Loading...
HomeMy WebLinkAboutContract 46981 C11Y SECRETAMY CONTPACTNO., #6129�91 CITY OF FORT WORTH, TEXAS STANDARD AGREEMENT FOR ENGINEERING RELATED DESIGN SERVICES This AGREEMENT is between the City of Fort Worth, a Texas home-rule municipality (the "CITY"), and Freese and Nichols, Inc., authorized to do business in Texas, (the "ENGINEER"), for a PROJECT generally described as: Six Points Urban Village Street Scape Improvements (Phase II) (City Project No. 02653). Article I Scope of Services A. The Scope of Services is set forth in Attachment A. Article 11 Compensation A. The ENGINEER's compensation shall be in the amount of $204,190.00 as set forth in Attachment B. Article III Terms of Payment Payments to the ENGINEER will be made as follows: A. Invoice and Payment (1) The Engineer shall provide the City sufficient documentation, including but not limited to meeting the requirements set forth in Attachment D to this AGREEMENT, to reasonably substantiate the invoices. (2) The ENGINEER will issue monthly invoices for all work performed under this AGREEMENT. Invoices are due and payable within 30 days of receipt. (3) Upon completion of services enumerated in Article I, the final payment of any balance will be due within 30 days of receipt of the final invoice. City of Fort Worth,Texas OFFICIAL �' `�"^ Standard Agreement for Engineering Related Design Services � "" OR� PMO official Release Date: v28/20'13 ' ��� R Page 1 of 16 qk (4) In the event of a disputed or contested billing, only that portion so contested will be withheld from payment, and the undisputed portion will be paid. The CITY will exercise reasonableness in contesting any bill or portion thereof. No interest will accrue on any contested portion of the billing until mutually resolved. (5) If the CITY fails to make payment in full to ENGINEER for billings contested in good faith within 60 days of the amount due, the ENGINEER may, after giving 7 days' written notice to CITY, suspend services under this AGREEMENT until paid in full. In the event of suspension of services, the ENGINEER shall have no liability to CITY for delays or damages caused the CITY because of such suspension of services. Article IV Obligations of the Engineer Amendments to Article IV, if any, are included in Attachment C. A. General The ENGINEER will serve as the CITY's professional engineering representative under this Agreement, providing professional engineering consultation and advice and furnishing customary services incidental thereto. B. Standard of Care The standard of care applicable to the ENGINEER's services will be the degree of skill and diligence normally employed in the State of Texas by professional engineers or consultants performing the same or similar services at the time such services are performed. C. Subsurface Investigations (1) The ENGINEER shall advise the CITY with regard to the necessity for subcontract work such as special surveys, tests, test borings, or other subsurface investigations in connection with design and engineering work to be performed hereunder. The ENGINEER shall also advise the CITY concerning the results of same. Such surveys, tests, and investigations shall be furnished by the CITY, unless otherwise specified in Attachment A. City of Fort Worlh,Texas Standard Agreernent for Engineering Related Design Services PMO Official Release Date: 1/28/2013 Page 2 of 16 (2) In soils, foundation, groundwater, and other subsurface investigations, the actual characteristics may vary significantly between successive test points and sample intervals and at locations other than where observations, exploration, and investigations have been made. Because of the inherent uncertainties in subsurface evaluations, changed or unanticipated underground conditions may occur that could affect the total PROJECT cost and/or execution. These conditions and cost/execution effects are not the responsibility of the ENGINEER. D. Preparation of Engineering Drawings The ENGINEER will provide to the CITY the original drawings of all plans in ink on reproducible mylar sheets and electronic files in pdf format, or as otherwise approved by CITY, which shall become the property of the CITY. CITY may use such drawings in any manner it desires; provided, however, that the ENGINEER shall not be liable for the use of such drawings for any project other than the PROJECT described herein. E. Engineer's Personnel at Construction Site (1) The presence or duties of the ENGINEER's personnel at a construction site, whether as on-site representatives or otherwise, do not make the ENGINEER or its personnel in any way responsible for those duties that belong to the CITY and/or the CITY's construction contractors or other entities, and do not relieve the construction contractors or any other entity of their obligations, duties, and responsibilities, including, but not limited to, all construction methods, means, techniques, sequences, and procedures necessary for coordinating and completing all portions of the construction work in accordance with the Contract Documents and any health or safety precautions required by such construction work. The ENGINEER and its personnel have no authority to exercise any control over any construction contractor or other entity or their employees in connection with their work or any health or safety precautions. (2) Except to the extent of specific site visits expressly detailed and set forth in Attachment A, the ENGINEER or its personnel shall have no obligation or responsibility to visit the construction site to become familiar with the progress or quality of the completed work on the PROJECT or to determine, in general, if the work on the PROJECT is being performed in a manner indicating that the PROJECT, when completed, will be in accordance with the Contract Documents, nor shall anything in the Contract Documents or the agreement between CITY and ENGINEER be construed as requiring ENGINEER to make exhaustive or continuous on-site inspections to City of Fort Worth,Texas Standard Agreement for Engineering Related Design Services PMO Official Release Date: 1/28/2013 Page 3 of 16 discover latent defects in the work or otherwise check the quality or quantity of the work on the PROJECT. If the ENGINEER makes on-site observation(s) of a deviation from the Contract Documents, the ENGINEER shall inform the CITY. (3) When professional certification of performance or characteristics of materials, systems or equipment is reasonably required to perform the services set forth in the Scope of Services, the ENGINEER shall be entitled to rely upon such certification to establish materials, systems or equipment and performance criteria to be required in the Contract Documents. F. Opinions of Probable Cost, Financial Considerations, and Schedules (1) The ENGINEER shall provide opinions of probable costs based on the current available information at the time of preparation, in accordance with Attachment A. (2) In providing opinions of cost, financial analyses, economic feasibility projections, and schedules for the PROJECT, the ENGINEER has no control over cost or price of labor and materials; unknown or latent conditions of existing equipment or structures that may affect operation or maintenance costs; competitive bidding procedures and market conditions; time or quality of performance by third parties; quality, type, management, or direction of operating personnel; and other economic and operational factors that may materially affect the ultimate PROJECT cost or schedule. Therefore, the ENGINEER makes no warranty that the CITY's actual PROJECT costs, financial aspects, economic feasibility, or schedules will not vary from the ENGINEER's opinions, analyses, projections, or estimates. G. Construction Progress Payments Recommendations by the ENGINEER to the CITY for periodic construction progress payments to the construction contractor will be based on the ENGINEER's knowledge, information, and belief from selective sampling and observation that the work has progressed to the point indicated. Such recommendations do not represent that continuous or detailed examinations have been made by the ENGINEER to ascertain that the construction contractor has completed the work in exact accordance with the Contract Documents; that the final work will be acceptable in all respects; that the ENGINEER has made an examination to ascertain how or for what purpose the construction contractor has used the moneys paid; that title to any of the work, materials, or equipment has passed to the CITY free and clear of liens, claims, security interests, or encumbrances; or that there are not other matters at issue between the CITY and the construction contractor that City of Fort Worth,Texas Standard Agreement for Engineering Related Design Services PMO Official Release Date: 1/28/2013 Page 4 of 16 affect the amount that should be paid. H. Record Drawings Record drawings, if required, will be prepared, in part, on the basis of information compiled and furnished by others, and may not always represent the exact location, type of various components, or exact manner in which the PROJECT was finally constructed. The ENGINEER is not responsible for any errors or omissions in the information from others that is incorporated into the record drawings. I. Minority Business and Small Business Enterprise (MBE)(SBE) Participation In accord with the City of Fort Worth Business Diversity Ordinance No. 20020-12-2011, as amended, the City has goals for the participation of minority business enterprises and/or small business enterprises in City contracts. Engineer acknowledges the MBE and SBE goals established for this contract and its accepted written commitment to MBE and SBE participation. Any misrepresentation of facts (other than a negligent misrepresentation) and/or the commission of fraud by the Engineer may result in the termination of this Agreement and debarment from participating in City contracts for a period of time of not less than three (3) years. J. Right to Audit (1) ENGINEER agrees that the CITY shall, until the expiration of five (5) years after final payment under this contract, have access to and the right to examine and photocopy any directly pertinent books, documents, papers and records of the ENGINEER involving transactions relating to this contract. ENGINEER agrees that the CITY shall have access during normal working hours to all necessary ENGINEER facilities and shall be provided adequate and appropriate work space in order to conduct audits in compliance with the provisions of this section. The CITY shall give ENGINEER reasonable advance notice of intended audits. (2) ENGINEER further agrees to include in all its subconsultant agreements hereunder a provision to the effect that the subconsultant agrees that the CITY shall, until the expiration of five (5) years after final payment under the subcontract, have access to and the right to examine and photocopy any directly pertinent books, documents, papers and records of such subconsultant, involving transactions to the subcontract, and further, that the CITY shall have access during normal working hours to all subconsultant facilities, and shall be provided adequate and appropriate work space, in City of Fort Worth,Texas Standard Agreement for Engineering Related Design Services PMO Official Release Date: 1/28/2013 Page 5 of 16 order to conduct audits in compliance with the provisions of this article together with subsection (3) hereof. CITY shall give subconsultant reasonable advance notice of intended audits. (3) ENGINEER and subconsultant agree to photocopy such documents as may be requested by the CITY. The CITY agrees to reimburse ENGINEER for the cost of copies at the rate published in the Texas Administrative Code in effect as of the time copying is performed. K. INSURANCE (1) ENGINEER'S INSURANCE a. Commercial General Liability — the ENGINEER shall maintain commercial general liability (CGL) and, if necessary, commercial umbrella insurance with a limit of not less than $1,000,000.00 per each occurrence with a $2,000,000.00 aggregate. If such Commercial General Liability insurance contains a general aggregate limit, it shall apply separately to this PROJECT or location. i. The CITY shall be included as an insured under the CGL, using ISO additional insured endorsement or a substitute providing equivalent coverage, and under the commercial umbrella, if any. This insurance shall apply as primary insurance with respect to any other insurance or self-insurance programs afforded to the CITY. The Commercial General Liability insurance policy shall have no exclusions by endorsements that would alter or nullify: premises/operations, products/completed operations, contractual, personal injury, or advertizing injury, which are normally contained within the policy, unless the CITY approves such exclusions in writing. ii. ENGINEER waives all rights against the CITY and its agents, officers, directors and employees for recovery of damages to the extent these damages are covered by the commercial general liability or commercial umbrella liability insurance maintained in accordance with this agreement. b. Business Auto — the ENGINEER shall maintain business auto liability and, if necessary, commercial umbrella liability insurance with a limit of not less than $1,000,000 each accident. Such insurance shall cover liability arising out of "any auto", including owned, hired, and non-owned autos, when said vehicle is used in the course of the PROJECT. If the engineer owns no vehicles, coverage for hired or non-owned is acceptable. City of Fort Worth,Texas Standard Agreement for Engineering Related Design Services PMO Official Release Date: 1/28/2013 Page 6 of 16 i. ENGINEER waives all rights against the CITY and its agents, officers, directors and employees for recovery of damages to the extent these damages are covered by the business auto liability or commercial umbrella liability insurance obtained by ENGINEER pursuant to this agreement or under any applicable auto physical damage coverage. c. Workers' Compensation —ENGINEER shall maintain workers compensation and employers liability insurance and, if necessary, commercial umbrella liability insurance with a limit of not less than $100,000.00 each accident for bodily injury by accident or $100,000.00 each employee for bodily injury by disease, with $500,000.00 policy limit. i. ENGINEER waives all rights against the CITY and its agents, officers, directors and employees for recovery of damages to the extent these damages are covered by workers compensation and employer's liability or commercial umbrella insurance obtained by ENGINEER pursuant to this agreement. d. Professional Liability — the ENGINEER shall maintain professional liability, a claims-made policy, with a minimum of $1,000,000.00 per claim and aggregate. The policy shall contain a retroactive date prior to the date of the contract or the first date of services to be performed, whichever is earlier. Coverage shall be maintained for a period of 5 years following the completion of the contract. An annual certificate of insurance specifically referencing this project shall be submitted to the CITY for each year following completion of the contract. (2) GENERAL INSURANCE REQUIREMENTS a. Certificates of insurance evidencing that the ENGINEER has obtained all required insurance shall be delivered to the CITY prior to ENGINEER proceeding with the PROJECT. b. Applicable policies shall be endorsed to name the CITY an Additional Insured thereon, as its interests may appear. The term CITY shall include its employees, officers, officials, agents, and volunteers as respects the contracted services. c. Certificate(s) of insurance shall document that insurance coverage specified in this agreement are provided under applicable policies documented thereon. City of Fort Worth,Texas Standard Agreement for Engineering Related Design Services PMO Official Release Date: 1/28/2013 Page 7 of 16 d. Any failure OD D@d Of the CITY to [8QU8St [8QUi[8d iDSU[@DC8 dOCUDl8Dt@tiOD shall not CODStitUt8 @ VV@i/8[ Of the iDSU[@DC8 n8QU|[8n08DtS. 8. /\ minimum Of thirty /30\ days notice Of cancellation O[ material change iD COV8[@g8 shall be D[OVid8d to the CITY. At8D /10\ d@VS DOtiC8 shall be 8CC8Dt@bl8 in the event Of non-payment Ofpremium. Notice shall be sent to the n8SD8CtiV8 [18D@rt08Dt [1in8CtO[ (by D@n08\' City Of Fort Worth, 1000Th[OCkn0OrtOD, Fort Worth, Texas 76102. f. IDSUn8[S for all DOliCi8S DlUSt be authorized to do bUSiD8SS in the State Of T8X8S and have @ n0iDin0Un0 rating Of A:\/ or Qn8@t8[, in the CU[n8Dt A.M. Best Key Rating Guide O[ have reasonably equivalent financial strength and solvency tO the satisfaction Of Risk Management. Q. Any deductible or self iDSUn8d n8t8DtiOD in 8XCeSS of $25,000.00 that VVOUld Ch@DQ8 O[ alter the [8QUin8Dl8DtS h8n8iD is subject to 8DDnDV8l by the CITY iD writing, if coverage iS not provided OD@ first-dollar basis. The CITY' at it SOl8 diSCn8tiDD' may CODS8Dt to 8lt8[D@tiV8 COV8[@g8 Dl@iDt@iD8d through iDSUn8DC8 DOO|S or risk n8t8DtiOD gPDUDS. Dedicated financial n8SOU[C8S or |8d8[S Of credit may also be @CC8Dt@bl8 to the CITY. h. Applicable policies shall each be endorsed with @ waiver Of SUb[Og@tiOD in f8VU[ of the CITY as n8SD8CtS the PROJECT. i. The CITY shall be 8Dtitl8d. UDOD its n8QU8St and without iDCU[[iOg 8XD8DS8' to P8Vi8VV the ENGINEER'S iDSU[8DC8 policies including endorsements thereto and, at the CITY'S discretion; the ENGINEER may be [8QUi[8d to D[OVid8 proof of iDSU[8DC8 Dn8n0iUnD D@Vn08DtS. '. Lines Of coverage, other than P[OfeSSiOD8l Liability, underwritten OD @ Cl@in0S-n0@d8 basis, shall CQDt8iD @ n8tV]@CtiV8 date coincident with or prior to the date Of the CODt[@CtU@l @g[88n08Dt. The C8difiC@t8 Of iDSU[8DC8 shall state both the n8t[O8CtiV8 date and that the COV8[@Q8 is Cl@in0S-n0@d8. k. COV8[@g8S. VVh8th8[ VV[i#8D OD an OCCU[n8DC8 or Cl@in0S-nl8d8 b8SiS' shall be n08iDt@iD8d without iDt8[nQDtiOD DO[ restrictive modification or Ch@Dg8g from date Of CODlDl8DC8[n8Dt Of the PROJECT until final D@Vr08Dt and t8[n0iD8tiOD of any COV8[8g8 n8OUi[8d to be n0@iDt@iD8d 8fL8[ final D@Vnl8DtS. 1. The CITY shall not be n8SDoDSib|8 for the direct D@Vn08Dt Of any iDSU[8DC8 DPen0iUn0S n8QUi[8d by this 8gn88nl8Dt. City o,Fort Worth,Texas Standard Agreement for Engineering Related Design Services pmo Official Release Date: xzo/co10 Page umm m. Sub consultants and subcontractors to/of the ENGINEER shall be required by the ENGINEER to maintain the same or reasonably equivalent insurance coverage as required for the ENGINEER. When sub consultants/subcontractors maintain insurance coverage, ENGINEER shall provide CITY with documentation thereof on a certificate of insurance. L. Independent Consultant The ENGINEER agrees to perform all services as an independent consultant and not as a subcontractor, agent, or employee of the CITY. M. Disclosure The ENGINEER acknowledges to the CITY that it has made full disclosure in writing of any existing conflicts of interest or potential conflicts of interest, including personal financial interest, direct or indirect, in property abutting the proposed PROJECT and business relationships with abutting property cities. The ENGINEER further acknowledges that it will make disclosure in writing of any conflicts of interest that develop subsequent to the signing of this contract and prior to final payment under the contract. N. Asbestos or Hazardous Substances (1) If asbestos or hazardous substances in any form are encountered or suspected, the ENGINEER will stop its own work in the affected portions of the PROJECT to permit testing and evaluation. (2) If asbestos or other hazardous substances are suspected, the CITY may request the ENGINEER to assist in obtaining the services of a qualified subcontractor to manage the remediation activities of the PROJECT. . Permitting Authorities - Design Changes If permitting authorities require design changes so as to comply with published design criteria and/or current engineering practice standards which the ENGINEER should have been aware of at the time this Agreement was executed, the ENGINEER shall revise plans and specifications, as required, at its own cost and expense. However, if design changes are required due to the changes in the permitting authorities' published design criteria and/or practice standards criteria which are published after the date of this Agreement which the ENGINEER could not have been reasonably aware of, the ENGINEER shall notify the CITY of such changes and an adjustment in compensation will be made through an amendment to this AGREEMENT. City of Fort Worth,Texas Standard Agreement for Engineering Related Design Services PMO Official Release Date:1/28/2013 Page 9 of 16 P. Schedule ENGINEER shall manage the PROJECT in accordance with the schedule developed per Attachment D to this AGREEMENT. Article V Obligations of the City Amendments to Article V, if any, are included in Attachment C. A. City-Furnished Data ENGINEER may rely upon the accuracy, timeliness, and completeness of the information provided by the CITY. B. Access to Facilities and Property The CITY will make its facilities accessible to the ENGINEER as required for the ENGINEER's performance of its services. The CITY will perform, at no cost to the ENGINEER, such tests of equipment, machinery, pipelines, and other components of the CITY's facilities as may be required in connection with the ENGINEER's services. The CITY will be responsible for all acts of the CITY's personnel. C. Advertisements, Permits, and Access Unless otherwise agreed to in the Scope of Services, the CITY will obtain, arrange, and pay for all advertisements for bids; permits and licenses required by local, state, or federal authorities; and land, easements, rights- of-way, and access necessary for the ENGINEER's services or PROJECT construction. D. Timely Review The CITY will examine the ENGINEER's studies, reports, sketches, drawings, specifications, proposals, and other documents; obtain advice of an attorney, insurance counselor, accountant, auditor, bond and financial advisors, and other consultants as the CITY deems appropriate; and render in writing decisions required by the CITY in a timely manner in accordance with the project schedule prepared in accordance with Attachment D. City of Fort Worth,Texas Standard Agreement for Engineering Related Design Services PMO Official Release Date 1/28/2013 Page 10 of 16 E. Prompt Notice The CITY will give prompt written notice to the ENGINEER whenever CITY observes or becomes aware of any development that affects the scope or timing of the ENGINEER's services or of any defect in the work of the ENGINEER or construction contractors. F. Asbestos or Hazardous Substances Release. (1) CITY acknowledges ENGINEER will perform part of the work at CITY's facilities that may contain hazardous materials, including asbestos containing materials, or conditions, and that ENGINEER had no prior role in the generation, treatment, storage, or disposition of such materials. In consideration of the associated risks that may give rise to claims by third parties or employees of City, City hereby releases ENGINEER from any damage or liability related to the presence of such materials. (2) The release required above shall not apply in the event the discharge, release or escape of hazardous substances, contaminants, or asbestos is a result of ENGINEER's negligence or if ENGINEER brings such hazardous substance, contaminant or asbestos onto the project. G. Contractor Indemnification and Claims The CITY agrees to include in all construction contracts the provisions of Article IV.E. regarding the ENGINEER's Personnel at Construction Site, and provisions providing contractor indemnification of the CITY and the ENGINEER for contractor's negligence. H. Contractor Claims and Third-Party Beneficiaries (1) The CITY agrees to include the following clause in all contracts with construction contractors and equipment or materials suppliers: "Contractors, subcontractors and equipment and materials suppliers on the PROJECT, or their sureties, shall maintain no direct action against the ENGINEER, its officers, employees, and subcontractors, for any claim arising out of, in connection with, or resulting from the engineering services performed. Only the CITY will be the beneficiary of any undertaking by the ENGINEER." (2) This AGREEMENT gives no rights or benefits to anyone other than the CITY and the ENGINEER and there are no third-party beneficiaries. City of Fort Worth,Texas Standard Agreernent for Engineering Related Design Services PMO Official Release Date:1/26/2613 Page 11 of 16 (3) The CITY will include in each agreement it enters into with any other entity or person regarding the PROJECT a provision that such entity or person shall have no third-party beneficiary rights under this Agreement. (4) Nothing contained in this section V.H. shall be construed as a waiver of any right the CITY has to bring a claim against ENGINEER. I. CITY's Insurance (1) The CITY may maintain property insurance on certain pre-existing structures associated with the PROJECT. (2) The CITY will ensure that Builders Risk/installation insurance is maintained at the replacement cost value of the PROJECT. The CITY may provide ENGINEER a copy of the policy or documentation of such on a certificate of insurance. (3) The CITY will specify that the Builders Risk/Installation insurance shall be comprehensive in coverage appropriate to the PROJECT risks. J. Litigation Assistance The Scope of Services does not include costs of the ENGINEER for required or requested assistance to support, prepare, document, bring, defend, or assist in litigation undertaken or defended by the CITY. In the event CITY requests such services of the ENGINEER, this AGREEMENT shall be amended or a separate agreement will be negotiated between the parties. K. Changes The CITY may make or approve changes within the general Scope of Services in this AGREEMENT. If such changes affect the ENGINEER's cost of or time required for performance of the services, an equitable adjustment will be made through an amendment to this AGREEMENT with appropriate CITY approval. City of Fort Worth,Texas Standard Agreement for Engineering Related Design Services PMO Official Release Date: 1/2£3/2013 Page 12 of 16 Article VI General Legal Provisions Amendments to Article VI, if any, are included in Attachment C. A. Authorization to Proceed ENGINEER shall be authorized to proceed with this AGREEMENT upon receipt of a written Notice to Proceed from the CITY. B. Reuse of Project Documents All designs, drawings, specifications, documents, and other work products of the ENGINEER, whether in hard copy or in electronic form, are instruments of service for this PROJECT, whether the PROJECT is completed or not. Reuse, change, or alteration by the CITY or by others acting through or on behalf of the CITY of any such instruments of service without the written permission of the ENGINEER will be at the CITY's sole risk. The CITY shall own the final designs, drawings, specifications and documents. C. Force Majeure The ENGINEER is not responsible for damages or delay in performance caused by acts of God, strikes, lockouts, accidents, or other events beyond the control of the ENGINEER that prevent ENGINEER's performance of its obligations hereunder. D. Termination (1) This AGREEMENT may be terminated only by the City for convenience on 30 days' written notice. This AGREEMENT may be terminated by either the CITY or the ENGINEER for cause if either party fails substantially to perform through no fault of the other and does not commence correction of such nonperformance with in 5 days of written notice and diligently complete the correction thereafter. (2) If this AGREEMENT is terminated for the convenience of the City, the ENGINEER will be paid for termination expenses as follows: a.) Cost of reproduction of partial or complete studies, plans, specifications or other forms of ENGINEER'S work product; b.) Out-of-pocket expenses for purchasing electronic data files and other data storage supplies or services; City of Fort Worth,Texas Standard Agreement for Engineering Related Design Services PMO Official Release Date: 112£312013 Page 13 of 16 C.) The time requirements for the ENGINEER'S personnel to document the work underway at the time of the CITY'S termination for convenience so that the work effort is suitable for long time storage. (3) Prior to proceeding with termination services, the ENGINEER will submit to the CITY an itemized statement of all termination expenses. The CITY'S approval will be obtained in writing prior to proceeding with termination services. E. Suspension, Delay, or Interruption to Work The CITY may suspend, delay, or interrupt the services of the ENGINEER for the convenience of the CITY. In the event of such suspension, delay, or interruption, an equitable adjustment in the PROJECT's schedule, commitment and cost of the ENGINEER's personnel and subcontractors, and ENGINEER's compensation will be made. F. Indemnification In accordance with Texas Local Government Code Section 271.904, the ENGINEER shall indemnify, hold harmless, and defend the CITY against liability for any damage caused by or resulting from an act of negligence, intentional tort, intellectual property infringement, or failure to pay a subcontractor or supplier committed by the ENGINEER or ENGINEER's agent, consultant under contract, or another entity over which the ENGINEER exercises control. G. Assignment Neither party shall assign all or any part of this AGREEMENT without the prior written consent of the other party. H. Interpretation Limitations on liability and indemnities in this AGREEMENT are business understandings between the parties and shall apply to all the different theories of recovery, including breach of contract or warranty, tort including negligence, strict or statutory liability, or any other cause of action, except for willful misconduct or gross negligence for limitations of liability and sole negligence for indemnification. Parties mean the CITY and the ENGINEER, and their officers, employees, agents, and subcontractors. City of Fort Worth,Texas Standard Agreement for Engineering Related Design Services PMO Official Release Date. 1/28/2013 Page 14 of 16 I. Jurisdiction The law of the State of Texas shall govern the validity of this AGREEMENT, its interpretation and performance, and any other claims related to it. The venue for any litigation related to this AGREEMENT shall be Tarrant County, Texas. J. Severability and Survival If any of the provisions contained in this AGREEMENT are held for any reason to be invalid, illegal, or unenforceable in any respect, such invalidity, illegality, or unenforceability will not affect any other provision, and this AGREEMENT shall be construed as if such invalid, illegal, or unenforceable provision had never been contained herein. Articles V.F., VI.B., VI.D., VI.F., VI.H., and VI.I. shall survive termination of this AGREEMENT for any cause. K. Observe and Comply ENGINEER shall at all times observe and comply with all federal and State laws and regulations and with all City ordinances and regulations which in any way affect this AGREEMENT and the work hereunder, and shall observe and comply with all orders, laws ordinances and regulations which may exist or may be enacted later by governing bodies having jurisdiction or authority for such enactment. No plea of misunderstanding or ignorance thereof shall be considered. ENGINEER agrees to defend, indemnify and hold harmless CITY and all of its officers, agents and employees from and against all claims or liability arising out of the violation of any such order, law, ordinance, or regulation, whether it be by itself or its employees. Article VII Attachments, Schedules, and Signatures This AGREEMENT, including its attachments and schedules, constitutes the entire AGREEMENT, supersedes all prior written or oral understandings, and may only be changed by a written amendment executed by both parties. The following attachments and schedules are hereby made a part of this AGREEMENT: Attachment A - Scope of Services Attachment B— Compensation Attachment C - Amendments to Standard Agreement for Engineering Services Attachment D - Project Schedule Attachment E - Location Map City of Fort Worth,Texas Standard Agreement for Engineering Related Design Services PMO Official Release Date: 1/28/2013 Page 15 of 16 Executed and effective this the --�i day o W , 2015. BY: BY: CITY OF FORT WORTH ENGINEER Freese and Nichols, Inc. Fernando Costa Chris B. Bosco, P.E. Assistant City Manager Principal Date: -qLz Ns Date: `e m APPRUVA REC MEN D: By: i ndle Ha oo Director, lanning and Development APPROVED AS TO FORM AND M&C No.: LEGALITY M&C Date: - ', By: Douglas W. Black Assistant City Attorney ATTEST: ,, M Mary J. City SeMa v ppryry;; "°Ii Y,,rr l il,a ��`C�,�n�,�R[),'i I o �o.w...,.... .,�....�.,...�.,..r�. .��.e......._,m..,,,.� City of Fort Worth,Texas Standard Agreement for Engineering Related Design Services PMO Official Release Date: 1/28/2013 Page 16 of 16 ATTACHMENT "A" Scope for Engineering Design Related Services for Street Improvements The scope set forth herein defines the work to be performed by the ENGINEER in completing the project. Both the CITY and ENGINEER have attempted to clearly define the work to be performed and address the needs of the Project. OBJECTIVE The Six Points Urban Village Phase 11 Streetscape is located along Race Street between Sylvania Avenue and Oakhurst Scenic Drive. The objective of this project is to construct capital improvements that promote compact, mixed residential and commercial uses that create a pedestrian-friendly environment. Pedestrian-friendly improvements to be considered for constructed include the following:pedestrian scale street lighting, sidewalks, crosswalks, Americans with Disabilities (ADA) improvements, street trees and landscaping, trash bids, bike racks, transit enhancements and way-finding signs. Race Street will be considered for modification to better accommodate vehicular parking and bicyclists. The scope of this project will also include streetscape enhancements between Sylvania and Grace Avenue and pavement marking improvements to Sylvania from Belknap Street to Race Street. WORK TO BE PERFORMED Task 1. Design Management Task 2. Conceptual Design Task 3. Preliminary Design Task 4. Final Design Task 5. Bid Phase Services Task 6. Construction Phase Services Task 7. ROW/Easement Services Task 8. Survey and Subsurface Utility Engineering Services Task 9. Permitting Task 10. Additional Services TASK 1. DESIGN MANAGEMENT. ENGINEER will manage the work outlined in this scope to ensure efficient and effective use of ENGINEER's and CITY's time and resources. ENGINEER will manage change, communicate effectively, coordinate internally and externally as needed, and proactively address issues with the CITY's Project Manager and others as necessary to make progress on the work. 1.1. Managing the Team • Lead, manage and direct design team activities • Ensure quality control is practiced in performance of the work • Communicate internally among team members • Task and allocate team resources City of Fort Worth,Texas Attachment A PMO Release Date:07.23.2012 Page 1 of 15 ^ . 1.2. Communications and Reporting • Attend 8 pre-design project kiCkoff/Ch8rt8hngnn88UngwithQTYst8#1oOonfi0O8nd clarify scope, understand CITY objectives, and ensure economical and functional designs that meet CITY requirements • Conduct and document monthly project upd8t8nn88bngSvvithC|TYP jeLt Manager uptoGmeetings. • Conduct review meetings (up to4) with the CITY at the end of each design phase • Prepare invoices, in accordance with Attachment Btothis Standard Agreement and submit monthly in the format requested by the CITY. • Prepare and submit monthly progress reports in the format provided by the respective CITY Department. • Prepare and submit baseline Project Schedule initially, and Project Schedule updates with a schedule narrative monthly, as required in Attachment D to this Standard Agreement and according to the City of Fort Worth's Schedule Guidance Document. • Complete Monthly DBE Report Form and Final Summary Payment Report Form at the end Of the project • Coordinate with other agencies and entities as necessary for the design of the proposed infrastructure, and provide and obtain information needed to prepare the design • With respect to cOOPd|D8UOn with permitting 8uthOr|USS' ENGINEER Sh8U communicate with permitting 8UthOrid8S such that their Pegu|80D[y requirements are appropriately reflected iD the designs. ENGINEER shall work with regulatory authorities to obtain approval of the designs, and make changes necessary to meet their requirements, 8S part Of the design scope. • Personnel and Vehicle Identification: When conducting site visits 0D the project location, the ENGINEER or any of its sub-consultants shall carry readily visible information identifying the name of the company and the company representative. • The ENGINEER shall prepare a decision log which documents and records key project decisions throughout the project. • Engineer shall complete and submit Plan Submittal Checklists in accordance with the fOUOvviDg table: City of Fort Worth,Texas Attachment pmm Release Date:or.2x.m1c Page of 15 PLAN SUBMITTAL CHECKLIST REQUIREMENTS Attachment"A" Concept Plan 60%Project Plans 90%Project Plans 100%Project Plans Type Exhibit &Proposal &Proposal &Proposal Document Document Document City Departments: Planning and Storm Water& Parks and Recreation& Transportation and Public Works Franchise Utility ASSUMPTIONS 0 12 project COOPdiD81iODDl88{iDgS8r8iDdUd8diDth8SCUp8OfSenjQeS 0 A Dl8xiDlUrQ of bid 8|t8rD8t8S may be included in the bid prOpOS8| DELIVERABLES A. Meeting summaries with action items B. Monthly invoices C. Monthly progress reports D. Baseline design schedule E. Monthly schedule updates with schedule narrative included in the monthly report describing any current O[ anticipated schedule changes F. Monthly DBE Report Form and Final Summary Payment Report Form G. P|@D and PnDpOS8| SUbrQitt@|S / See Task 1 — P|@D Submittal Checklist Requirements Table) TASK 2' CONCEPTUAL DESIGN (3OPERCENT). The Conceptual Design shall be submitted U] CITY per the approved Project SChedU|8. The pU[pOS8 of the CUDQe[tU@| design is for the ENGINEER to identify, d8v8|Op. communicate through the defined deliverables, and recommend the design concept that successfully addresses the design problem, and to obtain the CITY's endorsement of this concept. ENGINEER will develop the COnQ8[tU8| design of the infrastructure as fO||OvvS: City or Fort Worth,Texas Attachment A pwo Release Date:or.ox.zo1z Page xm10 2.1. Data Collection m In addition to data obtained from the QTY. ENGINEER will research and make efforts tOobtain pertinent information k) aid in coordination of the proposed improvements with any planned future improvements that may influence the project. ENGINEER will also identify and seek tOobtain data for existing conditions that may impact the project inC|uding; uU|iUeS. agenCieS (TxD[}Tand railroads), City Master Plans, and property ownership as available from the Tax Assessor's office. 2.2. The Conceptual Design Package shall include the following: • Conduct (2) project SiteviSitStOObServe the existing conditions • Existing typical sections of the roadway to be constructed along with proposed typical sections which outline the proposed improvements. Typical sections shall include existing and proposed ROW, existing and proposed lane widths and direction arFOvvS. existing and proposed Cu[bS. Sidevv8/kS. and retaining vva||S. • Prepare plan view base map with dimensions tOserve aS the base map for the StreetSCape design exhibit. • Conceptual 8t[eetSC8pe plan exhibit will be prepared and will include landscape plantings and paving enhancements. This concept will not include dimensioning control for the location Ofthese elements • Conceptual level typical sections (up tO3sections) • Estimate Ofprobable CODSt[uctiOD cost. • Meet with key stakeholders one ODone tO discuss future vision and planning concept for area (up tO3meetings) • Attend and present a conceptual level public meeting to gather ideas from the stakeholders for the concept plan (1 meeting) • Drainage study tOevaluate the existing drainage conditions On the site. Evaluation will include spread of water (inlet capacity) and pipe capacity of receiving storm drain. The purpose of the Study is to determine whether drainage improvements are vv8[[8nted as part of the project. FW| will also analyze uptO two (2) drainage improvement alternatives. 2.3. The utility management shall include the following: m Attend and conduct franchise utility meetings for the Six Points Urban Village Street 8C8pe Improvements project (uptO2nneeUDgS) ASSUMPTIONS m 3 plots of the project Schematic Design Layout will he submitted with the CODCe[tu8| deliverables. m The St[ee1SC8pe concept for Phase || race Street from Sylvania will be based On improvements that fit within the existing right-of-way and will be consistent with the reCOnnDlend8UOnS from the CNU design Ch8rrette; which includes two travel (8Des. bike lanes and sidewalk widening but does not include parking. City or Fort Worth,Texas Attachment A pmo Release Date:or.zx.uo1u Page*or/s . • DWF files created from design CAD drawings will be uploaded to the designated project folder in Buzzsaw. • ENGINEER shall not proceed with Preliminary Design activities without written approval by the CITY Of the Conceptual Design Package. • All storm water calculations shall COnfO[Dl 0o the City of Fort Worth iSN/M Criteria Manual for Site Development and Construction. • The City Of Fort Worth will prepare and send out invitations for the public meeting. DELIVERABLES A. Conceptual Schematic Design Package B. Typical Sections C. Existing Drainage Conditions Study D. Attend conceptual level public meeting E. Conceptual level cost estimate TASK 3. PRELIMINARY DESIGN (60 PERCENT). Preliminary plans and specifications shall be submitted tO CITY per the approved Project Schedule. ENGINEER will develop the preliminary design of the infrastructure as fO||OvvS. 3.1. Development Of Preliminary Design [)[8vviDgS and Specifications shall include the following: • Traffic Control Plan updated to reflect any changes as a result of the conceptual design submittal while also including all construction Signage and pavement markings which will bein accordance with the latest edition Of the Texas Manual On Uniform Traffic Control Devices. • A Project Control Sheet, showing all Control Points, used O[set while gathering data. Generally On 8 SC8|e Of not |eSS than 1:400. The following information shall be indicated for each Control Point: Identified (existing City Monument#8901, PK N8//. 5/8" |nDn Rod); X. Y and ZCoordinates, in an identified coordinate system, and a referred bearing base. Z coordinate On City Datum only; descriptive location (i.e. Set in the centerline of the inlet in the South Curb line Of North Side Drive at the East end Of radius Gt the Southeast corner Of North Side Drive and North Main Street). � Streetscape design (hardscape and softscape design) sheets will be prepared and will include landscape plantings, landscape irrigation, site furnishings, paving enhancements, and decorative DlOnuDlentskw8\|S. These plans will also include dimensioning control for the location of these elements. � The Pedestrian lighting plans will extend from on Race Street from Grace Street Oakhurst Scenic Drive. including preparation of pedestrian lighting plans including City o/Fort Worth,Texas Attachment A pwo Release Date:nr.uuuo/z Page 5o//u ' electrical service locations, conduit locations, pedestrian light locations, and foundation details. • Prepare Pavement marking plans for Sylvania from Race Street to Belknap (US 377) • Updated existing and proposed typical section sheets. • Updated roadway plan sheets displaying station and coordinate data for all horizontal curb modifications • No less than two bench marks per plan sheet. • Bearings given On all proposed centerlines, O[ baselines. • Preparation Of demolition plans • Preliminary roadway details to include cU[bs. curb expansion jOints, driveways, sidewalks, and pavement details. • Preliminary signing, pavement marking, i||UDliOahOO and signal layouts. 3.3. (|OOstrU(t8bi|ity Review � Prior to the 60 percent review meeting with the CITY, the ENGINEER shall schedule and attend 8 project Siteviaitvviththe (||TYP jeCtK8aOage[ aOd Construction personnel tO walk the project. The ENGINEER shall summarize the (||TY's comments from the field visit and submit this information tOthe CITY in vv[iUOg. 34. Public Involvement: • After the conceptual design p8oh8geh8sbeeO [evievv8daOd8pp[0vedbvUle CITY, the ENGINEER shall prepare project 6xhibitS. 8Od8tteOd8OdpngseOt at public meeting no. 2k} help explain the proposed project to residents. The CITY Sh8U select 8 suitable {OC8dOO. prepare and Dl8i| the invitation letters tDthe affected customers. • The ENGINEER will meet with property owners for UptO six (G) meetings • Prepare (1) artist rendering of the proposed street section view. 3.5. Utility Clearance • The ENGINEER will consult with the CITY's Transportation and Public Works Dep8rtOOeOt, Water Department, and other CITY departments, public utilities, private UU|iUes. private utilities and government agencies to determine the approximate location of above and underground utilities, and other facilities (current and future) that have 8O impact O[ influence on the project. ENGINEER will design CITY facilities to avoid or minimize conflicts with existing utilities, and where known and possible consider potential future utilities indesigns. • The ENGINEER shall upload individual OVVF files for each plan sheet ofthe approved preliminary plan s6{8J the designated project folder in Buzznmvvfor fOn^eandiOQ to all utility companies which have facilities within the limits of the City of Fort Worth,Texas Attachment A PMo Release Date:or-2a.2oo Page sn/1s project. The DWF files should be created directly from the CAD files as opposed to PDF files. ASSUMPTIONS • Design of a new drainage system is not included in this scope. • 6 sets of 11 x1 7 size plans will be delivered for the 60% design. • DWF files created from design CAD drawings will be uploaded to the designated project folder in Buzzsaw. • 6 sets of half size drawings will be delivered for Utility Clearance. • ENGINEER shall not proceed with Final Design activities without written approval by the CITY of the Preliminary Design plans. • Geotechnical investigation and pavement design are not included in this scope of services. • The CITY's front end and technical specifications will be used with modifications necessary to meet TxDOT requirements. The ENGINEER shall supplement the technical specifications if needed. • The City of Fort Worth will prepare and send out the invitations for the public meeting. DELIVERABLES A. Preliminary Design drawings and specifications B. Utility Clearance drawings C. Estimates of probable construction cost F. Public Meeting exhibits G. Artist rendering showing the proposed concept TASK 4. PRE-FINAL DESIGN (90 PERCENT) AND FINAL CONSTRUCTION DOCUMENTS (100 PERCENT). • Upon approval of the Preliminary plans, ENGINEER will prepare construction plans as follows: • Pre-Final draft construction plans (90%) and specifications shall be submitted to CITY per the approved Project Schedule. • Following a 90% construction plan review meeting with the CITY, the ENGINEER shall submit Final Construction Documents (1100%) to the CITY per the approved Project Schedule. Each plan sheet shall be stamped, dated, and signed by the ENGINEER registered in State of Texas. • The ENGINEER shall submit a final design estimate of probable construction cost with both the 90% and 100% design packages. City of Fort Worth,Texas Attachment A PMO Release Date:07.23.2012 Page 7 of 15 . ASSUMPTIONS * O sets Of11x17 size drawings and 8 specifications will b8 delivered for the 9096Design pQoKQg8. 0 ADVVF file for the 90% Design will b8 created from design CAD drawings and will b8 uploaded tO the project fD(darinBUzzsQvv. 0 8 sets Of11x17 size drawings and 4 specifications will be delivered for the 1OO96Design pQohQg8. 0 A DWF file for the 100 % Design will be created from design CAD drawings and will be uploaded tm the project fO|d8[ inBUzzsQvv. DELIVERABLES A. 9O% construction plans and specifications. B. 100% construction plans and specifications. C. C)8tQi|8d 8StinnQt8s of probable oOOSt[uotiOO oOStS including SunnDlQ[i8S Of bid items and quantities using the City standard and project sp8oifiobidit8DlSQOdfO[nnQL D. Original oOv8[ nny|Qr for the signatures of authorized CITY OffioiQ|S. TASK 5' BID PHASE SERVICES. ENGINEER will support the bid phase Of the project QSfOUOvvo. 5.1. Bid Support • The ENGINEER shall upload all plans and contract documents onto Buzzsaw for access tO potential bidders. • Contract documents shall b8 uploaded iOQ x|Sfi|8. • Unit Price Proposal documents are to be created utilizing and combined in a spreadsheet workbook, Bid Proposal Worksheet Template, and will b8 populated and configured sO that all pages are complete and the Summary Worksheet(s) in the workbook detail and automatically summarize the totals from the inserted Unit Price Proposal document worksheets. • P1QO 88tS are to be uploaded to BuzzSQvv in two fOrnnQtS' pdfQnd dwffi|8S. The pdf will consist Of one file Of the entire plan set. The Awf will consist Of individual files, one for each plan sheet, and will b8 numbered and named iO a manner similar tO that Of the plan set index. • The ENGINEER shall sell contract documents and maintain a plan holders list On Buzzsaw from documents sold and from Contractor's uploaded Plan Holder Registrations iOBUzzsavv. City o/Fort Worth,Texas mmu»mvnt A Pwo Release Date:ur.ux.uu1u Page onr1a • The ENGINEER will develop and implement procedures for receiving and answering bidders' questions and requests for additional information. The procedures shall include a log of all significant bidders questions and requests and the response thereto. The log shall be housed and maintained inthe project's Buzzsaw folder titled Request for Information. Th8ENGINEER will provide technical interpretation of the contract bid dUCUDl8ntS and will p[8p@[8 proposed responses tU all bidders questions and requests, iD the form Uf addenda. The ENGINEER shall upload all approved addenda onto BUzzSavvand mail addenda tU all plan holders. • Attend the p[8biU conference iD support Uf the CITY. • Assist the CITY in determining the qualifications and acceptability of prospective contractors, subcontractors, and suppliers. • When substitution prior to award of contracts is a||Uvved in the contract documents, the ENGINEER will advise the CITY aStU the acceptability of alternate materials and equipment proposed bybidders. • Attend the bid opening in support Uf the CITY. • Tabulate and review all bids received for the construction project, amsisttheC|TY in evaluating bids, and recommend award Of the contract. A copy Of the Bid Tabulation iStOb8 uploaded into the project's BidR8SpOnS8Sh3|d8rOn BuzzS@vv. • Incorporate all addenda into the contract documents and issue conformed sets. ASSUMPTIONS 0 The project will be bid only OnC8 and @vv@rd8d to one contractor. 0 20 S8tS Of 11x17 construction documents will be SU|d to and 0@d8 available On BUzzSevv for plan holders and/or given to plan viewing POODls. w 12 sets of 11x17 size plans and specifications (COnfUr08d, if applicable)will be delivered to the CITY. 0 4 S8tS of the CUDtF@Ct (3 bOUDd. 1 uDbOUDd) 0 P[}F and [}VVF files will be uploaded to BUzzSavv. DELIVERABLES A. Addenda B. Bid tabU|@dUnS C. R8CO008Dd@UOD Of award D. Construction documents (conformed, if applicable) TASK 6' CONSTRUCTION PHASE SERVICES. ENGINEER will support the construction phase of the project as h]||ovvS. 8.1 CODStrUCUOD Support City v,Fort Worth,Texas Attachment A pMo Release Date:nzxo.xo1z Page evr1s . • The ENGINEER shall attend the pr8CODStruCtiODconference. • After the pre-construction conference, the ENGINEER shall provide project exhibits and attend public meeting tO help explain the proposed project to residents. The CITY shall S8|8Lt 8SUit8b|8 |OC@tiOn and mail the invitation |8d8nS t0 the affected customers. • The ENGINEER will attend and conduct @ pre-construction public meeting. • The ENGINEER shall visit the project sit881r8qU8St8dint8rV8!SasCODStrUCbOD proceeds 10 observe and report on progress for upto12 site visits. • The ENGINEER shall review shop drawings, samples and other submittals submitted by the contractor for general conformance with the design concepts and general compliance with the requirements Of the contract for construction. Such review shall not relieve the Contractor from its responsibility for performance in accordance with the contract for construction, nor is such review a guarantee that the work covered by the shop drawings, samples and submittals iS free Oferrors, inconsistencies O[ omissions. The ENGINEER shall log and track all shop drawings, samples and other submittals inBuzzSavv. • AS requested by the CITY, the ENGINEER shall provide necessary interpretations and clarifications of contract documents, review change orders, and make recommendations osto the acceptability of the work. • The ENGINEER shall attend the ''Fin@}" project vv@|k through and assist with preparation Of final punch list. • FN| will endeavor to protect OWNER in providing these S8n/iC8S h0vv8v8[' it is understood that FN| does not guarantee the Contractor's performance, nor iSFM| responsible for supervision of the Contractor's operation and employees. FN| shall not b8 responsible for the means, methods, techniques, sequences O[ procedures Of construction selected by the Contractor, O[ any safety precautions and programs relating in any way to the condition of the premises, the work of the Contractor O[any Subcontractor. FN| shall not b8 responsible for the acts O[ omissions Of any person (except its own employees O[agents) at the Project Site O[otherwise performing any Of the work Of the Project. 8.2 R8CO[d D[@vviDgS � The ENGINEER shall prepare record drawings from information submitted by the inspector and/or Contractor. • The ENGINEER shall submit @ set Of sealed conformed my1@[drawings for record storage. • Record Drawings shall also be submitted aoanAdobe Acrobat PDF format (version 6.0 or higher)file aDdK]WF format. There shall b8 one (1) PDFfile and one (1) DVVF file for the lFPVV plan set. Each P[)F and DVVF file shall contain all associated sheets of the particular plan set. Singular PDF and DWF files for each sheet of a plan set will not be accer)ted. P[)F and DVVF files shall conform to naming conventions asfollows: City or Fort Worth,Texas Attachment A pmn Release Date:or.ez.eo1z Page 1oo,1s . L TPW file n80S example — "W-1 pdf" where "W-1956" is the assigned file number obtained from the CITY, " arg" designating the file is of an original plan Set. '^47" Sh8U be the total number Ofsheets in this file. Example: VV-0053 Org3.Ddf8ndK-O32O Org5.pdf Both PDF and DWF files shall be uploaded tO the project's F{ScOnjDr8vvingfO|der inBuzzsavv. For information on the proper manner to submit files and to obtain a file number for the project, cOnt8Ctthe [Jep8kDleDtOfTn8nSpOrt8dOn8ndPUb|iCVVOrhSV8U|t8t telephone number(817) 3Q2-8428. File numbers will not bS issued tO8project unless the appropriate project nu0bS[S8ndfundCOdeSh8vSbSS08SSignSd8nd are in the Department Of Transportation and Public Works database. ASSUMPTIONS 0 12 site visits are assumed. 0 10 SUbnnitt8| [SvievvS are 8SSuDlSd. 0 1ORF|'S are assumed. 0 2 Change [)[de[S are assumed. DELIVERABLES A. Public meeting exhibits B. Response to Contractor's Request for |nfO[Dl8UOn C. Review OfChange O[dSnS D. FlSviSvv of shop drawings E. Final Punch List items E. Record Drawings TASK 7. ROW/EASEMENT SERVICES' ENGINEER will support and pSdb[nn activities [S|8tSd to F{[)VV and land as outlined bS|Ovv, pe[SCOping di[SCdOn and guidance from the CITY'S Project Manager. 7.1. Right-of-Way Research � The ENGINEER Sh8|| determine [ightS-Of-vv8y, e8SSDlSntS needs for CO0St[UCtiOn of the project. F{SqUi[Sd temporary and permanent S8SSDlSntS will be identified based on available information and recommendations will be made for approval by the CITY. 7.2. Rig ht-Of4W8v/EaSennSnt Preparation and Submittal. � The ENGINEER Sh8|| prepare documents to be used to obtain 8 right-of-way instrument and permanent and/or temporary S8SeDlSntS i0StrUDlSntS required to COnSt[UCt the improvements. City of Fort Worth,Texas Attachment pmo Release Date:nr.zz.zu1z Page 11 of 15 . ` . � The documentation shall be provided in conformance with the checklists and templates available on the C|TY's Buzzsavvsite. ASSUMPTIONS • Right-Of-W8y research includes review OfpPOpert«/[ight-Of+m8y records based OD CU[[eDt iDte[Det based Tarrant Appraisal DiShi[t /TAC>) iDfO[Ol@tiOD available at the start of the project and @V8i|@b|e OO-g[OUOd property iOfO[Ol8hOO (i.e. iPOO [OdS' fences, stakes, etc.). It dO8S not include effort for chain of title [eSe8[Ch' parent track reseorch, additional research for easements not included in the TAD. right-of-way takings, easement vacations and @b@OdOOOlentS. right-of-way v@C@tiOOS. and street closures. • Twenty (20) Sidewalk Easement or R()VV Instruments are included in this scope of services. DELIVERABLES A. Twenty (2O) Easement/ROW Instruments TASK 8' SURVEY AND SUBSURFACE UTILITY ENGINEERING SERVICES. ENGINEER will provide survey support as follows. 8.1. Design Survey • ENGINEER will perform field surveys to collect horizontal and vertical elevations and other information needed by ENGINEER in design and preparation of plans for the project. |OfO[0@1iOO gathered during the survey Sh@|| include topographic data, elevations Of all sanitary and adjacent storm sewers, rim/invert elevations, |OC8tiOO Of buried Uh|i1ieS. St[uC1unSS. 1[88S (Ol8@sUre caliper for trees over 8" in diameter at 3 D above ground, and identify overall canopy), and other features relevant to the final plan sheets. Existing d[@iO8g8 81 intersections will be verified by field surveys. • The OliOiOluD1 survey information tOb8 provided OO the plans shall include the following: — A Project CODtnJ| Sheet, showing ALL Control Points, used O[set while gathering d@1@. Generally OO 8 SC@|8 Of not less than 1:400: — The following iDfO0O@1iOn about each COOtnJ| Point; 8. Identified (Existing. CITY Monument#8901, PK Nail, 5/8" |FOO Rod) b. }(, Y and Z COO[diD8t8S, in an identified COOndiD@te systoOl. and @ referred b8@hOg base. Z coordinate OO CITY D@1uD1 only. c. Descriptive Location (Ex. Get in the centerline of the inlet in the South curb |iO8 of North Side Drive 811h8 East end of radius at the Southeast corner Of North Side Drive and North Main Str8eU. — Coordinates OOall P.C.'S, PI's, P.|.'s, Manholes, V@|veS, e1c., in the same coordinate system, aa the Control. City o/Fort Worth,Texas Attachment pMo Release Date:orxu.xo1z Page 1zor1s . . — NO less than two horizontal bench marks, per line Orlocation. — Bearings given on all proposed centerlines, orbaselines. — Station equations relating utilities tO paving, when appropriate. 8.2. T8nnpOn8ry Right Of Entry Preparation and Submittal • Prior to entering property, the ENGINEER shall prepare and provide a right of entry letter to each property owner within the limit of the survey activities. • The documentation shall be provided in conformance with the checklists and t8nnp|Qt8s available on the CITY'S BUzzsQwsit8. 8.3. Subsurface Utility Engineering Provide Subsurface Utility Engineering (8UE) tO Quality Level C} and CQsdescribed below. The SUE shall b8 performed iO accordance with C|/A8CE38-O2. Quality Level D • Conduct appropriate investigations (8.g.' owner records, COUOty/C|TYr8COrds. p8[SOOQ| int8rVi8ws, visual inspections, 8tC.), to help identify utility owners that may have facilities within the project |innitSOrthQtDl8yb88ff8C18dbyth8project. • Collect applicable records (8.g.' utility owner b8S8 nn8pS, ''8S built" or record d[8wiOgS, permit records, field OOt8S, geographic infO[Dl8tiOO SySt8[D data, O[8| histories, etc.) on the existence and approximate location of existing involved utilities. • Review records for: evidence Or indication Of additional available records; duplicate O[ conflicting information; need for clarification. • Develop SUE plan sheets and transfer information OO all involved utilities b] appropriate design p|8O sheets, electronic files, QOd/O[ other dOCUnn8OtS as required. Exercise prOf8SSiOOQ|judgment to n8SO|v8 conflicting iOfO[Dl8tiOO. For iOfOrnn8tiOO depicted, indicate: utility type and ownership; date of depiction; quality |8v8|(S); end points of any utility data; line StQtUS (8.g, QC1iw8' 8bQndOO8d. out OfS8rviD8)� |iO8 �io8QOdCOOd�OO� Ounnb8rOf �{�nUvbuh8d cables; and '. jointly 8OC8S808O{. Quality Level C (includes tasks as described for Quality Level Q� • Identify surface features, from project topographic data ond from field observations, that are surface appurtenances Of subsurface utilities. • |OC|ud8 SU[V8y and COrn8|QtiOO of aerial or ground-mounted utility facilities in Quality Level Ctasks. • Survey surface features of subsurface utility facilities or SySt8nnS, if such f88tU[8S have not already been surveyed by8 professional surveyor. If previously surveyed, check survey data for accuracy and completeness. • The survey shall also include (in addition to subsurface utility features visible at the ground SUd8C8): determination Of invert elevations Of any manholes and vaults; sketches showing interior dimensions and line connections Ofsuch manholes and vaults; any surface markings denoting subsurface utilities, furnished by utility owners for design purposes. City o,Fort Worth,Texas Attachment A pmo Release Date:or.z3.zo1z Page 1so,10 • Exercise professional judgment to correlate data from different sources, and to resolve conflicting information. • Update (or prepare) plan sheets, electronic files, and/or other documents to reflect the integration of Quality Level D and Quality Level C information. • Recommend follow-up investigations (e.g., additional surveys, consultation with utility owners, etc.) as may be needed to further resolve discrepancies. • Provide Quality Level C to identify overhead utilities on the project and provide the overhead utility information on the SUE plan sheets. ASSUMPTIONS • This scope of Services includes Level "B" SUE (up to 1,600 feet) • Level "D" and "C" SUE will be included as part of topographic survey. • This scope of services includes up to 4 Level "A" SUE potholes up to 8 feet in depth. DELIVERABLES A. Copies of field survey data and notes signed and sealed by a licensed surveyor. B. Drawing of the project layout with dimensions and coordinate list. C. SUE plan drawings sealed by a professional engineer registered in the State of Texas. TASK 9. PERMITTING. ENGINEER will provide permitting support for the CITY to obtain any and all agreements and/or permits normally required for a project of this size and type, as follows. 9.1. Storm Water Pollution Prevention Plan • For projects that disturb an area greater than one (1) acre, ENGINEER will prepare the Storm Water Pollution Prevention Plan (SWPPP) required for the Project for use by the Contractor during construction. ENGINEER will prepare drawings and details for proposed SWPPP improvement that the Contractor must use during construction. Contractor will be responsible for filing the SWPPP with appropriate regulatory agencies. 9.5. Texas Department of Licensing and Regulation (TDLR) • Identify and analyze the requirements of the Texas Architectural Barriers Act, Chapter 68 Texas Administrative Code, and become familiar with the governmental authorities having jurisdiction to approve the design of the Project. • Submit construction documents to the TDLR • Completing all TDLR forms/applications necessary • Obtain the Notice of Substantial Compliance from the TDLR • Request an inspection from TDLR or a TDLR locally approved Registered Accessibility Specialist no later than 30 calendar days after construction substantial completion. Advise the CITY in writing of the results of the inspection. City of Fort Worth,Texas Attachment A PMO Release Date:07.23.2012 Page 14 of 15 * Responding tO agency comments and requests ASSUMPTIONS * No historical or archeological surveys will be performed under this scope of services. DELIVERABLES A. TDLR Submittal for Review and approval TASK 10' ADDITIONAL SERVICES ADDITIONAL SERVICES NOT INCLUDED |W THE EXISTING SCOPE C)FSERVICES Additional Services not included in the existing Scope of Services — CITY and ENGINEER agree that the fO||Ovving services are beyond the Scope Of Services described in the tasks above. HOVVgve[` ENGINEER can provide these services, if n88d8d. upon the C|TY's written request. Any additional 8OlOUnts paid to the ENGINEER as 8 result of any Ol8t8[i8| change to the Scope of the Project shall be agreed upon in writing by both parties before the S8rViC8s are performed. These additional services include the following: • Negotiation Of easements O[ property acquisition. • Services related tO development Of the C|TY's project fin8nCing8nd/O[ bUdyei. • Services related tO disputes over p[8-qUo|ifiCod0n. bid protests, bid rejection and re-bidding Of the contract for construction. • Water and Sanitary Sewer design • Construction management and inspection services • Construction survey staking • P8rfO[[DonC8 of materials testing Or specialty testing services. • Services necessary due tO the default Of the Contractor. • TxDC)T level environmental documentation • Services related tO damages caused by fire, flood, earthquake Or other acts Of God. • Services [8|8t8d tO warranty claims, enforcement and inspection after final COOlp|8tiOn. • Services tO support, prepare, document, bring, defend, O[ assist inlitigation undertaken Or defended by the CITY. • Performance of miscellaneous and supplemental services related to the project os requested by the CITY. • Traffic Signal replacement plans, the scope includes minor signal modification, but does not include plans for 8 full signal replacement. City nr Fort Worth,Texas Attachment A pMo Release Date:or.00.0010 Page 15 n/15 ATTACHMENT COMPENSATION Design Services for Six Points Urban Village Streetscape Improvements City Project No. 02653 I. Compensation A. The ENGINEER shall be compensated a cost plus max fee of $204,190.00 as summarized in Exhibit B-1 — Engineer Invoice and Section IV— Summary of Total Project Fees. The total lump sum fee shall be considered full compensation for the services described in Attachment A, including all labor materials, supplies, and equipment necessary to deliver the services. B. The ENGINEER shall be paid monthly payments as described in Section II - Method of Payment. IL Method of Payment A. Partial payment shall be made to the ENGINEER monthly upon City's approval of an invoice prepared and submitted by the ENGINEER in the format and including content as presented in Exhibit B-1, Progress Reports as required in item 111. of this Attachment B, and Schedule as required in Attachment D to this Agreement. B. The estimated current physical percent complete as required on the invoice shall be calculated from the progress schedule as required in Attachment D to this Standard Agreement and according to the current version of the City of Fort Worth's Schedule Guidance Document. C. The cumulative sum of such monthly partial fee payments shall not exceed the total current project budget including all approved Amendments. D. Each invoice shall be verified as to its accuracy and compliance with the terms of this Agreement by an officer of the ENGINEER. III. Progress Reports A. The ENGINEER shall prepare and submit to the designated representative of the Planning and Development Department monthly progress reports and schedules in the format required by the City. City of Fort Worth,Texas Attachment B PMO Official Release Date:8.09.2012 Page 1 of 3 B-1 ATTACHMENT B COMPENSATION ® Summary of Total Project Fees Firm Primary Responsibility Fee Amount ®/® Prime Consultant Freese and Nichols, Design and lanag�ernent $ Inc.. Proposed S E Sub-Consultants Spooner & Associates Land Surveying $15,100.00 7.4% Multatech Architects & Lighting Design $14,750.00 7.2% Engineers Non-SBE Consultants James Pole Irrigation Irrigation Design $5,000.00 2.4% Lamb-Star Engineering Subsurface Utiil'ity Engineering 9,950.00 4.9% Sterling Illustration Artist Illustrations $1,200000 0.6% TOTAL $204,190.00 1 100% Pr ject Number & Name _ Total Fee SBE Fee SBE 9/® Six Points Urban "Village $204,190.00 $29,650.00 14.6% Streetscape lmproveryients Phase I Freese and Nichols, Inc, will meet or exceed the city's DBE Goal of 14% for this project under the primary contract fort is project. City of Foil Woillk"Texas Attachment ent B Page 2 of 3 S-2 EXHIBIT "B-1 ENGINEER INVOICE (Supplement to Attachment B) Insert required invoice format following this page, including negotiated total budget and allocations of budgets across work types and work phases. City of Fort Worth,Texas Attachment B PMO Official Release Date:8-09.2012 Page 3 of 3 B-3 G> T IA E O US Is E '> � rL E E °v � O m E c 0® n CL 0 >m w 71 7 c e7 0 c E O O °a o B 7 es —C q1 a CL at z fn 03 m ,c Y a E Cs u '„ a) ip aes °a O a CL Q �2 E O a — 0E -U. cu U) 0 c° 0 4) (D as CL > w M n 6L �} E Pfd E f0 cn o B. O 0 EL e CX CO) cn O Eft° fl Vf ,,,,, m E g CL 0 E z O c •°�,m. co � � � as 0 O O uy � E Ea.a O x LL I C Q P Gb C Rib C � I1QI1YY .� C QS P89 7 0 CL bnA p. C w rL E u � m � ffi m � ab F e kY , j F, r �i r� PfA Q � CL � � CL 'n U. ..w w cr a CL t6b ®«� rr 0 cc ATTACHMENT "C" CHANGES AND AMENDMENTS TO STANDARD AGREEMENT Design Services for Six Points Urban Village Street Scape Improvements (Phase 11) City Project No. 02653 <List any changes to the Standard Agreement> City of Fort Worth,Texas Attachment C PMO Release Date:05.19.2010 Page I of I . . Consulting Contract Schedule Specifications fP""RT WORTH City of Fort Worth Capital Improvement Program Attachment D1. CONSULTING SERVICES SCHEDULE DEVELOPMENT: The CONSULTANT shall prepare schedules for consulting services that meet the requirements described in this specification, showing by Critical Path Method ([PM) the planned sequence and timing of the Work associated with the Agreement. All submittals shall be yobonithsd in P[)F format, and acbcdn|c G|cy shall also be aobonMrd in native file format (i.e. file formats associated with the scheduling software). The approved scheduling software ayatcrny for creating the schedule files are: — I`ziruavcza (Version 6.1 or later oz approved byCITY) — Primavera Contractor(Version 6.I or later or approved byCITY) — Microsoft Project /\/craion2UU3/2OU7orlutcroraPProvedbyC1TY\ D2. BASELINE CONSULTING SERVICES SCHEDULE: Following notice-to-proceed, the CONSULTANT shall develop, submit and review the draft detailed baseline consulting services schedule with the CITY to dcrumoatzatc the [DNS0LTANT'a understanding of the Agreement requirements and approach for performing the work. The CONSULTANT will prepare the final detailed baseline consulting services schedule based on CITY comments, if any, and submit to the CITY uo later than the submittal of the first project invoicc. The following guidelines ybaU be adhered to in preparing the baac|iuc schedule, and as described in further detail iu the[ITY'a Schedule Guidance Document. a. The scope shall be subdivided by work breakdown structure (WBS) representing the tasks, yobtaoka, and activities associated with delivering the work. b. The schedule shall accurately describe the major work activities, key milestones, and dependencies/relationships aa appropriate to the work. c. The schedule should include appropriate meetings, review periods, critical decision points,including third party utility dependencies and reviewing agencies. D3. PROGRESS CONSULTING SERVICES SCHEDULE: The CONSULTANT shall prepare and submit monthly to the CITY for approval the updated schedule in accordance with [)l and D2 and the [IT\/'a Schedule Guidance Document inclusive. &y the Work progresses, the CONSULTANT shall enter into the schedule and record actual progress as described in the C1TY'a Schedule Guidance Document. The updated ocbcdnlc aobndtte| abaD also include u concise schedule narrative that highlights the following, if appropriate and applicable: • Changes in the critical path, • Expected schedule changes, • Potential delays, • Opportunities to expedite the schedule, • Coordination issues the CITY should be aware ofor can assist with, City vr Fort Worth,Texas Attachment pwo Release Date:ou-1s.uo11 Page of ......................... ........ ..................... ....... • Oth.erscl!!ieiiij.le-,,i-elate(lisstAesti-i.atti-ie(,.-'()NSL)f,I'AN"l:" ishes to coinmurflcatc to the CITY E)4. PERFORMANCE AND CONSULTING S17RVICES SCHEDULIE: If the work -;L 111 .......... .................. .. . ....... accomplish,ed falls beNrid that scheduled due to factors within the CONSUL'l". ,NT' control, the CONSUL'rANTshall. take such actk)n. as necessary to improve the progress of the Work. In achiition., the c.1'ry nu y require, the CONSU1,TANT to submit a i-e-vised. s(:'hedule demonstrafing the l)roposed plan. to make up the clelay in schedule progress and. to ensure completion of the Work iA(ithin the allot-t: d Agreement time. D5. SCHEDULE TIERS SIPECJAL.INS"FRU(ITIONS: "11"h e requirernerits,for the schedule are determined based an the nature and needs of the project. The schedule fir For this project is stated at the top of this docurnerit. CONSULTANT shall submit each sche(Jule relying on the CITY's current Schedule G Mdance I)ocu ment. Q16. SCHEDULE SUBMFITAL AND PAYMENT: ..........—....................- As stated in 111,A,(0. of the Agreement, CONSULTANT' shall provftle the information required by Attach-merit D. CONSULT ms morithly invoices will not be accepted and proc.essed for payrnerit ivithout montlily schedule updates that are stub mitte-d in the time and manner required by Attachment D and the CI'l'Y's current Schedule Guidance 13ocument. "MV, City of If oirtWorth, IFexas Attachment ID FIMO ROease Da e':02,15.2011 Page 2 of 2 Attachment E Phase H -Six PoMts Urban\Mllage 5treetsca e 4nplrove1°rnents Oty Project No., 02653 �r r r 1 Sidewalk L�Rf}JEGI" Enhancements �y � r , n END Y P'ROJEG'P X11,1 I� , cope 11 01M i 6 n^ip��un'rt�l � ft!='��"I!�mi4„ ✓'pro ti i `� a r m « Project Location Race Street From Sylvania Ave 51 To Oakhurst Scenic Drive � t itv Proiect No. F', o RT WO TH t �r �, �� 1 a% � �..�aw�aa�u�m dmml � w uul �ur�ip u r n �, F�E ESE rill n .. Service 'uJW .i M ai -,.awira�wvwrlrr�w.nrWw rr«h wv r'�u�.owymmx m�ww ,� F OffidN sfte of the coy of 1Y ort Worth,rexas 'MRTH CITY COUNCIL AGENDA FOR] CZZZI'==Z=� COUNCIL AC71014: Approved on 8/18/2015 .......... .­­........................................... ..................___­............. DATE: 8/18/2015 REFERENCE ,..C-27418 LOG NAME: 06S IXPOI NTSUVPHASEI IDES IGN NO.: CODE: C TYPE: CONSENT PUBLIC NO HEARING: SUBJECT: Authorize Execution of an Engineering Services Agreement with Freese and Nichols, Inc., in the Amount of$204,190.00 for the Preparation of Engineering Documents for the Construction of the Six Points Urban Village Phase 11 Improvements Along Race Street from Grace Avenue to Oakhurst Scenic Drive and Along Sylvania Avenue from 150 Feet North of Race Street to the State Highway 121 Frontage Road (2014 BOND PROGRAM) (COUNCIL DISTRICT 9) ............... ................ . ..................... RECOMMENDATION: It is recommended that the City Council authorize the execution of an Engineering Agreement with Freese and Nichols, Inc., in the amount of$204,190.00 for the preparation of engineering documents for the construction of Six Points Urban Village Phase 11 Improvements along Race Street from Grace Avenue to Oakhurst Scenic Drive and along Sylvania Avenue from 150 feet north of Race Street to the State Highway 121 Frontage Road. DISCUSSION: In 2006 (M&C G-15065), the City Council allocated the amount of$1,547,142.00 in federal funds for street improvements in the Six Points and South in urban villages. In 2013 (M&C C-26562), the City Council authorized various actions resulting in transferring the South in portion of federal funds to Six Points in order to de-federalize the South Main Improvement Project. In October 2014 (M&C C-27028), the City Council authorized the execution of an Engineering Services Agreement for the design of complete street improvements on a portion of Race Street in the Six Points Urban Village. On June 2, 2015 (M&C G-18493), the City Council allocated an amount of$2,500,000.00 in 2014 and Program Urban Village Funds to the Six Points Urban Village for complete street improvements in accordance with the 2007 Six Points Urban Village Master Plan and the 2015 Comprehensive Plan and authorized the expansion of the urban village boundary to Oakhurst Scenic Drive. Under the current design phase for Race Street, staff convened four public meetings(September 18, 2014, November 13, 2014, March 12, 2015 and April 27, 2015) on the design of complete street improvements on Race Street between the intersection of Race Street, Belknap Street and Riverside Drive on the east and Grace Avenue on the west. Property owners and stakeholders provided input on the design elements and supported the draft design presented at the April 27, 2015 public meeting. At the April 27, 2015 public meeting, the proposed urban village boundary expansion to Oakhurst Scenic Drive was presented and unanimously endorsed by property owners and stakeholders in attendance. Additionally, a professional design charrette workshop hosted by the Congress for the New Urbanism and led by the Torti Gallas Design Team was held over a four day period in mid-March 2015 to engage property owners and stakeholders in a collaborative design and planning workshop for the Six Points Urban Village and proposed expanded urban village area. The Torti Gallas Design Team recommended urban village improvements including mixed-use, pedestrian-oriented development and complete street improvements within the proposed urban village expanded boundary and received support from property owners and stakeholders attending the charrefte workshop. http://apps.cfwnet.orf,)/council placket/mc—review.asp?ID=21304&councildate=8/18/2015 08/19/2015 In September 2014, the City of Fort Worth enrolled in the AARP Network of Age-Friendly Communities. In December 2014, AARP Texas and the Walkable and Livable Communities Institute conducted an Active Living workshop in the Six Points Urban Village. The workshop report, issued in February 2015, identifies complete street enhancements along Race Street and Sylvania Avenue as high priority for the urban village. Currently, developers are assembling land along Race Street and to the west along Oakhurst Scenic Drive and have secured zoning changes where necessary for mixed-use and urban residential development. During the design phase of the phase 11 improvements, staff will work with the Six Points Urban Village stakeholders in refining the scope of work and creating a complete street design in accordance with the 2007 Six Points Urban Village Master Plan, the 2015 Comprehensive Plan, the design charrette workshop, the AARP report and planned developments. The Six Points Urban Village Phase 11 Streetscape Project estimated project cost is Description of Project of Project Cost Design $204,190.00 Phase ] Construction $1740'0 0 s'ructio' .010 Phase 7 Contingency, Inspection, Survey Staking, $555,810.00 Material Soil and Testing, etc, Total Project Cost $2,500.000-0 Cost !F� Below is the Six Points Phase 11 Streets cape Project estimated schedule: • M&C Approval , 18 August 2015 • Design Phase - September 2015 • Design Complete/Advertise Construction August 2016 • Award Construction Contract November 2016 This project is included in the 2014 Bond Program. Available resources within the General Fund will be used to provide interim financing until debt is issued. Once debt associated with the project is sold, bond proceeds will reimburse the General Fund, in accordance with the statement expressing official Intent to Reimburse that was adopted as part of the ordinance canvassing the bond election (Ordinance No. 21241-05-2014). M/WBE OFFICE .- Freese and Nichols, Inc., is in compliance with the City's Business Diversity Enterprise (BDE) Ordinance by committing 14 percent Small Business Enterprise (SBE) participation on this project. The City's SBE goal on this project is 14 percent, The proposed capital improvements are located in COUNCIL DISTRICT 9 and partially in COUNCIL DISTRICT 8. FISCAL INFORMATION/CERTIFICATION: The Financial Management Services Director certifies that appropriations are included In the Fiscal Year 2015 Adopted Budget of the 2014 Bond Program pursuant to Ordinance No. 21457 09-2014 http://a-pi-)s.cf.'wnet,,om°g/c,o�.iiici( packethnc reviewarS])?11)=213014&councilda,te�= /18/2015 08/19/2015 - and funds are available in the General Fund to pay expenses which will be incurred on the Six Points Urban Village Phase 11 Streetscape Project until reimbursement can occur from the issuance of public securities and subject to receipt of the funds and adoption of the appropriation ordinance, funds will be available os approved, of the 2O14 Bond Program Fund. Available funding ie shown below: Fu]Existing FY Total P ojected Remaining nd 2015 Allotment Encumbrance/ Balance Appropriations Expenditure TO Fund/Account/Centers FROM Fund/Account/Centers C210 531200 069650265330 $204,19U0.00 Submitted for City Manager's Officg_b Fernando Costa (G122) Originating Departme t Head: Randle Harwood (G1O1) Additional Information Contact: Patrina Newton (OOGO) ATTACHMENTS MC Map SPUV Phase 11 Design Phase.pd hUp://uppo.ufWoeturg/oounoii_puokct/mo_rcview.asp?lD-2l3O4&oouooi|da1c=8/|8/2O|5 08/19/2015 e✓1^.°r-"'/,,''°'' .---``—. m f i 1 r / ff )W l' /r j ��j , '"' NJ(V6/Ii rF,/,. // r � lull rrrl/ l�i�i/� °.,�'`*w 'ear r VIN �✓ , r 0/1, r 1 , 14 co �3aIS�3AlJ LU n ry71ryp� ky, Ur m1Y r l i; ii a, irN r r L �a N ww r 1�i ��'%r� �'' � % rl� f { Y �r✓� riei Ifu"r1/, m" ✓Y r 'r '�. .h �.„ ".""" �l "% �/� / If �i �� �l a r o w'M" frr o rp, i� r r ✓��'1Y; f"r )ii � (W% { r % ,,, C „� c, rf li " Jf /i rr r W i,/ e✓%W 'J J I .w4ufl�r 4 r/" !'� IBM, Rk /rr � io o t � �%�," � w ,�.:. ..�,;... .. .�........ ��" .._,,. r J7�'�r; � Nt]N�I� i�r l yJ µ Po � LU Illy 1, " if �Yg� " w 1r✓ Q ,� lip! k !P Poi Il m 4 r / r ll J 1 / qp "NIA �f ' it �, 01, gg LD � � C �i � ,� / lu��,. /1 Iri/�/ �l 0����i;i�� r� i%/Y�� %r ✓.�.'d" w;a°: "'�leP � r ii n�ryy��� � � l ✓ �� W t,, -� .l �/ d�r��/��I r��,�,, E.��� �r � � 1 r,Yr by � /rr ILLf , CL r-- c� CL CL r a r �0 ,