Loading...
HomeMy WebLinkAboutContract 63125CSC No. 63125 CITY OF FORT WORTH, TEXAS STANDARD AGREEMENT FOR ENGINEERING RELATED PROFESSIONAL SERVICES This AGREEMENT is between the City of Fort Worth, a Texas home -rule municipality ("CITY"), and Baird, Hampton & Brown, Inc., authorized to do business in Texas, ("ENGINEER"), for a PROJECT generally described as: Pecan Valley Golf Course Bridge Replacement — Project No. 105401. Article I Scope of Services The Scope of Services is set forth in Attachment A. Negotiated changes to this Agreement, if any, are included in Attachment C. Article II Compensation The ENGINEER's compensation shall be in the amount up to Three Hundred Twenty -Five Thousand Three Hundred Fifty Dollars ($325,350.00) as set forth in Attachment B. Payment shall be considered full compensation for all labor (including all benefits, overhead and markups), materials, supplies, and equipment necessary to complete the Services. Engineer shall provide monthly invoices to City. The Engineer shall provide the City sufficient documentation, including but not limited to meeting the requirements set forth in Attachment D to this AGREEMENT, to reasonably substantiate the invoices. Payments for services rendered shall be made in accordance with the Texas Prompt Payment Act (Texas Government Code Ch. 2251). Acceptance by Engineer of said payment shall release City from all claims or liabilities under this Agreement for anything related to, performed, or furnished in connection with the Services for which payment is made, including any act or omission of City in connection with such Services. Article III Term Time is of the essence. Unless otherwise terminated pursuant to Article VI. D. herein, this Agreement shall be for a term beginning upon the effective date, as described below, and shall continue until the expiration of the funds or completion of the subject matter contemplated herein pursuant to the schedule, whichever occurs first. Unless specifically otherwise amended, the original term shall not exceed five years from the City of Fort Worth, Texas Pecan Valley Golf Course Bridge Replacement Standard Agreement for Engineering Related Design Services CPN 105401 Revised Date: 12-08-2023 Page 1 of 15 OFFICIAL RECORD CITY SECRETARY FT. WORTH, TX original effective date. Article IV Obligations of the Engineer A. General The ENGINEER will serve as the CITY's professional engineering representative under this Agreement, providing professional engineering consultation and advice and furnishing customary services incidental thereto. B. Standard of Care The ENGINEER shall perform its services: (1) with the professional skill and care ordinarily provided by competent engineers practicing under the same or similar circumstances and professional license; and (2) as expeditiously as is prudent considering the ordinary professional skill and care of a competent engineer. C. Designation of Engineer's Personnel (1) The ENGINEER and CITY shall agree upon the designation of the ENGINEER's "Project Manager" prior to starting work on contract. (2) ENGINEER shall inform CITY in writing of a proposed change to their designated project manager prior to making the change or immediately upon receiving notification that the designated project manager is separating employment with the ENGINEER. (3) ENGINEER shall provide resumes to the CITY of the proposed replacement project manager(s), who shall have similar qualifications and experience as the outgoing person, for review and approval. D. Subsurface Investigations (1) The ENGINEER shall advise the CITY with regard to the necessity for subcontract work such as special surveys, tests, test borings, or other subsurface investigations in connection with design and engineering work to be performed hereunder. The ENGINEER shall also advise the CITY concerning the results of same. Such surveys, tests, and investigations shall be furnished by the CITY, unless otherwise specified in Attachment A. City of Fort Worth, Texas Pecan Valley Golf Course Bridge Replacement Standard Agreement for Engineering Related Design Services CPN 105401 Revised Date: 12-08-2023 Page 2 of 15 (2) In soils, foundation, groundwater, and other subsurface investigations, the actual characteristics may vary significantly between successive test points and sample intervals and at locations other than where observations, exploration, and investigations have been made. Because of the inherent uncertainties in subsurface evaluations, changed or unanticipated underground conditions may occur that could affect the total PROJECT cost and/or execution. These conditions and cost/execution effects are not the responsibility of the ENGINEER. E. Preparation of Engineering Drawings The ENGINEER will provide to the CITY the original drawings of all plans in ink on reproducible mylar sheets and electronic files in .pdf format, or as otherwise approved by CITY, which shall become the property of the CITY. CITY may use such drawings in any manner it desires; provided, however, that the ENGINEER shall not be liable for the use of such drawings for any project other than the PROJECT described herein. F. Engineer's Personnel at Construction Site (1) The presence or duties of the ENGINEER's personnel at a construction site, whether as on -site representatives or otherwise, do not make the ENGINEER or its personnel in any way responsible for those duties that belong to the CITY and/or the CITY's construction contractors or other entities, and do not relieve the construction contractors or any other entity of their obligations, duties, and responsibilities, including, but not limited to, all construction methods, means, techniques, sequences, and procedures necessary for coordinating and completing all portions of the construction work in accordance with the contract documents and any health or safety precautions required by such construction work. The ENGINEER and its personnel have no authority to exercise any control over any construction contractor or other entity or their employees in connection with their work or any health or safety precautions. (2) Except to the extent of specific site visits expressly detailed and set forth in Attachment A, the ENGINEER or its personnel shall have no obligation or responsibility to visit the construction site to become familiar with the progress or quality of the completed work on the PROJECT or to determine, in general, if the work on the PROJECT is being performed in a manner indicating that the PROJECT, when completed, will be in accordance with the contract documents, nor shall anything in the contract documents or this AGREEMENT between CITY and ENGINEER be construed as requiring ENGINEER to make exhaustive or continuous on -site inspections to discover latent defects in the work or otherwise check the quality or quantity of the work City of Fort Worth, Texas Pecan Valley Golf Course Bridge Replacement Standard Agreement for Engineering Related Design Services CPN 105401 Revised Date: 12-08-2023 Page 3 of 15 on the PROJECT. If the ENGINEER makes on -site observation(s) of a deviation from the contract documents, the ENGINEER shall inform the CITY. (3) When professional certification of performance or characteristics of materials, systems or equipment is reasonably required to perform the services set forth in the Scope of Services, the ENGINEER shall be entitled to rely upon such certification to establish materials, systems or equipment and performance criteria to be required in the contract documents. G. Opinions of Probable Cost, Financial Considerations, and Schedules (1) The ENGINEER shall provide opinions of probable costs based on the current available information at the time of preparation, in accordance with Attachment A. (2) In providing opinions of cost, financial analyses, economic feasibility projections, and schedules for the PROJECT, the ENGINEER has no control over cost or price of labor and materials; unknown or latent conditions of existing equipment or structures that may affect operation or maintenance costs; competitive bidding procedures and market conditions; time or quality of performance by third parties; quality, type, management, or direction of operating personnel; and other economic and operational factors that may materially affect the ultimate PROJECT cost or schedule. Therefore, the ENGINEER makes no warranty that the CITY's actual PROJECT costs, financial aspects, economic feasibility, or schedules will not vary from the ENGINEER's opinions, analyses, projections, or estimates. H. Construction Progress Payments Recommendations by the ENGINEER to the CITY for periodic construction progress payments to the construction contractor will be based on the ENGINEER's knowledge, information, and belief from selective sampling and observation that the work has progressed to the point indicated. Such recommendations do not represent that continuous or detailed examinations have been made by the ENGINEER to ascertain that the construction contractor has completed the work in exact accordance with the contract documents; that the final work will be acceptable in all respects; that the ENGINEER has made an examination to ascertain how or for what purpose the construction contractor has used the moneys paid; that title to any of the work, materials, or equipment has passed to the CITY free and clear of liens, claims, security interests, or encumbrances; or that there are no other matters at issue between the CITY and the construction contractor that affect the amount that should be paid. City of Fort Worth, Texas Pecan Valley Golf Course Bridge Replacement Standard Agreement for Engineering Related Design Services CPN 105401 Revised Date: 12-08-2023 Page 4 of 15 I. Record Drawings Record drawings, if required, will be prepared, in part, on the basis of information compiled and furnished by others, and may not always represent the exact location, type of various components, or exact manner in which the PROJECT was finally constructed. The ENGINEER is not responsible for any errors or omissions in the information from others that is incorporated into the record drawings. J. Business Equity Participation City has goals for the full and equitable participation of minority business and/or women business enterprises in City contracts greater than $100,000. In accordance with the City's Business Equity Ordinance No. 25165-10-2021 (as codified in Chapter 20, Article X of the City's Code of Ordinances, as amended, and any relevant policy or guidance documents), Engineer acknowledges the MBE and WBE goals established for this Agreement and its execution of this Agreement is Engineer's written commitment to meet the prescribed MBE and WBE participation goals. Any misrepresentation of facts (other than a negligent misrepresentation) and/or the commission of fraud by the Engineer may result in the termination of this Agreement and debarment from participating in City contracts for a period of time of not less than three (3) years. K. Right to Audit (1) ENGINEER agrees that the CITY shall, until the expiration of five (5) years after final payment under this contract, have access to and the right to examine and photocopy any directly pertinent books, documents, papers and records of the ENGINEER involving transactions relating to this contract. ENGINEER agrees that the CITY shall have access during normal working hours to all necessary ENGINEER facilities and shall be provided adequate and appropriate work space in order to conduct audits in compliance with the provisions of this section. The CITY shall give ENGINEER reasonable advance notice of intended audits. (2) ENGINEER further agrees to include in all its subconsultant agreements hereunder a provision to the effect that the subconsultant agrees that the CITY shall, until the expiration of five (5) years after final payment under the subcontract, have access to and the right to examine and photocopy any directly pertinent books, documents, papers and records of such subconsultant, involving transactions to the subcontract, and further, that the CITY shall have access during normal working hours to all subconsultant facilities, and shall be provided adequate and appropriate work space, in order City of Fort Worth, Texas Pecan Valley Golf Course Bridge Replacement Standard Agreement for Engineering Related Design Services CPN 105401 Revised Date: 12-08-2023 Page 5 of 15 to conduct audits in compliance with the provisions of this article together with subsection (3) hereof. CITY shall give subconsultant reasonable advance notice of intended audits. (3) ENGINEER and subconsultant agree to reproduce such documents as may be requested by the CITY. The CITY agrees to reimburse ENGINEER for the cost of hard copies at the rate published in the Texas Administrative Code in effect as of the time copying is performed. L. INSURANCE Engineer shall not commence work under this Agreement until it has obtained all insurance required under Attachment F and City has approved such insurance. M. Independent Consultant The ENGINEER agrees to perform all services as an independent consultant and not as a subcontractor, agent, or employee of the CITY. The doctrine of respondent superior shall not apply. N. Disclosure The ENGINEER acknowledges to the CITY that it has made full disclosure in writing of any existing conflicts of interest or potential conflicts of interest, including personal financial interest, direct or indirect, in property abutting the proposed PROJECT and business relationships with abutting property cities. The ENGINEER further acknowledges that it will make disclosure in writing of any conflicts of interest that develop subsequent to the signing of this contract and prior to final payment under the contract. O. Asbestos or Hazardous Substances (1) If asbestos or hazardous substances in any form are encountered or suspected, the ENGINEER will stop its own work in the affected portions of the PROJECT to permit testing and evaluation. (2) If asbestos or other hazardous substances are suspected, the CITY may request the ENGINEER to assist in obtaining the services of a qualified subcontractor to manage the remediation activities of the PROJECT. P. Permitting Authorities - Design Changes If permitting authorities require design changes so as to comply with published design criteria and/or current engineering practice standards which the City of Fort Worth, Texas Pecan Valley Golf Course Bridge Replacement Standard Agreement for Engineering Related Design Services CPN 105401 Revised Date: 12-08-2023 Page 6 of 15 ENGINEER should have been aware of at the time this Agreement was executed, the ENGINEER shall revise plans and specifications, as required, at its own cost and expense. However, if design changes are required due to the changes in the permitting authorities' published design criteria and/or practice standards criteria which are published after the date of this Agreement which the ENGINEER could not have been reasonably aware of, the ENGINEER shall notify the CITY of such changes and an adjustment in compensation will be made through an amendment to this AGREEMENT. Q. Schedule ENGINEER shall manage the PROJECT in accordance with the schedule developed per Attachment D to this AGREEMENT. Article V Obligations of the City A. City -Furnished Data ENGINEER may rely upon the accuracy, timeliness, and completeness of the information provided by the CITY. B. Access to Facilities and Property The CITY will make its facilities accessible to the ENGINEER as required for the ENGINEER's performance of its services. The CITY will perform, at no cost to the ENGINEER, such tests of equipment, machinery, pipelines, and other components of the CITY's facilities as may be required in connection with the ENGINEER's services. The CITY will be responsible for all acts of the CITY's personnel. C. Advertisements, Permits, and Access Unless otherwise agreed to in the Scope of Services, the CITY will obtain, arrange, and pay for all advertisements for bids; permits and licenses required by local, state, or federal authorities; and land, easements, rights -of -way, and access necessary for the ENGINEER's services or PROJECT construction. D. Timely Review The CITY will examine the ENGINEER's studies, reports, sketches, drawings, specifications, proposals, and other documents; obtain advice of an attorney, insurance counselor, accountant, auditor, bond and financial advisors, and other consultants as the CITY deems appropriate; and render in writing City of Fort Worth, Texas Pecan Valley Golf Course Bridge Replacement Standard Agreement for Engineering Related Design Services CPN 105401 Revised Date: 12-08-2023 Page 7 of 15 decisions required by the CITY in a timely manner in accordance with the project schedule prepared in accordance with Attachment D. E. Prompt Notice The CITY will give prompt written notice to the ENGINEER whenever CITY observes or becomes aware of any development that affects the scope or timing of the ENGINEER's services or of any defect in the work of the ENGINEER or construction contractors. F. Asbestos or Hazardous Substances Release. (1) CITY acknowledges ENGINEER will perform part of the work at CITY's facilities that may contain hazardous materials, including asbestos containing materials, or conditions, and that ENGINEER had no prior role in the generation, treatment, storage, or disposition of such materials. In consideration of the associated risks that may give rise to claims by third parties or employees of City, City hereby releases ENGINEER from any damage or liability related to the presence of such materials. (2) The release required above shall not apply in the event the discharge, release or escape of hazardous substances, contaminants, or asbestos is a result of ENGINEER's negligence or if ENGINEER brings such hazardous substance, contaminant or asbestos onto the project. G. Contractor Indemnification The CITY agrees to include in all construction contracts the provisions of Article ME. regarding the ENGINEER's Personnel at the construction site, and provisions providing for contractor indemnification of the CITY and the ENGINEER for contractor's negligence. H. Contractor Claims and Third -Party Beneficiaries (1) The CITY agrees to include the following clause in all contracts with construction contractors and equipment or materials suppliers: "Contractors, subcontractors and equipment and materials suppliers on the PROJECT, or their sureties, shall maintain no direct action against the ENGINEER, its officers, employees, and subcontractors, for any claim arising out of, in connection with, or resulting from the engineering services performed. Only the CITY will be the beneficiary of any undertaking by the ENGINEER." City of Fort Worth, Texas Pecan Valley Golf Course Bridge Replacement Standard Agreement for Engineering Related Design Services CPN 105401 Revised Date: 12-08-2023 Page 8 of 15 (2) This AGREEMENT gives no rights or benefits to anyone other than the CITY and the ENGINEER and there are no third -party beneficiaries. (3) The CITY will include in each agreement it enters into with any other entity or person regarding the PROJECT a provision that such entity or person shall have no third -party beneficiary rights under this Agreement. (4) Nothing contained in this Section H. shall be construed as a waiver of any right the CITY has to bring a claim against ENGINEER. Litigation Assistance The Scope of Services does not include costs of the ENGINEER for required or requested assistance to support, prepare, document, bring, defend, or assist in litigation undertaken or defended by the CITY. In the event CITY requests such services of the ENGINEER, this AGREEMENT shall be amended or a separate agreement will be negotiated between the parties. J. Changes The CITY may make or approve changes within the general Scope of Services in this AGREEMENT. If such changes affect the ENGINEER's cost of or time required for performance of the services, an equitable adjustment will be made through an amendment to this AGREEMENT with appropriate CITY approval. Article VI General Legal Provisions A. Authorization to Proceed ENGINEER shall be authorized to proceed with this AGREEMENT upon receipt of a written Notice to Proceed from the CITY. B. Reuse of Project Documents All designs, drawings, specifications, documents, and other work products of the ENGINEER, whether in hard copy or in electronic form, are instruments of service for this PROJECT, whether the PROJECT is completed or not. Reuse, change, or alteration by the CITY or by others acting through or on behalf of the CITY of any such instruments of service without the written permission of the ENGINEER will be at the CITY's sole risk. The CITY shall own the final designs, drawings, specifications and documents. City of Fort Worth, Texas Pecan Valley Golf Course Bridge Replacement Standard Agreement for Engineering Related Design Services CPN 105401 Revised Date: 12-08-2023 Page 9 of 15 C. Force Majeure CITY and ENGINEER shall exercise their best efforts to meet their respective duties and obligations as set forth in this Agreement, but shall not be held liable for any delay or omission in performance due to force majeure or other causes beyond their reasonable control, including, but not limited to: acts of the public enemy, fires, strikes, lockouts, natural disasters, epidemics/pandemics, wars, riots, material or labor restrictions by any governmental authority and/or any other similar causes. D. Termination (1) This AGREEMENT may be terminated a.) by the City for its convenience upon 30 days' written notice to ENGINEER. b.) by either the CITY or the ENGINEER for cause if either party fails substantially to perform through no fault of the other and the nonperforming party does not commence correction of such nonperformance within 5 days' written notice or thereafter fails to diligently complete the correction. (2) If this AGREEMENT is terminated for the convenience of the City, the ENGINEER will be paid for termination expenses as follows: a.) Reasonable cost of reproduction or electronic storage of partial or complete studies, plans, specifications or other forms of ENGINEER'S work product; b.) The reasonable time requirements for the ENGINEER'S personnel to document the work underway at the time of the CITY'S termination for convenience so that the work effort is suitable for long time storage. (3) Prior to proceeding with termination services, the ENGINEER will submit to the CITY an itemized statement of all projected termination expenses. The CITY'S approval shall be obtained in writing prior to proceeding with termination services. E. Suspension, Delay, or Interruption to Work The CITY may suspend, delay, or interrupt the services of the ENGINEER for the convenience of the CITY. In the event of such suspension, delay, or interruption, an equitable adjustment in the PROJECT's schedule, City of Fort Worth, Texas Pecan Valley Golf Course Bridge Replacement Standard Agreement for Engineering Related Design Services CPN 105401 Revised Date: 12-08-2023 Page 10 of 15 commitment and cost of the ENGINEER's personnel and subcontractors, and ENGINEER's compensation will be made. F. Indemnification The ENGINEER shall indemnify or hold harmless the CITY against liability for any damage committed by the ENGINEER or ENGINEER's agent, consultant under contract, or another entity over which the ENGINEER exercises control to the extent that the damage is caused by or resulting from an act of negligence, intentional tort, intellectual property infringement, or failure to pay a subcontractor or supplier. CITY is entitled to recover its reasonable attorney's fees in proportion to the ENGINEER's liability. G. Assignment ENGINEER shall not assign all or any part of this AGREEMENT without the prior written consent of CITY. H. Jurisdiction The law of the State of Texas shall govern the validity of this AGREEMENT, its interpretation and performance, and any other claims related to it. The venue for any litigation related to this AGREEMENT shall be Tarrant County, Texas. Severability and Survival If any of the provisions contained in this AGREEMENT are held for any reason to be invalid, illegal, or unenforceable in any respect, such invalidity, illegality, or unenforceability will not affect any other provision, and this AGREEMENT shall be construed as if such invalid, illegal, or unenforceable provision had never been contained herein. Articles V.F., VI.B., VI.D., VI.F., VI.H., and VI.I. shall survive termination of this AGREEMENT for any cause. J. Observe and Comply ENGINEER shall at all times observe and comply with all federal and State laws and regulations and with all City ordinances and regulations which in any way affect this AGREEMENT and the work hereunder, and shall observe and comply with all orders, laws ordinances and regulations which may exist or may be enacted later by governing bodies having jurisdiction or authority for such enactment. No plea of misunderstanding or ignorance thereof shall be considered. ENGINEER agrees to defend, indemnify and hold harmless CITY and all of its officers, agents and employees from and against all City of Fort Worth, Texas Pecan Valley Golf Course Bridge Replacement Standard Agreement for Engineering Related Design Services CPN 105401 Revised Date: 12-08-2023 Page 11 of 15 claims or liability arising out of the violation of any such order, law, ordinance, or regulation, whether it be by itself or its employees. K. Contract Construction/No Waiver The parties acknowledge that each Party and, if it so chooses, its counsel, have reviewed and revised Agreement and that the normal rule of contract construction, to the effect that any ambiguities are to be resolved against the drafting party, must not be employed in the interpretation of Agreement or any amendments or exhibits hereto. The failure of CITY or ENGINEER to insist upon the performance of any term or provision of this Agreement or to exercise any right granted herein shall not constitute a waiver of CITY's or ENGINEER's respective right to insist upon appropriate performance or to assert any such right on any future occasion. L. Immigration Nationality Act ENGINEER shall verify the identity and employment eligibility of its employees who perform work under this Agreement, including completing the Employment Eligibility Verification Form (1-9). Upon request by CITY, ENGINEER shall provide CITY with copies of all 1-9 forms and supporting eligibility documentation for each employee who performs work under this Agreement. ENGINEER shall adhere to all Federal and State laws as well as establish appropriate procedures and controls so that no services will be performed by any ENGINEER employee who is not legally eligible to perform such services. ENGINEER SHALL INDEMNIFY CITY AND HOLD CITY HARMLESS FROM ANY PENALTIES, LIABILITIES, OR LOSSES DUE TO VIOLATIONS OF THIS PARAGRAPH BY ENGINEER, ENGINEER'S EMPLOYEES, SUBCONTRACTORS, AGENTS, OR LICENSEES. CITY, upon written notice to ENGINEER, shall have the right to immediately terminate this Agreement for violations of this provision by ENGINEER. M. Prohibition On Contracts With Companies Boycotting Israel ENGINEER unless a sole proprietor, acknowledges that in accordance with Chapter 2271 of the Texas Government Code, if ENGINEER has 10 or more full time -employees and the contract value is $100,000 or more, the City is prohibited from entering into a contract with a company for goods or services unless the contract contains a written verification from the company that it: (1) does not boycott Israel; and (2) will not boycott Israel during the term of the contract. The terms "boycott Israel" and "company" City of Fort Worth, Texas Pecan Valley Golf Course Bridge Replacement Standard Agreement for Engineering Related Design Services CPN 105401 Revised Date: 12-08-2023 Page 12 of 15 shall have the meanings ascribed to those terms in Section 808.001 of the Texas Government Code. By signing this contract, ENGINEER certifies that ENGINEER'S signature provides written verification to the City that if Chapter 2271, Texas Government Code applies, ENGINEER: (1) does not boycott Israel; and (2) will not boycott Israel during the term of the contract. N. Prohibition on Boycotting Energy Companies ENGINEER acknowledges that in accordance with Chapter 2276 of the Texas Government Code, the CITY is prohibited from entering into a contract for goods or services that has a value of $100,000 or more, which will be paid wholly or partly from public funds of the City, with a company (with 10 or more full-time employees) unless the contract contains a written verification from the company that it: (1) does not boycott energy companies; and (2) will not boycott energy companies during the term of the contract. The terms "boycott energy company" and "company" have the meaning ascribed to those terms by Chapter 2276 of the Texas Government Code. To the extent that Chapter 2276 of the Government Code is applicable to this Agreement, by signing this Agreement, ENGINEER certifies that ENGINEER's signature provides written verification to the CITY that ENGINEER: (1) does not boycott energy companies; and (2) will not boycott energy companies during the term of this Agreement. O. Prohibition on Discrimination Against Firearm and Ammunition Industries ENGINEER acknowledges that except as otherwise provided by Chapter 2274 of the Texas Government Code, the CITY is prohibited from entering into a contract for goods or services that has a value of $100,000 or more which will be paid wholly or partly from public funds of the City, with a company (with 10 or more full-time employees) unless the contract contains a written verification from the company that it: (1) does not have a practice, policy, guidance, or directive that discriminates against a firearm entity or firearm trade association; and (2) will not discriminate during the term of the contract against a firearm entity or firearm trade association. The terms "discriminate," "firearm entity" and "firearm trade association" have the meaning ascribed to those terms by Chapter 2274 of the Texas Government Code. To the extent that Chapter 2274 of the Government Code is applicable to this Agreement, by signing this Agreement, ENGINEER certifies that ENGINEER's signature provides written verification to the CITY that ENGINEER: (1) does not have a practice, policy, guidance, or directive that discriminates against a firearm entity or firearm trade association; and (2) will not discriminate against a firearm entity or City of Fort Worth, Texas Pecan Valley Golf Course Bridge Replacement Standard Agreement for Engineering Related Design Services CPN 105401 Revised Date: 12-08-2023 Page 13 of 15 firearm trade association during the term of this Agreement. This AGREEMENT, including its attachments and schedules, constitutes the entire AGREEMENT, which supersedes all prior written or oral understandings, and may only be changed by a written amendment executed by both parties. This AGREEMENT may be executed in one or more counterparts and each counterpart shall, for all purposes, be deemed an original, but all such counterparts shall together constitute but one and the same instrument. The following attachments and schedules are hereby made a part of this AGREEMENT: Attachment A - Scope of Services Attachment B - Compensation Attachment C - Amendments to Standard Agreement for Engineering Services Attachment D - Project Schedule Attachment E - Location Map Attachment F — Insurance Requirements Duly executed by each party's designated representative to be effective on the date subscribed by the City's designated Assistant City Manager. BY: CITY OF FORT WORTH bana 5GtlVG OGf Dana Burghdoff (Apr 1, 2025 015'3 CDT) Dana Burghdoff Assistant City Manager Date:04/18/2025 g444pORT�IlBd emers°° ° o p90 Pao 010 ATTEST: 00o°° _ alb aEapSQpp Jannette Goodall City Secretary APPROVAL RECOMMENDED: By. 49v Dave Lewis Director, Park & Recreation City of Fort Worth, Texas Standard Agreement for Engineering Related Design Services Revised Date: 12-08-2023 Page 14 of 15 BY: ENGINEER Baird, Hampton & Brown, Inc. Austin Baird fMar27, 202515:14 CDT) John Austin Baird, PE Principal, Senior Civil Engineer Date: 03/27/2025 Jy p 5PJocElhany Pecan Valley Golf Course Bridge Replacement CPN 105401 OFFICIAL RECORD CITY SECRETARY FT. WORTH, TX APPROVED AS TO FORM AND LEGALITY By: nualat Rlark iApr 17 2025 17: 1 u i Douglas W Black Sr. Assistant City Attorney Contract Compliance Manager: M&C No.: 25-0135 M&C Date: 02/25/2025 By signing, I acknowledge that I am the person responsible for the monitoring and administration of this contract, including ensuring all performance and reporting requirements. Auez-altd Paul Land Park Planner/Project Manager Park & Recreation Department City of Fort Worth, Texas Pecan Valley Golf Course Bridge Replacement Standard Agreement for Engineering Related Design Services CPN 105401 Revised Date: 12-08-2023 Page 15 of 15 M&C Review Page 1 of 2 CITY COUNCIL AGEND Create New From This M&C Official site of the City of Fort Worth, Texas FORTWORTH '11� REFERENCE **M&C 25- 80PECAN VALLEY GOLF DATE: 2/25/2025 NO.: 0135 LOG NAME: COURSE BRIDGE REPLACEMENT CODE: C TYPE: CONSENT PUBLIC NO HEARING: SUBJECT: (CD 3) Authorize Execution of an Engineering Agreement with Baird, Hampton & Brown, Inc., in the Amount of $325,350.00, for the Design and Preparation of Construction Documents for the Pecan Valley Golf Course Bridge Replacement, Adopt Appropriation Ordinances, Amend the Fiscal Year 2025 Adopted Budget and Fiscal Years 2025-2029 Capital Improvement Program RECOMMENDATION: It is recommended that the City Council: 1. Authorize execution of an engineering agreement with Baird, Hampton & Brown, Inc., in the amount of $325,350.00, for the design and preparation of construction documents for the Pecan Valley Golf Course Bridge Replacement; 2. Adopt the attached appropriation ordinance, increasing estimated receipts and appropriations in the Municipal Golf Fund in the amount of $375,000.00, from available fund balance, for the purpose of transferring to the General Capital Projects Fund for the purpose of funding the Golf Improvements Programmable project (City Project No. P00096); 3. Adopt the attached appropriation ordinance, increasing estimated receipts and appropriations in the General Capital Projects Fund in the amount of $375,000.00, transferred from the Municipal Golf fund for the purpose of funding the Golf Improvements Programmable project (City Project No. P00096); and 4. Amend the Fiscal Year 2025 adopted budget and Fiscal Years 2025-2029 Capital Improvement Program. DISCUSSION: The purpose of this Mayor and Council Communication (M&C) is to authorize execution of an engineering services agreement with Baird, Hampton & Brown, Inc., in the amount of $325,350.00 for the design and preparation of construction documents for the Pecan Valley Golf Course Bridge Replacement. Pecan Valley Golf Course is a 36-hole golf course on a 461-acre site located in southwest Fort Worth. It was established in 1963, the course is a poplular destination for golfers. In January 2024, a severe winter storm caused significant structural damage to the wing wall (abutment) of the bridge located between the 15th and 18th holes of the Pecan Valley River Course. As a result, the bridge was closed, and all golf cart and pedestrian traffic was redirected to an alternate route. This closure necessitated a slight course rerouting, and hole 15 was changed from a Par 4 to a Par 3. The Business Equity Division placed a 12.15\% business equity goal on this solicitation contract. Baird, Hampton & Brown, Inc., will be exceeding the goal at 17\%, meeting the City's Business Equity Ordinance. Any changes in subcontractors will be reviewed by the Business Equity Division. Pecan Valley Golf Course is located in COUNCIL DISTRICT 3. FISCAL INFORMATION/CERTIFICATION: http://apps.cfwnet.org/council_packet/mc review.asp?ID=33000&councildate=2/25/2O25 3/27/2025 M&C Review Page 2 of 2 The Director of Finance certifies that funds are currently available in fund balance within the Municipal Golf Fund and upon approval of the above recommendations and adoption of the attached appropriation ordinances, funds will be available in the General Capital Projects Fund for the Golf Improvements Programmable projet. Prior to any expenditure being incurred, the Park & Recreation Department has the responsibility to validate the availability of funds. TO Fund Department Account Project Program Activity Budget Reference # Amount ID ID Year (Chartfield 2) FROM Fund Department Account Project Program Activity Budget Reference # Amount ID ID Year (Chartfield 2) Submitted for Citv Manager's Office bv: Jesica McEachern (5804) Oriqinatinq Department Head: Richard Zavala (5711) Additional Information Contact: Joel McElhany (5745) ATTACHMENTS 25-105401(Pecan Vallev Golf Course Bridqe Reolacement)CM-NS.Ddf (CFW Internal) 80PECAN VALLEY GOLF COURSE BRIDGE REPLACEMENT funds avail.docx (CFW Internal) FID Table 80Pecan Vallev Golf Course Bridtae Replacement-UDdated.xlsx (CFW Internal) Form 1295 Certificate 2024-1235832.Ddf (CFW Internal) M&C Map .Dna (CFW Internal) ORD.APP 80PECAN VALLEY GOLF COURSE BRIDGE REPLACEMENT 20102 A025(R2).docx (Public) ORD.APP 80PECAN VALLEY GOLF COURSE BRIDGE REPLACEMENT 30100 A025(R3).docx (Public) SAM.GOV.Dna (CFW Internal) http://apps.cfwnet.org/council_packet/mc review.asp?ID=33000&councildate=2/25/2O25 3/27/2025 FORT WORTH® ATTACHMENT "A" Scope for Enaineerina Desian Related Services for Arterial Improvements The scope set forth herein defines the work to be performed by the ENGINEER in completing the project. Both the CITY and ENGINEER have attempted to clearly define the work to be performed and address the needs of the Project. OBJECTIVE The objective of the Pecan Valley Golf Course Bridge replacement project is to replace the failing existing golf course cart bridge located between holes 15 and 18 at the Pecan Valley Golf Course which spans the Clear Fork Trinity River. As currently planned the bridge replacement project is intended to remove the existing multi -span concrete bridge, including abutments and midspan piers located with the floodplain of the Clear Fork Trinity River. Replacing the existing structure with a pre - engineer metal truss bridge as a single span of approximately 150 linear feet spanning the ordinary high-water mark of the central river section. In support of this effort and the regulatory process required to facilitate the project the scope of work includes engineering of the proposed bridge support system and associated site improvements, environmental scientist services associated with Nation Wide Permit 14 approval for linear improvement projects affecting Waters of the US, as well as flood plain analysis and permitting services. WORK TO BE PERFORMED Task 1. Design Management Task 2. Conceptual Design (30%) Task 3. Preliminary Design (60%) Task 4. Final Design (90% and 100%) Task 5. Bid Phase Services Task 6. Construction Phase Services Task 7. ROW/Easement Services Task 8. Survey Task 9. Permitting Task 10. Quality Control/ Quality Assurance TASK 1. DESIGN MANAGEMENT. ENGINEER will manage the work outlined in this scope to ensure efficient and effective use of ENGINEER's and CITY's time and resources. ENGINEER will manage change, communicate effectively, coordinate internally and externally as needed, and proactively address issues with the CITY's Project Manager and others as necessary to make progress on the work. City of Fort Worth, Texas Page 1 of 20 Attachment A Revision Date: 05.23.2024 Page 1 of 20 FORT WORTH® 1.1. Managing the Team: • Lead, manage and direct design team activities • Ensure Quality Control / Quality Assurance (QC/QA) is practiced in performance of the work. • Communicate internally among team members • Task and allocate team resources 1.2. Communications and Reporting: • Attend a pre -design project kickoff/charter meeting with CITY staff to confirm and clarify scope, understand CITY objectives, and ensure economical and functional designs that meet CITY requirements • Attend one (1) constructability review meeting with CITY representatives at the 60% submittal milestone • Conduct and document monthly project update meetings with CITY Project Manager • Conduct review meetings with the CITY at the end of each design phase • Conduct QC/QA reviews and document those activities. • Prepare invoices, in accordance with Attachment B to this Standard Agreement and submit monthly in the format requested by the CITY. Multi -month billing is not allowed. Months in which no work is being invoiced shall require submission of a $0.00 invoice. Prepare and submit monthly Project Status Reports in the format provided by the Transportation and Public Works Department. • Prepare and submit baseline Project Schedule initially, and Project Schedule updates with a schedule narrative monthly, as required in Attachment D to this Standard Agreement in compliance with the City's Specification 00 31 15 entitled Engineer Project Schedule. This PROJECT requires a Tier 3 schedule as defined in the City's Specification 00 31 15 entitled Engineer Project Schedule. • Complete Monthly M/WBE Report Form and Final Summary Payment Report Form at the end of the project. • Coordinate with other agencies and entities as necessary for the design of the proposed infrastructure, and provide and obtain information needed to prepare the design. • With respect to coordination with permitting authorities, ENGINEER shall communicate with permitting authorities such that their regulatory requirements are appropriately reflected in the designs. ENGINEER shall work with regulatory authorities to obtain approval of the designs, and make changes necessary to meet their requirements, as part of the design scope. • Personnel and Vehicle Identification: When conducting site visits to the project location, the ENGINEER or any of its sub -consultants shall carry readily visible City of Fort Worth, Texas Page 2 of 20 Attachment A Revision Date: 05.23.2024 Page 2 of 20 FORT WORTH® information identifying the name of the company and the company representative. ASSUMPTIONS • One (1) pre -design project kickoff/chartering meeting • One (1) constructability review meeting during design • Twelve (12) monthly project update meetings during design phase • At least three (3) plan review meetings • All submittals to the City shall be Quality checked prior to submission. • Project design phase is anticipated to take Twelve (12) months. • Project construction phase is anticipated to take Six (6) months. • Twelve (12) monthly updates of Project Status Reports, DVIN forms and Project Schedule Updates. DELIVERABLES A. Meeting summaries with action items B. QC/QA documentation C. Baseline design schedule D. Monthly Schedule updates with schedule narrative describing any current or anticipated schedule changes E. Monthly Project Status Reports F. Monthly invoices G. Monthly DVIN Report Form and Final Summary Payment Report Form TASK 2. CONCEPTUAL DESIGN (30 PERCENT). The Conceptual Design shall be submitted to CITY per the approved Project Schedule. The purpose of the conceptual design is for the ENGINEER to identify, develop, communicate through the defined deliverables, and recommend the design concept that successfully addresses the design problem, and to obtain the CITY's endorsement of this concept. ENGINEER will develop the conceptual design of the infrastructure as follows. 2.1. Data Collection • In addition to data obtained from the CITY, ENGINEER will research and make efforts to obtain pertinent information to aid in coordination of the proposed City of Fort Worth, Texas Page 3 of 20 Attachment A Revision Date: 05.23.2024 Page 3 of 20 FORT WORTH® improvements with any planned future improvements that may influence the project. ENGINEER will also identify and seek to obtain data for existing conditions that may impact the project including; utilities, agencies (TxDOT and railroads), City Master Plans, and property ownership as available from the Tax Assessor's office. • The ENGINEER will consult with the CITY's Transportation and Public Works Department, Water Department, and other CITY departments, public utilities, private utilities, private utilities and government agencies to determine the approximate location of above and underground utilities, and other facilities (current and future) that have an impact or influence on the project. • The data collection efforts will also include conducting special coordination meetings with affected property owners and businesses as necessary to develop sewer re-routing plans where necessary. 2.2. Geotechnical Investigation Soil investigation, including field and laboratory tests, borings, related engineering analysis and recommendations for determining soil conditions will be made. In addition to the above investigations, borings and appropriate field and laboratory analysis will be made at reasonable intervals throughout the projects scope for the use in designing the bridge replacement as well as for the Contractor's use in determining soil conditions for preparing bids and Trench Safety Plan. • The study shall include recommendations regarding excavation requirements, structural foundation systems, retaining wall lateral loads, slope stability analysis and identify existing groundwater elevation at each boring. 2.3. Engineering Design Report To ensure adherence to project scope, that design approach is in line with project objectives, and to obtain concurrence on development of the conceptual layout, ENGINEER shall prepare and submit a design report in the format provided by the CITY prior to developing conceptual plans. The CITY shall review and provide feedback on the report prior to ENGINEER starting the conceptual design. 2.4. The Conceptual Design Package shall include the following: • Preliminary cover and index of sheets including project limits, area location map and beginning and end station limits. • Quantity Summary page and each design sheet shall include a quantity take off table. • Conceptual iSWM Checklist in accordance with the current CITY iSWM Criteria Manual for Site Development and Construction • PDF set of plans with the utility conflicts highlighted and a Utility Conflicts Table • Proposed typical sections of the cart path and bridge to be constructed which outline the proposed improvements. Typical sections shall include proposed paths and bridge widths. City of Fort Worth, Texas Page 4 of 20 Attachment A Revision Date: 05.23.2024 Page 4 of 20 FORT WORTH® • Conceptual site improvements including: • Cart path adjustments • Bridge realignment plans • Retaining wall plans • Abutment layouts • Site and grading plans. • Conceptual structural engineering to include: • Abutment design coordinated with geotechnical report, • Retaining wall sections • Bridge support design with attachment of bridge to abutment as well as midspan support should it become necessary • Pipe support details to accommodate exiting utilities currently mounted to the existing bridge • Coordination with pre -manufactured bridge supplier • Conceptual stream improvements including: • In coordination with the environmental and flood plain services (Task 9.3 & 9.4) stream bed and overbank improvements will be provided to facilitate the removal of the existing bridge structure as well as the restoration and installation of the proposed bridge. • Documentation of key design decisions. • Estimates of probable construction cost. ASSUMPTIONS • All stormwater calculations and design shall conform to the CITY's current iSWM Criteria Manual for Site Development and Construction. Two (2) sets of 11"xl7" size plans will be delivered for the 30% design. • PDF files created from design CAD drawings will be uploaded to the designated project folder in the City's document management system (eBuilder). • ENGINEER will not proceed with Preliminary Design activities without written approval by the CITY of the Conceptual Design Package. DELIVERABLES A. Conceptual Design Report B. Conceptual Design Package City of Fort Worth, Texas Page 5 of 20 Attachment A Revision Date: 05.23.2024 Page 5 of 20 FORT WORTH® C. Geotechnical Report D. Utility Conflict Plan PDF and Utility Conflict Table TASK 3. PRELIMINARY DESIGN (60 PERCENT). Preliminary plans and specifications shall be submitted to CITY per the approved Project Schedule. ENGINEER will develop the preliminary design of the infrastructure as follows. 3.1. The Preliminary Design Drawings and Specifications shall include the following: • Preliminary cover and index of sheets including project limits, area location map and beginning and end station limits. • Utility Conflict Matrix • Preliminary iSWM Checklist in accordance with the current CITY iSWM Criteria Manual for Site Development and Construction. • A Project Control Sheet, showing all Control Points, used or set while gathering data. Generally on a scale of not less than 1:400. The following information shall be indicated for each Control Point: Identified (existing City Monument #8901, PK Nail, 5/8" Iron Rod); X, Y and Z Coordinates, in an identified coordinate system, and a referred bearing base. Z coordinate on City Datum only; descriptive location (i.e. set in the centerline of the inlet in the South curb line of North Side Drive at the East end of radius at the Southeast corner of North Side Drive and North Main Street). • Updated typical section sheets. • Updated site improvements. • Update structural engineering plans. • Update stream improvements plans. • Preliminary construction details including, cart paths paving sections, bridge abutment, retaining walls, railing, slope reinforcements and stream improvements, etc. • Documentation of key design decisions. • Estimates of probable construction cost (OPCC). This estimate shall use standard CITY or TxDOT bid items, as applicable. 3.2. Constructability Review • Prior or posterior to the 60 percent review meeting with the CITY, the ENGINEER shall schedule and attend a project site visit with the CITY Project Manager and Construction personnel to walk the project. The ENGINEER shall summarize the CITY's comments from the field visit and submit this information to the CITY in writing. City of Fort Worth, Texas Page 6 of 20 Attachment A Revision Date: 05.23.2024 Page 6 of 20 FORT WORTH® ASSUMPTIONS • Two (2) sets of 11"x17" size plans will be delivered for the 60% design for review coordination. • One (1) set of the Project Manual (Contract and Specifications) will be delivered for the 60% design. • The following shall be uploaded to the designated project folder in the City's document management system (Trimble Unity Construct): ■ Single PDF file created from design CAD drawings. ■ The Project Manual (Contract and Specifications) ■ All other submitted documents and checklists • The CITY's front end and technical specifications will be used. The ENGINEER shall supplement the technical specifications if needed. • ENGINEER shall not proceed with Final Design activities without written approval by the CITY of the Preliminary Design plans. DELIVERABLES A. Preliminary Design drawings and specifications including QC/QA documentation B. Utility Conflict Coordination Package C. Opinion of probable construction cost (OPCC) TASK 4. A. FINAL DESIGN (90 PERCENT) Upon approval of the Preliminary plans, ENGINEER will prepare construction plans as follows: Final draft construction plans (90%) and Project Manual shall be submitted to CITY per the approved Project Schedule. • The ENGINEER will provide a PDF set of plans with the utility conflicts highlighted and a Utility Conflicts Table of those conflicts to be included in the Utility Clearance Letter to be issued by the City PM. • The ENGINEER shall submit an estimate or opinion of probable construction cost (OPCC) B. FINAL CONSTRUCTION DOCUMENTS (100 PERCENT). Following a 90% construction plan review meeting with the CITY, the ENGINEER shall submit Final Plans (100%) to the CITY per the approved Project Schedule. Each plan sheet shall be stamped, dated, and signed by the ENGINEER registered in State of Texas. City of Fort Worth, Texas Page 7 of 20 Attachment A Revision Date: 05.23.2024 Page 7 of 20 FORT WORTH® • Drainage Study checklist in accordance with the current iSWM Criteria Manual for Site Development and Construction. • A Quantity Summary page will be included in both the 90% and 100% design plans. Each design sheet of the plans shall also include a quantity take off table. • The ENGINEER shall submit an estimate of probable construction cost (OPCC) ASSUMPTIONS • Two (2) sets of 11"x17" size drawings and one (1) set of the Project Manual will be delivered for the 90% Design package. • A PDF created from design CAD drawings and CAD files for the 90% Design and will be uploaded to the project folder in the City's document management system (Trimble Unity Construct). • One (1) sets of 11"x17" size drawings and one (1) set of specifications will be delivered for the 100% Design package. • A PDF created from design CAD drawings and CAD files will be uploaded to the project folder in City's document management system (Trimble Unity Construct). DELIVERABLES A. 90% construction plans and specifications including QC/QA documentation. B. 100% construction plans and Project Manual including QC/QA documentation. C. Detailed estimates of probable construction costs including summaries of bid items and quantities using the CITY's or TxDOT's standard bid items and format, as applicable D. Cover sheet in PDF format for the signatures of authorized CITY officials. TASK 5. BID PHASE SERVICES. The CITY reserves the right to deliver the project by bidding it, issuing a work order out of an existing unit price contract or by alternative delivery. ENGINEER will support the construction procurement phase of the project as follows. 5.1. Bid Support • The ENGINEER shall upload all plans and contract documents onto the City's document management system (Trimble Unity Construct) for records. • Project Manual shall be uploaded in a single PDF file in Trimble Unity Construct as well as individual files as required to be included in the City's procurement portal, Bonfire. City of Fort Worth, Texas Page 8 of 20 Attachment A Revision Date: 05.23.2024 Page 8 of 20 FORT WORTH® • Bid Proposal Document of the Contract documents shall be uploaded in a file format of filename extension ".xls". Unit Price Proposal documents are to be created utilizing the city's unit price tool only and combined in a specified spreadsheet workbook, Bid Proposal Worksheet Template, that will be populated and configured so that all pages are complete and the Summary Worksheet(s) in the workbook detail and automatically summarize the totals from the inserted Unit Price Proposal document worksheets. • Plan Sets are to be uploaded to the City's document management system (Trimble Unity Construct) in two formats, PDF and CAD files. The PDF will consist of one file of the entire plan set. The ENGINEER will coordinate with the PM to respond to Vendor Discussions (RFI) and issue Public Notices (addenda) when necessary, in Bonfire. The ENGINEER will provide technical interpretation of the contract bid documents and will prepare proposed responses to all bidder's questions and requests in the form of an addenda. The ENGINEER will coordinate with the City PM to upload all approved addenda onto Bonfire as well as Trimble Unity Construct. • Attend the pre -bid conference in support of the CITY. • Assist the CITY in determining the qualifications and acceptability of prospective contractors, subcontractors, and suppliers. • When substitution prior to award of contracts is allowed in the contract documents, the ENGINEER will advise the CITY as to the acceptability of alternate materials and equipment proposed by bidders. • Review all materials received from bidders/proposers, assist the CITY in evaluating them, and recommend award of the contract. A copy of all submitted materials is to be uploaded into the project's Bid Results folder on the City's document management system (Trimble Unity Construct) Incorporate all addenda into the contract documents and issue conformed sets. After the bid opening, ENGINEER will provide a minimum of 5 full sets of plans, 5 half-size sets and 2 copies of the conformed Project Manual set incorporating all approved addenda. ASSUMPTIONS • The project will be bid only once and awarded to one contractor. • Construction documents will only be made available on the City's procurement platform, Bonfire. • Construction documents will not be printed by the CITY and made available for purchase by plan holders and/or given to plan viewing rooms. • All procurement materials will be uploaded to the City's procurement platfom, Bonfire, as well as Trimble Unity Construct. City of Fort Worth, Texas Page 9 of 20 Attachment A Revision Date: 05.23.2024 Page 9 of 20 FORT WORTH® DELIVERABLES A. Addenda B. Recommendation of award as required per project C. Construction documents (conformed) TASK 6. CONSTRUCTION PHASE SERVICES. ENGINEER will support the construction phase of the project as follows. 6.1. Construction Support • The ENGINEER shall attend the pre -construction conference. • The ENGINEER shall conduct periodic site visits as needed during the duration of construction. The ENGINEER will prepare or collaborate with the CITY PM on a Construction Progress Report using the CITY's standard format and upload it to the City's document management system (Trimble Unity Construct). The ENGINEER shall review shop drawings, samples and other submittals submitted by the contractor for general conformance with the design concepts and general compliance with the requirements of the contract for construction. Such review shall not relieve the Contractor from its responsibility for performance in accordance with the contract for construction, nor is such review a guarantee that the work covered by the shop drawings, samples and submittals is free of errors, inconsistencies or omissions. The ENGINEER shall log and track all shop drawings, samples and other submittals in the City's document management system (Trimble Unity Construct). • ENGINEER shall review material substitution requests, issue a recommendation and incorporate approved substitutions into the Record Drawings. As requested by the CITY, the ENGINEER shall provide necessary interpretations and clarifications of contract documents, respond to Request for Information (RFI) from the contractor, review change orders, and make recommendations as to the acceptability of the work. The ENGINEER will meet with the Project Delivery Team and Contractor on -site to review any field changes. • The ENGINEER shall attend the "Final" project walk through and assist with preparation of final punch list. 6.2 Record Drawings • The ENGINEER shall prepare record drawings from information provided by the CITY depicting any changes made to the Final Drawings during construction. Information provided by the CITY may include, but is not limited to the following: • As -Built Survey provided by the contractor, which includes vertical and horizontal coordinates of all water, sewer and storm drain assets, and in accordance with the Construction (As -Built) Survey Specification. City of Fort Worth, Texas Page 10 of 20 Attachment A Revision Date: 05.23.2024 Page 10 of 20 FORT WORTH® ENGINEER shall verify accuracy of the data provided by contractor and conformance with requirements. • Red -Line Markups from the Contractor • Red -Line Markups from City Inspector • Approved Substitutions The ENGINEER shall modify the Final Drawings electronically and shall place a stamp on the plans indicating that they represent Record Drawings of the project as constructed. The stamp shall be signed and dated by the ENGINEER and shall be placed on each plan sheet, whether there are any revisions on the sheet or not. Each sheet shall clearly indicate all changes which apply to that sheet by clouding and numbering, or other suitable means. • The following disclaimer shall be included with the Record Drawing stamp: These Record Drawings were prepared using information provided by others and represent the as constructed conditions to the extent that documented changes were provided for recording. The ENGINEER assumes no liability for undocumented changes and certifies only that the documented changes are accurately depicted on these drawings. The ENGINEER shall submit a set of sealed Final Drawings, modified and stamped as Record Drawings, in Adobe Acrobat PDF format (version 6.0 or higher). The set must include the cover sheet bearing City official signatures. The ENGINEER may keep copies of the information provided by the CITY for their files, but all original red -lined drawings shall be returned to the CITY with the digital files. • There shall be one (1) PDF file and one (1) CAD file for the TPW plan set and a separate PDF and CAD file for the Water plan set, if required. Each PDF file shall contain all associated sheets of the particular plan set. Sinqular PDF files for each sheet of a plan set will not be accepted. PDF files shall conform to naming conventions as follows: I. TPW file name example — "W-1956_org47.pdf" where "W-1956" is the assigned file number obtained from the CITY, "_org" designating the file is of an original plan set, "47" shall be the total number of sheets in this file. Example: W-0053—org3.pdf and K-0320—org5.pdf II. Water and Sewer file name example — "X-35667_org36.pdf" where "X- 35667" is the assigned file number obtained from the CITY, "_org" designating the file is of an original plan set, "36" shall be the total number of sheets in this file. Example: X-12755—orgl8.pdf Both PDF files shall be uploaded to the project's Record Drawing folder in the City's document management system (Trimble Unity Construct). City of Fort Worth, Texas Pagel 1 of 20 Attachment A Revision Date: 05.23.2024 Page 11 of 20 FORT WORTH® For information on the proper manner to submit Record Drawing files and to obtain a file number for the project, the ENGINEER should coordinate with the City project manager. File numbers will not be issued to a project unless the appropriate project numbers and fund codes have been assigned and are in the Department of Transportation and Public Works database. ASSUMPTIONS • One (1) Pre -Construction Meeting is assumed. • Three (3) site visits are assumed. • Six (6) submittal reviews are assumed. • Three (3) RFI's are assumed. • Two (2) Change Orders are assumed. • One (1) Final Walkthrough with Punchlist DELIVERABLES A. Response to Contractor's Request for Information B. Review of Change Orders C. Review of shop drawings D. Record Drawings in electronic format TASK 7. ROW/EASEMENT SERVICES. Please note that this task is currently omitted from the project scope of services, as the project is currently planned to occur within the boundaries of property operated by Fort Worth Park & Recreation Department and Right -of -Way and Easement services are not anticipated at this time. TASK 8. SURVEY AND SUBSURFACE UTILITY ENGINEERING SERVICES. ENGINEER will provide survey support as follows. 8.1. Design Survey ENGINEER will perform field surveys to collect horizontal and vertical elevations and other information needed by ENGINEER in design and preparation of plans for the project. Information gathered during the survey shall include topographic data, elevations of all sanitary and adjacent storm sewers, rim/invert elevations, location of buried utilities, structures, trees (measure caliper, identify overall canopy, and have qualified arborist identify species of trees), and other features relevant to the final plan sheets. Existing drainage at intersections will be verified by field surveys. Spot elevations will be shown on intersection layouts with cross slope to fit intersecting grade lines. City of Fort Worth, Texas Page 12 of 20 Attachment A Revision Date: 05.23.2024 Page 12 of 20 FORT WORTH® • Right -of -Way research includes review of property/right-of-way records based on current internet-based Tarrant Appraisal District (TAD) information available at the start of the voiect and tied to available on -around property information (i.e. iron rods, fences, stakes, etc.). • The minimum survey information to be provided on the plans shall include the following: — A Project Control Sheet, showing ALL Control Points, used or set while gathering data. Generally, on a scale of not less than 1:400: — The following information about each Control Point; a. Identified (Existing. CITY Monument#8901, PK Nail, 5/8" Iron Rod) b. X, Y and Z Coordinates, in an identified coordinate system, and a referred bearing base. Z coordinate on CITY Datum only. c. Descriptive Location (Ex. Set in the centerline of the inlet in the South curb line of North Side Drive at the East end of radius at the Southeast corner of North Side Drive and North Main Street). — Coordinates on all P.C.'s, P.T.'s, P.I.'s, Manholes, Valves, etc., in the same coordinate system, as the Control. — No less than two horizontal bench marks, per line or location. — Bearings given on all proposed centerlines, or baselines. — Station equations relating utilities to paving, when appropriate. ASSUMPTIONS 1. Design survey shall be completed prior to design 2. Right -of -Way research and mapping is limited to County Parcel data sets and does not include resolved boundaries within the project limits 3. Topographic design surveys throughout the project limits will be collected using traditional on the ground methods. 4. Temporary right of entry letters been excluded as the project as currently planned is fully within the property limits of Fort Worth Park & Recreation property. DELIVERABLES A. Copies of Field survey data and notes provided by a licensed surveyor. B. Drawing of the project layout with dimensions and coordinate list. City of Fort Worth, Texas Page 13 of 20 Attachment A Revision Date: 05.23.2024 Page 13 of 20 FORT WORTH® TASK 9. PERMITTING. ENGINEER will provide permitting support for the CITY to obtain any and all agreements and/or permits normally required for a project of this size and type, as follows: 9.1 Texas Department of Licensing and Regulation (TDLR) • Identify and analyze the requirements of the Texas Architectural Barriers Act, Chapter 68 Texas Administrative Code, and become familiar with the governmental authorities having jurisdiction to approve the design of the Project. • ENGINEER is responsible for providing plans that are in compliance with TDLR requirements. • Submit construction documents to the TDLR • Completing all TDLR forms/applications necessary • Obtain the Notice of Substantial Compliance from the TDLR • Request an inspection from TDLR or a TDLR locally approved Registered Accessibility Specialist no later than 30 calendar days after construction substantial completion. Advise the CITY in writing of the results of the inspection. • Responding to agency comments and requests • All costs associated with TDLR plan review and inspections are to be paid by the ENGINEER during the course of the project. 9.2 Storm Water Pollution Prevention Plan For projects that disturb an area greater than one (1) acre, the Contractor will be responsible for preparing and submitting the Storm Water Pollution Prevention Plan (SWPPP) with appropriate regulatory agencies. The Engineer will prepare the iSWM Construction Plan according to the current CITY iSWM Criteria Manual for Site Development and Construction which will be incorporated into the SWPPP by the contractor. 9.3 Environmental Services • 9.3.1 — Waters of the United States Delineation Provide professional services to delineate all waters of the United States, including wetlands, within the project site. A professional wetland ecologist will delineate the jurisdictional limits of the streams based on 33 Code of Federal Regulations (CFR) 328.3[e] and delineate the jurisdictional limits of any wetlands based on the 1987 USACE Wetland Delineation Manual and the Regional Supplement to the Corps of Engineers Wetland Delineation Manual: Great Plains Region (Version 2.0), and any current Regulatory Guidance Letters. The boundaries of all of these water features identified in the field will be recorded with a Global Positioning System (GPS) that is capable of sub -meter accuracy. After the delineation is completed, a digital map of these waters of the United States will be provided for planning, impact calculation, City of Fort Worth, Texas Page 14 of 20 Attachment A Revision Date: 05.23.2024 Page 14 of 20 FORT WORTH® and illustration purposes. This delineation will be provide so that it may be utilized in the engineering plans to avoid and minimize impacts to waters of the United States (if any are present on the site). The deliverable for this task is a delineation report that includes methods, results, and conclusions, along with the necessary data forms, photographs, maps, and a delineation map. The conclusion of this report will be detailed why any water features on the site are or are not considered waters of the United States. • 9.3.2 — Nation Wide Permit 14 Pre -construction Notification As the proposed project is associated with a linear cart path, there are four notification criteria for NWP 13 — Linear Transportation Projects — 1. Loss of waters of the United States greater than 0.1 acre; 2. Discharge into a special aquatic site (i.e., wetland); 3. Impacts to a eligible or potentially eligible cultural resource site; and 4. Impacts to a federally listed protected species. It has been determined that the project will be required to submit a Pre -Construction Notification (PCN) to the USACE under General Condition 32 of the NWP program for the discharge of fill into a wetland along the creek. Professional services will be provided to (1) prepare and submit an NWP 14 PCN for the proposed project, and (2) provide coordination with the USACE Fort Worth District. Although this project may only have minor impacts (i.e., those that are allowed under the NWP program), the NWP PCN must detail the planning process, the components fo the project, impacts to waters of the United States as a result of the proposed project, and compensatory mitigation for those unavoidable impacts. The cornerstone of the NWP PCN would be to detail the ecological features of the waters of the United States present on the site and how these ecological features relate to the functional conditions of the waters. These ecological functions and values based on the current conditions of the site. Once these baseline conditions are accepted by the USACE, these will be the functions and values that will be mitigated for. All permit applications to the USACE require mitigation for unavoidable impacts to waters of the United States. There are three forms of mitigation which are primarily identified and conducted during the project planning: avoidance, minimization, and compensatory. Avoidance and minimization mitigation strategies must be completed and documented before any permit is authorized by the USACE. Although the project does not have significant impacts, there are still requirements, by law, that there are no net loss of the functions and values of jurisdictional waters. To accomplish this goal, the USACE and EPA have issued guidance stating their preference for the use of mitigation banks. Compensatory mitigation is generally only required if the project results in a loss of greater than 0.1 acre of wetland or ponds or 0.03 acre for tributary waters of the United States. To reduce the losses associated with in -stream impacts, the Fort Worth District recently published their guidance for Stream Mitigation Method, which places preference to mitigation in mitigation banks with instream credits. If necessary, we will calculate the mitigation requirements following this guidance and coordinate with the client on the cost aspects of this component of the project. Utilizing the USACE standard form for NWP 14 PCN submittals, we will assemble and submit the following to the USACE: • Description of the proposed action; City of Fort Worth, Texas Page 15 of 20 Attachment A Revision Date: 05.23.2024 Page 15 of 20 FORT WORTH® • Description of the site, including a delineation of the waters of the United States; • Functional assessment; • Wetland data forms; • Representative photographs; and Supporting Illustrations; • Alternatives analysis to the proposed action that do not impact waters of the United States; • Description of the project's avoidance and minimization efforts; • Quantitative and qualitative description of the avoidable impacts to the waters of the United States; and • If necessary, proposed conceptual mitigation plan through the use of available mitigation banks, if required. • 9.3.3 — Coordination This task is to provide professional services to coordinate with the client for planning purposes to obtain a design that would maximize the site while still maintaining the project in a NWP. Additionally, this task is to address any comments and attend any meetings that the agencies require the permit is submitted. In the event that the project requires compensatory mitigation, we will utilize this budget to assist the client after the permit is authorized to coordinate with the mitigation banks to obtain the best mitigation costs and obtain the agreements for the credit purchases. All effort in this task will be based on a time and materials with an estimated not -to - exceed budget. • 9.3.4 — Cultural Resource Assessment Although the USACE Fort Worth District Regulatory Archeologist was not consulted prior to this proposal, the following scope was developed using the typical expectations of the USACE for NHPA Section 106 compliance. As such, it is assumed that the cultural resources assessment will be required for the project limits shown in the above exhibit and will be comprised of an above ground resources survey and an archeological desktop study. In addition, a 300-ft area outside the project area will be surveyed to account for the project's potential indirect impacts to above ground historic -age above ground resources. Cultural resources data and analysis will be consolidated into a draft report that will be prepared and submitted in support of the CWA NWP PCN and to ensure that the project complies with the National Historic Preservation Act (NHPA) Section 106. An Architectural Historian that meets the Secretary of the Interior Professional Qualification Standards for Architectural History to conduct an above ground resources survey within the project area and within 300 ft of the proposed project. City of Fort Worth, Texas Page 16 of 20 Attachment A Revision Date: 05.23.2024 Page 16 of 20 FORT WORTH® To these ends, we will complete the following services: • Complete a reconnaissance survey of the project area and within 300 ft to document historic age above ground resources. • Conduct sufficient research to evaluate each resource's current condition in comparison with its historical construction, as well as its historical significance within its context; • Evaluate each identified above ground resource for listing on the NRHP; and; • Draft a technical report section with supporting graphics that documents each resource's existing condition, provides NRHP eligibility assessments, evaluated the cultural integrity of the resources, assesses potential adverse effects to resources, and provides recommendations to ensure project compliance with NHPA Section 106. To gather information and perform analysis, a reconnaissance above ground resource survey will be conducted using photographic documentation from Task 1. Typical methods accepted for identification and evaluation by the USACE/THC place the cutoff date for historic -age resources as those determined to be 50 years old or greater, which for this project was 1974. Resources 50 years in and or older will be examined to observe and briefly document location, type, age, material, and integrity, which was primarily accomplished through photographs and field notes. Visible modern elements or intrusions with a historic -age property will be documented for context but will not be individually recorded. Each historic -age resource will be given a unique identifier, geographically documented on a location map, and included within a tabular inventory. Any available address or locational information will be recorded. Per the requirements of the NHPA Section 106, the USACE mush consider project impact to archeological resources during their evaluation of the CWA 404 Permit. As such, we will provide analysis and information pertaining to: • Project location and design • Soils • Topography and Geology • Known archeological sites, National Register properties and districts, historic -aged buildings and structures, cemeteries, and Historical markers within the project area. • Previously conducted archeological surveys within one -mile of the project area • Cultural resources probability assessment • Property ownership through deed chain -of -title research City of Fort Worth, Texas Page 17 of 20 Attachment A Revision Date: 05.23.2024 Page 17 of 20 FORT WORTH® • Recommendations 9.4 Floodplain Services 9.4.1 Flood Study • A flood study will be prepared to adequately model the effects of the proposed project to the existing stream and floodplain. • The flood study will include effective, corrected effective (should it be determined that existing effective model needs revisions), pre -project and proposed conditions hydraulic models in support of regulatory authority review and approvals. • The flood study is intended to utilize the existing effective hydrology associated with the current effective hydraulic models. Revised hydrology is not included in this scope of work. 9.4.2 Flood Plain Development Permit • Meet, negotiate and coordinate to obtain approval of the agency issuing the agreement and/or permits • Completing all forms/applications necessary • Submitting forms/applications for CITY review • Submitting revised forms for agency review • Responding to agency complaints and requests 9.4.3 USACE coordination • Meeting, negotiation and coordination to obtain approval of the agency issuing the agreement and/or permits • Completing all forms/applications necessary • Submitting forms/applications for CITY review • Submitting revised forms for agency review • Responding to agency comments and requests ASSUMPTIONS • Effective floodplain models will be provided by City of Fort Worth • Flood study does not include revised hydrology and is intended to utilize the existing hydrology contained within the effective models • CLOMR/LOMR services are excluded from this scope of work City of Fort Worth, Texas Page 18 of 20 Attachment A Revision Date: 05.23.2024 Page 18 of 20 FORT WORTH® • Flood Plain Development Permit Fees are excluded from this scope of work • Permit preparation will begin after approval of the Conceptual Design • Two (2) meetings are assumed with City of Fort Worth Floodplain Department for the Floodplain Development permit • Two (2) meetings are assumed with US Army Corp of Engineers for the Floodplain Development permit DELIVERABLES A. Copies of Flood Study B. Copies of Permit Applications C. Copies of Approved Permits TASK 10. ADDITIONAL SERVICES ENGINEER will provide project support as follows. 10.1. Additional Services This task establishes a budgetary item for additional services should they become necessary either due to additional efforts on tasks defined within the scope that exceed the project assumptions or items that are defined as additional services not currently included but which may become necessary during the course of the project. Prior to beginning any efforts within this budgetary item a sub -task scope and fee will be prepared and submitted to the CITY for review and approval. ADDITIONAL SERVICES NOT INCLUDED IN THE EXISTING SCOPE OF SERVICES Additional Services not included in the existinq Scope of Services — CITY and ENGINEER agree that the following services are beyond the Scope of Services described in the tasks above. However, ENGINEER can provide these services, if needed, upon the CITY's written request. Any additional amounts paid to the ENGINEER as a result of any material change to the Scope of the Project shall be agreed upon in writing by both parties before the services are performed. These additional services include the following: • Service related to boundary surveying • Negotiation of rights -of -entry, easements or property acquisition • CLOMR/LOMR preparation and submittal services • Park Conversion Services • Waters of the US mitigation fees • Public Meetings have been excluded from this scope of work City of Fort Worth, Texas Page 19 of 20 Attachment A Revision Date: 05.23.2024 Page 19 of 20 FORT WORTH® • Services related to disputes over pre -qualification, bid protests, bid rejection and re- bidding of the contract for construction. • Administration of the construction contract and inspection services • Performance of materials testing or specialty testing services. • Services necessary due to the default of the Contractor. • Services related to submitting for permits other than those specifically listed above (i.e. TxDOT, railroad, etc....) • Service related to Subsurface Utility Engineering Levels A, B, C, or D • Service related to Survey Construction Staking • Services related to damages caused by fire, flood, earthquake or other acts of God. • Services related to warranty claims, enforcement and inspection after final completion. • Services to support, prepare, document, bring, defend, or assist in litigation undertaken or defended by the CITY. • Performance of miscellaneous and supplemental services related to the project as requested by the CITY. City of Fort Worth, Texas Page 20 of 20 Attachment A Revision Date: 05.23.2024 Page 20 of 20 ATTACHMENT B COMPENSATION Design Services for PECAN VALLEY GOLF COURSE BRIDGE REPLACEMENT City Project No. 105401 Lump Sum Project Compensation A. The ENGINEER shall be compensated a total lump sum fee of $325.350.00 as summarized in Exhibit B-1 — Engineer Invoice and Section IV — Summary of Total Project Fees. The total lump sum fee shall be considered full compensation for the services described in Attachment A, including all labor materials, supplies, and equipment necessary to deliver the services. B. The ENGINEER shall be paid monthly payments as described in Section II - Method of Payment. Method of Payment A. Partial payment shall be made to the ENGINEER monthly upon City's approval of an invoice prepared and submitted by the ENGINEER in the format and including content as presented in Exhibit B-1, Progress Reports as required in item 111. of this Attachment B, and Schedule as required in Attachment D to this Agreement. B. The estimated current physical percent complete as required on the invoice shall be calculated from the progress schedule as required in Attachment D to this Standard Agreement and according to the current version of the City of Fort Worth's Schedule Guidance Document. C. The cumulative sum of such monthly partial fee payments shall not exceed the total current project budget including all approved Amendments. D. Each invoice shall be verified as to its accuracy and compliance with the terms of this Agreement by an officer of the ENGINEER. III. Progress Reports A. The ENGINEER shall prepare and submit to the designated representative of the Water Department monthly progress reports and schedules in the format required by the City. City of Fort Worth, Texas Attachment B Revised Date: 12/9/2022 Page 1 of 3 AM ATTACHMENT B COMPENSATION IV. Summary of Total Project Fees Firm Primary Responsibility Prime Consultant Baird, Hampton & Civil & Structural Engineering Brown, Inc Proposed MWBE Sub -Consultants Gorrondonna & Land Surveying Associate Inc. Geotex Engineering Geotechnical Engineering Integrated Environmental & Archeological Environmental Services Solutions LLC. BDA Associates TDLR Services Non-MWBE Consultants Project Number & Name Pecan Valley Gold Course Bridge Replacement City Project No. 105401 City MWBE Goal = 10% City of Fort Worth, Texas Attachment B Revised Date: 12/9/2022 Page 2 of 3 Fee Amount $270,050.00 83.0% $15,500.00 4.76% $17,400.00 5.35% $17,400.00 5.35% $5,000.00 1.54% TOTAL $ 325,350.00 100% Total Fee MWBE Fee MWBE % $ 325.350.00 $ 55.300.00 17.0 % Consultant Comm tted Goal = 10 % AM EXHIBIT "13-1" ENGINEER INVOICE (Supplement to Attachment B) Insert required invoice format following this page, including negotiated total budget and allocations of budgets across work types and work phases. City of Fort Worth, Texas Attachment B Revised Date: 12/9/2022 Page 3 of 3 LIM ATTACHMENT "C" CHANGES AND AMENDMENTS TO STANDARD AGREEMENT Design Services for Pecan Valley Golf Course Bridge Replacement City Project No. 105401 No changes have been made to the Standard Agreement. City of Fort Worth, Texas Attachment C PMO Release Date: 05.19.2010 Page I of I FORT WORTH ATTACHMENT "D" PROJECT SCHEDULE A. ENGINEER Project Schedule Development ENGINEER shall prepare a project schedule for the services to be provided in fulfilling the requirements of the Agreement and encompassing the Scope of Work defined in Attachment A to the Agreement. ENGINEER shall prepare and maintain project schedule throughout the life of the project as defined in the Agreement in compliance with the City's Specification 00 31 15 entitled Engineer Project Schedule. ENGINEER's project schedule will follow the Critical Path Methodology (CPM) for planned sequencing of the work activity and timing of the work. B. Schedule "Tier" Selection City has identified three "Tier" levels for project schedules as defined in City's Specification 00 31 15, to align with the size and complexity of the project as a basis for schedule development. City's Project Manager will determine the "Tier" level for the ENGINEER's project schedule as part of the negotiation of the Agreement. C. Project Baseline Schedule ENGINEER will produce an initial project schedule and submit as a "baseline" for review and acceptance by City's Project Manager as defined in City's Specification 00 31 15 which will be referred to as the Project Baseline Schedule. Updates to the baseline schedule follow the requirements of City's Specification 00 31 15. D. Project Progress Schedule ENGINEER will provide to the City, monthly updates to their project schedule indicating progress of the Work in compliance with the requirements of City's Specification 00 31 15 and said schedule will be referred to as the Project Progress Schedule. E. Master Project Schedule City will develop and maintain a master project schedule for the overall project. ENGINEER's project baseline and progress schedule submittals will be an integral part of the development and updating process of City's Master Project Schedule. City of Fort Worth, Texas Attachment D Revision Date: 07.20.2018 Page 1 of 1 ID Task Name D.— I SLLd Find, % omm Pa tlmy Bmdga RepMcemant Ua� M Daslgn pn a31rz5 Fmr9rzo128 0x ne sempea pn a:1rzs Fd srsorzs az 4 P Research & Data C0.-1 ys Mon 4121/25 Fn 5YL25 0% Deagn Survey Mon 515125 In 590125 0% 6 ers of lM1e US natures Mon 5l5rz5 Fn 630I25 % vestlga0onon days 9 nnPmaP10ea1gn 7D drys M M ­ 311-1 1. o% RepM &oPc n 0% nrepplR Ndn 1-5 13 CryRen w&Comment 41ays Mon]114125 Thu 2131125 0% 14 Incmpowm Concept IW-Commems&11-1 to days Fn 1-1 Thu811-5 0% Rewsm Relpd 5 - Design ReMew.-mil 1 tlay Fr &12Y25 16 Cnncem Dea9n eemmme Odays Fri 6I2- n 17 pn azsns "i rvPrepsre Prelemmary Co—.. pl. days M . 19 - Prelim.—dt Dow, Specs&OK 10 ' Mon 1016125 Fr 0% c.v Rewew & LammeM ecs. a E.—area 25 nn 22 wrp— Pmlimlmry Review Common%&—t 15 y on11110125 R1111-125 D% r Design Package mrery lmiDeapn Commem ri Flnee Enginring yn 25 Fina110-1i01 Plana (90%) s Man 12/125 Fr 26 .—.Dow -. Spemcaeons oni2rz9/25 I,, I— & Es -(90%) n CI1y Revmwlm, S & Lamm 29 Incorporate Fnal(—)) Comments end Submt —1 15 tlay' Mon 2/2126 Fn2-126 0% (100%) PMreand Sp 6,M- 30 Approve F il Plans and Sp M.U. & RauLL to 10 days Mon =3126 Fri .126 0% sMmm ea Desgn commMe gdaye ri 3t 5 days 9/&ne % 33 3113126 0% P pare Bid Package1 on III.n112012d 0% P.— a 612rz5 m n M22126 0% TDLR 146 days M 1211rz5 m nN22126 0% Mct Reglanatbn 9] Pmlect ReWew 5 days Mon 1126126 M n 0% I_ mien . 121 Man612v26 0% Rewew & Approve Pecan Valley Golf Course Bridge Replacment, CPN 105401 ntl Oua rtl CuA.o san 'IN'-- D sr Oue 2nd Oua 3N Oua 1M1 Oua 7,7 ]li -2 �119 I ew&Apprwel on12/29/25 Fn 3120126 0% Cut.. Resources Aweasm..t Perm -P...' Mon 612/25 Fn % Mon &19 Cultural Flan w R 1 Approval s Mon 811121 1,, 111121 0% radplaln SaMcea ys Man a25rz5 12/20126 0% 6mtly M.. 3125125 1925 n 0% l� a p!.n Devepoment Perrot Pmparetlon an12/1125 F F podpen Perml Subm lte y' Fn 1-5 Fr I21125 0% Foodpen Perrot— &Approve ys on 12/29125 II2-26 0% Pamarmwn u9ACE Perron. —it 0daya tFn 1-125 F ex ♦Horn 62 Adtlema BM Opening 65 —BE Owu—I. e 57 mpro 69 CeI.-m Pmwed 70 PreCor .—Meetlng 12 o ewt 0 ]3 Acwptance oak �eem: Pawn valley snags Wen 3/19/25 MlMamne 60 days Mon 1p120125 Fn 1-I n Man a93rre Frl tltl2] yspn a2&rze Fn aag6 Mon9123126 Fn a1]l28 Mon 4Ifil26 Mon M6l26 an4113126 Mon 411 N26 rtl 101 ' Mon-126 ri ri 111127OX Fn6— FI I-- nIll 9126 tlay' M n F 1119126 n 1.126 20 days Man 12r]126 Fin 11112] 0% 0% O% 0% 0% 0% 0% 0% 0% 0% 0% 0% O% Summery �� Ememel Mileamne ♦ MenuelTwk O ............... ♦ —.1 Tasks M.Idd— I. —Summary a ............... Duram.ely Manual Summary Rollup♦ ......, Meruel Summary ♦ Extemel Teske O Deadtlne 4 ma mat M�leamne � Fln—.1,, P.— Pase 1 Attachment E - Project Location l® ni.vb N ' �, Fayla Mouatin W E Pzlc �i .�go�a CMu'Hoiwx �c S Wala�9d _FoRT WORTH. sa4r<w Blue Mtauaa it ��NuRh:Rehhnd..Htlls lakeside; Hunt Lake Wnrth Haltom C'Ay RICHE y'ilh So- Palk. f/ River Oaks Whits Settlamenc Wsstwarth � EO�OIiJf ��� [Sil� iwi�LSlnf M+aMIMGa19E mB O Bentimok a. l� e© li`��"foresrW'Il PROJECT J Vlihpe Renredae HAMPTON & BROWN LOCATION Evernan -� BAI RD, MAPSC087Z I ITTIII engineering and surveying PaN ■a5[I Nwle. 3801 William D. Tate Ave, Ste 500 Grapevine, TX 76051 mail@bhbinc.com • 817.251.8550 • bhbinc.com VICINITY MAP TBPELS Firm #44, #10011300, #10011302, #10194146 BHB Project No. 2024.723.000 ® ATTACHMENT "F" I DATE (MM/DD/YYYY) A� CERTIFICATE OF LIABILITY INSURANCE 03/19/2025 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT Phyllis Constantino NAME: MEDALLION INSURANCE SERVICES I PHONE . Extl: (704) 256-6000 A/XX, No): (704) 256-6001 LA/CPO Box 79089 I E-MAIL phyllis@medallioninsurance.com Ilis medallioninsurance.com ADDRESS: INSURER(S) AFFORDING COVERAGE NAIC # Charlotte NC 28271 INSURERA: Hartford Underwriters Insurance Company 30104 INSURED INSURER B : Nutmeg Insurance Company 39608 Baird Hampton & Brown, Inc. INSURER C : Westfield Select Insurance Company 17105 6300 Ridglea PI INSURER D : Ste 700 INSURER E : Fort Worth TX 76116 INSURER F : COVERAGES CERTIFICATE NUMBER: CL2472510794 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR ADDL SUBR LTR TYPE OF INSURANCE INSD WVD POLICY NUMBER POLICY EFF POLICY EXP (MM/DD/YYYY) (MM/DD/YYYY) LIMITS X COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ 1,000,000 FX DAMAGE TO ence) 1,000,000 CLAIMS -MADE OCCUR PREMISES Ea occur $ MED EXP (Any one person) $ 10,000 _ A Y 22SBABB4DWT 12/01/2024 12/01/2025 PERSONAL & ADV INJURY $ 11000,000 GEN'LAGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ 2,000,000 POLICY � PRO FX LOC JECT PRODUCTS - COMP/OP AGG $ 2,000,000 OTHER: $ AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT (Ea accident) $ 1,000,000 _ X ANYAUTO I BODILY INJURY (Per person) $ B OWNED SCHEDULED 22UECAF8868 12/01/2024 12/01/2025 BODILY INJURY (Per accident) $ _ AUTOS ONLY AUTOS HIRED PROPERTY DAMAGE $ HNON-OWNED _ AUTOS ONLY AUTOS ONLY (Per accident) State surcharge 1 $ UMBRELLA LIAB X X OCCUR EACH OCCURRENCE 5,000,000 $ A EXCESS LAB CLAIMS -MADE 22SBABB4DWT 12/01/2024 12/01/2025 AGGREGATE $ 5,000,000 DED I XI RETENTION $ 10,000 $ WORKERS COMPENSATION XI I I AND EMPLOYERS' LIABILITY Y/ N SPER TATUTE ERH A ANY PROPRIETOR/PARTNER/EXECUTIVE N N/A 22WECBB4EEV 12/01/2024 12/01/2025 E.L. EACH ACCIDENT $ 1,000,000 OFFICER/MEMBER EXCLUDED? 1,000,000 (Mandatory in NH) E.L. DISEASE - EA EMPLOYEE $ If yes, describe under 1,000,000 DESCRIPTION OF OPERATIONS below E.L. DISEASE - POLICY LIMIT $ EACH CLAIM $5,000,000 PROFESSIONAL LIABILITY C CLAIMS -MADE DP-0000102 07/26/2024 07/26/2025 AGGREGATE $5,000,000 DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) RE: Pecan Valley Golf Course Bridge Replacement Project Number 105401. City of Fort Worth -Reference Blanket CGL Additional Insured Endorsement applies when required by written contract. All policy forms and endorsements are applicable and are available upon request. CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN City of Fort Worth ACCORDANCE WITH THE POLICY PROVISIONS. 100 Fort Worth Trail AUTHORIZED REPRESENTATIVE Fort Worth TX 76102 I ©1988-2015 ACORD CORPORATION. All rights reserved. ACORD 25 (2016/03) The ACORD name and logo are registered marks of ACORD THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. TEXAS WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT Policy Number: 22 WEC BB4EEV Endorsement Number: Effective Date: 12/01/24 Effective hour is the same as stated on the Information Page of the policy. Named Insured and Address: Baird, Hampton & Brown, Inc. 6300 RIDGLEA PL STE 700 FORT WORTH TX 76116 This endorsement applies only to the insurance provided by the policy because Texas is shown in Item 3.A. of the Information Page. We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule, but this waiver applies only with 1. () Special Waiver Name of person or organization respect to bodily injury arising out of the operations described in the Schedule where you are required by a written contract to obtain this waiver from us. This endorsement shall not operate directly or indirectly to benefit anyone not named in the Schedule. The premium for this endorsement is shown in the Schedule. Schedule (X) Blanket Waiver Any person or organization for whom the Named Insured has agreed by written contract to furnish this waiver. 2. Operations: All Texas Operations 3. Premium: The premium charge for this endorsement shall be 2 percent of the premium developed on payroll in connection with work performed for the above person(s) or organization(s) arising out of the operations described. 4. Advance Premium: Form WC 42 03 04 B Printed in U.S.A. Process Date: 10/22/24 Policy Expiration Date: 12/01/25 COMMERCIAL AUTOMOBILE HA99161221 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. COMMERCIAL AUTOMOBILE BROAD FORM ENDORSEMENT This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE FORM To the extent that the provisions of this endorsement provide broader benefits to the "insured" than other provisions of the Coverage Form, the provisions of this endorsement apply. 1. BROAD FORM INSURED Paragraph .1. - WHO IS AN INSURED - of Section II - Liability Coverage is amended to add the following: d. Subsidiaries and Newly Acquired or Formed Organizations The Named Insured shown in the Declarations is amended to include: (1) Any legal business entity other than a partnership or joint venture, formed as a subsidiary in which you have an ownership interest of more than 50% on the effective date of the Coverage Form. However, the Named Insured does not include any subsidiary that is an "insured" under any other automobile policy or would be an "insured" under such a policy but for its termination or the exhaustion of its Limit of Insurance. (2) Any organization that is acquired or formed by you and over which you maintain majority ownership. However, the Named Insured does not include any newly formed or acquired organization: (a) That is a partnership or joint venture, (b) That is an "insured" under any other policy, (c) That has exhausted its Limit of Insurance under any other policy, or (d) 180 days or more after its acquisition or formation by you, unless you have given us notice of the acquisition or formation. Coverage does not apply to "bodily injury" or "property damage" that results from an "accident" that occurred before you formed or acquired the organization. e. Employees as Insureds (1). Any "employee" of yours while using a covered "auto" you don't own, hire or borrow in your business or your personal affairs. f. Lessors as Insureds (1). The lessor of a covered "auto" while the "auto" is leased to you under a written agreement if: (a) The agreement requires you to provide direct primary insurance for the lessor and (b) The "auto" is leased without a driver. Such a leased "auto" will be considered a covered "auto" you own and not a covered "auto" you hire. g. Additional Insured if Required by Contract (1) When you have agreed, in a written contract or written agreement, that a person or organization be added as an additional insured on your business auto policy, such person or organization is an "insured", but only to the extent such person or organization is liable for "bodily injury" or "property damage" caused by the conduct of an "insured" under paragraphs a. or b. of Who Is An Insured with regard to the ownership, maintenance or use of a covered "auto." The insurance afforded to any such additional insured applies only if the "bodily injury" or "property damage" occurs: (a) During the policy period, and (b) Subsequent to the execution of such written contract, and Form HA 99 16 12 21 © 2021, The Hartford (Includes copyrighted material of Insurance Services Office, Inc. with its permission.) Page 1 of 5 (c) Prior to the expiration of the period of time that the written contract requires such insurance be provided to the additional insured. (2) How Limits Apply If you have agreed in a written contract or written agreement that another person or organization be added as an additional insured on your policy, the most we will pay on behalf of such additional insured is the lesser of: (a) The limits of insurance specified in the written contract or written agreement; or (b) The Limits of Insurance shown in the Declarations. Such amount shall be a part of and not in addition to Limits of Insurance shown in the Declarations and described in this Section. (3) Additional Insureds Other Insurance If we cover a claim or "suit" under this Coverage Part that may also be covered by other insurance available to an additional insured, such additional insured must submit such claim or "suit" to the other insurer for defense and indemnity. However, this provision does not apply to the extent that you have agreed in a written contract or written agreement that this insurance is primary and non-contributory with the additional insured's own insurance. (4) Duties in The Event Of Accident, Claim, Suit or Loss If you have agreed in a written contract or written agreement that another person or organization be added as an additional insured on your policy, the additional insured shall be required to comply with the provisions in LOSS CONDITIONS 2. - DUTIES IN THE EVENT OF ACCIDENT, CLAIM , SUIT OR LOSS — OF SECTION IV — BUSINESS AUTO CONDITIONS, in the same manner as the Named Insured. 2. Primary and Non -Contributory if Required by Contract Only with respect to insurance provided to an additional insured in A.1.g. - Additional Insured If Required by Contract, the following provisions apply: (1) Primary Insurance When Required By Contract This insurance is primary if you have agreed in a written contract or written agreement that this insurance be primary. If other insurance is also primary, we will share with all that other insurance by the method described in Other Insurance 5.d. (2) Primary And Non -Contributory To Other Insurance When Required By Contract If you have agreed in a written contract or written agreement that this insurance is primary and non-contributory with the additional insured's own insurance, this insurance is primary and we will not seek contribution from that other insurance. Paragraphs (1) and (2) do not apply to other insurance to which the additional insured has been added as an additional insured. When this insurance is excess, we will have no duty to defend the insured against any "suit" if any other insurer has a duty to defend the insured against that "suit". If no other insurer defends, we will undertake to do so, but we will be entitled to the insured's rights against all those other insurers. When this insurance is excess over other insurance, we will pay only our share of the amount of the loss, if any, that exceeds the sum of: (1) The total amount that all such other insurance would pay for the loss in the absence of this insurance; and (2) The total of all deductible and self -insured amounts under all that other insurance. We will share the remaining loss, if any, by the method described in SECTION IV - Business Auto Conditions, B. General Conditions, Other Insurance 5.d. 3. AUTOS RENTED BY EMPLOYEES Any "auto" hired or rented by your "employee" on your behalf and at your direction will be considered an "auto" you hire. The SECTION IV- Business Auto Conditions, B. General Conditions, 5. OTHER INSURANCE Condition is amended by adding the following: e. If an "employee's" personal insurance also applies on an excess basis to a covered "auto" hired or rented by your "employee" on your behalf and at your direction, this insurance will be primary to the "employee's" personal insurance. Page 2 of 5 Form HA 99 16 12 21 4. AMENDED FELLOW EMPLOYEE EXCLUSION EXCLUSION 5. - FELLOW MPLOYEE - of SECTION II - LIABILITY COVERAGE does not apply if you have workers' compensation insurance in -force covering all of your "employees". Coverage is excess over any other collectible insurance. 5. HIRED AUTO PHYSICAL DAMAGE COVERAGE If hired "autos" are covered "autos" for Liability Coverage and if Comprehensive, Specified Causes of Loss, or Collision coverages are provided under this Coverage Form for any "auto" you own, then the Physical Damage Coverages provided are extended to "autos" you hire or borrow, subject to the following limit. The most we will pay for "loss" to any hired "auto" is: (1) $100,000; (2) The actual cash value of the damaged or stolen property at the time of the "loss"; or (3) The cost of repairing or replacing the damaged or stolen property, whichever is smallest, minus a deductible. The deductible will be equal to the largest deductible applicable to any owned "auto" for that coverage. No deductible applies to "loss" caused by fire or lightning. Hired Auto Physical Damage coverage is excess over any other collectible insurance. Subject to the above limit, deductible and excess provisions, we will provide coverage equal to the broadest coverage applicable to any covered "auto" you own. W ill also cover loss of use of the hired "auto" if it results from an "accident", you are legally liable and the lessor incurs an actual financial loss, subject to a maximum of $1000 per "accident". This extension of coverage does not apply to any "auto" you hire or borrow from any of your "employees", partners (if you are a partnership), members (if you are a limited liability company), or members of their households. 6. PHYSICAL DAMAGE - ADDITIONAL TEMPORARY TRANSPORTATION EXPENSE COVERAGE Paragraph AA.a. of SECTION III - PHYSICAL DAMAGE COVERAGE is amended to provide a limit of $50 per day and a maximum limit of $1,000. 7. LOAN/LEASE GAP COVERAGE Under SECTION III - PHYSICAL DAMAGE COVERAGE, in the event of a total "loss" to a covered "auto", we will pay your additional legal obligation for any difference between the actual cash value of the "auto" at the time of the "loss" and the "outstanding balance" of the loan/lease. "Outstanding balance" means the amount you owe on the loan/lease at the time of "loss" less any amounts representing taxes; overdue payments; penalties, interest or charges resulting from overdue payments; additional mileage charges; excess wear and tear charges; lease termination fees; security deposits not returned by the lessor; costs for extended warranties, credit life Insurance, health, accident or disability insurance purchased with the loan or lease; and carry-over balances from previous loans or leases. 8. AIRBAG COVERAGE Under Paragraph B. EXCLUSIONS - of SECTION III - PHYSICAL DAMAGE COVERAGE, the following is added: The exclusion relating to mechanical breakdown does not apply to the accidental discharge of an airbag. 9. ELECTRONIC EQUIPMENT - BROADENED COVERAGE a. The exceptions to Paragraphs BA - EXCLUSIONS - of SECTION III - PHYSICAL DAMAGE COVERAGE are replaced by the following: Exclusions 4.c. and 4.d. do not apply to equipment designed to be operated solely by use of the power from the "auto's" electrical system that, at the time of "loss", is: (1) Permanently installed in or upon the covered "auto"; ew (2) Removable from a housing unit which is permanently installed in or upon the covered "auto"; (3) An integral part of the same unit housing any electronic equipment described in Paragraphs (1) and (2) above; or (4) Necessary for the normal operation of the covered "auto" or the monitoring of the covered "auto's" operating system. b. Section III, Physical Damage Coverage, Limit of Insurance, Paragraph C.2. is amended to add the following: $1,500 is the most we will pay for "loss" in any one "accident" to all electronic equipment (other than equipment designed solely for the reproduction of sound, and accessories used with such equipment) that reproduces, receives or transmits audio, visual or data signals which, at the time of "loss", is: Form HA 99 16 12 21 Page 3 of 5 (1) Permanently installed in or upon the covered "auto" in a housing, opening or other location that is not normally used by the "auto" manufacturer for the installation of such equipment; (2) Removable from a permanently installed housing unit as described in Paragraph 2.a. above or is an integral part of that equipment; or (3) An integral part of such equipment. c. For each covered "auto", should loss be limited to electronic equipment only, our obligation to pay for, repair, return or replace damaged or stolen electronic equipment will be reduced by the applicable deductible shown in the Declarations, or $250, whichever deductible is less. 10. EXTRA EXPENSE - BROADENED COVERAGE Under Paragraph A. - COVERAGE - of SECTION III - PHYSICAL DAMAGE COVERAGE, we will pay for the expense of returning a stolen covered "auto" to you. 11. GLASS REPAIR -WAIVER OF DEDUCTIBLE Under Paragraph D. - DEDUCTIBLE - of SECTION III - PHYSICAL DAMAGE COVERAGE, the following is added: No deductible applies to glass damage if the glass is repaired rather than replaced. 12. TWO OR MORE DEDUCTIBLES Under Paragraph D. - DEDUCTIBLE - of SECTION III - PHYSICAL DAMAGE COVERAGE, the following is added: If another Hartford Financial Services Group, Inc. company policy or coverage form that is not an automobile policy or coverage form applies to the same "accident", the following applies: (1) If the deductible under this Business Auto Coverage Form is the smaller (or smallest) deductible, it will be waived; (2) If the deductible under this Business Auto Coverage Form is smallest) deductible, amount of the deductible. not the smaller (or it will be reduced by the smaller (or smallest) 13. AMENDED DUTIES IN THE EVENT OF ACCIDENT, CLAIM, SUIT OR LOSS The requirement in LOSS CONDITIONS 2.a. - DUTIES IN THE EVENT OF ACCIDENT, CLAIM, SUIT OR LOSS - of SECTION IV - BUSINESS AUTO CONDITIONS that you must notify us of an "accident" applies only when the "accident" is known to: (1) You, if you are an individual; (2) A partner, if you are a partnership; (3) A member, if you are a limited liability company; or (4) An executive officer or insurance manager, if you are a corporation. 14. UNINTENTIONAL FAILURE TO DISCLOSE HAZARDS If you unintentionally fail to disclose any hazards existing at the inception date of your policy, we will not deny coverage under this Coverage Form because of such failure. 15. HIRED AUTO - COVERAGE TERRITORY SECTION IV, BUSINESS AUTO CONDITIONS, PARAGRAPH B. GENERAL CONDITIONS, 7. - POLICY PERIOD, COVERAGE TERRITORY - is added to include the following: (6) For short-term hired "autos", the coverage territory with respect to Liability Coverage is anywhere in the world provided that if the "insured's" responsibility to pay damages for "bodily injury" or "property damage" is determined in a "suit," the "suit" is brought in the United States of America, the territories and possessions of the United States of America, Puerto Rico or Canada or in a settlement we agree to. 16. WAIVER OF SUBROGATION Paragraph 5. TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US - of SECTION IV - BUSINESS AUTO CONDITIONS A. Loss Conditions is amended by adding the following: We waive any right of recovery we may have against any person or organization with whom you have a written contract that requires such waiver because of payments we make for damages under this Coverage Form. 17. RESULTANT MENTAL ANGUISH COVERAGE The definition of "bodily injury" in SECTION V- DEFINITIONS, C. is replaced by the following: "Bodily injury" means bodily injury, sickness or disease sustained by any person, including mental anguish or death resulting from any of these. 18. EXTENDED CANCELLATION CONDITION Paragraph 2. of the COMMON POLICY CONDITIONS - CANCELLATION - applies except as follows: If we cancel for any reason other than nonpayment of premium, we will mail or deliver to the first Named Insured written notice of cancellation at least 60 days before the effective date of cancellation. Page 4 of 5 Form HA 99 16 12 21 19. HYBRID, ELECTRIC, OR NATURAL GAS VEHICLE PAYMENT COVERAGE In the event of a total loss fb a non -hybrid" auto for which Comprehensive, Specified Causes of Loss, or Collision coverages are provided under this Coverage Form, then such Physical Damage Coverages are amended as follows: a. If the auto is replaced with a hybrid" auto or an auto powered solely by electricity or natural gas, we will pay an additional 10%, to a maximum of $2,500, of the "non -hybrid" auto's actual cash value or replacement cost, whichever is less, b. The auto must be replaced and a opy of a bill of sale or new lease agreement received by us within 60 calendar days of the date of "loss," c. Regardless of the number of autos deemed a total loss, the most we will pay under this Hybrid, Electric, or Natural Gas Vehicle Payment Coverage provision for any one "loss" is $10,000. For the purposes of the coverage provision, a. A "non -hybrid" auto is defined as an auto that uses only an internal combustion engine to move the auto but does not include autos powered solely by electricity or natural gas. b. A "hybrid" auto is defined as an auto with an internal combustion engine and one or more electric motors; and that uses the internal combustion engine and one or more electric motors to move the auto, or the internal combustion engine to charge one or more electric motors, which move the auto. 20. VEHICLE WRAP COVERAGE In the event of a total loss to an "auto" for which Comprehensive, Specified Causes of Loss, or Collision coverages are provided under this Coverage Form, then such Physical Damage Coverages are amended to add the following: In addition to the actual cash value of the "auto", we will pay up to $1,000 for vinyl vehicle wraps which are displayed on the covered "auto" at the time of total loss. Regardless of the number of autos deentied a otal loss, the most we will pay under this Vehicle Wrap Coverage provision for any one "loss" is $5,000. For purposes of this coverage provision, signs or other graphics painted or magnetically affixed to the vehicle are not considered vehicle wraps. Form HA 99 16 12 21 Page 5 of 5 THE HARTFORD BUSINESS LIABILITY COVERAGE FORM Various provisions in this Policy restrict coverage. Read the entire Policy carefully to determine rights, duties and what is and is not covered. Throughout this Coverage Part the words "you" and "your" refer to the Named Insured shown in the Declarations. The words "we", "us" and 'bur" refer to the insurance company shown in the Declarations. "Policy period", as used in this Coverage Part, means the period from the effective date of this Coverage Part to the expiration date of the Coverage Part as stated in the Declarations or the date of cancellation, whichever is earlier. The word "insured" means any person or organization qualifying as such under Section C. Who Is An Insured. Other words and phrases that appear in quotation marks have special meaning. Refer to Section F. Liability And dical Expenses Definitions. A. COVERAGES 1. Business Liability Coverage (Bodily Injury, Property Damage, Personal And Advertising Injury) Insuring Agreement a. We will pay those sums that the insured becomes legally obligated to pay as damages because of "bodily injury", "property damage" or "personal and advertising injury" to which this insurance applies. We will have the right and duty to defend the insured against any "suit' seeking those damages. However, we will have no duty to defend the insured against any "suit' seeking damages for "bodily injury", "property damage" or "personal and advertising injury" to which this insurance does not apply. We may, at our discretion, investigate any 'occurrence" or offense and settle any claim or "suit' that may result. But: (1) The amount we will pay for damages is limited as described in Section D. Liability And dical Expenses Limits Of Insurance; and (2) Our right and duty to defend ends when we have used up the applicable limit of insurance in the payment of judgments, settlements or medical expenses to which this insurance applies. No other obligation or liability to pay sums or perform acts or services is covered unless explicitly provided for under Coverage Extension - Supplementary Payments. b. This insurance applies: (1) To "bodily injury" and "property damage" only if: (a) The "bodily injury" or "property damage" is caused by an "occurrence" that takes place in the "coverage territory"; (b) The "bodily injury" or "property damage" occurs during the policy period; and (c) Prior to the policy period, no insured listed under Paragraph 1. of Section C. Who Is An Insured and no "employee" authorized by you to give or receive notice of an 'occurrence" or claim, knew that the "bodily injury" or "property damage" had occurred, in whole or in part. If such a listed insured or authorized "employee" knew, prior to the policy period, that the "bodily injury" or "property damage" occurred, then any continuation, change or resumption of such "bodily injury" or "property damage" during or after the policy period will be deemed to have been known prior to the policy period. (2) To "personal and advertising injury" caused by an offense arising out of your business, but only if the offense was committed in the "coverage territory" during the policy period. c. "Bodily injury" or "property damage" will be deemed to have been known to have occurred at the earliest time when any insured listed under Paragraph 1. of Section C. Who Is An Insured or any "employee" authorized by you to give or receive notice of an 'occurrence" or claim: (1) Reports all, or any part, of the "bodily injury" or "property damage" to us or any other insurer; (2) Receives a written or verbal demand or claim for damages because of the "bodily injury" or "property damage"; or Form SL 00 00 10 18 Page 1 of 22 © 2018, The Hartford (May include copyrighted material of Insurance Services Office, Inc., with its permission) THE HARTFORD (3) Becomes aware by any other means that "bodily injury" or "property damage" has occurred or has begun to occur. d. Damages because of "bodily injury" include damages claimed by any person or organization for care, loss of services or death resulting at any time from the "bodily injury". e. Incidental Medical Malpractice (1) "Bodily injury" arising out of the rendering of or failure to render professional health care services as a physician, dentist, nurse, emergency medical technician or paramedic shall be deemed to be caused by an "occurrence", but only if: (a) The physician, dentist, nurse, emergency medical technician or paramedic is employed by you to provide such services; and (b) You are not engaged in the business or occupation of providing such services. (2) For the purpose of determining the limits of insurance for incidental medical malpractice, any act or omission together with all related acts or omissions in the furnishing of these services to any one person will be considered one "occurrence". 2. Medical Expenses Insuring Agreement a. We will pay medical expenses as described below for "bodily injury" caused by an accident: (1) On premises you own or rent; (2) On ways next to premises you own or rent; or (3) Because of your operations; provided that: (1) The accident takes place in the "coverage territory" and during the policy period; (2) The expenses are incurred and reported to us within three years of the date of the accident; and (3) The injured person submits to examination, at our expense, by physicians of our choice as often as we reasonably require. b. We will make these payments regardless of fault. These payments will not exceed the applicable limit of insurance. We will pay reasonable expenses for: (1) First aid administered at the time of an accident; (2) Necessary medical, surgical, x-ray and dental services, including prosthetic devices; and (3) Necessary ambulance, hospital, professional nursing and funeral services. 3. Coverage Extension - Supplementary Payments a. We will pay, with respect to any claim we investigate or settle, or any "suit" against an insured we defend: (1) All expenses we incur. (2) Up to $1,000 for the cost of bail bonds required because of accidents or traffic law violations arising out of the use of any vehicle to which Business Liability Coverage for "bodily injury" applies. We do not have to furnish these bonds. (3) The cost of appeal bonds or bonds to release attachments, but only for bond amounts within the applicable limit of insurance. We do not have to furnish, finance, arrange for, guarantee, or collateralize these bonds, whether the collateral ization is characterized as premium or not. (4) All reasonable expenses incurred by the insured at our request to assist us in the investigation or defense of the claim or "suit", including actual loss of earnings up to $500 a day because of time off from work. (5) All court costs taxed against the insured in the "suit". However, such costs do not include attorneys' fees, attorneys' expenses, witness or expert fees, or any other expenses of a party taxed against the insured. (6) Prejudgment interest awarded against the insured on that part of the judgment we pay. If we make an offer to pay the applicable limit of insurance, we will not pay any prejudgment interest based on that period of time after the offer. Form SL 00 00 10 18 Page 2 of 22 © 2018, The Hartford (May include copyrighted material of Insurance Services Office, Inc., with its permission) THE HARTFORD (7) All interest on the full amount of any judgment that accrues after entry of the judgment and before we have paid, offered to pay, or deposited in court the part of the judgment that is within the applicable limit of insurance. Any amounts paid under (1) through (7) above will not reduce the Limits of Insurance. b. If we defend an insured against a "suit" and an indemnitee of the insured is also named as a party to the "suit", we will defend that indemnitee if all of the following conditions are met: (1) The "suit" against the indemnitee seeks damages for which the insured has assumed the liability of the indemnitee in a contract or agreement that is an "insured contract"; (2) This insurance applies to such liability assumed by the insured; (3) The obligation to defend, or the cost of the defense of, that indemnitee, has also been assumed by the insured in the same "insured contract"; (4) The allegations in the "suit" and the information we know about the "occurrence" are such that no conflict appears to exist between the interests of the insured and the interest of the indemnitee; (5) The indemnitee and the insured ask us to conduct and control the defense of that indemnitee against such "suit" and agree that we can assign the same counsel to defend the insured and the indemnitee; and (6) The indemnitee: (a) Agrees in writing to: (1) Cooperate with us in the investigation, settlement or defense of the "suit"; (ii) Immediately send us copies of any demands, notices, summonses or legal papers received in connection with the "suit"; (iii) Notify any other insurer whose coverage is available to the indemnitee; and (iv) Cooperate with us with respect to coordinating other applicable insurance available to the indemnitee; and (b) Provides us with written authorization to: (i) Obtain records and other information related to the "suit"; and (ii) Conduct and control the defense of the indemnitee in such "suit". So long as the above conditions are met, attorneys' fees incurred by us in the defense of that indemnitee, necessary litigation expenses incurred by us and necessary litigation expenses incurred by the indemnitee at our request will be paid as Supplementary Payments. Notwithstanding the provisions of Paragraph 1.b.(b) of Section B. Exclusions, such payments will not be deemed to be damages for "bodily injury" and "property damage" and will not reduce the Limits of Insurance. Our obligation to defend an insured's indemnitee and to pay for attorneys' fees and necessary litigation expenses as Supplementary Payments ends when: (1) We have used up the applicable limit of insurance in the payment of judgments or settlements; or (2) The conditions set forth above, or the terms of the agreement described in Paragraph (6) above, are no longer met. B. EXCLUSIONS 1. Applicable To Business Liability Coverage This insurance does not apply to: a. Expected Or Intended Injury (1) "Bodily injury" or "property damage" expected or intended from the standpoint of the insured. This exclusion does not apply to "bodily injury" or "property damage" resulting from the use of reasonable force to protect persons or property; or (2) "Personal and advertising injury" arising out of an offense committed by, at the direction of or with the consent or acquiescence of the insured with the expectation of inflicting "personal and advertising injury". Form SL 00 00 10 18 Page 3 of 22 © 2018, The Hartford (May include copyrighted material of Insurance Services Office, Inc., with its permission) THE HARTFORD b. Contractual Liability (1) "Bodily injury" or "property damage"; or (2) "Personal and advertising injury" for which the insured is obligated to pay damages by reason of the assumption of liability in a contract or agreement. This exclusion does not apply to liability for damages because of: (a) "Bodily injury", "property damage" or "personal and advertising injury" that the insured would have in the absence of the contract or agreement; or (b) "Bodily injury" or "property damage" assumed in a contract or agreement that is an "insured contract", provided the "bodily injury" or "property damage" occurs subsequent to the execution of the contract or agreement. Solely for the purpose of liability assumed in an "insured contract", reasonable attorneys' fees and necessary litigation expenses incurred by or for a party other than an insured are deemed to be damages because of "bodily injury" or "property damage" provided: (i) Liability to such party for, or for the cost of, that party's defense has also been assumed in the same "insured contract"; and (II) Such attorneys' fees and litigation expenses are for defense of that party against a civil or alternative dispute resolution proceeding in which damages to which this insurance applies are alleged. c. Liquor Liability "Bodily injury" or "property damage" for which any insured may be held liable by reason of: (1) Causing or contributing to the intoxication of any person; (2) The furnishing of alcoholic beverages to a person under the legal drinking age or under the influence of alcohol; (3) Providing or failing to provide transportation with respect to any person that may be under the influence of alcohol; or (4) Any statute, ordinance or regulation relating to the sale, gift, distribution or use of alcoholic beverages. This exclusion applies even if the claims allege negligence or other wrongdoing in the supervision, hiring, employment, training or monitoring of others by an insured, if the "bodily injury" or "property damage" involved that which is described in Paragraph (1), (2), (3) or (4) above. However, this exclusion applies only if you are in the business of manufacturing, distributing, selling, serving or furnishing alcoholic beverages. For the purposes of this exclusion, permitting a person to bring alcoholic beverages on your premises, for consumption on your premises, whether or not a fee is charged or a license is required for such activity, is not by itself considered the business of selling, serving, or furnishing alcoholic beverages. d. Workers' Compensation And Similar Laws Any obligation of the insured under a workers' compensation, disability benefits or unemployment compensation law or any similar law. e. Employer's Liability "Bodily injury" to: (1) An "employee" of the insured arising out of and in the course of: (a) Employment by the insured; or (b) Performing duties related to the conduct of the insured's business; or (2) The spouse, child, parent, brother or sister of that "employee" as a consequence of (1) above. This exclusion applies: (1) Whether the insured may be liable as an employer or in any other capacity; and (2) To any obligation to share damages with or repay someone else who st pay damages because of the injury. Form SL 00 00 10 18 Page 4 of 22 © 2018, The Hartford (May include copyrighted material of Insurance Services Office, Inc., with its permission) THE -A HARTFORD This exclusion does not apply to liability assumed by the insured under an "insured contract". f. Pollution (1) "Bodily injury", "property damage" or "personal and advertising injury" arising out of the actual, alleged or threatened discharge, dispersal, seepage, migration, release or escape of "pollutants": (a) At or from any premises, site or location which is or was at any time owned or occupied by, or rented or loaned to any insured. However, this paragraph does not apply to: (i) "Bodily injury" if sustained within a building and caused by smoke, fumes, vapor or soot produced by or originating from equipment that is used to heat, cool or dehumidify the building, or equipment that is used to heat water for personal use, by the building's occupants or their guests; (ii) "Bodily injury" or "property damage" for which you may be held liable, if you are a contractor and the owner or lessee of such premises, site or location has been added to this Coverage Part as an additional insured with respect to your ongoing operations performed for that additional insured at that premises, site or location and such premises, site or location is not and never was owned or occupied by, or rented or loaned to, any insured, other than that additional insured; or (III) "Bodily injury" or "property damage" arising out of heat, smoke or fumes from a "hostile fire"; (b) At or from any premises, site or location which is or was at any time used by or for any insured or others for the handling, storage, disposal, processing or treatment of waste; (c) Which are or were at any time transported, handled, stored, treated, disposed of, or processed as waste by or for: (1) Any insured; or (ii) Any person or organization for whom you may be legally responsible; (d) At or from any premises, site or location on which any insured or any contractors or subcontractors working directly or indirectly on any insured's behalf are performing operations if the "pollutants" are brought on or to the premises, site or location in connection with such operations by such insured, contractor or subcontractor. However, this paragraph does not apply to: (i) "Bodily injury" or "property damage" arising out of the escape of fuels, lubricants or other operating fluids which are needed to perform the normal electrical, hydraulic or mechanical functions necessary for the operation of "mobile equipment" or its parts, if such fuels, lubricants or other operating fluids escape from a vehicle part designed to hold, store or receive them. This exception does not apply if the "bodily injury" or "property damage" arises out of the intentional discharge, dispersal or release of the fuels, lubricants or other operating fluids, or if such fuels, lubricants or other operating fluids are brought on or to the premises, site or location with the intent that they be discharged, dispersed or released as part of the operations being performed by such insured, contractor or subcontractor; (ii) "Bodily injury" or "property damage" sustained within a building and caused by the release of gases, fumes or vapors from materials brought into that building in connection with operations being performed by you or on your behalf by a contractor or subcontractor; or (III) "Bodily injury" or "property damage" arising out of heat, smoke or fumes from a "hostile fire"; or (e) At or from any premises, site or location on which any insured or any contractors or subcontractors working directly or indirectly on any insured's behalf are performing operations if the operations are to test for, monitor, clean up, remove, contain, treat, detoxify or neutralize, or in any way respond to, or assess the effects of, "pollutants". (2) Any loss, cost or expense arising out of any: (a) Request, demand, order or statutory or regulatory requirement that any insured or others test for, monitor, clean up, remove, contain, treat, detoxify or neutralize, or in any way respond to, or assess the effects of, "pollutants"; or (b) Claim or "suit" by or on behalf of a governmental authority for damages because of testing for, monitoring, cleaning up, removing, containing, treating, detoxifying or neutralizing, or in any way responding to, or assessing the effects of, "pollutants". Form SL 00 00 10 18 Page 5 of 22 © 2018, The Hartford (May include copyrighted material of Insurance Services Office, Inc., with its permission) THE HARTFORD However, this paragraph does not apply to liability for damages because of "property damage" that the insured would have in the absence of such request, demand, order or statutory or regulatory requirement, or such claim or "suit" by or on behalf of a governmental authority. g. Aircraft, Auto Or Watercraft (1) Unmanned Aircraft "Bodily injury" or "property damage" arising out of the ownership, maintenance, use or entrustment to others of any aircraft that is an "unmanned aircraft'. Use includes operation and "loading or unloading". This Exclusion g.(1) applies even if the claims against any insured allege negligence or other wrongdoing in the supervision, hiring, employment, training or monitoring of others by that insured, if the "bodily injury" or "property damage" arises out of the ownership, maintenance, use or entrustment to others of any aircraft that is an "unmanned aircraft". (2) Aircraft (Other Than Unmanned Aircraft), Auto or Watercraft "Bodily injury" or "property damage" arising out of the ownership, maintenance, use or entrustment to others of any aircraft (other than "unmanned aircraft"), "auto" or watercraft owned or operated by or rented or loaned to any insured. Use includes operation and "loading or unloading". This Exclusion g.(2) applies even if the claims against any insured allege negligence or other wrongdoing in the supervision, hiring, employment, training or monitoring of others by that insured, if the "bodily injury" or "property damage" arises out of the ownership, maintenance, use or entrustment to others of any aircraft (other than "unmanned aircraft'), "auto" or watercraft that is owned or operated by or rented or loaned to any insured. This Exclusion g.(2) does not apply to: (a) A watercraft while ashore on premises you own or rent; (b) A watercraft you do not own that is: (1) Less than 51 feet long; and (ii) Not being used to carry persons or property for a charge; (c) Parking an "auto" on, or on the ways next to, premises you own or rent, provided the "auto" is not owned by or rented or loaned to you or the insured; (d) Liability assumed under any "insured contract' for the ownership, maintenance or use of aircraft (other than "unmanned aircraft') or watercraft; (e) "Bodily injury" or "property damage" arising out of: (i) The operation of any of the machinery or equipment listed in Paragraph f.(2) or f.(3) of the definition of "mobile equipment'; or (ii) The operation of machinery or equipment that is attached to, or part of, a land vehicle that would qualify under the definition of "mobile equipment' if it were not subject to aropulsory or financial responsibility law or other motor vehicle insurance or motor vehicle registration law where it is licensed or principally garaged; or (f) An aircraft (other than "unmanned aircraft') that is not owned by any insured and is hired, chartered or loaned with a paid crew. However, this exception does not apply if the insured has any other insurance for such "bodily injury" or "property damage", whether the other insurance is primary, excess, contingent or on any other basis. h. Mobile Equipment "Bodily injury" or "property damage" arising out of: (1) The transportation of "mobile equipment' by an "auto" owned or operated by or rented or loaned to any insured; or (2) The use of "mobile equipment' in, or while in practice or preparation for, a prearranged racing, speed or demolition contest or in any stunting activity. Form SL 00 00 10 18 Page 6 of 22 © 2018, The Hartford (May include copyrighted material of Insurance Services Office, Inc., with its permission) THE HARTFORD i. War "Bodily injury", "property damage" or "personal and advertising injury", however caused, arising, directly or indirectly, out of: (1) War, including undeclared or civil war; (2) Warlike action by a military force, including action in hindering or defending against an actual or expected attack, by any government, sovereign or other authority using military personnel or other agents; or (3) Insurrection, rebellion, revolution, usurped power, or action taken by governmental authority in hindering or defending against any of these. j. Professional Services "Bodily injury", "property damage" or "personal and advertising injury" arising out of the rendering of or failure to render any professional service. This includes but is not limited to: (1) Legal, accounting or advertising services; (2) Preparing, approving, or failing to prepare or approve maps, shop drawings, opinions, reports, surveys, field orders, change orders, designs or drawings and specifications; (3) Supervisory, inspection, architectural or engineering activities; (4) Medical, surgical, dental, x-ray or nursing services, treatment, advice or instruction; (5) Any health or therapeutic service treatment, advice or instruction; (6) Any service, treatment, advice or instruction for the purpose of appearance or skin enhancement, hair removal or replacement or personal grooming; (7) Optical or hearing aid services including the prescribing, preparation, fitting, demonstration or distribution of ophthalmic lenses and similar products or hearing aid devices; (8) Optometry or optometric services including but not limited to examination of the eyes and the prescribing, preparation, fitting, demonstration or distribution of ophthalmic lenses and similar products; (9) Any: (a) Body piercing (not including ear piercing); (b) Tattooing, including but not limited to the insertion of pigments into or under the skin; and (c) Similar services; (10)Pharmaceutical services including but not limited to: (a) The administering, prescribing, preparing, distributing or compounding of pharmaceutical drugs, vaccinations, immunizations or any of their component parts; (b) The providing of or failure to provide home health care or home infusion products or services; and (c) Advising and consulting customers; (11)Computer consulting, design or programming services, including web site design. This exclusion applies even if the claims allege negligence or other wrongdoing in the supervision, hiring, employment, training or monitoring of others by an insured, if the "bodily injury", "property damage", or "personal and advertising injury" arises out of the rendering of or the failure to render any professional service. Paragraphs (4) and (5) of this exclusion do not apply to the Incidental Medical Malpractice coverage afforded under Paragraph 1.e. in Section A. Coverages. k. Damage To Property "Property damage" to: (1) Property you own, rent or occupy, including any costs or expenses incurred by you, or any other person, organization or entity, for repair, replacement, enhancement, restoration or maintenance of such property for any reason, including prevention of injury to a person or damage to another's property; (2) Premises you sell, give away or abandon, if the "property damage" arises out of any part of those premises; Form SL 00 00 10 18 Page 7 of 22 © 2018, The Hartford (May include copyrighted material of Insurance Services Office, Inc., with its permission) THE HARTFORD (3) Property loaned to you; (4) Personal property in the care, custody or control of the insured; (5) That particular part of real property on which you or any contractors or subcontractors working directly or indirectly on your behalf are performing operations, if the "property damage" arises out of those operations; or (6) That particular part of any property that must be restored, repaired or replaced because "your work" was incorrectly performed on it. Paragraphs (1), (3) and (4) of this exclusion do not apply to "property damage" (other than damage by fire) to premises, including the contents of such premises, rented to you for a period of 7 or fewer consecutive days. A separate limit of insurance applies to Damage To Premises Rented To You as described in Section D. Limits Of Insurance. Paragraph (2) of this exclusion does not apply if the premises are "your work" and were never occupied, rented or held for rental by you. Paragraphs (3) and (4) of this exclusion do not apply to the use of elevators. Paragraphs (3), (4), (5) and (6) of this exclusion do not apply to liability assumed under a sidetrack agreement. Paragraphs (3) and (4) of this exclusion do not apply to "property damage" to borrowed equipment while not being used to perform operations at a job site. Paragraph (6) of this exclusion does not apply to "property damage" included in the "products -completed operations hazard". I. Damage To Your Product "Property damage" to "your product' arising out of it or any part of it. m. Damage To Your Work "Property damage" to "your work" arising out of it or any part of it and included in the "products -completed operations hazard". This exclusion does not apply if the damaged work or the work out of which the damage arises was performed on your behalf by a subcontractor. n. Damage To Impaired Property Or Property Not Physically Injured "Property damage" to "impaired property" or property that has not been physically injured, arising out of: (1) A defect, deficiency, inadequacy or dangerous condition in "your product' or "your work"; or (2) A delay or failure by you or anyone acting on your behalf to perform a contract or agreement in accordance with its terms. This exclusion does not apply to the loss of use of other property arising out of sudden and accidental physical injury to "your product' or "your work" after it has been put to its intended use. o. Recall Of Products, Work Or Impaired Property Damages claimed for any loss, cost or expense incurred by you or others for the loss of use, withdrawal, recall, inspection, repair, replacement, adjustment, removal or disposal of: (1) "Your product'; (2) "Your work"; or (3) "Impaired property"; if such product, work or property is withdrawn or recalled from the market or from use by any person or organization because of a known or suspected defect, deficiency, inadequacy or dangerous condition in it. p. Personal And Advertising Injury "Personal and advertising injury": (1) Arising out of oral, written, electronic, or any other manner of publication of material, if done by or at the direction of the insured with knowledge of its falsity; Form SL 00 00 10 18 Page 8 of 22 © 2018, The Hartford (May include copyrighted material of Insurance Services Office, Inc., with its permission) THE HARTFORD (2) Arising out of oral, written, electronic, or any other manner of publication of material whose first publication took place before the beginning of the policy period; (3) Arising out of a criminal act committed by or at the direction of the insured; (4) Arising out of any breach of contract, except an implied contract to use another's "advertising idea" in your "advertisement"; (5) Arising out of the failure of goods, products or services to conform with any statement of quality or performance made in your "advertisement"; (6) Arising out of the wrong description of the price of goods, products or services; (7) Arising out of: (a) Any actual or alleged infringement or violation of any intellectual property rights, such as copyright, patent, right of publicity, trademark, trade dress, trade name, trade secret, service mark or other designation of origin or authenticity; or (b) Any injury or damage alleged in any claim or "suit" that also alleges an infringement or violation of any intellectual property right, whether such allegation of infringement or violation is made against you, or by you or by any other party involved in the claim or "suit", regardless of whether this insurance would otherwise apply. However, this exclusion does not apply if the only allegation in the claim or "suit" involving any intellectual property right is limited to: (i) Infringement, in your "advertisement", of: a. Copyright; b. Slogan; unless the slogan is also arademark, trade dress, trade name, service mark or other designation of origin or authenticity; or c. Title of any literary or artistic work; or (ii) Copying, in your "advertisement", a person's or organization's "advertising idea" or style of "advertisement". Paragraph (7)(b)ii above shall not apply to claims or "suits" alleging infringement or violation of trademark, trade dress, trade name, service mark or other designation of origin or authenticity. (8) Arising out of an offense committed by an insured whose business is: (a) Advertising, broadcasting, publishing or telecasting; (b) Designing or determining content of web sites for others; or (c) An Internet search, access, content or service provider. However, this exclusion does not apply to Paragraphs a., b. and c. under the definition of "personal and advertising injury" in Section F. Liability And Medical Expenses Definitions. For the purposes of this exclusion, the placing of frames, borders, or links, or advertising, for you or others anywhere on the Internet, is not by itself, considered the business of advertising, broadcasting, publishing or telecasting; (9) Arising out of an electronic chat room or bulletin board the insured hosts, owns, or over which the insured exercises control; (10)Arising out of the unauthorized use of another's name or product in your e-mail address, domain name or metatags, or any other similar tactics to mislead another's potential customers; (11)Arising out of the violation of a person's right of privacy created by any state or federal act. However, this exclusion does not apply to liability for damages that the insured would have in the absence of such state or federal act; (12)Arising out of: (a) Advertising content for others on your web site; (b) Placing a link to a web site of others on your web site; Form SL 00 00 10 18 Page 9 of 22 © 2018, The Hartford (May include copyrighted material of Insurance Services Office, Inc., with its permission) THE HARTFORD (c) Content from a web site of others displayed within a frame or border on your web site. Content includes information, code, sounds, text, graphics or images; or (d) Computer code, software or programming used to enable: (i) Your web site; or (ii) The presentation or functionality of an "advertisement" or other content on your web site; (13)Arising out of a violation of any anti-trust law; (14)Arising out of the fluctuation in price or value of any stocks, bonds or other securities; (15)Arising out of any access to or disclosure of any person's or organization's confidential or personal information, including patents, trade secrets, processing methods, customer lists, financial information, credit card information, health information or any other type of nonpublic information. This exclusion applies even if damages are claimed for notification costs, credit monitoring expenses, forensic expenses, public relations expenses or any other loss, cost or expense incurred by you or others arising out of any access to or disclosure of any person's or organization's confidential or personal information; or (16)Arising out of the ownership, maintenance, use or entrustment to others of any aircraft that is an "unmanned aircraft". Use includes operation and "loading or unloading". This exclusion applies even if the claims against any insured allege negligence or other wrongdoing in the supervision, hiring, employment, training or monitoring of others by that insured, if the "personal and advertising injury" arises out of the ownership, maintenance, use or entrustment to others of any aircraft that is an "unmanned aircraft". However, this exclusion does not apply if the only allegation in the claim or "suit" involves an intellectual property right which is limited to: (a) Infringement, in your "advertisement", of: (i) Copyright; (ii) Slogan; or (iii) Title of any literary or artistic work; or (b) Copying, in your "advertisement", a person's or organization's "advertising idea" or style of "advertisement". q. Access Or Disclosure Of Confidential Or Personal Information And Data -Related Liability (1) Damages because of "bodily injury" or "property damage" arising out of any access to or disclosure of any person's or organization's confidential or personal information, including patents, trade secrets, processing methods, customer lists, financial information, credit card information, health information or any other type of nonpublic information; or (2) Damages arising out of the loss of, loss of use of, damage to, corruption of, inability to access, or inability to manipulate "electronic data". This exclusion applies even if such damages are claimed for notification costs, credit monitoring expenses, forensic expenses, public relations expenses or any other loss, cost or expense incurred by you or others arising out of that which is described in Paragraphs (1) or (2) above. However, unless Paragraph (1) above applies, this exclusion does not apply to damages because of "bodily injury". r. Employment -Related Practices "Bodily injury" or "personal and advertising injury" to: (1) A person arising out of any: (a) Refusal to employ that person; (b) Termination of that person's employment; or Form SL 00 00 10 18 Page 10 of 22 © 2018, The Hartford (May include copyrighted material of Insurance Services Office, Inc., with its permission) THE HARTFORD (c) Employment -related practices, policies, acts or omissions, such as coercion, demotion, evaluation, reassignment, discipline, defamation, harassment, humiliation, discrimination, malicious prosecution or false arrest directed at that person; or (2) The spouse, child, parent, brother or sister of that person as a consequence of "bodily injury" or "personal and advertising injury" to that person at whom any of the employment -related practices described in Paragraphs (a), (b), or (c) above is directed. This exclusion applies: (1) Whether the injury -causing event described in Paragraphs (a), (b), or (c) above occurs before employment, during employment or after employment of that person; (2) Whether the insured may be liable as an employer or in any other capacity; and (3) To any obligation to share damages with or repay someone else who must pay damages because of the injury. s. Asbestos (1) "Bodily injury", "property damage" or "personal and advertising injury" arising out of the "asbestos hazard". (2) Any damages, judgments, settlements, loss, costs or expenses that: (a) May be awarded or incurred by reason of any claim or "suit' alleging actual or threatened injury or damage of any nature or kind to persons or property which would not have occurred in whole or in part but for the "asbestos hazard"; (b) Arise out of any request, demand, order or statutory or regulatory requirement that any insured or others test for, monitor, clean up, remove, encapsulate, contain, treat, detoxify or neutralize or in any way respond to or assess the effects of an "asbestos hazard"; or (c) Arise out of any claim or "suit' for damages because of testing for, monitoring, cleaning up, removing, encapsulating, containing, treating, detoxifying or neutralizing or in any way responding to or assessing the effects of an "asbestos hazard". t. Recording And Distribution Of Material Or Information In Violation Of Law "Bodily injury", "property damage", or "personal and advertising injury" arising directly or indirectly out of any action or omission that violates or is alleged to violate: (1) The Telephone Consumer Protection Act (TCPA), including any amendment of or addition to such law; (2) The CAN-SPAM Act of 2003, including any amendment of or addition to such law; (3) The Fair Credit Reporting Act (FCRA), and any amendment of or addition to such law, including the Fair and Accurate Credit Transaction Act (FACTA); or (4) Any federal, state or local statute, ordinance or regulation, other than the TCPA, CAN-SPAM Act of 2003 or FCRA and their amendments and additions, that addresses, prohibits or limits the printing, dissemination, disposal, collecting, recording, sending, transmitting, communicating or distribution of material or information. Damage To Premises Rented To You — Exception For Damage By Fire, Lightning Or Explosion Exclusions c. through h. and k. through o. do not apply to damage by fire, lightning or explosion to premises rented to you or temporarily occupied by you with permission of the owner. A separate limit of insurance applies to this coverage as described in Section D. Liability And Medical Expenses Limits Of Insurance. 2. Applicable To Medical Expenses Coverage We will not pay expenses for "bodily injury": a. Any Insured To any insured, except "volunteer workers". b. Hired Person To a person hired to do work for or on behalf of any insured or a tenant of any insured. Form SL 00 00 10 18 Page 11 of 22 © 2018, The Hartford (May include copyrighted material of Insurance Services Office, Inc., with its permission) THE HARTFORD c. Injury On Normally Occupied Premises To a person injured on that part of premises you own or rent that the person normally occupies. d. Workers' Compensation And Similar Laws To a person, whether or not an "employee" of any insured, if benefits for the "bodily injury" are payable or must be provided under a workers' compensation or disability benefits law or a similar law. e. Athletics Activities To a person injured while practicing, instructing or participating in any physical exercises or games, sports or athletic contests. f. Products -Completed Operations Hazard Included with the "products -completed operations hazard". g. Business Liability Exclusions Excluded under Business Liability Coverage. C. WHO IS AN INSURED 1. If you are designated in the Declarations as: a. An individual, you and your spouse are insureds, but only with respect to the conduct of a business, other than that described in b. through e. below, of which you are the sole owner. b. A partnership or joint venture, you are an insured. Your members, your partners, and their spouses are also insureds, but only with respect to the conduct of your business. c. A limited liability company, you are an insured. Your members are also insureds, but only with respect to the conduct of your business. Your managers are insureds, but only with respect to their duties as your managers. d. An organization other than a partnership, joint venture or limited liability company, you are an insured. Your "executive officers" and directors are insureds, but only with respect to their duties as your officers or directors. Your stockholders are also insureds, but only with respect to their liability as stockholders. e. A trust, you are an insured. Your trustees are also insureds, but only with respect to their duties as trustees. 2. Each of the following is also an insured: a. Employees And Volunteer Workers Your "volunteer workers" only while performing duties related to the conduct of your business, or your "employees", other than either your "executive officers" (if you are an organization other than a partnership, joint venture or limited liability company) or your managers (if you are a limited liability company), but only for acts within the scope of their employment by you or while performing duties related to the conduct of your business. However, none of these "employees" or "volunteer workers" are insureds for: (1) "Bodily injury" or "personal and advertising injury": (a) To you, to your partners or members (if you are a partnership or joint venture), to your members (if you are a limited liability company), or to a co -"employee" while in the course of his or her employment or performing duties related to the conduct of your business, or to your other "volunteer workers" while performing duties related to the conduct of your business; (b) To the spouse, child, parent, brother or sister of that co -"employee" or that "volunteer worker" as a consequence of Paragraph (1)(a) above; (c) For which there is any obligation to share damages with or repay someone else who must pay damages because of the injury described in Paragraphs (1)(a) or (b) above; or (d) Arising out of his or her providing or failing to provide professional health care services. If you are not in the business of providing professional health care services, Paragraph (d) does not apply to any nurse, emergency medical technician or paramedic employed by you to provide such services. (2) "Property damage" to property: Form SL 00 00 10 18 Page 12 of 22 © 2018, The Hartford (May include copyrighted material of Insurance Services Office, Inc., with its permission) THE HARTFORD (a) Owned, occupied or used by: (b) Rented to, in the care, custody or control of, or over which physical control is being exercised for any purpose by you, any of your "employees", "volunteer workers", any partner or member (if you are a partnership or joint venture), or any member (if you are a limited liability company). b. Real Estate Manager Any person (other than your "employee" or "volunteer worker"), or any organization while acting as your real estate manager. c. Temporary Custodians Of Your Property Any person or organization having proper temporary custody of your property if you die, but only: (1) With respect to liability arising out of the maintenance or use of that property; and (2) Until your legal representative has been appointed. d. Legal Representative If You Die Your legal representative if you die, but only with respect to duties as such. That representative will have all your rights and duties under this insurance. e. Unnamed Subsidiary Any subsidiary and subsidiary thereof, of yours which is a legally incorporated entity of which you own a financial interest of more than 50% of the voting stock on the effective date of this Coverage Part. The insurance afforded herein for any subsidiary not shown in the Declarations as a named insured does not apply to injury or damage with respect to which an insured under this insurance is also an insured under another policy or would be an insured under such policy but for its termination or upon the exhaustion of its limits of insurance. 3. Newly Acquired Or Formed Organization Any organization you newly acquire or form, other than a partnership, joint venture or limited liability company, and over which you maintain financial interest of more than 50% of the voting stock, will qualify as a Named Insured if there is no other similar insurance available to that organization. However: a. Coverage under this provision is afforded only until the 180th day after you acquire or form the organization or the end of the policy period, whichever is earlier; and b. Coverage under this provision does not apply to: (1) "Bodily injury" or "property damage" that occurred; or (2) "Personal and advertising injury" arising out of an offense committed before you acquired or formed the organization. 4. Operator Of Mobile Equipment With respect to "mobile equipment" any person is an insured while driving such equipment along a public highway with your permission. Any other person or organization responsible for the conduct of such person is also an insured, but only with respect to liability arising out of the operation of the equipment, and only if no other insurance of any kind is available to that person or organization for this liability. However, no person or organization is an insured with respect to: a. "Bodily injury" to a co -"employee" of the person driving the equipment; or b. "Property damage" to property owned by, rented to, in the charge of or occupied by you or the employer of any person who is an insured under this provision. 5. Operator Of Nonowned Watercraft With respect to watercraft you do not own that is less than 51 feet long and is not being used to carry persons or property for a charge, any person is an insured while operating such watercraft with your permission. Any other person or organization responsible for the conduct of such person is also an insured, but only with respect to liability arising out of the operation of the watercraft, and only if no other insurance of any kind is available to that person or organization for this liability. However, no person or organization is an insured with respect to: Form SL 00 00 10 18 Page 13 of 22 © 2018, The Hartford (May include copyrighted material of Insurance Services Office, Inc., with its permission) THE HARTFORD a. "Bodily injury" to a co -"employee" of the person operating the watercraft; or b. "Property damage" to property owned by, rented to, in the charge of or occupied by you or the employer of any person who is an insured under this provision. No person or organization is an insured with respect to the conduct of any current or past partnership, joint venture or limited liability company that is not shown as a Named Insured in the Declarations. D. LIABILITY AND MEDICAL EXPENSES LIMITS OF INSURANCE 1. The Most We Will Pay The Limits of Insurance shown in the Declarations and the rules below fix the most we will pay regardless of the number of: a. Insureds; b. Claims made or "suits" brought; or c. Persons or organizations making claims or bringing "suits". 2. Aggregate Limits The most we will pay for: a. Damages because of "bodily injury" and "property damage" included in the "products -completed operations hazard" is the Products -Completed Operations Aggregate Limit shown in the Declarations. b. Damages because of all other "bodily injury", "property damage" or "personal and advertising injury", including medical expenses, is the General Aggregate Limit shown in the Declarations. This General Aggregate limit does not apply to "property damage" to premises while rented to you or temporarily occupied by you with permission of the owner, arising out of fire, lightning or explosion. 3. Each Occurrence Limit Subject to 2.a. or 2.b above, whichever applies, the most we will pay for the sum of all damages because of all "bodily injury", "property damage" and medical expenses arising out of any one 'occurrence" is the Liability and Medical Expenses Limit shown in the Declarations. The most we will pay for all medical expenses because of "bodily injury" sustained by any one person is the Medical Expenses Limit shown in the Declarations. 4. Personal And Advertising Injury Limit Subject to 2.b. above, the most we will pay for the sum of all damages because of all "personal and advertising injury" sustained by any one person or organization is the Personal and Advertising Injury Limit shown in the Declarations. 5. Damage To Premises Rented To You Limit The Damage To Premises Rented To You Limit is the most we will pay under Business Liability Coverage for damages because of "property damage" to any one premises, while rented to you, or in the case of damage by fire, lightning or explosion, while rented to you or temporarily occupied by you with permission of the owner. In the case of damage by fire, lightning or explosion, the Damage to Premises Rented To You Limit applies to all damage proximately caused by the same event, whether such damage results from fire, lightning or explosion or any combination of these. 6. How Limits Apply To Additional Insureds The most we will pay on behalf of a person or organization who is an additional insured under this Coverage Part is the lesser of: a. The limits of insurance required in a written contract, written agreement or permit; or b. The Limits of Insurance shown in the Declarations. Such amount shall be a part of and not in addition to the Limits of Insurance shown in the Declarations and described in this Section. If more than one limit of insurance under this Policy and any endorsements attached thereto applies to any claim or "suit", the most we will pay under this Policy and the endorsements is the single highest limit of liability of all Form SL 00 00 10 18 Page 14 of 22 © 2018, The Hartford (May include copyrighted material of Insurance Services Office, Inc., with its permission) THE HARTFORD coverages applicable to such claim or "suit". However, this paragraph does not apply to the Medical Expenses limit set forth in Paragraph 3. above. The Limits of Insurance of this Coverage Part apply separately to each consecutive annual period and to any remaining period of less than 12 months, starting with the beginning of the policy period shown in the Declarations, unless the policy period is extended after issuance for an additional period of less than 12 months. In that case, the additional period will be deemed part of the last preceding period for purposes of determining the Limits of Insurance. E. LIABILITY AND MEDICAL EXPENSES GENERAL CONDITIONS 1. Bankruptcy Bankruptcy or insolvency of the insured or of the insured's estate will not relieve us of our obligations under this Coverage Part. 2. Duties In The Event Of Occurrence, Offense, Claim Or Suit a. Notice Of Occurrence Or Offense You or any additional insured under this Coverage Part must see to it that we are notified as soon as practicable of an "occurrence" or an offense which may result in a claim. To the extent possible, notice should include: (1) How, when and where the "occurrence" or offense took place; (2) The names and addresses of any injured persons and witnesses; and (3) The nature and location of any injury or damage arising out of the "occurrence" or offense. b. Notice Of Claim If a claim is made or "suit" is brought against any insured, you or any additional insured under this Coverage Part must: (1) Immediately record the specifics of the claim or "suit" and the date received; and (2) Notify us as soon as practicable. You or any additional insured under this Coverage Part must see to it that we receive a written notice of the claim or "suit" as soon as practicable. c. Assistance And Cooperation Of The Insured You and any other involved insured must: (1) Immediately send us copies of any demands, notices, summonses or legal papers received in connection with the claim or "suit"; (2) Authorize us to obtain records and other information; (3) Cooperate with us in the investigation, settlement of the claim or defense against the "suit"; and (4) Assist us, upon our request, in the enforcement of any right against any person or organization that may be liable to the insured because of injury or damage to which this insurance may also apply. d. Obligations At The Insured's Own Cost No insured will, except at that insured's own cost, voluntarily make a payment, assume any obligation, or incur any expense, other than for first aid, without our consent. e. Additional Insured's Other Insurance If we cover a claim or "suit" under this Coverage Part that may also be covered by other insurance available to an additional insured under this Coverage Part, such additional insured must submit such claim or "suit" to the other insurer for defense and indemnity. However, this provision does not apply to the extent that you have agreed in a written contract, written agreement or permit that this insurance is primary and non-contributory with such additional insured's own insurance. f. Knowledge Of An Occurrence, Offense, Claim Or Suit Paragraphs a. and b. apply to you or to any additional insured under this Coverage Part only when such "occurrence", offense, claim or "suit" is known to: Form SL 00 00 10 18 Page 15 of 22 © 2018, The Hartford (May include copyrighted material of Insurance Services Office, Inc., with its permission) THE HARTFORD (1) You or any additional insured under this Coverage Part that is an individual; (2) Any partner, if you or an additional insured under this Coverage Part is a partnership; (3) Any manager, if you or an additional insured under this Coverage Part is a limited liability company; (4) Any "executive officer" or insurance manager, if you or an additional insured under this Coverage Part is a corporation; (5) Any trustee, if you or an additional insured under this Coverage Part is a trust; or (6) Any elected or appointed official, if you or an additional insured under this Coverage Part is a political subdivision or public entity. This Paragraph f. applies separately to you and any additional insured under this Coverage Part. 3. Legal action Against Us No person or organization has a right under this Coverage Part: a. To join us as a party or otherwise bring us into a "suit" asking for damages from an insured; or b. To sue us on this Coverage Part unless all of its terms have been fully complied with. A person or organization may sue us to recover on an agreed settlement or on a final judgment against an insured; but we will not be liable for damages that are not payable under the terms of this insurance or that are in excess of the applicable limit of insurance. An agreed settlement means a settlement and release of liability signed by us, the insured and the claimant or the claimant's legal representative. 4. Separation Of Insureds Except with respect to the Limits of Insurance, and any rights or duties specifically assigned in this Policy to the first Named Insured, this insurance applies: a. As if each Named Insured were the only Named Insured; and b. Separately to each insured against whom a claim is made or "suit" is brought. 5. Representations a. When You Accept This Policy By accepting this Policy, you agree: (1) The statements in the Declarations are accurate and complete; (2) Those statements are based upon representations you made to us; and (3) We have issued this Policy in reliance upon your representations. b. Unintentional Failure To Disclose Hazards If unintentionally you should fail to disclose all hazards relating to the conduct of your business at the inception date of this Coverage Part, we shall not deny any coverage under this Coverage Part because of such failure. 6. Other Insurance If other valid and collectible insurance is available for a loss we cover under this Coverage Part, our obligations are limited as follows: a. Primary Insurance This insurance is primary except when b. below applies. If other insurance is also primary, we will share with all that other insurance by the method described in c. below. b. Excess Insurance This insurance is excess over any of the other insurance, whether primary, excess, contingent or on any other basis: (1) Your Work That is Fire, Extended Coverage, Builder's Risk, Installation Risk, Owner Controlled Insurance Program or OCIP, Contractor Controlled Insurance Program or CCIP, Wrap Up Insurance or similar coverage for "your work"; Form SL 00 00 10 18 Page 16 of 22 © 2018, The Hartford (May include copyrighted material of Insurance Services Office, Inc., with its permission) THE HARTFORD (2) Premises Rented To You That is fire, lightning or explosion insurance for premises rented to you or temporarily occupied by you with permission of the owner; (3) Tenant Liability That is insurance purchased by you to cover your liability as a tenant for "property damage" to premises rented to you or temporarily occupied by you with permission of the owner; (4) Aircraft, Auto Or Watercraft If the loss arises out of the maintenance or use of aircraft, "autos" or watercraft to the extent not subject to Exclusion g. of Section B. Exclusions. (5) Property Damage To Borrowed Equipment Or Use Of Elevators If the loss arises out of "property damage" to borrowed equipment or the use of elevators to the extent not subject to Exclusion k. of Section B. Exclusions. (6) When You Are Added As An Additional Insured To Other Insurance That is other insurance available to you covering liability for damages arising out of the premises or operations, or products and completed operations, for which you have been added as an additional insured by that insurance; or (7) When You Add Others As An Additional Insured To This Insurance That is other insurance available to an additional insured. However, the following provisions apply to other insurance available to any person or organization who is an additional insured under this Coverage Part: (a) Primary Insurance When Required By Contract This insurance is primary if you have agreed in a written contract, written agreement or permit that this insurance be primary. If other insurance is also primary, we will share with all that other insurance by the method described in c. below. (b) Primary And Non -Contributory To Other Insurance When Required By Contract If you have agreed in a written contract, written agreement or permit that this insurance is primary and non-contributory with the additional insured's own insurance, this insurance is primary and we will not seek contribution from that other insurance. Paragraphs (a) and (b) do not apply to other insurance to which the additional insured has been added as an additional insured. When this insurance is excess, we will have no duty under this Coverage Part to defend the insured against any "suit" if any other insurer has a duty to defend the insured against that "suit". If no other insurer defends, we will undertake to do so, but we will be entitled to the insured's rights against all those other insurers. When this insurance is excess over other insurance, we will pay only our share of the amount of the loss, if any, that exceeds the sum of: (1) The total amount that all such other insurance would pay for the loss in the absence of this insurance; and (2) The total of all deductible and self -insured amounts under all that other insurance. We will share the remaining loss, if any, with any other insurance that is not described in this Excess Insurance provision and was not bought specifically to apply in excess of the Limits of Insurance shown in the Declarations of this Coverage Part. c. Method Of Sharing If all the other insurance permits contribution by equal shares, we will follow this method also. Under this approach, each insurer contributes equal amounts until it has paid its applicable limit of insurance or none of the loss remains, whichever comes first. Form SL 00 00 10 18 Page 17 of 22 © 2018, The Hartford (May include copyrighted material of Insurance Services Office, Inc., with its permission) THE HARTFORD If any of the other insurance does not permit contribution by equal shares, we will contribute by limits. Under this method, each insurer's share is based on the ratio of its applicable limit of insurance to the total applicable limits of insurance of all insurers. 7. Transfer Of Rights Of Recovery Against Others To Us a. Transfer Of Rights Of Recovery If the insured has rights to recover all or part of any payment, including Supplementary Payments, we have made under this Coverage Part, those rights are transferred to us. The insured st do nothing after loss to impair them. At our request, the insured will bring "suit" or transfer those rights to us and help us enforce them. This condition does not apply to Medical Expenses Coverage. b. Waiver Of Rights Of Recovery (Waiver Of Subrogation) If the insured has waived any rights of recovery against any person or organization for all or part of any payment, including Supplementary Payments, we have made under this Coverage Part, we also waive that right, provided the insured waived their rights of recovery against such person or organization in a contract, agreement or permit that was executed prior to the injury or damage. F. LIABILITY AND MEDICAL EXPENSES DEFINITIONS 1. "Advertisement" means a notice that is broadcast or published to the general public or specific market segments about your goods, products or services for the purpose of attracting customers or supporters. For the purpose of this definition: a. Notices that are published include material placed on the Internet or on similar electronic means of communication; and b. Regarding web sites, only that part of a web site that is about your goods, products or services for the purpose of attracting customers or supporters is considered an advertisement. 2. "Advertising idea" means any idea for an "advertisement". 3. "Asbestos hazard" means an exposure or threat of exposure to the actual or alleged properties of asbestos and includes the mere presence of asbestos in any form. 4. "Auto" means: a. A land for vehicle, trailer or semi -trailer designed for travel on public roads, including any attached machinery or equipment; or b. Any other land vehicle that is subject to a compulsory or financial responsibility law or other motor vehicle insurance or motor vehicle registration law where it is licensed or principally garaged. However, "auto" does not include "mobile equipment". 5. "Bodily injury" means physical: a. Injury; b. Sickness; or c. Disease sustained by a person and, if arising out of the above, mental anguish or death at any time. 6. "Coverage territory" means: a. The United States of America (including its territories and possessions), Puerto Rico and Canada; b. International waters or airspace, but only if the injury or damage occurs in the course of travel or transportation between any places included in a. above; c. All other parts of the world if the injury or damage arises out of: (1) Goods or products made or sold by you in the territory described in a. above; (2) The activities of a person whose home is in the territory described in a. above, but is away for a short time on your business; or Form SL 00 00 10 18 Page 18 of 22 © 2018, The Hartford (May include copyrighted material of Insurance Services Office, Inc., with its permission) THE HARTFORD (3) "Personal and advertising injury" offenses that take place through the Internet or similar electronic means of communication. provided the insured's responsibility to pay damages is determined in the United States of America (including its territories and possessions), Puerto Rico or Canada, in a "suit" on the merits according to the substantive law in such territory, or in a settlement we agree to. 7. "Electronic data" means information, facts or computer programs stored as or on, created or used on, or transmitted to or from computer software (including systems and applications software), on hard or floppy disks, CD-ROMs, tapes, drives, cells, data processing devices or any other repositories of computer software which are used with electronically controlled equipment. The term computer programs, referred to in the foregoing description of "electronic data", means a set of related electronic instructions which direct the operations and functions of a computer or device connected to it, which enable the computer or device to receive, process, store, retrieve or send data. 8. "Employee" includes a "leased worker". "Employee" does not include a "temporary worker". 9. "Executive officer" means a person holding any of the officer positions created by your charter, constitution, by- laws or any other similar governing document. 10. "Hostile fire" means one which becomes uncontrollable or breaks out from where it was intended to be. 11. "Impaired property" means tangible property, other than "your product" or "your work", that cannot be used or is less useful because: a. It incorporates "your product" or "your work" that is known or thought to be defective, deficient, inadequate or dangerous; or b. You have failed to fulfill the terms of a contract or agreement; if such property can be restored to use by: a. The repair, replacement, adjustment or removal of "your product" or "your work"; or b. Your fulfilling the terms of the contractor agreement. 12. "Insured contract" means: a. A contract for a lease of premises. However, that portion of the contract for a lease of premises that indemnifies any person or organization for damage by fire, lightning or explosion to premises while rented to you or temporarily occupied by you with permission of the owner is subject to the Damage To Premises Rented To You limit described in Section D. Liability And Medical Expenses Limits Of Insurance. b. A sidetrack agreement; c. Any easement or license agreement, including an easement or license agreement in connection with construction or demolition operations on or within 50 feet of a railroad; d. Any obligation, as required by ordinance, to indemnify a municipality, except in connection with work for a municipality; e. An elevator maintenance agreement; or f. That part of any other contract or agreement pertaining to your business (including an indemnification of a municipality in connection with work performed for a municipality) under which you assume the tort liability of another party to pay for "bodily injury" or "property damage" to a third person or organization. Tort liability means a liability that would be imposed by law in the absence of any contract or agreement. Paragraph If. includes that part of any contract or agreement that indemnifies a railroad for "bodily injury" or "property damage" arising out of construction or demolition operations within 50 feet of any railroad property and affecting any railroad bridge or trestle, tracks, road -beds, tunnel, underpass or crossing. However, Paragraph f. does not include that part of any contract or agreement: (1) That indemnifies an architect, engineer or surveyor for injury or damage arising out of: (a) Preparing, approving or failing to prepare or approve maps, shop drawings, opinions, reports, surveys, field orders, change orders, designs or drawings and specifications; or (b) Giving directions or instructions, or failing to give them, if that is the primary cause of the injury or damage; or Form SL 00 00 10 18 Page 19 of 22 © 2018, The Hartford (May include copyrighted material of Insurance Services Office, Inc., with its permission) THE HARTFORD (2) Under which the insured, if an architect, engineer or surveyor, assumes liability for an injury or damage arising out of the insured's rendering or failure to render professional services, including those listed in (1) above and supervisory, inspection, architectural or engineering activities. 13. "Leased worker" means a person leased to you by a labor leasing firm under an agreement between you and the labor leasing firm, to perform duties related to the conduct of your business. "Leased worker" does not include a "temporary worker". 14. "Loading or unloading" means the handling of property: a. After it is moved from the place where it is accepted for movement into or onto an aircraft, watercraft or "auto"; b. While it is in or on an aircraft, watercraft or "auto"; or c. While it is being moved from an aircraft, watercraft or "auto" to the place where it is finally delivered; but "loading or unloading" does not include the movement of property by means of a mechanical device, other than a hand truck, that is not attached to the aircraft, watercraft or "auto". 15. "Mobile equipment" means any of the following types of land vehicles, including any attached machinery or equipment: a. Bulldozers, farm machinery, forklifts and other vehicles designed for use principally off public roads; b. Vehicles maintained for use solely on or next to premises you own or rent; c. Vehicles that travel on crawler treads; d. Vehicles, whether self-propelled or not, on which are permanently mounted: (1) Power cranes, shovels, loaders, diggers or drills; or (2) Road construction or resurfacing equipment such as graders, scrapers or rollers; e. Vehicles not described in a., b., c., or d. above that are not self-propelled and are maintained primarily to provide mobility to permanently attached equipment of the following types: (1) Air compressors, pumps and generators, including spraying, welding, building cleaning, geophysical exploration, lighting and well servicing equipment; or (2) Cherry pickers and similar devices used to raise or lower workers; f. Vehicles not described in a., b., c., or d. above maintained primarily for purposes other than the transportation of persons or cargo. However, self-propelled vehicles with the following types of permanently attached equipment are not "mobile equipment" but will be considered "autos": (1) Equipment, of at least 1,000 pounds gross vehicle weight, designed primarily for: (a) Snow removal; (b) Road maintenance, but not construction or resurfacing; or (c) Street cleaning; (2) Cherry pickers and similar devices mounted on automobile or truck chassis and used to raise or lower workers; and (3) Air compressors, pumps and generators, including spraying, welding, building cleaning, geophysical exploration, lighting and well servicing equipment. However, "mobile equipment" does not include any land vehicle that is subject to a compulsory or financial responsibility law or other motor vehicle insurance or motor vehicle registration law where they are licensed or principally garaged. Land vehicles subject to a compulsory or financial responsibility law or other motor vehicle insurance law or motor vehicle registration law are considered "autos". 16. "Occurrence" means an accident, including continuous or repeated exposure to substantially the same general harmful conditions. 17. "Personal and advertising injury" means injury, including consequential "bodily injury", arising out of one or more of the following offenses: Form SL 00 00 10 18 Page 20 of 22 © 2018, The Hartford (May include copyrighted material of Insurance Services Office, Inc., with its permission) THE HARTFORD a. False arrest, detention or imprisonment; b. Malicious prosecution; c. The wrongful eviction from, wrongful entry into, or invasion of the right of private occupancy of a room, dwelling or premises that a person or organization occupies, committed by or on behalf of its owner, landlord or lessor; d. Oral, written, electronic, or any other manner of publication of material that slanders or libels a person or organization or disparages a person's or organization's goods, products or services; e. Oral, written, electronic, or any other manner of publication of material that violates a person's right of privacy; f. Copying, in your "advertisement", a person's or organization's "advertising idea" or style of "advertisement"; or g. Infringement of copyright, slogan, or title of any literary or artistic work, in your "advertisement". 18. "Pollutants" means any solid, liquid, gaseous or thermal irritant or contaminant, including smoke, vapor, soot, fumes, acids, alkalis, chemicals and waste. Waste includes materials to be recycled, reconditioned or reclaimed. 19. "Products -completed operations hazard"; a. Includes all "bodily injury" and "property damage" occurring away from premises you own or rent and arising out of "your product" or "your work" except: (1) Products that are still in your physical possession; or (2) Work that has not yet been completed or abandoned. However, "your work" will be deemed to be completed at the earliest of the following times: (a) When all of the work called for in your contract has been completed. (b) When all of the work to be done at the job site has been completed if your contract calls for work at more than one job site. (c) When that part of the work done at a job site has been put to its intended use by any person or organization other than another contractor or subcontractor working on the same project. Work that may need service, maintenance, correction, repair or replacement, but which is otherwise complete, will be treated as completed. The "bodily injury" or "property damage" must occur away from premises you own or rent, unless your business includes the selling, handling or distribution of "your product" for consumption on premises you own or rent. b. Does not include "bodily injury" or "property damage" arising out of: (1) The transportation of property, unless the injury or damage arises out of a condition in or on a vehicle not owned or operated by you, and that condition was created by the "loading or unloading" of that vehicle by any insured; or (2) The existence of tools, uninstalled equipment or abandoned or unused materials. 20. "Property damage" means: a. Physical injury to tangible property, including all resulting loss of use of that property. All such loss of use shall be deemed to occur at the time of the physical injury that caused it; or b. Loss of use of tangible property that is not physically injured. All such loss of use shall be deemed to occur at the time of "occurrence" that caused it. As used in this definition, "electronic data" is not tangible property. 21. "Suit" means a civil proceeding in which damages because of "bodily injury", "property damage" or "personal and advertising injury" to which this insurance applies are alleged. "Suit" includes: a. An arbitration proceeding in which such damages are claimed and to which the insured st submit or does submit with our consent; or b. Any other alternative dispute resolution proceeding in which such damages are claimed and to which the insured submits with our consent. Form SL 00 00 10 18 Page 21 of 22 © 2018, The Hartford (May include copyrighted material of Insurance Services Office, Inc., with its permission) THE HARTFORD 22. "Temporary worker" means a person who is furnished to you to substitute for a permanent "employee" on leave or to meet seasonal or short-term workload conditions. 23. "Unmanned aircraft" means an aircraft that is not: a. Designed; b. Manufactured; or c. Modified after manufacture; to be controlled directly by a person from within or on the aircraft. 24. "Volunteer worker" means a person who: a. Is not your "employee"; b. Donates his or her work; c. Acts at the direction of and within the scope of duties determined by you; and d. Is not paid a fee, salary or other compensation by you or anyone else for their work performed for you. 25. "Your product': a. Means: (1) Any goods or products, other than real property, manufactured, sold, handled, distributed or disposed of by: (a) You; (b) Others trading under your name; or (c) A person or organization whose business or assets you have acquired; and (2) Containers (other than vehicles), materials, parts or equipment furnished in connection with such goods or products. b. Includes: (1) Warranties or representations made at any time with respect to the fitness, quality, durability, performance or use of "your product'; and (2) The providing of or failure to provide warnings or instructions. c. Does not include vending machines or other property rented to or located for the use of others but not sold. 26. "Your work": a. Means: (1) Work or operations performed by you or on your behalf; and (2) Materials, parts or equipment furnished in connection with such work or operations. b. Includes: (1) Warranties or representations made at any time with respect to the fitness, quality, durability, performance or use of "your work"; and (2) The providing of or failure to provide warnings or instructions. Form SL 00 00 10 18 Page 22 of 22 © 2018, The Hartford (May include copyrighted material of Insurance Services Office, Inc., with its permission) THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. THE HARTFORD BLANKET ADDITIONAL INSURED BY CONTRACT This endorsement modifies insurance provided under the following: BUSINESS LIABILITY COVERAGE FORM Except as otherwise stated in this endorsement, the terms and conditions of the Policy apply. A. The following is added to Section C. WHO IS AN INSURED: Additional Insureds When Required By Written Contract, Written Agreement Or Permit The person(s) or organization(s) identified in Paragraphs a. through f. below are additional insureds when you have agreed, in a written contract or written agreement, or when required by a written permit issued by a state or governmental agency or subdivision or political subdivision that such person or organization be added as an additional insured on your Coverage Part, provided the injury or damage occurs subsequent to the execution of the contract or agreement, or the issuance of the permit. A person or organization is an additional insured under this provision only for that period of time required by the contract, agreement or permit. However, no such person or organization is an additional insured under this provision if such person or organization is included as an additional insured by any other endorsement issued by us and made a part of this Coverage Part. The insurance afforded to such additional insured will not be broader than that which you are required by the contract, agreement, or permit to provide for such additional insured. The insurance afforded to such additional insured only applies to the extent permitted by law. The limits of insurance that apply to additional insureds are described in Section D. LIABILITY AND MEDICAL EXPENSES LIMITS OF INSURANCE. How this insurance applies when other insurance is available to an additional insured is described in the Other Insurance Condition in Section E. LIABILITY AND MEDICAL EXPENSES GENERAL CONDITIONS. a. Vendors Any person(s) or organization(s) (referred to below as vendor), but only with respect to "bodily injury" or "property damage" arising out of "your products" which are distributed or sold in the regular course of the vendor's business and only if this Coverage Part provides coverage for "bodily injury" or "property damage" included within the "products -completed operations hazard". (1) The insurance afforded to the vendor is subject to the following additional exclusions: This insurance does not apply to: (a) "Bodily injury" or "property damage" for which the vendor is obligated to pay damages by reason of the assumption of liability in a contract or agreement. This exclusion does not apply to liability for damages that the vendor would have in the absence of the contract or agreement; (b) Any express warranty unauthorized by you; (c) Any physical or chemical change in the product made intentionally by the vendor; (d) Repackaging, except when unpacked solely for the purpose of inspection, demonstration, testing, or the substitution of parts under instructions from the manufacturer, and then repackaged in the original container; (e) Any failure to make such inspections, adjustments, tests or servicing as the vendor has agreed to make or normally undertakes to make in the usual course of business, in connection with the distribution or sale of the products; (f) Demonstration, installation, servicing or repair operations, except such operations performed at the vendor's premises in connection with the sale of the product; Form SL 30 32 06 21 Page 1 of 3 © 2021, The Hartford (May include copyrighted material of Insurance Services Office, Inc., with its permission) THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. THE HARTFORD (g) Products which, after distribution or sale by you, have been labeled or relabeled or used as a container, part or ingredient of any other thing or substance by or for the vendor; or (h) "Bodily injury" or "property damage" arising out of the sole negligence of the vendor for its own acts or omissions or those of its employees or anyone else acting on its behalf. However, this exclusion does not apply to: (1) The exceptions contained in Paragraphs (d) or (f); or (ii) Such inspections, adjustments, tests or servicing as the vendor has agreed to make or normally undertakes to make in the usual course of business, in connection with the distribution or sale of the products. (2) This insurance does not apply to any insured person or organization from whom you have acquired such products, or any ingredient, part or container, entering into, accompanying or containing such products. b. Lessors Of Equipment (1) Any person or organization from whom you lease equipment; but only with respect to their liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by your maintenance, operation or use of equipment leased to you by such person or organization. (2) With respect to the insurance afforded to these additional insureds, this insurance does not apply to any "occurrence" which takes place after you cease to lease that equipment. c. Lessors Of Land Or Premises (1) Any person or organization from whom you lease land or premises, but only with respect to liability arising out of the ownership, maintenance or use of that part of the land or premises leased to you. (2) With respect to the insurance afforded to these additional insureds, this insurance does not apply to: (a) Any "occurrence" which takes place after you cease to lease that land or be a tenant in that premises; or (b) Structural alterations, new construction or demolition operations performed by or on behalf of such person or organization. d. Architects, Engineers Or Surveyors (1) Any architect, engineer, or surveyor, but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by your acts or omissions or the acts or omissions of those acting on your behalf: (a) In connection with your premises; (b) In the performance of your ongoing operations performed by you or on your behalf; or (c) In connection with "your work" and included within the "products -completed operations hazard", but only if: (i) The written contract, written agreement or permit requires you to provide such coverage to such additional insured; and (II) This Coverage Part provides coverage for "bodily injury" or "property damage" included within the "products -completed operations hazard". (2) With respect to the insurance afforded to these additional insureds, the following additional exclusion applies: This insurance does not apply to "bodily injury", "property damage" or "personal and advertising injury" arising out of the rendering of or the failure to render any professional services, including: (1) The preparing, approving, or failure to prepare or approve, maps, shop drawings, opinions, reports, surveys, field orders, change orders, designs or drawings and specifications; or (ii) Supervisory, surveying, inspection, architectural or engineering activities. This exclusion applies even if the claims allege negligence or other wrongdoing in the supervision, hiring, employment, training or monitoring of others by an insured, if the "bodily injury", "property Form SL 30 32 06 21 Page 2 of 3 © 2021, The Hartford (May include copyrighted material of Insurance Services Office, Inc., with its permission) THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. THE HARTFORD damage", or "personal and advertising injury" arises out of the rendering of or the failure to render any professional service. e. State Or Governmental Agency Or Subdivision Or Political Subdivision Issuing Permit (1) Any state or governmental agency or subdivision or political subdivision, but only with respect to operations performed by you or on your behalf for which the state or governmental agency or subdivision or political subdivision has issued a permit. (2) With respect to the insurance afforded to these additional insureds, this insurance does not apply to: (a) "Bodily injury", "property damage" or "personal and advertising injury" arising out of operations performed for the federal government, state or municipality; or (b) "Bodily injury" or "property damage" included within the "products -completed operations hazard". f. Any Other Party (1) Any other person or organization who is not in one of the categories or classes listed above in Paragraphs a. through e. above, but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by your acts or omissions or the acts or omissions of those acting on your behalf: (a) In the performance of your ongoing operations performed by you or on your behalf; (b) In connection with your premises owned by or rented to you; or (c) In connection with "your work" and included within the "products -completed operations hazard", but only if: (i) The written contract, written agreement or permit requires you to provide such coverage to such additional insured; and (ii) This Coverage Part provides coverage for "bodily injury" or "property damage" included within the "products -completed operations hazard". (2) With respect to the insurance afforded to these additional insureds, the following additional exclusion applies: This insurance does not apply to "bodily injury", "property damage" or "personal and advertising injury" arising out of the rendering of, or the failure to render, any professional architectural, engineering or surveying services, including: (a) The preparing, approving, or failure to prepare or approve, maps, shop drawings, opinions, reports, surveys, field orders, change orders, designs or drawings and specifications; or (b) Supervisory, surveying, inspection, architectural or engineering activities. This exclusion applies even if the claims allege negligence or other wrongdoing in the supervision, hiring, employment, training or monitoring of others by an insured, if the "bodily injury", "property damage", or "personal and advertising injury" arises out of the rendering of or the failure to render any professional service described in Paragraphs f.(2)(a) or f.(2)(b) above. Form SL 30 32 06 21 Page 3 of 3 © 2021, The Hartford (May include copyrighted material of Insurance Services Office, Inc., with its permission)