance a. Provide erosion and sediment control in accordance with Section 3125 00 and Drawings. 2. 1 to less than 5 acres of disturbance a. Texas Pollutant Discharge Elimination System (TPDES) General Construction Permit is required b. Complete SWPPP in accordance with TCEQ requirements 1) TCEQ Small Construction Site Notice Required under general permit TXR150000 a) Sign and post at job site b) Prior to Preconstruction Meeting, send 1 copy to City Department of Transportation and Public Works, Environmental Division, (817) 392- 6088. 2) Provide erosion and sediment control in accordance with: a) Section 3125 00 b) The Drawings c) TXR150000 General Permit d) SWPPP e) TCEQ requirements 3. 5 acres or more of Disturbance a. Texas Pollutant Discharge Elimination System (TPDES) General Construction Permit is required b. Complete SWPPP in accordance with TCEQ requirements 1) Prepare a TCEQ NOI form and submit to TCEQ along with required fee a) Sign and post at job site b) Send copy to City Department of Transportation and Public Works, Environmental Division, (817) 392-6088. 2) TCEQ Notice of Change required if making changes or updates to NOI 3) Provide erosion and sediment control in accordance with: a) Section 3125 00 b) The Drawings c) TXR150000 General Permit d) SWPPP e) TCEQ requirements 4) Once the project has been completed and all the closeout requirements of TCEQ have been met a TCEQ Notice of Termination can be submitted. a) Send copy to City Department of Transportation and Public Works, Environmental Division, (817) 392-6088. 40 1.5 SUBMITTALS 41 42 43 44 45 46 47 A. SWPPP Submit in accordance with Section 01 33 00, except as stated herein. a. Prior to the Preconstruction Meeting, submit a draft copy of SWPPP to the City as follows: 1) 1 copy to the City Project Manager a) City Project Manager will forward to the City Department of Transportation and Public Works, Environmental Division for review CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised July 1, 2011 0157 13 - 3 DAP STORM WATER POLLUTION PREVENTION Page 3 of 3 1 B. Modified SWPPP 2 1. If the SWPPP is revised during construction, resubmit modified SWPPP to the City 3 in accordance with Section 0133 00. 4 1.6 ACTION SUBMITTALSANFORMATIONAL SUBMITTALS [NOT USED] 5 1.7 CLOSEOUT SUBMITTALS [NOT USED] 6 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 7 1.9 QUALITY ASSURANCE [NOT USED] 8 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] 9 1.11 FIELD [SITE] CONDITIONS [NOT USED] R 10 1.12 WARRANTY [NOT USED] 11 PART 2 - PRODUCTS [NOT USED] 12 PART 3 - EXECUTION [NOT USED] 13 END OF SECTION 14 Revision Log .,. I DATE NAME SUMMARY OF CHANGE PM - CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 ..i Revised July 1, 2011 i 1 2 3 PART1- GENERAL 4 1.1 SUMMARY SECTION 0160 00 PRODUCT REQUIREMENTS 01 60 00 - 1 DAP PRODUCT REQUIREMENTS Page I of 2 5 A. Section Includes: 6 1. References for Product Requirements and City Standard Products List 7 B. Deviations from this City of Fort Worth Standard Specification 8 1. None. 9 C. Related Specification Sections include, but are not necessarily limited to: 10 1. Division 0 — Bidding Requirements, Contract Forms and Conditions of the Contract 11 2. Division 1 — General Requirements 12 1.2 PRICE AND PAYMENT PROCEDURES [NOT USED] 13 1.3 REFERENCES [NOT USED] 14 1.4 ADMINISTRATIVE REQUIREMENTS 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 34 A. A list of City approved products for use is located on Buzzsaw as follows: 1. Resources\02 - Construction Documents\Standard Products List B. Only products specifically included on City's Standard Product List in these Contract Documents shall be allowed for use on the Project. 1. Any subsequently approved products will only be allowed for use upon specific approval by the City. C. Any specific product requirements in the Contract Documents supersede similar products included on the City's Standard Product List. 1. The City reserves the right to not allow products to be used for certain projects even though the product is listed on the City's Standard Product List. D. Although a specific product is included on City's Standard Product List, not all products from that manufacturer are approved for use, including but not limited to, that manufacturer's standard product. E. See Section 01 33 00 for submittal requirements of Product Data included on City's Standard Product List. 1.5 SUBMITTALS [NOT USED] 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 1.7 CLOSEOUT SUBMITTALS [NOT USED] 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 1.9 QUALITY ASSURANCE [NOT USED] CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised April 7, 2014 016000-2 DAP PRODUCT REQUIREMENTS Page 2 of 2 1 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] '— 2 1.11 FIELD [SITE] CONDITIONS [NOT USED] 3 1.12 WARRANTY [NOT USED] 4 PART 2 - PRODUCTS [NOT USED] 5 PART 3 - EXECUTION [NOT USED] 6 END OF SECTION 7 Revision Log DATE NAME SUMMARY OF CHANGE 10/12/12 D. Johnson Modified Location of City's Standard Product List 4/7/2014 M.Domenech Revised for DAP application PM 8 m W* Me an r CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised April 7, 2014 01 66 00 - 1 DAP PRODUCT STORAGE AND HANDLING REQUIREMENTS Page I of 4 1 SECTION 0166 00 2 PRODUCT STORAGE AND HANDLING REQUIREMENTS 3 PART1- GENERAL 4 1.1 SUMMARY 5 A. Section Includes: 6 1. Scheduling of product delivery 7 2. Packaging of products for delivery 8 3. Protection of products against damage from: 9 a. Handling 10 b. Exposure to elements or harsh environments 11 B. Deviations from this City of Fort Worth Standard Specification 12 1. None. 13 C. Related Specification Sections include, but are not necessarily limited to: 14 1. Division 0 — Bidding Requirements, Contract Forms and Conditions of the Contract 15 2. Division 1 — General Requirements 16 1.2 PRICE AND PAYMENT PROCEDURES 17 A. Measurement and Payment 18 1. Work associated with this Item is considered subsidiary to the various Items bid. 19 No separate payment will be allowed for this Item. 20 1.3 REFERENCES [NOT USED] 21 1.4 ADMINISTRATIVE REQUIREMENTS [NOT USED] 22 1.5 SUBMITTALS [NOT USED] 23 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 24 1.7 CLOSEOUT SUBMITTALS [NOT USED] 25 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 26 1.9 QUALITY ASSURANCE [NOT USED] 27 1.10 DELIVERY AND HANDLING 28 A. Delivery Requirements 29 1. Schedule delivery of products or equipment as required to allow timely installation 30 and to avoid prolonged storage. 31 2. Provide appropriate personnel and equipment to receive deliveries. 32 3. Delivery trucks will not be permitted to wait extended periods of time on the Site 33 for personnel or equipment to receive the delivery. CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised April 7, 2014 i 01 66 00 - 2 DAP PRODUCT STORAGE AND HANDLING REQUIREMENTS Page 2 of 4 1 4. Deliver products or equipment in manufacturer's original unbroken cartons or other 2 containers designed and constructed to protect the contents from physical or 3 environmental damage. 4 5. Clearly and fully mark and identify as to manufacturer, item and installation 5 location. 6 6. Provide manufacturer's instructions for storage and handling. 7 B. Handling Requirements 8 1. Handle products or equipment in accordance with these Contract Documents and 9 manufacturer's recommendations and instructions. 10 C. Storage Requirements 11 1. Store materials in accordance with manufacturer's recommendations and 12 requirements of these Specifications. 13 2. Make necessary provisions for safe storage of materials and equipment. 14 a. Place loose soil materials and materials to be incorporated into Work to prevent 15 damage to any part of Work or existing facilities and to maintain free access at 16 all times to all parts of Work and to utility service company installations in 17 vicinity of Work. 18 3. Keep materials and equipment neatly and compactly stored in locations that will 19 cause minimum inconvenience to other contractors, public travel, adjoining owners, 20 tenants and occupants. 21 a. Arrange storage to provide easy access for inspection. 22 4. Restrict storage to areas available on construction site for storage of material and 23 equipment as shown on Drawings, or approved by City's Project Representative. 24 5. Provide off -site storage and protection when on -site storage is not adequate. 25 a. Provide addresses of and access to off -site storage locations for inspection by 26 City's Project Representative. 27 6. Do not use lawns, grass plots or other private property for storage purposes without 28 written permission of owner or other person in possession or control of premises. 29 7. Store in manufacturers' unopened containers. 30 8. Neatly, safely and compactly stack materials delivered and stored along line of 31 Work to avoid inconvenience and damage to property owners and general public 32 and maintain at least 3 feet from fire hydrant. 33 9. Keep public and private driveways and street crossings open. 34 10. Repair or replace damaged lawns, sidewalks, streets or other improvements to 35 satisfaction of City's Project Representative. 36 a. Total length which materials may be distributed along route of construction at 37 one time is 1,000 linear feet, unless otherwise approved in writing by City's 38 Project Representative. CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 10I876 Revised April 7, 2014 016600-3 DAP PRODUCT STORAGE AND HANDLING REQUIREMENTS Page 3 of 4 1 1.11 FIELD [SITE] CONDITIONS [NOT USED] 2 1.12 WARRANTY [NOT USED] 3 PART 2 - PRODUCTS [NOT USED] 4 PART 3 - EXECUTION 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 go 3.1 INSTALLERS [NOT USED] 3.2 EXAMINATION [NOT USED] 3.3 PREPARATION [NOT USED] 3.4 ERECTION [NOT USED] 3.5 REPAIR / RESTORATION [NOT USED] 3.6 RE -INSTALLATION [NOT USED] 3.7 FIELD [OR] SITE QUALITY CONTROL A. Tests and Inspections 1. Inspect all products or equipment delivered to the site prior to unloading. B. Non -Conforming Work 1. Reject all products or equipment that are damaged, used or in any other way unsatisfactory for use on the project. 3.8 SYSTEM STARTUP [NOT USED] 3.9 ADJUSTING [NOT USED] 3.10 CLEANING [NOT USED] 3.11 CLOSEOUT ACTIVITIES [NOT USED] 3.12 PROTECTION A. Protect all products or equipment in accordance with manufacturer's written directions. B. Store products or equipment in location to avoid physical damage to items while in storage. C. Protect equipment from exposure to elements and keep thoroughly dry if required by the manufacturer. 3.13 MAINTENANCE [NOT USED] 3.14 ATTACHMENTS [NOT USED] END OF SECTION CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised April 7, 20I4 1 rir ON DATE 4/7/2014 01 66 00 - 4 DAP PRODUCT STORAGE AND HANDLING REQUIREMENTS Page 4 of 4 Revision Log NAME SUMMARY OF CHANGE M.Domenech Revised for DAP application CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Ip Revised April 7, 2014 1 2 3 PART1- GENERAL 4 1.1 SUMMARY 5 A. Section Includes: 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 r 27 017000-1 DAP MOBILIZATION AND REMOBILIZATION Page 1 of 6 SECTION 0170 00 MOBILIZATION AND REMOBILIZATION 1. Mobilization and Demobilization a. Mobilization 1) Transportation of Contractor's personnel, equipment, and operating supplies to the Site 2) Establishment of necessary general facilities for the Contractor's operation at the Site 3) Premiums paid for performance and payment bonds 4) Transportation of Contractor's personnel, equipment, and operating supplies to another location within the designated Site 5) Relocation of necessary general facilities for the Contractor's operation from 1 location to another location on the Site. b. Demobilization 1) Transportation of Contractor's personnel, equipment, and operating supplies away from the Site including disassembly 2) Site Clean-up 3) Removal of all buildings and/or other facilities assembled at the Site for this Contract c. Mobilization and Demobilization do not include activities for specific items of work that are for which payment is provided elsewhere in the contract. 2. Remobilization a. Remobilization for Suspension of Work specifically required in the Contract Documents or as required by City includes: CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS— DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised April 7, 2014 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 017000-2 DAP MOBILIZATION AND REMOBILIZATION Page 2 of 6 1) Demobilization a) Transportation of Contractor's personnel, equipment, and operating supplies from the Site including disassembly or temporarily securing equipment, supplies, and other facilities as designated by the Contract Documents necessary to suspend the Work. b) Site Clean-up as designated in the Contract Documents 2) Remobilization a) Transportation of Contractor's personnel, equipment, and operating supplies to the Site necessary to resume the Work. b) Establishment of necessary general facilities for the Contractor's operation at the Site necessary to resume the Work. 3) No Payments will be made for: a) Mobilization and Demobilization from one location to another on the Site in the normal progress of performing the Work. b) Stand-by or idle time c) d) Lost profits 3. Mobilizations and Demobilization for Miscellaneous Projects a. Mobilization and Demobilization 1) Mobilization shall consist of the activities and cost on a Work Order basis necessary for: a) Transportation of Contractor's personnel, equipment, and operating supplies to the Site for the issued Work Order. b) Establishment of necessary general facilities for the Contractor's operation at the Site for the issued Work Order 2) Demobilization shall consist of the activities and cost necessary for: a) Transportation of Contractor's personnel, equipment, and operating supplies from the Site including disassembly for each issued Work Order b) Site Clean-up for each issued Work Order CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS— DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised April 7, 2014 017000-3 DAP MOBILIZATION AND REMOBILIZATION Page 3 of 6 1 c) Removal of all buildings or other facilities assembled at the Site for 2 each Work Oder 3 b. Mobilization and Demobilization do not include activities for specific items of 4 work for which payment is provided elsewhere in the contract. 5 4. Emergency Mobilizations and Demobilization for Miscellaneous Projects 6 a. A Mobilization for Miscellaneous Projects when directed by the City and the 7 mobilization occurs within 24 hours of the issuance of the Work Order. 8 B. Deviations from this City of Fort Worth Standard Specification 9 1. None. 10 C. Related Specification Sections include, but are not necessarily limited to: 11 1. Division 0 — Bidding Requirements, Contract Forms and Conditions of the Contract 12 2. Division 1— General Requirements 13 1.2 PRICE AND PAYMENT PROCEDURES 14 A. Measurement and Payment 15 1. Mobilization and Demobilization 16 a. Measure 17 1) This Item is considered subsidiary to the various Items bid. 18 b. Payment 19 1) The work performed and materials furnished in accordance with this Item 20 are subsidiary to the various Items bid and no other compensation will be R 21 allowed. _ 22 2. Remobilization for suspension of Work as specifically required in the Contract 23 Documents 24 a. Measurement 25 1) Measurement for this Item shall be per each remobilization performed. 26 b. Payment CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS— DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised April 7, 2014 017000-4 DAP MOBILIZATION AND REMOBILIZATION Page 4 of 6 1 1) The work performed and materials furnished in accordance with this Item 2 and measured as provided under "Measurement" will be paid for at the 3 unit price per each "Specified Re mobilization" in accordance with 4 Contract Documents. 5 c. The price shall include: 6 1) Demobilization as described in Section 1.1.A.2.a.1) 7 2) Remobilization as described in Section 1.1.A.2.a.2) 8 d. No payments will be made for standby, idle time, or lost profits associated this 9 Item. 10 3. Remobilization for suspension of Work as required by City 11 a. Measurement and Payment 12 1) This shall be submitted as a Contract Claim in accordance with Article 10 13 of Section 00 72 00. 14 2) No payments will be made for standby, idle time, or lost profits associated 15 with this Item. 16 4. Mobilizations and Demobilizations for Miscellaneous Projects 17 a. Measurement 18 1) Measurement for this Item shall be for each Mobilization and 19 Demobilization required by the Contract Documents 20 b. Payment 21 1) The Work performed and materials furnished in accordance with this Item 22 and measured as provided under "Measurement" will be paid for at the 23 unit price per each "Work Order Mobilization" in accordance with 24 Contract Documents. Demobilization shall be considered subsidiary to 25 mobilization and shall not be paid for separately. 26 c. The price shall include: 27 1) Mobilization as described in Section 1.1.A.3.a.1) 28 2) Demobilization as described in Section 1.1.A.3.a.2) 29 d. No payments will be made for standby, idle time, or lost profits associated this 30 Item. CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS— DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised April 7, 2014 017000-5 DAP MOBILIZATION AND REMOBILIZATION Page 5 of 6 1 5. Emergency Mobilizations and Demobilizations for Miscellaneous Projects 2 a. Measurement 3 1) Measurement for this Item shall be for each Mobilization and 4 Demobilization required by the Contract Documents 5 b. Payment 6 1) The Work performed and materials furnished in accordance with this Item 7 and measured as provided under "Measurement" will be paid for at the 8 unit price per each "Work Order Emergency Mobilization" in accordance 9 with Contract Documents. Demobilization shall be considered subsidiary 10 to mobilization and shall not be paid for separately. 11 c. The price shall include 12 1) Mobilization as described in Section 1.1.A.4.a) 13 2) Demobilization as described in Section 1.1.A.3.a.2) 14 d. No payments will be made for standby, idle time, or lost profits associated this 15 Item. 16 1.3 REFERENCES [NOT USED] 17 1.4 ADMINISTRATIVE REQUIREMENTS [NOT USED] 18 1.5 SUBMITTALS [NOT USED] 19 1.6 INFORMATIONAL SUBMITTALS [NOT USED] 20 1.7 CLOSEOUT SUBMITTALS [NOT USED] 21 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 22 1.9 QUALITY ASSURANCE [NOT USED] 23 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] 24 1.11 FIELD [SITE] CONDITIONS [NOT USED] 25 1.12 WARRANTY [NOT USED] CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS— DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised April 7, 2014 1 PART 2 - PRODUCTS [NOT USED] 2 PART 3 - EXECUTION [NOT USED] 3 END OF SECTION 4 5 017000-6 DAP MOBILIZATION AND REMOBILIZATION Page 6 of 6 Revision Log DATE NAME SUMMARY OF CHANGE 4/7/2014 M.Domenech Revised for DAP application CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS— DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised April 7, 2014 i i 1 i 2 3 PART1- GENERAL 4 WE 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 34 01 74 23 - 1 DAP CLEANING Page 1'of4 SECTION 0174 23 CLEANING 1.1 SUMMARY A. Section Includes: 1. Intermediate and final cleaning for Work not including special cleaning of closed systems specified elsewhere B. Deviations from this City of Fort Worth Standard Specification 1. None. C. Related Specification Sections include, but are not necessarily limited to: 1. Division 0 — Bidding Requirements, Contract Forms and Conditions of the Contract 2. Division 1 — General Requirements 3. Section 32 92 13 — Hydro -Mulching, Seeding and Sodding 1.2 PRICE AND PAYMENT PROCEDURES A. Measurement and Payment 1. Work associated with this Item is considered subsidiary to the various Items bid. No separate payment will be allowed for this Item. 1.3 REFERENCES [NOT USED] 1.4 ADMINISTRATIVE REQUIREMENTS A. Scheduling 1. Schedule cleaning operations so that dust and other contaminants disturbed by cleaning process will not fall on newly painted surfaces. 2. Schedule final cleaning upon completion of Work and immediately prior to final inspection. 1.5 SUBMITTALS [NOT USED] 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 1.7 CLOSEOUT SUBMITTALS [NOT USED] 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 1.9 QUALITY ASSURANCE [NOT USED] 1.10 STORAGE, AND HANDLING A. B. Storage and Handling Requirements 1. Store cleaning products and cleaning wastes in containers specifically designed for those materials. CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised April 7, 2014 1 1.11 FIELD [SITE] CONDITIONS [NOT USED] 2 1.12 WARRANTY [NOT USED] 3 PART 2 - PRODUCTS 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 wr 21 22 +f 23 24 w 25 26 27 28 29 w■ 30 31 32 �I 01 74 23 - 2 DAP CLEANING Page 2 of 4 2.1 OWNER -FURNISHED [OR] OWNER-SUPPLIEDPRODUCTS [NOT USED] 2.2 MATERIALS A. Cleaning Agents 1. Compatible with surface being cleaned 2. New and uncontaminated 3. For manufactured surfaces a. Material recommended by manufacturer 2.3 ACCESSORIES [NOT USED] 2.4 SOURCE QUALITY CONTROL [NOT USED] PART 3 - EXECUTION 3.1 INSTALLERS [NOT USED] 3.2 EXAMINATION [NOT USED] 3.3 PREPARATION [NOT USED] 3.4 APPLICATION [NOT USED] 3.5 REPAIR / RESTORATION [NOT USED] 3.6 RE -INSTALLATION [NOT USED] 3.7 FIELD [oR] SITE QUALITY CONTROL [NOT USED] 3.8 SYSTEM STARTUP [NOT USED] 3.9 ADJUSTING [NOT USED] 3.10 CLEANING A. General 1. Prevent accumulation of wastes that create hazardous conditions. 2. Conduct cleaning and disposal operations to comply with laws and safety orders of governing authorities. 3. Do not dispose of volatile wastes such as mineral spirits, oil or paint thinner in storm or sanitary drains or sewers. 4. Dispose of degradable debris at an approved solid waste disposal site. 5. Dispose of nondegradable debris at an approved solid waste disposal site or in an alternate manner approved by City and regulatory agencies. CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised April 7, 2014 01 74 23 - 3 DAP CLEANING Page 3 of 4 1 6. Handle materials in a controlled manner with as few handlings as possible. 2 7. Thoroughly clean, sweep, wash and polish all Work and equipment associated with 3 this project. 4 8. Remove all signs of temporary construction and activities incidental to construction 5 of required permanent Work. 6 9. If project is not cleaned to the satisfaction of the City, the City reserves the right to 7 have the cleaning completed at the expense of the Contractor. 8 10. Do not burn on -site. 9 B. Intermediate Cleaning during Construction 10 1. Keep Work areas clean so as not to hinder health, safety or convenience of 11 personnel in existing facility operations. 12 2. At maximum weekly intervals, dispose of waste materials, debris and rubbish. 13 3. Confine construction debris daily in strategically located container(s): 14 a. Cover to prevent blowing by wind 15 b. Store debris away from construction or operational activities 16 c. Haul from site at a minimum of once per week 17 4. Vacuum clean interior areas when ready to receive finish painting. 18 a. Continue vacuum cleaning on an as -needed basis, until Final Acceptance. 19 5. Prior to storm events, thoroughly clean site of all loose or unsecured items, which 20 may become airborne or transported by flowing water during the storm. 21 C. Exterior (Site or Right of Way) Final Cleaning 22 1. Remove trash and debris containers from site. 23 a. Re -seed areas disturbed by location of trash and debris containers in accordance 24 with Section 32 92 13. 25 2. Sweep roadway to remove all rocks, pieces of asphalt, concrete or any other object 26 that may hinder or disrupt the flow of traffic along the roadway. 27 3. Clean any interior areas including, but not limited to, vaults, manholes, structures, 28 junction boxes and inlets. 29 4. If no longer required for maintenance of erosion facilities, and upon approval by 30 City, remove erosion control from site. 31 5. Clean signs, lights, signals, etc. 32 3.11 CLOSEOUT ACTIVITIES [NOT USED] 33 3.12 PROTECTION [NOT USED] 34 3.13 MAINTENANCE [NOT USED] 35 3.14 ATTACHMENTS [NOT USED] 36 37 38 39 40 CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 i Revised April 7, 2014 1 2 3 Im 01 74 23 - 4 DAP CLEANING Page 4 of 4 END OF SECTION Revision Log DATE NAME SUMMARY OF CHANGE 47/2014 M.Domenech Revised for DAP application CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised April 7, 2014 017719-1 DAP CLOSEOUT REQUIREMENTS Page 1 of 3 1 SECTION 0177 19 2 CLOSEOUT REQUIREMENTS 3 PART1- GENERAL 4 1.1 SUMMARY T 5 A. Section Includes: 6 1. The procedure for closing out a contract 7 B. Deviations from this City of Fort Worth Standard Specification 8 1. None. _ 9 C. Related Specification Sections include, but are not necessarily limited to: 10 1. Division 0 — Bidding Requirements, Contract Forms and Conditions of the Contract 11 2. Division 1 — General Requirements 12 1.2 PRICE AND PAYMENT PROCEDURES 13 A. Measurement and Payment 14 1. Work associated with this Item is considered subsidiary to the various Items bid. 15 No separate payment will be allowed for this Item. 16 i 1.3 REFERENCES [NOT USED] 17 1.4 ADMINISTRATIVE REQUIREMENTS 18 A. Guarantees, Bonds and Affidavits Mo 19 1. No application for final payment will be accepted until all guarantees, bonds, 20 certificates, licenses and affidavits required for Work or equipment as specified are 21 satisfactorily filed with the City. 22 B. Release of Liens or Claims 23 1. No application for final payment will be accepted until satisfactory evidence of 24 release of liens has been submitted to the City. 25 1.5 SUBMITTALS -� 26 A. Submit all required documentation to City's Project Representative. am CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised April 7, 2014 1 1.6 INFORMATIONAL SUBMITTALS [NOT USED] 2 1.7 CLOSEOUT SUBMITTALS [NOT USED] 3 PART 2 - PRODUCTS [NOT USED] 4 PART 3 - EXECUTION 5 3.1 INSTALLERS [NOT USED] 6 3.2 EXAMINATION [NOT USED] 7 3.3 PREPARATION [NOT USED] 8 3.4 CLOSEOUT PROCEDURE 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 0177 19 - 2 DAP CLOSEOUT REQUIREMENTS Page 2 of 3 A. Prior to requesting Final Inspection, submit: 1. Project Record Documents in accordance with Section 01 78 39 2. Operation and Maintenance Data, if required, in accordance with Section 01 78 23 B. Prior to requesting Final Inspection, perform final cleaning in accordance with Section 01 7423. C. Final Inspection 1. After final cleaning, provide notice to the City Project Representative that the Work is completed. a. The City will make an initial Final Inspection with the Contractor present. b. Upon completion of this inspection, the City will notify the Contractor, in writing within 10 business days, of any particulars in which this inspection reveals that the Work is defective or incomplete. 2. Upon receiving written notice from the City, immediately undertake the Work required to remedy deficiencies and complete the Work to the satisfaction of the City. 3. Upon completion of Work associated with the items listed in the City's written notice, inform the City, that the required Work has been completed. Upon receipt of this notice, the City, in the presence of the Contractor, will make a subsequent Final Inspection of the project. 4. Provide all special accessories required to place each item of equipment in full operation. These special accessory items include, but are not limited to: a. Specified spare parts b. Adequate oil and grease as required for the first lubrication of the equipment c. Initial fill up of all chemical tanks and fuel tanks d. Light bulbs e. Fuses f. Vault keys g. Handwheels h. Other expendable items as required for initial start-up and operation of all equipment D. Notice of Project Completion CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised April 7, 2014 PM 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 017719-3 DAP CLOSEOUT REQUIREMENTS Page 3 of 3 1. Once the City Project Representative finds the Work subsequent to Final Inspection to be satisfactory, the City will issue a Notice of Project Completion (Green Sheet). E. Supporting Documentation 1. Coordinate with the City Project Representative to complete the following additional forms: a. Final Payment Request b. Statement of Contract Time c. Affidavit of Payment and Release of Liens d. Consent of Surety to Final Payment e. Pipe Report (if required) f. Contractor's Evaluation of City g. Performance Evaluation of Contractor F. Letter of Final Acceptance 1. Upon review and acceptance of Notice of Project Completion and Supporting Documentation, in accordance with General Conditions, City will issue Letter of Final Acceptance and release the Final Payment Request for payment. 3.5 REPAIR / RESTORATION [NOT USED] 3.6 RE -INSTALLATION [NOT USED] 3.7 FIELD [OR] SITE QUALITY CONTROL [NOT USED] 3.8 SYSTEM STARTUP [NOT USED] 3.9 ADJUSTING [NOT USED] 3.10 CLEANING [NOT USED] 3.11 CLOSEOUT ACTIVITIES [NOT USED] 3.12 PROTECTION [NOT USED] 3.13 MAINTENANCE [NOT USED] 3.14 ATTACHMENTS [NOT USED] END OF SECTION Revision Log DATE NAME SUMMARY OF CHANGE 4/7/2014 M.Domenech Revised for DAP application CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. I01876 Revised April 7, 2014 01 78 23 - 1 DAP OPERATION AND MAINTENANCE DATA Page 1 of 5 1 SECTION 0178 23 2 OPERATION AND MAINTENANCE DATA 3 PART1- GENERAL 4 1.1 SUMMARY 5 A. Section Includes: 6 1. Product data and related information appropriate for City's maintenance and 7 operation of products furnished under Contract 8 2. Such products may include, but are not limited to: 9 a. Traffic Controllers 10 b. Irrigation Controllers (to be operated by the City) 11 c. Butterfly Valves 12 B. Deviations from this City of Fort Worth Standard Specification 13 1. None. 14 C. Related Specification Sections include, but are not necessarily limited to: 15 1. Division 0 — Bidding Requirements, Contract Forms and Conditions of the Contract 16 2. Division 1 — General Requirements 17 1.2 PRICE AND PAYMENT PROCEDURES 18 A. Measurement and Payment 19 1. Work associated with this Item is considered subsidiary to the various Items bid. 20 No separate payment will be allowed for this Item. 21 1.3 REFERENCES [NOT USED] - 22 1.4 ADMINISTRATIVE REQUIREMENTS 23 A. Schedule _ 24 1. Submit manuals in final form to the City within 30 calendar days of product 25 shipment to the project site. 26 1.5 SUBMITTALS 27 A. Submittals shall be in accordance with Section 0133 00. All submittals shall be 28 approved by the City prior to delivery. 29 1.6 INFORMATIONAL SUBMITTALS 30 A. Submittal Form _ 31 1. Prepare data in form of an instructional manual for use by City personnel. 32 2. Format 33 a. Size: 8 '/2 inches x 11 inches _ 34 b. Paper 35 1) 40 pound minimum, white, for typed pages 36 2) Holes reinforced with plastic, cloth or metal i 37 c. Text: Manufacturer's printed data, or neatly typewritten CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 '� Revised April 7, 2014 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 40 41 42 43 44 45 46 47 48 w.� 01 78 23 - 2 DAP OPERATION AND MAINTENANCE DATA Page 2 of 5 d. Drawings 1) Provide reinforced punched binder tab, bind in with text 2) Reduce larger drawings and fold to size of text pages. e. Provide fly -leaf for each separate product, or each piece of operating equipment. 1) Provide typed description of product, and major component parts of equipment. 2) Provide indexed tabs. f. Cover 1) Identify each volume with typed or printed title "OPERATING AND MAINTENANCE INSTRUCTIONS". 2) List: a) Title of Project b) Identity of separate structure as applicable c) Identity of general subject matter covered in the manual 3. Binders a. Commercial quality 3-ring binders with durable and cleanable plastic covers b. When multiple binders are used, correlate the data into related consistent groupings. 4. If available, provide an electronic form of the O&M Manual. B. Manual Content 1. Neatly typewritten table of contents for each volume, arranged in systematic order a. Contractor, name of responsible principal, address and telephone number b. A list of each product required to be included, indexed to content of the volume c. List, with each product: 1) The name, address and telephone number of the subcontractor or installer 2) A list of each product required to be included, indexed to content of the volume 3) Identify area of responsibility of each 4) Local source of supply for parts and replacement d. Identify each product by product name and other identifying symbols as set forth in Contract Documents. 2. Product Data a. Include only those sheets which are pertinent to the specific product. b. Annotate each sheet to: 1) Clearly identify specific product or part installed 2) Clearly identify data applicable to installation 3) Delete references to inapplicable information 3. Drawings a. Supplement product data with drawings as necessary to clearly illustrate: 1) Relations of component parts of equipment and systems 2) Control and flow diagrams b. Coordinate drawings with information in Project Record Documents to assure correct illustration of completed installation. c. Do not use Project Record Drawings as maintenance drawings. 4. Written text, as required to supplement product data for the particular installation: a. Organize in consistent format under separate headings for different procedures. b. Provide logical sequence of instructions of each procedure. CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised April 7, 2014 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 40 41 42 43 44 45 46 47 48 01 78 23 - 3 DAP OPERATION AND MAINTENANCE DATA Page 3 of 5 5. Copy of each warranty, bond and service contract issued a. Provide information sheet for City personnel giving: 1) Proper procedures in event of failure 2) Instances which might affect validity of warranties or bonds C. Manual for Materials and Finishes 1. Submit 5 copies of complete manual in final form. 2. Content, for architectural products, applied materials and finishes: a. Manufacturer's data, giving full information on products 1) Catalog number, size, composition 2) Color and texture designations 3) Information required for reordering special manufactured products b. Instructions for care and maintenance 1) Manufacturer's recommendation for types of cleaning agents and methods 2) Cautions against cleaning agents and methods which are detrimental to product 3) Recommended schedule for cleaning and maintenance 3. Content, for moisture protection and weather exposure products: a. Manufacturer's data, giving full information on products 1) Applicable standards 2) Chemical composition 3) Details of installation b. Instructions for inspection, maintenance and repair D. Manual for Equipment and Systems 1. Submit 5 copies of complete manual in final form. 2. Content, for each unit of equipment and system, as appropriate: a. Description of unit and component parts 1) Function, normal operating characteristics and limiting conditions 2) Performance curves, engineering data and tests 3) Complete nomenclature and commercial number of replaceable parts b. Operating procedures 1) Start-up, break-in, routine and normal operating instructions 2) Regulation, control, stopping, shut -down and emergency instructions 3) Summer and winter operating instructions 4) Special operating instructions c. Maintenance procedures 1) Routine operations 2) Guide to "trouble shooting" 3) Disassembly, repair and reassembly 4) Alignment, adjusting and checking d. Servicing and lubrication schedule 1) List of lubricants required e. Manufacturer's printed operating and maintenance instructions f. Description of sequence of operation by control manufacturer 1) Predicted life of parts subject to wear 2) Items recommended to be stocked as spare parts g. As installed control diagrams by controls manufacturer h. Each contractor's coordination drawings 1) As installed color coded piping diagrams CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised April 7, 2014 M 01 78 23 - 4 DAP OPERATION AND MAINTENANCE DATA Page 4 of 5 1 i. Charts of valve tag numbers, with location and function of each valve 2 j. List of original manufacturer's spare parts, manufacturer's current prices, and 3 recommended quantities to be maintained in storage 4 k. Other data as required under pertinent Sections of Specifications 5 3. Content, for each electric and electronic system, as appropriate: 6 a. Description of system and component parts 7 1) Function, normal operating characteristics, and limiting conditions 8 2) Performance curves, engineering data and tests 9 3) Complete nomenclature and commercial number of replaceable parts 10 b. Circuit directories of panelboards 11 1) Electrical service -- 12 2) Controls 13 3) Communications 14 c. As installed color coded wiring diagrams 15 d. Operating procedures 16 1) Routine and normal operating instructions 17 2) Sequences required 18 3) Special operating instructions 19 e. Maintenance procedures 20 1) Routine operations 21 2) Guide to "trouble shooting" 22 3) Disassembly, repair and reassembly 23 4) Adjustment and checking 24 f. Manufacturer's printed operating and maintenance instructions 25 g. List of original manufacturer's spare parts, manufacturer's current prices, and 26 recommended quantities to be maintained in storage 27 h. Other data as required under pertinent Sections of Specifications 28 4. Prepare and include additional data when the need for such data becomes apparent 29 during instruction of City's personnel. 30 1.7 CLOSEOUT SUBMITTALS [NOT USED] 31 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 32 1.9 QUALITY ASSURANCE 33 A. Provide operation and maintenance data by personnel with the following criteria: _ 34 1. Trained and experienced in maintenance and operation of described products 35 2. Skilled as technical writer to the extent required to communicate essential data 36 3. Skilled as draftsman competent to prepare required drawings mr CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised April 7, 2014 01 78 23 - 5 DAP OPERATION AND MAINTENANCE DATA Page 5 of 5 1 1.10 DELIVERY, STORAGE, AND HANDLING [NOT USED] 2 1.11 FIELD [SITE] CONDITIONS [NOT USED] 3 1.12 WARRANTY [NOT USED] 4 PART 2 - PRODUCTS [NOT USED] 5 PART 3 - EXECUTION [NOT USED] 6 END OF SECTION 7 Revision Log IDATE NAME SUMMARY OF CHANGE i 8/31/2012 D. Johnson 1.5.A.1 —title of section removed 4/7/2014 M.Domenech Revised for DAP Application 8 w w MW CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised April 7, 2014 q, M Mt am M i 1 2 3 PART1- GENERAL 4 1.1 SUMMARY 01 78 39 - 1 DAP PROJECT RECORD DOCUMENTS Page 1 of 4 SECTION 0178 39 PROJECT RECORD DOCUMENTS 5 A. Section Includes: 6 1. Work associated with the documenting the project and recording changes to project 7 documents, including: 8 a. Record Drawings 9 b. Water Meter Service Reports 10 c. Sanitary Sewer Service Reports 11 d. Large Water Meter Reports 12 B. Deviations from this City of Fort Worth Standard Specification 13 1. None. 14 C. Related Specification Sections include, but are not necessarily limited to: 15 1. Division 0 — Bidding Requirements, Contract Forms and Conditions of the Contract 16 2. Division 1 — General Requirements 17 1.2 PRICE AND PAYMENT PROCEDURES 18 A. Measurement and Payment 19 1. Work associated with this Item is considered subsidiary to the various Items bid. 20 No separate payment will be allowed for this Item. 21 1.3 REFERENCES [NOT USED] 22 1.4 ADMINISTRATIVE REQUIREMENTS [NOT USED] 23 1.5 SUBMITTALS 24 A. Prior to submitting a request for Final Inspection, deliver Project Record Documents to 25 City's Project Representative. 26 1.6 ACTION SUBMITTALS/INFORMATIONAL SUBMITTALS [NOT USED] 27 1.7 CLOSEOUT SUBMITTALS [NOT USED] 28 1.8 MAINTENANCE MATERIAL SUBMITTALS [NOT USED] 29 1.9 QUALITY ASSURANCE 30 A. Accuracy of Records 31 1. Thoroughly coordinate changes within the Record Documents, making adequate 32 and proper entries on each page of Specifications and each sheet of Drawings and 33 other Documents where such entry is required to show the change properly. 34 2. Accuracy of records shall be such that future search for items shown in the Contract 35 Documents may rely reasonably on information obtained from the approved Project 36 Record Documents. CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. I01876 Revised April 7, 20I4 01 78 39 - 2 DAP PROJECT RECORD DOCUMENTS Page 2 of 4 1 3. To facilitate accuracy of records, make entries within 24 hours after receipt of 2 information that the change has occurred. 3 4. Provide factual information regarding all aspects of the Work, both concealed and 4 visible, to enable future modification of the Work to proceed without lengthy and i 5 expensive site measurement, investigation and examination. 6 1.10 STORAGE AND HANDLING 7 y A. Storage and Handling Requirements 8 1. Maintain the job set of Record Documents completely protected from deterioration 9 and from loss and damage until completion of the Work and transfer of all recorded 10 data to the final Project Record Documents. 11 2. In the event of loss of recorded data, use means necessary to again secure the data 12 to the City's approval. 13 a. In such case, provide replacements to the standards originally required by the 14 Contract Documents. 15 1.11 FIELD [SITE] CONDITIONS [NOT USED] 16 1.12 WARRANTY [NOT USED] - 17 PART 2 - PRODUCTS 18 2.1 OWNER -FURNISHED [OR] OWNER -SUPPLIED PRODUCTS [NOT USED] 19 2.2 RECORD DOCUMENTS 20 A. Job set 21 1. Promptly following receipt of the Notice to Proceed, secure from the City, at no 22 charge to the Contractor, 1 complete set of all Documents comprising the Contract. 23 B. Final Record Documents 24 1. At a time nearing the completion of the Work and prior to Final Inspection, provide 25 the City 1 complete set of all Final Record Drawings in the Contract. 26 2.3 ACCESSORIES [NOT USED] 27 2.4 SOURCE QUALITY CONTROL [NOT USED] 28 PART 3 - EXECUTION 29 3.1 INSTALLERS [NOT USED] 30 3.2 EXAMINATION [NOT USED] 31 3.3 PREPARATION [NOT USED] 32 3.4 MAINTENANCE DOCUMENTS - 33 A. Maintenance of Job Set 34 1. Immediately upon receipt of the job set, identify each of the Documents with the 35 title, "RECORD DOCUMENTS - JOB SET". CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised April 7, 2014 ,.. i — 1 2 3 4 5 i 6 7 8 9 10 11 i 12 13 14 15 16 17 i 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 40 41 42 43 44 45 46 47 48 01 78 39 - 3 DAP PROJECT RECORD DOCUMENTS Page 3 of 4 2. Preservation a. Considering the Contract completion time, the probable number of occasions upon which the job set must be taken out for new entries and for examination, and the conditions under which these activities will be performed, devise a suitable method for protecting the job set. b. Do not use the job set for any purpose except entry of new data and for review by the City, until start of transfer of data to final Project Record Documents. c. Maintain the job set at the site of work. 3. Coordination with Construction Survey a. At a minimum clearly mark any deviations from Contract Documents associated with installation of the infrastructure. 4. Making entries on Drawings a. Record any deviations from Contract Documents. b. Use an erasable colored pencil (not ink or indelible pencil), clearly describe the change by graphic line and note as required. c. Date all entries. d. Call attention to the entry by a "cloud" drawn around the area or areas affected. e. In the event of overlapping changes, use different colors for the overlapping changes. 5. Conversion of schematic layouts a. In some cases on the Drawings, arrangements of conduits, circuits, piping, ducts, and similar items, are shown schematically and are not intended to portray precise physical layout. 1) Final physical arrangement is determined by the Contractor, subject to the City's approval. 2) However, design of future modifications of the facility may require accurate information as to the final physical layout of items which are shown only schematically on the Drawings. b. Show on the job set of Record Drawings, by dimension accurate to within 1 inch, the centerline of each run of items. 1) Final physical arrangement is determined by the Contractor, subject to the City's approval. 2) Show, by symbol or note, the vertical location of the Item ("under slab", "in ceiling plenum", "exposed", and the like). 3) Make all identification sufficiently descriptive that it may be related reliably to the Specifications. c. The City may waive the requirements for conversion of schematic layouts where, in the City's judgment, conversion serves no useful purpose. However, do not rely upon waivers being issued except as specifically issued in writing by the City. B. Final Project Record Documents 1. Transfer of data to Drawings a. Carefully transfer change data shown on the job set of Record Drawings to the corresponding final documents, coordinating the changes as required. b. Clearly indicate at each affected detail and other Drawing a full description of changes made during construction, and the actual location of items. c. Call attention to each entry by drawing a "cloud" around the area or areas affected. CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised April 7, 2014 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 01 78 39 - 4 DAP PROJECT RECORD DOCUMENTS Page 4 of 4 d. Make changes neatly, consistently and with the proper media to assure longevity and clear reproduction. 2. Transfer of data to other Documents a. If the Documents, other than Drawings, have been kept clean during progress of the Work, and if entries thereon have been orderly to the approval of the City, the job set of those Documents, other than Drawings, will be accepted as final Record Documents. b. If any such Document is not so approved by the City, secure a new copy of that Document from the City at the City's usual charge for reproduction and handling, and carefully transfer the change data to the new copy to the approval of the City. 3.5 REPAIR / RESTORATION [NOT USED] 3.6 RE -INSTALLATION [NOT USED] 3.7 FIELD [OR] SITE QUALITY CONTROL [NOT USED] 3.8 SYSTEM STARTUP [NOT USED] 3.9 ADJUSTING [NOT USED] 3.10 CLEANING [NOT USED] 3.11 CLOSEOUT ACTIVITIES [NOT USED] 3.12 PROTECTION [NOT USED] 3.13 MAINTENANCE [NOT USED] 3.14 ATTACHMENTS [NOT USED] END OF SECTION Revision Log DATE NAME SUMMARY OF CHANGE 4/7/2014 M.Domenech Revised for DAP Application CITY OF FORT WORTH Victory Shops at Bailey Boswell STANDARD CONSTRUCTION SPECIFICATION DOCUMENTS — DEVELOPER AWARDED PROJECTS City Project No. 101876 Revised April 7, 2014