Loading...
HomeMy WebLinkAboutContract 46607 • CITY SECRETARY CONTRACT NO. !hW7 CITY OF FORT WORTH, TEXAS STANDARD AGREEMENT FOR ENGINEERING RELATED DESIGN SERVICES This AGREEMENT is between the City of Fort Worth, a Texas home-rule municipality (the "CITY"), and A.N.A. Consultants, L.L.C., authorized to do business in Texas, (the "ENGINEER"), for a PROJECT generally described as: Near Southside Medical District Medical Water and Sanitary Sewer Improvements. Article I Scope of Services A. The Scope of Services is set forth in Attachment A. Article II Compensation A. The ENGINEER's compensation shall be in the amount of $107,865.00 as set forth in Attachment B. Article III Terms of Payment Payments to the ENGINEER will be made as follows: A. Invoice and Payment 0 N O (1) The Engineer shall provide the City sufficient documentation, including but Q not limited to meeting the requirements set forth in Attachment D to this AGREEMENT, to reasonably substantiate the invoices. CDLU 2 The ENGINEER will issue monthly invoices for all work performed under this LU AGREEMENT. Invoices are due and payable within 30 days of receipt. (3) Upon completion of services enumerated in Article I, the final payment of any balance will be due within 30 days of receipt of the final invoice. City of Fort Worth,Texas OFFICIAL RECORD Standard Agreement for Engineering Related Design Services RECORD Revised f Date: 12/ 1/2014 Pageo6 CITY SECRETARY FT.WORTH,TX (4) In the event of a disputed or contested billing, only that portion so contested will be withheld from payment, and the undisputed portion will be paid. The CITY will exercise reasonableness in contesting any bill or portion thereof. No interest will accrue on any contested portion of the billing until mutually resolved. (5) If the CITY fails to make payment in full to ENGINEER for billings contested in good faith within 60 days of the amount due, the ENGINEER may, after giving 7 days' written notice to CITY, suspend services under this AGREEMENT until paid in full. In the event of suspension of services, the ENGINEER shall have no liability to CITY for delays or damages caused the CITY because of such suspension of services. Article IV Obligations of the Engineer Amendments to Article IV, if any, are included in Attachment C. A. General The ENGINEER will serve as the CITY's professional engineering representative under this Agreement, providing professional engineering consultation and advice and furnishing customary services incidental thereto. B. Standard of Care The standard of care applicable to the ENGINEER's services will be the degree of skill and diligence normally employed in the State of Texas by professional engineers or consultants performing the same or similar services at the time such services are performed. C. Subsurface Investigations (1) The ENGINEER shall advise the CITY with regard to the necessity for subcontract work such as special surveys, tests, test borings, or other subsurface investigations in connection with design and engineering work to be performed hereunder. The ENGINEER shall also advise the CITY concerning the results of same. Such surveys, tests, and investigations shall be furnished by the CITY, unless otherwise specified in Attachment A. City of Fort Worth,Texas Standard Agreement for Engineering Related Design Services Revised Date: 12/11/2014 Page 2 of 16 (2) In soils, foundation, groundwater, and other subsurface investigations, the actual characteristics may vary significantly between successive test points and sample intervals and at locations other than where observations, exploration, and investigations have been made. Because of the inherent uncertainties in subsurface evaluations, changed or unanticipated underground conditions may occur that could affect the total PROJECT cost and/or execution. These conditions and cost/execution effects are not the responsibility of the ENGINEER. D. Preparation of Engineering Drawings The ENGINEER will provide to the CITY the original drawings of all plans in ink on reproducible mylar sheets and electronic files in .pdf format, or as otherwise approved by CITY, which shall become the property of the CITY. CITY may use such drawings in any manner it desires, provided, however, that the ENGINEER shall not be liable for the use of such drawings for any project other than the PROJECT described herein. E. Engineer's Personnel at Construction Site (1) The presence or duties of the ENGINEER's personnel at a construction site, whether as on-site representatives or otherwise, do not make the ENGINEER or its personnel in any way responsible for those duties that belong to the CITY and/or the CITY's construction contractors or other entities, and do not relieve the construction contractors or any other entity of their obligations, duties, and responsibilities, including, but not limited to, all construction methods, means, techniques, sequences, and procedures necessary for coordinating and completing all portions of the construction work in accordance with the Contract Documents and any health or safety precautions required by such construction work. The ENGINEER and its personnel have no authority to exercise any control over any construction contractor or other entity or their employees in connection with their work or any health or safety precautions. (2) Except to the extent of specific site visits expressly detailed and set forth in Attachment A, the ENGINEER or its personnel shall have no obligation or responsibility to visit the construction site to become familiar with the progress or quality of the completed work on the PROJECT or to determine, in general, if the work on the PROJECT is being performed in a manner indicating that the PROJECT, when completed, will be in accordance with the Contract Documents, nor shall anything in the Contract Documents or the agreement between CITY and ENGINEER be construed as requiring ENGINEER to make exhaustive or continuous on-site inspections to City of Fort Worth,Texas Standard Agreement for Engineering Related Design Services Revised Date: 12/11/2014 Page 3 of 16 discover latent defects in the work or otherwise check the quality or quantity of the work on the PROJECT. If the ENGINEER makes on-site observation(s) of a deviation from the Contract Documents, the ENGINEER shall inform the CITY. (3) When professional certification of performance or characteristics of materials, systems or equipment is reasonably required to perform the services set forth in the Scope of Services, the ENGINEER shall be entitled to rely upon such certification to establish materials, systems or equipment and performance criteria to be required in the Contract Documents. F. Opinions of Probable Cost, Financial Considerations, and Schedules (1) The ENGINEER shall provide opinions of probable costs based on the current available information at the time of preparation, in accordance with Attachment A. (2) In providing opinions of cost, financial analyses, economic feasibility projections, and schedules for the PROJECT, the ENGINEER has no control over cost or price of labor and materials; unknown or latent conditions of existing equipment or structures that may affect operation or maintenance costs; competitive bidding procedures and market conditions; time or quality of performance by third parties; quality, type, management, or direction of operating personnel; and other economic and operational factors that may materially affect the ultimate PROJECT cost or schedule. Therefore, the ENGINEER makes no warranty that the CITY's actual PROJECT costs, financial aspects, economic feasibility, or schedules will not vary from the ENGINEER's opinions, analyses, projections, or estimates. G. Construction Progress Payments Recommendations by the ENGINEER to the CITY for periodic construction progress payments to the construction contractor will be based on the ENGINEER's knowledge, information, and belief from selective sampling and observation that the work has progressed to the point indicated. Such recommendations do not represent that continuous or detailed examinations have been made by the ENGINEER to ascertain that the construction contractor has completed the work in exact accordance with the Contract Documents; that the final work will be acceptable in all respects; that the ENGINEER has made an examination to ascertain how or for what purpose the construction contractor has used the moneys paid; that title to any of the work, materials, or equipment has passed to the CITY free and clear of liens, claims, security interests, or encumbrances; or that there are not other matters at issue between the CITY and the construction contractor that City of Fort Worth,Texas Standard Agreement for Engineering Related Design Services Revised Date: 12/11/2014 Page 4 of 16 affect the amount that should be paid. H. Record Drawings Record drawings, if required, will be prepared, in part, on the basis of information compiled and furnished by others, and may not always represent the exact location, type of various components, or exact manner in which the PROJECT was finally constructed. The ENGINEER is not responsible for any errors or omissions in the information from others that is incorporated into the record drawings. I. Minority Business and Small Business Enterprise (MBE)(SBE) Participation In accord with the City of Fort Worth Business Diversity Ordinance No. 20020-12-2011, as amended, the City has goals for the participation of minority business enterprises and/or small business enterprises in City contracts. Engineer acknowledges the MBE and SBE goals established for this contract and its accepted written commitment to MBE and SBE participation. Any misrepresentation of facts (other than a negligent misrepresentation) and/or the commission of fraud by the Engineer may result in the termination of this Agreement and debarment from participating in City contracts for a period of time of not less than three (3) years. J. Right to Audit (1) ENGINEER agrees that the CITY shall, until the expiration of five (5) years after final payment under this contract, have access to and the right to examine and photocopy any directly pertinent books, documents, papers and records of the ENGINEER involving transactions relating to this contract. ENGINEER agrees that the CITY shall have access during normal working hours to all necessary ENGINEER facilities and shall be provided adequate and appropriate work space in order to conduct audits in compliance with the provisions of this section. The CITY shall give ENGINEER reasonable advance notice of intended audits. (2) ENGINEER further agrees to include in all its subconsultant agreements hereunder a provision to the effect that the subconsultant agrees that the CITY shall, until the expiration of five (5) years after final payment under the subcontract, have access to and the right to examine and photocopy any directly pertinent books, documents, papers and records of such subconsultant, involving transactions to the subcontract, and further, that the CITY shall have access during normal working hours to all subconsultant facilities, and shall be provided adequate and appropriate work space, in City of Fort Worth,Texas Standard Agreement for Engineering Related Design Services Revised Date:12/11/2014 Page 5 of 16 order to conduct audits in compliance with the provisions of this article together with subsection (3) hereof. CITY shall give subconsultant reasonable advance notice of intended audits. (3) ENGINEER and subconsultant agree to photocopy such documents as may be requested by the CITY. The CITY agrees to reimburse ENGINEER for the cost of copies at the rate published in the Texas Administrative Code in effect as of the time copying is performed. K. INSURANCE (1) ENGINEER'S INSURANCE a. Commercial General Liability — the ENGINEER shall maintain commercial general liability (CGL) and, if necessary, commercial umbrella insurance with a limit of not less than $1,000,000.00 per each occurrence with a $2,000,000.00 aggregate. If such Commercial General Liability insurance contains a general aggregate limit, it shall apply separately to this PROJECT or location. i. The CITY shall be included as an insured under the CGL, using ISO additional insured endorsement or a substitute providing equivalent coverage, and under the commercial umbrella, if any. This insurance shall apply as primary insurance with respect to any other insurance or self-insurance programs afforded to the CITY. The Commercial General Liability insurance policy shall have no exclusions by endorsements that would alter or nullify: premises/operations, products/completed operations, contractual, personal injury, or advertizing injury, which are normally contained within the policy, unless the CITY approves such exclusions in writing. ii. ENGINEER waives all rights against the CITY and its agents, officers, directors and employees for recovery of damages to the extent these damages are covered by the commercial general liability or commercial umbrella liability insurance maintained in accordance with this agreement. b. Business Auto — the ENGINEER shall maintain business auto liability and, if necessary, commercial umbrella liability insurance with a limit of not less than $1,000,000 each accident. Such insurance shall cover liability arising out of "any auto", including owned, hired, and non-owned autos, when said vehicle is used in the course of the PROJECT. If the engineer owns no vehicles, coverage for hired or non-owned is acceptable. City of Fort Worth,Texas Standard Agreement for Engineering Related Design Services Revised Date:12/11/2014 Page 6 of 16 i. ENGINEER waives all rights against the CITY and its agents, officers, directors and employees for recovery of damages to the a extent these damages are covered by the business auto liability or commercial umbrella liability insurance obtained by ENGINEER pursuant to this agreement or under any applicable auto physical damage coverage. c. Workers' Compensation —ENGINEER shall maintain workers compensation and employers liability insurance and, if necessary, commercial umbrella liability insurance with a limit of not less than $100,000.00 each accident for bodily injury by accident or $100,000.00 each employee for bodily injury by disease, with $500,000.00 policy limit. i. ENGINEER waives all rights against the CITY and its agents, officers, directors and employees for recovery of damages to the extent these damages are covered by workers compensation and employer's liability or commercial umbrella insurance obtained by ENGINEER pursuant to this agreement. d. Professional Liability — the ENGINEER shall maintain professional liability, a claims-made policy, with a minimum of $1,000,000.00 per claim and aggregate. The policy shall contain a retroactive date prior to the date of the contract or the first date of services to be performed, whichever is earlier. Coverage shall be maintained for a period of 5 years following the completion of the contract. An annual certificate of insurance specifically referencing this project shall be submitted to the CITY for each year following completion of the contract. (2) GENERAL INSURANCE REQUIREMENTS a. Certificates of insurance evidencing that the ENGINEER has obtained all required insurance shall be delivered to the CITY prior to ENGINEER proceeding with the PROJECT. b. Applicable policies shall be endorsed to name the CITY an Additional Insured thereon, as its interests may appear. The term CITY shall include its employees, officers, officials, agents, and volunteers as respects the contracted services. c. Certificate(s) of insurance shall document that insurance coverage specified in this agreement are provided under applicable policies documented thereon. d. Any failure on part of the CITY to request required insurance City of Fort Worth,Texas Standard Agreement for Engineering Related Design Services Revised Date: 12/11/2014 Page 7 of 16 documentation shall not constitute a waiver of the insurance requirements. e. A minimum of thirty (30) days notice of cancellation or material change in coverage shall be provided to the CITY. A ten (10) days notice shall be acceptable in the event of non-payment of premium. Notice shall be sent to the respective Department Director (by name), City of Fort Worth, 1000 Throckmorton, Fort Worth, Texas 75102. f. Insurers for all policies must be authorized to do business in the State of Texas and have a minimum rating of A:V or greater, in the current A.M. Best Key Rating Guide or have reasonably equivalent financial strength and solvency to the satisfaction of Risk Management. g. Any deductible or self insured retention in excess of $25,000.00 that would change or alter the requirements herein is subject to approval by the CITY in writing, if coverage is not provided on a first-dollar basis. The CITY, at it sole discretion, may consent to alternative coverage maintained through insurance pools or risk retention groups. Dedicated financial resources or letters of credit may also be acceptable to the CITY. h. Applicable policies shall each be endorsed with a waiver of subrogation in favor of the CITY as respects the PROJECT. i. The CITY shall be entitled, upon its request and without incurring expense, to review the ENGINEER's insurance policies including endorsements thereto and, at the CITY's discretion; the ENGINEER may be required to provide proof of insurance premium payments. j. Lines of coverage, other than Professional Liability, underwritten on a claims-made basis, shall contain a retroactive date coincident with or prior to the date of the contractual agreement. The certificate of insurance shall state both the retroactive date and that the coverage is claims-made. k. Coverages, whether written on an occurrence or claims-made basis, shall be maintained without interruption nor restrictive modification or changes from date of commencement of the PROJECT until final payment and termination of any coverage required to be maintained after final payments. I. The CITY shall not be responsible for the direct payment of any insurance premiums required by this agreement. City of Fort Worth,Texas Standard Agreement for Engineering Related Design Services Revised Date: 12/11/2014 Page 8 of 16 m. Sub consultants and subcontractors to/of the ENGINEER shall be required by the ENGINEER to maintain the same or reasonably equivalent insurance coverage as required for the ENGINEER. When sub consultants/subcontractors maintain insurance coverage, ENGINEER shall provide ("ITY with documentation thereof on a certificate of insurance. L. Independent Consuitant The ENGINEER . agrees to perform all services as an independent consultant and not as a subcontractor, agent, or employee of the CITY. M. Disclosure The ENGINEER acknowledges to the CITY that it has made full disclosure in writing of any existing conflicts of interest or potential conflicts of interest, including personal financial interest, direct or indirect, in property abutting the proposed PROJECT and business relationships with abutting property cities. The ENGINEER further acknowledges that it will make disclosure in writing of any conflicts of interest that develop subsequent to the signing of this contract and prior to final payment under the contract. N. Asbestos or Hazardous Substances (1) If asbestos or hazardous substances in any form are encountered or suspected, the ENGINEER will stop its own work in the affected portions of the PROJECT to permit testing and evaluation. (2) If asbestos or other hazardous substances are suspected, the CITY may request the ENGINEER to assist in obtaining the services of a qualified subcontractor to manage the remediation activities of the PROJECT. O. Permitting Authorities - Design Changes If permitting authorities require design changes so as to comply with published design criteria and/or current engineering practice standards which the ENGINEER should have been aware of at the time this Agreement was executed, the ENGINEER shall revise plans and specifications, as required, at its own cost and expense. However, if design changes are required due to the changes in the permitting authorities' published design criteria and/or practice standards criteria which are published after the date of this Agreement which the ENGINEER could not have been reasonably aware of, the ENGINEER shall notify the CITY of such changes and an adjustment in compensation will be made through an amendment to this AGREEMENT. City of Fort Worth,Texas Standard Agreement for Engineering Related Design Services Revised Date:12/11/2014 Page 9 of 16 r P. Schedule ENGINEER shall manage the PROJECT in accordance with the schedule developed per Attachment D to this AGREEMENT. , Article V Obligations of the City Amendments to Article V, if any, are included in Attachment C. A. City-Furnished Data ENGINEER may rely upon the accuracy, timeliness, and completeness of the information provided by the CITY. B. Access to Facilities and Property The CITY will make its facilities accessible to the ENGINEER as required for the ENGINEER's performance of its services. The CITY will perform, at no cost to the ENGINEER, such tests of equipment, machinery, pipelines, and other components of the CITY's facilities as may be required in connection with the ENGINEER's services. The CITY will be responsible for all acts of the CITY's personnel. C. Advertisements, Permits, and Access Unless otherwise agreed to in the Scope of Services, the CITY will obtain, arrange, and pay for all advertisements for bids; permits and licenses required by local, state, or federal authorities; and land, easements, rights- of-way, and access necessary for the ENGINEER's services or PROJECT construction. D. Timely Review The CITY will examine the ENGINEER's studies, reports, sketches, drawings, specifications, proposals, and other documents; obtain advice of an attorney, insurance counselor, accountant, auditor, bond and financial advisors, and other consultants as the CITY deems appropriate; and render in writing decisions required by the CITY in a timely manner in accordance with the project schedule prepared in accordance with Attachment D. City of Fort Worth,Texas Standard Agreement for Engineering Related Design Services Revised Date: 12/11/2014 Page 10 of 16 E. Prompt Notice The CITY will give prompt written notice to the ENGINEER whenever CITY observes or becomes aware of any development that affects the scope or timing of the ENGINEER's services or of any defect in the work of the ENGINEER or construction contractors. F. Asbestos or Hazardous Substances Release. (1) CITY acknowledges ENGINEER will perform part of the work at CITY's facilities that may contain hazardous materials, including asbestos containing materials, or conditions, and that ENGINEER had no prior role in the generation, treatment, storage, or disposition of such materials. In consideration of the associated risks that may give rise to claims by third parties or employees of City, City hereby releases ENGINEER from any damage or liability related to the presence of such materials. (2) The release required above shall not apply in the event the discharge, release or escape of hazardous substances, contaminants, or asbestos is a result of ENGINEER's negligence or if ENGINEER brings such hazardous substance, contaminant or asbestos onto the project. G. Contractor Indemnification and Claims The CITY agrees to include in all construction contracts the provisions of Article IV.E. regarding the ENGINEER's Personnel at Construction Site, and provisions providing contractor indemnification of the CITY and the ENGINEER for contractor's negligence. H. Contractor Claims and Third-Party Beneficiaries (1) The CITY agrees to include the following clause in all contracts with construction contractors and equipment or materials suppliers: "Contractors, subcontractors and equipment and materials suppliers on the PROJECT, or their sureties, shall maintain no direct action against the ENGINEER, its officers, employees, and subcontractors, for any claim arising out of, in connection with, or resulting from the engineering services performed. Only the CITY will be the beneficiary of any undertaking by the ENGINEER." (2) This AGREEMENT gives no rights or benefits to anyone other than the CITY and the ENGINEER and there are no third-party beneficiaries. City of Fort Worth,Texas Standard Agreement for Engineering Related Design Services Revised Date:12/11/2014 Page 11 of 16 (3) The CITY will include in each agreement it enters into with any other entity or person regarding the PROJECT a provision that such entity or person shall have no third-party beneficiary rights under this Agreement. (4) Nothing contained in this section V.H. shall be construed as a waiver of any right the CITY has to bring a claim against ENGINEER. I. CITY's Insurance (1) The CITY may maintain property insurance on certain pre-existing structures associated with the PROJECT. (2) The CITY will ensure that Builders Risk/Installation insurance is maintained at the replacement cost value of the PROJECT. The CITY may provide ENGINEER a copy of the policy or documentation of such on a certificate of insurance. (3) The CITY will specify that the Builders Risk/installation insurance shall be comprehensive in coverage appropriate to the PROJECT risks. J. Litigation Assistance The Scope of Services does not include costs of the ENGINEER for required or requested assistance to support, prepare, document, bring, defend, or assist in litigation undertaken or defended by the CITY. In the event CITY requests such services of the ENGINEER, this AGREEMENT shall be amended or a separate agreement will be negotiated between the parties. K. Changes The CITY may make or approve changes within the general Scope of Services in this AGREEMENT. If such changes affect the ENGINEER's cost of or time required for performance of the services, an equitable adjustment will be made through an amendment to this AGREEMENT with appropriate CITY approval. Article VI General Legal Provisions Amendments to Article VI, if any, are included in Attachment C. A. Authorization to Proceed City of Fort Worth,Texas Standard Agreement for Engineering Related Design Services Revised Date:12/11/2014 Page 12 of 16 ENGINEER shall be authorized to proceed with this AGREEMENT upon receipt of a written Notice to Proceed from the CITY. B. Reuse of Project Documents All designs, drawings, specifications, documents, and other work products of the ENGINEER, whether in hard copy or in electronic form, are instruments of service for this PROJECT, whether the PROJECT is completed or not. Reuse, change, or alteration by the CITY or by others acting through or on behalf of the CITY of any such instruments of service without the written permission of the ENGINEER will be at the CITY's sole risk. The CITY shall own the final designs, drawings, specifications and documents. C. Force Majeure The ENGINEER is not responsible for damages or delay in performance caused by acts of God, strikes, lockouts, accidents, or other events beyond the control of the ENGINEER that prevent ENGINEER's performance of its obligations hereunder. D. Termination (1) This AGREEMENT may be terminated only by the City for convenience on 30 days' written notice. This AGREEMENT may be terminated by either the CITY or the ENGINEER for cause if either party fails substantially to perform through no fault of the other and does not commence correction of such nonperformance with in 5 days of written notice and diligently complete the correction thereafter. (2) If this AGREEMENT is terminated for the convenience of the City, the ENGINEER will be paid for termination expenses as follows: a.) Cost of reproduction of partial or complete studies, plans, specifications or other forms of ENGINEER'S work product; b.) Out-of-pocket expenses for purchasing electronic data files and other data storage supplies or services; C.) The time requirements for the ENGINEER'S personnel to document the work underway at the time of the CITY'S termination for convenience so that the work effort is suitable for long time storage. (3) Prior to proceeding with termination services, the ENGINEER will submit to the CITY an itemized statement of all termination expenses. The City of Fort Worth,Texas Standard Agreement for Engineering Related Design Services Revised Date: 12/11/2014 Page 13 of 16 CITY'S approval will be obtained in writing prior to proceeding with termination services. E. Suspension, Delay, or Interruption to Work The CITY may suspend, delay, or interrupt the services of the ENGINEER for the convenience of the CITY. In the event of such suspension, delay, or interruption, an equitable adjustment in the PROJECT's schedule, commitment and cost of the ENGINEER's personnel and subcontractors, and ENGINEER's compensation will be made. F. Indemnification In accordance with Texas Local Government Code Section 271.904, the ENGINEER shall indemnify, hold harmless, and defend the CITY against liability for any damage caused by or resulting from an act of negligence, intentional tort, intellectual property infringement, or failure to pay a subcontractor or supplier committed by the ENGINEER or ENGINEER's agent, consultant under contract, or another entity over which the ENGINEER exercises control. G. Assignment Neither party shall assign all or any part of this AGREEMENT without the prior written consent of the other party. H. Interpretation Limitations on liability and indemnities in this AGREEMENT are business understandings between the parties and shall apply to all the different theories of recovery, including breach of contract or warranty, tort including negligence, strict or statutory liability, or any other cause of action, except for willful misconduct or gross negligence for limitations of liability and sole negligence for indemnification. Parties mean the CITY and the ENGINEER, and their officers, employees, agents, and subcontractors. I. Jurisdiction The law of the State of Texas shall govern the validity of this AGREEMENT, its interpretation and performance, and any other claims related to it. The venue for any litigation related to this AGREEMENT shall be Tarrant County, Texas. City of Fort Worth,Texas Standard Agreement for Engineering Related Design Services Revised Date: 12/11/2014 Page 14 of 16 Executed and effective this the day ofC2015. BY: BY: CITY OF FORT WORTH ENGINEER 9 A A.N.A. Consultants, L .C. erna do Costa M saad Assistant City Manager Vice Presid Date: r 1'� 5 • Date: 2ro 1- 5--APPROVAL RECOMMENDED: Andrew T. Cronberg, P. E. Assistant Director, Water D ment APPROVED AS TO FORM AND M&C No. C-27261 LEGALITY 9 Q- 0t.. M&C Date: April 14, 2015 By: Doug as W. Black Senior Assistant City Attorney ATTEST: p®fit�0 �,%0 ° 0 o d ary J. K s r *o o a 0 00°00°° b City Secre ry ��aa� A�uv4 City of Fort Worth,Texas OFFICIAL RECORD Standard Agreement for Engineering Related Design Services CITY SECRETARY Revised Date:12/11/2014 Page 16 of 16 FT.WORTH,TX c ATTACHMENT A DESIGN SERVICES FOR NEAR SOUTHSIDE MEDICAL DISTRICT WATER AND SANrrARY SEWER MAIN IMPROVMENTS CITY PROJECT NO.:02415 ATTACHMENT A Scope for Engineering Design Related Services for Water and/or Sanitary Sewer Improvements DESIGN SERVICES FOR NEAR SOUTHSIDE MEDICAL DISTRICT WATER AND SANITARY SEWER MAIN IMPROVMENTS CITY PROJECT NO.: 02445 The scope set forth herein defines the work to be performed by the ENGINEER in completing the project. Both the CITY and ENGINEER have attempted to clearly define the work to be performed and address the needs of the Project. STREET WATER SEWER U U N NU U N_ N_ C 'C C '� N N fo U) 7 C/) U o Water Map o U o Sewer Map N o Street/Limits No W n Length LF No W a Length LF College Vickery 9 2048-388 12" 12" 900 9 2078-388 6" 8" 50 Pennsylvania 100-599 blk. Jarvis Abandon in 9 2048-388 2" N/A Lipscomb place College 800-899 bik. Jennings Rosedale 9 2048-384 18" 12" 550 Magnolia 1100-1299 blk.' Leuda St.W S.Main 9 2048-388 6" 8" 650 St.Louis 100-299 blk. Lipscomb Vickery 9 2048-388 6" 8: 1000 9 2048-388 6" 8" 50 Pennsylvania 100-599 blk. May St. Magnolia 9 2048-384 6" 8" 850 Feliks Gwozdz(1300-1499 blk. Petersmith 6" 8" 100 Hemphill 9 2078-388 6" 8" 1000 9 2048-388 12" 12" 50 Fulton 700-999 blk. 6" 8" 600 TOTAL 4,950 LF 850 LF City of Fort Worth,Texas Attachment A PMO Release Date:07.23.2012 Page 1 of 17 ATTACHMENT A DESIGN SERVICES FOR NEAR SOUTHSIDE MEDICAL DISTRICT WATER AND SANITARY SEWER MAIN IMPROVMENTS CITY PROJECT NO.:02445 WORK TO BE PERFORMED Task 1. Design Management Task 2. Conceptual Design Task 3. Preliminary Design Task 4. Final Design Task 5. Bid Phase Services Task 6. Construction Phase Services Task 7. ROW/Easement Services Task 8. Survey and Subsurface Utility Engineering Services Task 9. Plan Submittal Checklists TASK 1. DESIGN MANAGEMENT. ENGINEER shall ensure efficient and effective use of ENGINEER's and CITY's time and resources. ENGINEER shall manage change, ■ communicate effectively, ■ coordinate internally and externally as needed, and ■ proactively address issues with the CITY's Project Manager and others as necessary to make progress on the work. 1.1. Managing the Team • Lead, manage and direct design team activities • Ensure quality control is practiced in performance of the work • Communicate internally among team members • Task and allocate team resources 1.2. Communications and Reporting • Attend a pre-design project kickoff/chartering meeting with CITY staff to confirm and clarify scope, understand CITY objectives, and ensure economical and functional designs that meet CITY requirements • Conduct review meetings with the CITY at the end of each design phase • Prepare invoices and submit monthly in the format requested by the CITY. • Prepare and submit monthly progress reports in the format provided by the Water Department. • Prepare and submit baseline Project Schedule initially, and Project Schedule updates with a schedule narrative monthly, as required in Attachment D to this Standard Agreement and according to the City of Fort Worth's Schedule Guidance Document. City of Fort Worth,Texas Attachment A PMO Release Date:08.1.2014 Page 2 of 17 ATTACHMENT A DESIGN SERVICES FOR NEAR SOUTHSIDE MEDICAL DISTRICT WATER AND SANITARY SEWER MAIN IMPROVMENTS CITY PROJECT NO.:02445 • Complete Monthly M/WBE Report Form and Final Summary Payment Report Form at the end of the project • Coordinate with other agencies and entities as necessary for the design of the proposed infrastructure, and provide and obtain information needed to prepare the design • With respect to coordination with permitting authorities, ENGINEER shall communicate with permitting authorities such that their regulatory requirements are appropriately reflected in the designs. ENGINEER shall work with regulatory authorities to obtain approval of the designs, and make changes necessary to meet their requirements, as part of the design scope. • Personnel and Vehicle Identification: When conducting site visits to the project location, the ENGINEER or any of its sub-consultants shall carry readily visible information identifying the name of the company and the company representative. ASSUMPTIONS • 11 MWBE reports will be prepared • 4 meetings with city staff • 11 monthly water department progress reports will be prepared • 11 monthly project schedule updates will be prepared DELIVERABLES A. Meeting summaries with action items B. Monthly invoices C. Monthly progress reports D. Baseline design schedule E. Monthly schedule updates with schedule narrative describing any current or anticipated schedule changes F. Monthly M/WBE Report Form and Final Summary Payment Report Form G. Plan Submittal Checklists (See Task 9) TASK 2. CONCEPTUAL DESIGN (30 PERCENT). The Conceptual Design shall be submitted to CITY per the approved Project Schedule. The purpose of the conceptual design is for the ENGINEER to ■ Study the project, ■ Identify and develop alternatives that enhance the system, ■ Present (through the defined deliverables) these alternatives to the CITY ■ Recommend the alternatives that successfully addresses the design problem, and City of Fort Worth,Texas Attachment A PMO Release Date:08.1.2014 Page 3 of 17 ATTACHMENT DESIGN SERVICES FOR NEAR SOUTHSIDE MEDICAL DISTRICT WATER AND SANITARY SEWER MAIN IMPROVMENTS CITY PROJECT NO.:02445 ■ Obtain the CITY's endorsement of this concept. ENGINEER will develop the conceptual design of the infrastructure as follows. 2.1. Data Collection • In addition to data obtained from the CITY, ENGINEER will research proposed improvements in conjunction with any other planned future improvements that may influence the project. • The ENGINEER will also identify and seek to obtain data for existing conditions that may impact the project including but not limited to; utilities, agencies (TxDOT and railroads), City Master Plans, and property ownership as available from the Tax Assessor's office. • The data collection efforts will also include conducting special coordination meetings with affected property owners and businesses as necessary to develop sewer re-routing plans. • The ENGINEER shall visit the project site and obtain the meter numbers and sizes on all existing meters to be replaced on the project and shall identify existing sample stations and fire line locations. 2.2. GeeteGhRiGal Investigat (NOT APPLICABLE) • ENGINEER EER shall advise the CITY of test beFiRgS and rather s Choi rfaGe iRvestigatiGRS that rRay be needed for the pFejeGt. if the CITY determines that such b0nAgS or investigations are needed, then the ENGINEER shall werk with the GITV and (MTV's oeo+oehni6al e ultent to draw u G'ficat'o s for G Gh testing PFGgFaM. The Gest of suGh testing will he paid for by the CITY 2.3. The Conceptual Design Package shall include the following: • Cover Sheet • Graphic exhibits and written summary of alternative design concepts considered, strengths and weaknesses of each, and the rationale for selecting the recommended design concept. • Proposed phasing of any water and sanitary sewer work that is included in this project documented in both the project schedule and narrative form. • Documentation of key design decisions. • Estimates of probable construction cost. ASSUMPTIONS • 0 Geotechnical borings are expected for this project. • 2 copies of the conceptual design package (30% design) will be delivered. Report shall be letter sized and comb-bound with a clear plastic cover. Drawings will be 11"X17" size fold outs bound in the report City of Fort Worth,Texas Attachment A PMO Release Date:08.1.2014 Page 4 of 17 ATTACHMENT DESIGN SERVICES FOR NEAR SOUTHSIDE MEDICAL DISTRICT WATER AND SANITARY SEWER MAIN IMPROVMENTS CITY PROJECT NO.:02445 • DWF files created from design CAD drawings will be uploaded to the designated project folder in Buzzsaw • ENGINEER shall prepare the meeting minutes of the Concept Review meeting and revise the report, if needed. • ENGINEER shall not proceed with Preliminary Design activities without obtaining written approval by the CITY of the Conceptual Design Package. DELIVERABLES A. Conceptual Design Package TASK 3. PRELIMINARY DESIGN (60 PERCENT). Preliminary plans and specifications shall be submitted to CITY per the approved Project Schedule. ENGINEER will develop the preliminary design of the infrastructure as follows. 3.1. Development of Preliminary Design Drawings and Specifications shall include the following: • Cover Sheet • A Prosect Control Sheet, showing all Control Points, used or set while gathering data. Generally on a scale of not less than 1:400. The following information shall be indicated for each Control Point: Identified (existing City Monument#8901, PK Nail, 5/8" Iron Rod); X, Y and Z Coordinates, in an identified coordinate system, and a referred bearing base. Z coordinate on City Datum only; descriptive location (i.e. set in the centerline of the inlet in the South curb line of North Side Drive at the East end of radius at the Southeast corner of North Side Drive and North Main Street). • Overall project easement layout sheet(s) with property owner information. • Overall project water and/or sanitary sewer layout sheets. The water layout sheet shall identify the proposed water main improvement/existing water mains in the vicinity and all water appurtenances along with pressure plane boundaries, water tanks, pump stations, valves, and fire hydrants. The sewer layout sheet shall identify the proposed sewer main improvement/existing sewer mains and all sewer appurtenances in the vicinity. • Overall water and/or sanitary sewer abandonment sheet. • Coordinates on all P.C.'s, P.T.'s, P.I.'s, manholes, valves, mainline fittings, etc., in the same coordinate system as the Control Points. • Bench marks per 1,000 ft of plan/profile sheet—two or more. • Bearings given on all proposed centerlines, or baselines. • Station equations relating utilities to paving, when appropriate. City of Fort Worth,Texas Attachment A PMO Release Date:08.1.2014 Page 5 of 17 ATTACHMENT A DESIGN SERVICES FOR NEAR SOUTHSIDE MEDICAL DISTRICT WATER AND SANITARY SEWER MAIN IMPROVMENTS CITY PROJECT NO.:02445 • Plan and profile sheets which show the following: proposed water and/or sanitary sewer plan/profile and recommended pipe size, fire hydrants, water service lines and meter boxes, gate valves, isolation valves, manholes, existing meter numbers and sizes that are to be replaced, existing sample locations, existing fire line locations, existing utilities and utility easements, and all pertinent information needed to construct the project. Legal description (Lot Nos., Block Nos., and Addition Names) along with property ownership shall be provided on the plan view. • The ENGINEER shall make provisions for reconnecting all identifiable water and/or wastewater service lines which connect directly to any main being replaced, including replacement of existing service lines within City right-of-way or utility easement. When the existing alignment of a water and sanitary sewer main or lateral is changed, provisions will be made in the final plans and/or specifications by the ENGINEER to relocate all service lines which are connected to the existing main and connect said service lines to the relocated main. • The following shall be applicable at all locations where it is necessary to relocate or reroute the existing private sanitary sewer service line due to the abandonment or realignment of the existing public sanitary sewer lateral or main: The CITY shall furnish the ENGINEER with a sample format of how the sewer service line reroute/relocation should be designed and submitted for construction. During design survey, if a rod can be inserted through the cleanout to the bottom of the service line, the ENGINEER will obtain the flow line elevation and design the service line prior to advertising the project for bid. If the service flow line information cannot be obtained during design survey, the ENGINEER shall delay the design of the sewer service line until after a Quality Level A Subsurface Utility Engineering (SUE investigation has been performed). The Level A SUE will be performed; (1) by the ENGINEER if included in the fee proposal; or (2) by the CITY prior to bidding if the CITY determines that it is needed for satisfactory completion of the design; or (3) by the Contractor after the project has been bid, by means of a bid item to that effect. In all options, the ENGINEER shall propose appropriate de- hole locations in the project and collect flow line elevation and other applicable information of the sewer service line. The ENGINEER shall use this information to provide the design for the sanitary sewer service line to be rerouted or relocated. • Provide map showing location of new manhole construction at the end of existing sewer segments, 90 degree bends, or tee connections. Site survey or specific design plans for manhole construction is not included as part of the scope. The contract documents shall specify that it is the Contractor's responsibility to coordinate utility location, etc. manhole construction. • The ENGINEER will prepare standard and special detail sheets for water line installation and sewer rehabilitation or replacement that are not already included in the D-section of the CITY's specifications. These may included connection details between various parts of the project, tunneling details, boring and jacking details, waterline relocations, details unique to the construction of the project, trenchless details, and special service lateral reconnections. 3.2. (7 pp At phniGal !Ryestigat;„n (NOT APPLICABLE) City of Fort Worth,Texas Attachment A PMO Release Date:08.1.2014 Page 6 of 17 ATTACHMENT A DESIGN SERVICES FOR NEAR SOUTHSIDE MEDICAL DISTRICT WATER AND SANITARY SEWER MAIN IMPROVMENTS CITY PROJECT NO.:02445 Cn'I 'n eo+ina+'enc GII Jinn field and IabGFatE)Fy tests, herinnc related laberatery analysis will be made at reasonable iRtervals alORg the pirejeet alignment fer+he GORtFan+nr'o use in de+errr,'n nil n Rditin S fnr n rep i bids and a Trnnnh Safety Plan 3.3. Constructability Review • Prior to the 60 percent review meeting with the CITY, the ENGINEER shall schedule and attend a project site visit with the CITY Project Manager and Construction personnel to walk the project. The ENGINEER shall summarize the CITY's comments from the field visit and submit this information to the CITY in writing. 3.4. Utility Clearance • The ENGINEER will consult with the CITY's Transportation and Public Works Department, Water Department, and other CITY departments, public utilities, private utilities, private utilities and government agencies to determine the approximate location of above and underground utilities, and other facilities (current and future) that have an impact or influence on the project. ENGINEER will design CITY facilities to avoid or minimize conflicts with existing utilities, and where known and possible consider potential future utilities in designs. • The ENGINEER shall upload individual DWF files for each plan sheet of the approved preliminary plan set to the designated project folder in Buzzsaw for forwarding to all utility companies which have facilities within the limits of the project. The DWF files should be created directly from the CAD files as opposed to PDF files. 3.5. Traffic Control Plan • Develop a traffic control plan utilizing standard traffic reroute configurations posted as "Typicals" on the CITY's Buzzsaw website. The typicals need not be sealed individually, if included in the sealed contract documents. • Develop supplemental traffic control drawings as needed for review and approval by the Traffic Division of the Transportation and Public Works Department. These drawings shall be sealed by a professional engineer registered in the State of Texas. ASSUMPTIONS • 0 public meeting(s) will be conducted or attended during the preliminary design phase. • 0 borings at an average bore depth of 0 feet each will be provided. • Traffic Control "Typicals" will be utilized to the extent possible. It is assumed an additional 0 project specific traffic control sheets will be developed for • 2 sets of 22"X34" size plans will be delivered for the Preliminary Design (60% design). City of Fort Worth,Texas Attachment A PMO Release Date:08.1.2014 Page 7 of 17 ATTIACHMENTA DESIGN SERVICES FOR NEAR SOUTHSIDE MEDICAL DISTRICT WATER AND SANITARY SEWER MAIN IMPROVMENTS CITY PROJECT NO.:02445 • 1 sets of specifications will be delivered for the Preliminary Design (60% design). • DWF files created from design CAD drawings will be uploaded to the designated project folder in Buzzsaw. • The CITY's front end and technical specifications will be used. The ENGINEER shall supplement the technical specifications if needed. • Construction drawings will be posted on Buzzsaw for Utility Clearance. • ENGINEER shall not proceed with Final Design activities without written approval by the CITY of the Preliminary Design plans. DELIVERABLES A. Preliminary Design drawings and specifications B. Utility Clearance drawings C. Traffic Control Plan D. Storm Water Pollution Prevention Plan E. Estimates of probable construction cost F. Data Base listing names and addresses of residents and businesses affected by the project. TASK 4. FINAL DESIGN (90 PERCENT)AND FINAL CONSTRUCTION DOCUMENTS (100 PERCENT). Upon approval of the Preliminary plans, ENGINEER will prepare construction plans as follows: • For projects that disturb an area greater than one (1) acre, the Contractor will be responsible for preparing and submitting the Storm Water Pollution Prevention Plan (SWPPP) with appropriate regulatory agencies. The Engineer will prepare the iSWM Construction Plan according to the current CITY iSWM Criteria Manual for Site Development and Construction which will be incorporated into the SWPPP by the contractor. • Draft Final plans (90%) and specifications shall be submitted to CITY per the approved Project Schedule. • Following a 90% construction plan review meeting with the CITY, the ENGINEER shall submit Construction Documents (100%) to the CITY per the approved Project Schedule. Each plan sheet shall be stamped, dated, and signed by the ENGINEER registered in State of Texas. • The ENGINEER shall submit a final design estimate of probable construction cost with both the 90% and 100% design packages. This estimate shall use ONLY standard CITY bid items. ASSUMPTIONS City of Fort Worth,Texas Attachment A PMO Release Date:08.1.2014 Page 8 of 17 ATTACHMENTA DESIGN SERVICES FOR NEAR SOUTHSIDE MEDICAL DISTRICT WATER AND SANITARY SEWER MAIN IMPROVMENTS CITY PROJECT NO.:02445 • 1 sets of 11"x17" size drawings and 1 sets of 22"X34" size drawings and 1 set of specifications will be delivered for the 90% Design package. • A DWF file for the 90% Design will be created from design CAD drawings and will be uploaded to the project folder in Buzzsaw. • 1 sets of 11"x17" size drawings and 1 sets of 22"X34" size drawings and 1 set of specifications will be delivered for the 100% Design package. • A DWF file for the 100% Design will be created from design CAD drawings and will be uploaded to the project folder in Buzzsaw. DELIVERABLES A. 90% construction plans and specifications. B. 100% construction plans and specifications. C. Detailed estimates of probable construction costs including summaries of bid items and quantities using the CITY's standard bid items and format. D. Original cover mylar for the signatures of authorized CITY officials. TASK 5. BID PHASE SERVICES. ENGINEER will support the bid phase of the project as follows. 5.1. Bid Support • The ENGINEER shall upload all plans and contract documents onto Buzzsaw for access to potential bidders. • Contract documents shall be uploaded in a .xIs file. • Unit Price Proposal documents are to be created utilizing CFW Bidtools only and combined in a specified spreadsheet workbook, Bid Proposal Worksheet Template, and will be populated and configured so that all pages are complete and the Summary Worksheet(s) in the workbook detail and automatically summarize the totals from the inserted Unit Price Proposal document worksheets. • Plan Sets are to be uploaded to Buzzsaw in two formats, .pdf and .dwf files. The .pdf will consist of one file of the entire plan set. The .dwf will consist of individual files, one for each plan sheet, and will be numbered and named in a manner similar to that of the plan set index. • The ENGINEER shall sell contract documents and maintain a plan holders list on Buzzsaw from documents sold and from Contractor's uploaded Plan Holder Registrations in Buzzsaw. • The ENGINEER will develop and implement procedures for receiving and answering bidders' questions and requests for additional information. The procedures shall include a log of all significant bidders questions and requests and the response thereto. The log shall be housed and maintained in the project's Buzzsaw folder titled Request for Information. The ENGINEER will City of Fort Worth,Texas Attachment A PMO Release Date:08.1.2014 Page 9 of 17 ATTACHMENT A DESIGN SERVICES FOR NEAR SOUTHSIDE MEDICAL DISTRICT WATER AND SANITARY SEWER MAIN IMPROVMENTS CITY PROJECT NO.:02445 provide technical interpretation of the contract bid documents and will prepare proposed responses to all bidders questions and requests, in the form of addenda. The ENGINEER shall upload all approved addenda onto Buzzsaw and mail addenda to all plan holders. • Attend the prebid conference in support of the CITY. • Assist the CITY in determining the qualifications and acceptability of prospective contractors, subcontractors, and suppliers. • When substitution prior to award of contracts is allowed in the contract documents, the ENGINEER will advise the CITY as to the acceptability of alternate materials and equipment proposed by bidders. • Attend the bid opening in support of the CITY. • Tabulate and review all bids received for the construction project, assist the CITY in evaluating bids, and recommend award of the contract. A copy of the Bid Tabulation and the CFW Data Spreadsheet created utilizing CFW Bidtools only are to be uploaded into the project's Bid Results folder on Buzzsaw. • Incorporate all addenda into the contract documents and issue conformed sets. 5.2 Final Design Drawings 1) Final Design Drawings shall be submitted in both Adobe Acrobat PDF format (version 6.0 or higher) format and DWF format. There shall be one (1) PDF file and one (1) DWF file for the TPW plan set and a separate PDF and DWF file for the Water plan set. Each PDF and DWF file shall be created from the original CAD drawing files and shall contain all associated sheets of the particular plan set. Singular PDF and DWF files for each sheet of a plan set will not be accepted. PDF and DWF files shall conform to naming conventions as follows: I. TPW file name example — "W-1956_org47.pdf" where "W-1956" is the assigned file number obtained from the CITY, "_org" designating the file is of an original plan set, "47" shall be the total number of sheets in this file. Example: W-0053_org3.pdf and K-0320_org5.pdf ll. Water and Sewer file name example — "X-35667_org36.pdf" where "X- 35667" is the assigned file number obtained from the CITY, "_org" designating the file is of an original plan set, "36" shall be the total number of sheets in this file. Example: X-12755_org18.pdf Both PDF and DWF files shall be uploaded to the project's Final Drawing folder in Buzzsaw. City of Fort Worth,Texas Attachment A PMO Release Date:08.1.2014 Page 10 of 17 ATTACHMENT DESIGN SERVICES FOR NEAR SOUTHSIDE MEDICAL DISTRICT WATER AND SANITARY SEWER MAIN IMPROVMENTS CITY PROJECT NO.:02445 2) In addition to the PDF and DWF files, the ENGINEER shall submit each plan sheet as an individual DWG file with all reference files integrated into the sheet. If the plans were prepared in DGN format, they shall be converted to DWG prior to uploading. The naming convention to be used for the DWG files shall be as follows: I. TPW files shall use the W number as for PDF and DWF files, but shall include the sheet number in the name — "W-1956_SHT01.dwg", "W- 1956—SHT02.dwg", etc. II. Water and Sewer file names shall use the X number as for PDF and DWF files, but shall include the sheet number in the name — "X- 12155_SHT01.dwg", "X-12755_SHT02.dwg", etc. For information on the proper manner to submit files and to obtain a file number for the project, contact the Department of Transportation and Public Works Vault at telephone number(817) 392-8426. File numbers will not be issued to a project unless the appropriate project numbers and fund codes have been assigned and are in the Department of Transportation and Public Works database. ASSUMPTIONS • The project will be bid only once and awarded to one contractor. • 10 sets of construction documents will be sold to and made available on Buzzsaw for plan holders and/or given to plan viewing rooms. • 8 sets of 11"x17" size and 4 sets of 22"X34" size drawings plans and 8 specifications (conformed, if applicable) will be delivered to the CITY. • PDF, DWF and DWG files will be uploaded to Buzzsaw. DELIVERABLES A. Addenda B. Bid tabulations C. CFW Data Spreadsheet D. Recommendation of award E. Construction documents (conformed, if applicable) TASK 6. CONSTRUCTION PHASE SERVICES. ENGINEER will support the construction phase of the project as follows. 6.1 Construction Support City of Fort Worth,Texas Attachment A PMO Release Date:08.1.2014 Page 11 of 17 ATTACHMENT A DESIGN SERVICES FOR NEAR SOUTHSIDE MEDICAL DISTRICT WATER AND SANITARY SEWER MAIN IMPROVMENTS CITY PROJECT NO.:02445 • The ENGINEER shall attend the preconstruction conference. • After the pre-construction conference, the ENGINEER shall provide project exhibits and attend public meeting to help explain the proposed project to residents. The CITY shall select a suitable location and mail the invitation letters to the affected customers. • The ENGINEER shall visit the project site at requested intervals as construction proceeds to observe and report on progress. • As requested by the CITY, the ENGINEER shall provide necessary interpretations and clarifications of contract documents, review change orders, and make recommendations as to the acceptability of the work. The ENGINEER shall attend the "Final" project walk through and assist with preparation of final punch list. The final punch list documentation will be prepared by CITY inspector. 6.2 Record Drawings • The ENGINEER shall prepare Record Drawings from information provided by the CITY depicting any changes made to the Final Drawings during construction. The following information shall be provided by the CITY: o As-Built Survey o Red-Line Markups from Contractor o Red-Line Markups from City Inspector o Copies of Approved Change Orders o Approved Substitutions • The ENGINEER shall modify the Final Drawings electronically and shall place a stamp on the plans indicating that they represent Record Drawings of the project as constructed. The stamp shall be signed and dated by the ENGINEER and shall be placed on each plan sheet, whether there are any revisions on the sheet or not. Each sheet shall clearly indicate all changes which apply to that sheet by clouding and numbering, or other suitable means. • The following disclaimer shall be included with the Record Drawing stamp: o These Record Drawings were prepared using information provided by others and represent the as constructed conditions to the extent that documented changes were provided for recording. The ENGINEER assumes no liability for undocumented changes and certifies only that the documented changes are accurately depicted on these drawings. • The ENGINEER shall submit a set of sealed Final Drawings, modified and stamped as Record Drawings, on mylar for record storage. The ENGINEER may keep copies of the information provided by the CITY for their files, but all original red-lined drawings shall be returned to the CITY with the mylars. 2) Record Drawings shall also be submitted in both Adobe Acrobat PDF format (version 6.0 or higher) format and DWF format. There shall be one (1) PDF file City of Fort Worth,Texas Attachment A PMO Release Date:08.1.2014 Page 12 of 17 ATTACHMENT A DESIGN SERVICES FOR NEAR SOUTHSIDE MEDICAL DISTRICT WATER AND SANITARY SEWER MAIN IMPROVMENTS CITY PROJECT NO.:02445 and one (1) DWF file for the TPW plan set and a separate PDF and DWF file for the Water plan set. Each PDF and DWF file shall contain all associated sheets of the particular plan set. Singular PDF and DWF files for each sheet of a plan set will not be accepted. PDF and DWF files shall conform to naming conventions as follows: I. TPW file name example — "W-1956_rec47.pdf' where "W-1956" is the assigned file number obtained from the CITY, "—rec" designating the file is of a record drawing plan set, "47" shall be the total number of sheets in this file. Example: W-0053_rec3.pdf and K-0320_org5.pdf II. Water and Sewer file name example — "X-35667_rec36.pdf' where "X- 35667" is the assigned file number obtained from the CITY, "_rec" designating the file is of a record drawing plan set, "36" shall be the total number of sheets in this file. Example: X-12755—rec18.pdf Both PDF and DWF files shall be uploaded to the project's Record Drawings folder in Buzzsaw. ASSUMPTIONS • 2 RFI's are assumed. • 2 Change Orders are assumed • Attendance at public meeting DELIVERABLES A. Public meeting exhibits will be provided at public meeting B. Response to Contractor's Request for Information C. Review of Change Orders D. Review of shop drawings E. Final Punch List items F. 1 Set of Record Drawings on Mylar TASK 7. ROW/EASEMENT SERVICES. ENGINEER will support and perform activities related to ROW and land as outlined below, per scoping direction and guidance from the CITY's Project Manager. City of Fort Worth,Texas Attachment A PMO Release Date:08.1.2014 Page 13 of 17 ATTACHMENT A DESIGN SERVICES FOR NEAR SOUTHSIDE MEDICAL DISTRICT WATER AND SANITARY SEWER MAIN IMPROVMENTS CITY PROJECT NO.:02445 7.1. 7.1. Right-of-Way Research (NOT APPLICABLE) The ENGINEER shall determine rights of way, easements needs feF GeRStFulstion e en available iRfeFmat;en and reisommendatwens will be made for approval by the CITY. 7.2. Right-of-Way/Easement Preparation and Submittal (NOT APPLICABLE) • The ENGINEER EER shall n _paF elan nts to be ed to ahta!R F h+ f way rJ • The ENGINEER shall submit the Fight Of Way 2Rd/9F easemeRt dGGlJmeRtS te GITY • template available as the CITV's ❑ site. 7.3. Temporary Right of Entry Preparation and Submittal (NOT APPLICABLE) • Prinr te_ nnnstn Il the ENGINEER EER shall pFepape nel submit TempeFa Fy Right of Gntn/de is meets far lanelGWRers to CITY DNA far real are peFty ann1 Iisit'nn It is assumed that letters will GRIy be required for land ewners adjalsent te tempera-ry is required to enter theiF pFepeFty. • The documentation shall be provided in conformance with the checklists and templates available on the CITY's Buzzsaw site. ASSUMPTIONS • 0 Easements or right-of-way documents will be necessary. • 0 Temporary right-of-entry documents will be necessary. • Right-of-Way research and mapping includes review of property/right-of-way records based on current internet based Tarrant Appraisal District (TAD) information available at the start of the project and available on-ground property information (i.e. iron rods, fences, stakes, etc.). It does not include effort for chain of title research, parent track research, additional research for easements not included in the TAD, right-of-way takings, easement vacations and abandonments, right-of-way vacations, and street closures. DELIVERABLES A. NONE TASK 8. SURVEY AND SUBSURFACE UTILITY ENGINEERING SERVICES. ENGINEER will provide survey support as follows. City of Fort Worth,Texas Attachment A PMO Release Date:08.1.2014 Page 14 of 17 ATTACHMENTA DESIGN SERVICES FOR NEAR SOLITHSIDE MEDICAL DISTRICT WATER AND SANITARY SEWER MAIN IMPROVMENTS CITY PROJECT NO.:02445 8.1. Design Survey • ENGINEER will perform field surveys to collect horizontal and vertical elevations and other information needed by ENGINEER in design and preparation of plans for the project. Information gathered during the survey shall include topographic data, elevations of all sanitary and adjacent storm sewers, rim/invert elevations, location of buried utilities, structures, trees (measure caliper, identify overall canopy, and have qualified arborist identify species of trees), and other features relevant to the final plan sheets. Existing drainage at intersections will be verified by field surveys. Spot elevations will be shown on intersection layouts with cross slope to fit intersecting grade lines. • The minimum survey information to be provided on the plans shall include the following: - A Project Control Sheet, showing ALL Control Points, used or set while gathering data. Generally on a scale of not less than 1:400: - The following information about each Control Point; a) Identified (Existing. CITY Monument#8901, PK Nail, 5/8" Iron Rod) b) X, Y and Z Coordinates, in an identified coordinate system, and a referred bearing base. Z coordinate on CITY Datum only. c) Descriptive Location (Ex. Set in the centerline of the inlet in the South curb line of North Side Drive at the East end of radius at the Southeast corner of North Side Drive and North Main Street). - Coordinates on all P.C.'s, P.T.'s, P.l.'s, Manholes, Valves, etc., in the same coordinate system, as the Control. - No less than two horizontal bench marks, per line or location. - Bearings given on all proposed centerlines, or baselines. - Station equations relating utilities to paving, when appropriate. 8.2. Temporary Right of Entry Preparation and Submittal • Prior to entering property, the ENGINEER shall prepare and submit Temporary Right of Entry for landowners to CITY PM. • The documentation shall be provided in conformance with the checklists and templates available on the CITY's Buzzsaw site. ASSUMPTIONS • Topographic survey at intersection will include no more than 100 ft. in each direction. DELIVERABLES City of Fort Worth,Texas Attachment A PMO Release Date:08.1.2014 Page 15 of 17 ATTACHMENT A DESIGN SERVICES FOR NEAR SOUTHSIDE MEDICAL DISTRICT WATER AND SANITARY SEWER MAIN IMPROVMENTS CITY PROJECT NO.:02445 A. Copies of field survey data and notes signed and sealed by a licensed surveyor. B. Drawing of the project layout with dimensions and coordinate list. ADDITIONAL SERVICES NOT INCLUDED IN THE EXISTING SCOPE OF SERVICES Additional Services not included in the existing Scope of Services — CITY and ENGINEER agree that the following services are beyond the Scope of Services described in the tasks above. However, ENGINEER can provide these services, if needed, upon the CITY's written request. Any additional amounts paid to the ENGINEER as a result of any material change to the Scope of the Project shall be agreed upon in writing by both parties before the services are performed. These additional services include the following: • Negotiation of easements or property acquisition including temporary right-of-entries. • Services related to development of the CITY's project financing and/or budget. • Services related to disputes over pre-qualification, bid protests, bid rejection and re- bidding of the contract for construction. • Construction management and inspection services • Periodic site visits during construction phase • Design phase public meetings • Performance of materials testing or specialty testing services. • Services necessary due to the default of the Contractor. • Services related to damages caused by fire, flood, earthquake or other acts of God. • Services related to warranty claims, enforcement and inspection after final completion. • Services related to submitting for permits (ie.TxDOT, railroad, etc...) • Services related to Subsurface Utility Engineering Levels A, B, C or D • Services related to Survey Construction Staking • Services related to acquiring real property including but not limited to easements, right-of-way, and/or temporary right-of-entries. • Service related to Right-of-Way base mapping • Service related to property ownership verification or boundary survey services • Services to support, prepare, document, bring, defend, or assist in litigation undertaken or defended by the CITY. City of Fort Worth,Texas Attachment A PMO Release Date:08.1.2014 Page 16 of 17 ATTACHMENT A DESIGN SERVICES FOR NEAR SOUTHSIDE MEDICAL DISTRICT WATER AND SANITARY SEWER MAIN IMPROVMENTS CITY PROJECT NO.:02445 • Construction Shop drawing review, samples and other submittals submitted by the contractor. • Performance of miscellaneous and supplemental services related to the project as requested by the CITY. City of Fort Worth,Texas Attachment A PMO Release Date:08.1.2014 Page 17 of 17 11/17/14 ATTACHMENT B COMPENSATION DESIGN SERVICES FOR NEAR SOUTHSIDE MEDICAL DISTRICT WATER AND SANITARY SEWER MAIN IMPROVMENTS City Project No.:02445 I. Compensation A. The ENGINEER shall be compensated a total lump sum fee of$107,,865 as summarized in Exhibit B-1-Engeener Invoice and Section IV-Summary of Total Project Fees. The total lump sum fee shall be considered full compensation for the services described in Attachment A, including all labor materials, supplies, and equipment necessary to deliver the services. B. The ENGINEER shall be paid monthly payments as described in Section II - Method of Payment. II. Method of Payment A. Partial payment shall be made to the ENGINEER monthly upon City's approval of an invoice prepared and submitted by the ENGINEER in the format and including content as presented in Exhibit B-1, Progress Reports as required in item III. of this Attachment B, and Schedule as required in Attachment D to this Agreement. B. The estimated current physical percent complete as required on the invoice shall be calculated from the progress schedule as required in Attachment D to this Standard Agreement and according to the current version of the City of Fort Worth's Schedule Guidance Document. C. The cumulative sum of such monthly partial fee payments shall not exceed the total current project budget including all approved Amendments. D. Each invoice shall be verified as to its accuracy and compliance with the terms of this Agreement by an officer of the ENGINEER. III. Progress Reports A. The ENGINEER shall prepare and submit to the designated representative of the Transportation and Public Works Departmen monthly progress reports and schedules in the format required by the City. City of Fort Worth,Texas Attachment B PMO Official Release Date:08.09.2012 Page 1 B-1 11/17/14 ATTACHMENT B COMPENSATION IV. Summary of Total Project Fees Firm Primary Responsibility Fee Amount I Fee % Prime Consultant A.N.A. Consultants, L.L.C. En ineerin , Surveying, and Project Management 1 $ 93,865 87% Proposed M/WBE Sub-Consultants Ground Engineering Group Engineering Design Services $ 14,000—F-1 3% Total $ 107,865 100% M/WBE Project Number& Name Total Fee M/WBE Fee % City Project No. 02445 W and SS CD 9 FW South FY15 $107,865.00 $ 14,000 13% City M/WBE Goal= 10% Consultant Committed Goal= 13% City of Fort Worth,Texas Attachment B PMO Official Release Date:08.09.2012 Page 2 B-2 11/17/14 EXHIBIT "B-1" ENGINEER INVOICE (Supplement to Attachment B) Insert required invoice format following this page, including negotiated total budget and allocations of budgets across work types and work phases. City of Fort Worth,Texas Attachment B PMO Official Release Date:08.09.2012 Page 3 B-3 }� \ \ �\ § ); E (\ 3 _ 13 )j! \ CL 0 _ \ \) ) ) \` \ m - \ \ §! cu � \ \ LU } E \ C 2 (2 ! /\ ; m \ / 2 ) - ` / - - � / § E ! ƒ \ g f \ LS { / kU3 _ J � - § ` ® \ \ ) \k u ) \ } ) / / $ § ` E z - \ jC --(§;� ) 7\ \ E /x (000 a ab u L)CLF- A ) ! J ] ) ! S 0 000 000in_cno0 h0cn v>o��o�no 00 000 0 o0moo 00o coon o0 oc O r°� 4) N O� tnNOr NORM O mN NAm Q) O V Nm NN V wwww `N (n hO O C m(O Z(7 m 0 O m A 6 p m fA�tA N4 r O r wN � � �of N r�wm m A Vi N t9 t9m www ,p V � w � to en w f9 fn w N w fn to t9 Vi w w �� w to N N R w N 0 U O 1 O . U) w Oz o Y Ir Z F 0 O � N 0 0 0 0 0 0 0.0 0 O O 0 0 0 O 0 0 0 0 0 O O O 0 0 0 0 O O O Z a ° w en ss e»en en enwen- www orn e»<»o oe»en eno eno we»w f» vi en wwo en eno wenwe» ww o Q3a � h oen o o en v> o gw< �Oz K N° w w w U Q w 3 U w A Cl) H Ir c w w w w w w w w w Q o Z a Q o Z a Ir w y W W ow w w N w w w 3 C m Ir d 3 � x c w c F o Cl) Z Z Q W O O O O O O O O O O O O O O J U w w O O O 00 O w O O w w 00 Q a w O N 3 w w e» w e» w w Ca Q C O 0 0 0 0 0 0 0 0 0 0 N e 00 i O N 0�0 0 O O O O O O O O O O O O O O O O O h c o A O rm rN d) NAO) N No LOONm O ON NAm Q7 md'chNm NNC MwVj EA N N m = (O C'J M R m f 0 tID M m 0 Y9 c0 A m O A O Z N 4J c+j t9 V3 en cV r O r wN� eD �.-m ��A O)N � h r r r enw� wfn� V a N j QJ O w w to Ela w w en Nw end 69 w tY Vi w fA En V) w fA M 0 U U ~ W W o o O O O O O O O O Z m C w W E (n Z Q n o 0 0 0 0 0 m Vl O Q Nap a QZ v m �' Q w � c ,U O U) W �.a3i eo 0 0 o mrn m QZ Z m � m d2 O � UD) W d ii C ~ o o mm aov v amo m am oo mo 0 0 o ere U1 M X p rnQ Q N N N O m 0m mm M LLJ j U) L) U w J ~ s N N N m m O b 0 y r c0 N M N N p J U QQ _U awy p W M O O r r a N r N r O d' N, O N V NNN N N m O r C cO N W w p d m N O C = a`E H O O O O O O O O O O m N N N A N Q. o. Q c W a Z ° N C N K m O a F" o _ p r o 0 0 m Q o - E o m ni a v " a - ac m c0 E a a m m m °' r g o 0 o E- �j m o p d m m a a m vJ o g 2 c� o rn m`�' u y = ` N cnNdeN Umcm`of0 ❑�O�> D'0cE �lfU Na_d cc ayo aNm aYac -aCO°m maaoaci``0vc w°cmry'owoN W �CO a � o N� M E -a E o . amoui E 0 ~v E 5 w 0 3 Emo m d'ut WoJo LoEto UUo UwU r o a¢ooaiam ¢ OL aU,01 m :DQU)ii aUm_ L) 'T Q ci awm mc I I U Q O Z N N N N N N N N Y NNN r M[+J M t 7 M N m r N O M O O y � O f V� O m m[+]O V V <V O • p A A A O N r r r lV •7� M V N eG 1� m m in000 o�o Doco oo o«»o to ino v o vo ui Fv� oO N Z Z LL m.J O y ZLL.O xoz J t0 t0 C C U V U Q n W O O d E O 3 d 'o u)u) wa a ww m � � m m o u)m co wwom m z m z N o z Z Q x W H Q 3 U f' U Z 0 W rL U cl O Ljj n W a o Z Q o w W z W N } y ZLO Q F- N v 0 o Q DLu o F_ cnw � QZ m m m owcw co Cf) , '2 Wo = 'o IL m � � o p V o j Cn U o y Q o o J F- N omm oaai m`� N 3 d r p cW mm L l N 7 N W o Uz 2. m dvm�co°' p mm H >>m � N ONE O D C C O N O N� U) LL r ry 3 N �fA Q W r Z Q m U m E M� � r ) r N w N 7 (0 A N D y_ m"E c r v o o v o va 3m o aci LL E o� �< U Q 5000 Thompson Terrace Colleyville,TX 76034 (817)335-9900 FAX(817)335-9955 CONSULTANTS, EXHIBIT B-3 SUMMARY OF OPINION OF PROBABLE CONSTRUCTION COST NEAR SOUTHSIDE MEDICAL DISTRICT WATER AND SANITARY SEWER MAIN IMPROVMENTS City Project No.02445 November 12,2014 N Water Main Sewer Main d Location Construction Construction Total Construction E m College Street W. Broadway-Vickery) $100,864.00 $0.00 $100,864.00 o Jarvis Street(Lipscomb-College) $11,725.00 $12,372.00 $24,097.00 EJennings Street 200-ft North of Oleander-Magnolia) $103,990.00 $0.00 $103,990.00 Leuda Street IS. Main-St. Louis $91,282.00 $0.00 $91,282.00 `m Lipscomb Street(Vickery-Pennsylvania) $190,105.00 $0.00 $190,105.00 Q May Street(Magnolia-Feliks Gwozdz $104,266.00 $0.00 $104,266.00 VJ Peter Smith Street(Hemphill-Fulton $78,124.00 $73,580.00 $151,704.00 TOTAL CONSTRUCTION COST $680,356.00 $85,952.00 $766,308.00 M20%CONTINGENCIES $136,071.20 $17,190.40 $153,261.60 TOTAL ESTIMATED CONSTRUCTION COST $816,427.20 $103,142.40 $919,569.60 -j- L—J Percent of Construction Cost 88.78% 11.22% 100.00% Since ENGINEER has no control over the cost of labor,materials,equipment or services furnished by others,or over the Contractor(s) methods of determining prices,or over competitive bidding or market conditions,ENGINEER's opinions of probable Total project Costs and Construction Cost provided for herein are made on the basis of ENGINEER's experience and qualifications and represent ENGINEER's best judgment as an experienced and qualified professional engineer,familiar with the construction industry;but ENGINEER cannot and does not guarantee that proposals,bids or actual Total Project or Construction Costs will not vary from opinions of probable cost prepared by ENGINEER. If prior to the Bidding or Negotiating Phase OWNER wishes greater assurance to the Construction Cost he shall employ an independent cost estimator. Company:JOBA40410:Contract:Exhibit B-3 FW South-02445-ANA14-0410.x1sx 11/19/14 8:29AM 8 -� ESTIMATED CONST COST Summery ® 5000 Thompson Terrace Colleyville,TX 76034 (817)335-9900 FAX(817)335-9955 CONSULTANTS,L.L.G. ���� EXHIBIT B-3 NEAR SOUTHSIDE MEDICAL DISTRICT WATER AND SANITARY SEWER MAIN IMPROVMENTS City Project No.02445 SUMMARY OF QUANITIES November 12,2014 m s' Q m rn � rn to to a y a L m t c m u w CPMS BID Q n n - L r UNIT NO. DESCRIPTION a AUNTY UNIT COST SUB-TOTAL WATER CONSTRUCTION COST BID-XXXX Abandoning of Existing 2"Water Pie 469 469 LF $25.00 $11,725.00 Pipe-Pressure-12 Inch—Install;12"PVC(Includes Removal orAbandoning of BID-00591 Existing Water Pie) 960 630 1,590 LF $54.00 $85,860.00 Pipe-Pressure-8 Inch—Install;8"PVC(Includes Removal orAbandoning of BID-00618 Existing Water Pie) 730 1585 878 730 3,923 LF $28.00 $109,844.00 BID-00547 Fire Hydrant—Remove 1 2 3 2 1 9 EA $360.00 $3,240.00 BID-00546 Fire Hydrant—Install 1 2 3 2 1 9 EA $2,760.00 $24,840.00 BID-00548 Fire Hydrant-Barrel&Stem Extension—Install 5 10 15 10 5 45 VF $312.00 $14,040.00 BID-00568 Pie Fittings-<Than 16 Inch DI Pipe—Install 0.5 0.5 0.5 1 0.5 0.5 4 TON $5,400.00 $18,900.00 BID-00762 Water Service-1 Inch-Tap to Main—Install 22 30 16 45 18 7 138 EA $360.00 $49,680.00 BID-00758 Water Service-1 Inch—Install;Install 1-Inch Copper Service from Main to Meter 660 900 480 1350 540 210 4,140 LF $13.00 $53,820.00 BID-00550 Meter Box-Class A—Install;Class"A"Plastic Meter Box Complete in Place 22 1 30 16 45 18 7 138 EA $192.00 $26,496.00 Water Service-2 Inch-Temporary—Install;Furnish and Lay 2-Inch Pipe and BID-00768 Fittings for Temora Water Service Connection 1 1 1 1 1 1 1 LS $21,600.00 $21,600.00 Pavement-2 Inch Min HMAC on 2/27 Concrete Base(STR-028)—Install; BID-00443 Permanent Asphalt Pavement Repair 630 730 1585 878 730 4,553 LF $45.00 $204,885.00 Pavement-2 Inch HMAC on 6 Inch Flex Base-Temporary—Install;Temporary BID-00442 Asphalt Pavement Repair Per Std.STR-030 960 960 LF $10.00 $9,600.00 BID-00430 Pavement—Instal;2"Inch HMAC Pavement Repair Outside of Trench Width 50 50 50 50 50 50 300 SY $24.00 $7,200.00 BID-00372 Trench SafetySystem 5 Foot Depth—Install 960 630 730 1585 878 730 5,513 LF $2.00 $11,026.00 BID-00099 Storm Water Pollution Prevention Plan<Than 1 Ac SWPPP—Install 1 1 1 1 1 1 1 LS $9,600.00 $9,600.00 BID-01189 Signal-Traffic Control-Design&Provide,—Install 1 1 1 1 1 1 1 LS $18,000.00 $18,000.00 Subtotal Section WATER $680,356.00 m m a in 00 .y L inn m to a O1 c C) o a E a CPMS BID tj , NO. DESCRIPTION J ti AUNTY UNIT UNIT COST SUB-TOTAL SANITARY SEWER CONSTRUCTION COST BID-00351 Pipe-Sewer-8 Inch-SDR35 All Depths)—Install;by Oen Cut 50 1 620 670 LF $42.00 $28,140.00 BID-00258 Pipe-Sewer-12 Inch-SDR26 All Depths)—Install;by Oen Cut 50 50 LF $52.00 $2,600.00 Sewer Service-4 Inch—Install;4-Inch PVC Sanitary Sewer Service Line by Open BID-00354 Cut,all Depths 180 180 LF $30.00 $5,400.00 BID-00355 Sewer Service-4 Inch Service Ta —Install 6 6 EA $240.00 $1,440.00 BID-00213 Manhole-Std 4 Ft Diam to 6 Ft Depth)—Install 2 5 7 EA $2,880.00 $20,160.00 BID-00214 Manhole-Std 4 Ft Diam-Added Depth over 6 Ft Depth)—Install 4 4 VF $180.00 $720.00 Pavement-2 Inch Min HMAC on 2/27 Concrete Base(STR-028)—Install; BID-00443 Permanent Asphalt Pavement Repair 50 620 6701 LF $30.00 $20,100.00 BID-00217 Manhole-VacuumTest—Services 2 5 7 EA $144.00 $1,008.00 BID-00206 IM22hole—Remove 2 57 EA $312.00 $2,184.00 BID-011139 Si nal-Traffic Control-Design&Provide,—Install 1 1 1 LS $2,760.00 $2,760.00 BID-00099 Storm Water Pollution Prevention Plan<Than 1 Ac SWPPP—Install 1 1 1 LS $1,440.00 $1,440.00 Subtotal Section SEWER $85,952.00 Sub-Total Water Improvements $680,356.00 Sub-Total Sewer Improvements $85,952.00 Proect Total $766,308.00 Since ENGINEER hes no control over the cost of labor,materials,equipment or services furnished by adws,or over the Conbaclor(s) methods of determining prices,or war compellihm bidding or market conditions,ENGINEER'S opinion of probable Total project Coale and Construction Cost provided for heroin ere made on the basis of ENGINEER's experience and qualifications and represent ENGINEER's best Judgment as an experienced and qualified professional engineer,familiar with the oonsbucaon industry,b°d ENGINEER cannot and does not guarantee that proposals,bids or achal Total Project or Construction Costa will not vary from opinions of probable cost prepared by ENGINEER. If prior to the Bidding or Negotiating Phase OWNER wishes greater assurance to the Construction Cost he shelf employ an Independent cost estimator. Company:JOB:140410:Cantract:Exh@0 B-3 FW South-02445-ANA14-0410.xlsx 11/19/14 8:04 AM ESTIMATED CONST.COST College - 5000 Thompson Terrace Colleyville,TX 76034 (817)335-9900 FAX(817)335-9955 CCRMLTANTS, EXHIBIT B-3 NEAR SOUTHSIDE MEDICAL DISTRICT WATER AND SANITARY SEWER MAIN IMPROVMENTS City Project No.02445 College Street(W. Broadway -Vickery) OPINION OF PROBABLE WATER CONSTRUCTION COST November 12,2014 CPMS BID NO. DESCRIPTION QUANTITY UNIT UNIT COST SUB-TOTAL Pipe-Pressure-12 Inch—Install;12"PVC(Includes Removal or Abandoning of Existing Water BID-00591 Pipe) 960 LF $54.00 $51,840.00 BID-00547 Fire Hydrant—Remove 1 EA $360.00 $360.00 BID-00546 Fire Hydrant—Install 1 EA $2,760.00 $2,760.00 BID-00548 Fire Hydrant-Barrel&Stem Extension—Install 5 VF $312.00 $1,560.00 BID-00568 Pipe Fittings-<Than 16 Inch DI Pipe—Install 0.5 TON $5,400.00 $2,700.00 BID-00762 Water Service-1 Inch-Tap to Main—Install 22 EA $360.00 $7,920.00 BID-00758 Water Service-1 Inch—Install;Install 1-Inch Copper Service from Main to Meter 660 LF $13.00 $8,580.00 BID-00550 Meter Box-Class A—Install;Class"A"Plastic Meter Box Complete in Place 22 EA $192.00 $4,224.00 Water Service-2 Inch-Temporary—Install;Furnish and Lay 2-Inch Pipe and Fittings for Temporary BID-00768 Water Service Connection 1 LS $3,600.00 $3,600.00 Pavement-2 Inch HMAC on 6 Inch Flex Base-Temporary—Install;Temporary Asphalt Pavement BID-00442 Repair Per Std.STR-030 960 LF $10.001 $9,600.00 BID-00430 Pavement—Instal;2"Inch HMAC Pavement Repair Outside of Trench Width 50 SY $24.00 $1,200.00 BID-00372 Trench Safety System 5 Foot Depth—Install 960LF $2.00 $1,920.00 BID-00099 Storm Water Pollution Prevention Plan< Than 1 Ac SWPPP—Install 1 LS $1,600.00 $1,600.00 BID-01189 Signal-Traffic Control-Design&Provide,—Install 1 LS $3,000.00 $3,000.00 Subtotal Section WATER ------------------------------- $100,864.00 Since ENGINEER has no control over the cost of labor,materials,equipment or services fumished by others,or over the Contractors) methods of determining prices,or over competitive bidding or market conditions,ENGINEER's opinions of probable Total project Costs and Construction Cost provided for herein are made on the basis of ENGINEER's experience and qualifications and represent ENGINEER's best judgment as an experienced and qualified professional engineer,familiar with the construction industry;but ENGINEER cannot and does not guarantee that proposals,bids or actual Total Project or Construction Costs will not vary from opinions of probable cost prepared by ENGINEER. If prior to the Bidding or Negotiating Phase OWNER wishes greater assurance to the Construction Cost he shall employ an independent cost estimator. Estimated Construction Cost-Water $100,864.00 Estimated Construction Cost Sewer $0.00 Total Estimated Construction Cost-Water&Sewer $100,864.00 Company:JOB:140410:ContractExhibit B-3 FW South-02445-ANA14-0410.xlsx 11/19/14 7:59AM ESTIMATED CONST COST Jarvis - 5000 Thompson Terrace (817)335-9 00 76034 ASK (817)335-9900 FAX(817)335-9955 CONWLTANTS L.L-C. it ISA EXHIBIT B-3 NEAR SOUTHSIDE MEDICAL DISTRICT WATER AND SANITARY SEWER MAIN IMPROVMENTS City Project No.02445 Jarvis Street (Lipscomb -College) OPINION OF PROBABLE WATER CONSTRUCTION COST November 12,2014 CPMS BID ITEM NO. NO. DESCRIPTION QUANTITY UNIT UNIT COST SUB-TOTAL BID-XXXX Abandoning of Existing 2"Water Pipe 469 LF $25.00 $11,725.00 Subtotal Section WATER ---__----------____________ $11,725.00 SEWER CONSTRUCTION COST CPMS BID ITEM NO. NO. DESCRIPTION QUANTITY UNIT UNIT COST SUB-TOTAL BID-00351 Pi e-Sewer-8 Inch-SDR35 All Depths)-Install;by Oen Cut 50 LF $42.00 $2,100.00 BID-00213 Manhole-Std 4 Ft Diam-(to 6 Ft Depth)-Install 2 EA $2,880.00 $5,760.00 Pavement-2 Inch Min HMAC on 2/27 Concrete Base(STR-028)-Install;Permanent Asphalt BID-00443 Pavement Repair 50 LF $30.00 $1,500.00 BID-00217 Manhofe-Vacuum Test-Services 2 EA $144.00 $288.00 BID-00206 Manhole-Remove 2 EA $312.00 $624.00 BID-01189 Si nal-Traffic Control-Desi n&Provide,-Install 1 LS $1,380.00 $1,380.00 BID-00099 Storm Water Pollution Prevention Plan< Than 1 Ac SWPPP-Install 11 LS 1 $720.001 $720.00 Subtotal Section ISEWER ------------------------ $12,372.00 Since ENGINEER has no control over the cost of labor,materials,equipment or services furnished by others,or over the Contractor(s) methods of determining prices,or over competitive bidding or market conditions,ENGINEER's opinions of probable Total project Costs and Construction Cost provided for herein are made an the basis of ENGINEER's experience and qualifications and represent ENGINEER's best judgment as an experienced and qualified professional engineer,familiar with the construction industry;but ENGINEER cannot and does not guarantee that proposals,bids or actual Total Project or Construction Costs will not vary from opinions of probable cost prepared by ENGINEER. If prior to the Bidding or Negotiating Phase OWNER wishes greater assurance to the Construction Cost he shall employ an independent cost estimator. Estimated Construction Cost-Water $11,725.00 Estimated Construction Cost Sewer $12,372.00 Total Estimated Construction Cost-Water&Sewer $24,097.00 Company:JOB:140410:ConlractExhibit B-3 FW South-02445-ANA14-0410.x1sx 11/19/14 8:33 AM ESTIMATED CONST.COST Jennings - 5000 Thompson Terrace Colley5 76034 A%k (817)3335-9-990000 FAX(817)335-9955 aowaur tours u e. - EXHIBIT B-3 NEAR SOUTHSIDE MEDICAL DISTRICT WATERAND SANITARY SEWER MAIN IMPROVMENTS City Project No.02445 Jennings Street (200-ft North of Oleander- Magnolia) OPINION OF PROBABLE WATER CONSTRUCTION COST November 12,2014 CPMS BID NO. DESCRIPTION QUANTITY UNIT UNIT COST SUB-TOTAL Pipe-Pressure-12 Inch-Install;12"PVC(Includes Removal or Abandoning of Existing Water BID-00591 Pipe) 630 LF $54.00 $34,020.00 BID-00568 Pipe Fittings-<Than 16 Inch DI Pipe-Install 0.5 TON $5,400.00 $2,700.00 BID-00762 Water Service-1 Inch-Tap to Main-Install 30 EA $360.00 $10,800.00 BID-00758 Water Service-1 Inch-Install;Install 1-Inch Copper Service from Main to Meter 900 LF $13.00 $11,700.00 BID-00550 Meter Box-Class A-Install;Class"A"Plastic Meter Box Complete in Place 30 EA $192.00 $5,760.00 Water Service-2 Inch-Temporary-Install;Furnish and Lay 2-Inch Pipe and Fittings for Temporary BID-00768 Water Service Connection 1 LS $3,600.00 $3,600.00 Pavement-2 Inch Min HMAC on 2/27 Concrete Base(STR-028)-Install;Permanent Asphalt BID-00443 Pavement Repair 630 LF $45.00 $28,350.00 BID-00430 Pavement-Instal;2"Inch HMAC Pavement Repair Outside of Trench Width 50 SY $24.00 $1,200.00 BID-00372 Trench Safety System 5 Foot Depth-Install 630 LF $2.00 $1,260.00 BID-00099 Storm Water Pollution Prevention Plan< Than 1 Ac SWPPP-Install 1 LS $1,600.00 $1,600.00 BID-01189 Signal-Traffic Control-Design&Provide,-Install 1 LS $3,000.00 $3,000.00 Subtotal Section IWATER ------------------------------- $103,990.00 Since ENGINEER has no control over the cost of labor,materials,equipment or services furnished by others,or over the Contractor(s) methods of determining prices,or over competitive bidding or market conditions,ENGINEER's opinions of probable Total project Costs and Construction Cost provided for herein are made on the basis of ENGINEER's experience and qualifications and represent ENGINEER's best judgment as an experienced and qualified professional engineer,familiar with the construction industry;but ENGINEER cannot and does not guarantee that proposals,bids or actual Total Project or Construction Costs will not vary from opinions of probable cost prepared by ENGINEER. If prior to the Bidding or Negotiating Phase OWNER wishes greater assurance to the Construction Cost he shall employ an independent cost estimator. Estimated Construction Cost-Water $103,990.00 Estimated Construction Cost Sewer $0.00 Total Estimated Construction.Cost-Water&Sewer $103,990.00 Company:JOB:140410:Contract Exhibit B-3 FW South-02445-ANA 14-0410.xlsx 11/19114 7:59 AM ESTIMATED CONST.COST Leuda - 5000 Thompson Terrace Colleyville,TX 76034 (817)335-9900 FAX(817)335-9955 calm TS,L. X. ~ EXHIBIT B-3 NEAR SOUTHSIDE MEDICAL DISTRICT WATER AND SANITARY SEWER MAIN IMPROVMENTS City Project No.02445 Leuda Street (S. Main -St. Louis) OPINION OF PROBABLE WATER CONSTRUCTION COST November 12,2014 CPMS BID NO. DESCRIPTION QUANTITY UNIT UNIT COST SUB-TOTAL BID-00618 Pipe-Pressure-8 Inch—Install;8"PVC Includes Removal or Abandoning of Existing Water Pie 730 LF $28.00 $20,440.00 BID-00547 Fire Hydrant—Remove 2 EA $360.00 $720.00 BID-00546 Fire Hydrant—Install 2 EA $2,760.00 $5,520.00 BID-00548 Fire Hydrant-Barrel&Stem Extension—Install 10 VF $312.00 $3,120.00 BID-00568 Pie Fittings-<Than 16 Inch DI Pipe—Install 0.5 TON $5,400.00 $2,700.00 BID-00762 Water Service-1 Inch-Tap to Main—Install 16 EA $360.00 $5,760.00 BID-00758 Water Service-1 Inch—Install;Install 1-Inch Copper Service from Main to Meter 480 LF $13.00 $6,240.00 BID-00550 Meter Box-Class A—Install;Class"A"Plastic Meter Box Complete in Place 16 EA $192.00 $3,072.00 Water Service-2 Inch-Temporary—Install;Furnish and Lay 2-Inch Pipe and Fittings for Temporary BID-00768 Water Service Connection 1 LS $3,600.00 $3,600.00 Pavement-2 Inch Min HMAC on 2/27 Concrete Base(STR-028)—Install;Permanent Asphalt BID-00443 Pavement Repair 730 LF $45.00 $32,850.00 BID-00430 Pavement—Instal;2"Inch HMAC Pavement Repair Outside of Trench Width 501 SY 1 $24.001 $1,200.00 BID-00372 Trench Safety System 5 Foot Depth—Install 730 LF $2.00 $1,460.00 BID-00099 Storm Water Pollution Prevention Plan< Than 1 Ac SWPPP—Install 11 LS $1,600.00 $1,600.00 BID-01189 Signal-Traffic Control-Design&Provide,—Install 11 LS 1 $3,000.001 $3,000.00 Subtotal Section IWATER -------—---—------------- $911,282.00 Since ENGINEER has no control over the cost of labor,materials,equipment or services furnished by others,or over the Contractor(s) methods of determining prices,or over competitive bidding or market conditions,ENGINEER's opinions of probable Total project Costs and Construction Cost provided for herein are made on the basis of ENGINEER's experience and qualifications and represent ENGINEER's best judgment as an experienced and qualified professional engineer,familiar with the construction industry;but ENGINEER cannot and does not guarantee that proposals,bids or actual Total Project or Construction Costs will not vary from opinions of probable cost prepared by ENGINEER. If prior to the Bidding or Negotiating Phase OWNER wishes greater assurance to the Construction Cost he shall employ an independent cost estimator. Estimated Construction Cost-Water $91,282.00 Estimated Construction Cost Sewer $0.00 Total Estimated Construction Cost-Water&Sewer $91,282.00 Company:JOB:140410:Contract:Exhibit B-3 FW South-02445-ANA14-0410.xlsx 11/19/14 7:59 AM ESTIMATED CONST.COST Lipscomb - 5000 Thompson Terrace Colleyville,TX 76034 (817)335-9900 _ FAX(817)335-9955 CONS TS,L.. C. Oi -- EXHIBIT B-3 NEAR SOUTHSIDE MEDICAL DISTRICT WATER AND SANITARY SEWER MAIN IMPROVMENTS City Project No.02445 Lipscomb Street (Vickery - Pennsylvania) OPINION OF PROBABLE WATER CONSTRUCTION COST November 12,2014 CPMS BID NO. DESCRIPTION UANTI UNIT UNIT COST SUB-TOTAL BID-00618 Pipe-Pressure-8 Inch—Install;8"PVC Includes Removal or Abandoning of Existing Water Pipe 1585 LF $28.00 $44,380.00 BID-00547 Fire Hydrant—Remove 3 EA $360.00 $1,080.00 BID-00546 Fire Hydrant—Install 3 EA $2,760.00 $8,280.00 BID-00548 Fire hydrant-Barrel&Stem Extension—Install 15 VF $312.00 $4,680.00 BID-00568 Pipe Fittings-<Than 16 Inch DI Pipe—Install 1 TON $5,400.00 $5,400.00 BID-00762 Water Service-1 inch-Tap to Main—Install 45 EA $360.00 $16,200.00 BID-00758 Water Service-1 Inch—Install;Install 1-Inch Copper Service from Main to Meter 1350 LF $13.00 $17,550.00 BID-00550 Meter Box-Class A—Install;Class"A"Plastic Meter Box Complete in Place 45 EA $192.00 $8,640.00 Water Service-2 Inch-Temporary—Install;Furnish and Lay 2-Inch Pipe and Fittings for Temporary BID-00768 Water Service Connection 1 LS $3,600.00 $3,600.00 Pavement-2 Inch Min HMAC on 2/27 Concrete Base(STR-028)—Install;Permanent Asphalt BID-00443 Pavement Repair 1585 LF $45.00 $71,325.00 BID-00430 Pavement—Instal;2"Inch HMAC Pavement Repair Outside of Trench Width 50 SY $24.00 $1,200.00 BID-00372 Trench Safety System 5 Foot Depth—Install 1585LF $2.00 $3,170.00 BID-00099 Storm Water Pollution Prevention Plan< Than 1 Ac SWPPP—Install 1 LS $1,600.001 $1,600.00 BID-01189 Signal-Traffic Control-Design&Provide,—Install 11 LS 1 $3,000.001 $3,000.00 Subtotal Section WATER ----------------------—----— $190,105.00 Since ENGINEER has no control over the cost of labor,materials,equipment or services furnished by others,or over the Contractor(s) methods cf determining prices,or over competitive bidding or market conditions,ENGINEER's opinions of probable Total project Costs and Construction Cost provided for herein are made on the basis of ENGINEER's experience and qualifications and represent ENGINEER's best judgment as an experienced and qualified professional engineer,familiar with the construction industry;but ENGINEER cannot and does not guarantee that proposals,bids or actual Total Project or Construction Costs will not vary from opinions of probable cost prepared by ENGINEER. If prior to the Bidding or Negotiating Phase OWNER wishes greater assurance to the Construction Cost he shall employ an independent cost estimator. Estimated Construction Cost-Water $190,105.00 Estimated Construction Cost Sewer $0.00 Total Estimated Construction Cost-Water&Sewer $190,105.00 Company:JOB:14 04 10:Contract:Exhibit B-3 FW South-02445-ANA14-0410.xlsx 11/19/14 7:59 AM ESTIMATED CONST.COST May - 5000 Thompson Terrace (817)335-9 00 76034 (817)335-9900 FAX(817)335-9955 CONOULTANTS LL.C. -- EXHIBIT B-3 NEAR SOUTHSIDE MEDICAL DISTRICT WATER AND SANITARY SEWER MAIN IMPROVMENTS City Project No.02445 May Street (Magnolia -Feliks Gwozdz) OPINION OF PROBABLE WATER CONSTRUCTION COST November 12,2014 CPMS BID NO. DESCRIPTION QUANTITY UNIT UNIT COST SUB-TOTAL BID-00618 Pipe-Pressure-8 Inch—Install;8"PVC Includes Removal or Abandoning of Existing Water Pipe 878 LF $28.00 $24,584.00 BID-00547 Fire Hydrant—Remove 2 EA $360.00 $720.00 BID-00546 Fire Hydrant—Install 2 EA $2,760.00 $5,520.00 BID-00548 Fire Hydrant-Barrel&Stem Extension—Install 10 VF $312.00 $3,120.00 BID-00568 Pipe Fittings-<Than 16 Inch DI Pipe—Install 0.5 TON $5,400.00 $2,700.00 BID-00762 Water Service-1 Inch-Tap to Main—Install 18 EA $360.00 $6,480.00 BID-00758 Water Service-1 Inch—Install;Install 1-Inch Copper Service from Main to Meter 540 LF $13.00 $7,020.00 BID-00550 Meter Box-Class A—Install;Class"A"Plastic Meter Box Complete in Place 18 EA $192.00 $3,456.00 Water Service-2 Inch-Temporary—Install;Furnish and Lay 2-Inch Pipe and Fittings for Temporary BID-00768 Water Service Connection 1 LS $3,600.00 $3,600.00 Pavement-2 Inch Min HMAC on 2127 Concrete Base(STR-028)—Install;Permanent Asphalt BID-00443 Pavement Repair 878 LF $45.00 $39,510.00 BID-00430 Pavement—Instal;2"Inch HMAC Pavement Repair Outside of Trench Width 50 SY $24.00 $1,200.00 BID-00372 Trench Safety System 5 Foot Depth—Install 878 LF $2.00 $1,756.00 BID-00099 Storm Water Pollution Prevention Plan< Than 1 Ac SWPPP—Install 1 LS $1,600.00 $1,600.00 BID-01189 Signal-Traffic Control-Design&Provide,—Install 1 LS $3,000.00 $3,000.00 Subtotal Section WATER -------------------------------- $104,266.00 Since ENGINEER has no control aver the cost of labor,materials,equipment or services furnished by others,or over the Contractor(s) methods of determining prices,or over competitive bidding or market conditions,ENGINEER's opinions of probable Total project Costs and Construction Cost provided for herein are made on the basis of ENGINEER's experience and qualifications and represent ENGINEER's best judgment as an experienced and qualified professional engineer,familiar with the construction industry;but ENGINEER cannot and does not guarantee that proposals,bids or actual Total Project or Construction Costs will not vary from opinions of probable cost prepared by ENGINEER. If prior to the Bidding or Negotiating Phase OWNER wishes greater assurance to the Construction Cost he shall employ an independent cost estimator. Estimated Construction Cost-Water $104,20�22 Estimated Construction Cost Sewer Total Estimated Construction Cost-Water&Sewer $104,2 Company:J0 B:14041 O:Contract:Exhibit B-3 FW South-02445-ANAs 4-0410.x1 sx 11/19/14 7:59 AM ESTIMATED CONST.COST PeterSmith 5000 Thompson Terrace Colleyville,TX 76034 AN" (817)335-9900 FAX(817)335-9955 0011111 ANTS,L.L.C. -- EXHIBIT B-3 NEAR SOUTHSIDE MEDICAL DISTRICT WATER AND SANITARY SEWER MAIN IMPROVMENTS City Project No.02445 Peter Smith Street (Hemphill - Fulton) OPINION OF PROBABLE WATER CONSTRUCTION COST November 12,2014 CPMS BID NO. DESCRIPTIO`: QUANTITY UNIT UNIT COST SUB-TOTAL BID-00618 Pipe-Pressure-8 Inch-Install;8"PVC Includes Removal or Abandoning of Existing Water Pipe 730 LF $28.00 $20,440.00 BID-00547 Fire Hydrant-Remove 1 EA $360.00 $360.00 BID-00546 Fire Hydrant-Install 1 EA $2,760.00 $2,760.00 BID-00548 Fire Hydrant-Barrel&Stem Extension-Install 5 VF $312.00 $1,560.00 BID-00568 Pipe Fittings-<Than 16 Inch DI Pipe-Install 0.5 TON $5,400.00 $2,700.00 BID-00762 Water Service-1 Inch-Tap to Main-Install 7 EA $360.00 $2,520.00 BID-00767 Water Service-2 Inch-Tap to Main-Install 0 EA $780.00 $0.00 BID-00758 Water Service-1 Inch-Install;Install 1-Inch Copper Service from Main to Meter 210 LF $13.00 $2,730.00 BID-00550 Meter Box-Class A-Install;Class"A"Plastic Meter Box Complete in Place 7 EA $192.00 $1,344.00 Water Service-2 Inch-Temporary-Install;Furnish and Lay 2-Inch Pipe and Fittings for Temporary BID-00768 Water Service Connection 1 LS $3,600.00 $3,600.00 Pavement-2 Inch Min HMAC on 2/27 Concrete Base(STR-028)-Install;Permanent Asphalt BID-00443 Pavement Repair 730 LF $45.00 $32,850.00 BID-00430 Pavement-Instal;2"Inch HMAC Pavement Repair Outside of Trench Width 50 SY $24.00 $1,200.00 BID-00372 Trench Safety System 5 Foot Depth-Install 730 LF $2.00 $1,460.00 BID-00099 Storm Water Pollution Prevention Plan< Than 1 Ac SWPPP-Install 1 LS $1,600.00 $1,600.00 BID-01189 Signal-Traffic Control-Design&Provide,-Install 1 LS $3,000.00 $3,000.00 Subtotal Section IWATER -------------------------------- $78,124.00 SEWER CONSTRUCTION COST December 18,2009 CPMS BID NO. DESCRIPTION QUANTITY UNIT UNIT COST SUB-TOTAL BID-00351 Pipe-Sewer-8 Inch-SDR35(All Depths)-Install;by Open Cut 620 LF $42.00 $26,040.00 BID-00258 Pipe-Sewer-12 Inch-SDR26(All Depths)-Install;by Open Cut 50 LF $52.00 $2,600.00 BID-00354 Sewer Service-4 Inch-Install;4-Inch PVC Sanitary Sewer Service Line by Oen Cut,all Depths 180 LF $30.00 $5,400.00 BID-00355 Sewer Service-4 Inch Service Tap-Install 6 EA $240.00 $1,440.00 BID-00213 Manhole-Std 4 Ft Diam-to 6 Ft Depth)-Install 5 EA $2,880.00 $14,400.00 BID-00214 Manhole-Std 4 Ft Diam-Added Depth over 6 Ft Depth -Install 4 VF $180.00 $720.00 Pavement-2 Inch Min HMAC on 2/27 Concrete Base(STR-028)-Install;Permanent Asphalt BID-00443 Pavement Repair 620 LF $30.00 $18,600.00 BID-00217 Manhole-Vacuum Test-Services 5 EA $144.00 $720.00 BID-00206 Manhole-Remove 5 EA $312.00 $1,560.00 BID-01189 Si nal-Traffic Control-Design&Provide,-Install 1 LS $1,380.00 $1,380.00 BID-00099 Storm Water Pollution Prevention Plan< Than 1 Ac SWPPP-Install 1 LS $720.00 $720.00 Subtotal Section ISEWER ------------------------------ $73,580.00 Since ENGINEER has no control over the cost of labor,materials,equipment or services furnished by others,or over the Contractors) methods of determining prices,or over competitive bidding or market conditions,ENGINEER's opinions of probable Total project Costs and Construction Cost provided for herein are made on the basis of ENGINEER's experience and qualifications and represent ENGINEER's best judgment as an experienced and qualified professional engineer,familiar with the construction industry;but ENGINEER cannot and does not guarantee that proposals,bids or actual Total Project or Construction Costs will not vary from opinions of probable cost prepared by ENGINEER. If prior to the Bidding or Negotiating Phase OWNER wishes greater assurance to the Construction Cost he shall employ an independent cost estimator. Estimated Construction Cost-Water $78,124.00 Estimated Construction Cost Sewer $73,580.00 Total Estimated Construction Cost-Water&Sewer $151,704.00 Company:JOB:140410:Contract:Exhibit B-3 FW South-02445-ANA14-0410.x1sx 11/19/14 8:35 AM ATTACHMENT C CHANGES AND AMENDMENTS TO STANDARD AGREEMENT DESIGN SERVICES FOR NEAR SOUTHSIDE MEDICAL DISTRICT WATER AND SANITARY SEWER MAIN IMPROVMENTS CITY PROJECT NO.: 02445 This contract has NO changes to the Standard Agreement. City of Fort Worth,Texas Attachment C PMO Release Date:05.19.2010 Page 1 of 1 o g CL o O � o � o � I v o Z - o u a O ri L. J CL o Q Z Z aT Q a y I , z s E 0 E '0 z c 0 W a U a 0 Q Q Q ti N N z N f C_ z 61 f z O f � � O 3 = I � - C r b z a a o z _ cu u w E -, � E � ~ a a m -6 u I � 3 � m - — U E E O E w I N v 0 3 N 0 �. ate+ r y o a b b o W W H a LL H A LL h LL n y y ? H p a w o `o c o. E o '" c E `mc 5o U Q E — 0 9 On b U C So z 3 z in �0 �. LL m LL m o a p I NO r N rn .y �� t� f� m m b .. .+ � .rr+ .. ti .�, ti C ry r� N ry v ,J •v � (J N _ ill■. ,,, a �d ,mss iMrt.l �- - •- � rty = -•t 11vi � ¢ R9B •' '' t fir• k - � t 1 r 4 2 1 3 i. Y:�,� •4,t t3B. 1.P R._ 1:.3� 2 r 5., 6 ,. . A 58- 7 _ 1 e4r - i Irl 6F®m® MID m arm d eC'11 _ _ �__P. ,.h• _ - E a�1 j 4 3A 313 l 1i� 3 Y' S ;A t • � to f ` • �6 f. 1B 7rL, 2A� ID 1E i •i It' ,3B' t7Mt - � � 6'F A aB g - Ir - 11 3A16'.Z M� 4C(s a 4B 1 E y1 111 6 rIh 4 X11 fr ' 4 I, 3Ft X53 I • • i--I� --- - _ 2L C�tn I "iR i •.�fl �'A 12R 2 I I t f i3' 8A ,iBB 7A 78 tittlikk B. 2F 2 1E e;p: .. B] !fl i - � 1 'Ji s 2E 6 ��.I ... ,f -_ a 12 j .. • _ . 1 . ' ( �.�. !, as - .c.-•- — F' 2F >4A A TTA CHMENT'T" (SHEET >) ( COUNCIL DISTRICT 9) COLLEGE STREET ( BROADWAY AVE TO VICKERY BLVD) N AA WA TER IMPR0VEMEIVTS WATER & SANITARY SEWER REPLACEMENT CD 9 FW SOUTH FY 15 SCALE: 1"=300' ENGINEERS•SURVEYORS°PLANNERS CITY PROJECT NO. 02445 WTR 2048-388 Cafiffydill6080 Tha�ron70D34 5 99 I MAPSCO 76H FA%817.=.9966 T.B.P.E.Flm No.:F-20 wwwANALLC—i eatlbits.dgn 111282014 2'42:11 PM 9 Jk- -4-1 SB' .T—, , t3 B. z 4 t t I7 I t ' I 4 is 38 47 1 DAGGETT to Irr -2D 1A .tE i..r•111Rr I B, UE 17 R d, ' s aaafi F 4B 3A 4b'.. e I aC 1G I' 3F Lj- L ' *• A• t1t+�illt� T I —" . -— — —fes� — ——— — -F- —— - -- to — 11 k I I jj f 72R YD aN .,P.s r 18 . _G ° j. , 0 SA iSB I 17. . y I 7A 7B I — aA I -r I t I - - tl •^ E 6A ,Ir - ae6 oiE I ;rte � - . _z I p A ttjrtdia"t 14, t r 2 ,7f iG' 1 C - I 2F 2E Bt ZF �t �strtt I _ •4 .4A, I }g it r yt � 9 = ® p .M6 to A TTA CHME lT 'E" (SHEET2) (COUNCIL DISTRICT 9) JARVIS STREET ( LIPSCOMB ST TO COLLEGE ST) N A%k WA TER/MPRO VEMEVTS ANA CONSULTANTS,L.L.C. WATER & SANITARY SEWER REPLACEMENT CD 9 FW SOUTH FY 15 SCALE: P=300' ENOINEERS•SUMMYORS•PLANNERS CITY PROJECT NO. 02445 WTR2048-388 5000 Thompson Tertsce °°"�'°•TX7B03t MAPSCO 76H 7.335.'996 FAX-817-1W.:F-20 .8865 T.B.P.E.Firm No.:F-7D vnvw.ANALLC.mm 1R - ;) ` is �f • r 5 ,�"� A 1 r Ir 6. tt'l -3-1 y I I 7 AN ' -�" _� •02D OOG��F:' , sop_ e 1 a z, 1-• '13 1: �' ! "� I `.'" f. _ L __.R - titi:'-'' �'i:'t ,•`. O ®' .�� �, _� • _ � I ,� B n 736' ,' 14 � f rt.m�.Abo-i ad a•al► r r ,j r. -3 �c 2�1 13 ped+' Ms�rAt M Fd y. .�. `SIF+ rwwt'aat><s �' "..� • tR.-_ ® r..,�_'12 i 3 1 - - T ytS� g- • .I. 11 i 1 4-.%Kral 1211 1 (•07i;.00004 '" -- ! 3� _ 03 0 2 E04 fdw 11 3 - r i zti { Im - 7 7' r . 5 IV -is as It t I 11®sl 1 •��i R I s_ ! ,� • f 1 a t�1 1 ja 13 IR 91 I r aiQYV•Ary,! L" � . r� { r !tl 4'`PETE 7 3 1 r cat M�Ieteai wt gip` : lir . • r I A TTACHMENT 'E" (SHEET 3) ( COUNCIL DISTRICT 9) JENNINGS AVE ( 200FT NORTH OF OLEANDER TO MAGNOLIA AVE) N AN WA TER IMPROVEMENTS ANA CONBULTANTS,LIC. WATER & SANITARY SEWER REPLACEMENT CD 9 FW SOUTH FY 15 SCALE: 1"=300' ENGINEERS'SURVEY Te PLANNERS 5000 Tlgnpeon Tetrece CITY PROJECT NO. 02445 WTR 2048-384 0oH417.335.78034 MAPSCO 77J PN-817.335.-"5 FAX-817.3359855 T.B.P.E.Fl-Na:F-20 —ANALLG=m exhibits.dan 1126/20142:43:14 P <<�1 LLJ Or Jill i, CA 1� kVNN(� 4T. fir. 4. -71 !AL � � � r Willi az �IFA '� k l Qj ki " rt° , IL MOM f „� (IL IL Aw AP M - • • A - - - - • s" r � � � � < 2 1 t � � �•� 4's 3F) z.— 3 • �.� I SA B 5. r 1 84 . . 1. ,� A 5B im 7 a t� 1. rai aracsc7o❑o r•' +a d.. 3.A 3B r' 48' 1A 1BJ_ 3 s •�c r9 ® r ,� 6� -sB sc s� r a5 sc ' _ c zA "A �' --•1+ '=——— I-- y. 9A 1B 1q, I" 2A IA 1E .'. ID 1 d .38 �; , �� 4B g_ 4 t I 3A A a i ' •y ® -, 40 ® 4 4 `• p 8 aH 1 3F f 1&53 Ir 1R 2 .'PA, I 9A I 1 18 � 7A 1e I, C cl � 1 - i r t 1-1 J 1 1 144_ 1G C 2 ti [, 2, 5 2F 2 E 1�D zE 81 lrfir 3 - + r 4' f' 1 9 i —A^• 1 i' 1 I, _ „�. ;..�— 2F ` e4A1 ��we38, co � f�1 4B c Ll ! _ ------ --- ----- -;- -moi-- ---- - - ---! 'mow -�-�f- d ----- r ---8„--� ir� ' 3 7B I FI�3 S4 .6 12 I S "lima . A TTA CHMENT 'E” (SHEET,'P (COUNCIL DISTRICT 9) LIPSCOMB STREET (VICKERY BLVD TO PENNSYLVANIA AVE) N A%k WA TER IMPROVEMENTS ANA CON9ULiANT9,L.�.C. WATER & SANITARY SEWER REPLACEMENT „- CD 9 FW SOUTH FY 15 SCALE.' 7 —300, ENGINEERS•SURVEYORS'PLANNERS CITY PROJECT NO. 02445 WTR 2048-388 Cok"Oh6000 TM e,TX Terrace P"17.335 5'9� MAPSCO 76H FAX-5179 mss T.B.P.E.FRm No_F-20 —.ANALLC— 12014 2,4152 PM +d 4 wrt ,11 t t I 31 t'4 . . r R 1 d hk1. go%Amor! 13 iK>• r1I/•�+i r io 3 •/ oft auto 1_12 90lap 1 � n r■ •+wh , T I . .1� 6 gF,r. e J ip 3 ' 1 w J1�.01Q;OD004-- 12" rli,�'�'�_..�..-�._k.:�......— _ ALE 32 31 3i, 11 3 de ly—1 13 5. �`°+ >:.T 1"I.•.. •�• �t i� �t .t 11� z - • (j r I � •_ . I r r r- -- -------� "dam;'ta �� '� �� j� 13 t 9 IfK " r 1Nf IR - I I 4"�ETE i 3 f 1 1 ""II"'r 'R` 117 M k1 fin C T 11 r --I � e•- tat p tt - �.Ts = 6 FL �• •� �` SSi lrljrl� P m" F"4T 1tlrib 2. 6 �� atdrrr'�bDsmr �•�a:rRtr , � .:�� ffrMl ,1• a a D � I R r R 0"Itillq m t t 11 �jT, A TTA CHMENTE" (SHEET 6) ( COUNCIL DISTRICT 9) MAY STREET ( MAGNOLIA AVE TO FELIKS GWOZDZ) N A%k WA TER/MPRO VEMENTS ANA CONSLILTANTS.L.L.C. WATER & SANITARY SEWER REPLACEMENT CD 9 FW SOUTH FY 15 SCALE: 9"=300' ENGINEERS•SUWVEYORS PLANNERS 6000 Tlampem Tartare CITY PROJECT NO. 02445 WTR 2048-384 OOO TX 7803' MAPSCO 77J PN-61PH-617.335.91M FAX-817.335.8955 T.B.P.E.Rm Na:F-20 w .ANALLC. exhibits.don 11126QO14 Z4137 P 4 2 fitlL� Y a u EL "H r C i 6 13 ■ i r 1 D i3¢E p E1 C9 E3 ) q3p y g �r h 1' r„ .A r g d 5 67. 85 6C ammaj 2 �. D a "qik.% *i } aJ 11A i8 � 2A `A I� '�r2p 1A lE VR S 17R . p _ 4B - t qy��� 1 3A 4C d i�_ ',... 4B t� 19 , 4 —. 4p � d � 4 Y' 4 A Fi '-SF IA 12R I :v - d• 9A ? 4 1 tB BA _,,PB J - fI1 »^ 4E 7A I I §r 18 '. 6 A f' 4 D 135' Is 44 e 2' B. i� J; i -151_, t _ i I 2F-,es 2 ,E �o' e1 2F '— 1 t i■trh .P — 4` 4A } sRB` 4B pp Ly 4B C aS F t 17 G 4r a t�AI i - - - -- --- - - ---- --7---{ - dr - -.J4 y ---_ - -- I^ - A .{ ( T- 2 I 31 ic II r 3 }s3 �r 8A 1 a3A rt. . 6 In SA A '�.7B 4 12 I S g„ II � .sq,� t� r i ri■ I 6 2 A 7TACHMENT 'E" (SHEET;� ( COUNCIL DISTRICT 9) PETER SMITH STREET ( HEMPHILL ST TO FULTON ST) N A%kWA TER/MPRO VEMENTS ANA CONSULTANTS.L.L.C. WATER & SANITARY SEWER REPLACEMENT , CD 9 FW SOUTH FY 15 SCALE: V'=300 eMINMRS•SURVEYQRS•PLANNERS CITY PROJECT N O. 02445 VVTR 2048-388 =. 6000 -7X 78034 MAPSCO 76H PN-817.396.9800 FAX-617.336,9955 T.S.P.E.Flan No.F-20 —ANALLr-- exhibits dgn 1126/2014 2.44'09 PM 'i LLQ- ess. �����. �. �,���,� a�.-�.• �s���"�-� - �F I��7 7 ON h Orr,31! ,�-!- oil Im P all pill " 1 � � • • I I J I� i i �_t '��•� - - � 10-.�� � � ��' 1: �`. Trl Sp - .lows a � • 'iii' � �` r� �r . . _ I ,���N� �. I �J - ,I .► w I, a. - .rr e, >c- . i IF - (Ili O l'!II �II �_ �ryl� ��,#� ��_ - il•1 51 vi DOW pig WIN VAR' -_ k• - !i_ .I per;�_ _—� _1 _ ��� •I is a .� Z-i r - sir, . Y• e � - `- SO f �• 4 ��. . - ..� A . OY Low - - w • . . s M&C Review Page 1 of 4 Official site of the City of Fort Worth;Texas CITY COUNCIL AGENDA FoRTWoRTH COUNCIL ACTION: Approved on 4/14/2015 - Ordinance No. 21722-04-2015 &Ordinance No. 21723-04-2015 DATE: 4/14/2015 REFERENCE **C-27261 LOG NAME: 60NEARSSMEDWSS-ANA NO.. CODE: C TYPE: CONSENT PUBLIC NO HEARING: SUBJECT: Authorize Execution of an Engineering Agreement with A.N.A. Consultants, L.L.C. in the Amount of$107,865.00 for Near Southside Medical District Water and Sanitary Sewer Improvements on College Avenue, Jarvis Street, Jennings Avenue, Leuda Street, Lipscomb Street, May Street and Peter Smith Street, Provide for Additional Staff Project Costs for a Project Total in the Amount of$114,165.00 and Adopt Appropriation Ordinances (COUNCIL DISTRICT 9) RECOMMENDATION: It is recommended that the City Council: 1. Authorize the transfer of$114,165.00 from the Water and Sewer Operating Fund to the Water Capital Projects Fund in the amount of$96,692.00 and the Sewer Capital Projects Fund in the amount of$17,473.00; 2. Adopt the attached appropriation ordinances increasing estimated receipts and appropriations in the Water Capital Projects Fund in the amount of$96,692.00 and in the Sewer Capital Projects Fund in the amount of$17,473.00 from available funds; and 3. Authorize the execution of an Engineering Agreement with A.N.A. Consultants, L.L.C. in the amount of$107,865.00 for Water and Sanitary Sewer Replacement Contract 2015, WSM-E. DISCUSSION: On August 5, 2014, (M&C C-26906) the City Council authorized a Funding Agreement with Fort Worth South, Inc. and TIF No. 4 (City Secretary Contract No. 45858) for the Near Southside Medical District Street Repair and Reconstruction Program. The general time frame for the design and construction of all program streets is 2014-2018 based upon the following construction plan and schedule: Group A Streets (FY 14-15), Group B Streets (FY 15-16), Group C Streets (FY 16-17) and Group D Streets (FY 17-18). This project will allow for the replacement of the deteriorated water and/or sanitary sewer mains as indicated on the following Group A Streets table: IF- IF- ---I _ _..,.... A A/l A Tlnl C A/l C/'lnl c M&C Review Page 2 of 4 LStreet I From IlTo 11scope of Work College Avenue JJWest Vickery BoulevardPennsylvania Avenue Iwater/sewer Jarvis Street College Avenue Lipscomb Street water South Jennings Avenue Rosedale StreetMagnolia Avenue water Lueda Street South Main Street St. Louis Avenue water Lipscomb Street West Vickery Boulevard Pennsylvania Avenue Iwater/sewer May Street Magnolia Avenue Feliks Gwozdz Place water Peter Smith Street Fulton Street Hemphill S'tree't water/sewer A.N.A. Consultants, L.L.C. proposes to perform the design work for a lump sum fee of$107,865.00. Staff considers this fee to be fair and reasonable for the scope of services proposed. M/WBE Office -A.N.A. Consultants, L.L.C. is in compliance with City's BIDE Ordinance by committing to 13 percent SBE participation on this project. The City' s SBE goal on this project is 10 percent. Additionally, A.N.A. Consultants, L.L.C. is a certified M/WBE firm. In addition to the contract amount, $6,300.00 (Water: $4,500.00; Sewer: $1,800.00) is required for project management, utility coordination and material testing. Upon approval of the Mayor and Council Communication, appropriations for the near Southside Medical District Water and Sanitary Sewer Main Improvements project will consist of the following: A.N.A. Consultants, L.L.C. Engineering Agreement $107,865.00 Project Management, Utility Coordination, Material Testing $6,300.00 Total Appropriations $114,165.00 The project is located in COUNCIL DISTRICT 9, Mapsco 76H, 77J. FISCAL INFORMATION/CERTIFICATION: The Financial Management Services Director certifies that upon approval of the above recommendations and adoption of the attached appropriation ordinances, funds will be available in the current capital budgets, as appropriated, of the Water Capital Projects Fund and the Sewer Capital Projects Fund for transfer to the Near South Side Medical District Water and Sanitary Sewer Improvements project for this Agreement. The Fiscal Year 2015 operating budget includes appropriations of$51,724,257.00 for the purpose of providing pay-as-you go funding for capital projects. Upon execution of this contract, the amount transferred year to date will be $37,094,165.04 and remaining funds will be $14,630,091.96 in the operating budget as depicted in the table below. FY15 Available Revised Fund Appropriations Transfers YTD Balance Transfer Balance Water and Sewer Fund $21,840,314.00 $19,632,330.98 $2,207,983.02 $96,692.00 $2,111,291.02 (Water - Pay as You Go n /)(11 c n ii c i)ni c M&C Review Page 3 of 4 Funding for Capital Projects) Water and Sewer Fund (Sewer- Pay as You Go $29,883,943.00 $17,347,669.06 $12,536,273.94 $17,473.00 $12,518,800.94 Funding for Capital Projects) Total J$51,724,257.-00]$36,980,000.04 $14,744,256.96 $114,165.00 $14,630,091.96 Subject to Mayor and Council approval, transfer and appropriation of funds to the Near South Side Medical District Water and Sanitary Sewer Main Improvements project, the proposed funding for the project will consist of the following: Existing Revised Revised Fund Encumbrances Expenditures Appropriations Appropriations Balance Water Capital Projects Fund $0.00 $96,692.00 $0.00 $0.00 $96,692.00 (P253) Sewer Capital Projects Fund $0.00 $17,473.00 $0.00 $0.00 $17,473.00 (P258) Total $0.00—] $114,165.00 $0.00 $0.00 $114,165.00 TO Fund/Account/Centers FROM Fund/Account/Centers 2) P253 511010 609170244530 $2,000.00 3) P253 531200 609170244531 $21,473.00 2) P253 531350 609170244573 $500.00 3) P253 531200 609170244532 $42,946.00 2) P253 533010 609170244581 $250.00 3) P253 531200 609170244533 $7,158.00 2) P253 531200 609170244584 $1,250.00 3) P253 531200 609170244551 $20,615.00 2) P253 531350 609170244584 $500.00 3) P258 531200 709170244531 $3,650.00 2) P258 511010 709170244530 $500.00 3) P258 531200 709170244532 $7,301.00 2) P258 531200 709170244551 $3,505.00 3) P258 531200 709170244533 $1,217.00 2) P258 531350 709170244573 $250.00 3) P258 531200 709170244551 $3,505.00 2) P258 533010 709170244581 $250.00 1) PE45 538040 0609020 $96,962.00 2) P258 531200 709170244584 $550.00 1) PE45 538040 0709020 $17.473.00 2) P258 531350 709170244584 $250.00 2) P253 531200 609170244531 $21,473.00 2) P253 531200 609170244532 $42,946.00 2) P253 531200 609170244533 $7,158.00 2) P253 531200 609170244551 $20,615.00 2) P258 531200 709170244531 $3,650.00 2) P258 531200 709170244532 $7,301.00 2) P258 531200 709170244533 $1,217.00 1&2) $96.692.00 P253 476045 6091702445ZZ M&C Review Page 4 of 4 11&2� $17,473.00 P258 476045 7091702445ZZ Submitted for City Manager's Office by: Fernando Costa (6122) Originating Department Head: Andrew T. Cronberg (5020) Additional Information Contact: John Kasavich (8480) ATTACHMENTS 60NEARSSMEDWSS ANA MAP.pdf 60NEARSSMEDWSS-ANA P253 A015(Revised3.20.15).docx 60NEARSSMEDWSS-ANA P258 A015.docx 1,4+....ii --r--- _ :t i. ,i -„_..-- A a—... .1 4 —n ii n I)A1 c n ii c i)ni c