HomeMy WebLinkAboutContract 29432 CITY SECRETARY rY�
CONTRACT NO. 43��
FORT WORTH TRANSPORTATION AUTHORITY AND
CITY OF FORT WORTH, TEXAS
JOINT AGREEMENT FOR PLANNING, DESIGN, AND ENGINEERING SERVICES
This AGREEMENT is between the Fort Worth Transportation Authority (the "T")
and the City of Fort Worth (the "CITY"), acting jointly, and Turner Collie & Braden Inc.,
(the "CONSULTANT"), for a PROJECT generally described as: Planning, Urban Design,
and Engineering Services for the Hyde Park Transit Plaza.
Article I
Scope of Services
A. The Scope of Services is set forth in Attachment A.
Exhibit A-1, Supplemental Scope of Services shall be revised as
appropriate and agreed to by the T, the CITY, and the CONSULTANT after
the completion of "Phase 1: Conceptual Design" so as to accurately reflect
the "Phase 2: Final Design" services required to fully develop the elements
of the approved 30 percent conceptual plan.
Article II
Compensation
A. The CONSULTANT's compensation is set forth in Attachment B.
Attachment B, Compensation and Schedule, shall be revised as
appropriate and agreed to by the T, the CITY, and the CONSULTANT after
the completion of "Phase 1: Conceptual Design" so as to accurately reflect
the "Phase 2: Final Design" compensation and schedule required to fully
develop the elements of the approved 30 percent conceptual plan.
Article III
Terms of Payment
Payments to the CONSULTANT will be made as follows:
A. Invoice and Payment
(1) The CONSULTANT shall provide the T sufficient documentation to
reasonably substantiate the invoices.
(2) The CONSULTANT will issue monthly invoices for all work performed under
this AGREEMENT. Invoices are due and payable within 30 days of receipt.
(3) Upon completion of services enumerated in Article I, the final pE yrr)ent pf
16:e 1 `"Art : _. ....
any balance will be due within 30 days of receipt of the final invoice.
(4) In the event of a disputed or contested billing, only that portion so contested
will be withheld from payment, and the undisputed portion will be paid. The
T and the CITY will exercise reasonableness in contesting any bill or portion
thereof. No interest will accrue on any contested portion of the billing until
mutually resolved.
(5) If the T fails to make payment in full to CONSULTANT for billings contested
in good faith within 60 days of the amount due, the CONSULTANT may,
after giving 7 days' written notice to T, suspend services under this
AGREEMENT until paid in full, including interest. In the event of
suspension of services, the CONSULTANT shall have no liability to the T or
the CITY for delays or damages caused the T or the CITY because of such
suspension of services.
Article IV
Obligations of the CONSULTANT
Amendments to Article IV, if any, are included in Attachment C.
A. General
The CONSULTANT will serve as professional design and engineering
representative for the T and the CITY under this Agreement, providing professional
design and engineering consultation and advice and furnishing customary services
incidental thereto.
B. Standard of Care
The standard of care applicable to the CONSULTANT's services will be the degree
of skill and diligence normally employed in the State of Texas by professional
engineers or consultants performing the same or similar services at the time such
services are performed.
C. Subsurface Investigations
(1) The CONSULTANT shall advise the T and the CITY with regard to the
necessity for subcontract work such as special surveys, tests, test borings,
or other subsurface investigations in connection with design and
engineering work to be performed hereunder. The CONSULTANT shall
also advise the T and the CITY concerning the results of same. Such
surveys, tests, and investigations shall be furnished by the T and the CITY,
unless otherwise specified in Attachment A.
(2) In soils, foundation, groundwater, and other subsurface investigations, the
DESIGN AND ENGINEERING CONTRACT � I �r;i
Page 2 of 31 CatV jury l
CIS
actual characteristics may vary significantly between successive test points
and sample intervals and at locations other than where observations,
exploration, and investigations have been made. Because of the inherent
uncertainties in subsurface evaluations, changed or unanticipated
underground conditions may occur that could affect the total PROJECT cost
and/or execution. These conditions and cost/execution effects are not the
responsibility of the CONSULTANT.
D. Preparation of Engineering Drawings
The CONSULTANT will provide to the T and the CITY the original drawings of all
plans in ink on reproducible plastic film sheets, or as otherwise approved by the T
and the CITY, which shall become the property of the T and the CITY. The T and
the CITY may use such drawings in any manner desired; provided, however, that
the CONSULTANT shall not be liable for the use of such drawings for any project
other than the PROJECT described herein.
E. CONSULTANT's Personnel at Construction Site
(1) The presence or duties of the CONSULTANT's personnel at a construction
site, whether as on-site representatives or otherwise, do not make the
CONSULTANT or its personnel in any way responsible for those duties that
belong to the T or the CITY and/or the T's or the CITY's construction
contractors or other entities, and do not relieve the construction contractors
or any other entity of their obligations, duties, and responsibilities, including,
but not limited to, all construction methods, means, techniques, sequences,
and procedures necessary for coordinating and completing all portions of
the construction work in accordance with the Contract Documents and any
health or safety precautions required by such construction work. The
CONSULTANT and its personnel have no authority to exercise any control
over any construction contractor or other entity or their employees in
connection with their work or any health or safety precautions.
(Z) Except to the extent of specific site visits expressly detailed and set forth in
Attachment A, the CONSULTANT or its personnel shall have no obligation
or responsibility to visit the construction site to become familiar with the
progress or quality of the completed work on the PROJECT or to determine,
in general, if the work on the PROJECT is being performed in a manner
indicating that the PROJECT, when completed, will be in accordance with
the Contract Documents, nor shall anything in the Contract Documents or
the agreement between the T and the CITY and CONSULTANT be
construed as requiring CONSULTANT to make exhaustive or continuous
on-site inspections to discover latent defects in the work or otherwise check
the quality or quantity of the work on the PROJECT. If, for any reason, the
CONSULTANT should make an on-site observation(s), on the basis of such
on-site observations, if any, the CONSULTANT shall endeavor to keep the
T and the CITY informed of any deviation from the Contract Documents
DESIGN AND ENGINEERING CONTRACT
Page 3 of 31 c
coming to the actual notice of CONSULTANT regarding the PROJECT.
(3) When professional certification of performance or characteristics of
materials, systems or equipment is reasonably required to perform the
services set forth in the Scope of Services, the CONSULTANT shall be
entitled to rely upon such certification to establish materials, systems or
equipment and performance criteria to be required in the Contract
Documents.
F. Opinions of Probable Cost, Financial Considerations, and Schedules
(1) The CONSULTANT shall provide opinions of probable costs based on the
current available information at the time of preparation, in accordance with
Attachment A.
(2) In providing opinions of cost, financial analyses, economic feasibility
projections, and schedules for the PROJECT, the CONSULTANT has no
control over cost or price of labor and materials; unknown or latent
conditions of existing equipment or structures that may affect operation or
maintenance costs; competitive bidding procedures and market conditions;
time or quality of performance by third parties; quality, type, management,
or direction of operating personnel; and other economic and operational
factors that may materially affect the ultimate PROJECT cost or schedule.
Therefore, the CONSULTANT makes no warranty that the actual
PROJECT costs, financial aspects, economic feasibility, or schedules will
not vary from the CONSULTANT's opinions, analyses, projections, or
estimates.
G. Construction Progress Payments
Recommendations by the CONSULTANT to the T and the CITY for periodic
construction progress payments to the construction contractor will be based on the
CONSULTANT's knowledge, information, and belief from selective sampling and
observation that -the work has progressed to the point indicated. Such
recommendations do not represent that continuous or detailed examinations have
been made by the CONSULTANT to ascertain that the construction contractor has
completed the work in exact accordance with the Contract Documents; that the
final work will be acceptable in all respects; that the CONSULTANT has made an
examination to ascertain how or for what purpose the construction contractor has
used the moneys paid; that title to any of the work, materials, or equipment has
passed to the T and the CITY free and clear of liens, claims, security interests, or
encumbrances; or that there are not other matters at issue between the T and the
CITY and the construction contractor that affect the amount that should be paid.
H. Record Drawings
Record drawings, if required, will be prepared, in part, on the basis of information
DESIGN AND ENGINEERING CONTRACT
Page 4 of 31
compiled and furnished by others, and may not always represent the exact
location, type of various components, or exact manner in which the PROJECT was
finally constructed. The CONSULTANT is not responsible for any errors or
omissions in the information from others that is incorporated into the record
drawings.
I. Disadvantaged Business Enterprise (DBE) Participation
The T and the CITY have goals for the participation of disadvantaged business
enterprises in contracts. CONSULTANT acknowledges the 25 percent DBE goal
established for this contract and its commitment to meet that goal. Any
misrepresentation of facts (other than a negligent misrepresentation) and/or the
commission of fraud by the CONSULTANT may result in the termination of this
agreement and debarment from participating in T and CITY contracts for a period
of time of not less than three (3) years.
J. Right to Audit
(1) CONSULTANT agrees that the T and the CITY shall, until the expiration of
three (3) years after final payment under this contract, have access to and
the right to examine and photocopy any directly pertinent books,
documents, papers and records of the CONSULTANT involving
transactions relating to this contract. CONSULTANT agrees that the T and
the CITY shall have access during normal working hours to all necessary
CONSULTANT facilities and shall be provided adequate and appropriate
work space in order to conduct audits in compliance with the provisions of
this section. The T and the CITY shall give CONSULTANT reasonable
advance notice of intended audits.
(2) CONSULTANT further agrees to include in all its subconsultant agreements
hereunder a provision to the effect that the subconsultant agrees that the T
and the CITY shall, until the expiration of three (3) years after final payment
under the subcontract, have access to and the right to examine and
photocopy any directly pertinent books, documents, papers and records of
such subconsultant, involving transactions to the subcontract, and further,
that the T and the CITY shall have access during normal working hours to
all subconsultant facilities, and shall be provided adequate and appropriate
work space, in order to conduct audits in compliance with the provisions of
this article together with subsection (3) hereof. The T and the CITY shall
give subconsultant reasonable advance notice of intended audits.
(3) CONSULTANT and subconsultant agree to photocopy such documents as
may be requested by the T and the CITY. The T and the CITY agree to
reimburse CONSULTANT for the cost of copies at the rate published in the
Texas Administrative Code in effect as of the time copying is performed.
K. CONSULTANT's Insurance
DESIGN AND ENGINEERING CONTRACT
Page 5 of 31 �" 1 Zl� �� C_'�•�
(1) Insurance coverage and limits:
CONSULTANT shall provide to -the T and the City certificate(s) of insurance
documenting policies of the following coverage at minimum limits that are to be in
effect prior to commencement of work on the PROJECT:
Commercial General Liability
$1,000,000 each occurrence
$1,000,000 aggregate
Automobile Liability
$1,000,000 each accident (or reasonably equivalent limits of coverage
if written on a split limits basis). Coverage shall be on any vehicle used
in the course of the PROJECT.
Worker's Compensation
Coverage A: statutory limits
Coverage B: $100,000 each accident
$500,000 disease - policy limit
$100,000 disease - each employee
Professional Liability
$1,000,000 each claim/annual aggregate
(2) Certificates of insurance evidencing that the CONSULTANT has obtained
all required insurance shall be delivered to the T and the CITY prior to
CONSULTANT proceeding with the PROJECT.
(a) Applicable policies shall be endorsed to name the T and CITY as
Additional Insured thereon, as its interests may appear. The terms
the T and the CITY shall include employees, officers, officials,
agents, and volunteers for both entities as respects the contracted
services.
(b) Certificate(s) of insurance shall document that insurance coverage
specified according to items section K.(1) and K.(2) of this
agreement are provided under applicable policies documented
thereon.
(c) Any failure on part of the T and the CITY to request required
insurance documentation shall not constitute a waiver of the
insurance requirements.
(d) A minimum of thirty (30) days notice of cancellation or material
change in coverage shall be provided to the T and the CITY. A ten
(10) days notice shall be acceptable in the event of non-payment of
premium. Such terms shall be endorsed onto CON Ts_
DESIGN AND ENGINEERING CONTRACT
Page 6 of 31 _
insurance policies. Notice shall be sent to the respective
Department Director (by name), City of Fort Worth, 1000
Throckmorton Street, Fort Worth, Texas 76102.
(e) Insurers for all policies must be authorized to do business in the
state of Texas or be otherwise approved by the T and the CITY; and,
such insurers shall be acceptable to the T and the CITY in terms of
their financial strength and solvency.
(f) Deductible limits, or self-insured retentions, affecting insurance
required herein shall be acceptable to the T and the CITY; and, in
lieu of traditional insurance, any alternative coverage maintained
through insurance pools or risk retention groups must be also
approved. Dedicated financial resources or letters of credit may also
be acceptable to the T and the CITY.
(g) Applicable policies shall each be endorsed with a waiver of
subrogation in favor of the T and the CITY as respects the
PROJECT.
(h) The T and the CITY shall be entitled, upon its request and without
incurring expense, to review the CONSULTANT's insurance policies
including endorsements thereto and, at the T's and the CITY's
discretion, the CONSULTANT may be required to provide proof of
insurance premium payments.
(i) The Commercial General Liability insurance policy shall have no
exclusions by endorsements unless the T and the CITY approve
such exclusions.
(j) The Professional Liability insurance policy, if written on a claims
made basis shall be maintained by the CONSULTANT for a
minimum two (2) year period subsequent to the term of the
respective PROJECT contract with the T and the CITY unless such
coverage is provided the CONSULTANT on an occurrence basis.
(k) The T and the CITY shall not be responsible for the direct payment
of any insurance premiums required by this agreement. It is
understood that insurance cost is an allowable component of
CONSULTANT's overhead.
(1) All insurance required in section K., except for the Professional
Liability insurance policy, shall be written on an occurrence basis in
order to be approved by the T and the CITY.
(m) Subconsultants to the CONSULTANT shall be required by the
CONSULTANT to maintain the same or reasonably equivalent
DESIGN AND ENGINEERING CONTRACT
Page 7 of 31 .'f
insurance coverage as required for the CONSULTANT. When
subconsultants maintain insurance coverage, CONSULTANT shall
provide -the T and the CITY with documentation thereof on a
certificate of insurance. Notwithstanding anything to the contrary
contained herein, in the event a subconsultant's insurance coverage
is canceled or terminated, such cancellation or termination shall not
constitute a breach by CONSULTANT of the Agreement.
L. Independent Consultant
The CONSULTANT agrees to perform all services as an independent consultant
and not as a subcontractor, agent, or employee of the T or the CITY.
M. Disclosure
The CONSULTANT acknowledges to the T and the CITY that it has made full
disclosure in writing of any existing conflicts of interest or potential conflicts of
interest, including personal financial interest, direct or indirect, in property abutting
the proposed PROJECT and business relationships with abutting property cities.
The CONSULTANT further acknowledges that it will make disclosure in writing of
any conflicts of interest that develop subsequent to the signing of this contract and
prior to final payment under the contract.
N. Asbestos or Hazardous Substances
(1) If asbestos or hazardous substances in any form are encountered or
suspected, the CONSULTANT will stop its own work in the affected portions
of the PROJECT to permit testing and evaluation.
(2) If asbestos or other hazardous substances are suspected, the
CONSULTANT will, if requested, assist the T and the CITY in obtaining the
services of a qualified subcontractor to manage the remediation activities of
the PROJECT.
O. Permitting Authorities - Design Changes
If permitting authorities require design changes so as to comply with published
design criteria and/or current engineering practice standards which the
CONSULTANT should have been aware of at the time this Agreement was
executed, the CONSULTANT shall revise plans and specifications, as required, at
its own cost and expense. However, if design changes are required due to the
changes in the permitting authorities' published design criteria and/or practice
standards criteria which are published after the date of this Agreement which the
CONSULTANT could not have been reasonably aware of, the CONSULTANT
shall notify the T and the CITY of such changes and an adjustment in
compensation will be made through an amendment to this AGREEMENT.
hCulw�
DESIGN AND ENGINEERING CONTRACT {rc��+� �
Page 8 of 31 INV`
�tl�' `�������
Article V
Obligations of the T and the City
Amendments to Article V, if any, are included in Attachment C.
A. T- and City-Furnished Data
The T and the CITY will make available to the CONSULTANT all technical data in
the T's and the CITY's possession relating to the CONSULTANT's services on the
PROJECT. The CONSULTANT may rely upon the accuracy, timeliness, and
completeness of the information provided by the T and the CITY.
B. Access to Facilities and Property
The T and the CITY will make its facilities accessible to the CONSULTANT as
required for the CONSULTANT's performance of its services and will provide labor
and safety equipment as required by the CONSULTANT for such access. The T
and the CITY will perform, at no cost to the CONSULTANT, such tests of
equipment, machinery, pipelines, and other components of the T's and the CITY's
facilities as may be required in connection with the CONSULTANT's services. The
T and the CITY will be responsible for all acts of the T's and the CITY's personnel.
C. Advertisements, Permits, and Access
Unless otherwise agreed to in the Scope of Services, the T and the CITY will
obtain, arrange, and pay for all advertisements for bids; permits and licenses
required by local, state, or federal authorities; and land, easements, rights-of-way,
and access necessary for the CONSULTANT's services or PROJECT
construction.
D. Timely Review
The T and the CITY will examine the CONSULTANT's studies, reports, sketches,
drawings, specifications, proposals, and other documents; obtain advice of an
attorney, insurance counselor, accountant, auditor, bond and financial advisors,
and other consultants as the T and the CITY deem appropriate; and render in
writing decisions required by the T and the CITY in a timely manner in accordance
with the project schedule in Attachment B.
E. Prompt Notice
The T and the CITY will give prompt written notice to the CONSULTANT whenever
the T and the CITY observe or become aware of any development that affects the
scope or tinning of the CONSULTANT's services or of any defect in the work of the
CONSULTANT or construction contractors.
DESIGN AND ENGINEERING CONTRACT
Page 9 of 31
�' ICl � '.
�� ygf(lu] 1T
F. Asbestos or Hazardous Substances and Indemnification
(1) To the maximum extent permitted by law, the T and the CITY will indemnify
and release CONSULTANT and its officers, employees, and subcontractors
from all claims, damages, losses, and costs, including, but not limited to,
attorney's fees and litigation expenses arising out of or relating to the
presence, discharge, release, or escape of hazardous substances,
contaminants, or asbestos on or from the PROJECT. Nothing contained
herein shall be construed to require the T and the CITY to levy, assess or
collect any tax to fund this indernnification.
(2) The indemnification and release required above shall not apply in the event
the discharge, release or escape of hazardous substances, contaminants,
or asbestos is a result of CONSULTANT'S negligence or if such hazardous
substance, contaminant or asbestos is brought onto the PROJECT by
CONSULTANT.
G. Contractor Indemnification and Claims
The T and the CITY agree to include in all construction contracts the provisions of
Article IV.E. regarding the CONSULTANT's Personnel at Construction Site, and
provisions providing contractor indemnification of the T and the CITY and the
CONSULTANT for contractor's negligence.
H. Contractor Claims and Third-Party Beneficiaries
(1) The T and the CITY agree to include the following clause in all contracts
with construction contractors and equipment or materials suppliers:
"Contractors, subcontractors and equipment and materials
suppliers on the PROJECT, or their sureties, shall maintain
no direct action against the CONSULTANT, its officers,
employees, and subcontractors, for any claim arising out
of, in connection with, or resulting from the engineering
services performed. Only the T (CITY) will be the
beneficiary of any undertaking by -the CONSULTANT."
(2) This AGREEMENT gives no rights or benefits to anyone other than the T,
the CITY and the CONSULTANT and there are no third-party beneficiaries.
(3) The T and the CITY will include in each agreement it enters into with any
other entity or person regarding the PROJECT a provision that such entity
or person shall have no third-party beneficiary rights under this Agreement.
(4) Nothing contained in this section V.H. shall be construed as a waiver of any
right the T and the CITY have to bring a claim against CONSULTANT.
DESIGN AND ENGINEERING CONTRACT
NP
Page 10 of 31
I. T's and CITY's Insurance
(1) The T and the CITY may maintain property insurance on certain pre-
existing structures associated with the PROJECT.
(2) The T and the CITY will ensure that Builders Risk/installation insurance is
maintained at the replacement cost value of the PROJECT. The T and the
CITY may provide CONSULTANT a copy of the policy or documentation of
such on a certificate of insurance.
(3) The T and the CITY will specify that the Builders Risk/Installation insurance
shall be comprehensive in coverage appropriate to the PROJECT risks.
J. Litigation Assistance
The Scope of Services does not include costs of the CONSULTANT for required
or requested assistance to support, prepare, document, bring, defend, or assist in
litigation undertaken or defended by the T and the CITY. In the event the T and the
CITY request such services of the CONSULTANT, this AGREEMENT shall be
amended or a separate agreement will be negotiated between the parties.
K. Changes
The T and the CITY may make or approve changes within the general Scope of
Services in this AGREEMENT. If such changes affect the CONSULTANT's cost or
time required for performance of the services, an equitable adjustment will be
made through an amendment to this AGREEMENT with appropriate T and CITY
approval.
Article VI
General Legal Provisions
Amendments to Article VI, if any, are included in Attachment C.
A. Authorization to Proceed
CONSULTANT shall be authorized to proceed with this AGREEMENT upon
receipt of a written Notice to Proceed from the T and the CITY.
B. Reuse of Project Documents
All designs, drawings, specifications, documents, and other work products of the
CONSULTANT, whether in hard copy or in electronic form, are instruments of
service for this PROJECT, whether the PROJECT is completed or not. Reuse,
change, or alteration by the T and the CITY or by others acting through or on
behalf of the T and the CITY of any such instruments of service without the written
DESIGN AND ENGINEERING CONTRACT
Page 11 of 31 '
permission of the CONSULTANT will be at the T and the CITY's risk. The final
designs, drawings, specifications and documents shall be owned by the T and the
CITY.
C. Force Majeure
The CONSULTANT is not responsible for damages or delay in performance
caused by acts of God, strikes, lockouts, accidents, or other events beyond the
control of the CONSULTANT.
D. Termination
(1) This AGREEMENT may be terminated only by the T and the CITY for
convenience on 30 days' written notice. This AGREEMENT may be
terminated by either the T, the CITY or the CONSULTANT for cause if any
party fails substantially to perform through no fault of the other and does not
commence correction of such nonperformance with 5 days of written notice
and diligently complete the correction thereafter.
(2) If this AGREEMENT is terminated for the convenience of the T and the City,
the CONSULTANT will be paid for termination expenses as follows:
a.) Cost of reproduction of partial or complete studies, plans,
specifications or other forms of CONSULTANT'S work product;
b.) Out-of-pocket expenses for purchasing storage containers,
microfilm, electronic data files, and other data storage supplies or services,-
c.)
ervices;c.) The time requirements for the CONSULTANT'S personnel to
document the work underway at the time the T and the CITY'S termination
for convenience so that the work effort is suitable for long time storage.
(3) Prior to proceeding with termination services, the CONSULTANT will submit
to the T and the CITY an itemized statement of all termination expenses. The T's
and the CITY'S approval will be obtained in writing prior to proceeding with
termination services.
E. Suspension, Delay, or Interruption to Work
The T and the CITY may suspend, delay, or interrupt the services of the
CONSULTANT for the convenience of the T and the CITY. In the event of such
suspension, delay, or interruption, an equitable adjustment in the PROJECT's
schedule, commitment and cost of the CONSULTANT's personnel and
subcontractors, and CONSULTANT's compensation will be made.
F. Indemnification
DESIGN AND ENGINEERING CONTRACT
Page 12 of 31
(1) The CONSULTANT agrees to indemnify and defend the T and the CITY
from any loss, cost, or expense claimed by third parties for property
damage and bodily injury, including death, caused solely by the negligence
or willful misconduct of the CONSULTANT, its employees, officers, and
subcontractors in connection with the PROJECT.
(2) If the negligence or willful misconduct of both the CONSULTANT, the T,
and the CITY (or a person identified above for whom each is liable) is a
cause of such damage or injury, the loss, cost, or expense shall be shared
between the CONSULTANT, the T, and the CITY in proportion to their
relative degrees of negligence or willful misconduct as determined pursuant
to T.C.P. & R. Code, section 33.011(4) (Vernon Supplement 1996).
G. Assignment
Neither party shall assign all or any part of this AGREEMENT without the prior
written consent of the other party.
H. Interpretation
Limitations on liability and indemnities in this AGREEMENT are business
understandings between the parties and shall apply to all the different theories of
recovery, including breach of contract or warranty, tort including negligence, strict
or statutory liability, or any other cause of action, except for willful misconduct or
gross negligence for limitations of liability and sole negligence for indemnification.
Parties mean the T, the CITY, and the CONSULTANT, and their officers,
employees, agents, and subcontractors.
I. Jurisdiction
The law of the State of Texas shall govern the validity of this AGREEMENT, its
interpretation and performance, and any other claims related to it. The venue for
any litigation related to this AGREEMENT shall be Tarrant County, Texas.
J. Alternate Dispute Resolution
(1) All claims, disputes, and other matters in question between the T, the CITY
and CONSULTANT arising out of, or in connection with this Agreement or
the PROJECT, or any breach of any obligation or duty of the T, the CITY or
CONSULTANT hereunder, will be submitted to mediation. If mediation is
unsuccessful, the claim, dispute or other matter in question shall be
submitted to arbitration if both parties acting reasonably agree that the
amount of the dispute is likely to be less than $50,000, exclusive of
attorney's fees, costs and expenses. Arbitration shall be in accordance with
the Construction Industry Arbitration Rules of the American Arbitration
Association or other applicable rules of the Association then in effect. Any
award rendered by the arbitrators less than $50,000, exclusive of attorney's
DESIGN AND ENGINEERING CONTRACT r..z
Page 13 of 31 jL�:^��
fees, costs and expenses, will be final, judgment may be entered thereon in
any court having jurisdiction, and will not be subject to appeal or
modification except to the extent permitted by Sections 10 and 11 of the
Federal Arbitration Act (9 U.S.C. Sections 10 and 11).
(2) Any award greater than $50,000, exclusive of attorney's fees, costs and
expenses, may be litigated by either party on a de novo basis. The award
shall become final ninety (90) days from the date same is issued. If litigation
is filed by either party within said ninety (90) day period, the award shall
become null and void and shall not be used by either party for any purpose
in the litigation.
K. Severability and Survival
If any of the provisions contained in this AGREEMENT are held for any reason to
be invalid, illegal, or unenforceable in any respect, such invalidity, illegality, or
unenforceability will not affect any other provision, and this AGREEMENT shall be
construed as if such invalid, illegal, or unenforceable provision had never been
contained herein. Articles V.F., VI.B., VI.D., VI.H., VI.I., and VI.J. shall survive
termination of this AGREEMENT for any cause.
L. Observe and Comply
CONSULTANT shall at all times observe and comply with all federal and State
laws and regulations and with all local ordinances and regulations which in any
way affect this AGREEMENT and the work hereunder, and shall observe and
comply with all orders, laws ordinances and regulations which may exist or may be
enacted later by governing bodies having jurisdiction or authority for such
enactment. No plea of misunderstanding or ignorance thereof shall be considered.
CONSULTANT agrees to defend, indemnify and hold harmless the T and the
CITY and all T and CITY officers, agents and employees -from and against all
claims or liability arising out of the violation of any such order, law, ordinance, or
regulation, whether it be by itself or its employees.
Article VII
Attachments, Schedules, and Signatures
This AGREEMENT, including its attachments and schedules, constitutes the entire
AGREEMENT, supersedes all prior written or oral understandings, and may only be
changed by a written amendment executed by both parties. The following attachments
and schedules are hereby made a part of this AGREEMENT:
Attachment A - Scope of Services
Attachment B - Compensation
Attachment C - Amendments to Agreement for Planning, Design, and Engineering
Services
DESIGN AND ENGINEERING CONTRACT
Page 14 of 31 -
ATTEST: FORT WORTH
TRANPORTATION AUTHORITY
Gloria Pearson Ri and L. Ruddell
City Secretary President/Executive Director
APPROVED AS TO FORM CITY OF FORT WORTH
AND LEMA
Cynthia 6arcia Charles Boswell
Assistant City Attorney Assistant City Manager
ATTEST: TURNER COLLIE & BRADEN,
INC.
Ann Kovich
10 Associate Vice President
Contract Authorization
r
Aa€e
DESIGN AND ENGINEERING CONTRACT OFFICIAL WjuA::,
Page 16 of 31 CIS 13.
r,
Executed this the day of , 20
(REMAINDER OF PAGE INTENTIONALLY LEFT BLANK)
DESIGN AND ENGINEERING CONTRACT
Page 15 of 31 - -- -
ATTACHMENT A
GENERAL SCOPE OF SERVICES
"Scope of Services set forth herein can only be modified by additions,
clarifications, and/or deletions set forth in the supplemental Scope of Services. In
cases of conflict between the Supplemental Scope of Services and the General
Scope of Services, the Supplemental Scope of Services shall have precedence
over the General Scope of Services."
GENERAL
1) Preliminary Conference with City and the T
The Consultant shall attend preliminary conferences with authorized
representatives of the City and the T regarding the scope of project so that
the plans and specifications which are to be developed hereunder by the
Consultant will result in providing facilities which are economical in design
and conform to the City's and the T's requirements and budgetary
constraints.
2) Coordination with Outside Agencies/Public Entities
The Consultant shall coordinate with officials of other outside agencies as
may be necessary for the design of the proposed improvements. It shall be
the Consultant's duty hereunder to secure necessary information from such
outside agencies, to meet their requirements.
3) Agreements and Permits
The Consultant shall complete all forms/applications to allow the City of Fort
Worth and the T to obtain any and all agreements and/or permits normally
required for a project of this size and type. The Consultant will be
responsible for negotiating and coordinating to obtain approval of the
agency issuing the agreement and/or permits and will make any revisions
necessary to bring the plans into compliance with the requirements of said
agency, including but not limited to highways, railroads, water authorities,
Corps of Engineers and other utilities.
4) Design Changes Relating to Permitting Authorities
If permitting authorities require design changes, the Consultant shall revise
the plans and specifications as required at the Consultant's own cost and
expense, unless such changes are required due to changes in the design of
the facilities made by the permitting authority. If such changes are required,
the Consultant shall notify the City and the T and an amendment to the
DESIGN AND ENGINEERING CONTRACT
Page 17 of 31
contract shall be made if the Consultant incurs additional cost. If there are
unavoidable delays, a mutually agreeable and reasonable time extension
shall be negotiated.
5) Plan Submittal
Copies of the original plans shall be provided on reproducible mylar or
approved plastic film sheets, or as otherwise approved by the City's
Department of Engineering and the T, and shall become the property of the
City and the T. The City and the T may use such drawings in any manner it
desires; provided, however that the Consultant shall not be liable for the use
of such drawings for any project other than the project described herein;
and further provided, that the Consultant shall not be liable for the
consequences of any changes that are made to the drawings or changes
that are made in the implementation of the drawings without the written
approval of the Consultant.
CITY
DESIGN AND ENGINEERING CONTRACTa^p^ tP "
Page 18 of 31 I
EXHIBIT A-1
SUPPLEMENTAL SCOPE OF SERVICES
(SUPPLEMENT TO ATTACHMENT A)
Hyde Park Transit Plaza and Related Improvements
Hyde Park Limits of Project:
For conceptual design (up to 15%):
• Both sides of Houston Street from Tenth Street Pedestrian Mall north to
the intersection of Ninth Street;
• Jennings Street from Texas Street to Tenth Street, including the east
fagade of City Hall;
• Tenth Street from Monroe Street to Jennings Street, including the north
fagade of City Hall, the north plaza of City Hall (City Hall Plaza), and the
public right-of-way (ROW) along the north side of Tenth Street;
• John Peter Smith Park;
• Tenth Street Pedestrian Mall (pedestrian easement only);
• "Edge" walls for Hyde Park: SBC building, Federal building, and parking
garage on the north side of Hyde Park, and
• Areas designated below for design to 30%.
For conceptual design (up to 30%):
• Hyde Park Transit Plaza, bounded by the northern ROW of the realigned
Ninth Street to the north, Throckmorton Street to the west, Houston Street
to the east, and the southern boundary of Old Hyde Park to the south;
• Realigned portion of Ninth Street between Houston and Throckmorton
Streets; and
• Intersection of Tenth, Throckmorton, and Jennings Streets, including west
side of Throckmorton, east and west side of Jennings and north and south
side of Tenth Street.
For design beyond 30%:
• All areas included in the 30% conceptual design as listed above, and
other areas as designated in the preferred design alternative developed
under this scope of work.
A. Concept Design
Al. Background
Ala. Kick-off Conference: Attend a kick-off conference with City and T
staff to review requirements, visit the site, review available material, and discuss
scheduling.
�: 1..
DESIGN AND ENGINEERING CONTRACT r+ r,
Page 19 of 31 CIrk;7 f SIC,ii ?,,
Al b. Additional Meetings: Attend two (2) additional meetings with Federal
Transit Administration officials and utility providers (City and franchise utilities).
Al c. Research and Site Urban Design Analysis: Research site features,
existing conditions at public buildings and private property for property line
verification and potential basement incursions beyond property lines. Research
historic features and other thematic information that may affect site development.
Research adjacent property ownership, existing plans for roadways, drainage,
and utilities. Contact franchise utilities and request plans of their facilities within
-the project limits.
Following a site visit, prepare a broad, conceptual visual and urban design
analysis of the study area. This analysis will be done using AutoCAD-based
plans provided by the Client. Prepare a 30"x40" colored board with text,
diagrams and photographs.
A1d. Topographic Survey & Right-of-Way Documents: Identify and locate
physical features within the project limits. Features located shall be identified on
the plans and shall include right-of-way limits, sidewalks, curbing, landscaping,
utilities, traffic patterns, traffic signals, and lighting.
Prepare realignment survey for realigned Ninth Street.
Ale. Geotechnical Investigation: Take soil borings and make
recommendations for stabilization of the pavement subgrade.
A2. Meetings and Briefings
A2a. Staff Review of 15% Alternatives: Present the two 15% alternative
concept designs to the staff.
A2b. Advisory Committee Review of 15% Plans: Present the two 15%
alternative concept designs to the advisory committee to finalize 15% alternative
concepts and to determine which alternative will be taken forward to the 30%
conceptual design phase.
A2(a)b. Public Art Charette: Participate in a two-day public art charette
coordinated by the Arts Commission with selected artists.
A2c. Staff 30% Review: Present final 30% conceptual design to staff.
A2d. Prepare and Conduct One (1) Public Stakeholder Meeting at the
30% Design Stage: Develop a stakeholder database for the distribution of
meeting notifications. Information for the database will be compiled from the
City, the T, and other mailing lists to include interested parties and groups.
I
DESIGN AND ENGINEERING CONTRACTP
Page 20 of 31 Z4 a 'Mu YEN.,.
Prepare for and conduct 30% Public Meeting. The purpose of this meeting is to
present the 30% design and to facilitate review and input by the general public.
A2e. Advisory Committee Review of 30% Conceptual Design: Present the
final 30% conceptual design to the advisory committee and determine which
elements will be taken forward into final design.
A3. Develop Conceptual Design Plans
A3a. Programming: The consultant team will prepare alternative programs
for utilization of the public space and will make programming assumptions for the
design interface with each of the surrounding or abutting properties.
Formulate transit requirements, operational requirements and policies and
degree of flexibility of transit-related structures for both bus and streetcar
movements. Conduct programming analysis through work sessions and
interviews with key stakeholders, technical staff, and GSA representatives.
Prepare a program statement that outlines the urban design approach and
improvements that should be incorporated in the schematic (15%) design.
A3b. Coordination: Meet with the City Transportation and Public Works
Department officials and T staff during conceptual design to determine the list of
improvements and/or modifications of traffic patterns that will be built in the 15%
concept design plan. These coordination meetings are also aimed at gathering
information about private sector development plans.
Meet with City Water Department staff during the concept design phase to
determine list of improvements and/or modifications to water/sanitary sewer lines
requested by the Water Department. Fee for design of requested improvements
will be provided in a supplemental authorization request.
Coordinate definition of urban design, landscape and architectural components
with multiple stakeholders. Define design issues to be addressed in the
preparation of project design plans. Integrate project research and programming
results into baseline understanding of project parameters.
A3c. Alternative Site and Architectural Plans — 15% Design: Prepare a
maximum of two (2) alternative site plans for development of the Hyde Park
Transit Plaza. Each site plan will depict alternative design solutions shown in a
30"x40" format that will depict illustrative details for sidewalks, landscape, lighting
and other urban design features. An additional 30"x40" board will include an eye-
level perspective of the site and, if appropriate, an axonometric drawing and
annotated cross sections.
Develop two alternatives for architectural elements to include a transit transfer
DESIGN AND ENGINEERING CONTRACT :yi5-.L1L
Page 21 0131 CJ711 l
�: .IL
facility concept, transit shelter concept, and other site elements. Develop two
alternatives for other architectural site elements, including a vertical element at
the intersection of the Ninth Street and Jennings Street view corridors, facade
walls, and entry features. The two concepts will be provided in a drawing format:
front and side elevation (scaled to patron/vehicle), plan insert within overall site
plan, and materials list. These illustrations will provide a visual context to
evaluate the overall design intent of the site and its structures at the concept
phase.
Water features, fountains, spray walls, etc. are specifically excluded from this
scope of work. Conceptual and Final design of such features may be
accomplished with a supplemental work authorization.
Aad. Preferred 15% Concept Design and Program and Construction Cost
Estimates: Based on feedback and comments from the client representative and
staff technical committee and advisory committee, prepare a preferred 15%
concept design plan in 30"x40" format for site, architectural and civil elements
and a technical memorandum that summarizes the plan concept and
implementation strategy. Prepare construction cost estimates based on preferred
15% concept design.
A3e. 30% Concept Design (Final Concept Desi: Based on comments
and directives received on the 15% Design, prepare a 30% site plan and an
architectural elements plan presenting urban design, landscape, civil and
architectural elements. The site plan will identify site materials, landscape species,
street furniture, lightning, concepts for public art, and finished footprint of buildings.
Prepare final illustration to present the 30% design scheme to the public
and client representatives. This illustration can be a perspective or axonometric
drawing that would be in a 30"x40" panel. Prepare material sample boards to be
used for the selection of urban design, landscape and architectural elements that
will be selected for the final design.
For the selected architectural elements, isometric views and design detail
vignettes (focus on structure only) will be provided to illustrate the visual sense of
the construction. Outline materials specifications will be provided. Written
descriptions of systems such as lighting, electrical, and other features will be
provided to accompany design drawings.
Based on comments and directives received during 30% briefings,
presentations and staff review, prepare a Final Urban Design Development
Program that identifies and describes all elements that will be included in the 30%
design. The technical memorandum will also describe a phasing strategy for the
project.
Prepare 30% Concept Design construction cost estimates.
DESIGN AND ENGINEERING CONTRACT
Page 22 of 31 U a
Submit 30% Concept Design plans to FTA for review.
A4. Project Management: Provide comprehensive project management
for all tasks and project phases, including meeting coordination, budget and
schedule oversight, and quality control.
Additional Services Not Included in Scope of Work
Using AutoCAD files and other information gathered during site inspections
and/or provided by the client relative to development plans of adjacent parcels of
land, build a digital 3-D model of the site using a 3D Studio rendering program
with an AutoCAD base.
B. Final Design
B1. Meetings and Briefings
131 a. 60% Staff Review Meetings: Present 60% plans to staff.
131b. 90% Staff Review Meeting: Present 90% design plans to staff.
131c. Prepare and Conduct One (1) 90% Public Stakeholder Meeting at
the 90% Design Stage: Present the 90% design and facilitate review and input
by the general public.
131d. 90% Advisory Committee Review Meeting: Present 90% design
plans to the advisory committee.
B1e. 100% Staff Review Meetings: Present 100% design plans to staff.
131f. Subsurface Utility Engineering (SUE): Perform a subsurface utility
survey to pinpoint the location of critical underground utilities that may have an
impact on the location of the proposed storm drain system.
B2. Develop Final Design Plans
132a. Develop 30% and 60% Construction Documents: Prepare 30% and
60% plans and specifications for architectural elements: transit transfer facility,
transit shelter structure, and other architectural site elements.
Prepare 30% and 60% plans and specifications for civil and site elements to
include:
Roadway Plans and Details
Site Plans and Details
DESIGN AND ENGINEERING CONTRACT
Page 23 of 31
Architectural Plans and Specifications
Traffic Control Plans
Grading Plans
Storm Drain Plan and Profiles
Sidewalk/Plaza Plans and Elevations
Erosion Control Plans
Horizontal and Vertical Control Data
Lighting and Electrical Plans
All details in accordance with City of Fort Worth, T, FTA, and Texas Department
of Licensing and Regulation standards.
Prepare construction cost estimates.
132b. Develop 90% Construction Documents: Prepare 90% plans and
specifications for architectural elements: transit transfer facility, transit shelter
structure, and other architectural site elements.
Prepare 90% plans and specifications for civil and site elements to include:
Roadway Plans and Details
Site Plans and Details
Architectural Plans and Specifications
Traffic Control Plans
Grading Plans
Storm Drain Plan and Profiles
Sidewalk/Plaza Plans and Elevations
Erosion Control Plans
Horizontal and Vertical Control Data
Lighting and Electrical Plans
All details in accordance with City of Fort Worth, T, FTA and TDLR standards.
Prepare construction cost estimates.
Submit 90% Plans to FTA for review.
132c. Develop 100% Construction Documents:
Prepare 100% plans and specifications for architectural elements: transit transfer
facility, transit shelter structure, and other architectural site elements,
Prepare 100% plans and specifications for civil and site elements to include:
Roadway Plans and Details
Site Plans and Details
Architectural Plans and Specifications
71 7
DESIGN AND ENGINEERING CONTRACT
Page 24 of 31 , ?�'y-';• ;,
I
Traffic Control Plans
Grading Plans
Storm Drain Plan and Profiles
Sidewalk/Plaza Plans and Elevations
Erosion Control Plans
Horizontal and Vertical Control Data
Lighting and Electrical Plans
All details in accordance with City of Fort Worth, T, FTA and TDLR standards.
Prepare construction cost estimates.
DESIGN AND ENGINEERING CONTRACT �
Page 25 of 31 „.
ATTACHMENT B
COMPENSATION AND SCHEDULE
HYDE PARK TRANSIT PLAZA AND RELATED IMPROVEMENTS
I. COMPENSATION
A. The CONSULTANT shall be compensated a lump sum fee of
$469,539 for Basic and Special Services as summarized on Exhibit "B-
3". Payment of the lump sum fee shall be considered full
compensation for the services described in Exhibit "A-1" for all labor,
materials, supplies, and equipment necessary to complete the project.
B. Partial payment shall be made monthly as stipulated on Exhibit "B-1"
upon receipt of an invoice from the CONSULTANT, prepared from the
books and records of the CONSULTANT. Each invoice is to be
verified as to its accuracy and compliance with the terms of this
contract by an officer of the CONSULTANT. Payment according to
statements will be subject to certification by the Executive Director of
the Fort Worth Transportation Authority or his authorized
representative that such work has been performed.
II. SCHEDULE
A. Phase One— Conceptual Design will be completed within 354
calendar days after "Notice to Proceed".
B. Phase Two — Plans, specifications, and contract documents will be
completed within 211 calendar days after City and the T approval of
Concept Plans.
ill t,_,
DESIGN AND ENGINEERING CONTRACT CITY guxl i
Page 26 of 31
EXHIBIT B-1
METHOD OF PAYMENT
(SUPPLEMENT TO ATTACHMENT B)
HYDE PARK TRANSIT PLAZA AND RELATED IMPROVEMENTS
I. METHOD OF PAYMENTS
The CONSULTANT shall be paid in monthly partial payments as outlined
below:
A. The CONSULTANT shall be paid in monthly payments upon receipt of
the individual invoices for each partial payment request from the
CONSULTANT.
II. PROGRESS REPORT
A. The CONSULTANT shall submit to the designated representative of
the Executive Director of the T monthly progress reports covering all
phases of design by the 15�h of every month in the format required by
the T.
DESIGN AND ENGINEERING CONTRACT 3�'�1 ::� ::
Page 27 of 31 11
��� °✓:: INS 7}:,'.,
EXHIBIT B-3
COST SUMMARY
HYDE PARK TRANSIT PLAZA AND RELATED IMPROVEMENTS
Exhibit Scope of Fee MIWBE %
Services
A-1 $469,539 $141 ,573 30%
Proposed M/WBE Services Fees
Subconsultants
Komatsu Architecture Architectural Design $109,573
AEI Subsurface Utility $32,000
Engineering
DESIGN AND ENGINEERING CONTRACT Q
Page 28 of 31 !. .. _ •. ; -
O V O (D O V I- O O to N N O to V
Cl) (1) (n M O O V r t2 N I� O to O
J CD to O co ►� a (V r r (D 7 O O (.O
¢ ^ (D O N r Lo N N N O (.D N
O N `7 N LO r O NN
N
~ r I r
to 69 (» Efl tH (» b9 b9 bfl 69 b9 U) (i9 to tR in W
O (D 6'> O Q) (- O O u') N N O (D
«> N (l- ( (T V t!) O O
O I- tfi r r N o) (.D O
N O
C
¢ to 69 to b9 Efl to to 69 H9 V) to tH to H9
O co u7 c0 O 00
(� N U) c0 (LJ r (- Cr
p to (D
•+ N c N O
.O
7 r
N
� 69 Efl to 69 Efl Efl
O
V
U co
d �
_ Efl
U
c o O
to v co
L �
U
d
C—
C O
,La t
O c) O
Lo
C C
v 3 Efl
d �
H
C O O O O O O O
m C14 v
a) (U O (�D N •0p
m C C G to (il N N r O N
L
te
xLU ~ Q ffl to
O (O O N O O O
" O N co 7 O O
d U tD N m
v N V 4 N N
u N w (f) C
A
L O H ^ E
¢ Q Y
to uv
O (fl O O N N O tr) O0 0 0 O O
+� w N n V I� M t17 O O t1 CN O V
O N O M . O .2- O M c0 O) O V N m O f�
U O U M U (1)
0 d c c U
7 a p 61.- to 'C H
Oa a z V) t9 (fl to 69 to tH
:. E (n
> o
0 0
C. Q a
C E U
Z
O
c Z U Z a)
!d y 0 c Z
O c OLUz
Q w a N C7
co
C7
CL �
O m Z a u w w ) a Q
LL w O Z Z U W a.
N J d U O Z N c U w
C to m Q O U O
Y c U) Z
aZ Q °' > U ° OU Z
t+ N 0 d 2 E to (n w J
c d (D p y ¢
O
LU
c m
�r
Q O OU CL CO
N N avtv 5 m It c
LL a. Q p cm '� m 1T �.pI{
0awaO iN
a W _ J ¢ y
p o -:Q m C
Z m cQ
ZoA O C) 0tvc i Fu 0 OO
Y a
L) LT- QQ
fi
.e
'
Z F—
O OW f- 00 N (- m N N N ID N N O (A Q O O N N m O V (D O
N O v O O N O O N O O v O N O NII- C) N N P') O C) Cl)
J O N m y f- N I- v N !r N O c) (D O O h N
L-0O
C) (pIAN co N NN cn
t O M .- P')N 00 I w
^NNV) V) V> Vi V) V) V) Vi V) V) V) V1 Vi Vi Vo Vi Vi V) Vi V) Vi V) W Vi:W Vi i
(D O N N co ti co N D) N O N O O O N N co O
N O I- C) ti C) I- v m W O I� O C) C]
N N N C) M C) C) O f'+ N C) N h
EC C) W N N (D C)
� r
a
Vi 69 V) 69 V) V) V) fA V) V) V) V) V) V) V) V) 64 V)
J N O N D) OO N O O N O N N O O
a (D O (D O r- m0 n co O N v W " O
F I"I O n Q C) f- N cl n v v Cl) (3 C
(D Na) N C) C) O CI C) Df N O f` N
C) N N N N C%4
N (�
m
Q
cn Vf 69 V) V) V) V) K1 V) V) Vl
O O �
v O
R I
U OD
I
O O N D N
C O n C -
N (D m lD
V co
D C
u �
F I
0 0 cD O O o 0
C O O O O O O O i
o C
O U O N
cn u N
H i
O O v 0 0 N O O 0 0 O O f
Y , c o p
o co 1
m C N •V N 0 0 2 coO ro N N N N v O M N N
Cco 0. wID
m fn C 64 U IA O to ri
W W ~ N ❑ V) Vf I
O Li—
(D (D O O n O O coo
O O O
vO CO N N co N v N n O O
U d N u N n V � C) c (D 1- N co N
N C
ea _vO N m
c r w E
o +
(D O O O O O O O
�+ N N O N v N !b INA 0 0 0 (OA N N
U A ry N N O) N V) O p .-
Lm
0 m u ^ c2 .� vpi I aG co c
69 ` bo ; v
3 a o a a ~
C u)vi w 64 (a Vi w la
> z
0 0 c�
H a cn
c E w
° a
s z
cc m LL
3 _ y z 0 z
a a (n S2 z
0 m Z E LU cn
m Z J ❑ W
LL m u) o C J ❑ W
p ii W
C 2 Y cn c c c w O z c a Z ❑
ra d cn .__ ° W m Q a 2 Z O
s a m U w h E , m m LL 0) z
a a °i z � o LL
0 C m a W cn H N U a
L Z C O C LL } N ~ a F LUJ
3F � H me A m 2 m L) � V) OF W aF
r N (\j N y L) Q )- O) N U
0 L W f0 O Q U m !n �-' C C
LL L ❑ o ❑ W o o m o ; o v a 00 o mQ1-
0 d J 01 "'' F. m o) > > .,�. a °) y .n °' r ` K .=N. J n c m J J lOir
T Q .0 m a q g rn p m m ❑ m m Q m m d a O m
Z E ^� � s� (i ces E � mea Eg vas Eg o m Ecli g — z m m E zrf O
U 2 lL m LL H OY O m m m ~ Y ❑ m H Y 0 m FU- Y O m J Y ❑ a Z d d' ❑ 0. `t U I, 2 FQ G
ATTACHMENT C
AMENDMENTS TO AGREEMENT FOR PLANNING, DESIGN, AND
ENGINEERING SERVICES
Article IV, Paragraph E is deleted.
Article IV, Paragraph G is deleted.
Article IV, Paragraph H is deleted.
Article VI, Paragraph B "Reuse of Project Documents" is replaced with the
following:
All designs, drawings, specifications, documents, and other work products
of the CONSULTANT, hereinafter referred to as the "Work Product",
whether in hard copy or in electronic form, are instruments of service for this
PROJECT, whether the PROJECT is completed or not, and all Work
Products shall be owned by the T and the City upon completion or early
termination. Consultant shall not be liable for the use of the Work Product
for any project other than the Project described herein; and provided further,
that Consultant shall not be liable for the consequences of any changes that
are made to the Work Product without the written consent of Consultant.
Reuse, change, or alteration by the T and the CITY or by others acting
through or on behalf of the T and the CITY of any such instruments of
service without the written permission of the CONSULTANT will be at the T
and the CITY's risk. The T and the CITY shall own the final designs,
drawings, specifications and documents.
DESIGN AND ENGINEERING CONTRACT
Page 31 of 31
City of Fort Worth, Texas
Mayor and Council Communication
COUNCIL ACTION: Approved on 11/11/2003
DATE: Tuesday, November 11, 2003
LOG NAME: 22HYDE PARK TCB REFERENCE NO.: **C-19848
SUBJECT:
Authorize the City Manager to enter into a Joint Contract with the Fort Worth Transportation
Authority and Tumer Collie & Braden, Inc. for the Planning, Design, and Engineering of the Hyde
Park Transit Plaza Project
RECOMMENDATION:
It is recommended that the City Council:
1. Authorize the City Manager to enter into a joint contract with the Fort Worth Transportation Authority
and Turner Collie & Braden, Inc. (TCB) for the planning, design, and engineering of the Hyde Park
Transit Plaza project, for an amount not to exceed $470,000; and
2. Authorize payment to the Fort Worth Transportation Authority for the City's share of local matching
funds in the amount of$148,000.
DISCUSSION:
The City of Fort Worth, the Fort Worth Transportation Authority (the T), the U.S. General Services
Administration (GSA), Downtown Fort Worth, Inc. (DFWI), and adjacent property owners are working
together to reestablish Hyde Park as Downtown Fort Worth's civic square. This transit-oriented public
space was originally conceptualized in 1999 by consultants studying the Intermodal Transportation Center
(ITC) at Ninth and Jones Streets. Signs of progress are already visible, including the sculpture fountain in
the section of Hyde Park adjacent to the Flatiron Building. In a closely related effort, the T and the City are
working collaboratively to design and construct the central public space within the square: the Hyde Park
Transit Plaza on the former library site at Ninth and Throckmorton Streets.
The City Council has previously appropriated local matching funds and authorized a partnership with the T
for the Hyde Park Transit Plaza. The City Council appropriated local matching funds for design and
construction in the amount of$148,000 on March 19, 2002 (M&C G-13550). On November 26, 2002 (M&C
C-19364), the City Council authorized an interlocal agreement between the two entities for this project, and
adopted a resolution formally designating "Hyde Park" as the official name for the proposed transit-oriented
civic square. On June 3, 2003, the City Council received an update on the design consultant selection
process as part of a more comprehensive presentation on the various initiatives of the Lancaster Corridor
Redevelopment Project. The consultant selection process is now complete, and the project partners are
prepared to enter into a contract for the design of the Hyde Park Transit Plaza with the preferred design
team led by local firm TCB.
The contract's scope of services will result in final construction drawings for the Transit Plaza and the
Ninth/Throckmorton/Tenth/Jennings intersection. In addition, conceptual plans will explore ways to
improve other public spaces in the Hyde Park area and to integrate those spaces with the Transit
Plaza. Hyde Park's other public spaces include: the portion of the original Hyde Park now known as
Logname: 22HYDE PARK TCB Page 1 of 3
Federal Plaza; the remaining triangular section of Hyde Park adjacent to the Flatiron Building; John Peter
Smith Park just north of Saint Patrick Cathedral; City Hall Plaza at the north end of City Hall; and the Tenth
Street Pedestrian Mall between the SBC Communications and Park Central Hotel buildings.
The design team is an interdisciplinary group with extensive experience in the design of public
spaces. Antonio Di Mambro will serve as lead urban designer and landscape architect, local architect Karl
Komatsu will serve as lead architect, and Ann Kovich and Steve James of TCB will serve as project
manager and lead engineer, respectively. The Hyde Park and Ninth Street Consultant Selection
Committee, appointed by former Mayor Kenneth Barr and chaired by Councilmember Wendy Davis,
selected the TCB team from among a group of four finalists.
The design fee represents 13.4 percent of total project costs. "phis percentage is consistent with design
costs for similar capital improvement projects that involve a combination of planning, urban design, and
engineering tasks. Staff has determined the fee to be fair and reasonable. The design and construction
budget is listed in the table below.
Status Grant Grantee Purpose Federal Q tj[ The T TOTAL
Secured FTA The T Transit Plaza $1,184,000 $148,000 $148,000 $1,480,000
(CMAQ) design and
Construction
Unsecured CMAQ The T Construction $1,600,000 $200,000 $200,000 $2,000,000
(NCTCOG of Ninth Street
Transit realignment
Partnership and additional
No. 2) improvements
TOTAL $2,784,000 $348,000 $348,000 $3,480,000
It is anticipated that unsecured funds will be secured from future grants and local matching funds from the
City and the T.
The City and the T will jointly execute the Hyde Park Transit Plaza design contract with TCB. In a related
Mayor and Council Communication, staff is requesting authorization to enter into a separate contract with
TCB for the design of improvements along Ninth Street between Hyde Park and the Intermodal
Transportation Center. Since the T and the City are the recipients of separate federal transportation grants
for the Hyde Park Transit Plaza and Ninth Street projects, respectively, the administration of the grant
funds requires separate contracts.
Tumer Collie & Braden, Inc. is in compliance with the City's DBE Ordinance by committing to 30%Q DBE
participation. The City's DBE goal on this progect is 25%.
This project is located in COUNCIL DISTRICT 9.
FISCAL INFORMATIONXERTIFICATION:
The Finance Director certifies that funds are available in the current capital budget, as appropriated, of the
Critical Projects Improvements Fund.
Logname: 22HYDE PARK TCB Page 2 of 3
TO Fund/Account/Centers FROM Fund/Account/Centers
C116 531200 022116021221 $148,000.00
Submitted for City Manager's Office by: Richard Zavala (Acting) (6183)
Originating Department Head: Fernando Costa (8042)
Additional Information Contact: Mike Brennan (8011)
Logname: 22HYDE PARK TCB Page 3 of 3