HomeMy WebLinkAboutContract 45276 Aty 0SE""My,
colff I
STATE OF TEXAS § ONTRACTW,
KNOW L BY THESE PRESENTS'
COUNTY OF TARRANT
"THIS AGREEMENT is made and entered bey, and between the City of Fort Worth, Texas, a
muniolpal corporation situated *in Tarrant,Denton,Parker,and Wise Counties,Texas,hereinafter called the
"City"', acting herein by and through. Fernando' Costa, its duly authorized Assistant City Manager, are
Elements of Architecture, Inc., hereinafter called the "Architect", acting herein by and through Debbie
Fualwiler All its duly authorized representative, for the purpose of providing architectural design for
Schematic Design Phase Services for the KXAS Studio Building located at 3900, Barnett Street, in Fort
Worth,Texas. �
W I T N E S SETHv-
'"hat for and in consideration of the mutual covenants and agreements herein contained, City and Architect
do hereby covenant and agree as follows.
SECTION T SERVICES OF THE ARCHITECT
1.1 The City hereby contracts with Architect as an independent contractor, and the Architect hereby
agrees to pe forn, within the professional standards normally accepted in the State of Texas,
professional services in connection with the following general scope of Ivor
Provide design, construction documents, and construction administration services for the
Schematic Design Phase Services for the old KXAS Studio Building located at 3900 Barnett
Street, in Fort Worth, Teas. ("Project"),. The scope of services is dcswcribcd more fully Mi
Attachment A"of this Agreement.
The following personnel will be assigned to this Project;
1,1. City of Fort Worth
1.1.1,Project M ager: Ronald Clements,Registered Architect
12, Architect
1.2.1,Principal 'in Charge:Debbie Fulwiler,AIA
1.2,2.Project Manager: DebIble Fulwile#,AI
1.23.Project Architect: Debbie Fulwiler,AIA
2. Neither party may change key personnel without the prior written agreement of the other party.
SECTION CHARACTER ER F ARCHITECT'S SERVICES
1, Architect shall consult with the City to clarify and define City's requirements relative to the Projects
and review available data..
2. Architect agrees to commit the personnel to each Project assignment as necessary in order to'complete
the asslignment in an expeditious manner.
3. The A rchitect shall advise City as to the necessity of City's providing or obta" ng additional services
and data •om others required in connection with the Projects at City's cost and expense(which services
and data Architect is not to provide hereunder but on which Architect may rely mi performing services
hereunder),,aaa d acct as City's representative in connection with any such services of others.
OFFICIAL RECORD
Page I of
R�c
4. The Architect shall pay for the printing of contract documents required for design submittals and
presentations as a part of the reimbursable allowance.
5. The Architect shall perform services, as outlined in the Elements of Architecture Inc letter.Jated
No KXAS T
yvember 1..,9,2011, subject: Pmposal for A/E Services V Studio _c esign
5_hemanc,D phase
Services,which is attached hereto as Attachment"A"and made a part of this Agieement,
6. If at any time in,the course of the design,the City expands the scope of services,or the Architect
believes the City has requested services that are beyond the scope of this Agreement,the Architect shall
submit a proposal for additional fees and a written agreement shall,be reached on said proposal prior to
the Architect proceeding with the work considered to be beyond the scope of this Agreement.
Architect shall not perform any additional services without a written agreement with City. Any services
provided prior to reaching an agreement on additional fees,will be,non-compensabile.
SECTION IV SPECIAL SERVICES OF ARCHITECT
I If authorized m' writing by City,Architect shall furnish or obtain from others special services necessary
to complete the Pr jects, These special services are not included as pail of the Basic Services outlined
01
in SECTION I - SERVICES OF THE ARCHITECT and Attachment"A." These special services will
be paid for by City as indicated in Section V.
SECTION V COMPENSATION TO ARCHITECT
L The total co ensation for all of the assignments to be performed by Architect to complete the Pr 'ects,
mp oJ
as described i CHARACTER AND EXTENT of ARCHITECT'S SERVICES and Attachment "A"
hereof shall be$26,620.00,plus up to .00 in reimbursable expenses,hereinafter referred to as the
"total fee,
2. Architect shall be paid the following percentages of the total fee at the following stages of the project:
1.1, Reimbursement of allowable expenses shall have prior approval of the City. Allowable expenses
include.-
1.1.I.Printing Costs
1.1„2.Enhanced CAD drawings for public and City meetings.
1.1.3..Long distance phone calls
1.1 w4.Postage and courier expenses
1.1.5.Other costs with prior approval of the City.
SECTION VI RESPONSIBILITY FOR CONSTRUCTION COSTS
THIS SECTION IS NOT APPLICABLE FOR THIS PRELIMINARY DESIGN SERVICE
SECTION VII METHOD OF PAYMENT
I. The Architect shall be paid not more fi-equently than once per month on the basis of statements
prepared ftom, the bolo�ks and records of account of the Architect, such statements to be verified as to
accuracy and compliance with the terms, of this Agreement by an officer of the Architect. Payment
according to statements will be subject to certification by the Director, Transportation and. Public
Works Department or his duly authorized representative that such work has been perforined.
2. The above charges are on the basis of prompt payment of bills rendered and conthitious,progress of the
work on the Projects until completion. If City falls to make any payment required herein services
Page 2 of 9
and reimbursable expenses within sixty days after approval of Architect's statement thereof, Architect
may after giving seven days written notice to City, suspend services under this Agreement until
I I I
Architect has been paid in full all amounts due for services actually performed and reimbursable
expenses incurred.
SECTION VIII PROCEDURES FOR PROVIDING DESIGN SERVIC'ES
1. Schematic Design Phase:
1.1. The Architect shall visit the sites and make himself familiar with the scopes of the Projects,
1.2. Prepare alternative floor plans, architectural concepts, and fmish plans and area-based cost
estimates,'
1.3.
2. Format of Drawings
2.1.1.Drawings at all stages of design will have the following;characteristics:stics: Scale for floor plans
will be 1/8" or such other scale as may be agreed to in writing for all disciplines,,elevations
w'11 be at same scale as floor plans, area plans will have same scale for all disciplines and
I J
site plans for all disciplines will be at same scale.
2.,1.2. Drawings shall plot'to 2204 sheet to facilitate ha If-slize 11 x 17 prints. Fonts shall be legible
at half-size,
2.2. Architect, at its sole cost and expense, shall engage a consultant to prepare "Elimmiatlon of
Architectural Barriers Registration" and submit the applications to the Texas Department of
Licensing and Regulation. 'fhe City will pay all fees required for TDLR reviews and ispections.
All designs, shall be in conformance with the Elimination of Architectural Barriers Act, State of
Texas,City of Fort Worth Building Codes and the Americans with Disabilities Act,
2.2.1. The Architect shall reimburse the City of Fort Worth for all costs and fees incurred in
modifying a facility in the event it is constructed in accordance with the Architect's designs
and is subsequently determined to be in non-conformance with the above Act, Codes or
Guidelines.
3. All designs, drawings, specifications, documents, and other work products of the Architect',whether in
hard copy or in electronic form, are instruments of service for this Project, whether the Project is
completed or not. Reuse, change, or alteration by the City or by others acting through or on behalf of
the City of any such instruments of service without the written permission of the Architect will be at the
City's sole risk. The City shall own the final printed designs, drawings, specifications and documents,
Transfer of ownership of the contract documents does not constitute sale of the documents.
SECTION IX CITY RESPONSIBILITIES
L Provide criteria,and information as to City's requirements and designate, a person with authority to act
on City's behalf on all matters concerning,the Projects,
2. Assist Architect in obtaining existing studies, reports and other available data and services of others
pertinent to the Projects and*in obtaining additional reports and data as required.
3. Upon reasonable notice arrange for access to and make all provisions for Architect to enter upon public
and private property as may be required for Architect to perform services hereunder.
4. Designate in writing qualified persons who will act as City"s representatives with respect to the Projects
a, 0 0
for the purposes of transmitting instructions,, receiving information, nilterpreting and defining City's,
policies and decisions with respect to Architect's services.
Page 3 of 9
5. Review all reports, recommendations and other documents and provide written decisions pertaining
thereto withm* a reasonable time.
6. Upon reasonable notice provide labor and safety equipment to expose structural elements, to make
tempVrary repairs, and to operate mechanical and electrical systems as required by the Architect,in the
development of the design.
7. Examie all studies, reports, sketches, drawings,, specifications, proposals and other documents
i
presented by Architect, obtain advice of an attorney,, nsurance counselor and other architects as it
deems appropriate for such examination and render in writing decisions pertaining thereto within a
reasonable time so as not to delay,the services of Architect.
8. Provide,"Front End", 'including Division I requirements,for use "in assembling the Project Manual.
9. Prepare easements and right-of-way acquisition conveyance documents, from description provided by
Architect, contact owners,, negotiate for or condemn all easements and right-of-way, pay all filing and
legal fees,associated therewith,
10. Provide such legal, accounting, insurance and other,counseling services to City as may be required for
the Pr"ojects"
11. Manage the advertisement and bidding of the project, issue addenda, distribute bid documents, award
contract,and execute the contracts.
12. Administer the construction of the Project.
13. Provide 'Inspection and management services,.
14. Provide conti-actors, prepared field drawings to the Architect for review.
15. Play all impact and utility fees and other fees not expressly assigned to the Architect. is includes fees
charged by Oncor for new or revised service.
16, Print,documents for bidding and record.
17. Bear all costs incident to compliance with this Section.
SECTION X TERMINA1.'111ON
1. The City may terminate this Agreement at any time for convenience or for any cause by notice in
writing to the Architect,. Upon receipt of such notice, the Architect shall imediately discontinue al l
services and work and the placing of all orders or the entering into contracts for supplies, assistance,
facilities and materials 'in connection with the performance of this Agreement and shall proceed to
cancel promptly all existing contracts insofar as they are chargeable to this Agreement.
2. If the City terminates this Agreement under the foregoing paragraph, the City shall, pay the Architect
for services performed in accordance herewith prior to such termination, less such payments having
been previously made. Such payment shall be based upon the work completed up to the date of
termination of the Agreement'in accordance with the method of compensation prescribed in Sections V
and VI hereof Architect shall also be compensated for all termination related expenses such as
meeting attendance, document reproduction, transfer of records, etc. Provided, however, Architect
shall not be entitled to any compensation that exceeds the total fee to be paid hereunder at the
applicable phase as stated in Section V.
3. Upon early termination or conclusion of this Agreement, the Architect shall provide the City
reproducible copies,of all completed or partially completed engineering documents prepared under this
Agreement that shall become the property of the City and may be used by the City in any manner it
Page 4 of 91
desires. The Architect shall not be liable for the use of such n1aterials, for any project other than the
project described in this Agreement.
SECTION XI WDEM-NITY AND INSURANCE
1. Approval by the City of contract documents shall not constitute or be deemed to be a release of the
responsibility and liability of the Architect, its officers, agents, employees and consultants, for the
accuracy and competency of the services performed under this Agreement, 'including but not limited to
surveys, location of subsurface investigations, designs, working drawings and specifications, and other
Engineering documents.
2. Such approval shall not be deemed to be an assumption,of such responsibility and liability by the City
for any negligent act, error or ornission M* the conduct or preparation of the subsurface investigations,
surveys, designs, working drawings and specifications and other Engineering documents by the
Architect, its officers, agents,employees and consultants,,, it being the "intent of the parties that approval,
by the City signifies the City's approval of only the general design concept of the in to be
constructed.
3. In this connection the Architect shall indemnify and hold the City and all its officers, agents, servants
and employees harrrdiess,from any loss,damage,,liability or expenses,on account of damage to property
and injuries, including death,to all persons, including but not limited to officers, agents, or employees
of the Architect or consultant,and all other persons performing any part of the work and improvements,
which may anise out of any negligent act, error or Mission iris the performance of the Architect's
professional services or in the preparation of designs,, working drawings, specifications and other
documents.
4. The Architect shall defend at its own expense any suits or other proceedings brought against the City,
its officers, agents, servants, and employees,, or any of them on account thereof, and shall pay all
expenses and satisfy all judgments which may be incurred by or rendered against them arisig out or
the indemm'fication; provided and except, however, that this indemnification provision shall not be
construed as requiring the Architect to Widemnify or hold the City or any of its officers,agents,servants
or employees harmless from any loss, damages, liability or expense, on account of damage to property
or injuries to person caused by defects or deficiencies in design criteria and Miformation provided to
Architect by City, or any deviation in construction from Architect's designs, working drawings,
specifications or other documents.
5. Without limiting the above indemnity, Architect shall maintain a policy of comprehensive general
liability insurance coverage with carriers,acceptable to City i at least the following amounts:
Commercial General Liability $11000 Qw PerOCCUrrence
$2,000,000 Aggregate Limit
Workers Compensation
Coverage A: Statutory lifflits
Coverage B:Employers Liability Insurance
$1 O�0,000 Each Accident/Each Occurrence
$100,000 Disease—per each employee
$500,000 Bodily Injury/Disease—Policy Limit
Automobile Liability
$1,,000,000 each accident on a combined single basis,
OR
$250,000: Property Damage
Page 5 of'9
$500,000 Bodily Injury per person per occurrence
Professional Liability Insurance
(Errors and Omissions) $1)0005000 Per claim
$2)00U00 Annual aggregate
6. Architect shall furnish City a Certificate of Insurance in at least the above amounts. Certificate shall
41
contam" a provision that such insurance cannot be canceled without 30 days prior written notice to City.
The City reserves the right to revise 'insurance requirements specified M1 this Agreement to the blest
interests of the City.
7. General Insurance Requirements
.1. Commercial General Liability coverage shall be endorsed to name the City an Additional Insured
thereon. The terrn "City" shall include its employees, officers, officials, agents, and volunteers as
respects,the contracted services,,
7.2. Certificate(s) of insurance shall document that insurance coverage specified are provided under
applicable policies documented thereon.
7.3. Any failure on part of the City to request required insurance documentation shall not constitute a
waiver of the*insurance requirements.
7.4. A minimum of thirty days notice of cancellation or non-renewal in coverage shall be provided to the
City. A ten days notice shall be acceptable in the event of non-payment of premium. Such terms
shall be endorsed onto Architect's "insurance policies. Notice shall be sent to the Facilities Manager,
Transportation and Public Works Department, 1000 Throckmorton,Fort Worth,TX 76102.
7.5. T The City shall not be responsible for the direct payment of any insurance premituns required by this
Agreement. It is understood that'insurance cost is an allowable component of the Architect's general
overhead.
7.6. The City reserves the right to revise*insurance requirements,specified in this agreement according,to
the best interests of the City.
7.7. hisurers for all policies must be authorized to do business in the state of Texas or be otherwise
approved by the City; and, such insurers shall be acce table to the City in terms of their financial
P p
strength and solvency.
7'.8, Deductible limits,or self-insured retentions,affecting insurance required herein may be acceptable to
the City at its sole discretion; and, 'in lieu of traditional insurance, any alternative coverage
main tam* ed through isuratice, pools or risk retention, groups rnust, be also approved. Dedicated
Financial resources,or letters of credit may also be acceptable to the City.
7-9. The City shall be entitled,upon its request and without incurring expense,to review the Architect's
insurance policies including endorsements thereto and, at the City's discretion, the Architect may be
required to provide proof of*insurance premium payments.
'x'.10.All 'insurance, except for the Professional Liability 'insurance policy, shall be written on an
occurrence basis,
7.11,The Professional Liability Policy shall be written on a"claims made" and shall be in effect for the
duration of this Agreement and for 12 months following Architect's issuance of the Certificate of
Substantial Completion,., The Architect's current insurer shall list tile City as a certificate holder
for a period of six years followmig the issuance of the Certificate of Substantial Completion by the
Architect. The City shall be notified at least 30 days prior to cancellation or non-renewal in
coverage.
Page 6 of 9
SECTION X11 HAZARDOus MAT1
I City, acknowledges Architect will perform, part of the work at City's facilities that may contain
hazardous materials, including asbestos containing materials, or conditions,,, and that Architect had no
prior roles the generation, treatnient,storage,or disposition of such materials. In consideration of the
associated risks that may give rise to claims by third parties or employees of City,City hereby releases
Architect from any,damage or liability related to the presence of such materials.
2. The release required above shall not apply fil the event the discharge, release, or escape of hazardous
substances, contaminants or asbestos is a result of Architect's net glicence or if Architect bnings such
hazardous substance,contaminant,or asbestos onto the Projects,
SECTION XIII RIGHT TO AUDIT
1. Architect agrees that the City shall,until the expiration of three(3)years after final payment under this
Agreement, have access to and the right to examine any directly pertinent books, documents, papers
and records of the Architect involving g transactions relating to this Agreement. Architect agrees,that the
City shall have access during normal working hours to all necessary Architect facilities, and shall be
provided adequate and appropriate workspace in order to conduct audits in compliance, with the
i i
provisions of this section. The City shall give Architect reasonable advance notice of imended audits.
a
2. A f
rchitect urther agrees to 'Include in all its subcontracts hereunder a provision to the effect that the
subconsultant agrees that the City shall,until the expiration of three(3)years after fmal payment under
the subcontract, have access to and the right to examine any directly pertinent books, documents,
papers and records of such subconsultant, involvffig transactions to the subcontract, and fLuther, that
City shall have access during normal working hours to all subconsultant facilities,and shall be provided
adequate and appropriate work space, in order to conduct audits M compliance with the provisions of
this article. City shall give subconsultant reasonable advance notice of Wended audits.
3. Architect and consultants agree to photocopy such project-related documents as may.be requested by
the City, The City agrees to reimburse Architect and consultants for the costs of copies at the rate
.
published in the,Texas Adnun istrative Code.
SECTION XIV SUCCESSORS AND ASSIGNS
1. The City and the Architect each bind themselves,their successors and assigns, to the other party,to this
Agreement and to the successors and assigns of each other party in respect to all covenants of this
Agreement.
SECTION XV ASSIGNMENT
1. Neither party hereto shall assign, sublet or transfer its 'Interest herein without prior written consent or
the other party, and any attempted assignment, sublease or transfer of all or any pail hereof without
such prior written consent shall be void.
SECTION XVI INDEPENDENT ARCHITECT
1. Architect shall perform all work and, services hereunder as an independent Architect, and not as an
officer, agent, servant o r e mployee of the City. Architect shall have exclusive control of, and the
exclusive right to control the details of the work performed hereunder, and all. persons performing
same, and shall be solely responsible for the acts and omissions of its officers, agents, employees and
Page 7 of 9
consultants. Nothing here Hii shall be construed as, creating a partn,ership or joint venture between the
City and the Architect I ts officers, agents, employees and consultants, and doctrine of respondent
superior has no application ication as between the City and the Architect,
SECTION X M/WBE GOALS
THIS SECTION IS NOT APPLICABLE FOR THIS PRELIMINARY DESIGN SERVICE
SECTION XVTH OBSERVE AND COMPLY
1. Architect shall at all times observe and comply with all Federal and State laws,and regulations and with
all City ordinances and regulations, which "in any way affect this Agreement and the work hereunder,
and shall observe and comply with all orders,, laws,ordinances,and regulations which may exist or may
be enacted later by governing bodies having jurisdiction or authority for such enactment. No plea of
misunderstand'Ing or ignorance thereof shall be considered. Architect agrees to defend, demnify and
hold harmless, City and all 'its officers, agents, and employees from and against all claims or liability
i
arising out of the violation of any such order, law,ordinance,or regulation,whether it be by itself or its
employees.
SECTION XIX MISCELLANEOUS
I. If any action, whether real or asserted, at law or in equity, arises on the basis of any provision of this
Agreement, venue for such action shall lie in state courts, located mi Tarrant County, Texas or the
United States District Court for the Northern District of Texas—Fort Worth Division. This Agreement
shall be construed in accordance with the laws of the State of Texas.,
2. The parties, acknowledge that each party and, if it so chooses, its counsel have reviewed and revised
this Agreement and that the normal rule of construction to the effect that any ambiguities are to be
resolved against the drafting party must not be employed 'in,the interpretation of this Agreement or any
amendments or exhibits hereto,
3. This Agreement shall inure only to the benefit of the parties hereto and third persons not privy hereto
shall not,in any form.or manner,be considered a third party beneficiary of this Agreement, Each party
hereto shall be solely responsible for the fulfillment of'Its,own contracts or commitments,.
IN TESTIMONY THEREOF.,the City of Fort Worth has caused this instrument to be signed in triplicate In
its name and on its behalf, by its City Manager and attested by its City Secretary, with the Corporate Seal
affted; and the Architect has also properly executed this instrument in triplicate copies, each of which is
deemed an original.
Page 8 of 9
EXECUTED IN THE CITY OF FORT WORTH,TEXAS,Tll[ d a' y 0 A.D.,�2014.
Elements of Architecture,Inc. APPROVED:
By.
Debbie Fu 'ier,AIA
-nando Costa
0000
Principal C1 ity Manager
itant
left
APPROVAL COMM-EANDED:
1 00
As 0 ,
Bya,
Doug sig,PE,Director 01-
-9 1 Ct
Trans ate. and Public Works Department City Secretary
APPROVED AS TO FORM AND LEGALITY: M&C C- Not Regu ire d
J ion
Contract Author"zat"
Bys- Date:
Dou,g as Black
,
Assistant City Attorney
The Texas Board of Architectural Examiners,8213 Shoal Creek Boulevard,Suite 107,Austin,Texas,78758,telephone(5 12)305-
900 ,hasjurisdiction over individuals licensed under the Architects'Registration LaNy,Texas Civil Statutes,Article 249a.
OFFICIAL RIECORI)
FOFF ECORD
Page 9 of 9 Cir y
CITY SECREURY
FT. WORTH, TX
500 W 7th St.,sprite 502
Fart Worth,Texas 76 102
E"LE4MENTS Phonue 81 7 333.2880
of Architecture, Inc, Fax 17.333,2883
N" ovember 19, 2013
Dalton Murayarmua
City of Fart Worth
401 vest 13th Street
Fed Worth,TX 761
Ike. proposal'for /E Services—Annual A E Contract
,AS TV Studio—Schematic Design phase Services- Revised
Dear Dalton.
Elements is pleased to provide to you this proposal for Architectural and Englneering Services associated with
the schematic design phase services for the existing KXAS TV Stucllos located on Barnett Street In Fort Worth.
We understand that the Intent of this phase of the project is to determine what will be required for renovation
and the preliminary,casts associated with these renovations for determining the project budget and funding,
We anticipate the scope of services anti cl ate l for this project Is as follows-,
SCOPE OF SERVICES
Schematic Design Phase
1 pre-Design Meetings - Meet with the City of Fort "'earth and designated representatives to define
project scope, determine operations requirements, and identify local constraints and conditions that
must be considered In the delivery,of the project.
2. Site Survey-Obtain building drawings,Including any record drawings of the space. Generally measure
and photograph the existing conditions, collect available information on electrical power, mechanical'
systems and, other existing conditions that will Influence the design ancl specific to the nominal
changes anticipated for the project. Develop "as-built" floor plan In CAD format from the available
Information to use as base d raW n s,
3, Programming Meetings-Meet with the City,of Fart Worth's designated representatives and users to
define operations requirements and,,develop programming,ming, It Is assumed for determining our fee that
a total of three meetings will he scheduled with the city and the architects and that one of'these
meetings with be with MEP engineers.
4. Code/Permlt study— Review existing building for compliance with applicable codes. Meet with local
officials to review,what wil!l be required for compliance,
5. Schematic Design -Develop floor,playas Illustrating proposed layouts along with a written narrative to
describe modifications ns lanned for building systems.
6. Preliminary Cost estimate based on the schematic design submitted and approved for general
compliance with programming needs, prepare a prellrmwinlary opinion of probable construction
documents. Givers the schematic nature of the phase of this project at this point,,a 25%contingency
wili be added to the estimate of costs.
Exclusions and Qualifications iu actions>to This Proposal:
I As we understand that the modifications anticipate i for the project will be more finishes In nature with
minimal wall modifications, we have only included minimal review of the existing drawings. if
extensive review of the documents for as-bu:l It conditions is required,we have provided a separate line
Item, for additional detailed survey as listed below.
CFw kXS Tv
Proposal For SD Phase Services
November 1 , 013
Page
2, Services requested in addition to those specifically outlined In this proposal will be lldentlfled and a Fee
proposal provided with approval required before continuing with those services.
3. we have not Ilnclluded any structural or civil engineering In this phase or the project as we do not
believe they will be required. IF It Is determined that these services will be needed,we w i►111 provide a
proposal for services,
4. As It may be required that additional programming meetings are held,we have provided au separate
line itern Fee for each additional programming meeting.
PROPOSED FEE
Labor
We propose to provide our services as Identified in this proposal on an hourly basis with the not to exceed
arnounts as follows:
Architectural/Project Management 16,500.00
""iEi'En ineerin 200 x 1.] Ito 1 20.00
Total $264201.00
Expenses
Reimbursable expenses as outlined in the Master Contract are not Included In our labor Fee and are estimated at
600.00.
ADDiOrll+ NAL SERVICES—Defined Tasks
d'ditivnal Detailed "" u uivey
Archil tectu ral/Project Management $2,000.00
MEP;Engineering ($2400 x 1.l) J& 401.00
Total l $4,640.00,
Additional Programming Meetings
Architectural/Project Management 550.00
Electrical Engineer($500 x 1.i) $ 51510.00,
Mechanical Engineer($500 x 1,1) 550.00
Total 1, 50.0
DELIVERABLE
Deliverable for this project will be schematic plans and narrative and an opinion of probable constructlon costs,
PROJECT TEAM
NEIL'Engineedng willl be by Torres Engineering. All other services will be by Elements.
SCHEDULE
We will work with the city on the schedulle of this project and provide a timeline as we begin our services.
IF you have any questions regarding this proposal) or need to discuss, please call me. Thank you For this
opportunity to continue to provide our services to you and we look forward to working with you on this
project.
Sincerely,
"11 1
Jo 4
--, ..-
Debbile Fulwiler,AIA.
President