The URL can be used to link to this page

Home My WebLink About024918 - Construction-Related - Contract - Ned K. Burleson and Associates, Inc.CITY SECRETARY l CONTRACT NO. 277 I CITY OF FORT WORTH, TEXAS STANDARD AGREEMENT FOR ENGINEERING SERVICES This AGREEMENT is between the City of Fort Worth (the "CITY"), and Ned K. Burleson and Associates, Inc., (the "ENGINEER"), for a PROJECT generally described as: 195AR Drainage Area Sanitary Sewer System Rehabilitation and Improvements (Group 7, Contract 4), Part 4. Article I Scope of Services A. The Scope of Services is set forth in Attachment A. Article II Compensation A. The ENGINEER's compensation is set forth in Attachment B. Article III Terms of Payment Payments to the ENGINEER will be made as follows: A. Invoice and Payment • (1). The Engineer shall. provide the City sufficient do.cu_rnentation to reasonably substantiate the invoices. (2) Monthly invoices will be issued by the ENGINEER for all work performed under this AGREEMENT. Invoices are due and payable within 30 days of receipt. (3) Upon completion of services enumerated in Article I, the final payment of any balance will be due within 30 days of receipt of the final invoice. (4) In the event of a disputed or contested billing, only that portion so contested will be withheld from payment, and the undisputed portion will be paid. The CITY will exercise reasonableness in contesting any bill or portion thereof. No interest will accrue on any contested portion of the billing until mutually resolved. (5) If the CITY fails to make payment in full to ENGINEER for billings contested in good faith within 60 days of the amount due, the ENGINEER may, after giving seven (7) days' written notice to CITY, suspend services under this AGREEMENT until paid in full, including interest. In the event of suspension of services, the ENGINEER shall have no liability to CITY for delays or damages caused the CITY because of such suspension of M nnr��'G1�(°�� rM services. Article IV Obligations of the Engineer Amendments to Article IV, if any, are included in Attachment C. A.- General The ENGINEER will serve as the CITY's professional engineering representative under this Agreement, providing professional engineering consultation and advice and furnishing customary services incidental thereto. B. Standard of Care The standard of care applicable to the ENGINEER's services will be the degree of skill and diligence normally employed in the State of Texas by professional engineers or consultants performing the same or similar services at the time such services are performed. C. - Subsurface Investigations (1) The ENGINEER shall advise the CITY with regard to the necessity for subcontract work such as special surveys, tests, test borings, or other subsurface investigations in connection with design and engineering work to be performed hereunder. The ENGINEER shall also. .advise the. CIT'y. concerning the results of same. Such surveys, tests, and investigations shall be furnished by -the CITY,. unless otherwise. specified in Attachment A. (2) In soils, foundation; groundwater, and other subsurface investigations, the actual characteristics may vary significantly between successive test points and sample intervals and at locations other than where observations, exploration, and investigations have been made. Because of the inherent uncertainties in subsurface evaluations, changed or unanticipated underground conditions may occur that could affect the total PROJECT cost and/or execution. These conditions and cost/execution effects are not the responsibility of the ENGINEER. D. Preparation of Engineering Drawings The ENGINEER will provide to the CITY the original drawings of all plans in ink on reproducible plastic film sheets, or as otherwise approved by CITY, which shall become the property of the CITY. CITY may use such drawings in any manner it desires; provided, however, that the ENGINEER shall not be liable for the use of such drawings for any project other than the PROJECT described herein. -2- E. Engineer's Personnel at Construction Site (1) The presence or duties of the ENGINEER's personnel at a construction site, whether as on -site representatives or otherwise, do not make the ENGINEER or its personnel in any way responsible for those duties that belong to the CITY and/or the CITY's construction contractors or other entities, and do not relieve the construction contractors or any other entity of their obligations, duties, and responsibilities, including, but not limited to, all construction methods, means, techniques, sequences, and procedures necessary for coordinating and completing all portions of the construction work in accordance with the Contract Documents and any health or safety precautions required by such construction work. The ENGINEER and its personnel have no authority to exercise any control over any construction contractor or other entity or their employees in connection with their work or any health or safety precautions. (2) Except to the extent of specific site visits expressly detailed and set forth in Attachment A, the ENGINEER or its personnel shall have no obligation or responsibility to visit the construction site to become familiar with the progress or quality of the completed work on the PROJECT or to determine, in general, if the work on the PROJECT is being performed in a • manner indicating :that the PROJECT, when- completed; will - be in accordance with the Contract Documents, nor shall anything in the Contract Documents or the. agreement between CITY and ENGINEER be • construed as requiring ENGINEER to make exhaustive or continuous on - site inspections to discover latent defects in the work or otherwise check • the quality or quantity•of•the work.on the PROJECT. -If, for any reason, the ENGINEER should make an on -site observation(s), on the basis of such on -site; gpservations,.%f _any.; .the ENGINEER .shall. endeavor to keep -the CITY informed of any deviation from the Contract Documents coming to the actual notice of ENGINEER regarding the PROJECT. (3) When professional certification of performance or characteristics of materials, systems or equipment is reasonably required to perform the services set forth in the Scope of Services, the ENGINEER shall be entitled to rely upon such certification to establish materials, systems or equipment and performance criteria to be required in the Contract Documents. F. Opinions of Probable Cost, Financial Considerations, and Schedules (1) The ENGINEER shall provide opinions of probable costs based on the current available information at the time of preparation, in accordance with Attachment A. (2) In providing opinions of cost, financial analyses, economic feasibility projections, and schedules for the PROJECT, the ENGINEER has no control over cost or price of labor and materials; unknown or latent conditions of existing equipment or structures that may affect operation or maintenance costs; competitive bidding procedures and market conditions; time or qualify of performance by third parties; quality, type, management, or direction of operating personnel; and other economic and operational factors that may materially affect the ultimate PROJECT cost or schedule. Therefore, the ENGINEER makes no warranty that the CITY's actual PROJECT costs, financial aspects, economic feasibility, or schedules will not vary from the ENGINEER's opinions, analyses, projections, or estimates. G. Construction Progress Payments Recommendations by the ENGINEER to the CITY for periodic construction progress payments to the construction contractor will be based on the ENGINEER's knowledge, information, and belief from selective sampling and observation that the work has progressed to the point indicated. Such recommendations do not represent that continuous or detailed examinations have been made by the ENGINEER to ascertain that the construction contractor has completed the work in exact accordance with the Contract Documents; that the final work will be acceptable in all respects; that the ENGINEER has made an examination to ascertain how or for what purpose the construction contractor has used the moneys paid; that title to any of the work, materials, or equipment has passed to the CITY free and clear of liens, claims, security interests, •or encumbrances; or that there are not other matters at issue between the CITY and the construction contractor that affect.the amount that should be paid. H. Record Drawings Record drawings, if required, will be prepared, in part, on the basis of information -.....compiled and furnished by :others;. and may not. always .represent _the ..exact location, type of various components, or exact manner in which the PROJECT was finaiiy construct.d,•. The. ENGINEER.is. riot responsible.for any errors or omissions....: . in the information from others that is incorporated into the record drawings. I. Minority and Woman Business Enterprise (MIWBE) participation In accord with City of Fort Worth Ordinance No. 11923, as amended by Ordinance 13471, the City has goals for the participation of minority business enterprises and woman business enterprises in City contracts. Engineer acknowledges the M/WBE goal established for this contract and its commitment to meet that goal. Any misrepresentation of facts (other than a negligent misrepresentation) and/or the commission of fraud by the Engineer may - result in the termination of this agreement and debarment from participating in City contracts for a period of time of not less than three (3) years. J. Right to Audit (1) ENGINEER agrees that the CITY shall, until the expiration of three (3) years after final payment under this contract, have access to and the right to examine and photocopy any directly pertinent books, documents, papers and records of the ENGINEER involving transactions relating to this contract. ENGINEER agrees that the CITY shall have access during normal working hours to all necessary ENGINEER facilities and shall be -4- provided adequate and appropriate work space in order to conduct audits in compliance with the provisions of this section. The CITY shall give ENGINEER reasonable advance notice of intended audits. (2) ENGINEER further agrees to include in all its subconsultant agreements hereunder a provision to the effect that the subconsultant agrees that the CITY shall, until the expiration of three (3) years after final payment under the subcontract, have access to and the right to examine and photocopy any directly pertinent books, documents, papers and records of such subconsultant, involving transactions to the subcontract, and further, that the • CITY shall have access during normal working hours to all subconsultant facilities, and shall be provided adequate and appropriate work space, in order to conduct audits in compliance with the provisions of this article together with subsection (3)hereof. CITY shall give subconsultant reasonable advance notice of intended audits. (3) ENGINEER and subconsultant agree to photo copy such documents as may be requested by the CITY. The CITY agrees to reimburse ENGINEER for the cost of copies at the rate published in the Texas Administrative Code in effect as of the time copying is performed. K. ENGINEER's Insurance (1) Insurance coverage and limits: . ENGINEER shall provide to the City certificate(s) of insurance documenting policies of the following coverage at minimum limits which.are.to.be in effect prior to commencement of work on the PROJECT: Commercial General Liability $1,000,000 each occurrence $1,000,000 aggregate Automobile Liability $1,000,000 each accident (or reasonably equivalent limits of coverage if written on a split limits basis). Coverage shall be on any vehicle used in the course of the PROJECT. Worker's Compensation Coverage A: statutory limits Coverage B: $100,000 each accident $500,000 disease - policy limit $100,000 disease - each employee Professional Liability $1,000,000 each claim/annual aggregate (2) Certificates of insurance evidencing that the ENGINEER has obtained all required insurance shall be delivered to the CITY prior to ENGINEER proceeding with the PROJECT. -5- (a) Applicable policies shall be endorsed to name the CITY an Additional Insured thereon, as its interests may appear. The term CITY shall include its employees, officers, officials, agents, and volunteers as respects the contracted services. (b) Certificate(s) of insurance shall document that insurance coverages specified according to items section K.(1) and K.(2) of this agreement are provided under applicable policies documented thereon. (c) Any failure on part of the CITY to request required insurance documentation shall not constitute a waiver of the insurance requirements. (d) A minimum of thirty (30) days notice of cancellation, non -renewal or material change in coverage shall be provided to the CITY. A ten. (10) days notice shall be acceptable in the event of non-payment of premium. Such terms shall be endorsed onto ENGINEER's insurance policies. Notice shall be sent to the" respective Department Director (by name), City of Fort Worth, 1000 Throckmorton, Fort Worth, Texas .76102.' (e) .. Insurers for all policies, must be authorized to' do business in the state of Texas or be otherwise approved by the CITY; and, such insurers shall be acceptable to the CITY in terms of their financial strength and solvency: - • . (f) Deductible limits, . or self insured . retentions,.' affecting. insurance required herein may be acceptable to the CITY at its sole discretion; and, in lieu of traditional insurance, any alternative coverage maintained through insurance pools or risk retention groups must be also approved. Dedicated financial resources or letters of credit may also be acceptable to the City. (g) Applicable policies shall each be endorsed with a waiver of subrogation in favor of the CITY as respects the PROJECT. (h) The City shall be entitled, upon its request and without incurring expense, to review the ENGINEER's insurance policies including endorsements thereto and, at the CITY's discretion, the ENGINEER may be required to provide proof of insurance premium payments. (I) The Commercial General Liability insurance policy shall have no exclusions by endorsements unless such are approved by the CITY. (j) The Professional Liability insurance policy, if written on a claims made basis shall be maintained by the ENGINEER for a minimum two (2) year period subsequent to the term of the respective L PROJECT contract with the CITY unless such coverage is provided the ENGINEER on an occurrence basis. (k) The CITY shall not be responsible for the direct payment of any insurance premiums required by this agreement. It is understood that insurance cost is an allowable component of ENGINEER's overhead. (I) All insurance required in section K., except for the Professional Liability insurance policy, shall be written on an occurrence basis in order to be approved by the CITY. (m) Subconsultants to the ENGINEER shall be required by the ENGINEER to maintain the same or reasonably equivalent insurance coverage as required for the ENGINEER. When insurance coverage is maintained by subconsultants, ENGINEER shall provide CITY with documentation thereof on a certificate of insurance. Notwithstanding anything to the contrary contained herein, in the event a subconsultant's insurance coverage is canceled or terminated, such cancellation or termination shall not constitute a breach by ENGINEER of the Agreement. L. Independent Consultant The ENGINEER agrees to perform all services as an independent consultant and not as a subcontractor, agent, or employee of the CITY. M. Disclosure The ENGINEER acknowledges to the CITY that it has made full disclosure in writing of any existing conflicts of interest or potential conflicts of interest, including personal financial interest, direct or indirect, in property abutting the proposed PROJECT and business relationships with abutting property cities. The ENGINEER further acknowledges that it will make disclosure in writing of any conflicts of interest which develop subsequent to the signing of this contract and prior to final payment under the contract. N. Asbestos or Hazardous Substances (1) If asbestos or hazardous substances in any form are encountered or suspected, the ENGINEER will stop its own work in the affected portions of the PROJECT to permit testing and evaluation. (2) If asbestos or other hazardous substances are suspected, the ENGINEER will, if requested, assist the CITY in obtaining the services of a qualified subcontractor to manage the remediation activities of the PROJECT. O. Permitting Authorities - Design Changes If permitting authorities require design changes so as to comply with published -7- design criteria and/or current engineering practice standards which the ENGINEER should have been aware of at the time this Agreement was executed, the ENGINEER shall revise plans and specifications, as required, at its own cost and expense. However, if design changes are required due to the changes in the permitting authorities' published design criteria and/or practice standards criteria which are published after the date of this Agreement which the ENGINEER could not have been reasonably aware of, the ENGINEER shall notify the CITY of such changes and an adjustment in compensation will be made through an amendment to this AGREEMENT. Article V Obligations of the City Amendments to Article V, if any, are included in Attachment C. A. City -Furnished Data The CITY will make available to the ENGINEER all technical data in the CITY's possession relating to the ENGINEER's services on the PROJECT. • The ENGINEER may rely upon the accuracy, timeliness, and completeness of the information provided by the CITY. . B. Access to Facilities. and Property The CITY will make its facilities accessible to the ENGINEER as required for the ENGINEER's performance of its •services and will provide .labor and. safety equipment as required by the ENGINEER for such access. The CITY will perform, at.no cost to the. ENGLN.EER, such tests. pf equipment, machinery, pipelines,, and other components of the CITY's facilities as may be required in connection with the ENGINEER's services. The CITY will be responsible for all acts of the CITY's personnel. C. Advertisements, Permits, and Access Unless otherwise agreed to in the Scope of Services, the CITY will obtain, arrange, and pay for all advertisements for bids; permits and licenses required by local, state, or federal authorities; and land, easements, rights -of -way, and access necessary for the ENGINEER's services or PROJECT construction. D. Timely Review The CITY will examine the ENGINEER's studies, reports, sketches, drawings, specifications, proposals, and other documents; obtain advice of an attorney, insurance counselor, accountant, auditor, bond and financial advisors, and other consultants as the CITY deems appropriate; and render in writing decisions required by the CITY in a timely manner in accordance with the project schedule in Attachment D. E. Prompt Notice The CITY will give prompt written notice to the ENGINEER whenever CITY observes or becomes aware of any development that affects the scope or timing of the ENGINEER's services or of any defect in the work of the ENGINEER or construction contractors. F. Asbestos or Hazardous Substances and Indemnification (1) To the maximum extent permitted by law, the CITY will indemnify and release ENGINEER and its officers, employees, and subcontractors from all claims, damages, losses, and costs, including, but not limited to, attorney's fees and litigation expenses arising out of or relating to the presence, discharge, release, or escape of hazardous substances, contaminants, or asbestos on or from the PROJECT. Nothing contained herein shall be construed to require the CITY to levy, assess or collect any - tax to fund this indemnification. (2) The indemnification and release required above shall not apply in the event the discharge, release or escape of hazardous substances, contaminants, or asbestos is*a result of ENGINEER'S negligence or if such hazardous substance, contaminant or asbestos is brought onto the PROJECT by ENGINEER. . G. Contractor Indemnification and Claims The CITY agrees to include in all construction contracts the provisions of Article IV.E.. regarding the ENGINEER's Personnel at. Construction Site,, and. provisions providing contractor indemnification of the CITY and the ENGINEER for contractor's negligence. H. Contractor Claims and Third -Party Beneficiaries (1) The CITY agrees to include the following clause in all contracts with construction contractors and equipment or materials suppliers: "Contractors, subcontractors and equipment and materials suppliers on the PROJECT, or their sureties, shall maintain no direct action against the ENGINEER, its officers, employees, and subcontractors, for any claim arising out of, in connection with, or resulting from the engineering services performed. Only the CITY will be the beneficiary of any undertaking by the ENGINEER." (2) This AGREEMENT gives no rights or benefits to anyone other than the CITY and the ENGINEER and there are no third -party beneficiaries. (3) The CITY will include in each agreement it enters into with any other entity or person regarding the PROJECT a provision that such entity or person shall have no third -party beneficiary rights under this Agreement. -9- (4) Nothing contained in this section V.H. shall be construed as a waiver of any right the CITY has to' bring a claim against ENGINEER. I. CITY's Insurance (1) The CITY may maintain property insurance on certain pre-existing structures associated with the PROJECT. (2) The CITY will ensure that Builders Risk/installation insurance is maintained at the replacement cost value of the PROJECT. The CITY may provide ENGINEER a copy of the policy or documentation of such on a certificate of insurance. (3) The CITY will specify that the Builders Risk/Installation insurance shall be comprehensive in coverage appropriate to the PROJECT risks. J. Litigation Assistance The Scope of Services does not include costs of the ENGINEER for required or requested assistance to support, prepare, document, bring, defend, or assist in litigation undertaken or defended by the -CITY: Intheevent CITY requests such services of the ENGINEER, this AGREEMENT shall be amended or a separate agreement will be negotiated between the parties. K. Changes The CITY may make or approve changes within the general Scope of Services in ...this. AGREEMENT.. If such . changes..aff. ect the. ENGJNEER's cost .of or time required for performance of the services, an equitable adjustment will be made through an amendment to this AGREEMENT with appropriate CITY approval. Article VI General Legal Provisions Amendments to Article VI, if any, are included in Attachment C. A. Authorization to Proceed ENGINEER shall be authorized to proceed with this AGREEMENT upon receipt of a written Notice to Proceed from the CITY. B. Reuse of Project Documents All designs, drawings, specifications, documents, and other work products of the ENGINEER, whether in hard copy or in electronic form, are instruments of service for this PROJECT, whether the PROJECT is completed or not. Reuse, change, or alteration by the CITY or by others acting through or on behalf of the CITY of any such instruments of service without the written permission of the ENGINEER will -10- be at the CITY's sole risk. The final designs, drawings, specifications and documents shall be owned by the CITY. C. E. Force Majeure The ENGINEER is not responsible for damages or delay in performance caused by acts of God, strikes, lockouts, accidents, or other events beyond the control of the ENGINEER. Termination (1) This AGREEMENT may be terminated only by the City for convenience on 30 days' written notice. This AGREEMENT may be terminated by either the CITY or the ENGINEER for cause if either party fails substantially to perform through no fault of the other and does not commence correction of such nonperformance with five (5) days of written notice and diligently complete the correction thereafter. (2) If this AGREEMENT is terminated for the convenience of the City, the ENGINEER will be paid for termination expenses as follows: a) Cost of reproduction ` 'of partial or complete studies, plans, specifications or other forms of ENGINEER'S work product; b) Out-of-pocket expenses. for • purchasing storage containers, microfilm, electronic data files, and other data storage supplies or services; c) The time. requirements.for the ENGINEER'S personnel to document.... the work underway at the time the CITY'S termination for convenience so that the work effort is suitable for long time storage. (3) Prior to proceeding with termination services, the ENGINEER will submit to the CITY an itemized statement of all termination expenses. The CITY'S approval will be obtained in writing prior to proceeding with termination services. Suspension, Delay, or Interruption to Work The CITY may suspend, delay, or interrupt the services of the ENGINEER for the convenience of the CITY. In the event of such suspension, delay, or interruption, an equitable adjustment in the PROJECT's schedule, commitment and cost of the ENGINEER's personnel and subcontractors, and ENGINEER's compensation will be made. -11- F. Indemnification (1) The ENGINEER agrees to indemnify and defend the CITY from any loss, cost, or expense claimed by third parties for property damage and bodily injury, including death, caused solely by the negligence or willful misconduct of the ENGINEER, its employees, officers, and subcontractors in connection with the PROJECT. (2) If the negligence or willful misconduct of both the ENGINEER and the CITY (or a person identified above for whom each is liable) is a cause of such damage or injury, the loss, cost, or expense shall be shared between the ENGINEER and the CITY in proportion to their relative degrees of negligence or willful misconduct as determined pursuant to T.C.P. & R. Code, section 33.011(4) (Vernon Supplement 1996). G. Assignment Neither party will assign all or any part of this AGREEMENT without the prior written consent of the other party. H. Interpretation Limitations on liability and indemnities in this AGREEMENT are business understandings between the parties and shall apply to all the different theories of recovery, including breach of contract or warranty, tort, including negligence, strict or statutory liability, or any other cause of action, except for willful misconduct or gross negligence for limitations of liability and sole negligence for indemnification.. • Parties means the CITY and the ENGINEER, and their officers, employees, agents, and subcontractors.,. . I. Jurisdiction The law of the State of Texas shall govern the validity of this AGREEMENT, its interpretation and performance, and any other claims related to it. The venue for any litigation related to this AGREEMENT shall be Tarrant County, Texas. J. Alternate Dispute Resolution (1) All claims, disputes, and other matters in question between the CITY and ENGINEER arising out of, or in connection with this Agreement or the PROJECT, or any breach of any obligation or duty of CITY or ENGINEER hereunder, will be submitted to mediation. If mediation is unsuccessful, the claim, dispute or other matter in question shall be submitted to arbitration if both parties acting reasonably agree that the amount of the dispute is likely to be less than $50,000, exclusive of attorney's fees, costs and expenses. Arbitration shall be in accordance with the Construction Industry Arbitration Rules of the American Arbitration Association or other applicable rules of the Association then in effect. Any award rendered by the arbitrators less than $50,000, exclusive of attorney's fees, costs and expenses, will be final, judgment may be entered thereon in any court having jurisdiction, and -12- will not be subject to appeal or modification except to the extent permitted by Sections 10 and 11 of the Federal Arbitration Act (9 U.S.C. Sections 10 and 11). (2) Any award greater than $50,000, exclusive of attorney's fees, costs and expenses, may be litigated by either party on a de novo basis. The award shall become final ninety (90) days from the date same is issued. If litigation is filed by either party within said ninety (90) day period, the award shall become null and void and shall not be used by either party for any purpose in the litigation. K. Severability and Survival If any of the provisions contained in this AGREEMENT are held for any reason to be invalid, illegal, or unenforceable in any. respect, such invalidity, illegality, or unenforceability will not affect any other provision, and this AGREEMENT shall be construed as if such invalid, illegal, or unenforceable provision had never been contained herein. Articles V.F., VI.B., VI.D., VI.H., VI.I., and VI.J. shall survive termination of this AGREEMENT for any cause. L. Observe and Comply ENGINEER shall at all times observe and comply with all federal and State laws and regulations and with all City ordinances and regulations which in any way affect this AGREEMENT and the work hereunder, and shall observe and comply with all orders, laws ordinances and regulations which may exist or may be enacted .later by governing. bodies having jurisdiction or..authority. for such enactment. No plea of misunderstanding or ignorance thereof shall be considered. ENGINEER agrees to defend, indemnify and hold harmless CITY and all of its officers, agents and employees from and against all claims or liability arising out of the violation of any such order, law, ordinance, or regulation, whether it be by itself or its employees. -13- Article VII Attachments, Schedules, and Signatures This AGREEMENT, including its attachments and schedules, constitutes the entire AGREEMENT, supersedes all prior written or oral understandings, and may only be changed by a written amendment executed by both parties. The following attachments and schedules are hereby made a part of this AGREEMENT: Attachment A - Scope of Services Attachment B - Compensation Attachment C - Amendments to Standard Agreement for Engineering Services A Gloria Pearson City Secretary APPROVED AS TO FORM AND LEGALITY Assistant Ci y Attorney M195AR -14- CITY OF FORT WORTL1,L4 Bv: -Mike Groomer Assistant City Manager APPROVED A. Douglas Rademaker, P.E. Director, Engineering Department NED K. BURLESON AND ASSOC.. INC ENGINEER By: Ned K. Burleson, Ph.D., P.E. President C- /74D Contract Authorization Date ATTACHMENT "A" General Scope of Services "Scope of Services set forth herein can only be modified by additions, clarifications, and/or deletions set forth in the supplemental Scope of Services. In cases of conflict between the Supplemental Scope of Services and the General Scope of Services, the Supplemental Scope of Services shall have precedence over the General Scope of Services." GENERAL 1) Preliminary Conference with City The Engineer shall attend preliminary conferences with authorized representatives of the City regarding the scope of project so that the plans and specifications which are to be developed hereunder by the Engineer will result in providing facilities which are economical in design and conform to the City's requirements and budgetary constraints. 2) Coordination with Outside Agencies/Public Entities The Engineer shall coordinate with officials of other outside - agencies as may be necessary for the design of the proposed street, and storm drain and/or water and wastewater facilities/improvements. It shall be the Engineer's duty hereunder to secure necessary information from such outside agencies,.to meet their requirements. - 3) Geotechnical Investigations The Engineer shall advise the City of test borings, and other subsurface investigations that may be needed. In the event it is determined necessary to make borings or excavate test holes or pits, the Engineer shall in coordination with the City and the City's geotechnical engineering consultant, draw up specifications for such testing program. The cost of the borings or excavations shall be paid for by the City. 4) Agreements and Permits The Engineer shall complete all forms/applications to allow the City of Fort Worth to obtain any and all agreements and/or permits normally required for a project of this size and type. The Engineer will be responsible for negotiating and coordinating to obtain approval of the agency issuing the agreement and/or permits and will make any revisions necessary to bring the plans into compliance with the requirements of said agency, including but not limited to highways, railroads, water authorities, Corps of Engineers and other utilities. 5) Design Changes Relating to Permitting Authorities If permitting authorities require design changes, the Engineer shall revise the plans and specifications as required at the Engineers own cost and expense, unless such changes are required due to changes in the design of the facilities made by the permitting authority. If such changes are required, the Engineer shall notify the City and an amendment to the contract shall be made if the Engineer incurs additional cost. If there are unavoidable -1- delays, a mutually agreeable and reasonable time extension shall be negotiated. 6) Plan Submittal Copies of the original plans shall be provided on reproducible mylar or approved plastic film sheets, or as otherwise approved by the Department of Engineering and shall become the property of the City. City may use such drawings in any manner it desires; provided, however that the Engineer shall not be liable for the use of such drawings for any project other than the project described herein; and further provided, that the Engineer shall not be liable for the consequences of any changes that are made to the drawings or changes that are made in the implementation of the drawings without the written approval of the Engineer. PHASE I 7) Right -of -Way, Easement and Land Acquisition Needs The Engineer shall determine the rights -of -way, easement needs for the construction of the project. Engineer shall determine ownership of such land and furnish the City with the necessary right-of-way sketches, prepare necessary easement descriptions for acquiring the- rights -of -way and/or easements for the construction of this project. Sketches and easement descriptions are to be presented in form suitable for direct use by the Department of Engineering in obtaining rights -of -way, easements, permits and licensing agreements. All materials shall be furnished on the appropriate City forms in a minimum of four (4) copies each. 8) Design Survey The Engineer shall provide necessary field survey for use in the preparation of Plans and Specifications. The Engineer shall furnish the City certified copies of the field data. 9) Utility Coordination The Engineer shall coordinate with all utilities, including utilities owned by the City, as to any proposed utility liens or adjustment to existing utility lines within the project limits. The information obtained shall be shown on the conceptual plans. The Engineer shall show on the preliminary and final plans the location of the proposed utility lines, existing utility lines, based on the information provided by the utility, and any adjustments and/or relocation of the existing lines within the project limits. The Engineer shall also evaluate the phasing of the water, wastewater, street and drainage work, and shall submit such evaluation in writing to the City as part of this phase of the project. -2- 10) Conceptual Plans The Engineer shall furnish four (4) copies of the Phase 1 concept engineering plans which include layouts, preliminary right-of-way needs and preliminary estimates of probable construction costs for the Engineer's recommended plan. For all submittals, the Engineer shall submit plans and documents for street/storm drain and water/wastewater facilities. The Engineer shall receive written approval of the Phase 1 Plans from the City's project manager before proceeding with Phase 2. PHASE 2 11) Design Data The Engineer shall provide design data, reports, cross -sections, profiles, drainage calculations, and preliminary estimates of probable construction cost. 12) Preliminary Construction Plans and Technical Specifications The Engineer shall submit twenty (20) copies of Phase 2 preliminary construction plans and five (5) copies of the preliminary technical specifications for review by the City and for submission to utility companies and other agencies for the purposes of coordinating work with existing and proposed utilities. The preliminary construction plans shall indicate location of existing/proposed utilities, and storm drain lines. The Engineer. shall .receive written approval of the Phase 2 plans from the City's project manager before proceeding with Phase 3. PHASE 3 13) Final Construction Plans The Engineer shall furnish five (5) copies of the final construction plans and contract specifications for review by the City. 14) Detailed Cost Estimate The Engineer shall furnish four (4) copies of detailed estimates of probable construction costs for the authorized construction project, which shall include summaries of bid items and quantities. 15) Plans and Specification Approval The Engineer shall furnish an original cover mylar for the signatures of authorized City officials. The Contract Documents shall comply with applicable local, state and federal laws and with applicable rules and regulations promulgated by local, state and national boards, bureaus and agencies. The Engineer shall receive written approval of the Phase 3 plans from the City's project manager before proceeding with Phase 4. -3- PHASE 4 16) Final Approved Construction Plans The Engineer shall furnish 45 bound copies of Phase 4 final approved construction plans and contract specifications. The approved plans and contract specifications shall be used as authorized by the City for use in obtaining bids, awarding contracts, and constructing the project. 17) Bidding Assistance The Engineer shall issue addenda as appropriate to interpret, clarify, or expand the bidding documents, and assist the owner in determining the qualifications and acceptability of prospective constructors, subcontractors, and suppliers. When substitution prior to the award of contracts is allowed by the bidding documents, the Engineer will advise the owner as to the acceptability of alternate materials and equipment proposed by the - prospective constructors. 18) Recommendation of Award The Engineer shall assist in the tabulation and review of all bids received for the construction of the project and shall make a recommendation of award to the City. 19) Prebid Conference The Engineer shall attend the prebid conference and the bid opening, prepare bid tabulation sheets and provide assistance to the owner in evaluating bids or proposals and in assembling and awarding contracts for construction, materials, equipment, and services. PHASE 5 20) Preconstruction Conference The Engineer shall attend the preconstruction conference. 21) Construction Survey The Engineer shall be available to the City on matters concerning the layout of the project during its construction and will set control points in the field to allow City survey crews to stake the project. The setting of line and grade stakes and route inspection of construction will be performed by the City. 22) Site Visits The Engineer shall visit the project site at appropriate intervals as construction proceeds to observe and report on the progress and the quality of the executed work. -4- 23) Shop Drawing Review The Engineer shall review shop and erection drawings submitted by the contractor for compliance with design concepts. The Engineer shall review laboratory, shop, and mill test reports on materials and equipment. 24) Instructions to Contractor The Engineer shall provide necessary interpretations and clarifications of contract documents, review change orders and make recommendations as to the acceptability of the work, at the request of the City. 25) ,, Differing Site Conditions The Engineer shall prepare sketches required to resolve problems due to actual field conditions encountered. 26) Record Drawings The Engineer shall prepare record drawings from information submitted by the contractor. -5- ATTACHMENT "13" COMPENSATION AND SCHEDULE M-195AR Drainage Area Sanitary Sewer System Rehabilitation and Improvements (Group 7, Contract 4), Part 4 D.O.E. Project No. 2495 Sewer Project No. PS46-070460410320 Ned K. Burleson & Associates, Inc. I. Compensation A. Payment for services will be computed on the basis of Salary Costs times a multiplier of 3.2 to determine the payment due for services. The multiplier is a factor which compensates ENGINEER for fringe benefits, overhead, and profit. B. Payment shall also include Direct Non -Labor Expenses which, in general, in- clude expenses for supplies, transportation, equipment, travel, communication, subsistence and lodging away from home, and similar incidentals. C. The Direct Non -Labor expanses shall be reimbursable at actual invoice cost plus 10% except for living and travel expenses when away from the home office on business connected with the Project. D. Subcontractor cost shall be reimbursed at the actual invoice cost plus 10%. E. Payment for expenses, cost, and services as described in Attachment "A" and Exhibit "B-3" shall not exceed $ 57,962.80. F. Partial payment shall be made monthly, as stipulated on Exhibit B-1, upon receipt of an invoice from the ENGINEER, prepared from the books and records of the ENGINEER outlining the amount of hours worked by each employee, the employee's name and classification, and the employee's salary rate along with itemized charges for any subcontract and reproduction work performed during the period covered by said invoice. Each invoice is to be verified as to its accuracy and compliance with the terms of this contract by an officer of the ENGINEER. Payment according to statements will be subject to certification by the Director of Engineering Department or his authorized representative that such work has been performed. H. Schedule A. Final Phase ll Plans shall be submitted within 240 calendar days after "Notice to Proceed" letter is issued, provided that the CITY responds with timely approval of each submission within 30 days. EXHIBIT "B-1" (SUPPLEMENT TO ATTACHMENT "B") M-195AR Drainage Area Sanitary Sewer System Rehabilitation and Improvements (Group 7, Contract 4) , Part 4 D.O.E. Project No. 2495 Sewer Project No. PS46-070460410320 Ned K. Burleson & Associates, Inc. Method of Payment Partial payment shall be made monthly upon receipt of an invoice from the ENGINEER as stipulated on Item E on Attachment B. The salary rates in Exhibit B-2 do not include the multiplier of 3.2. The ENGINEER shall be paid within 30 days of receipt of the monthly invoice. The aggregate of such monthly partial payment shall not exceed the following: Until satisfactory completion- of Exhibit A-1, Part A, Section 2, hereunder a fee not to exceed 32 percent of the maximum fee. Until satisfactory completion- of Exhibit A-1, Part B, Section 1i, hereunder a fee not to exceed 61 percent of the maximum fee. Until satisfactory completion- of Exhibit A-1, Part B, Section 2, hereunder a fee not to exceed 83 percent of the maximum fee. Balance of earnings are due and payable after City approval of the Engineer's Post - Construction Report. Progress Report A. The ENGINEER shall submit to the designated representative of Director of the Department of Engineering monthly progress reports covering all phases of design by the 150' of every month in the format required by the CITY. If the ENGINEER fails to submit the monthly report by the 15"' of the month, a time charge shall be made for each working day thereafter, not as a penalty but as liquidated damages. The ENGINEER shall pay liquidated damages of Two Hundred Dollars ($200.00) per day for non-compliance. B. If the ENGINEER determines in the course of making design drawings and specifications that the construction cost estimate of $ 546,705.50 (as estimated on Exhibit "B-5") will be exceeded, whether by change in the scope of the project, increased costs or other conditions, the ENGINEER shall immediately report such fact to the CITY'S Director of Engineering and, if so instructed by the Director of the Department of Engineering, shall suspend all work hereunder. EB1-1 EXHIBIT "B-2" (SUPPLEMENT TO ATTACHMENT "B") HOURLY RATE SCHEDULE M-195AR Drainage Area Sanitary Sewer System Rehabilitation and Improvements (Group 7, Contract 4) , Part 4 D.O.E. Project No. 2495 Sewer Project No. PS46-070460410320 Ned K. Burleson & Associates, Inc. Job Classification Hourly Rate Principal $ 35.00 Senior Engineer/Project Manager $ 25.0Q Project Engineer $ 20.00 Staff Engineer $ 12.00-18.00 Draftsman/Technician $ 9.00-15.00 Clerical $ 10.00 EB2-1 EXHIBIT "B -3A" (SUPPLEMENT TO ATTACHMENT "B") SUMMARY OF DESIGN FEE M-195AR Drainage Area Sanitary Sewer System Rehabilitation and Improvements (Group 7, Contract 4) , Part 4 D.O.E. Project No. 2495 Sewer Project No. PS46-070460410320 Ned K. Burleson & Associates, Inc. The proposed work will be completed in accordance with the following fee schedule: Proposed Fee: 1. Engineering Cost, Design Phase $ 39,362.80 • Preliminary Opinion of Probable Cost: $ 546,705.50 • Curve A Fee: 7.2% of Construction Cost 2. H.M.A.C. Surface Overlay - Plans & Specs. 3. Public Meetings, including exhibits 4. Design Surveys (M/WBE = 17.25%) 5. Sub -Consultant Fee 6. Construction Services 7. Reproduction '(estimate at 15 sheets per plan) • 16 Sets, Prelim. Plans (Utility Clearance) $ 350.00 • 40 Sets of Construction Plans 850.00 • 40 Sets of Specifications ($30 each) 1,200.00 • Mounted Exhibits 500.00 • Miscellaneous Printing (6 sets, other misc.) 200.00 1,000.00 1,000.00 10,000.00 1,000.00 2,500.00 3,100.00 $ 57,962.80 We will be using Brown & Maclin Consultants, Inc., for design survey services for a total M/WBE participation of 17.25%. EB3A-1 EXHIBIT "B-4" (SUPPLEMENT TO ATTACHMENT "B") LISTING OF HOURS FOR EACH ACTIVITY FOR DIFFERENT LEVELS OF THE DESIGN WORK M-195AR Drainage Area Sanitary Sewer System Rehabilitation and Improvements (Group 7, Contract 4) , Part 4 D.O.E. Project No. 2495 Sewer Project No. PS46-070460410320 Ned K. Burleson & Associates, Inc. 1. Utility Research and Concept Plan Senior Engineer/PM 16 hrs. @ $25.00 x 3.2 = $1,280.00 Project Engineer 24 hrs. @ $20.00 x 3.2 = $1,536.00 Staff Engineer 40 hrs. @ $17.00 x 3.2 = $2,176.00 Draftsman/Technician 20 hrs. @ $12.00 x 3.2 = $768.00 Clerical 24 hrs. @ $10.00 x 3.2 = $768.00 2. Preliminary Engineering Senior Engineer/PM 20 hrs. @ $25.00 x 3.2 = $1,600.00 Project Engineer 40 hrs. @ $20.00 x 3.2 = $2,560.00 Staff Engineer 48 hrs. @ $17.00 x 3.2 = $2,611.20 Draftsman/Technician 200 hrs. @ $12.00 x 3.2 = $7,680.00 Clerical 16 hrs. @ $10.00 x 3.2 = $512.00 3. Final Plans Senior Engineer/PM 12 hrs. @ $25.00 x 3.2 = $960.00 Project Engineer 24 hrs. @ $20.00 x 3.2 = $1,536.00 Staff Engineer 40 hrs. @ $17.00 x 3.2 = $2,176.00 Draftsman/Technician 100 hrs. @ $12.00 x 3.2 = $3,840.00 Clerical 20 hrs. @ $10.00 x 3.2 = $640.00 4. Final Plans and Preparation for Advertisement Senior Engineer/PM 8 hrs. @ $25.00 x 3.2 = $640.00 Project Engineer 16 hrs. @ $20.00 x 3.2 = $1,024.00 Staff Engineer 16 hrs. @ $17.00 x 3.2 = $870.40 Draftsman/Technician 24 hrs. @ $12.00 x 3.2 = $921.60 Clerical 40 hrs. @ $10.00 x 3.2 = $1,280.00 5. Administration and Miscellaneous Expenses Principal Project Manager Clerical Miscellaneous Expenses 20 hrs. @ $35.00 x 3.2 = 8 hrs. @ $20.00 x 3.2 = 35 hrs. @ $10.00 x 3.2 = Total Engineering Fee for Construction Design $2,240.00 $512.00 $1,120.00 $111.60 $6,528.00 $14,963.20 $9,152.00 $4,736.OO $3,983.60 $39,362.80 EB4-1 EXHIBIT "B-5" (SUPPLEMENT TO ATTACHMENT "B") OPINION OF PROBABLE CONSTRUCTION COST M-195AR- Drainage Area Sanitary Sewer System Rehabilitation and Improvements (Group 7, Contract 4) , Part 4 D.O.E. Project No. 2495 Sewer Project No. PS46-070460410320 Ned K. Burleson & Associates, Inc. Pay Approx. Unit Total Item Quantity Description of Pay items Price Price 1 5,115 LF 8" PVC San. Sewer (All Depths) 28.00 143,220.00 2 200 LF 8" Class 51 D.I.P. San. Sewer (All Depths) 35.00 7,000.00 3 130 Each 4" Service Reconnect 250.00 32,500.00 4 10 Each 6" Service Reconnect 300.00 3,000.00 5 13 Each Remove Existing Manhole 300.00 3,900.00 6 15 Each Standard 4' Dia. Manhole 1,800.00 27,000,00 7 3 Each Std. 4' Dia. Drop Manhole 2,200.00 6,600.00 8 50 VF Extra Depth in Manholes 200.00 10,000.00 9 650 LF 4" Sewer Lateral 18.00 11,700.00 10 200 LF 6" Sewer Lateral 22.00 4,400.00 11 18 Each Concrete Collars at SS Manholes 250.00 4,500.00 12 18 Each Watertight Gasketed MH Inserts 150.00 2,700.00 13 18 Each Vacuum Testing of SS Manholes 150.00 2,700.00 14 5,315 LF Post -Construction TV Inspection 2.00 10,630.00 15 5,965 LF Pavement Repair 35.00 208,775.00 16 200 SF Grass Sodding 12.00 2,400.00 17 100 LF Curb and Gutter Replacement 30.00 3,000.00 18 10 CY Type "B" Backfill for Misc. Placement 10.00 100.00 19 10 CY Class "B" Concrete for Misc. Placement 40.00 400.00 20 10 CY Class "E" Concrete for Misc. Placement 30.00 300.00 21 10 CY Crushed Limestone for Misc. Placement 25.00 250.00 22 5,965 LF Trench Safety Program 2.00 11,930.00 Subtotal $ 497,005.00 10% Contingencies $ 49,700.50 Preliminary Estimated Construction Costs $ 546,705.50 EB5-1 ATTACHMENT "C" CHANGES AND AMENDMENTS TO STANDARD AGREEMENT AND ATTACHMENT A NONE ATTACHMENT D PROJECT SCHEDULE BAR GRAPH AND TABLE OF TARGET DATES M-1 95AR Drainage Area Sanitary Sewer System Rehabilitation and Improvements (Group 7, Contract 4) , Part 4 D.O.E. Project No. 2495 Sewer Project No. PS46-070460410320 TASK DESCRIPTION PROJECTED ACTUAL START FINISH DURATION* START FINISH DURATION* PHASE II Notice to Proceed May 19, 1999 Conceptual Design and Survey May 19, 1999 June 9, 1999 15 Review Concept Design June 9, 1999 June 9, 1999 1 Preliminary Design June 10, 1999 July 22, 1999 30 Review Preliminary Design July 23, 1999 August 20, 1999 20 Final Design August 23, 1999 September 13,1999 15 Review Final Design September 14, 1999 October 12, 1999 20 Prepare for Advertisement October 13, 1999 October 21, 1999 6 Advertise October 22, 1999 November 18, 1999 20 Award November 19, 1999 January 14, 2000 60 Construction January 17, 2000 July 16, 2000 120 Final Inspection & Acceptance July 17, 2000 August 17, 2000 20 * Number of Days 5 = 5 working day week 20 = I working month 4 9 m m HANWLN 9 ILR' - _•` — _._ .. r '� + �� ODESSA a ; N h'PARK WABASH RIDG tT.:. lECREEK CO • ' ROTUND UTUN y JUNETTE R R RECTOR RE I K UNIVERSITY yi DR �'rry. ROTUND ( ' � JJOy COCKRELL AV $ N �e1 „r0 a n Tp e� GREENE AVE •+ KRCLL O�KREImI SAVE : ? C WATT p a m O 4i REEVE AVE Cg a Gge FE 1. t s x 2 n WAITS AVE Al' 'Sil 4s z •(� a O AVE n n I CSo ,y WAITS GY TA .} T Al' 'p LUBBOCK ^+ AVE K '^ 9 mLUBBOCK V �^ p,� LUBBOCK " AVE O 0 :��y`- f•>'C D MERIDA AVE w c>i Z N MERIDA e . NNIE GgCRr SANDAGE ST A 0 y a SANDAGE 4,."T,. RT ST o 2 MC CART No AYSIDE a p a DR p c m fOREST IRANDELL , RANDELL WAYSIDE C •v ' WAYSIDE ti N y 2 ry- AYSIDE -f ST- •� #fl,. ti �, _. }y„ RAZIER > AVE o m o a FRAZIER tg;k. .;';w,:-,,.. 1Y O TO 3 c RES 1/y� D \! Wys, : • .. . Op 70WNSEND =1 p o 2 o p y TRAZI a a RD v :> ll a •'C FHO a DRJ1. y 2 TOWNSEI by GOR ONNFCR n z TOWNS ND X!:-><; . ~•` ^r't�,.. p AVE z "' N GORDO ,.: fir.;?,CORDON -f t O QO $y N lE ';hsa�W :.:?a: 4a:•:%y:.. is. .. w FAO...': •3 Op N OR ¢- 'G i- :•?'ig::,?.A LIVlNGSTON o 1 s w oE�� g zt�m§:' �` iko-:u�'?kg??.::..:::..•: y � Av i LI n A AH STANLEY a .aF2:$.:- � ': g. ST ��°• : a'•s•; '' '••�ok ;. STANLEY AVE`S•in, STANLEY y AVE 5 JAMES AVEai?a'•. .t :6. :?uc T4 A m • O%. > 7n. t � ..... ?:;" JAMES AVE _ f JAMES=r � JAMES -,AVE z p a n I BASIL ,a.?;2eff>YrJfA;:•, ...,'.kf'.�*'tiv�;:a'?.: ' °'•. m °• . Y:.'r"' . cc#: a'. H ,•:�" S 7H K TH NAVE •mc \ Op •' !�� ,ter;, RYAN -I AVE O n WILLIN ay:k..: • ''?"'•r''s �;3:,�tg: }>. 7f jl;L% a WILLING 2 AVE m NN DW y .� `. :t i1�7 `≥ t ,::r?s; .Y,.:f.:fy,. A n m O {"9•;i.' ;.�5.. ^' 9 T H Al' _ '• ::r r• i..,: n a > :� 2 iH m AVE TH =r A .` 'v`4: -j i+ i f:.Y" 5TH VEr N > m O _f`..\•• st;'.,�Jf`t ::'i¢: -,'"'.'.:: :r' BA DWIN O 0 +": BALDWIN 2 >: O MERIDI7H f+� h¢::i rt, ; .+'=�>?c<≥ k,? HEND SON 2 ST n > HENDERSON ST S ^ "HLNDER ON R,�C D COAOY R r�s` f ? m S ADAMS Si c.o fi:.:;'s., •.rC'8;n;:: .. DAM ST ADAM • ":5:<{• DAMS S7 O AM ST Hi • ;m -,f . ;"::`•f ' ,'w'r₹' > A AM ST UU HTON S i {y: N0 ti ^ o"•r3;c :. ? ?3?: m y COLL GE CO1"LLEGE m 111YBON '" -Ni 4;� 4ir? +: •::;k;.: , COLLEGE ti ; COLLCGE v yM. „"i:` ;E"" k m r>- IIPSCOMB 'r%a�'# .,,�:... p LIPSCOMB ST `•.,:. __AVE\ CTKi y bVIS 'IAVTRAVIS �NEMPHILLST rn I =/ -f � , .. is =r HCMPHIII =r • a: RD :^.f.:•:,5;3.,.y x n z m m O JENNINGS -. A < C / y„. r>.•.;. (ZI m:, k';' % Ny ~ uC i y M.K•T RR 4N 4:1 U z?ss3x zrr. rR: MAY ST - .f C7 ALIC MAY MAY ST LOUIS_vE[A "YS. :.: �Q?.;.. `:�>.t�3::• : :.._ .. ... ::: w.. MAIN f ST 3 S 0 1 AV MICNIGA 2 �: c MAIN c ST i MAINm 57 • TIM TN BRYA tONTp 8 YAN AVE n BRYAN Y mSTUART m DR 2 =. = ONES GROVE s y 4.5 FAI ON SMITH _ ( c Crrrk �g ^ C B pe 2 T ≥MEADEIJ< x i O 8 '�� EVANS AYE m C l g A 7 1y r^O t T ; 0 EVANS Z A 2 AV �p�i m MSSOURf y y N .i)'•.i�iy'ii'::.:` C 'I'. COLE ', ? ABNEY CONROY x ! tftY! FAIR 3 PARK 1 * RLIN 2 • OA'UA• � m WHI EN AO Oti '^V : ci OU'CK01U Y }•IOaO g` �\ x y m R BERKE; � a8 RKE ^; >••�~'' C ,yT� 2 BANDY T 1• //J ' �n�. •` 3 .: A ...;`,:•.'�.�� 'g'� � q0 � la "' x Q � � m � �� y �''� T''�C�frJE MANSEII ra/ s.3;�, • ee'':;.' „,. ;:•;, �.,, S NBERGC $i > •e onMA . N / �?Y>n,5i.t!r.@: _.:Jr•af:dY''.<Ta•3' j m � � A CD a D C W o n g Q 0) o CD Cl) to OO C ^r IV 0 ccn o A Q i1 ox 0) "'i Z .-« m 0-1 CD Z m "0 C) rn m 0 C Z =' n V) CD0 XJ O) City of Fort Worth, Texas 'Ajar and Council Communication DATE REFERENCE NUMBER LOG NAME PAGE 5/25/99 **C-1 7440 30SHARON 1 of 2 SUBJECT ENGINEERING AGREEMENT WITH NED K. BURLESON & ASSOCIATES, INC. FOR MAIN 195AR DRAINAGE AREA SANITARY SEWER SYSTEM REHABILITATION AND IMPROVEMENTS GROUP 7, CONTRACT 4), PART 4 RECOMMENDATION: It is recommended that the City Council authorize the City Manager to execute an engineering agreement with Ned K. Burleson & Associates, Inc. in the amount of $57,962.80 to prepare plans and specifications for Main 195AR Drainage Area Sanitary Sewer System Rehabilitation and Improvements (Group 7, Contract 4), Part 4. DISCUSSION: The engineering services to be performed under this agreement consist of preparing plans and specifications for the replacement of approximately 5,115 linear feet of sanitary sewer mains. The project is part of the City's Integrated Wet Weather Wastewater Management Program to comply with an administrative order from the U.S. Environmental Protection Agency to eliminate sewer overflows from the City's wastewater collection system. The project is generally bound on the north by Sharondale Street, on the south by Hamsted Street, on the east by Hemphill Street, and on the west by 6th Avenue. Ned K. Burleson & Associates, Inc. proposes to perform the design work for the project for a fee not to exceed $57,962.80 based on established hourly rates. Staff considers this fee to be fair and reasonable for the scope of services proposed. Ned K. Burleson & Associates, Inc. is in compliance with the City's M/WBE Ordinance by committing to 17% M/WBE participation. The City's goal on this project is 17%. The project is located in COUNCIL DISTRICT 6, Mapsco 90V. In addition to the contract amount, $3,000.00 is required for project management by the Department of Engineering. 4 City of Fort Worth, Texas "noor.eind. council Communication. DATE REFERENCE NUMBER LOG NAME PAGE 5/25/99 **C-17440 30SHARON 2 of 2 SUBJECT ENGINEERING AGREEMENT WITH NED K. BURLESON & ASSOCIATES, INC. FOR MAIN 195AR DRAINAGE AREA SANITARY SEWER SYSTEM REHABILITATION AND IMPROVEMENTS (GROUP 7, CONTRACT 4), PART 4 FISCAL INFORMATION/CERTIFICATION: The Finance Director certifies that funds are available in the current budget, as appropriated, of the Commercial Paper -Sewer Fund. MG:j Submitted for City Manager's Office by: Mike Groomer Originating Department Head: A. Douglas Rademaker Additional Information Contact: A. Douglas Rademaker FUND ACCOUNT CENTER AMOUNT CITY SECRETARY 6140 (to) APPROVED CITY COUNCIL h+dY 25 1999 City City of Fort Worrth. Texas 6157 (from) . PS46 531200 070460410320 $57,962.80 6157 City of Fort Worth, Texas 41nagor and Council Communication DATE REFERENCE NUMBER LOG NAME PAGE 5/25/99 **C-17440 30SHARON 1 of 2 SUBJECT ENGINEERING AGREEMENT WITH NED K. BURLESON & ASSOCIATES, INC. FOR MAIN 195AR DRAINAGE AREA SANITARY SEWER SYSTEM REHABILITATION AND IMPROVEMENTS (GROUP 7. CONTRACT 4), PART 4 RECOMMENDATION: It is recommended that the City Council authorize the City Manager to execute an engineering agreement with Ned K. Burleson & Associates, Inc. in the amount of $57,962.80 to prepare plans and specifications for Main 195AR Drainage Area Sanitary Sewer System Rehabilitation and Improvements (Group 7, Contract 4), Part 4. DISCUSSION: The engineering services to be performed under this agreement consist of preparing plans and specifications for the replacement of approximately 5,115 linear feet of sanitary sewer mains. The project is part of the City's Integrated Wet Weather Wastewater Management Program to comply with an administrative order from the U.S. Environmental Protection Agency to eliminate sewer overflows from the City's wastewater collection system. The project is generally bound on the north by Sharondale Street, on the south by Hamsted Street, on the east by Hemphill Street, and on the west by 6th Avenue. Ned K. Burleson & Associates, Inc. proposes to perform the design work for the project for a fee not to exceed $57,962.80 based on established hourly rates. Staff considers this fee to be fair and reasonable for the scope of services proposed. Ned K. Burleson & Associates, Inc. is in compliance with the City's M/WBE Ordinance by committing to 17% M/WBE participation. The City's goal on this project is 17%. The project is located in COUNCIL DISTRICT 6, Mapsco 90V. In addition to the contract amount, $3,000.00 is required for project management by the Department of Engineering. City of Fort Worth, Texas "Affor and .council..Communication DATE REFERENCE NUMBER LOG NAME PAGE 5/25/99 **C-17440 30SHARON 2 of 2 SUBJECT ENGINEERING AGREEMENT WITH NED K. BURLESON & ASSOCIATES, INC. FOR MAIN 1'95AR DRAINAGE AREA SANITARY SEWER SYSTEM REHABILITATION AND IMPROVEMENTS (GROUP 7, CONTRACT 4), PART 4 FISCAL_ INFORMATION/CERTIFICATION: The Finance Director certifies that funds are available in the current budget, as appropriated, of the Commercial Paper -Sewer Fund. MG:] Submitted for City Manager's Office by: Mike Groomer 6140 Originating Department Head: A. Douglas Rademaker 6157 Additional Information Contact: A. Douglas Rademaker 6157 FUND ` I ACCOUNT ;o)` (from) PS46 I 531 CENTER I AMOUNT 070460410320 I $57,962.80 CITY SECRETARY APPROVED CITY COUNCIL MAY 25 1999 • City Secretary of the Cit of Fort Worth, Texas